Template-Type: ReDIF-Article 1.0 Author-Name: Simon Rawlinson Author-X-Name-First: Simon Author-X-Name-Last: Rawlinson Author-Name: John Raftery Author-X-Name-First: John Author-X-Name-Last: Raftery Title: Price stability and the business cycle: UK construction bidding patterns 1970-91 Abstract: Problems of competitive pricing and strategic management in the construction industry are discussed. A statistical analysis of tender spread patterns over the period 1970-91 shows that changing market conditions influence levels of risk exposure and in turn affect the establishment of a market-generated 'going rate' for construction. A pattern of increasing stability of pricing is identified during the 1980s, and this pattern is linked to developments in the strategic management of contracting organizations. Despite trenchant criticism of the sealed bid as a method of price determination, the industry's price levels do respond relatively quickly to changed economic conditions. Journal: Construction Management and Economics Pages: 5-18 Issue: 1 Volume: 15 Year: 1997 Keywords: Business Cycles, Bidding, Market Prices, X-DOI: 10.1080/014461997373079 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997373079 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:1:p:5-18 Template-Type: ReDIF-Article 1.0 Author-Name: Zedan Hatush Author-X-Name-First: Zedan Author-X-Name-Last: Hatush Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Criteria for contractor selection Abstract: This paper is concerned with identifying universal criteria for prequalification and bid evaluation, and the means by which different emphases can be accommodated to suit the requirements of clients and projects. The information, assessment and evaluation strategies currently used by procurers for screening contractors are considered, and the results are reported of an extensive literature review and a Delphic interview study with a small select sample of construction professionals with extensive experience in prequalification and bid evaluation processes. The findings indicate that the most common criteria considered by procurers during the prequalification and bid process are those pertaining to financial soundness, technical ability, management capability, and the health and safety performance of contractors. Journal: Construction Management and Economics Pages: 19-38 Issue: 1 Volume: 15 Year: 1997 Keywords: Prequalification, Bid Evaluation, Information, Criteria Assessment, X-DOI: 10.1080/014461997373088 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997373088 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:1:p:19-38 Template-Type: ReDIF-Article 1.0 Author-Name: Eric Wong Author-X-Name-First: Eric Author-X-Name-Last: Wong Author-Name: George Norman Author-X-Name-First: George Author-X-Name-Last: Norman Title: Economic evaluation of materials planning systems for construction Abstract: It has been noted that many problems exist among local construction contractors owing to inefficient materials management. Problems reported include delays in the supply of construction materials, and inappropriate scheduling of materials in construction projects. There is a need for an improved materials planning approach. Efficient planning of materials not only means increased productivity and profit to the company, but also facilitates the completion of construction projects. In view of the variation in size, timing and frequency of material orders, the authors felt that the implementation of a materials planning system (MPS) in construction would produce cost savings similar to those achieved in the manufacturing industry. However, an economic evaluation of a construction MPS would probably involve the treatment of uncertain costs and savings. A practical risk analysis based on converting subjective estimates of timing and magnitude of cash flows to beta distributions was used to illustrate the feasibility of implementing such a system in construction. Journal: Construction Management and Economics Pages: 39-47 Issue: 1 Volume: 15 Year: 1997 Keywords: Construction, Materials Planning, Risk Simulation, X-DOI: 10.1080/014461997373097 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997373097 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:1:p:39-47 Template-Type: ReDIF-Article 1.0 Author-Name: Chun-Li Peng Author-X-Name-First: Chun-Li Author-X-Name-Last: Peng Author-Name: Domenic Scorpio Author-X-Name-First: Domenic Author-X-Name-Last: Scorpio Author-Name: Charles Kibert Author-X-Name-First: Charles Author-X-Name-Last: Kibert Title: Strategies for successful construction and demolition waste recycling operations Abstract: Establishing a successful construction/demolition (C&D) waste recyling operation in the USA is a challenge today, especially because secondary materials markets have not yet matured. Increasingly, municipal solid waste (MSW) landfill operations refuse to accept C&D waste. Skyrocketing tipping fees due to the scarcity of landfill sites, and growing concerns from regulatory agencies and the public, have placed C&D waste recycling operations under intense scrutiny. The experiences of regional C&D recyclers indicate that successful recycling operations require a minimum of 0.8 ha of clear space for processing equipment, incoming waste stockpiles, recycled materials, and manoeuvring room for mobile equipment and operations. Reasonable quality, reliable equipment suitable for these operations generally costs between $300 000 and $750 000 for a 400-500 tonne/day operation. At present, operators of these facilities make a profit almost solely on tipping fees, with the recycling operation functioning mainly to maintain materials throughput. Different categories of C&D recycling machinery and waste processing strategies are presented. Strategies for converting C&D landfills into successful C&D recycling operations are also examined. C&D waste recycling economics are presented to demonstrate the essential ingredients for successful operations. Journal: Construction Management and Economics Pages: 49-58 Issue: 1 Volume: 15 Year: 1997 Keywords: Recycling, Landfill, Machinery, Demolition, Waste, Sustainability, Environmental Impact, X-DOI: 10.1080/014461997373105 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997373105 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:1:p:49-58 Template-Type: ReDIF-Article 1.0 Author-Name: Christopher Preece Author-X-Name-First: Christopher Author-X-Name-Last: Preece Author-Name: Steven Male Author-X-Name-First: Steven Author-X-Name-Last: Male Title: Promotional literature for competitive advantage in UK construction firms Abstract: This paper outlines the findings of an in-depth survey exploring the effective use of promotional brochures and other corporate literature in providing a competitive advantage in the marketing of contractual services in construction. The research project on which this paper is based involved surveys of major client organizations and their professional advisers, i.e. architects, engineers, project managers etc., who provided constructive criticism of the promotional efforts of contracting firms. The research also involved the senior marketing management responsible for promotion in construction firms, and promotional design consultants and agents employed by the industry to produce promotional brochures and other material. The principal findings are that construction firms need to give more attention to the careful targeting of their promotional literature to specific members of the client's team, tailoring material to the particular needs of the client and proposed project, and trimming material so that it concisely communicates a persuasive message concerning the firms' corporate image and the benefits of a clearly differentiated service. The paper presents practical recommendations based on the analysis for the more effective use of brochures and annual reports as part of the promotional strategies in the provision of construction contractual services. Journal: Construction Management and Economics Pages: 59-69 Issue: 1 Volume: 15 Year: 1997 Keywords: Promotion, Marketing, Competitive Advantage, Construction, X-DOI: 10.1080/014461997373114 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997373114 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:1:p:59-69 Template-Type: ReDIF-Article 1.0 Author-Name: Roberto Pietroforte Author-X-Name-First: Roberto Author-X-Name-Last: Pietroforte Title: Communication and governance in the building process Abstract: Through a proposed interpretative framework the relationship between forms of transactional governance and type of information processing and communication media is analysed. Building projects are successfully completed through the development of federative mechanisms, such as cooperation, informal roles and rules, that complement and circumvent the hierarchical and formal provisions of standard contracts. At present there is a dislocation between the pattern of roles and rules advocated by standard contracts and that observed in practice. During the design and engineering process, federative mechanisms are supported by the exchange of qualitative and uncertain information through personal communication media such as group meetings and direct contacts. The focus of new information technologies should be broadened from controlling contractual compliance to facilitating communication and interaction among project participants. Journal: Construction Management and Economics Pages: 71-82 Issue: 1 Volume: 15 Year: 1997 Keywords: Building Process, Transactional Organizations, Contracts, Communication Factors, Information Technology, X-DOI: 10.1080/014461997373123 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997373123 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:1:p:71-82 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Kaming Author-X-Name-First: Peter Author-X-Name-Last: Kaming Author-Name: Paul Olomolaiye Author-X-Name-First: Paul Author-X-Name-Last: Olomolaiye Author-Name: Gary Holt Author-X-Name-First: Gary Author-X-Name-Last: Holt Author-Name: Frank Harris Author-X-Name-First: Frank Author-X-Name-Last: Harris Title: Factors influencing construction time and cost overruns on high-rise projects in Indonesia Abstract: Many variables have an impact upon construction time and cost overruns in Indonesia. A questionnaire survey was undertaken of project managers working on high-rise construction projects in two Indonesian cities: Jakarta and Yogyakarta. The variables identified were ranked according to their perceived importance and frequencies of occurrence. Inflationary increases in material cost, inaccurate material estimating and project complexity are the main causes of cost overruns. The predominant causes of delay are design changes, poor labour productivity and inadequate planning. Using factor analysis techniques, delay and cost overrun variables were grouped into factors, and their relationships analysed. Although Indonesia specific, the results reflect construction management problems common to developing countries. Journal: Construction Management and Economics Pages: 83-94 Issue: 1 Volume: 15 Year: 1997 Keywords: Delays, Cost Overruns, Productivity, High-rise, Indonesia, X-DOI: 10.1080/014461997373132 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997373132 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:1:p:83-94 Template-Type: ReDIF-Article 1.0 Author-Name: Olugboyega Adams Author-X-Name-First: Olugboyega Author-X-Name-Last: Adams Title: Contractor development in Nigeria: perceptions of contractors and professionals Abstract: Foreign construction firms dominate the major projects in most developing countries as a result of deficiencies in indigenous construction capacity. A plethora of measures have been formulated and implemented to promote development of domestic contractors in these countries, but most attempts have achieved little success. This paper, arising from a larger study on management training needs of contractors in Nigeria, describes findings on constraints on indigenous contractors' performance in the Nigerian industry. Contractor-development programmes perceived as relevant and appropriate to improve their performance in the industry are also reported. The views of indigenous contractors and professionals were compared. There was a strong agreement between both groups on the major constraints in the industry and on the measures perceived as most important for the development of Nigerian contractors. Problems emanating from the business environment were generally perceived by both groups as the most severe constraints. Contractor-development programmes, perceived as very important by both groups, are also the measures required to ameliorate the most important constraints identified: obtaining interim payments, uncertainties in supplies and prices of materials, inadequate access to capital, plant and equipment. Contractor development is inevitably an integral part of a construction industry development programme, given the nature of constraints and development needs emphasized by both groups. The focus therefore should be on establishing a comprehensive programme for the development of the construction industry. More attention should be placed on contractor training to promote management development of trained construction professionals, now emerging as the new crop of construction entrepreneurs. Journal: Construction Management and Economics Pages: 95-108 Issue: 1 Volume: 15 Year: 1997 Keywords: Contractor Development, Developing Countries, Nigeria, Smes, Industry Development, X-DOI: 10.1080/014461997373141 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997373141 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:1:p:95-108 Template-Type: ReDIF-Article 1.0 Author-Name: Kwong Wing Chau Author-X-Name-First: Kwong Wing Author-X-Name-Last: Chau Title: Monte Carlo simulation of construction costs using subjective data: response Abstract: This communication is a response to the insightful note by Fellows on previous papers by the author. Not only has Fellows supplemented Chau's major arguments, he has also expanded the scope of discussion and raised new issues. While the author agrees with most of the points made by Fellows, there are concepts and arguments that need to be clarified. This note is a response to certain issues raised by Fellows. It also clarifies certain concepts and gives alternative viewpoints. Most of these viewpoints complement rather than contradict those given by Fellows. It is hoped that this note will arouse readers' interest in the subject as well as contribute to the academic debate of the issue. The sequence of the discussion follows that in Fellows' note. Journal: Construction Management and Economics Pages: 109-115 Issue: 1 Volume: 15 Year: 1997 Keywords: Construction Cost Distribution, Monte Carlo Simulation, Probabilistic Cost Estimate, X-DOI: 10.1080/014461997373150 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997373150 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:1:p:109-115 Template-Type: ReDIF-Article 1.0 Author-Name: David Seymour Author-X-Name-First: David Author-X-Name-Last: Seymour Author-Name: Darryll Crook Author-X-Name-First: Darryll Author-X-Name-Last: Crook Author-Name: John Rooke Author-X-Name-First: John Author-X-Name-Last: Rooke Title: The role of theory in construction management: a call for debate Abstract: We raise a number of questions concerning the theoretical basis of construction management, and enquire into the nature of construction management theory. We highlight the dominant research paradigm in construction management, and call for attention to be paid to alternative research paradigms. We call for a scholarly debate to investigate these issues. Journal: Construction Management and Economics Pages: 117-119 Issue: 1 Volume: 15 Year: 1997 Keywords: Management Theory, Management Research, Research Paradigms, Interpretive Paradigms, Rationalist Paradigm, X-DOI: 10.1080/014461997373169 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997373169 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:1:p:117-119 Template-Type: ReDIF-Article 1.0 Author-Name: Zedan Hatush Author-X-Name-First: Zedan Author-X-Name-Last: Hatush Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Evaluating contractor prequalification data: selection criteria and project success factors Abstract: A Delphic study investigating the perceived relationship between 20 contractor selection criteria (CSC) currently in use and project success factors (PSFs) in terms of time, cost and quality is described involving a sample of eight experienced construction personnel, including two validators. A consensus of the likely impact of each criterion on time, cost and quality is established in terms of pessimistic, average and optimistic values, which are then converted into expected means and variances via the PERT approach. The ten most and ten least important CSCs are identified and examined for differences and similarities between PSFs. The results show that past failures, financial status, financial stability, credit ratings, experience, ability, management personnel and management knowledge are perceived to be the dominant CSCs affecting all three PSFs, with safety criteria (safety, experience modification rate, OSHA incidence rate, management safety accountability) and the length of time in business being perceived to have the least effect overall. Some CSCs, such as past performance, bank arrangements, project management organization, plant and equipment were perceived to affect only one or two PSFs. Journal: Construction Management and Economics Pages: 129-147 Issue: 2 Volume: 15 Year: 1997 Keywords: Prequalification, selection criteria, project success factors, Delphic study, X-DOI: 10.1080/01446199700000002 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446199700000002 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:2:p:129-147 Template-Type: ReDIF-Article 1.0 Author-Name: Derek Walker Author-X-Name-First: Derek Author-X-Name-Last: Walker Title: Choosing an appropriate research methodology Abstract: The choice of research methodology is a difficult step in the research process. By way of a case study, the approach adopted in one PhD study is explored. The research project involved a detailed study of 33 building projects constructed in Melbourne during the period 1987 to 1993. The principal research objective was to understand better why some buildings are constructed faster than others, by identifying risk factors and how construction managers respond to them. Multiple regression analysis was used to derive a model that predicts construction time from a representative sample of projects. The performance model was then used to compare predicted with actual construction project duration to develop a construction time performance index. This performance ratio was then used to compare 102 variable factors by testing the null hypothesis that each variable does not affect construction time performance (at the 95% confidence level). Correlation analysis of all identified variables was also undertaken to link associations between factors for those affecting and not affecting construction time performance. The contribution of this paper is to identify one research approach for a specific research problem within the construction discipline so that others may be aware of this when making a choice of methodologies for pursuing their own research work. Journal: Construction Management and Economics Pages: 149-159 Issue: 2 Volume: 15 Year: 1997 Keywords: Research methodology, case study, X-DOI: 10.1080/01446199700000003 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446199700000003 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:2:p:149-159 Template-Type: ReDIF-Article 1.0 Author-Name: C. K. Mok Author-X-Name-First: C. K. Author-X-Name-Last: Mok Author-Name: V.M. Rao Tummala Author-X-Name-First: V.M. Rao Author-X-Name-Last: Tummala Author-Name: H. M. Leung Author-X-Name-First: H. M. Author-X-Name-Last: Leung Title: Practices, barriers and benefits of risk management process in building services cost estimation Abstract: The preparation of cost estimates for construction projects is not an easy job, because construction projects are subject to risks and uncertainties, particularly at the inception stage, when very limited information about the project is available. However, the cost estimates prepared at this stage are usually the most important to the client. Nowadays, the costs for building services installations contribute a significant share of the total construction cost of building projects. Thus the accuracy of the building services cost estimates plays an important role in the total building construction project cost estimates. Traditionally, building services cost estimates are prepared by a deterministic single-figure (most likely) approach. This approach is often cost-ineffective and reactionary in nature. The risk management process (RMP) provides a logical consistent framework in identifying the risk factors affecting costs and in making allowances for risks in cost estimation. A survey was conducted to find out the current building services cost estimation practices and to obtain an insight into the understanding, use and application of RMP in preparing building services cost estimates within the building services industry. The results of the survey have suggested that the traditional deterministic cost estimation method is still being adopted by the majority of building services engineers in preparing cost estimates. Also, RMP has not been widely adopted by the building services industry in Hong Kong. From the analysis of building services firms and engineers with regard to the critical success factors for implementation of risk management, the survey reflects that the potential of implementing RMP for building services cost estimation is high. Journal: Construction Management and Economics Pages: 161-175 Issue: 2 Volume: 15 Year: 1997 Keywords: Building services, cost, estimating, risk, uncertainty, X-DOI: 10.1080/01446199700000004 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446199700000004 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:2:p:161-175 Template-Type: ReDIF-Article 1.0 Author-Name: S. L. Tang Author-X-Name-First: S. L. Author-X-Name-Last: Tang Author-Name: H. K. Lee Author-X-Name-First: H. K. Author-X-Name-Last: Lee Author-Name: K. Wong Author-X-Name-First: K. Author-X-Name-Last: Wong Title: Safety cost optimization of building projects in Hong Kong Abstract: A survey was undertaken of the losses or costs incurred in building contracts because of accidents on building sites. Altogether, 576 accidents from 18 building sites were investigated. On each site, an accident occurrence index (AOI) was calculated by dividing the total equivalent day loss by the total man-days required for the project. Using the results of the 18 projects, a relationship was obtained between the site accident costs and the AOI. Similarly, a relationship was found between the safety investment and the AOI. From these two curves, the optimal safety investment on a building site by a contractor could be determined. It was found that the minimum safety investment on a building project is about 0.6% of the contract sum. The above finding was based on accidents in which employees sustain fatal injuries or are absent from work for more than 3 consecutive days through injury. If first-aid-only and non-injury accidents were also considered, the minimum safety investment increased to 0.8% of the contract sum. Journal: Construction Management and Economics Pages: 177-186 Issue: 2 Volume: 15 Year: 1997 Keywords: Safety, accident, cost, site operations, X-DOI: 10.1080/01446199700000005 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446199700000005 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:2:p:177-186 Template-Type: ReDIF-Article 1.0 Author-Name: Ali Shash Author-X-Name-First: Ali Author-X-Name-Last: Shash Author-Name: Mohammed Al-Amir Author-X-Name-First: Mohammed Author-X-Name-Last: Al-Amir Title: Information technology in contractors' firms in Saudi Arabia Abstract: The evolution of the Saudi construction industry correlated with rapid growth in Saudi Arabian oil revenues. Construction companies of all sizes were established during this rapid growth. The extent of computer use in these companies has been surveyed using a structured questionnaire. This reveals that computers are not widely used among contractors. However, all large contractors, 62% of medium-sized contractors and 41% of small contractors use computers mainly for administrative operations, such as accounting and database management. Journal: Construction Management and Economics Pages: 187-200 Issue: 2 Volume: 15 Year: 1997 Keywords: Information technology, computer, Saudi Arabia, contractors, X-DOI: 10.1080/01446199700000006 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446199700000006 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:2:p:187-200 Template-Type: ReDIF-Article 1.0 Author-Name: Philip Leather Author-X-Name-First: Philip Author-X-Name-Last: Leather Author-Name: Susan Rolfe Author-X-Name-First: Susan Author-X-Name-Last: Rolfe Title: Fit for the task: the future of the small scale domestic repair and maintenance industry in the UK Abstract: The poor condition of much of the UK's older housing stock is an important policy issue. Some disrepair arises because owners cannot afford work, because they are not aware of the need for it or because they do not know how to go about organizing it. However, the poor reputation of that sector of the building industry dealing with small scale domestic repair and maintenance is also a deterrent. If anything, the problems of this sector have worsened during the recession as the supply of unskilled 'cowboy' operators has increased. This paper reviews the factors leading to underinvestment and poor quality work in the privately owned housing stock and examines the extent to which the shortcomings of the building industry contribute to this phenomenon. It describes the results of a survey of firms operating in the domestic repair and maintenance sector of the UK building industry, the majority of which were very small. The survey examined the size and composition of firms, their organization and working practices, the types of work they carried out, how they went about obtaining business, the extent to which their work-force was trained and the problems they faced in competing with one another and with the cowboy sector. On the basis of the survey conclusions and discussions with a wide range of organisations representing the industry, consumers, local authorities and government, a series of options for reform are discussed with the aim of stimulating debate on the future of this sector of the construction industry. It is argued that the problems of the UK industry cannot be solved by tighter controls on builders alone, but by a range of measures designed to provide more support and training to reputable builders, measures to exert greater controls over building techniques and safety provision to reduce unfair competition and programmes to educate the consumer to demand better standards and to be willing to pay for them. Ultimately only compulsory measures may succeed in improving standards, but much could be achieved by voluntary licensing or registration schemes backed up by incentives to use qualifying firms such as guarantees. This is more likely to work if backed up for an initial period by government or local authority funding. In the long run, however, the improvements to building quality could save public money. Journal: Construction Management and Economics Pages: 201-212 Issue: 2 Volume: 15 Year: 1997 Keywords: repair, maintenance, industry development, SMEs, training, licensing, X-DOI: 10.1080/01446199700000007 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446199700000007 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:2:p:201-212 Template-Type: ReDIF-Article 1.0 Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Title: Book reviews Abstract: Journal: Construction Management and Economics Pages: 213-215 Issue: 2 Volume: 15 Year: 1997 X-DOI: 10.1080/01446199700000008 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446199700000008 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:2:p:213-215 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Erhan Kozan Author-X-Name-First: Erhan Author-X-Name-Last: Kozan Title: Book reviews Abstract: Journal: Construction Management and Economics Pages: 215-217 Issue: 2 Volume: 15 Year: 1997 X-DOI: 10.1080/01446199700000009 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446199700000009 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:2:p:215-217 Template-Type: ReDIF-Article 1.0 Author-Name: Richard Hill Author-X-Name-First: Richard Author-X-Name-Last: Hill Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Title: Sustainable construction: principles and a framework for attainment Abstract: The evolution of the concept of sustainable development is used as a basis for advancing understanding of sustainable construction. Principles of sustainable construction are developed and divided into four 'pillars' - social, economic, biophysical and technical - with a set of over-arching, process-oriented principles, to be used as a checklist in practice. A multi-stage framework is proposed which requires the application of Environmental Assessment and Environmental Management Systems for construction projects. Journal: Construction Management and Economics Pages: 223-239 Issue: 3 Volume: 15 Year: 1997 Keywords: Sustainable, Development, Environment, Assessment, Management, X-DOI: 10.1080/014461997372971 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372971 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:3:p:223-239 Template-Type: ReDIF-Article 1.0 Author-Name: David Wall Author-X-Name-First: David Author-X-Name-Last: Wall Title: Distributions and correlations in Monte Carlo simulation Abstract: The use of Monte Carlo simulation in construction cost analysis is of interest to construction professionals as part of the risk analysis of construction projects. In recent high profile publications the presentation of Monte Carlo simulation based cost analysis overplays the importance of the choice of which distribution to use to represent input variables and underplays the importance of assessing and including correlations between the variables. The British literature also overplays the suitability of the beta distribution to represent input variables. This paper addresses these issues using a data set comprising elemental rates from 216 office buildings drawn from the BCIS of the RICS. Using a chi-squared test for goodness of fit it is shown that lognormal distributions are superior to beta distributions in representing the data set. Simulation runs of the cost model including and excluding correlations show that correlations must be included in Monte Carlo simulation otherwise the analysis leads to serious misassessment of risk. Simulation results show also that the effect of excluding correlations is more profound than the effect of the choice between lognormal and beta distributions. Journal: Construction Management and Economics Pages: 241-258 Issue: 3 Volume: 15 Year: 1997 Keywords: Monte Carlo Simulation, Distributions, Correlation, Interdependence, Cost Analysis, X-DOI: 10.1080/014461997372980 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372980 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:3:p:241-258 Template-Type: ReDIF-Article 1.0 Author-Name: C. H. Nam Author-X-Name-First: C. H. Author-X-Name-Last: Nam Author-Name: C. B. Tatum Author-X-Name-First: C. B. Author-X-Name-Last: Tatum Title: Leaders and champions for construction innovation Abstract: Based on empirical studies of the role of key individuals in the processes of ten successful innovations in the US construction industry, this paper makes three principal arguments. First, effective leadership is essential for technological innovation - in particular in construction. Second, technological competence is an utmost prerequisite for effective leadership for construction innovation - regardless of the size of the firm. In other words, an entrepreneurial role as a technical champion in a small firm does not change even as the firm grows. Lastly, the role of technical champion can be delegated only with slack resources and adequate power. This paper also highlights conclusions and practical applications to increase technological innovation in design and construction firms. Journal: Construction Management and Economics Pages: 259-270 Issue: 3 Volume: 15 Year: 1997 Keywords: Innovation, Leadership, Technology, Entrepreneurship, X-DOI: 10.1080/014461997372999 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372999 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:3:p:259-270 Template-Type: ReDIF-Article 1.0 Author-Name: Chimay Anumba Author-X-Name-First: Chimay Author-X-Name-Last: Anumba Author-Name: Nosa Evbuomwan Author-X-Name-First: Nosa Author-X-Name-Last: Evbuomwan Title: Concurrent engineering in design-build projects Abstract: The design and build procurement route has witnessed significant growth in the UK construction industry over the last ten years. It is now being used for both private and public sector projects of varying complexity. There are several advantages associated with this method of construction procurement including shortening of lead times, involvement of the contractor in the design process, greater price certainty, improved communication and reduced construction time amongst others. Conversely, there are also a number of disadvantages ascribed to the design and build method of procurement. Some of these include reduced design quality, inhibition of changes by clients, and high tendering costs. A new process model is proposed to address many of the procurement route's present shortcomings. In particular, the model facilitates concurrent project development in the design and build process through the integration of all project participants into a multi-functional matrix team capable of resolving potential 'downstream' problems early in the project life-cycle, and the provision of a formal mechanism for the improved abstraction of client requirements based on design function deployment (DFD)- a concurrent engineering design system. Journal: Construction Management and Economics Pages: 271-281 Issue: 3 Volume: 15 Year: 1997 Keywords: Design And Build, Concurrent Engineering, Process Modelling, Client Requirements, X-DOI: 10.1080/014461997373006 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997373006 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:3:p:271-281 Template-Type: ReDIF-Article 1.0 Author-Name: Jean Jinghan Chen Author-X-Name-First: Jean Jinghan Author-X-Name-Last: Chen Author-Name: David Wills Author-X-Name-First: David Author-X-Name-Last: Wills Title: Development of urban housing policies in China Abstract: Housing in China has proved problematic for many years. Since economic reform started in the 1980s, urbanization has been a token of modernization, and consequently housing provision in urban areas has been a major social and economic issue. The major housing problem in China is the scarcity of supply of housing provision. This paper analyses the initial housing reform prior to 1993, and points out the reasons for the lack of success and the lessons drawn from it. It also studies the present reform programme from 1993, and highlights the problems associated with it. It shows that the housing reforms so far, while having moved away from a complete socialist provision of housing, have gone only a small part of the way to a free market in housing. The reforms have been proved disappointing. Although privatization of housing has been the major objective of housing reforms, the reforms are still focused on the rental sector. On the economics side, the rents are set below costs, and the link between the value that people place on housing and the cost to the country's economy has failed to be appreciated. On the management side, the critical shortcoming of the strategy is its inability to bring an end to the state-owned enterprise's direct obligations for employee housing. Several problems associated with the current reforms have also been identified, especially on the legal side. Journal: Construction Management and Economics Pages: 283-290 Issue: 3 Volume: 15 Year: 1997 Keywords: China, Economic Reform, Urban Housing, Privatization, State-owned Enterprise, X-DOI: 10.1080/014461997373015 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997373015 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:3:p:283-290 Template-Type: ReDIF-Article 1.0 Author-Name: John Raftery Author-X-Name-First: John Author-X-Name-Last: Raftery Author-Name: Denny McGeorge Author-X-Name-First: Denny Author-X-Name-Last: McGeorge Author-Name: Megan Walters Author-X-Name-First: Megan Author-X-Name-Last: Walters Title: Breaking up methodological monopolies: a multi-paradigm approach to construction management research Abstract: A note written in response to: Seymour D. and Rooke, J. (1995). The culture of the industry and the culture research. Construction Management and Economics 13, 511-523. Journal: Construction Management and Economics Pages: 291-297 Issue: 3 Volume: 15 Year: 1997 X-DOI: 10.1080/014461997373024 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997373024 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:3:p:291-297 Template-Type: ReDIF-Article 1.0 Author-Name: Goran Runeson Author-X-Name-First: Goran Author-X-Name-Last: Runeson Title: The role of theory in construction management research: comment Abstract: Seymour et al. claim that positivist research methods are unsuitable for research into construction management. On the contrary, mainstream methodology has been modified to deal with the special demands of such research and conventional research methods have been instrumental in substantial advances in science. Seymour et al.'s argument, ostensibly about research methods, is essentially anti-scientific, and, although it has been around for a long time, there are no positive achievements to suggest that we would benefit from adopting it. Contrary to Seymour et al.'s claims, positivist research methods are our best insurance against bad research. Journal: Construction Management and Economics Pages: 299-302 Issue: 3 Volume: 15 Year: 1997 Keywords: Research Methods, Methodology, X-DOI: 10.1080/014461997373033 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997373033 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:3:p:299-302 Template-Type: ReDIF-Article 1.0 Author-Name: G. Bowles Author-X-Name-First: G. Author-X-Name-Last: Bowles Author-Name: J. S. Dagpunar Author-X-Name-First: J. S. Author-X-Name-Last: Dagpunar Author-Name: H. Gow Author-X-Name-First: H. Author-X-Name-Last: Gow Title: Financial management of planned maintenance for housing associations Abstract: Since the Housing Act 1988, UK housing associations (HAs) have been responsible, with the removal of government grants, for funding all maintenance necessary for the upkeep of new stock over its lifespan. Sinking funds (SFs) have to be created, out of rental income, that are adequate to finance the long term projected maintenance demand. This paper reviews the use of SFs for building asset management with particular reference to the requirements being made of HAs. Current assumptions of what constitutes an adequate level of SF investment by their funding agencies are questioned with an analysis of case study data. Using linear-programming, the benefits of modelling an SF over merely calculating it are demonstrated. The technique is used to formulate SF strategies, some of which admit the possibility of going into deficit in the future, and these are compared with results from conventional SF projections. Finally, the effect that varying element and component lifespans can have on SF projections are investigated by using Monte Carlo methods to simulate profiles of long term maintenance expenditure, and observing how well funds projected with the original SF strategy match them. The results show the importance of reviewing regularly the SF policy in order that it remains relevant to the needs of the stock. Journal: Construction Management and Economics Pages: 315-326 Issue: 4 Volume: 15 Year: 1997 Keywords: Housing Associations, Maintenance, Sinking Funds, Linear Programming, Simulation, X-DOI: 10.1080/014461997372872 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372872 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:4:p:315-326 Template-Type: ReDIF-Article 1.0 Author-Name: Zedan Hatush Author-X-Name-First: Zedan Author-X-Name-Last: Hatush Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Assessment and evaluation of contractor data against client goals using PERT approach Abstract: A methodology for assessing and evaluating contractor data for the purpose of prequalification and bid evaluation is presented. The PERT approach is used to develop a linear model for the assessment of contractor data. The model incorporates a multiple ratings permitting the uncertainty in contractor data to be evaluated. An empirical study investigating the importance of different contractor criteria is described. A lexicographical ordering with aspiration levels and risk analysis with sensitivity methods are used to evaluate and select or rank-order contractors against the main client goals of time, cost, and quality. A literature review is reported regarding client goals and current evaluation strategies. The assumptions, advantages and disadvantages of this work as well as an example are also presented. Journal: Construction Management and Economics Pages: 327-340 Issue: 4 Volume: 15 Year: 1997 Keywords: Prequalification, Bid Evaluation, Pert, Criteria, Client Goals, Contractor, Data, X-DOI: 10.1080/014461997372881 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372881 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:4:p:327-340 Template-Type: ReDIF-Article 1.0 Author-Name: A. Griffith Author-X-Name-First: A. Author-X-Name-Last: Griffith Author-Name: J. D. Headley Author-X-Name-First: J. D. Author-X-Name-Last: Headley Title: Using a weighted score model as an aid to selecting procurement methods for small building works Abstract: This paper focuses on the selection of procurement methods for small building works. While a range of procurement methods is needed to accommodate different types of small works, and procurement methods often are applied across different types, for any particular small works job (or group of jobs), there should be an optimum method of procurement. An optimum method is one that not only considers the characteristics of the small works in themselves, but also considers the impact of the works upon the wider organization and its business operations. In doing so, the small works organization is assisted to deliver an efficient effective service which adds value to the client organization. The client, to be in a position to select the method of procurement that best meets a particular type of works, needs to consider the realistic measure of performance of each of the procurement methods which it could employ. This paper proposes the use of a weighted score model as an aid to selecting procurement methods for small building works. From this paper, client organizations should become more aware of the potential to select, with reliability and consistency over time, the optimum procurement method for a particular type of small works, given those criteria which they identify as being important at the time and in consideration of not only the characteristics of the small works themselves, but the works in the context of the organization's ongoing business. Journal: Construction Management and Economics Pages: 341-348 Issue: 4 Volume: 15 Year: 1997 Keywords: Small Building Works, Procurement Methods, Selection, X-DOI: 10.1080/014461997372890 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372890 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:4:p:341-348 Template-Type: ReDIF-Article 1.0 Author-Name: Anita Punwani Author-X-Name-First: Anita Author-X-Name-Last: Punwani Title: A study of the growth-investment-financing nexus of the major UK construction groups Abstract: This paper compares the relationship between growth, investment and financing of the contracting operations with that of the housebuilding operations in the large, diversified UK construction groups during the 1980s. A graphical presentation of a financial analysis of the contracting and housebuilding divisions' company accounts illustrates significant changes in the levels of capital investment and the sources and uses of finance of these two activities during a period of marked growth in turnover. It is established that the major contractors not only achieved significant growth in their turnover with negligible recourse to additional capital investment but in fact generated surplus funds which could be diverted into other businesses in their respective construction group's portfolio of business activities. It is shown that their 'cash-requiring' speculative housebuilding businesses relied on such intra-group funds as a main source of finance for investment in land during the 1980s. Journal: Construction Management and Economics Pages: 349-361 Issue: 4 Volume: 15 Year: 1997 Keywords: Construction Majors, Growth, Investment, Intra-group Financing, Contracting, Housebuilding, X-DOI: 10.1080/014461997372908 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372908 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:4:p:349-361 Template-Type: ReDIF-Article 1.0 Author-Name: D. Bajaj Author-X-Name-First: D. Author-X-Name-Last: Bajaj Author-Name: J. Oluwoye Author-X-Name-First: J. Author-X-Name-Last: Oluwoye Author-Name: D. Lenard Author-X-Name-First: D. Author-X-Name-Last: Lenard Title: An analysis of contractors' approaches to risk identification in New South Wales, Australia Abstract: This study addresses the process of risk identification at the tendering and estimating stage, which is the first stage of the risk management process, and for the risk management process be of benefit and for the project objectives to be achieved, the risk identification stage should be very detailed and thorough. The aim of this study is to identify, investigate and evaluate the process of risk identification at the tendering and estimating stage for construction contractors in the NSW region. The data for this were collected during the months of December '94 and January '95 using a sample survey of a cross-section of 19 construction contractors, and the results were analysed using frequency distribution. The results show that the most frequently used methods of risk identification are the top-down approach techniques, where the project is analysed from an overall point of view. Techniques based on top-down approach lead to guesswork in terms of contingency for risks accepted by the construction contractors. Bottom-up risk identification techniques are not popular except for a questionnaire and check-list approach. Also, it was unlikely that the contractors would discuss risk allocation with the clients. All the contractors interviewed agreed that when a risk identification process is followed it improves the accuracy of their estimates. Journal: Construction Management and Economics Pages: 363-369 Issue: 4 Volume: 15 Year: 1997 Keywords: Risk Identification, Estimating, Tendering, Contractor, X-DOI: 10.1080/014461997372917 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372917 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:4:p:363-369 Template-Type: ReDIF-Article 1.0 Author-Name: Raymond Tse Author-X-Name-First: Raymond Author-X-Name-Last: Tse Author-Name: Sivaguru Ganesan Author-X-Name-First: Sivaguru Author-X-Name-Last: Ganesan Title: Causal relationship between construction flows and GDP: evidence from Hong Kong Abstract: Granger causality methodology is used to investigate lead-lag relationships between construction activity and aggregate economy. Using data from Hong Kong, the results of this paper suggest strongly that the GDP tends to lead the construction flow not vice versa. Our finding is contrary to the view that construction is more volatile than the GDP. However, our results show that the construction volatility after 1990 is smaller than that in the period 1983-1989, a result that is particularly important for policymakers in that it is the macroeconomic policy of government that affects output, and influences the construction activity, and not vice versa. Journal: Construction Management and Economics Pages: 371-376 Issue: 4 Volume: 15 Year: 1997 Keywords: Unit Root Test, Causality, Hong Kong, X-DOI: 10.1080/014461997372926 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372926 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:4:p:371-376 Template-Type: ReDIF-Article 1.0 Author-Name: Anthony Songer Author-X-Name-First: Anthony Author-X-Name-Last: Songer Author-Name: James Diekmann Author-X-Name-First: James Author-X-Name-Last: Diekmann Author-Name: Roger Pecsok Author-X-Name-First: Roger Author-X-Name-Last: Pecsok Title: Risk analysis for revenue dependent infrastructure projects Abstract: Recent trends in the construction industry indicate continued use of alternative procurement methods such as design-build, construction management, build-operate-transfer, and privatization. Increased use of these evolving methods produces higher levels of uncertainty with respect to long term performance and profitability. The uncertainties inherent in implementing new procurement methods necessitate investigation of enhanced methods of pre-project planning and analysis. This is particularly true for revenue dependent privatization projects such as toll roads. Poor initial performance of toll road projects suggests traditional methods of project analysis are inadequate. Sustaining investor and stakeholder support of privatized revenue dependent projects is dependent upon successful financial performance. Enhanced risk analysis tools provide improved information for pre-project decision making and performance outcome. One such risk analysis method is the Monte Carlo. Monte Carlo methods are especially useful in evaluating which of several uncertain quantities most significantly contributes to the overall risk of the project. This paper demonstrates a Monte Carlo risk assessment methodology for revenue dependent infrastructure projects. Journal: Construction Management and Economics Pages: 377-382 Issue: 4 Volume: 15 Year: 1997 Keywords: Project Finance, Monte Carlo, Privatization, Risk Analysis, Computer, X-DOI: 10.1080/014461997372935 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372935 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:4:p:377-382 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Fenn Author-X-Name-First: Peter Author-X-Name-Last: Fenn Title: Rigour in research and peer review Abstract: This note discusses rigour in research and in the peer review of academic journals by examining current research into construction conflict and disputes. Comments are made on a paper by Alkass, S., Mazerolle, M. and Harris, F.C. (1996) Construction Management and Economics, 14, 375-394. The paucity of research in this field is discussed and the current literature is reviewed. The note concludes that: more work is required in this area; the lack of data is no excuse for subjective theorizing; basic rules of research must be complied with for research to retain its integrity; and the value of peer reviewed journals is reduced by the publication of papers which ignore these points. Journal: Construction Management and Economics Pages: 383-385 Issue: 4 Volume: 15 Year: 1997 Keywords: Conflict, Disputes, Causation, Methodology, Research Rigour, X-DOI: 10.1080/014461997372944 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372944 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:4:p:383-385 Template-Type: ReDIF-Article 1.0 Author-Name: Chau Kwong Wing Author-X-Name-First: Chau Kwong Author-X-Name-Last: Wing Title: The ranking of construction management journals Abstract: The quality of construction management journals is assessed using a questionnaire survey approach. Construction management is broadly defined to include studies of the human aspects of the construction process. Twenty-two journals related to construction management are identified. Questionnaires were sent to potential respondents by e-mail. Respondents were asked to assess the quality of the journals that they are familiar with. Although there is some evidence showing that respondents who are editorial board members or authors of a journal tend to give a slightly higher score to that journal, the relative ranking of the journals is not affected substantially by such tendency. Some statistically significant results on the ranking of the journals are obtained irrespective of the relatively small sample size compared with some surveys of other main stream journals. Journal: Construction Management and Economics Pages: 387-398 Issue: 4 Volume: 15 Year: 1997 Keywords: Attitude Survey, Journals, Academic Discipline, Construction Management, X-DOI: 10.1080/014461997372953 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372953 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:4:p:387-398 Template-Type: ReDIF-Article 1.0 Author-Name: Sunkuk Kim Author-X-Name-First: Sunkuk Author-X-Name-Last: Kim Title: Organization and managerial environment of the Korean construction industry Abstract: In 1983, Korean construction contractors captured over 11% of the overseas market and twenty-five of them were listed in the top 250 international contractors. However, they have struggled against the inefficiency of their organizations, accelerating competition, and the rapid changes in the managerial environment. Although the various features of the environment had required variety in strategy and organization structure, the managers of construction firms have not kept pace with the requirement, but have shown an inability to predict what kind of influence the changes will have on their organizations and what kind of response is proper to the environmental changes they confront. These problems are mainly caused by a lack of understanding of the suitability of their organization's structure and managerial environment. The present research shows that: the functional structure is the archetype of the Korean construction organizations; direction and delegation are the mainstream in corporate management; the critical factors for corporate management are accelerating competition, inconsistent government policy and the pressure of rising costs; and most of the contractors, except the top 5% large-sized firms, have little capability to respond to a new environment. Journal: Construction Management and Economics Pages: 409-419 Issue: 5 Volume: 15 Year: 1997 Keywords: Korean Construction Industry, Organization Structure, Organizational Life Cycle, Managerial Environment, X-DOI: 10.1080/014461997372782 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372782 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:5:p:409-419 Template-Type: ReDIF-Article 1.0 Author-Name: Lu Youjie Author-X-Name-First: Lu Author-X-Name-Last: Youjie Author-Name: Zhang Qiang Author-X-Name-First: Zhang Author-X-Name-Last: Qiang Title: Building economics research in the People's Republic of China: a review Abstract: Research in China into building economics is currently focused on the transition from a centrally planned economy to a market economy. Particular attention is being paid to the theoretical and practical issues arising from the economic reforms. Outside China, there is little known about the various organizations and individuals involved in this field. Their work is funded through the Ministry of Construction and the China National Science Foundation. It is difficult to get commercial sponsorship for this kind of research. Research has focused upon such issues as the role of the construction industry in the national economy, the use of competitive tendering, price formation, urban housing, structuring of the industry and of firms, project management, expert systems and management information systems. There have been some notable successes in terms of building economics researchers influencing the way in which the construction industry is dealt with in China. Future research will be aimed at converting state enterprises to true companies and devising the means to deregulate the pricing of built facilities and construction services without disrupting the market. Journal: Construction Management and Economics Pages: 421-428 Issue: 5 Volume: 15 Year: 1997 Keywords: China, Economic Reform, Research Funding, Development, X-DOI: 10.1080/014461997372791 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372791 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:5:p:421-428 Template-Type: ReDIF-Article 1.0 Author-Name: Ronie Navon Author-X-Name-First: Ronie Author-X-Name-Last: Navon Author-Name: Hillel Arkin Author-X-Name-First: Hillel Author-X-Name-Last: Arkin Author-Name: Isaac Burg Author-X-Name-First: Isaac Author-X-Name-Last: Burg Title: Economic evaluation of HVAC systems with ice storage designed using an optimization technique Abstract: Thermal energy storage (TES) is recognized as an important technique for energy management in heating, ventilation and air conditioning (HVAC) systems. This paper discusses the economic aspects of the optimal design for such systems. The model for optimal design so determines the sizes of the main components of the system - namely the chiller and the storage tank - that the system's life cycle cost is minimal. The model is based on linear programming and is implemented in a computer program for HVAC systems with ice storage. This paper demonstrates that the optimal sizes of chiller and storage tanks differ from those selected using traditional techniques. It emphasizes the cost-effectiveness of the optimally designed system and also includes a sensitivity analysis pertaining to the economic feasibility of such systems under different economic conditions. Journal: Construction Management and Economics Pages: 429-439 Issue: 5 Volume: 15 Year: 1997 Keywords: Economic Analysis, Hvac Systems, Ice Storage, Design, Optimization, X-DOI: 10.1080/014461997372809 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372809 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:5:p:429-439 Template-Type: ReDIF-Article 1.0 Author-Name: Richard Barkham Author-X-Name-First: Richard Author-X-Name-Last: Barkham Title: The financial structure and ethos of property companies: an empirical analysis Abstract: Property companies are a key group in the economy of the built environment. The entrepreneurs that run property companies are responsible for initiating development projects and managing them. The risk incurred by participants in the development process, such as banks and construction firms, is related not only to the risk of the project being undertaken but also to the financial risk associated with the property company that initiates and manages the project. This paper attempts to develop a taxonomy of property companies, for consideration by decision makers in the construction industry in assessing the risk of being involved in a project. Journal: Construction Management and Economics Pages: 441-456 Issue: 5 Volume: 15 Year: 1997 Keywords: Property, Trading, Investment, Development, Gearing, Bank, Contractor, Cycle, X-DOI: 10.1080/014461997372818 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372818 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:5:p:441-456 Template-Type: ReDIF-Article 1.0 Author-Name: Irtishad Ahmad Author-X-Name-First: Irtishad Author-X-Name-Last: Ahmad Author-Name: Maung Sein Author-X-Name-First: Maung Author-X-Name-Last: Sein Title: Construction project teams for TQM: a factor-element impact model Abstract: The factor-element impact model is a normative, theory-based contingency model. It is concerned with identifying the factors that affect the success of total quality management (TQM) initiatives in construction projects. This model is based upon organizational theory, utilizing an interactionist view of organizational design. If TQM is to succeed, construction project teams should be formed with its implementation in mind. The most important factors influencing the success of particular project team configurations are project characteristics. Organizational characteristics of participating firms are also significant. The contingency model developed in this paper involves an iterative approach of designing construction project teams to minimize negative effects on TQM. Guidelines are offered on how to apply the model, and two scenarios are presented to illustrate its application. Journal: Construction Management and Economics Pages: 457-467 Issue: 5 Volume: 15 Year: 1997 Keywords: Project Team, Organization Theory, Total Quality Management Tqm, Normative Models, X-DOI: 10.1080/014461997372827 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372827 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:5:p:457-467 Template-Type: ReDIF-Article 1.0 Author-Name: Derek Drew Author-X-Name-First: Derek Author-X-Name-Last: Drew Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: The effect of contract type and size on competitiveness in bidding Abstract: Multiple regression is used to construct a prediction equation relating bidder competitiveness (the dependent variable) to the independent variables of bidder, contract type and contract size. The regression model shows that differences in contractor competitiveness are greater for different contract sizes than for different contract types. The most competitive contractors appear to be those with a preferred contract size range. Such a model can be used as part of a more systematic approach in prequalifying contractors. It may also be used by contractors as a basis for assessing bidding performance. Journal: Construction Management and Economics Pages: 469-489 Issue: 5 Volume: 15 Year: 1997 Keywords: Competitiveness, Bidding, Regression Analysis, Contract, Contractor Selection, X-DOI: 10.1080/014461997372836 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372836 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:5:p:469-489 Template-Type: ReDIF-Article 1.0 Author-Name: J. Rooke Author-X-Name-First: J. Author-X-Name-Last: Rooke Author-Name: D. Seymour Author-X-Name-First: D. Author-X-Name-Last: Seymour Author-Name: D. Crook Author-X-Name-First: D. Author-X-Name-Last: Crook Title: Preserving methodological consistency: a reply to Raftery, McGeorge and Walters Abstract: Raftery, J., McGeorge, D. and Walters, M. (1977) Construction Management and Economics, 15(3), 291-297, criticise Seymour, D.E. and Rooke, J.A. (1995) Construction Management and Economics 13(6), 511-523 for setting out battle lines in their use of the terms rationalist and interpretive paradigms and argue that such dichotomies lead to a degeneration in research standards. Sharing their concern for research standards, in reply, we argue that Raftery et al.'s plea for methodological liberalism will itself undermine standards. Different research methods are required for different research purposes and are to be evaluated according to different criteria. These criteria must be made explicit. We state our own research purposes and make an initial attempt to set out some criteria against which we would wish our own research to be judged. Journal: Construction Management and Economics Pages: 491-494 Issue: 5 Volume: 15 Year: 1997 Keywords: Research Methodology, Research Paradigms, Methodological Debate, X-DOI: 10.1080/014461997372845 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372845 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:5:p:491-494 Template-Type: ReDIF-Article 1.0 Author-Name: Anthony Lavers Author-X-Name-First: Anthony Author-X-Name-Last: Lavers Title: Guest Editorial: Special Issue on Law and Dispute Resolution in Construction Abstract: Journal: Construction Management and Economics Pages: 501-504 Issue: 6 Volume: 15 Year: 1997 X-DOI: 10.1080/014461997372692 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372692 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:6:p:501-504 Template-Type: ReDIF-Article 1.0 Author-Name: Thomas Stipanowich Author-X-Name-First: Thomas Author-X-Name-Last: Stipanowich Title: At the cutting edge: conflict avoidance and resolution in the US construction industry Abstract: The American Arbitration Association (AAA) has undertaken a number of reforms to the dispute resolution process, engendered by the 'quiet revolution' of alternative dispute resolution (ADR) and its impact upon traditional arbitration mechanisms. This paper appraises the procedural changes which relate to the three distinct schemes: Fast Track Rules, Regular Track Rules, and Large Complex Case Rules; it also looks at parallel progress in mediation and partnering. The author concludes that the US construction industry has undergone, and continues to undergo, a transition from private adjudication, such as arbitration, through the 'settlement-oriented interventions' of ADR to more comprehensive approaches, as exemplified by partnering. Journal: Construction Management and Economics Pages: 505-512 Issue: 6 Volume: 15 Year: 1997 Keywords: Dispute Resolution, Adr, Arbitration, Us Construction Industry, Aaa Rules, Partnering, X-DOI: 10.1080/014461997372700 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372700 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:6:p:505-512 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Fenn Author-X-Name-First: Peter Author-X-Name-Last: Fenn Author-Name: David Lowe Author-X-Name-First: David Author-X-Name-Last: Lowe Author-Name: Christopher Speck Author-X-Name-First: Christopher Author-X-Name-Last: Speck Title: Conflict and dispute in construction Abstract: 'Conflict' and 'dispute' are two distinct notions. The conceptual difference between the two is explored and further reviewed through the literature on conflict and dispute in the field of construction; a taxonomy for future study is also introduced. Conflict, it is proposed, exists wherever there is incompatibility of interest, and therefore is pandemic. Conflict can be managed, possibly to the extent of preventing a dispute resulting from the conflict. Dispute is associated with distinct justiciable issues. Disputes require resolution. This means that they can be managed: the process of dispute resolution lends itself to third party intervention. The construction industry and the chemical process industry in the UK are compared, through perceptions and experiences of conflict and disputes arising from their two sets of standard contract forms. The methodology is a review of published cases and a survey conducted among professionals with experience. The paucity of research in this field is discussed and the empirical work on the causes of conflict and dispute is reviewed. It is concluded that effective management of conflicts and disputes would be furthered by separating the two fields, and particularly by applying a more stringent structuring. Journal: Construction Management and Economics Pages: 513-518 Issue: 6 Volume: 15 Year: 1997 Keywords: Conflict, Construction, Chemical Industry, Dispute, Standard Contracts, Taxonomy, X-DOI: 10.1080/014461997372719 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372719 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:6:p:513-518 Template-Type: ReDIF-Article 1.0 Author-Name: Penny Brooker Author-X-Name-First: Penny Author-X-Name-Last: Brooker Author-Name: Anthony Lavers Author-X-Name-First: Anthony Author-X-Name-Last: Lavers Title: Perceptions of alternative dispute resolution as constraints upon its use in the UK construction industry Abstract: Attitudes to alternative dispute resolution (ADR) among contractors and subcontractors/specialists in the UK construction industry are analysed on the basis of an extensive survey. Positive attitudes contrasted ADR with litigation and arbitration in terms of cost, delay and damage to working relationships through confrontation. The study also examined negative perceptions of ADR which may reduce its appeal and explain its limited use to date. These include a fear that lawyers may 'colonize' ADR and that its non-binding quality may prove a deficiency. It is concluded that these perceptions will be influential in determining the extent to which ADR is used in construction disputes. Journal: Construction Management and Economics Pages: 519-526 Issue: 6 Volume: 15 Year: 1997 Keywords: Adr, Alternative Dispute Resolution, Arbitration, Construction Disputes, Dispute Resolution, Litigation, Resolution, X-DOI: 10.1080/014461997372728 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372728 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:6:p:519-526 Template-Type: ReDIF-Article 1.0 Author-Name: P. Kennedy Author-X-Name-First: P. Author-X-Name-Last: Kennedy Author-Name: A. Morrison Author-X-Name-First: A. Author-X-Name-Last: Morrison Author-Name: D. O. Milne Author-X-Name-First: D. O. Author-X-Name-Last: Milne Title: Resolution of disputes arising from set-off clauses between main contractors and subcontractors Abstract: Set-off relates to the situation where a main contractor raises a counterclaim against a subcontractor's claim or where an employer raises a counterclaim against the main contractor. The alternative terms cross claim, counterclaim, contra charge, compensation and retention are explained in the context of Scots law. Set-off in the construction industry in Scotland is then discussed within the contractual frameworks upon which main contractors are entitled to exercise such rights and how these conditions of contract have been formed over recent years. A study reported shows the extent of the use of amended and unamended forms of subcontract and main contractors' own forms of subcontract which imposed more onerous set-off conditions than the standard forms, the reasons given by main contractors for exercising their rights of set-off, the level of satisfaction amongst subcontractors with the sums set-off against them, the means by which main contractors and subcontractors settled disputed set-offs, and subcontractors' reasons for accepting unsatisfactory instances of set-off. The research was undertaken using a questionnaire to a stratified sample of subcontractors throughout central Scotland in 1995. Forty-seven subcontractors responded to the questionnaire and 427 instances of set-off were recorded. The study indicated that, despite the considerable protection given to subcontractors in the standard forms of subcontract and in common law, they were prepared to settle set-offs with which they were dissatisfied without initiating contractual proceedings which would have improved their situation. It would appear from this study that subcontractors are reluctant to use their contractual entitlements either because of fears over the costs of disputing set-offs or because they fear that they will be denied opportunities to tender for work in the future. Until there is a culture shift in the industry, reliance on contractual conditions alone may be inadequate to meet the needs of subcontractors. Journal: Construction Management and Economics Pages: 527-537 Issue: 6 Volume: 15 Year: 1997 Keywords: Adjudication, Conflict, Counterclaim, Set-off, Subcontractors, Disputes, X-DOI: 10.1080/014461997372737 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372737 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:6:p:527-537 Template-Type: ReDIF-Article 1.0 Author-Name: Edwin Chan Author-X-Name-First: Edwin Author-X-Name-Last: Chan Title: Amicable dispute resolution in the People's Republic of China and its implications for foreign-related construction disputes Abstract: A combined mediation/arbitration process is unique to the People's Republic of China (PRC). This paper looks at how this amicable, out-of-court dispute resolution system works if the dispute is foreign-related, as defined under the Foreign Economic Contract Law. First, it outlines Chinese culture and its relation to the PRC legal framework and also to the amicable dispute resolution system discussed. Second, the system is appraised in the context of the uncertainty of the local judicial system. Third, distinctive features of domestic and foreign-related dispute resolution mechanisms are discussed by comparison with international practice. Finally, the amicable dispute resolution system for resolving construction disputes and its enforcement mechanisms are analysed, with statistical data to explain their implications for foreign investors in the construction industry of the PRC. Journal: Construction Management and Economics Pages: 539-548 Issue: 6 Volume: 15 Year: 1997 Keywords: Adr, Arbitration, Award Enforcement, China, Construction Dispute, Enforcement, Mediation, Foreign Economic Contract Law, People's Republic Of China, Prc, X-DOI: 10.1080/014461997372746 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372746 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:6:p:539-548 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Bick Author-X-Name-First: Paul Author-X-Name-Last: Bick Title: Statutory reform of aspects of construction law in Australia Abstract: Construction contract law in the common law world is largely free of direct statutory intervention. The agenda of calls within the United Kingdom to remedy major defects in construction law is used as a framework in a series of comparisons with recent legislation and practice in Australia, notably in Victoria where a holistic approach to the industry's problems has been adopted with signal success. It is suggested that policy makers in the UK consider what Commonwealth jurisdictions have to offer to the solution of homegrown problems. Journal: Construction Management and Economics Pages: 549-558 Issue: 6 Volume: 15 Year: 1997 Keywords: Australia, Consumer Protection, Construction Law, Housing Grants, Construction And Regeneration Act 1996, Latham, Post-construction Liability, X-DOI: 10.1080/014461997372755 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461997372755 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:15:y:1997:i:6:p:549-558 Template-Type: ReDIF-Article 1.0 Author-Name: Ching-Hwang Wang Author-X-Name-First: Ching-Hwang Author-X-Name-Last: Wang Author-Name: Yu-Chun Huang Author-X-Name-First: Yu-Chun Author-X-Name-Last: Huang Title: Controlling activity interval times in LOB scheduling Abstract: A new scheduling method is presented in this paper which overcomes the inability of the line of balance (LOB) method to control the interval times between adjacent activities in a repetitive construction unit. The interval times are analysed and then expressed as functions of the number of repetitive construction units, the difference between construction times of adjacent activities and the sequence of repetitive construction units. In order to overcome the LOB problem, this paper presents a new scheduling method, the multistage linear scheduling (MLS) method, based on the concept of a multistage decision process. With the MLS method, the project's completion time is smaller or equal to that estimated with the LOB method. The sum of construction times of each activity in all units is the same as that estimated with the LOB method. However, no interval times are generated. The adjacent activities in a repetitive construction unit can progress continuously (not allowed under the LOB method). Therefore, the MLS method can be used to schedule a repetitive project which has necessary practical constraints on the interval times. This results in the retention of construction quality, safety and efficiency. Journal: Construction Management and Economics Pages: 5-16 Issue: 1 Volume: 16 Year: 1998 Keywords: Repetitive Project, Interval Time, Scheduling, Multistage Linear Scheduling, X-DOI: 10.1080/014461998372547 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372547 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:1:p:5-16 Template-Type: ReDIF-Article 1.0 Author-Name: Mohan Kumaraswamy Author-X-Name-First: Mohan Author-X-Name-Last: Kumaraswamy Author-Name: Daniel Chan Author-X-Name-First: Daniel Author-X-Name-Last: Chan Title: Contributors to construction delays Abstract: Projects can be delayed for a large number of reasons. The third phase of an investigation into such factors focused on the causes of construction delays in Hong Kong. A questionnaire was based on 83 factors identified in previous phases of the investigation. Analysis of the responses reveals differences in perceptions of the relative significance of factors between clients, consultants and contractors. There was general agreement about the relative importance of delay factors such as unforeseen ground conditions. Improving productivity is a useful approach to controlling delays. Important factors affecting productivity itself are thus examined in more depth, with a view to enhancing productivity and reducing delays. The conclusions of this phase of the investigation include a ranking of factors and factor categories that are perceived by different groups of project participants to contribute to delays. For example, higher-ranking factors, such as unforeseen ground conditions, and factor categories such as project-related factors, are found to merit special management attention in countering construction delays. The high degree of disagreement as discerned between the groups of clients, consultants and contractors is indicative of their experiences, possible prejudices and lack of effective communication. It is also confirmed that productivity and other non-scope factors such as effective communications should supplement the project scope factors incorporated into the construction time prediction models that were proposed in the previous phases of this investigation. Journal: Construction Management and Economics Pages: 17-29 Issue: 1 Volume: 16 Year: 1998 Keywords: Productivity, Project Management, Delay, Time, Hong Kong, X-DOI: 10.1080/014461998372556 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372556 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:1:p:17-29 Template-Type: ReDIF-Article 1.0 Author-Name: Malik Ranasinghe Author-X-Name-First: Malik Author-X-Name-Last: Ranasinghe Title: Risk management in the insurance industry: insights for the engineering construction industry Abstract: A probabilistic framework is developed to analyse a risk management approach adopted by an insurance firm. The analysis shows that when the insurance firm classifies a client as 'superior' and 'most acceptable', the probability of the insurer having to pay out on those claims is negligible. Even for a policy that is classified as 'acceptable', the highest probability of a claim is only 12%. When the probability of a claim is over 50%, the client is considered to be 'unacceptable' for an insurance policy. Based on that analysis, the insights that the engineering construction industry can gain from risk management in the insurance firm with respect to project duration and cost are highlighted. It is shown that, in responding to risks and uncertainty, the engineering construction industry should not allocate contingency at a predetermined probability of success for global variables such as project cost or duration as suggested in the literature, but at the input level. It is suggested that the predetermined probability of success value to allocate contingency at the input level should be at least 70%. Then, the contingency available for project cost and duration can ensure a high probability of success in the completion of the project. Journal: Construction Management and Economics Pages: 31-39 Issue: 1 Volume: 16 Year: 1998 Keywords: Risk Management, Insurance, Engineering Construction, Target Cost, Contingency, X-DOI: 10.1080/014461998372565 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372565 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:1:p:31-39 Template-Type: ReDIF-Article 1.0 Author-Name: Nashwan Dawood Author-X-Name-First: Nashwan Author-X-Name-Last: Dawood Title: Estimating project and activity duration: a risk management approach using network analysis Abstract: Variations in the durations of activities are commonplace in the construction industry. This is due to the fact that the construction industry is influenced greatly by variations in weather, productivity of labour and plant, and quality of materials. Stochastic network analysis has been used by previous researchers to model variations in activities and produce more effective and reliable project duration estimates. A number of techniques have been developed in previous literature to solve the uncertain nature of networks, these are: PERT (program evaluation and review techniques), PNET (probabilistic network evaluation technique), NRB, (narrow reliability bounds methods) and MCS (Monte Carlo simulation). Although these techniques have proved to be useful in modelling variations in activities, dependence of activity duration is not considered. This can have a severe impact on realistically modelling projects. In this context, the objective of the present research is to develop a methodology that can accurately model activity dependence and realistically predict project duration using a risk management approach. A simulation model has been developed to encapsulate the methodology and run experimental work. In order to achieve this, the following tasks are tackled: identify risk factors that cause activity variations using literature reviews and conducting interviews with contractors; model risk factors and their influence on activity variations through conducting case studies and identifying any dependence between them; develop a computer based simulation model that uses a modified Monte Carlo technique to model activity duration and dependence of risk factors; and run experimental work to validate and verify the model. Journal: Construction Management and Economics Pages: 41-48 Issue: 1 Volume: 16 Year: 1998 Keywords: Network Analysis, Monte Carlo Simulation, Pert, Stochastic Analysis, X-DOI: 10.1080/014461998372574 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372574 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:1:p:41-48 Template-Type: ReDIF-Article 1.0 Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Author-Name: Ivan Fung Author-X-Name-First: Ivan Author-X-Name-Last: Fung Title: Effectiveness of safety management strategies on safety performance in Hong Kong Abstract: This research describes a study of safety attitudes, practices and characteristics of construction firms in Hong Kong and their relationship to safety performance on construction sites. Forty-five construction companies are compared and studied. Each adopts different safety management strategies. The 45 companies were composed of 11 small, 25 medium and 9 large-scale construction firms. Construction firms' safety performance is measured by site casualty rates. Based upon the information collected from the survey, the accident rates are first derived and compared with the industrial norms. Then the following safety measures, and strategies of contractors in Hong Kong and their associated safety performance, are compared: involvement of top management in safety management; safety orientation programmes for new workers; safety awards or incentive schemes; use of post-accident investigation systems; safety training schemes; safety committees; level of subcontracting. The first part of the research studies the relation between these measures and the safety performance using a number of tables. The results show that these practices have indeed improved site safety. The second part uses a multiple regression analysis to study the combined effect of these schemes and practices on safety performance. The study concludes that the provision of safety training, the use of directly employed labour, the use of post-accident investigation as a feedback, and promoting safety practices by safety award campaigns and incentive schemes, are the most effective tool in mitigating site casualties. Journal: Construction Management and Economics Pages: 49-55 Issue: 1 Volume: 16 Year: 1998 Keywords: Safety, Training, Subcontracting, Hong Kong, X-DOI: 10.1080/014461998372583 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372583 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:1:p:49-55 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Brandon Author-X-Name-First: Peter Author-X-Name-Last: Brandon Author-Name: Francisco Loforte Ribeiro Author-X-Name-First: Francisco Loforte Author-X-Name-Last: Ribeiro Title: A knowledge-based system for assessing applications for house renovation grants Abstract: This research is concerned with the development of a knowledge-based expert system for supporting human experts in assessing applications for the house renovation grant system. The development of the system followed the task structure analysis and the client-centred approach. The task structure analysis describes the system at knowledge level in terms of tasks, problem-solving methods and knowledge types. The implementation of the system followed the client-centred approach. The resulting system implements a framework that integrates case-based reasoning, abductive assembly, decomposition and associative methods. In addition, this framework combines different types of knowledge, which are required by the problem-solving methods. The implementation was carried out together with verification and validation, making it possible to have the system more valid after each stage of the client-centred approach. The system has demonstrated that various problem-solving methods are required for performing the different tasks of the assessment of application for the house renovation grant system. Therefore the system has proved to perform as accurately as human experts do for all of the tasks. Journal: Construction Management and Economics Pages: 57-69 Issue: 1 Volume: 16 Year: 1998 Keywords: Case-based Reasoning, Housing, Knowledge-based Expert Systems, X-DOI: 10.1080/014461998372592 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372592 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:1:p:57-69 Template-Type: ReDIF-Article 1.0 Author-Name: Bruce Mcdonald Author-X-Name-First: Bruce Author-X-Name-Last: Mcdonald Author-Name: Mark Smithers Author-X-Name-First: Mark Author-X-Name-Last: Smithers Title: Implementing a waste management plan during the construction phase of a project: a case study Abstract: The construction industry in Australia contributes approximately 15%, by volume, of all solid waste disposed in landfills each year. Similar volumes have been recorded in other countries. The Australian government, in common with many other countries, has legislation in place to reduce landfill requirements by 50% by the year 2000. As part of this programme an Australian division of a multinational construction company has developed a company policy with the aim of managing waste generated on site and, thereby, reducing the amount deposited in landfill sites. The programme has been supported by the Victorian Recycling and Resource Recovery Council. The first implementation of this policy was at the Dandenong Police and Court Complex in Melbourne. The effects of the programme have been compared against a similar project built concurrently. The results of the trial revealed substantial savings. A total volume of 15% less waste was generated on site prior to recycling and 43% less waste went to landfill. Cost savings of 50% were made in terms of waste handling charges. The savings resulted almost entirely from site based strategies for handling waste. Journal: Construction Management and Economics Pages: 71-78 Issue: 1 Volume: 16 Year: 1998 Keywords: Recycling, Waste, Audit, Landfill, X-DOI: 10.1080/014461998372600 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372600 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:1:p:71-78 Template-Type: ReDIF-Article 1.0 Author-Name: David Noyce Author-X-Name-First: David Author-X-Name-Last: Noyce Author-Name: Awad Hanna Author-X-Name-First: Awad Author-X-Name-Last: Hanna Title: Planned and unplanned schedule compression: the impact on labour Abstract: Constructors confronted with the need to compress or accelerate a construction schedule face the potential for extreme difficulties. Unfortunately, a limited knowledge base exists for determining the techniques, methods, or concepts to be employed in mitigating these potential negative outcomes of lower labour productivity rates and higher project costs. This paper explores the impacts of planned and unplanned schedule compression on labour productivity. Additional impacts of schedule compression related to project costs and schedule duration are also evaluated. Telephone interviews and questionnaire surveys primarily were used as the means for data collection to determine which methods of schedule compression identified are most effective in each of the aforementioned areas. Members of the National Electrical Contractors Association (NECA) were used as the data source for this investigation because of their diversified experience and because of the support received from NECA management. A number of schedule compression methods are presented that have been shown to be effective. Journal: Construction Management and Economics Pages: 79-90 Issue: 1 Volume: 16 Year: 1998 Keywords: Planned Schedule Compression, Unplanned Schedule Compression, Schedule Acceleration, Labour, Productivity, Project Costs, Schedule Duration, Electrical Contractor, X-DOI: 10.1080/014461998372619 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372619 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:1:p:79-90 Template-Type: ReDIF-Article 1.0 Author-Name: Ezekiel Chinyio Author-X-Name-First: Ezekiel Author-X-Name-Last: Chinyio Author-Name: Paul Olomolaiye Author-X-Name-First: Paul Author-X-Name-Last: Olomolaiye Author-Name: Simon Kometa Author-X-Name-First: Simon Author-X-Name-Last: Kometa Author-Name: Frank Harris Author-X-Name-First: Frank Author-X-Name-Last: Harris Title: A needs-based methodology for classifying construction clients and selecting contractors Abstract: Clients' needs are inadequately evaluated in project schemes. Without a precise establishment of clients' preferences, the essential criteria for project implementation and especially contractor evaluation cannot be appreciated fully. It is not surprising therefore that subjective decisions have prevailed in tender evaluations and clients' needs have not been satisfied completely. Objective contractor evaluation will be realized only when clients' needs and contractors' capabilities can be quantified and matched reliably. The methodology described herein rests on identifying clients' needs preferences as comprehensively as possible at project inception and progressing to identifying contractors who can satisfy them optimally; relying on 'multidimensional scaling' and 'cluster analysis' techniques. The investigations suggest that clients' project needs are not along the traditional classifications of private, public and developer clients; a reclassification of clients into five needs-based groups is proposed. A new contractor evaluation methodology matching client satisfaction to attainment of established needs in project schemes has been developed for bidding purposes. Journal: Construction Management and Economics Pages: 91-98 Issue: 1 Volume: 16 Year: 1998 Keywords: Classification, Clients, Tender Evaluation, Scaling, Briefing, X-DOI: 10.1080/014461998372628 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372628 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:1:p:91-98 Template-Type: ReDIF-Article 1.0 Author-Name: Chau Kwong Wing Author-X-Name-First: Chau Kwong Author-X-Name-Last: Wing Author-Name: John Raftery Author-X-Name-First: John Author-X-Name-Last: Raftery Author-Name: Anthony Walker Author-X-Name-First: Anthony Author-X-Name-Last: Walker Title: The baby and the bathwater: research methods in construction management Abstract: This note is written in response to Seymour, D., Crook, D. and Rooke, J. (1997) Construction Management and Economics, 15 (1), 117-19. We argue against their narrow focus on the interpretative approach. Also, Seymour et al. are incorrect in implying that the 'rationalist approach' is necessarily quantitative. Our contention is that the choice of research approach in construction management depends on the nature of the problem. However, whatever choice of approach is adopted, it is important that the problem and associated key concepts are defined clearly and that the methods used, underlying assumptions and limitations are transparent and defensible. It is difficult to argue in favour of any single approach based purely on epistemological grounds as what constitutes knowledge is still an unsolved philosophical issue. Since construction management is a practical subject, we suggest that the choice of approach should be a pragmatic one: the approach that is likely to generate practical solutions should be adopted. Seymour et al.'s suggestion serves only to limit our choice of research tools. Furthermore, a lot of the research issues in construction management are practical problems which involve generalization of experience and formulation of hypothesis that can generate empirically testable implications. For problems of this nature, testability of hypothesis and reproducibility of results are important, and the naturalist approach (which is labelled 'rationalist paradigm' in Seymour et al.) of discovering causal relationship is more likely to produce general practical solutions. However, this does not deny the value of the interpretative approach, as it may be more suitable for certain types of problem. Moreover, in practice, an understanding of human behaviour 'from within' often provides useful insights for formulation of empirically testable hypotheses, despite the philosophical incompatibility of the interpretative and naturalist approaches. Journal: Construction Management and Economics Pages: 99-104 Issue: 1 Volume: 16 Year: 1998 Keywords: Epistemology, Interpretative Approach, Research Methods, X-DOI: 10.1080/014461998372637 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372637 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:1:p:99-104 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Edwards Author-X-Name-First: Peter Author-X-Name-Last: Edwards Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Title: Practices, barriers and benefits of risk management process in building services costs estimation: comment Abstract: This note is a comment on Mok, C.K., Rao Tummala, V.M. and Leung, H.M. (1997) Practices, barriers and benefits of risk management process in building services cost estimation, Construction Management and Economics, 15 (2), 161-75, which describes research into the risk perceptions and risk management practices of building services engineers in Hong Kong. The note questions statements made in the paper and parts of the research design and data analyses. Journal: Construction Management and Economics Pages: 105-108 Issue: 1 Volume: 16 Year: 1998 Keywords: Risk, Risk Management, Survey Research, Cost Estimating, X-DOI: 10.1080/014461998372646 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372646 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:1:p:105-108 Template-Type: ReDIF-Article 1.0 Author-Name: David Seymour Author-X-Name-First: David Author-X-Name-Last: Seymour Author-Name: Darryll Crook Author-X-Name-First: Darryll Author-X-Name-Last: Crook Author-Name: John Rooke Author-X-Name-First: John Author-X-Name-Last: Rooke Title: The role of theory in construction management: reply to Runeson Abstract: In his comment on Seymour, D.E., Crook, D.J. and Rooke, J.A. (1997). Construction Management and Economics, 15, 117-19 (Construction Management and Economics, 15, 299-302) argues that positivism provides the best insurance against bad research in construction management studies. He claims that positivist methods of theory building have been modified sufficiently to cope with the demands of management research. He accuses Seymour et al. of being anti-scientific in questioning the viability of these methods. In this short reply, we refute these assertions, pointing out some remaining obstacles to the application of positivist methods to management research. Journal: Construction Management and Economics Pages: 109-112 Issue: 1 Volume: 16 Year: 1998 Keywords: Management Theory, Positivism, Research Paradigms, Research Methodology, X-DOI: 10.1080/014461998372655 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372655 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:1:p:109-112 Template-Type: ReDIF-Article 1.0 Author-Name: Chris Harriss Author-X-Name-First: Chris Author-X-Name-Last: Harriss Title: Why research without theory is not research A reply to Seymour, Crook and Rooke Abstract: Construction management researchers have for too long ignored the centrality of theory to human activity. A simple analogy from everyday life, the quest for a suitable life partner, will demonstrate that all productive action depends on theory if it is to be shared and form a worthwhile addition to the body of knowledge. This analogy provides a useful introduction to the philosophy of science, and a criticism of those who propose a non-scientific approach to construction management research. Journal: Construction Management and Economics Pages: 113-116 Issue: 1 Volume: 16 Year: 1998 Keywords: Philosophy Of Science, Scientific Paradigms, X-DOI: 10.1080/014461998372664 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372664 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:1:p:113-116 Template-Type: ReDIF-Article 1.0 Author-Name: A. Agapiou Author-X-Name-First: A. Author-X-Name-Last: Agapiou Author-Name: L. E. Clausen Author-X-Name-First: L. E. Author-X-Name-Last: Clausen Author-Name: R. Flanagan Author-X-Name-First: R. Author-X-Name-Last: Flanagan Author-Name: G. Norman Author-X-Name-First: G. Author-X-Name-Last: Norman Author-Name: D. Notman Author-X-Name-First: D. Author-X-Name-Last: Notman Title: The role of logistics in the materials flow control process Abstract: Frequently, the supply of building materials to the construction site is fraught with difficulties which can have a significant effect on productivity. Major productivity gains are possible, particularly if the building process is planned from a logistics perspective. The concept of logistics was developed initially within the manufacturing industry, and now constitutes an important management tool to ensure an overall strategic perspective on the flow of materials in the production process. This paper contends that logistics are relevant also to the construction industry, and describes the development of a logistics model to manage the flow of materials from suppliers to installation on-site and its application to a Danish house building project. The case study evidence suggests that the primary focus of the logistics concept in construction is to improve coordination and communication between project participants during the design and construction phases, particularly in the materials flow control process. The logistics concept requires accurate scheduling of materials to programmed delivery dates keyed to actual site layout and storage arrangements. The logistics approach also involves a new role for materials suppliers, including early involvement in the design phase and overall responsibility for the flow of information relating to materials. Journal: Construction Management and Economics Pages: 131-137 Issue: 2 Volume: 16 Year: 1998 Keywords: Logistics, Materials Flow Control, House Building, Denmark, X-DOI: 10.1080/014461998372420 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372420 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:2:p:131-137 Template-Type: ReDIF-Article 1.0 Author-Name: Sabah Alkass Author-X-Name-First: Sabah Author-X-Name-Last: Alkass Author-Name: Mark Mazerolle Author-X-Name-First: Mark Author-X-Name-Last: Mazerolle Author-Name: Frank Harris Author-X-Name-First: Frank Author-X-Name-Last: Harris Title: Rigour in research and peer-review: a reply Abstract: Discussion and constructive criticism of research work when based on facts and sound scientific arguments are good practice which not only enrich research work but potentially improve the findings. For these reasons, they should be encouraged. However, when discussions are put forward out of ignorance for the sake of criticism to attack the integrity of some particular research, and to that matter the integrity of its researchers and the reviewers ability to judge researchers contribution, then it not only becomes dangerous but is on the verge of being irresponsible. This should not go unchallenged. This note addresses the issues brought forth in (Fenn, P. (1997) Construction Management and Economics, 15 (4), 383-385. Journal: Construction Management and Economics Pages: 139-140 Issue: 2 Volume: 16 Year: 1998 Keywords: Research In Delay Analysis, Project Management, X-DOI: 10.1080/014461998372439 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372439 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:2:p:139-140 Template-Type: ReDIF-Article 1.0 Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Title: Sustainable construction: principles and a framework for attainment - comment Abstract: Hill, R.C. and Bowen, P. (1997) Construction Management and Economics, 15, 223-239 discuss the evolution of the concepts of 'environmentalism' and 'sustainability', highlighting their importance in today's context. They relate these concepts, especially the latter, to construction, and provide a framework for environmental management in the construction process. This is a comment on the contents of Hill and Bowen, and endorses their stress on the importance of environmental considerations in the construction process. The paper suggests that other areas relating to the subject of sustainability in construction also require attention, and highlights, in particular, the need to take cognisance of the perspective of developing countries. Journal: Construction Management and Economics Pages: 141-145 Issue: 2 Volume: 16 Year: 1998 Keywords: Sustainable Construction, Management, Developing Countries, Progress, X-DOI: 10.1080/014461998372448 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372448 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:2:p:141-145 Template-Type: ReDIF-Article 1.0 Author-Name: Ching-Hwang Wang Author-X-Name-First: Ching-Hwang Author-X-Name-Last: Wang Author-Name: Yong-Ho Mei Author-X-Name-First: Yong-Ho Author-X-Name-Last: Mei Title: Model for forecasting construction cost indices in Taiwan Abstract: A new approach to the forecasting of construction cost indices in Taiwan is presented. Construction cost indices have always been used to assess the variations in construction labour and material costs. These indices have been traditionally based on historical statistical information in Taiwan. However, the indices fall short in forecasting the future cost trends in the construction industry. By investigating the characteristic data that make up the construction cost indices, the major determining factors were identified as (1) 'the number of difference', (2) the required periods of preceding construction cost indices, (3) the weight associated with each preceding construction cost index, (4) the mean value of the series of construction cost indices that have been converted into a stationary series, and (5) the estimation of the errors between the predicted values of construction cost indices and the observed values of construction cost indices. An analytical model has been established to forecast the present and future construction cost indices based on these factors, and its feasibility tested by using the observed data of the construction cost indices obtained from the Executive Yuan of the Republic of China. The results suggest that this model is reasonably adequate in forecasting the trend values of construction cost indices in Taiwan. Journal: Construction Management and Economics Pages: 147-157 Issue: 2 Volume: 16 Year: 1998 Keywords: Construction Cost Indices, Determining Factors, Forecasting, Modelling, Taiwan, Experience, X-DOI: 10.1080/014461998372457 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372457 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:2:p:147-157 Template-Type: ReDIF-Article 1.0 Author-Name: Akintola Akintoye Author-X-Name-First: Akintola Author-X-Name-Last: Akintoye Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Author-Name: Cliff Hardcastle Author-X-Name-First: Cliff Author-X-Name-Last: Hardcastle Title: Macro-economic leading indicators of construction contract prices Abstract: An understanding of future trends in construction prices is likely to influence the construction investment strategy of a variety of interested parties, ranging from private and public clients to construction contractors, property speculators, financial institutions, and construction professionals. This paper derives leading indicators for construction prices in the United Kingdom. These indicators are based on two experimental methods: turning points of the basic indicators in relation to construction price turning points; and predictive power of lags of the basic indicators. It is concluded, based on the analyses, that unemployment level, construction output, industrial production, and ratio of price to cost indices in manufacturing are consistent leading indicators of construction prices. Building cost index and gross national product constitute coincident indicators. 'Popular' macro-economic time series such as nominal interest rate, inflation rate, real interest rate, all share index and money supply produced inconclusive results. Journal: Construction Management and Economics Pages: 159-175 Issue: 2 Volume: 16 Year: 1998 Keywords: Price, Tender Price Index, Forecasting, Leading Indicator, Time Series, Analysis, Macro-economic, Variables, X-DOI: 10.1080/014461998372466 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372466 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:2:p:159-175 Template-Type: ReDIF-Article 1.0 Author-Name: Mazin Shammas-Toma Author-X-Name-First: Mazin Author-X-Name-Last: Shammas-Toma Author-Name: David Seymour Author-X-Name-First: David Author-X-Name-Last: Seymour Author-Name: Leslie Clark Author-X-Name-First: Leslie Author-X-Name-Last: Clark Title: Obstacles to implementing total quality management in the UK construction industry Abstract: Since at least the Tavistock studies, the need to improve communication and coordination in the construction process has been stressed. This paper reports from a study of 25 construction projects where QA and a number of procedures were in use which might have been expected to bring such improvement. The finding was, however, that coordination was poor. The purpose of the paper is to consider how this finding is to be explained. With reference to the markets/hierarchy theoretical framework, it is proposed that the use of this and other similar frameworks in fact obscures the empirical reality which they are intended to explain. It is accepted that the meta-language which such frameworks supply may enable researchers and those practitioners who choose to use this language to share their interests and concerns. However, the relationship between the abstract and global concepts which feature in such talk and the reality to which they refer needs closer enquiry. This paper proposes that our knowledge of the impact of QA has been compromised by the lack of such attention. The paper then inspects the global proposition that QA has been a step in the right direction towards TQM. With the aim of giving this proposition a stronger empirical referent, six key principles of TQM are used as a benchmark against which to assess the significance of the empirical data drawn from the study. It is proposed that greater attention to such data is necessary to provide a sounder basis for establishing what needs to be done to stimulate change. Journal: Construction Management and Economics Pages: 177-192 Issue: 2 Volume: 16 Year: 1998 Keywords: Lean Construction, Continuous Improvement, Concurrent Engineering, Process Re-engineering, Markets-hierarchies, Contractual Controls, Subcontracting, X-DOI: 10.1080/014461998372475 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372475 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:2:p:177-192 Template-Type: ReDIF-Article 1.0 Author-Name: Graham Winch Author-X-Name-First: Graham Author-X-Name-Last: Winch Author-Name: Aalia Usmani Author-X-Name-First: Aalia Author-X-Name-Last: Usmani Author-Name: Andrew Edkins Author-X-Name-First: Andrew Author-X-Name-Last: Edkins Title: Towards total project quality: a gap analysis approach Abstract: This paper presents a critique of existing approaches to the management of projects and the definition of project success, arguing that these are both fragmented and fail to place the client at the centre of the process. In this critique, the paper focuses on quality management, and places the minimization of client surprise at the heart of the assessment of project success. As an alternative, a gap analysis approach, derived from the service quality management literature, is developed which, it is argued, provides a better way of understanding the challenge of managing projects. The model is then applied empirically to the Glaxo project, the largest building project in the UK in recent years. The Glaxo project was remarkably successful, and the lessons can be learned well through the perspective of the gap analysis model. In conclusion the paper concludes that quality on construction projects is a negotiated order, and that design reviews are the principal means by which this order is negotiated. Journal: Construction Management and Economics Pages: 193-207 Issue: 2 Volume: 16 Year: 1998 Keywords: Project Management, Quality Management, Gap Analysis, Client Satisfaction, Glaxo, X-DOI: 10.1080/014461998372484 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372484 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:2:p:193-207 Template-Type: ReDIF-Article 1.0 Author-Name: Anita Liu Author-X-Name-First: Anita Author-X-Name-Last: Liu Author-Name: Anthony Walker Author-X-Name-First: Anthony Author-X-Name-Last: Walker Title: Evaluation of project outcomes Abstract: The evaluation of the outcome of construction projects has been the subject of unresolved debate for many years. This paper argues that previous views have tried to find a simple solution to a complex problem. The complexities of the issues which underlie the evaluation of project outcomes are derived from project goals, participants' behaviour and the performance of project organizations. Earlier studies did not recognize the manner by which individuals' perceptions of project outcomes were influenced by the range of factors in each person's perception. A model is constructed with two levels of outcome developed from the fundamental behaviour-to-performance-to-outcome (B-P-O) cycle in industrial/organizational psychology. It is postulated that the valence of the first-level outcome (project success) is dependent on the instrumentality relating to the second-level outcome (participant satisfaction). The identification of factors of influence, such as self-efficacy, project complexity, commitment, expectancy, rewards, goals and environmental variables, are shown to be fundamental in understanding an individual's perception of the merit of the outcome of a project. Journal: Construction Management and Economics Pages: 209-219 Issue: 2 Volume: 16 Year: 1998 Keywords: Evaluation, Performance, Outcome, Success, Satisfaction, X-DOI: 10.1080/014461998372493 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372493 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:2:p:209-219 Template-Type: ReDIF-Article 1.0 Author-Name: P. E. D. Love Author-X-Name-First: P. E. D. Author-X-Name-Last: Love Author-Name: M. Skitmore Author-X-Name-First: M. Author-X-Name-Last: Skitmore Author-Name: G. Earl Author-X-Name-First: G. Author-X-Name-Last: Earl Title: Selecting a suitable procurement method for a building project Abstract: Building procurement has become a fashionable term with industry practitioners and researchers. It determines the overall framework and structure of responsibilities and authorities for participants within the building process. It is a key factor contributing to overall client satisfaction and project success. The selection of the most suitable procurement method consequently is critical for both clients and project participants, and is becoming an important and contemporary issue within the building industry. The problem, nevertheless, lies in the fact that there has been limited empirical research in this field of study. Postal questionnaire surveys of 41 clients and 35 consultants were carried out, and were used to obtain experience of and attitudes to a variety of procurement methods and the criteria used for selection. The findings indicate that a simple set of the criteria generally is adequate and sufficient for procurement path selection, and that there is a reasonable consensus on the appropriate weighting for each path. Moreover, it is shown that, contrary to expectations, similar clients generally do not have similar procurement needs. Journal: Construction Management and Economics Pages: 221-233 Issue: 2 Volume: 16 Year: 1998 Keywords: Procurement Selection, Criteria Weighting, Client Needs, Utility Rating, X-DOI: 10.1080/014461998372501 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372501 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:2:p:221-233 Template-Type: ReDIF-Article 1.0 Author-Name: John Burchett Author-X-Name-First: John Author-X-Name-Last: Burchett Author-Name: V.M. Rao Tummala Author-X-Name-First: V.M. Rao Author-X-Name-Last: Tummala Title: The application of the risk management process in capital investment decisions for EHV transmission line projects Abstract: This paper reviews the viability of applying a risk management process to enhance capital investment decisions, when planning the construction of an extra-high voltage (EHV) overhead transmission line project that could be designed and built in the next 10 years by China Light & Power Company Limited, Hong Kong. Different project proposals will be considered for this transmission line as well as different completion dates. Each scenario will be investigated to determine the rate of return and expected cost to customer, using the net present value model. The lowest 'cost to customer' approach would be the normal criterion for project selection, assuming all proposals are technically viable and compatible with Hong Kong Government infrastructure plans. Journal: Construction Management and Economics Pages: 235-244 Issue: 2 Volume: 16 Year: 1998 Keywords: Risk Management Process, Capital Investment Decision, Ehv Transmission, Line, X-DOI: 10.1080/014461998372510 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372510 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:2:p:235-244 Template-Type: ReDIF-Article 1.0 Author-Name: Ching-Hwang Wang Author-X-Name-First: Ching-Hwang Author-X-Name-Last: Wang Author-Name: Mei-Wei Wang Author-X-Name-First: Mei-Wei Author-X-Name-Last: Wang Author-Name: Yu-Chun Huang Author-X-Name-First: Yu-Chun Author-X-Name-Last: Huang Title: Hierarchical indices for measuring the effectiveness of construction automation implementation Abstract: The construction industry in Taiwan is reaching the turning point of industry upgrade and is confronted by such problems as slow productivity growth; increases in labour costs, and awareness of environmental protection requirements. In addition, Taiwan is vigorously preparing to join the World Trade Organization (WTO), and the Agreement on Government Procurement will be signed. Then the market of local public works will be able to be opened. After Taiwan has joined the WTO, local contractors will no longer enjoy special protection, and will compete with foreign contractors on equal grounds. To address these problems, Taiwan is launching the first phase of a construction automation plan (1990-2000), trying to assist local contractors in boosting their global competitiveness through automation. This paper establishes a Taiwanese approach to measuring the overall effectiveness of automation implemented in the construction industry in Taiwan. With this approach, 30%, 71% and 94% increases in commitment aspects and 15%, 20% and 24% increases in benefit aspects have been achieved from 1991 to 1993 (taking 1990 as the base year): significant improvements after the launch of the construction automation plan. The effectiveness of the commitment aspects, however, is far greater than that of the benefit aspects. Journal: Construction Management and Economics Pages: 257-267 Issue: 3 Volume: 16 Year: 1998 Keywords: Construction Automation, Taiwan, World Trade Organization, Effectiveness, X-DOI: 10.1080/014461998372295 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372295 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:3:p:257-267 Template-Type: ReDIF-Article 1.0 Author-Name: Kumaru Yogeswaran Author-X-Name-First: Kumaru Author-X-Name-Last: Yogeswaran Author-Name: Mohan Kumaraswamy Author-X-Name-First: Mohan Author-X-Name-Last: Kumaraswamy Author-Name: Douglas Miller Author-X-Name-First: Douglas Author-X-Name-Last: Miller Title: Claims for extensions of time in civil engineering projects Abstract: This paper focuses on the principles and practices in formulating and assessing claims for extensions of time due to excusable delays. Typical frequency and magnitude profiles of claims for extensions of time are derived from a surveyed sample of 67 civil engineering projects in Hong Kong, and major categories of claims for extensions of time have been identified from the data obtained. Recommendations are made to minimize claims for extensions of time and to achieve more consistent assessments of the unavoidable claims, for example those relating to inclement weather. Journal: Construction Management and Economics Pages: 283-293 Issue: 3 Volume: 16 Year: 1998 Keywords: Time Extension, Delay, Hong Kong, Claims, Civil Engineering, X-DOI: 10.1080/014461998372312 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372312 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:3:p:283-293 Template-Type: ReDIF-Article 1.0 Author-Name: John Raftery Author-X-Name-First: John Author-X-Name-Last: Raftery Title: From Ptolemy to Heisenberg: quantitative models and reality Abstract: An aspect of methodology in research in the field of design economics and cost modelling is described, discussed and evaluated. This review is designed for post-graduate students and built-environment professionals embarking on a PhD in that field. Models, built using methods regarded as 'scientific' at the time, have enabled us to solve specific problems and to learn more about the world. A generalized approach to building and testing symbolic models is outlined. In conclusion, a number of limitations are identified which are inherent in the conventional quantitative modelling approach. Journal: Construction Management and Economics Pages: 295-302 Issue: 3 Volume: 16 Year: 1998 Keywords: Research Methods, Models, X-DOI: 10.1080/014461998372321 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372321 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:3:p:295-302 Template-Type: ReDIF-Article 1.0 Author-Name: Donald Jensen Author-X-Name-First: Donald Author-X-Name-Last: Jensen Author-Name: James Craig Author-X-Name-First: James Author-X-Name-Last: Craig Title: The impact of TAMRA '88 on US construction accounting practices Abstract: This article addresses the accounting process for a long term construction contract and the effect of recent income tax reform on revenue recognition for income tax liability purposes. The Tax Reform Act of 1986 (TRA '86) introduced several significant changes in tax accounting for long term construction projects. Further tax legislation reform was promulgated via the Technical and Miscellaneous Revenue Act of 1988 (TAMRA '88). Prior to the promulgation of these income tax reform acts, a US contractor could use the percentage-completion method for reporting income to creditors and investors, while using the completed-contract method for income tax recognition purposes. After TRA '86 and ending with TAMRA '88 tax legislation, the contractor is now required by law to utilize a 90/10 split for an income recognition schedule if a contract is longer than two years and the contractor has sales of more than $10 million per year. An intent of this article is to create an awareness of these rules and resulting practices, so that international readers may gain a better understanding of any global implications. Journal: Construction Management and Economics Pages: 303-313 Issue: 3 Volume: 16 Year: 1998 Keywords: Percentage-completion Method, Completed-contract Method, Long-term Construction Accounting, Accrual Basis Accounting, Technical And Miscellaneous Revenue Act Of 1988;Tamra '88, X-DOI: 10.1080/014461998372330 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372330 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:3:p:303-313 Template-Type: ReDIF-Article 1.0 Author-Name: Charles Egbu Author-X-Name-First: Charles Author-X-Name-Last: Egbu Author-Name: Barbara Young Author-X-Name-First: Barbara Author-X-Name-Last: Young Author-Name: Victor Torrance Author-X-Name-First: Victor Author-X-Name-Last: Torrance Title: Planning and control processes and techniques for refurbishment management Abstract: Using a case study approach involving four refurbishment projects from both the construction and shipping industries (hospital, warship, hotel and passenger ship), 36 semi-structured interviews with key functionaries from both sectors and 49 completed postal questionnaires, this paper attempts to shed light on the function of planning and control by examining the various systems, methods and techniques associated with refurbishment management in both industries. The conclusion is that there is a substantially longer planning lead time in the ship refurbishment sector than in construction. The state of completion of design before refurbishment work commences is higher in the shipping industry. Site managers from the ship refurbishment sector are brought into the planning and control processes earlier than their counterparts from the construction industry. In both industries, however, schedules and bar charts are the most frequently used formal planning techniques, in comparison with computer based techniques such as PERT, GERT and expert systems; the main reasons being familiarity, the relatively low levels of skill and knowledge needed to understand them as much as their perceived flexibility and relative cheapness for their production and updating. Planning and control involving the management of risks and uncertainty by improving the quality and timing of relevant information for the works, and the timely integration of key functionaries in the refurbishment process, help to improve planning accuracy and effectiveness. Journal: Construction Management and Economics Pages: 315-325 Issue: 3 Volume: 16 Year: 1998 Keywords: Control, Planning, Refurbishment, X-DOI: 10.1080/014461998372349 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372349 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:3:p:315-325 Template-Type: ReDIF-Article 1.0 Author-Name: David Bordoli Author-X-Name-First: David Author-X-Name-Last: Bordoli Author-Name: Andrew Baldwin Author-X-Name-First: Andrew Author-X-Name-Last: Baldwin Title: A methodology for assessing construction project delays Abstract: Different categories of delay and the different types of delay found on construction projects are identified. Existing methods for assessing the effect of delaying events are reviewed and the results of an industry survey presented. None of the commonly recognized methods for delay analysis allow the assessment of three important issues at the same time: the progress of the project at the time the delay occurred; the changing nature of the critical path; and the effects of action taken (or that should have been taken) to minimize potential delays. A new method of delay analysis is presented. This method takes into consideration all these issues, and is a clear, straightforward step-by-step approach to the calculation of the expected delay in the completion of the project as a result of delays in activities encountered during the project. It uses a dynamic model considered by both experts and practitioners to be the best method to take account of progress and form the basis of delay claims. Journal: Construction Management and Economics Pages: 327-337 Issue: 3 Volume: 16 Year: 1998 Keywords: Project Delays, Claims, Delay Analysis, Critical Path Methods, X-DOI: 10.1080/014461998372358 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372358 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:3:p:327-337 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Atkinson Author-X-Name-First: Andrew Author-X-Name-Last: Atkinson Title: Human error in the management of building projects Abstract: This paper seeks to improve the understanding of human error as it is applied to the generation of defects in construction projects. It reviews the literature concerning human error, commencing at the psychological basis of errors. From this, the review is expanded to include literature from forensic engineering, industrial safety, reliability engineering, sociology and quality management. Based on the literature, a model of the factors influencing the incidence of errors in project based industries is constructed. This model proposes that errors leading to defects and more dramatic failures can be generated from all levels of project organizations. They stem from primary factors (related to the performance of the individual), management factors (related to a range of managerial tasks) and global factors (related to wider external influences). These factors can be displayed as a hierarchy with primary factors at the base and global factors at the top. The paper reports on the results of an initial test of this model by reference to a survey of a sample of construction industry practitioners. The findings of the survey support the model, with some modifications. Additionally, some differences in view were noted: in particular, respondents from a construction background emphasized managerial factors more strongly than those from a design background. Journal: Construction Management and Economics Pages: 339-349 Issue: 3 Volume: 16 Year: 1998 Keywords: Human Error, Defects, Project Management, X-DOI: 10.1080/014461998372367 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372367 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:3:p:339-349 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Agapiou Author-X-Name-First: Andrew Author-X-Name-Last: Agapiou Author-Name: Roger Flanagan Author-X-Name-First: Roger Author-X-Name-Last: Flanagan Author-Name: George Norman Author-X-Name-First: George Author-X-Name-Last: Norman Author-Name: David Notman Author-X-Name-First: David Author-X-Name-Last: Notman Title: The changing role of builders merchants in the construction supply chain Abstract: Builders merchants are an integral part of the construction industry, yet rarely are they consulted when discussions take place on the future of the construction industry. Throughout history, builders merchants have played a dominant role in the construction industry, initially as an intermediary between the artisan and the buyer, and more recently as a source of working capital for contracting firms. The merchanting industry currently is undergoing considerable change. The depressed construction market and the failure of the housing repair and maintenance sector to recover in the first half of the 1990's as activity in the private non-housing repair and maintenance sector has increased, has raised competition between merchants. The major building merchants are becoming larger by acquisition and merger, the smaller merchants are seeking niche areas, and the medium-size firms are under serious threat from acquisition by the larger merchanting firms. The trend towards consolidation in the sector, driven by the need to reduce costs, has meant that the large merchanting firms now control around 60% of the building materials market sales. Factoring is a growing trend, particularly with smaller companies sourcing goods from the cheapest source. The larger merchants have to respond by sourcing goods from the lowest cost base, irrespective of whether they buy from overseas markets. This paper analyses the UK builders merchants sector and evaluates the important role played in the supply chain. Journal: Construction Management and Economics Pages: 351-361 Issue: 3 Volume: 16 Year: 1998 Keywords: Building Materials, Builders' Merchants, Components;Imports, X-DOI: 10.1080/014461998372376 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372376 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:3:p:351-361 Template-Type: ReDIF-Article 1.0 Author-Name: William Vidogah Author-X-Name-First: William Author-X-Name-Last: Vidogah Author-Name: Issaka Ndekugri Author-X-Name-First: Issaka Author-X-Name-Last: Ndekugri Title: Improving the management of claims on construction contracts: consultant's perspective Abstract: There is tremendous scope for improving claims management practice. This research comprised a postal questionnaire survey of contractors, project owners' architects, quantity surveyors and engineers, case studies on actual claims situations on projects, and structured interviews with consultants and contractors. Although based mainly on consultants' views although contractors' views are brought in occasionally for corroboration and clarification. The main findings are that: (i) claims management is still performed in an ad hoc manner; (ii) contractors' management information systems are ill designed to support claims; (iii) the products of basic good management practice, such as diaries, timesheets, and programmes, often are inadequate in content even if available; and (iv) some aspects of claims are impossible to quantify with precision even with the best information available at reasonable cost. Main remedial measures suggested include: (a) greater emphasis on the quality of claims management practice and information systems during evaluation of tenders; (b) agreeing figures usually in contention as terms of contracts; (c) implementation of electronic document management systems; and (d) stricter contractual provisions on the quality of programmes, timesheets and content of claims. Journal: Construction Management and Economics Pages: 363-372 Issue: 3 Volume: 16 Year: 1998 Keywords: Claims Management, Contract, Contractor, Disputes, Project, X-DOI: 10.1080/014461998372385 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372385 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:3:p:363-372 Template-Type: ReDIF-Article 1.0 Author-Name: Laurence Marsh Author-X-Name-First: Laurence Author-X-Name-Last: Marsh Author-Name: Eddy Finch Author-X-Name-First: Eddy Author-X-Name-Last: Finch Title: Attitudes towards auto-ID technologies within the UK construction industry Abstract: Automatic identification (auto-ID) technologies such as bar coding have become widespread within manufacturing, medicine and retailing. Bar coding has also attracted many applications within the US construction industry, providing tangible cost savings through improved speed and accuracy of data entry. However, over the past decade the rate of adoption of auto-ID among UK construction firms has been significantly lower than the US. This paper presents the findings of a UK survey of construction organizations, designed to ascertain key factors which attract firms to use auto-ID, the barriers which have prevented some from doing so, and future developments which are perceived as important in encouraging more widespread adoption of the technology within the UK construction supply chain. Key issues identified include a low level of awareness of auto-ID technologies and the absence of appropriate industry standards. Recommendations include the establishment of a standards body and educational initiatives to promote auto-ID solutions. Journal: Construction Management and Economics Pages: 383-388 Issue: 4 Volume: 16 Year: 1998 Keywords: Auto-id, Bar Coding, Barriers, Standards, X-DOI: 10.1080/014461998372169 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372169 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:4:p:383-388 Template-Type: ReDIF-Article 1.0 Author-Name: David Crosthwaite Author-X-Name-First: David Author-X-Name-Last: Crosthwaite Title: The internationalization of British construction companies 1990-96: an empirical analysis Abstract: The internationalization of British construction companies is not a new phenomenon. A recent stated aim of some of the larger companies has been to increase their overseas activities in an attempt to counteract some of the problems within the domestic construction market. This paper examines the international performance of British construction firms during the period 1990-1996, and is based on a questionnaire survey of senior executives of the largest British construction companies in an attempt to analyse their perceptions of the overseas market. The survey was concerned with the companies' general views, reasons, objectives, conditions, location and future expectations with regard to their overseas operations. The principal findings indicate that British firms had increased their overseas activities during the study period. However, despite theory to the contrary and relatively high levels of construction demand in some developing countries, they had tended to conduct the major share of their overseas work in developed countries. The reasons given for this bias were that developed countries provided: a secure environment in which to evaluate risks; financial security; and less corruption. The results suggest further that shareholder influence is an important factor affecting the respondent companies location overseas. It was concluded that while market demand is a factor for overseas location by British construction companies, it is only one of many. Journal: Construction Management and Economics Pages: 389-395 Issue: 4 Volume: 16 Year: 1998 Keywords: Internationalization, British Construction Companies, Location, Perceptions, X-DOI: 10.1080/014461998372178 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372178 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:4:p:389-395 Template-Type: ReDIF-Article 1.0 Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Author-Name: Yaw Debrah Author-X-Name-First: Yaw Author-X-Name-Last: Debrah Title: Flexible management of workers: review of employment practices in the construction industry in Singapore Abstract: The human resource management literature has covered the issues relating to labour market flexibility (LMF), and highlighted a trend in many sectors towards increasing reliance on peripheral workers. Construction has been cited as a model in terms of its ability to exploit the benefits of LMF in its widespread use of peripheral workers as a response to an uncertain operating environment. This paper examines employers' quests for LMF in the construction industry in Singapore, explores the prevailing approaches to labour use in the industry, considers the rationales for the reliance on peripheral workers, and evaluates the merits and disadvantages of this practice. It argues that Singapore's construction firms have always relied on a traditional form of employment based on a labour subcontracting system, but recent years have witnessed changes in the structure of the system as well as an increase in the proportion of foreign workers in the labour force. In addition, it is argued that the conditions for the increasing use of these peripheral workers are different from those suggested to be underlying the quest for 'flexibility' in industrialized countries. The practice is observed to have considerable adverse effects, although firms derive some of the benefits relating to LMF. Possible measures are put forward for improving construction labour use strategies in Singapore. Journal: Construction Management and Economics Pages: 397-408 Issue: 4 Volume: 16 Year: 1998 Keywords: Labour Market Flexibility, Construction Industry, Singapore, Employment Systems, Formalizing, Labour Subcontracting, X-DOI: 10.1080/014461998372187 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372187 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:4:p:397-408 Template-Type: ReDIF-Article 1.0 Author-Name: David Notman Author-X-Name-First: David Author-X-Name-Last: Notman Author-Name: George Norman Author-X-Name-First: George Author-X-Name-Last: Norman Author-Name: Roger Flanagan Author-X-Name-First: Roger Author-X-Name-Last: Flanagan Author-Name: Andrew Agapiou Author-X-Name-First: Andrew Author-X-Name-Last: Agapiou Title: A time-series analysis of UK annual and quarterly construction output data (1955-95) Abstract: United Kingdom construction output makes a vitally important contribution to the gross domestic product of the UK economy. Nevertheless, despite the obvious importance of UK construction, very little is known about the output behaviour of the industry. This paper endeavours to redress the imbalance by analysing the post-war time-series behaviour of annual and quarterly UK construction output. The primary technique of analysis is to estimate an autoregressive integrated moving-average (ARIMA) model of UK construction output. Such a model proxies the stochastic or random process that underlies UK construction output data. Also, a review is given of the methodology of estimation and diagnostic checking of ARIMA models in the context of UK construction output, together with ex-post and ex-ante forecasts of UK construction output using the estimated ARIMA models. Journal: Construction Management and Economics Pages: 409-416 Issue: 4 Volume: 16 Year: 1998 Keywords: Time-series Data, Arima Models, Random Processes, Ex-post, Ex-ante Forecasts, X-DOI: 10.1080/014461998372196 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372196 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:4:p:409-416 Template-Type: ReDIF-Article 1.0 Author-Name: R. K. Gowda Author-X-Name-First: R. K. Author-X-Name-Last: Gowda Author-Name: Amarjit Singh Author-X-Name-First: Amarjit Author-X-Name-Last: Singh Author-Name: Michael Connolly Author-X-Name-First: Michael Author-X-Name-Last: Connolly Title: Holistic enhancement of the production analysis of bituminous paving operations Abstract: The construction and repair of highways are becoming very important in these days of crumbling infrastructure. Costs for these projects have continued to increase. In order for contractors to stay competitive, it is essential that their construction operations be as productive as possible. Money for research usually does not exist for the average contractor. An inexpensive solution for production studies is process simulation, which can help improve the productivity of construction operations. This paper focuses on the paving cycle of a highway resurfacing project, using MicroCyclone simulation software. The process modelling using MicroCyclone is applied readily to any construction cyclic process, and aids the engineer in determining the most economical and efficient way to plan resources for processes. Different production parameters are measured and translated to a utility factor that indicates the performance of the system. Results from the utility factor perspective are considered more sensitive in decision making, owing to the holistic nature of the utility factor. Numerous statistical runs were undertaken, and parameters were weighted and averaged. Based on the holistic analysis, it was possible to establish that 12 trucks were optimal for the system, a determination that cannot be made using deterministic analysis, but that a 7% waste of resources was unavoidable with the existing system of resources. This paper highlights the analytical method of using MicroCyclone output to generate useful information that can be used to compare in detail the performance of different scenarios. Journal: Construction Management and Economics Pages: 417-432 Issue: 4 Volume: 16 Year: 1998 Keywords: Cyclone, Modelling, Process, Simulation, Utility Factor, Productivity, X-DOI: 10.1080/014461998372204 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372204 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:4:p:417-432 Template-Type: ReDIF-Article 1.0 Author-Name: Khaled El-Rayes Author-X-Name-First: Khaled Author-X-Name-Last: El-Rayes Author-Name: Osama Moselhi Author-X-Name-First: Osama Author-X-Name-Last: Moselhi Title: Resource-driven scheduling of repetitive activities Abstract: Repetitive activities are found commonly in the construction of high-rise buildings, pipeline networks and highway and housing projects. Construction crews assigned to these activities often perform the work sequentially, moving from one repetitive unit in the project to the next. Because of this frequent crew movement, construction of repetitive activities should be scheduled in such a way as to enable prompt movement of crews among the repetitive units so as to minimize idle crew time. In order to maximize the efficiency of crew utilization, the schedule of repetitive activities should be resource driven, and should satisfy the crew work continuity constraint in addition to precedence relationships and crew availability constraints. This paper presents a flexible algorithm for resource-driven scheduling of repetitive activities that satisfies the three constraints, and considers the impact of a number of practical factors encountered commonly during the construction of this class of projects. The algorithm is applied in two stages: the first achieves compliance with logical precedence relationships and crew availability constraints, and the second achieves compliance with the crew work continuity constraint. A numerical example of a highway project is analysed to illustrate the use of the algorithm and demonstrate its capabilities. Journal: Construction Management and Economics Pages: 433-446 Issue: 4 Volume: 16 Year: 1998 Keywords: Planning, Scheduling, Repetitive Projects, Crew Work Continuity, Resource-driven Scheduling, X-DOI: 10.1080/014461998372213 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372213 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:4:p:433-446 Template-Type: ReDIF-Article 1.0 Author-Name: Steve McCabe Author-X-Name-First: Steve Author-X-Name-Last: McCabe Author-Name: John Rooke Author-X-Name-First: John Author-X-Name-Last: Rooke Author-Name: David Seymour Author-X-Name-First: David Author-X-Name-Last: Seymour Author-Name: Phil Brown Author-X-Name-First: Phil Author-X-Name-Last: Brown Title: Quality managers, authority and leadership Abstract: Some quality managers in the construction industry are attempting to institute total quality (TQ) management. Having established quality assurance (QA) systems, these managers have realized that the benefits to be gained from this bureaucratic approach are limited. They now aim to transform the culture of the industry, making it less adversarial and more customer centred. Using a sociological analysis based on the forms of legitimation of power identified by Max Weber, the institutional situation of quality managers is examined and their consequent ability to introduce innovation is assessed. Weber suggests that there are three forms of authority: traditional, charismatic and rational. These are considered in the light of some modern organization theory and with reference to the particular problem of cultural change. Managers have the best hope of successfully introducing TQ when they can establish a measure of charismatic authority. This is consis7 tent with the centrality given to the concept of leadership by writers on TQ. The practicalities of this are investigated through an account of the process of setting up a quality circle. Journal: Construction Management and Economics Pages: 447-457 Issue: 4 Volume: 16 Year: 1998 Keywords: Quality Management, Change Management, Culture, Charismatic Authority, Leadership, X-DOI: 10.1080/014461998372222 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372222 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:4:p:447-457 Template-Type: ReDIF-Article 1.0 Author-Name: Assem Al-Hajj Author-X-Name-First: Assem Author-X-Name-Last: Al-Hajj Author-Name: Malcolm Horner Author-X-Name-First: Malcolm Author-X-Name-Last: Horner Title: Modelling the running costs of buildings Abstract: The Building Maintenance Cost Information Service (BMCIS) offers a comprehensive and rigorous framework for collecting data about the running costs of buildings. Nevertheless, it is pitched at such a level of detail that the amount of data collected and analysed may be constrained. This paper describes the deveopment and testing of a novel technique which reduces the amount of data to be collected without any unacceptable reduction in utility. It draws on the principle of cost-significance to create a simple model of maintenance and operating costs (together called running costs) from a rare and consistent set of data for 20 buildings at York University. The model contains only 11 elements, yet can predict the total running costs of each of four categories of building to an accuracy of about 21 2%. It can also predict annual costs to about 7%, despite variations in the periodicity of costs such as painting and insurance. The model was tested using the jacknife method and on virgin data. It proved to be extremely robust, predicting the running costs of 12 new buildings to within 5%. The model offers a simple framework for collecting and analysing reliable and consistent data on running costs. Journal: Construction Management and Economics Pages: 459-470 Issue: 4 Volume: 16 Year: 1998 Keywords: Life Cycle Costs, Maintenance Costs, Operating Costs, Cost-significance, X-DOI: 10.1080/014461998372231 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372231 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:4:p:459-470 Template-Type: ReDIF-Article 1.0 Author-Name: A. H. Boussabaine Author-X-Name-First: A. H. Author-X-Name-Last: Boussabaine Author-Name: A. P. Kaka Author-X-Name-First: A. P. Author-X-Name-Last: Kaka Title: A neural networks approach for cost flow forecasting Abstract: Artificial neural networks, which simulate neuronal systems of the brain, are useful methods that have attracted the attention of researchers in many disciplinary areas. They have many advantages over traditional methods in situations where the input-output relationship of the system under study is not explicitly known. This paper investigates the feasibility of using neural networks for predicting the cost flow of construction projects, explains the need for cost flow forecasting, and demonstrates the limitation of the existing models. It then introduces neural networks as an alternative approach to those mathematical and statistical methods. The method used in collecting data and modelling the cost flow is described. Results of the testing are presented and discussed. Journal: Construction Management and Economics Pages: 471-479 Issue: 4 Volume: 16 Year: 1998 Keywords: Neural Networks, Cost Flow, Forecasting, Artificial Intelligence, Cost, Modelling, X-DOI: 10.1080/014461998372240 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372240 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:4:p:471-479 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Title: Behaviour-based safety management in Hong Kong's construction industry: the results of a field study Abstract: Hong Kong's construction industry has had a poor site safety record for over a decade. Behaviour-based methods of safety management (BSM) have proved successful in other industries and in other countries. Hence, this study aimed to test the effectiveness of BSM by applying goal-setting and feedback interventions to specific areas of safety performance on Hong Kong Housing Authority construction sites. Using a within-group experimental design and with the use of a proportional rating safety measurement instrument, data were collected on the effectiveness of BSM on Hong Kong sites. The data were recognized as time series data; this has been a serious methodological oversight in much previous research. The data were analysed using autoregressive moving averages models, and the results were mixed in that a significant improvement in safety performance occurred in the housekeeping category of intervention but no improvement was observed in the access to heights and bamboo scaffolding categories. Based on these results a goal setting/expectancy theory model of site safety improvement has been synthesized, and the lack of provision of an adequate safety infrastructure has been identified as a serious impediment to improvement. Journal: Construction Management and Economics Pages: 481-488 Issue: 4 Volume: 16 Year: 1998 Keywords: Safety, Motivation, Behaviour-based Methods, Goal Setting, Feedback, Intervention, X-DOI: 10.1080/014461998372259 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372259 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:4:p:481-488 Template-Type: ReDIF-Article 1.0 Author-Name: Jingsheng Shi Author-X-Name-First: Jingsheng Author-X-Name-Last: Shi Author-Name: Simaan Abourizk Author-X-Name-First: Simaan Author-X-Name-Last: Abourizk Title: Continuous and combined event-process models for simulating pipeline construction Abstract: A continuous model and a combined event-process discrete model are developed by employing the Slam II general purpose simulation language. The continuous model addressed the on-going progress of the construction process on a higher level; and the combined event-process discrete model describes the pipeline construction on the operational level. Resource sharing and related issues also are investigated in the two models through an actual gas line project adopted for the purpose of this research. A comparison of the two models provides insights into the modelling approaches. It is concluded that the combined event-process model is more flexible and more powerful for modelling complex construction operations than the continuous model, but at the price of requiring a better understanding of the actual operations and more detailed information. Journal: Construction Management and Economics Pages: 489-498 Issue: 4 Volume: 16 Year: 1998 Keywords: Linear Construction, Pipeline Construction, Computer Simulation, Modelling, Planning, Slam Ii, Slamsystem, X-DOI: 10.1080/014461998372268 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372268 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:4:p:489-498 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Agapiou Author-X-Name-First: Andrew Author-X-Name-Last: Agapiou Title: A review of recent developments in construction operative training in the UK Abstract: Future skill requirements and training initiatives designed to meet them, are highly topical issues in the construction industry. The pace of change affecting the structure of training generally has created considerable confusion among employers in the construction industry. In the mind of the average employer there is still uncertainty about the nature and value of competence-based qualifications (NVQs) which are still at a relatively early stage of implementation. Training provision has been decimated by the effects of the recession. The range of options for training routes has become more complex due to continuing government initiatives and frequent changes in funding policy. This paper traces the prevailing trends in the provision of craft training in the UK construction industry, highlighting the fragmentation of funding arrangements and its effects on the structure of training. First, recent developments in government policy for youth training in the UK in general are reviewed. Second, formalized training procedures and the roles of the different training organizations in the construction industry are discussed. This forms an important backdrop for understanding issues affecting the introduction of new vocational qualifications. Finally, the aims, objectives and key characteristics of these qualifications are presented. Factors that have constrained the implementation and delivery of the new qualifications are identified also. Journal: Construction Management and Economics Pages: 511-520 Issue: 5 Volume: 16 Year: 1998 Keywords: Skills, Training Provision, Vocational Qualifications, X-DOI: 10.1080/014461998372051 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372051 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:5:p:511-520 Template-Type: ReDIF-Article 1.0 Author-Name: A. K. W. Jayawardane Author-X-Name-First: A. K. W. Author-X-Name-Last: Jayawardane Author-Name: N. D. Gunawardena Author-X-Name-First: N. D. Author-X-Name-Last: Gunawardena Title: Construction workers in developing countries: a case study of Sri Lanka Abstract: This paper addresses human resource development (HRD) issues in the Sri Lankan construction industry. It reports an analysis of the occupational structure and characteristics of the construction work force as an aid to meeting the challenges of maintaining a skilled craft work force. Information was collected through on-site structured interview surveys of 3300 construction workers and a questionnaire survey of contractors, consultants and clients which included 56 organizations. Results indicate that the work force consists of 51% unskilled workers, 33% masons, 10% carpenters and 1-2% each of plumbers, bar benders, painters and electricians. The highest percentage of skilled workers is aged 30-39 years. Approximately 80% of the work force is casually employed, only 40% is fully utilized and 86% of the skilled work force have received informal training only. More than 20% of the work force is dissatisfied due to low income, lack of job security and difficulty in finding regular work. Comparing HRD practices to those in the USA and the UK indicates that Sri Lanka needs to adopt a more structured approach, including a more formal training system and proper grading of the skilled work force. Journal: Construction Management and Economics Pages: 521-530 Issue: 5 Volume: 16 Year: 1998 Keywords: Labour Force Structure, Characteristics, Construction Industry, Sri Lanka, X-DOI: 10.1080/014461998372060 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372060 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:5:p:521-530 Template-Type: ReDIF-Article 1.0 Author-Name: Graham Winch Author-X-Name-First: Graham Author-X-Name-Last: Winch Title: The growth of self-employment in British construction Abstract: This paper explores the issues around the remarkable growth in labour-only subcontracting on a selfemployment basis in the British construction industry over the last 30 years. Following a presentation of the available data from the Department of Employment, the paper explores the reasons behind this remarkable development, and concludes that the main reason for the growth of self-employment since 1977 is the strategic choice of construction companies to emphasize flexibility over productivity as sources of competitive advantage. The paper also explores the implications of this strategic choice, and concludes that, as a result, the ability of the industry to increase productivity and quality is compromised due to the ways in which labour-only subcontracting and self-employment hinder training and innovation. Journal: Construction Management and Economics Pages: 531-542 Issue: 5 Volume: 16 Year: 1998 Keywords: Labour-only Subcontracting, Self-employment, Productivity, Safety, Training, X-DOI: 10.1080/014461998372079 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372079 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:5:p:531-542 Template-Type: ReDIF-Article 1.0 Author-Name: Michael Coffey Author-X-Name-First: Michael Author-X-Name-Last: Coffey Author-Name: David Langford Author-X-Name-First: David Author-X-Name-Last: Langford Title: The propensity for employee participation by electrical and mechanical trades in the construction industry Abstract: Employee participation has attracted scant attention in the construction industry, yet the experience of firms in many other industries indicate that considerable benefits in terms of improved quality, lower production costs and greater competitiveness can be achieved from formal employee participation. Studies show that there are numerous examples of employee participation, in a variety of forms, being used successfully in other industries, but none in construction- why? One possible explanation is that some fundamental aspects of the construction industry prevent the application of participation. This paper reports on research that explored whether a propensity for participation exists in the construction industry, and if so, how significant is it. The research established a conceptual model of the factors that contribute towards participation in any given workplace and established the relationship between the main variables and their constituent subvariables and subsubvariables. The model was used to determine the propensity for participation in the construction industry. The results revealed that a significant amount of informal (direct) participation already occurs in the construction industry, and a strong propensity for direct participation exists. Workers are shown to have a strong desire to participate and to have significant potential for participation in defining and controlling their everyday work (defined as the 'task'). The contextual variables of 'environment' and 'organization' are shown to be non-preventive and conducive to participation, respectively. The conclusion is that there are no inherent reasons that prevent participation being successfully applied in the construction industry. Journal: Construction Management and Economics Pages: 543-552 Issue: 5 Volume: 16 Year: 1998 Keywords: Participation, Involvement, Employees, Human Resource Management, X-DOI: 10.1080/014461998372088 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372088 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:5:p:543-552 Template-Type: ReDIF-Article 1.0 Author-Name: Linda Clarke Author-X-Name-First: Linda Author-X-Name-Last: Clarke Author-Name: Christine Wall Author-X-Name-First: Christine Author-X-Name-Last: Wall Title: UK construction skills in the context of European developments Abstract: A critical examination is made of the ways in which UK construction skills training contributes to and diverges from the dynamic of European developments. In identifying aspects increasingly shared by different countries, the paper is intended to help in the formulation of a common training policy. These aspects include: (i) comprehensive training systems covering all aspects of construction work on site and subsumed under broad skill groupings, with the 'traditional trades' assuming a 'universal' character and labourers becoming a residual category; (ii) three locations for learning- the college, the site and the training workshop- with increasing prominence being given to workshops and trainee sites; (ii) a modular training system with broad-based foundation followed by gradual specialization; (iv) social partnership between employers and employees in the regulation of training, the maintenance of skill standards, and the administering of the industrial levy; (v) training and skill categories linked to wage grades, so providing an incentive to training and further training, and recognized additionally through certification; (vi) training for life, with greater emphasis on adult and further training; and (vii) equality of access to training and employment in construction to open up this largely white male preserve. The UK construction training system is out of step with many of these developments, being employer-led, largely confined to the traditional trades and dominated by qualifications broken into narrow task-related units. Nevertheless, a framework still exists which, if built on, would bring the UK training system into line with European developments. Journal: Construction Management and Economics Pages: 553-567 Issue: 5 Volume: 16 Year: 1998 Keywords: Labour, Training, Skills, Europe, X-DOI: 10.1080/014461998372097 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372097 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:5:p:553-567 Template-Type: ReDIF-Article 1.0 Author-Name: David Gann Author-X-Name-First: David Author-X-Name-Last: Gann Author-Name: Peter Senker Author-X-Name-First: Peter Author-X-Name-Last: Senker Title: Construction skills training for the next millennium Abstract: Construction skills and training needs have changed with the introduction of new business processes, different forms of organizing production and technical innovation. In the UK, training provision has failed to adapt fully to the needs of a modernizing industry. Formal training programmes have been inappropriate in content and inadequate in quantity. Many of them are out of date. An assessment is provided of the types of skill and training required to implement innovative approaches for improving construction performance. It is based on analysis of work carried out during a major national review of construction operative and supervisory skills training in the UK undertaken for the Construction Industry Board. It seeks to provide a framework for analysing skill needs in the context of modern performance targets, together with policy recommendations for decision-makers in firms, government and training institutions. The conclusion that a new generic training programme is required is of general relevance to practitioners, trainers and researchers in the UK and in other countries. Journal: Construction Management and Economics Pages: 569-580 Issue: 5 Volume: 16 Year: 1998 Keywords: Construction Skills, Training, New Technology, Business Process Change, Innovation, X-DOI: 10.1080/014461998372105 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372105 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:5:p:569-580 Template-Type: ReDIF-Article 1.0 Author-Name: Ansgar Richter Author-X-Name-First: Ansgar Author-X-Name-Last: Richter Title: Qualifications in the German construction industry: stocks, flows and comparisons with the British construction sector Abstract: The paper provides an overview of qualifications in the German construction workforce and draws comparisons with the situation in the British construction industry. The German system of general education and vocational training is outlined. Data from a variety of sources are used to describe both the stocks and the flows of qualifications in the German construction workforce. Particular attention is paid to vocational qualifications, such as apprenticeships and the Meister qualification. Key findings are that the majority of German construction workers are qualified up to apprenticeship level, and that most of these employees have achieved a general schooling certificate from at least a lower secondary school prior to their vocational training. These factors are taken as signs of strength of the German construction workforce. Comparisons between the stocks of qualifications in the construction industry in the two countries suggest that intermediate qualifications of the apprenticeship type are far less prevalent in the British construction workforce. Journal: Construction Management and Economics Pages: 581-592 Issue: 5 Volume: 16 Year: 1998 Keywords: Construction Industry, Germany, Vocational Training, Education, Qualifications, Apprenticeships, X-DOI: 10.1080/014461998372114 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372114 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:5:p:581-592 Template-Type: ReDIF-Article 1.0 Author-Name: Gerd Syben Author-X-Name-First: Gerd Author-X-Name-Last: Syben Title: A qualifications trap in the German construction industry: changing the production model and the consequences for the training system in the German construction industry Abstract: German construction companies traditionally rely on qualified workers. This has influenced both their production model (work organization on site) and their policy towards training and education. Due to the massive inflow of workers from countries with low labour costs, firms may fundamentally change this model to a new one which is distinguished by the combination of less qualified workers with a larger number of managers for instruction, supervision and control. This change is initially likely to have a considerable knock-on effect on the training system. However, what is even worse is that the new model is not likely to work in the long run. To date the construction industry has acquired its site managers and supervisors directly from the pool of qualified workers. By reducing training it produces a shortage of the very resource inevitably needed to be able to reduce training. The industry will fall into a qualifications trap. What is more significant is that this trap is shown as a first step towards lowering corporate image, quality of human resources, productivity and, in the end, competitiveness. Journal: Construction Management and Economics Pages: 593-601 Issue: 5 Volume: 16 Year: 1998 Keywords: Training, Labour Market, Germany, X-DOI: 10.1080/014461998372123 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372123 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:5:p:593-601 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Mak Author-X-Name-First: Stephen Author-X-Name-Last: Mak Author-Name: Jenny Wong Author-X-Name-First: Jenny Author-X-Name-Last: Wong Author-Name: David Picken Author-X-Name-First: David Author-X-Name-Last: Picken Title: The effect on contingency allowances of using risk analysis in capital cost estimating: a Hong Kong case study Abstract: In 1993 the Hong Kong Government implemented a methodology for capital cost estimating using risk analysis (ERA) in its estimating for the planning of public works projects. ERA is a simple approach and is used to estimate and calculate an amount of money to allow for uncertainties associated with a project. This calculated amount of money replaces the pre-1993 contingency allowance, which was merely a percentage addition on top of the base estimate of a project. A team approach is adopted to identify, classify and cost the uncertainties associated with a project. The sum of the 'average risk allowance' for the identified risk events thus becomes the 'contingency'. A study of the effect of ERA was carried out to compare the variability and consistency of the contingency estimates between non-ERA and ERA projects. This paper presents preliminary results of a survey which compares a total of 72 non-ERA and 19 ERA projects. The result shows a significant difference in variation and consistency between these groups. It indicates initial success in using the ERA method for public works projects to reduce unnecessary and exaggerated allowance for risk. Further improvement and refinement of the ERA method is suggested. Journal: Construction Management and Economics Pages: 615-619 Issue: 6 Volume: 16 Year: 1998 Keywords: Contingency, Era, Quantitative Risk Analysis, Variations, X-DOI: 10.1080/014461998371917 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998371917 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:6:p:615-619 Template-Type: ReDIF-Article 1.0 Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Author-Name: Stephanie Tan Author-X-Name-First: Stephanie Author-X-Name-Last: Tan Title: How 'just-in-time' wastages can be quantified: case study of a private condominium project Abstract: Compared with the manufacturing sector, the construction industry suffers from relatively lower productivity, although some attempts are being made to overcome low construction productivity by introducing manufacturing-based concepts to the construction industry. The just-in-time (JIT) concept is one of the manufacturing-based concepts introduced to streamline construction operations and help raise productivity in the industry. The fundamental philosophy of JIT is to eliminate wastes from delays, transportation, unnecessary processing and unnecessary motion. This is because any activities which do not add value to a process are considered wasteful. Construction productivity therefore can be enhanced if these activities are eliminated. This paper presents an accounting procedure for measuring JIT wastes. The case study of a private condominium project, where this accounting procedure was applied, shows that indeed JIT wastes can be identified and eliminated to raise construction productivity. Journal: Construction Management and Economics Pages: 621-635 Issue: 6 Volume: 16 Year: 1998 Keywords: Productivity, Just-in-time, Wastes Quantification, X-DOI: 10.1080/014461998371926 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998371926 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:6:p:621-635 Template-Type: ReDIF-Article 1.0 Author-Name: Jorge Lopes Author-X-Name-First: Jorge Author-X-Name-Last: Lopes Title: The construction industry and macroeconomy in Sub-Saharan Africa post 1970 Abstract: This paper reports research aimed at the establishment of a model of interdependence between the construction sector and the national economy, based on a long term trend, for the developing countries of Sub-Saharan Africa. This study follows research undertaken by previous writers who have investigated the relationship between the construction sector and economic development and found a positive relationship between the share of construction in gross domestic product (GDP) and the level of per capita national income. In addition, recent economic and demographic trends in Sub-Saharan Africa are presented and significant events that have had a great impact in this region are highlighted. Evidence is presented that a long term decreasing growth in GDP per capita corresponds directly to a relative decrease in construction volume. The converse does not appear to be true. Journal: Construction Management and Economics Pages: 637-649 Issue: 6 Volume: 16 Year: 1998 Keywords: Construction Industry, Economic Development, Sub-saharan Africa, X-DOI: 10.1080/014461998371935 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998371935 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:6:p:637-649 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Jennings Author-X-Name-First: Paul Author-X-Name-Last: Jennings Author-Name: Gary Holt Author-X-Name-First: Gary Author-X-Name-Last: Holt Title: Prequalification and multi-criteria selection: a measure of contractors' opinions Abstract: The procurement of a construction contractor normally involves some form of prequalification. The better prequalification regimes adopt a structured multi-criteria approach (i.e. contractor evaluation based on a multiple of factors over and above cost). This research solicits contractors' viewpoints on prequalification, in contrast to earlier works which have tended to present clients' perspectives. Contractors are dissatisfied with the frequency and adequacy of current prequalification regimes. An investigation of the mutual benefits of multi-criteria selection leads to the suggestion that such benefits could be better capitalized upon. Contractors' perceived levels of importance (with respect to selection criteria considered by clients during the selection process) are evaluated and show that, in line with earlier findings, 'cost' is still the predominant selection factor, followed by 'contractor experience' and 'company reputation'. A comparison between contractors' rankings of the selection criteria with similar rankings derived from an earlier survey of clients, finds significant correlation, indicating that contractors agree with clients' importance levels of multi-criteria selection factors. Journal: Construction Management and Economics Pages: 651-660 Issue: 6 Volume: 16 Year: 1998 Keywords: Procurement, Tendering, Prequalification, Contractor, Multi-criteria Selection, X-DOI: 10.1080/014461998371944 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998371944 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:6:p:651-660 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: The influence of communication structure upon management efficiency Abstract: A construction crisis stimulates a network of communications within its host organization, the structure of which influences crisis management efficiency. It does so by determining the effectiveness of information transfer between project participants, and thereby the level of uncertainty, misunderstanding and ultimately conflict which materializes. These conclusions arose from research which was concerned specifically with the patterns of communication and behaviour which emerge in response to construction crises. The methodology adopted a longitudinal, multiple case study approach and combined the complementary techniques of content analysis and social network analysis. Journal: Construction Management and Economics Pages: 661-671 Issue: 6 Volume: 16 Year: 1998 Keywords: Crisis Management, Efficiency, Communication, Structure, Networks, X-DOI: 10.1080/014461998371953 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998371953 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:6:p:661-671 Template-Type: ReDIF-Article 1.0 Author-Name: Mahmoud Idris Author-X-Name-First: Mahmoud Author-X-Name-Last: Idris Title: Assessment of the factors influencing the maintenance programme of a large university building in Riyadh Abstract: The amount of money invested in the building industry in the last two decades in Saudi Arabia is about SR 1251 ($234) billion. The result is a stock of large projects in housing, hospitals, universities (seven in number) etc. These buildings require efficient maintenance programmes to enable them to be serviced properly. Such programmes are handicapped by a number of interrelated factors. Such factors, like the harsh climatic conditions, presence of chlorides and sulphates in soil and water, contracting systems and lack of codes and building standards, have varied influences in maintenance. This paper, attempts to examine these factors through an analysis of the maintenance programmes of a university campus building in Riyadh. Journal: Construction Management and Economics Pages: 673-679 Issue: 6 Volume: 16 Year: 1998 Keywords: Contractors Classification, Maintenance Programme, Spare Parts, Procurement, X-DOI: 10.1080/014461998371962 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998371962 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:6:p:673-679 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Poh Author-X-Name-First: Paul Author-X-Name-Last: Poh Author-Name: Jundong Chen Author-X-Name-First: Jundong Author-X-Name-Last: Chen Title: The Singapore buildable design appraisal system: a preliminary review of the relationship between buildability, site productivity and cost. Abstract: This paper presents preliminary findings of a study to examine the relationship between site productivity, construction costs and the 'buildable score' of a buildable design appraisal system recently developed by the Singapore Construction Industry Development Board. The buildable score for a building is a numerical figure computed by taking into account the level of standardization, simplicity and extent of integrated elements used in the design of a building. The stated objective of the appraisal system is 'to promote more buildable designs in the industry through assessing the contribution of design to site efficiency and produc6 tivity'. Empirical results from 37 completed building projects provide support for the appraisal system's proposition that 'a design with a higher buildable score will result in more efficient labour usage in construction and therefore higher site labour productivity'. However, the relationship between construction costs and buildable score is less distinct. Journal: Construction Management and Economics Pages: 681-692 Issue: 6 Volume: 16 Year: 1998 Keywords: Buildability, Buildable Score, Site Labour Productivity, Construction Costs, X-DOI: 10.1080/014461998371971 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998371971 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:6:p:681-692 Template-Type: ReDIF-Article 1.0 Author-Name: Qiping Shen Author-X-Name-First: Qiping Author-X-Name-Last: Shen Author-Name: Kak-Keung Lo Author-X-Name-First: Kak-Keung Author-X-Name-Last: Lo Author-Name: Qian Wang Author-X-Name-First: Qian Author-X-Name-Last: Wang Title: Priority setting in maintenance management: a modified multi-attribute approach using analytic hierarchy process Abstract: In the current economic climate, budgets for the maintenance of public buildings are unlikely to meet the ever-increasing maintenance needs. Although it is unlikely that this problem can be overcome completely without an injection of further resources, it is possible for government maintenance authorities to improve the situation by ensuring that the best solution in terms of 'value for money' is achieved in the planned maintenance programme. A maintenance plan which is based on a rational assessment of priorities and up-to-date knowledge of the condition of the property stock will help to ensure the best use of available resources. Based on the multi-attribute maintenance prioritization model developed by Alan Spedding, Roy Holmes and Qiping Shen at the University of West of England, which is simple in practice and flexible from a management point of view, this paper presents the results of some further research into this area by modifying the original model using an analytical hierarchy process in deciding the weightings of the criteria set out in the prioritization model. This modified model is more quantitative and objective than the original model. The validation of the framework is also discussed. Journal: Construction Management and Economics Pages: 693-702 Issue: 6 Volume: 16 Year: 1998 Keywords: Planned Maintenance, Multi-attribute Prioritization, Priority Setting, Public Buildings, Analytic Hierarchy Process Ahp, X-DOI: 10.1080/014461998371980 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998371980 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:6:p:693-702 Template-Type: ReDIF-Article 1.0 Author-Name: A. Griffith Author-X-Name-First: A. Author-X-Name-Last: Griffith Author-Name: J. D. Headley Author-X-Name-First: J. D. Author-X-Name-Last: Headley Title: Management of small building works Abstract: This paper focuses on the management dimension of small building works. The paper presents a subset of findings from a major research study, supported by governmental and industry based sources, which investigated the efficiency and effectiveness of procurement methods, organizational systems and management approaches to small works and minor maintenance projects. The findings indicate that management for small works must be exerted at two levels. One is within the organization of the works themselves. The second is the development of a framework and organization which considers the implication of the works upon the organization's ongoing business. Effective small works management requires that an organization responds promptly to an identified situation, determines the cost of the work, ensures that the work is undertaken successfully, and gives value for money within the context of the organization's current business circumstance. Journal: Construction Management and Economics Pages: 703-709 Issue: 6 Volume: 16 Year: 1998 Keywords: Small Building Works, Minor Maintenance, Structure And Organization, Workload Management, X-DOI: 10.1080/014461998371999 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998371999 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:6:p:703-709 Template-Type: ReDIF-Article 1.0 Author-Name: Jean Jinghan Chen Author-X-Name-First: Jean Jinghan Author-X-Name-Last: Chen Title: The characteristics and current status of China's construction industry Abstract: The development of China's construction industry is presented by describing its current status and highlighting its achievements, identifying the main constraints preventing the industry from playing a more effective and efficient role in the country's economic development. Fundamental changes occurred in the construction industry after the economic reform, and the industry has been playing a very important role in the national economy, having made impressive progress and been developed at an amazing speed. However, reforms in the construction industry are difficult since this industry is not a single sector. The reform process by its very nature is not systematic. The challenges ahead are serious, and deeper reforms of the economic system are required. Journal: Construction Management and Economics Pages: 711-719 Issue: 6 Volume: 16 Year: 1998 Keywords: China, Construction Industry, Economic Reform, Business Environment, X-DOI: 10.1080/014461998372006 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372006 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:6:p:711-719 Template-Type: ReDIF-Article 1.0 Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Author-Name: P. E. D. Love Author-X-Name-First: P. E. D. Author-X-Name-Last: Love Title: Developing a theory of construction problem solving Abstract: Construction problem solving characterizes much of construction management practice and thus is an important research domain. Nonetheless, research in construction problem solving has not yet crossed the threshold into a mature discipline as there is no universally accepted theory for construction problem solving research. In exploring the possibility of establishing such a theory, this paper reviews existing research works in two important research categories: cognitive science and decision support systems. A strategy for building a theory for construction problem solving, focusing on the existing models and techniques developed in the two research categories, is proposed. Future research needs and opportunities are identified. Journal: Construction Management and Economics Pages: 721-727 Issue: 6 Volume: 16 Year: 1998 Keywords: Problem Solving, Cognitivism, Information Processing, Decision Support Systems, X-DOI: 10.1080/014461998372015 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372015 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:6:p:721-727 Template-Type: ReDIF-Article 1.0 Author-Name: John Raftery Author-X-Name-First: John Author-X-Name-Last: Raftery Author-Name: Bernie Pasadilla Author-X-Name-First: Bernie Author-X-Name-Last: Pasadilla Author-Name: Y. H. Chiang Author-X-Name-First: Y. H. Author-X-Name-Last: Chiang Author-Name: Eddie Hui Author-X-Name-First: Eddie Author-X-Name-Last: Hui Author-Name: Bo-Sin Tang Author-X-Name-First: Bo-Sin Author-X-Name-Last: Tang Title: Globalization and construction industry development: implications of recent developments in the construction sector in Asia Abstract: Recent developments in the construction sector in the Asian region demonstrate three trends: (1) larger private sector participation in infrastructure projects, (2) increasing vertical integration in the packaging of construction projects, and (3) increased foreign participation in domestic construction. This paper attributes the trends to the globalization and deregulation of markets necessitated by fiscal, technological and managerial constraints. Although these trends present intra-Asian opportunities, there are also areas of concern. The trends have helped polarize the financial and technical superiority of the developed countries and the corresponding inferiority of the developed countries in the region of the developing ones. In the long term, this gap could be filled through technology transfer. In the short term, however, there are concerns that imported construction services could grow at the expense of the indigenous sectors of the developing countries. This paper illustrates this dilemma with the case of Japan as a world leader in international construction services. Its dominance has apparently come through the orchestration of industrial and corporate policies, implemented in a highly regulated and protected domestic market. However, construction industries in other Asian economies (such as China) will have to leapfrog in technology, finance and management know-how (e.g. through joint ventures with developed countries' construction companies) before they can become formidable powers in an environment that has become much more global, more de-regulated, more open and more competitive than before. Journal: Construction Management and Economics Pages: 729-737 Issue: 6 Volume: 16 Year: 1998 Keywords: Construction, Asia, Globalization, Construction Industry Development, X-DOI: 10.1080/014461998372024 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372024 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:6:p:729-737 Template-Type: ReDIF-Article 1.0 Author-Name: Graham Winch Author-X-Name-First: Graham Author-X-Name-Last: Winch Title: Book review Abstract: Journal: Construction Management and Economics Pages: 738-738 Issue: 6 Volume: 16 Year: 1998 X-DOI: 10.1080/014461998372033 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461998372033 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:16:y:1998:i:6:p:738-738 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Anthony Mills Author-X-Name-First: Anthony Author-X-Name-Last: Mills Title: A needs based methodology for classifying construction clients and selecting contractors: comment Abstract: This note is a comment on Chinyio, E.A., Olomolaiye, P.O., Kometa, S.T. and Harris, F.C. (1998) A needs based methodology for classifying construction clients and selecting contractors, Construction Management and Economics, 16(1), 91-98, which describes research aimed at classifying clients by their needs rather than by the traditional public/private/developer approach. The paper also proposes a new method of selecting contractors by matching clients' needs to contractors' ability to satisfy them. The note offers constructive criticism of some aspects of the analysis. Journal: Construction Management and Economics Pages: 5-7 Issue: 1 Volume: 17 Year: 1999 Keywords: Classification, Clients, Construction, Contractors, Tender Evaluation, Scaling Briefing, X-DOI: 10.1080/014461999371772 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371772 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:1:p:5-7 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: A grounded theory of construction crisis management Abstract: Construction crisis management research is in an exploratory state where contemplated questions are of more value than hasty answers. For this reason, this paper is more concerned with theory formulation than theory testing. More specifically, it derives a grounded theory of construction crisis management which forms a useful basis for future research. It does so from an investigation of the complex patterns of communication and behaviour which emerge in response to construction crises. The conclusion is that construction crisis management is about the effective control of social and behavioural instability and the conflict which arises out of it. However, effective crisis management is made difficult by the in-built defence mechanisms which construction crises appear to have. The grounded theory also is contrasted with current crisis management theory and thereby, the uniqueness of crisis management in a construction context is identified. Journal: Construction Management and Economics Pages: 9-19 Issue: 1 Volume: 17 Year: 1999 Keywords: Crisis Management, Grounded Theory, Conflict, Behaviour, Uncertainty, Power, X-DOI: 10.1080/014461999371781 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371781 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:1:p:9-19 Template-Type: ReDIF-Article 1.0 Author-Name: John Raftery Author-X-Name-First: John Author-X-Name-Last: Raftery Title: Quasi-rational behaviour in the property and construction market Abstract: The notion of quasi-rationality is discussed and some new empirical evidence of actual (as revealed in experiments) rather than theorized behaviour is presented. Results from a series of experiments show evidence of money illusion in perception of salary levels and frame dependent risk aversion in agreeing contracts for property development. The implications for the property and construction markets and for research in property and construction economics are discussed. Journal: Construction Management and Economics Pages: 21-27 Issue: 1 Volume: 17 Year: 1999 Keywords: Quasi Rationality, Money Illusion, Human Behaviour, X-DOI: 10.1080/014461999371790 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371790 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:1:p:21-27 Template-Type: ReDIF-Article 1.0 Author-Name: Charles Egbu Author-X-Name-First: Charles Author-X-Name-Last: Egbu Title: Skills, knowledge and competencies for managing construction refurbishment works Abstract: An appropriate body of management skills and knowledge for construction refurbishment is established: a skills and knowledge inventory. Of the 75 types of management skill and knowledge, the six most important are leadership, communication (oral/written), motivation of others, health and safety, decision making, and forecasting and planning. Refurbishment managers' jobs as defined by their application of skills/knowledge are, on the whole, homogeneous, with some overlap across levels of management and types of organization, and this dispels the view that management tasks are totally different across management strata. A comparison of the relative importance of management skills/knowledge for refurbishment and management skills for general construction shows that the skills/knowledge associated with forecasting and planning, managing conflict and crisis, tenant welfare, team building, and decision making are higher than in general construction management; reflecting the uncertain nature and the relatively higher levels of risks associated with refurbishment works. Journal: Construction Management and Economics Pages: 29-43 Issue: 1 Volume: 17 Year: 1999 Keywords: Competencies, Construction Management, Education And Training, Refurbishment, Skills And Knowledge, X-DOI: 10.1080/014461999371808 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371808 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:1:p:29-43 Template-Type: ReDIF-Article 1.0 Author-Name: D. G. Proverbs Author-X-Name-First: D. G. Author-X-Name-Last: Proverbs Author-Name: G. D. Holt Author-X-Name-First: G. D. Author-X-Name-Last: Holt Author-Name: P. O. Olomolaiye Author-X-Name-First: P. O. Author-X-Name-Last: Olomolaiye Title: Productivity rates and construction methods for high rise concrete construction: a comparative evaluation of UK, German and French contractors Abstract: Recent investigations concerning the productivity of the UK construction industry and its performance compared with other European and world-wide nations have reported conflicting findings. These investigations have utilized various methodologies in attempting to measure and compare productivity levels. The present investigation uses a customized method to gauge the productivity at site level of three European national construction industries, namely Germany, France and the UK. Analysis of variance is employed to compare the productivity rates used by contractors' planning engineers for a specific concreting operation. The performance of UK contractors is found to be more disparate than those of contractors in either France or Germany. Although leading UK contractors can compete with the best on the continent, there are a number of companies whose performance is far worse than any in France and Germany, due mainly to the construction methods used by UK contractors. It is concluded therefore, that a best practice recommenda9 tion for UK contractors would be for them to avoid using traditional timber formwork methods to beams, and instead adopt more productive approaches afforded using either proprietary or prefabricated systems. Journal: Construction Management and Economics Pages: 45-52 Issue: 1 Volume: 17 Year: 1999 Keywords: Productivity Rates, Formwork, European Comparison, Construction Methods, Analysis Of Variance, X-DOI: 10.1080/014461999371817 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371817 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:1:p:45-52 Template-Type: ReDIF-Article 1.0 Author-Name: Tuula Laukkanen Author-X-Name-First: Tuula Author-X-Name-Last: Laukkanen Title: Construction work and education: occupational health and safety reviewed Abstract: An overview is given of occupational safety and health and of training in the construction sector, summarizing the findings of different researchers. The studies discussed emphasize safety instruction and on the job training at sites, especially the teaching of first aid skills and accident prevention. Construction workers regard occupational training as important in maintaining work ability. Present developments of vocational training with new flexible pathways are described. Rehabilitation needs are found to be a further important target of work ability promotion. The study provides support for comprehensive occupational health and safety measures. New feedback safety measures (LIIKKUVA, TR- safety audit), which are based on goal setting and a follow up in collaboration, seem to improve considerably both the safety and the development of construction work. Journal: Construction Management and Economics Pages: 53-62 Issue: 1 Volume: 17 Year: 1999 Keywords: Safety Instruction, On The Job Training, Vocational Education, Occupational Safety And Health, Construction Occupations, X-DOI: 10.1080/014461999371826 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371826 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:1:p:53-62 Template-Type: ReDIF-Article 1.0 Author-Name: Stuart Green Author-X-Name-First: Stuart Author-X-Name-Last: Green Author-Name: Stephen Simister Author-X-Name-First: Stephen Author-X-Name-Last: Simister Title: Modelling client business processes as an aid to strategic briefing Abstract: The briefing process can be divided into two stages. The first is referred to as strategic briefing and is concerned with understanding the client's business processes. The second stage comprises the conceptualization of built solutions and issues of performance specification. It is the first of these two stages which often is the most problematic. Several authors have established a relationship between strategic briefing and business process re-engineering (BPR), but doubts remain regarding both the originality of BPR and the extent of its theoretical justification. A social constructivist interpretation of BPR is presented and the connection is made with soft systems methodology (SSM). It is argued that SSM offers a rigorous framework for modelling client business processes which subsumes the principles of BPR. A participative research seminar is described which evaluates the potential use of SSM using case study material. Feedback from the seminar participants provides strong support for the contention that SSM could indeed provide the basis for a significant enhancement of current briefing practice. However, there is a danger that practitioners may adopt the techniques of SSM without necessarily buying in at the methodology level. The terminology of SSM also is likely to present a barrier to those construction professionals who are unwilling to make the necessary intellectual investment. Journal: Construction Management and Economics Pages: 63-76 Issue: 1 Volume: 17 Year: 1999 Keywords: Briefing, Clients, Business Process Re-engineering, Social Constructivism, Soft Systems, Methodology, X-DOI: 10.1080/014461999371835 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371835 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:1:p:63-76 Template-Type: ReDIF-Article 1.0 Author-Name: J. F. Burchett Author-X-Name-First: J. F. Author-X-Name-Last: Burchett Author-Name: V. M. Rao Tummala Author-X-Name-First: V. M. Rao Author-X-Name-Last: Tummala Author-Name: H. M. Leung Author-X-Name-First: H. M. Author-X-Name-Last: Leung Title: A world-wide survey of current practices in the management of risk within electrical supply projects Abstract: A survey is described which examines the current risk handling practices in evaluating capital development projects (transmission, generation and distribution) within the electricity supply industry world-wide. As risk perception is an important aspect of risk management, the attitudes towards and the barriers created by management to risk management plus the benefits perceived are examined and compared with the results of previous surveys. The survey will assist also in determining the need and feasibility of applying a risk management process to capital budgets in investments such as transmission construction works and other appropriate applications. The survey has demonstrated that a formal risk management process is more likely to apply to large, complex projects with potential of cost overrun. However, the criteria for application are likely to depend more on overcoming managers concerns about time involvement, human/organizational resistance and understanding of quantitative techniques, such as assessing probability distributions, determining and interpreting expected values, variances, and risk management output results, so as to appreciate the benefits and enable effective decisions to be made. The world-wide survey confirms that there is a drive towards a more thorough assessment of risks than previously recorded, with a formal risk management process that will meet the expectations of business growth and project sponsors and ensure that all risks are actively managed throughout the life cycle of a project. Journal: Construction Management and Economics Pages: 77-90 Issue: 1 Volume: 17 Year: 1999 Keywords: Risk Management, Practices, Power Generation, Power Distribution, World-wide Survey, Electricity Supply Industry, X-DOI: 10.1080/014461999371844 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371844 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:1:p:77-90 Template-Type: ReDIF-Article 1.0 Author-Name: Nie-Jia Yau Author-X-Name-First: Nie-Jia Author-X-Name-Last: Yau Author-Name: Jyh-Bin Yang Author-X-Name-First: Jyh-Bin Author-X-Name-Last: Yang Author-Name: Ting-Ya Hsieh Author-X-Name-First: Ting-Ya Author-X-Name-Last: Hsieh Title: Inducing rules for selecting retaining wall systems Abstract: Rule induction is a paradigm of machine learning that governs how knowledge is acquired from experience. This paradigm not only classifies existing data into logical sets, but also expresses them by 'if-then' rules. Rule induction can be applied to the experience-oriented construction industry. A typical example would be to select an appropriate retaining wall system at the project planning stage, in which engineers normally employ certain empirical laws or select from the types for which they have relevant expertise in making appropriate selections. This work presents a novel rule induction approach, capable of inducing from 254 retaining wall cases in engineering design reports into 181 rules, thereby allowing for an appropriate retaining wall system to be selected. A system referred to herein as RULES is also constructed with an illustrative example provided as well. Test results of the system demonstrate that the rule induction approach can effectively resolve retaining wall selection problems at the project planning stage. The approach proposed herein is highly promising for resolving experience-oriented problems in the construction industry. Journal: Construction Management and Economics Pages: 91-98 Issue: 1 Volume: 17 Year: 1999 Keywords: Rule Induction, Retaining Wall Selection, Knowledge Discovery, Artificial Intelligence, X-DOI: 10.1080/014461999371853 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371853 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:1:p:91-98 Template-Type: ReDIF-Article 1.0 Author-Name: Robert Chapman Author-X-Name-First: Robert Author-X-Name-Last: Chapman Title: The likelihood and impact of changes of key project personnel on the design process Abstract: Both the construction and the risk analysis and management literature have overlooked the highly disruptive influence of the loss of key project personnel. It is clear from other industries involved in managing projects, such as information technology, that the likelihood of this adverse event is openly recognized. The construction literature looks at a series of issues which all relate to communication and information transfer but fails to isolate one of the key issues which, when it materializes, seriously undermines the essence of design- the complete integration of the creative contribution of all the participating design disciplines. The risk analysis and management literature recognizes the significance of risk identification but pays scant attention to discontinuity, and the borrowed identification techniques are reliant solely on subjective judgements. Propositions for examination are tested against a documentary analysis of twenty-two projects to establish the existence of this threat to a project's objectives. Of the sample of projects examined, changes to personnel are commonplace, and clearly lead to project overruns. Journal: Construction Management and Economics Pages: 99-106 Issue: 1 Volume: 17 Year: 1999 Keywords: Design Management, Risk, Key Project Personnel, X-DOI: 10.1080/014461999371862 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371862 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:1:p:99-106 Template-Type: ReDIF-Article 1.0 Author-Name: Ramin Moatazed-Keani Author-X-Name-First: Ramin Author-X-Name-Last: Moatazed-Keani Author-Name: Ali R. Ghanbari-Parsa Sechi Author-X-Name-First: Ali R. Ghanbari-Parsa Author-X-Name-Last: Sechi Title: ISO 9000 standards: perceptions and experiences in the UK construction industry Abstract: With the adoption by construction firms of BS EN ISO 9000 there has been much debate concerning its effectiveness and value as a quality management system. In spite of the reported benefits of ISO 9000 certification, however, concerns regarding its overall benefit to construction firms due to unnecessary bureaucracy and paperwork, increased costs, stifling of innovation, etc. still persist in the industry. This paper reports on the results of a research carried out on the implementation of BS EN ISO 9000 as a continuation of BS5750 in the UK construction industry from the view point of the experiences and perceptions of quality assurance managers of selected construction firms. Journal: Construction Management and Economics Pages: 107-119 Issue: 1 Volume: 17 Year: 1999 Keywords: Quality Assurance, Quality Management Systems, Iso 9000 Standard, Certification, Construction Firms, X-DOI: 10.1080/014461999371871 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371871 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:1:p:107-119 Template-Type: ReDIF-Article 1.0 Author-Name: Willie Tan Author-X-Name-First: Willie Author-X-Name-Last: Tan Title: Construction cost and building height Abstract: A simple neoclassical production function model is used to determine the incremental cost of each floor as building height increases. This analytic method provides an alternative to earlier studies using computer simulation and more cumbersome attempts at measuring the cost variation directly. By modelling construction costs analytically, it is possible to identify and assess the impacts of particular variables more explicitly. There are two main findings. First, cost variation with building height is not only affected by technology; building design, demand and institutional factors also play important roles. Secondly, the model may be used to estimate construction cost variation with building height from readily available data. In this sense it is an improvement over previous methods using simulated or direct cost measurement. Journal: Construction Management and Economics Pages: 129-132 Issue: 2 Volume: 17 Year: 1999 Keywords: Construction Cost, Building Height, Productivity, X-DOI: 10.1080/014461999371628 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371628 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:2:p:129-132 Template-Type: ReDIF-Article 1.0 Author-Name: S. D. Green Author-X-Name-First: S. D. Author-X-Name-Last: Green Title: The missing arguments of lean construction Abstract: The emerging concept of lean construction is concerned with the application of lean thinking to the construction industry. The ideas of lean thinking seem set to dominate the UK construction industry's quest to improve quality and efficiency. However, the current debate is based on a highly selective interpretation of the available literature. The extent to which the Japanese model of lean production is applicable in Western contexts remains hotly debated. An extensive body of critical opinion equates the Japanese model of lean production with technocratic totalitarianism. Whilst the claims of productivity achievements in Japanese manufacturing transplants are impressive, the rhetoric of flexibility, quality and teamwork too often translates in practice to control, exploitation and surveillance. Furthermore, it cannot be taken for granted that any increases in productivity necessarily serve the interests of the end customer. The current agenda for the implementation of lean thinking in the UK construction industry notably ignores the extensive critical literature on lean production. In the absence of a more balanced research agenda, there is a danger that dogma rather than a balanced appraisal of the available evidence will drive construction policy. Journal: Construction Management and Economics Pages: 133-137 Issue: 2 Volume: 17 Year: 1999 Keywords: Lean Construction, Human Resource Management, Total Quality Management, Critical Theory, Customer Responsiveness, Technocratic Totalitarianism, X-DOI: 10.1080/014461999371637 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371637 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:2:p:133-137 Template-Type: ReDIF-Article 1.0 Author-Name: Richard Ray Author-X-Name-First: Richard Author-X-Name-Last: Ray Author-Name: John Hornibrook Author-X-Name-First: John Author-X-Name-Last: Hornibrook Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Anna Zarkada-Fraser Author-X-Name-First: Anna Author-X-Name-Last: Zarkada-Fraser Title: Ethics in tendering: a survey of Australian opinion and practice Abstract: The main issues in the philosophical foundations of ethics and tendering ethics are outlined, and an introduction is provided to the Australian codes of tendering practice. A questionnaire survey is then described which sought to ascertain the extent to which ethical behaviour in tendering is supported and practiced in Australia. The results of the survey indicate that most companies support the use of codes of tendering; defend the right of withdrawal of tenders; disapprove of bid shopping, cover pricing and union involvement in the tendering process, and support the principals' right to know what is included in a tender as well as the self-regulation of the tendering codes. It is also shown that most companies have developed, and follow, idiosyncratic ethical guidelines that are independent of, and often contrary to, the nationally prescribed codes. The conclusions recommend a need for the development of a theoretical frame of reference that can be tested through a more detailed empirical approach to the development of future ethical prescriptions in the field. Journal: Construction Management and Economics Pages: 139-153 Issue: 2 Volume: 17 Year: 1999 Keywords: Ethics, Tendering, Codes, Restrictive Practices, X-DOI: 10.1080/014461999371646 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371646 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:2:p:139-153 Template-Type: ReDIF-Article 1.0 Author-Name: A. N. Baldwin Author-X-Name-First: A. N. Author-X-Name-Last: Baldwin Author-Name: S. A. Austin Author-X-Name-First: S. A. Author-X-Name-Last: Austin Author-Name: T. M. Hassan Author-X-Name-First: T. M. Author-X-Name-Last: Hassan Author-Name: A. Thorpe Author-X-Name-First: A. Author-X-Name-Last: Thorpe Title: Modelling information flow during the conceptual and schematic stages of building design Abstract: This paper reports on recent research the aim of which was to study, model and simulate the information flow at the conceptual and schematic stages of building design. The development of a generic model of the conceptual and schematic design process for buildings is described. This model comprising design tasks and their information requirements was produced using data flow diagrams. Examples from several levels of the model are provided. Details are then given as to how the model may be used to assist the management of the design process both directly and by providing primary data for other tools and techniques. Industry feedback on the data modelling and these tools and techniques is then discussed. It is concluded that it is only by a better understanding of the flow of information among project participants that the management of design may be improved, and that although the generic data flow model provides immediate benefits to design managers these can be enhanced greatly by the use of the model as a primary data source for other tools and techniques including the design structure matrix and simulation. Journal: Construction Management and Economics Pages: 155-167 Issue: 2 Volume: 17 Year: 1999 Keywords: Conceptual And Schematic Design, Information Flow, Data Flow Diagrams, Design Structure Matrix, Simulation, X-DOI: 10.1080/014461999371655 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371655 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:2:p:155-167 Template-Type: ReDIF-Article 1.0 Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Author-Name: Peter Love Author-X-Name-First: Peter Author-X-Name-Last: Love Title: Combining rule-based expert systems and artificial neural networks for mark-up estimation Abstract: Rule-based expert systems and artificial neural networks are two major systems for developing intelligent decision support systems. The integration of the two systems can generate a new system which shares the strengths of both rule-based and artificial neural network systems. This research presents a computer based mark-up decision support system called InMES (integrated mark-up estimation system) that integrates a rule-based expert system and an artificial neural network (ANN) based expert system. The computer system represents an innovative approach for estimating a contractor's mark-up percentage for a construction project. A rule extraction method is developed to generate rules from a trained ANN. By using the explanation facility embedded in the rule-based expert system, InMES provides users with a clear explanation to justify the rationality of the estimated mark-up output. Cost data derived from a contractor's successful bids were used to train an ANN and, in conjunction with a rule-based expert system, select the expected mark-up for a project. The combination of both ANN- and rule-based expert systems for estimating mark-up allows significant benefits to be made from each individual system, such as understanding why and how the estimated mark-up was derived and also the effects of imposing rules and constraints on a company's mark-up estimation. The mark-up decision support system presented can assist contractors in preparing a rational mark-up percentage for a project. Moreover, InMES as proposed will assist contractors in their tender decision making, that is, whether or not to submit a bid for a project considering the estimated mark-up. Journal: Construction Management and Economics Pages: 169-176 Issue: 2 Volume: 17 Year: 1999 Keywords: Hybrid Systems, Mark-up Decision, Rule Extraction, Explanation Facility, X-DOI: 10.1080/014461999371664 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371664 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:2:p:169-176 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: Bargaining tactics in construction disputes Abstract: Bargaining is the initial and informal means by which parties attempt to resolve their differences during a construction dispute. However, knowledge of the bargaining process in construction projects is scant, with most attention being given to developing more formal, costly and reactive means of dispute resolution. This approach is questioned, in favour of a more efficient one based upon a better understanding of bargaining behaviour and improved bargaining skills. To this end, the behavioural complexities of the bargaining process during construction disputes are investigated. It is concluded that the majority of construction disputes are unintentional and escalate as a result of misunderstandings and tactical miscalculations during the bargaining process. A series of recommendations is set out to reduce the potential for unintentional escalation during a construction dispute. Journal: Construction Management and Economics Pages: 177-188 Issue: 2 Volume: 17 Year: 1999 Keywords: Bargaining, Negotiation, Behaviour, Claim, Conflict, Dispute, X-DOI: 10.1080/014461999371673 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371673 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:2:p:177-188 Template-Type: ReDIF-Article 1.0 Author-Name: Albert Chan Author-X-Name-First: Albert Author-X-Name-Last: Chan Title: Modelling building durations in Hong Kong Abstract: The duration of Australian construction has been modelled by a time-cost formula expressed in the form of T=KCB, where T is the actual construction time in working days, C is the final cost of contract in millions, K is a constant characteristic of building time performance, and B is a constant indicative of the sensitivity of time performance to cost level. This paper applies the relationship to building projects in Hong Kong using time and cost data from 110 projects. Regression analysis was used to compute the values of K and B and check how well the model actually fits, and the best predictor of average construction time of building projects in Hong Kong is found to be T=152C0.29. It is also found that the Hong Kong private sector takes a shorter time (120 days) to complete a hypothesized project with a contract sum of HK$1 million (at December 1994 price) than its government counterpart (166 days). The time-cost relationship serves as a convenient tool for both project managers and clients for predicting the actual optimum time required for delivery of a building project. Journal: Construction Management and Economics Pages: 189-196 Issue: 2 Volume: 17 Year: 1999 Keywords: Time Cost Relationship, Regression Model, Building Projects, Hong Kong, X-DOI: 10.1080/014461999371682 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371682 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:2:p:189-196 Template-Type: ReDIF-Article 1.0 Author-Name: Diane Gyi Author-X-Name-First: Diane Author-X-Name-Last: Gyi Author-Name: Alistair Gibb Author-X-Name-First: Alistair Author-X-Name-Last: Gibb Author-Name: Roger Haslam Author-X-Name-First: Roger Author-X-Name-Last: Haslam Title: The quality of accident and health data in the construction industry: interviews with senior managers Abstract: Despite recent changes in legislation and advances towards an integrated project-wide approach, health and safety management in the construction industry is still a major problem, involving a substantial cost to business, society and individuals. A prerequisite to improving the situation and developing an effective management strategy is monitoring, providing a detailed understanding of the effectiveness of different approaches to intervention. This paper describes a feasibility study using in-depth interviews with senior managers to explore the quality of accident and health data of nine large, high profile companies from the engineering construction sector. The interview dialogue comprised a series of questions and issues to be explored on the organization's accident reporting systems (e.g. what is reported, analysis performed, computerization), unsafe act and near miss auditing (e.g. definition, validity), failure type indicators (e.g. auditing, quantification) and safety culture indicators (e.g. commitment, health). Although safety was a priority for companies, health (i.e. medicals and monitoring systems) had not been given the same consideration, especially with regard to subcontracted labour. This study shows that the validity of accident statistics as a measure of safety remains a limitation, and that there is a requirement for a consistent and integrated approach to the measurement of health and safety performance. Journal: Construction Management and Economics Pages: 197-204 Issue: 2 Volume: 17 Year: 1999 Keywords: Health, Safety, Interviews, Accident Data, X-DOI: 10.1080/014461999371691 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371691 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:2:p:197-204 Template-Type: ReDIF-Article 1.0 Author-Name: Scott Baker Author-X-Name-First: Scott Author-X-Name-Last: Baker Author-Name: David Ponniah Author-X-Name-First: David Author-X-Name-Last: Ponniah Author-Name: Simon Smith Author-X-Name-First: Simon Author-X-Name-Last: Smith Title: Risk response techniques employed currently for major projects Abstract: Risk management is fundamental to the success of a major project. However, the variations in using risk management practices are considerable and are dependent on numerous factors such as the industry sector, the size of the project, and the stage in the project life cycle. One of the major constituents of successful risk control is the use of risk response. This paper concentrates on the choice and use of the most successful risk response techniques within the oil and gas industry and compares them with the use of those chosen by the construction industry. Results were ascertained through a survey of over one hundred companies within these two sectors by use of an extensive questionnaire. The main conclusions are that risk reduction as a response to assessed risks is most commonly used by both sectors; and that the construction industry concentrates almost exclusively on reduction of financial risk. It is proposed that the construction industry can benefit greatly from the more experienced oil and gas industry in managing technical risk which, with the advent of private funding, is likely to become a more predominant part of construction procurement. Journal: Construction Management and Economics Pages: 205-213 Issue: 2 Volume: 17 Year: 1999 Keywords: Risk Management, Risk Response, X-DOI: 10.1080/014461999371709 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371709 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:2:p:205-213 Template-Type: ReDIF-Article 1.0 Author-Name: Zeynep Sozen Author-X-Name-First: Zeynep Author-X-Name-Last: Sozen Author-Name: Mehmi Kucuk Author-X-Name-First: Mehmi Author-X-Name-Last: Kucuk Title: Secondary subcontracting in the Turkish construction industry Abstract: Based on the findings of a survey carried out in 1995 among Turkish subcontractors, the present paper argues that pressures (time, overload of work and commercial considerations) play an important role in the subcontracting of work by subcontractors to secondary subcontractors. The tendency to sublet work to secondary subcontractors is associated with cost control and payment problems. Subcontractors also seem to perceive the lack of written agreements with secondary subcontractors as problematic, especially in terms of physical progress of work. Journal: Construction Management and Economics Pages: 215-220 Issue: 2 Volume: 17 Year: 1999 Keywords: Subcontracting Secondary Subcontracting, Turkish Construction Practices, X-DOI: 10.1080/014461999371718 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371718 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:2:p:215-220 Template-Type: ReDIF-Article 1.0 Author-Name: D. G. Proverbs Author-X-Name-First: D. G. Author-X-Name-Last: Proverbs Author-Name: G. D. Holt Author-X-Name-First: G. D. Author-X-Name-Last: Holt Author-Name: P. O. Olomolaiye Author-X-Name-First: P. O. Author-X-Name-Last: Olomolaiye Title: European construction contractors: a productivity appraisal of in situ concrete operations Abstract: Site productivity levels for high rise, in situ concrete operations are compared among three groups of European construction contractors. Results confirm significant differences between the contractor's productivity rates for each of the three countries investigated (Germany, France and the UK). German firms are the most efficient at reinforcement and concrete placing operations, whereas French firms are most productive at formwork. UK firms are the least productive for two operations, namely formwork and concrete. French firms are least productive at fixing reinforcement. Based on a specific model project, it is determined that French and German firms require significantly fewer man-hours to carry out the said concrete operations than do UK firms. UK contractors achieve the lowest levels of labour productivity for the operations involved. The UK also exhibited greater productivity variation, i.e. providing evidence of extreme (most and least efficient) levels of labour output for several concrete operations. Leading on from these analyses, a construction (labour) cost comparison indicates that French contractors are the least expensive. Furthermore, the ideal solution for clients would be to have French firms build their projects in the UK, since this combination provides the most economic solution to the model building overall. Journal: Construction Management and Economics Pages: 221-230 Issue: 2 Volume: 17 Year: 1999 Keywords: Productivity Rates, European Comparison, Labour Costs, In Situ Concrete Operations, Analysis Of Variance, X-DOI: 10.1080/014461999371727 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371727 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:2:p:221-230 Template-Type: ReDIF-Article 1.0 Author-Name: Goh Bee-Hua Author-X-Name-First: Goh Author-X-Name-Last: Bee-Hua Title: An evaluation of the accuracy of the multiple regression approach in forecasting sectoral construction demand in Singapore Abstract: In the current state of research in construction demand modelling and forecasting there is a predominant use of the multiple regression approach, particularly the linear technique. Because of the popularity, it may be useful at this stage to gain an insight into the accuracy of the approach by comparing the forecasting performance of different forms of regression analysis. It is only through such formal means that the relative accuracy of different regression techniques can be assessed. In a case-study of modelling Singapore's residential, industrial and commercial construction demand, both linear and nonlinear regression techniques are applied. The techniques used include multiple linear regression (MLR), multiple log-linear regression (MLGR) and autoregressive nonlinear regression (ANLR). Quarterly time-series data over the period 1975-1994 are used. The objective is to evaluate the reliability of these techniques in modelling sectoral demand based on ex-post forecasting accuracy. Relative measures of forecasting accuracy dealing with percentage errors are used. It is found that the MLGR outperforms the other two methods in two of the three sectors examined by achieving the lowest mean absolute percentage error. The general conclusion is that nonlinear techniques are more accurate in representing the complex relationship between demand for construction and its various associated indicators. In addition to improved accuracy, the use of nonlinear forms also expands the scope of regression analysis. Journal: Construction Management and Economics Pages: 231-241 Issue: 2 Volume: 17 Year: 1999 Keywords: Regression Techniques, Construction Demand, Forecasting Accuracy, Nonlinear, Model Evaluation, X-DOI: 10.1080/014461999371736 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371736 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:2:p:231-241 Template-Type: ReDIF-Article 1.0 Author-Name: Samuel Stocks Author-X-Name-First: Samuel Author-X-Name-Last: Stocks Author-Name: Amarjit Singh Author-X-Name-First: Amarjit Author-X-Name-Last: Singh Title: Studies on the impact of functional analysis concept design on reduction in change orders Abstract: Functional analysis concept design (FACD) is a method by which owners and designers can 'partner' during the design phase of projects. Much has been written and reported about partnering on construction projects, but little is available on the applications and results of FACD. While FACD has been mentioned in the literature to be a valuable tool, evidence on its effectiveness has been missing. Consequently, FACD has not hitherto emerged as a common management system used during design. Management processes on its implementation also had not been developed fully until the United States Navy carried out research, much involving tedious trials and revisions. This paper describes processes that have been found suitable. The economic benefits of FACD have never been directly evaluated, but by examining and testing the quantum of change orders on projects, this study finds that FACD is a viable method that can reduce construction costs overall. Whereas value engineering and constructability review are other common tools, FACD is distinct from them both. FACD is allied to functional analysis system technique (FAST); regulations, and specifications have been developed to implement FACD to ensure its success. Journal: Construction Management and Economics Pages: 251-267 Issue: 3 Volume: 17 Year: 1999 Keywords: Change Orders, Anova, Cost, Fast, Design, Functional Analysis, X-DOI: 10.1080/014461999371475 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371475 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:3:p:251-267 Template-Type: ReDIF-Article 1.0 Author-Name: Henk Vermande Author-X-Name-First: Henk Author-X-Name-Last: Vermande Author-Name: Peter-Hein Van Mulligen Author-X-Name-First: Peter-Hein Author-X-Name-Last: Van Mulligen Title: Construction costs in The Netherlands in an international context Abstract: OECD purchasing power parities (PPPs) are used regularly in strategic governmental policy papers to compare the performance of construction industries among countries. These PPPs suggest that the relative competitiveness of the Dutch construction sector is fairly weak compared with surrounding countries. This contradicts the general view that the Dutch construction industry is very productive and efficient, especially in house-building. For the member countries of the European Union the OECD uses data from Eurostat, the statistical office of the European Union. In this paper the methodology followed by OECD/Eurostat in their calculation of PPPs for construction is reviewed. The data for five European countries (Netherlands, Belgium, UK, France and Germany) are analysed. Next, the Eurostat results are placed alongside the results of other international building cost comparisons. The differences are observed and the conclusion is that the Eurostat PPPs do not reflect the real construction price or cost differentials among the five EU countries. It appears that the basic construction price data used by Eurostat are not very accurate, that the comparison methodology applied by Eurostat itself is insufficient to express and explain building cost differences among countries, and that the Eurostat figures for construction are the result of a complex statistical weighting and processing procedure in which corrections are not applied for extreme deviations. The conclusion is that the Eurostat data cannot be used for comparison purposes. Proposals for improvement of the comparison methodology are reviewed. Journal: Construction Management and Economics Pages: 269-283 Issue: 3 Volume: 17 Year: 1999 Keywords: Building Costs, International Comparison, Statistics, Purchasing Power Parities, X-DOI: 10.1080/014461999371484 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371484 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:3:p:269-283 Template-Type: ReDIF-Article 1.0 Author-Name: Goran Runeson Author-X-Name-First: Goran Author-X-Name-Last: Runeson Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Tendering theory revisited Abstract: This paper discusses the content, origin and development of tendering theory as a theory of price determination. It demonstrates how tendering theory determines prices and how it is different from game and decision theories, and that in the tendering process, with non-cooperative, simultaneous, single sealed bids with individual private valuations, extensive public information, a large number of bidders and a long sequence of tendering occasions, there develops a competitive equilibrium. The development of a competitive equilibrium means that the concept of the tender as the sum of a valuation and a strategy, which is at the core of tendering theory, cannot be supported, and that there are serious empirical, theoretical and methodological inconsistencies in the theory. Journal: Construction Management and Economics Pages: 285-296 Issue: 3 Volume: 17 Year: 1999 Keywords: Tendering Theory, Tendering, Price Determination, Bidding, X-DOI: 10.1080/014461999371493 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371493 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:3:p:285-296 Template-Type: ReDIF-Article 1.0 Author-Name: Roberto Pietroforte Author-X-Name-First: Roberto Author-X-Name-Last: Pietroforte Author-Name: Ranko Bon Author-X-Name-First: Ranko Author-X-Name-Last: Bon Title: The Italian residential construction sector: an input-output historical analysis Abstract: Two sets of input-output tables are employed in this paper to analyse the role of the Italian residential construction sector in the national economy. The analysis focuses on changes in construction technology over a period of some 30 years, ending in 1985, the last year for which such data are available. A set of eight-sector input-output tables is used to show the weakening of the residential construction sector's effect on the economy as a whole. This trend is caused by the progressive saturation of the residential construction market and the transformation of the overall Italian economy. As expected, the achieved maturity of the Italian economy is accompanied by the growing importance of maintenance and repair construction because of the ageing building infrastructure. Another set of 24-sector input-output tables is used to analyse the input and output profiles of the residential and non-residential construction sectors, by selecting key supply industries. Significant differences are reported in the technology of the residential sector, with a shift towards services and away from manufacturing inputs. Finally, the main findings and directions for future research are summarized. Journal: Construction Management and Economics Pages: 297-303 Issue: 3 Volume: 17 Year: 1999 Keywords: Input-output Analysis, Backward And Forward Linkage Indicators, Construction Technology, Residential Construction, X-DOI: 10.1080/014461999371501 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371501 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:3:p:297-303 Template-Type: ReDIF-Article 1.0 Author-Name: Arthur Leung Author-X-Name-First: Arthur Author-X-Name-Last: Leung Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Title: Prediction of hoisting time for tower cranes for public housing construction in Hong Kong Abstract: Material transportation for high-rise building construction relies heavily on tower cranes. Hence the proper use of tower cranes is of paramount importance for high-rise residential building construction. In planning and monitoring crane usage in Hong Kong, a schedule is usually prepared to coordinate hoisting operations. Apart from that, little research in optimizing crane usage has been carried out previously, except on operation cycle times, e.g. concreting using a crane and skip and formwork erection. Allocation of time for the hoisting schedule is based on the planners' and operators' experience. The accuracy of the hoisting schedule for crane dominated construction works has significant effects on the materials supply and on concreting operations. Imbalance in the allocation of crane usage for subcontractors may lead to conflicts between trades and idling of workers due to a shortage of materials. Although planners understand that the load hoisting time is proportional to hoisting height and other factors, floor construction cycles usually, for simplicity, are assigned to be constant six day, eight day or ten day cycles without making the necessary compensation for the longer hoisting times for upper floors. The prediction of hoisting times is of great importance to planners to ensure the accuracy of the construction schedule for crane dominated construction. This paper describes the derivation of a mathematical model to predict the hoisting times for a tower crane for public housing construction. Work measurement is used to collect hoisting times data for analysis. Twelve factors considered to influence hoisting time are identified for the model. Multiple regression models are built for predicting supply hoisting times and return hoisting times. The effects of the variables on hoisting time are reviewed. Estimated hoisting times calculated from the models are compared with actual hoisting times, and a worked example illustrating the application of the models is presented. Journal: Construction Management and Economics Pages: 305-314 Issue: 3 Volume: 17 Year: 1999 Keywords: Tower Crane, Multiple Regression Analysis, Public Housing, Hoisting Time, X-DOI: 10.1080/014461999371510 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371510 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:3:p:305-314 Template-Type: ReDIF-Article 1.0 Author-Name: M. I. Okoroh Author-X-Name-First: M. I. Author-X-Name-Last: Okoroh Author-Name: V. B. Torrance Author-X-Name-First: V. B. Author-X-Name-Last: Torrance Title: A model for subcontractor selection in refurbishment projects Abstract: A model is presented for analysing the subcontractor's risk elements in construction refurbishment projects. The system is based on the use of fuzzy set theory with the fuzzy set representing the overall weighted average rating of refurbishment contractors criterion for the selection of subcontractors. A prototype knowledge based expert system is described, which provides a systematic and objective approach to the selection of subcontractors. Knowledge elicitation methodology using the 'repertory grid' technique is detailed. The implementation of a subcontractor selection and appointment Model for refurbishment contractors (SSARC) in linguistic terms allows the user to interact with the system in a very friendly manner using natural language expressions. Journal: Construction Management and Economics Pages: 315-327 Issue: 3 Volume: 17 Year: 1999 Keywords: Refurbishment, Subcontractors, Repertory Grid, Knowledge Based System, Fuzzy Logic, X-DOI: 10.1080/014461999371529 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371529 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:3:p:315-327 Template-Type: ReDIF-Article 1.0 Author-Name: S. D. Green Author-X-Name-First: S. D. Author-X-Name-Last: Green Title: A participative research strategy for propagating soft methodologies in value management practice Abstract: The emerging methodologies of 'soft operational research' have been developed for the purposes of structuring multi-perspective problems characterized by uncertainty, ambiguity and conflict. A participative research project is reported that sought to propagate the three most established 'soft' methodologies within UK value management practice. The adopted research strategy consisted of four key stages. Following an initial literature review, an insight into existing value management was gained by twelve semi-structured interviews with leading practitioners. This was followed by a series of six participative research seminars which used simulated case studies to evaluate the potential application of the three methodologies within the context of value management. A final series of interviews then determined the extent to which the three methodologies subsequently had been adopted in practice. The results are encouraging in that already the research has had an influence on UK value management practice. However, doubts remain as to whether the practitioners have assimilated the methodologies fully, or simply have adopted individual techniques in the absence of any theoretical understanding. Journal: Construction Management and Economics Pages: 329-340 Issue: 3 Volume: 17 Year: 1999 Keywords: Briefing, Group Decision Support, Participative Research, Risk Management, Soft Operational Research, Value Management, X-DOI: 10.1080/014461999371538 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371538 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:3:p:329-340 Template-Type: ReDIF-Article 1.0 Author-Name: E. Sarah Slaughter Author-X-Name-First: E. Sarah Author-X-Name-Last: Slaughter Title: Assessment of construction processes and innovations through simulation Abstract: The objectives of this research are to represent construction activities accurately, and to provide a means for assessing the impacts from using innovations. The research approach is the detailed characterization of construction processes, and the development of system and material specific dynamic process simulation models. The ongoing research program is developing a set of specific models, based on extensive empirical data, to enable the accurate modelling of all of the construction processes for a complete facility construction project. A specific process model, glass/metal curtainwall erection, demonstrates the approach, with an analysis of the impacts from a related innovation. Journal: Construction Management and Economics Pages: 341-350 Issue: 3 Volume: 17 Year: 1999 Keywords: Construction Process Improvement, Dynamic Process Simulation, Construction Innovation, Simulation Models, Estimates Of Cost, Worker Safety, X-DOI: 10.1080/014461999371547 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371547 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:3:p:341-350 Template-Type: ReDIF-Article 1.0 Author-Name: Daniel Chan Author-X-Name-First: Daniel Author-X-Name-Last: Chan Author-Name: Mohan Kumaraswamy Author-X-Name-First: Mohan Author-X-Name-Last: Kumaraswamy Title: Modelling and predicting construction durations in Hong Kong public housing Abstract: Construction time performance is provoking world-wide concern and discussion within the industry. This paper reports the results of a survey in the fourth stage of an investigation seeking to identify a set of significant variables influencing construction durations of projects in Hong Kong, the stage addressing the formulation of standard norms for overall construction durations of public housing projects by modelling the primary work packages in the building process, namely piling, pile caps/raft, superstructure, E&M services, finishes and their respective sequential start-start lag times, on the basis of the identified groups of critical factors. Data were collected from a sample of 56 standard 'Harmony' type domestic blocks of the Hong Kong Housing Authority; (the 'Harmony' series of block design having become popular for average quality public housing blocks in the 1990s, ranging from 30 to 40 storeys and containing about 16 residential units on each floor). These data were analysed through a series of multiple linear regression exercises that helped to establish the time prediction model. This model was then tested and validated using information from a further nine projects from the Housing Authority. Both the usefulness and shortcomings of the model are briefly presented and discussed. It is concluded that the model is applicable to the public housing industry in Hong Kong, and that the methodology used may be applied to develop similarly useful models in other subsectors, and in other countries. Journal: Construction Management and Economics Pages: 351-362 Issue: 3 Volume: 17 Year: 1999 Keywords: Modelling, Predicting, Construction Durations, Hong Kong Public Housing, Multiple Linear Regression, X-DOI: 10.1080/014461999371556 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371556 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:3:p:351-362 Template-Type: ReDIF-Article 1.0 Author-Name: Daniel Irurah Author-X-Name-First: Daniel Author-X-Name-Last: Irurah Author-Name: Dieter Holm Author-X-Name-First: Dieter Author-X-Name-Last: Holm Title: Energy impact analysis of building construction as applied to South Africa Abstract: Basic embodied-energy intensities of building construction materials/systems by various units and building types are shown to produce conflicting results and are not directly applicable at a national policy-intervention level. Using building construction and the allied sectors in South Africa, this paper demonstrates the extension of basic energy intensities derived through an improved input-output (I-O) method into a sectoral energy conservation framework. The framework is based on sectoral total embodiment energy impact coefficients derived through the multiplication of the total-embodiment energy intensity coefficients with the use-intensity coefficients. A ranking of building construction and the allied sectors in South Africa according to their energy impact coefficients is used to formulate a priority listing of critical sectors for energy conservation measures. The framework is used also to identify generic conservation measures for further investigation and evaluation. Journal: Construction Management and Economics Pages: 363-374 Issue: 3 Volume: 17 Year: 1999 Keywords: Building Construction, Embodied Energy, Input-output, Use-intensity, South Africa, X-DOI: 10.1080/014461999371565 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371565 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:3:p:363-374 Template-Type: ReDIF-Article 1.0 Author-Name: Steve Scott Author-X-Name-First: Steve Author-X-Name-Last: Scott Author-Name: Sami Assadi Author-X-Name-First: Sami Author-X-Name-Last: Assadi Title: A survey of the site records kept by construction supervisors Abstract: A number of writers have cited poor records as limiting the ability of supervisors, and indeed of contractors, to carry out some of their most important functions. The study reported in this paper aimed to identify the problems in detail. This was achieved by conducting a mail-shot survey of construction supervisors working for firms of civil engineering consultants. The results indicate that there is considerable room for improvement in the records kept on most sites, where guidelines are said to be inadequate and the problems of enforcing these inadequate guidelines were also recognized. The main source data for progress records was identified as the site diaries kept by individual members of the supervisor's team, and these were found to be particularly difficult to access for a number of reasons. Since the site diaries are such an important source of information, it is argued that most benefit may be gained by taking steps to improve these daily logs which, in turn, will allow better overviews of progress to be produced. Journal: Construction Management and Economics Pages: 375-382 Issue: 3 Volume: 17 Year: 1999 Keywords: Site Procedures, Supervisor's Functions, Claims, Progress Records, X-DOI: 10.1080/014461999371574 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371574 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:3:p:375-382 Template-Type: ReDIF-Article 1.0 Author-Name: Hisham Gaafar Author-X-Name-First: Hisham Author-X-Name-Last: Gaafar Author-Name: John Perry Author-X-Name-First: John Author-X-Name-Last: Perry Title: Strategies for insuring subcontracted works Abstract: In the UK construction industry there are different strategies used in practice for the insurance of subcontracted work of which two predominate: one is for subcontracted work to be insured by both main contractor and subcontractor (model A) and the other is for only the main contractor to insure the subcontracted work (model B). The extent of use of these approaches is discussed and the rationales for them are presented in the context of research undertaken by questionnaire surveys and structured interviews. The paper provides a background to the requirements for subcontractor insurance found in commonly used forms of contract, including FIDIC. Four possible models of subcontractor insurance are identified and their relationships to the contract provisions in model forms is outlined. Two of the models have little practical relevance to subcontractor insurance and the reasons for this are given. About 75% of the main contractors in the research sample were found to adopt model A for all disciplines, although the reasons given were not entirely consistent. About 15% of the sample adopt model B for all disciplines and the remainder use different models for different disciplines. Again, the rationales for these choices were not found to be robust. The main conclusions are first that the choice of strategy for subcontractor insurance is highly independent of both the discipline and the selected form of subcontract, and second that some commercial decisions in this area may be sub-optimal. There is an unreconciled argument over the immediate commercial advantages claimed by many for model A and the potential for longer term reduction in insurance costs which might arise from the widespread adoption of model B. Journal: Construction Management and Economics Pages: 383-391 Issue: 3 Volume: 17 Year: 1999 Keywords: Subcontractor, Insurance, Works, Form Of Contract, Discipline, X-DOI: 10.1080/014461999371583 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371583 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:3:p:383-391 Template-Type: ReDIF-Article 1.0 Author-Name: Russell Kenley Author-X-Name-First: Russell Author-X-Name-Last: Kenley Title: Cash farming in building and construction: a stochastic analysis Abstract: Cash flow management is a significant issue in the management of a building or construction firm. This paper steps back from the well researched area of poor cash management and its relationship with failure, to focus on the funds which are generated through operations, and the positive benefits which can follow in a well managed organization. A stochastic model is developed which illustrates how an average of 16% of turnover can be available for reinvestment. This is sufficient to allow investment in non-liquid assets, provided that this is managed carefully and precautions are taken against a severe reduction in turnover. This level of funds is sufficient to encourage firms to enter the industry with the motivation of generating funds, rather than a desire to build. This has implications for large clients and for government when dealing with the industry. Journal: Construction Management and Economics Pages: 393-401 Issue: 3 Volume: 17 Year: 1999 Keywords: Cash Farming, Liquidity, Net Cash Flow, Stochastic Modelling, Monte Carlo, X-DOI: 10.1080/014461999371592 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371592 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:3:p:393-401 Template-Type: ReDIF-Article 1.0 Author-Name: Ranko Bon Author-X-Name-First: Ranko Author-X-Name-Last: Bon Author-Name: Rachael Luck Author-X-Name-First: Rachael Author-X-Name-Last: Luck Title: Outsourcing of property-related management functions in Europe and North America, 1993-1998 Abstract: The annual survey of corporate real estate practices in Europe and North America conducted by the Corporate Real Estate Management Research Unit at the University of Reading and Johnson Controls Incorporated includes information on outsourcing trends of several property-related management functions-design, construction, facilities, and maintenance management. The visual inspection of responses would suggest a gradual trend away from outsourcing, but the statistical tests indicate a significant increase only in in-house construction management function, and only for the period between 1993 and 1994. There are no significant trends in any of the four functions for the remaining period through 1998. However, the survey shows also that these management functions are interrelated. That is, when an organization undertakes one of these functions it is likely that they will perform the others in-house as well. Finally, the shift towards in-house construction management seems to reflect a wider trend away from outsourcing. Journal: Construction Management and Economics Pages: 409-412 Issue: 4 Volume: 17 Year: 1999 Keywords: Corporate Real Estate Management, Facilities Management, Outsourcing, X-DOI: 10.1080/014461999371321 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371321 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:4:p:409-412 Template-Type: ReDIF-Article 1.0 Author-Name: Ezekiel Chinyio Author-X-Name-First: Ezekiel Author-X-Name-Last: Chinyio Author-Name: Paul Olomolaiye Author-X-Name-First: Paul Author-X-Name-Last: Olomolaiye Title: A needs based methodology for classifying construction clients and selecting contractors-a rejoinder Abstract: Our original article (Chinyio et al., 1998a) 'A needs based methodology for classifying construction clients and selecting contractors', Construction Management and Economics, 16 (1), 91-98 discussed the empirical classification of construction clients and illustrated a new methodology for selecting contractors. The techniques we adopted have not been applied in a construction scenario before and thus their implementation may face teething difficulties as differences between construction and the disciplines from which the techniques were adopted are ironed out. Due to brevity we did not highlight some of the potential problems their implementation would encounter, as we could not explain everything on the subject matters in one article. Skitmore and Mills (1999) in a comment, Construction Management and Economics, 17 (1), 5-7, highlighted some anticipated difficulties and posed some insightful questions concerning the applicability of our concepts. From an optimistic perspective we have addressed most of the sundry issues raised by Skitmore and Mills wherein 'Decision Analysis' was reviewed as a basis for responding to the comments. Journal: Construction Management and Economics Pages: 413-417 Issue: 4 Volume: 17 Year: 1999 Keywords: Classification, Clients, Tender Evaluation, Scaling, Briefing, Decision-making, X-DOI: 10.1080/014461999371330 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371330 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:4:p:413-417 Template-Type: ReDIF-Article 1.0 Author-Name: Roberto Pietroforte Author-X-Name-First: Roberto Author-X-Name-Last: Pietroforte Author-Name: Piero Tangerini Author-X-Name-First: Piero Author-X-Name-Last: Tangerini Title: From boom to bust: the case of Italian construction firms Abstract: The characteristics of the Italian construction market and firm operations are reviewed. The analysis focuses on the environments of the late 1980s and early 1990s, during which major scandals and economic recession ended a business paradigm based on closed competition. Discussion builds upon a study of the market positioning of the 50 largest firms during the period under consideration that reflects the state industrial policy over the years. Long term transformations of the market require firms to develop new organizational capabilities and to shift their corporate focus from a production to a service orientation in order to remain competitive. Journal: Construction Management and Economics Pages: 419-425 Issue: 4 Volume: 17 Year: 1999 Keywords: Contracting System, Italy, Construction Firms, Competitive Environments, Public Procurement, Market Positioning, X-DOI: 10.1080/014461999371349 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371349 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:4:p:419-425 Template-Type: ReDIF-Article 1.0 Author-Name: I. D. Cox Author-X-Name-First: I. D. Author-X-Name-Last: Cox Author-Name: J. P. Morris Author-X-Name-First: J. P. Author-X-Name-Last: Morris Author-Name: J. H. Rogerson Author-X-Name-First: J. H. Author-X-Name-Last: Rogerson Author-Name: G. E. Jared Author-X-Name-First: G. E. Author-X-Name-Last: Jared Title: A quantitative study of post contract award design changes in construction Abstract: The investigation reported forms part of a wider study into the applicability of design for manufacture (DFM) thinking to the total construction process, and the ways in which this could be implemented. Historical data from change order request procedures were examined for several case studies which were considered to be successful projects. These procedures are intended to capture information about design modifications, and thus can be considered to be analogous to the rework procedures used in manufacturing. It was found that in monetary terms alone, the direct cost of post contract design changes amounts to 5.1-7.6% of the total project cost. Although the case studies used here were a convenience sample, the typical financial opportunity for controlling design changes better is likely to be considerably greater than this. Frequently cited reasons for design changes included: employer has changed his requirements, designer's omission in tender documents and new information on existing site conditions. Little commonality between case studies was found at the work package level. In contrast to manufacturing, the availability and accessibility of data relating to rework is problematic. Journal: Construction Management and Economics Pages: 427-439 Issue: 4 Volume: 17 Year: 1999 Keywords: Design For Manufacture Dfm, Design Changes, Change Order, Design, Process Mapping, X-DOI: 10.1080/014461999371358 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371358 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:4:p:427-439 Template-Type: ReDIF-Article 1.0 Author-Name: Terry Williams Author-X-Name-First: Terry Author-X-Name-Last: Williams Title: Allocation of contingency in activity duration networks Abstract: This paper describes a method for apportioning contingency in a probabilistic network. It distinguishes between two requirements for contingency: for high variance crucial activities, and for high float noncritical activities. This enables a logical two-step apportionment, the first based upon the idea of 'cruciality', which has become established as an important indicator of an activity's importance in risk terms, and the second based upon standard ideas about float. A numerical example is given based on data used by previous work, so that a comparison of the methods can be made. Journal: Construction Management and Economics Pages: 441-447 Issue: 4 Volume: 17 Year: 1999 Keywords: Network Analysis, Stochastic Networks, Construction Planning, Cpm, Contingency, X-DOI: 10.1080/014461999371367 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371367 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:4:p:441-447 Template-Type: ReDIF-Article 1.0 Author-Name: Alan Tan Tong Kein Author-X-Name-First: Alan Tan Tong Author-X-Name-Last: Kein Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Author-Name: Cle Briffett Author-X-Name-First: Cle Author-X-Name-Last: Briffett Title: ISO 14000: Its relevance to the construction industry of Singapore and its potential as the next industry milestone Abstract: ISO 14000 is a series of standards defining a formal and structured approach to environmental management. It demonstrates, with assurance, that an organization which complies with current policy and legislation actively addresses environmental issues. Construction activities have a myriad of environmental implications. Hence, construction entities must manage their environmental performance. ISO 14000 represents a possible solution. This study considers the relevance of environmental management to construction organizations. After an overview of the environmental impacts of construction, ISO 14000 and its principles are explored. A field study is reported that was set up to assess the level of commitment of construction enterprises in Singapore to environmental management. Contractors in Singapore are aware of the merits of environmental management, but are not instituting systems towards achieving it. A framework for the development and implementation of an environmental management system (EMS) is proposed. Journal: Construction Management and Economics Pages: 449-461 Issue: 4 Volume: 17 Year: 1999 Keywords: Construction Industry, Environmental Management, Iso 14000, Implementation, Singapore, X-DOI: 10.1080/014461999371376 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371376 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:4:p:449-461 Template-Type: ReDIF-Article 1.0 Author-Name: Jonathan Jingsheng Shi Author-X-Name-First: Jonathan Jingsheng Author-X-Name-Last: Shi Title: A neural network based system for predicting earthmoving production Abstract: An artificial neural network based system (NN earth) is developed for construction practitioners as a simple tool for predicting earthmoving operations, which are modelled by back propagation neural networks with four expected parameters and seven affecting factors. These networks are then trained using the data patterns obtained from simulation because there are insufficient data available from industrial sources. The trained network is then incorporated as the computation engine of NN earth. To engender confidence in the results of neural computation, a validation function is implemented in NN earth to allow the user to apply the engine to historic cases prior to applying it to a new project. An equipment database is also implemented in NN earth to provide default information, such as internal cost rate, fuel cost, and operator's cost. User interfaces are developed to facilitate inputting project information and manipulating the system. The major functions and use of NN earth are illustrated in a sample application. In practice, NN earth can assist the user either in selecting a crew to minimize the unit cost of a project or in predicting the performance of a given crew. Journal: Construction Management and Economics Pages: 463-471 Issue: 4 Volume: 17 Year: 1999 Keywords: Artificial Neural Networks, Back Propagation, Earthmoving, Prediction, Simulation, Site Operations, X-DOI: 10.1080/014461999371385 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371385 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:4:p:463-471 Template-Type: ReDIF-Article 1.0 Author-Name: Chau Kwong Wing Author-X-Name-First: Chau Kwong Author-X-Name-Last: Wing Title: On the issue of plan shape complexity: plan shape indices revisited Abstract: Plan shape indices are based on the geometry of the plan shape rather than on empirical data, and are problematic as they embrace implicit assumptions that are not tested empirically nor justified theoretically. Empirical research using data in Hong Kong confirms that these plan shape indices are much poorer predictors of unit construction costs than the variables used to construct the indices. This study also develops a method for constructing a plan shape index that is free from the unjustified assumptions implicit in existing plan shape indices; it involves an empirical cost model. Different functional specifications of the cost models are tested. The result rejects the linear model and other special case models such as semi-log and log-linear models. However, the reciprocal model is not rejected. This result suggests that a linear plan shape index can predict the amount of floor area that can be constructed with a fixed sum of money better than the construction cost per floor area. Journal: Construction Management and Economics Pages: 473-482 Issue: 4 Volume: 17 Year: 1999 Keywords: Building Cost Models, Box-cox Transformation, Construction Cost, Design Variables, Plan Shape, X-DOI: 10.1080/014461999371394 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371394 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:4:p:473-482 Template-Type: ReDIF-Article 1.0 Author-Name: L. M. Swaffield Author-X-Name-First: L. M. Author-X-Name-Last: Swaffield Author-Name: C. L. Pasquire Author-X-Name-First: C. L. Author-X-Name-Last: Pasquire Title: Examination of relationships between building form and function, and the cost of mechanical and electrical services Abstract: This paper describes analysis work undertaken to examine relationships between building function, building form and mechanical and electrical services cost, including the collection of raw data, and the transformation work undertaken to enable analysis. Relationships are identified between building form parameters, e.g. perimeter of external walls, gross floor area, storey heights, percentage of glazing, and the mechanical and electrical services costs for buildings of different functions (commercial, industrial and residential). There are relationships between the costs of the mechanical and electrical services installations and some building form descriptors, but the particular descriptors and the strength of the relationships vary according to the function of the building. Journal: Construction Management and Economics Pages: 483-492 Issue: 4 Volume: 17 Year: 1999 Keywords: Mechanical And Electrical Services, Tender Cost, Cost Planning, Building Function, Building Form, X-DOI: 10.1080/014461999371402 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371402 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:4:p:483-492 Template-Type: ReDIF-Article 1.0 Author-Name: Serdar Kale Author-X-Name-First: Serdar Author-X-Name-Last: Kale Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Title: Age-dependent business failures in the US construction industry Abstract: Age-dependent failure in the construction industry is explored over two 11-year periods (1973-1983 and 1984-1994) by analysing the age distribution of failed construction companies in each year and computing age-specific failure probabilities over a 10 year period (1985-1994). The conflicting perspectives of organizational theory are reconciled by taking advantage of the complementary nature of the adaptationist and organizational ecology theories while the effects of the characteristics of the construction industry are also considered. The research findings reveal an age-dependent business failure pattern in the US construction industry where the risk of failure increases initially with increasing age, reaches a peak point and decreases thereafter as companies grow older. Newness of a construction company which implies lack of organizational learning and lack of legitimacy, appears to be the main factor explaining this pattern. Journal: Construction Management and Economics Pages: 493-503 Issue: 4 Volume: 17 Year: 1999 Keywords: Construction Company, Business Failure, Adaptation, Inertia, Learning, Legitimacy, X-DOI: 10.1080/014461999371411 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371411 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:4:p:493-503 Template-Type: ReDIF-Article 1.0 Author-Name: P. E. D. Love Author-X-Name-First: P. E. D. Author-X-Name-Last: Love Author-Name: P. Mandal Author-X-Name-First: P. Author-X-Name-Last: Mandal Author-Name: H. Li Author-X-Name-First: H. Author-X-Name-Last: Li Title: Determining the causal structure of rework influences in construction Abstract: One of the most perplexing issues facing organizations in the construction industry is their inability to become quality focused. As a result sub-standard products and services often emanate, which inadvertently result in rework. Typically, rework is caused by errors made during the design process. These errors appear downstream in the procurement process and therefore have a negative impact on a project's performance. The lack of attention to quality, especially during the design process, has meant that rework has become an inevitable feature of the procurement process, and the costs have been found to be as high as 12.4% of total project costs. Such costs could be even higher because they do not represent schedule delays, litigation costs and other intangible costs of poor quality. To reduce the cost and effect of rework, an understanding of its causal structure is needed so that effective prevention strategies can be identified and the effects of rework reduced or eliminated. A case study approach based upon deductive and inductive reasoning is used to identify the major factors that influence rework in projects. From the findings and with reference to recent literature, the concept of system dynamics is used to develop a series of influence diagrams, which are then integrated to develop a conceptual causal loop model that is used to determine the overall causal structure of rework. Once an understanding of the causal structure of rework events has been acquired, effective strategies for rework prevention can be designed and implemented in order to improve project performance. This paper contributes to study of quality in construction by capturing the complexity and dynamism of those factors that influence rework and project performance in a holistic manner. Journal: Construction Management and Economics Pages: 505-517 Issue: 4 Volume: 17 Year: 1999 Keywords: Quality Management, Rework, System Dynamics, Causal Loop Diagramming, X-DOI: 10.1080/014461999371420 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371420 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:4:p:505-517 Template-Type: ReDIF-Article 1.0 Author-Name: Aviad Shapira Author-X-Name-First: Aviad Author-X-Name-Last: Shapira Author-Name: Clifford Schexnayder Author-X-Name-First: Clifford Author-X-Name-Last: Schexnayder Title: Selection of mobile cranes for building construction projects Abstract: The complicated process of selecting cranes for construction projects can be divided roughly into two main phases: (1) a general decision on the type of crane, mobile or tower; and (2) selection of the particular model according to the required size and technical specification. Several determinants of this second phase of the selection process in a typical mobile crane culture were investigated through on-site interviews with representatives of major construction companies. Factors affecting mobile crane selection were identified, classified, and rated according to their degree of influence. The involvement in equipment planning and crane selection was characterized with regard to project stages and planning parties. The findings were analysed with a view to the changing participation level of each party throughout project life. The conclusions of the study portray a picture that is different from the common assumptions about mobile crane selection, with respect to both influencing factors and the process itself. The study underlines the weight of non-project-specific factors, and shows that equipment planning is not merely a one-time technical exercise executed by a planner, but rather a process carried out throughout project life by a joint effort of several parties. Journal: Construction Management and Economics Pages: 519-527 Issue: 4 Volume: 17 Year: 1999 Keywords: Building Construction, Crane Selection, Equipment Planning, Mobile Cranes, Planning Parties, X-DOI: 10.1080/014461999371439 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371439 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:4:p:519-527 Template-Type: ReDIF-Article 1.0 Author-Name: Goran Runeson Author-X-Name-First: Goran Author-X-Name-Last: Runeson Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: Gate-keepers or judges: peer reviews in construction management Abstract: Peer review has a momentous influence upon the lives of those who seek to publish, upon the credibility of an academic discipline and upon the way it develops. It is used widely within the academic community on the assumption that it encourages high standards of scholarly writing by providing an informed, fair, reasonable and professional opinion about the merits of research work. This paper reports an experiment which tested the extent to which peer review in construction management serves this function. The results indicate that the outcome of the peer review process is not significantly different from random, and that there is little consistency in the reasons advanced for rejection or revision. Journal: Construction Management and Economics Pages: 529-536 Issue: 4 Volume: 17 Year: 1999 Keywords: Peer Review, Publication, Research, Construction Management, X-DOI: 10.1080/014461999371448 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371448 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:4:p:529-536 Template-Type: ReDIF-Article 1.0 Author-Name: Ranko Bon Author-X-Name-First: Ranko Author-X-Name-Last: Bon Author-Name: Talat Birgonul Author-X-Name-First: Talat Author-X-Name-Last: Birgonul Author-Name: Irem Ozdogan Author-X-Name-First: Irem Author-X-Name-Last: Ozdogan Title: An input-output analysis of the Turkish construction sector, 1973-1990: a note Abstract: Using the four input-output tables compiled in Turkey to date, the aim of this paper is to examine the construction sector's role in the Turkish economy and analyse its relationships with the other sectors of the national economy. Analysis results show that the share of construction in Gross National Product (GNP) and National Income (NI) tend to increase whereas the GNP share of manufacturing is relatively stable and that of services tend to increase after an abrupt decrease in 1985; backward linkage indicators and output multipliers, as well as forward linkage indicators and input multipliers of construction industry are stable; and finally, direct and total construction inputs from manufacturing show relative stability and those from services tend to increase in recent years. These findings point out the similarities between the Turkish construction industry and some advanced industrial countries (AICs) like Japan and Italy showing signs of growing 'maturity' of the Turkish economy. Journal: Construction Management and Economics Pages: 543-551 Issue: 5 Volume: 17 Year: 1999 Keywords: Input-output Analysis, Backward Forward Linkage Indicators, Output And Input Multipliers, Turkish Construction Sector, X-DOI: 10.1080/014461999371169 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371169 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:5:p:543-551 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: International construction management research: cultural sensitivity in methodological design Abstract: The process of globalization is occurring in the research community as well as in the business community and it is increasingly likely that collaborative research across national boundaries will be undertaken. This paper is concerned with the problems inherent in this process. More specifically, it focuses upon data collection, conceiving it as an act of communication. Models of communication are used to investigate problems of interaction between researchers and respondents of different cultural backgrounds and to help in the identification of culturally sensitive methodological strategies. The paper concludes that current criticisms of construction management research methods, which are being presented from a global perspective, are more relevant outside a western context. Journal: Construction Management and Economics Pages: 553-561 Issue: 5 Volume: 17 Year: 1999 Keywords: Research, Methodology, Communication, International, Culture, X-DOI: 10.1080/014461999371178 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371178 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:5:p:553-561 Template-Type: ReDIF-Article 1.0 Author-Name: Huaming Zhai Author-X-Name-First: Huaming Author-X-Name-Last: Zhai Author-Name: Jeffrey Russell Author-X-Name-First: Jeffrey Author-X-Name-Last: Russell Title: Stochastic modelling and prediction of contractor default risk Abstract: The purpose of this paper is to describe a systematic framework of stochastic modelling and prediction of financial default risk of construction contractors. Net-worth-to-asset ratio is identified as an index for default process modelling. The default condition is defined as when the ratio becomes negative the first time. A mean-reverting dynamic model for the contractor default process is found by statistical analysis and is justified by using the theory of optimal capital structure. The stochastic modelling of default uses the time to default as the fundamental random variable. A discrete time trinomial Markov chain model is developed to assess default risk in terms of a cumulative default probability function, a default probability function, and the mean and variance of time to default. Practical examples are given to illustrate the stochastic methods. A default discriminant study on a group of contractors and publicly traded companies validates the methods, and indicates a high predictability of events of default and declines of credit rating. Journal: Construction Management and Economics Pages: 563-576 Issue: 5 Volume: 17 Year: 1999 X-DOI: 10.1080/014461999371187 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371187 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:5:p:563-576 Template-Type: ReDIF-Article 1.0 Author-Name: D. G. Proverbs Author-X-Name-First: D. G. Author-X-Name-Last: Proverbs Author-Name: G. D. Holt Author-X-Name-First: G. D. Author-X-Name-Last: Holt Author-Name: P. O. Olomolaiye Author-X-Name-First: P. O. Author-X-Name-Last: Olomolaiye Title: Construction resource/method factors influencing productivity for high rise concrete construction Abstract: Research among European countries had confirmed variance in productivity rates ascribed by construction planning engineers for identical operations. Similar differences in planned construction resource/method factors also had been identified. It is hypothesized that such variance may be due to differences in contractor preference, resulting from socio-economic and corporate objective impacts. Analysis of variance and correlation tests are used to examine this hypothesis on data obtained from French, German and UK contractors. Numerous construction resource/method factors are tested for their impact on mean productivity rates for principal high rise in situ concrete construction operations. Significant productivity rate variations are identified for reinforcement fixing and formwork erection, while variance in concrete placing productivity rates are not found to be dependent upon construction resource/method factors. Contractors seeking to improve productivity might wish to consider solutions for construction resource/method decisions that have been found herein to be related to higher productivity rates and (in some cases) lower costs. Journal: Construction Management and Economics Pages: 577-587 Issue: 5 Volume: 17 Year: 1999 Keywords: Productivity Rates, In Situ Concrete Work, Resource Utilization, Construction Methods, High Rise Construction, X-DOI: 10.1080/014461999371196 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371196 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:5:p:577-587 Template-Type: ReDIF-Article 1.0 Author-Name: Ka Chi Lam Author-X-Name-First: Ka Chi Author-X-Name-Last: Lam Author-Name: Goran Runeson Author-X-Name-First: Goran Author-X-Name-Last: Runeson Title: Modelling financial decisions in construction firms Abstract: Some contractors predict their corporate cash flow on the basis of individual contracts without considering the relationships between the overall before-tax profit, risks, other crucial qualitative factors, or the allocation of resources within the company. Moreover, some contractors, in predicting their cash flow, focus only on the early-start progress in the project and their predictions of progress are too pessimistic, or result in the overuse of resource in order to make up for delays. In the present research a decision model is established for a contracting firm. It provides a methodical system for construction financial decision-making, and a way of solving a financial decision problem under qualitative and fuzzy circumstances. The model can be applied to the management of corporate cash flow, thereby facilitating the minimal use of resources. The information provided by the model allows the planner to eliminate excess use or idleness of resources during the scheduling of a project. Financial forecasting may also suggest the best time to invest in a new project. Four projects for a medium size construction firm in Hong Kong were employed as case studies in order to evaluate the mathematical model. The cases involve two objectives: maximize profit margin and minimize construction risk (consider in a qualitative factor). The model leads to a compromise optimal schedule that provides the contracting firm with the optimal schedule for achieving optimal profit and construction risk by making optimal use of the contractor's resources. Journal: Construction Management and Economics Pages: 589-602 Issue: 5 Volume: 17 Year: 1999 Keywords: Fuzzy, Qualitative, Multiple-objectives, Cash Flow, Optimization, X-DOI: 10.1080/014461999371204 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371204 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:5:p:589-602 Template-Type: ReDIF-Article 1.0 Author-Name: Wei Lo Author-X-Name-First: Wei Author-X-Name-Last: Lo Author-Name: Raymond Krizek Author-X-Name-First: Raymond Author-X-Name-Last: Krizek Author-Name: Ahmad Hadavi Author-X-Name-First: Ahmad Author-X-Name-Last: Hadavi Title: Effects of high prequalification requirements Abstract: When designing a set of prequalification requirements, the first objective is to select the basic factors that are deemed appropriate to scrutinize, and the second objective is to establish the threshold for each of these factors to evaluate the capability and capacity of the bidders on a given project; together, these factors and the limits imposed on each constitute the basis for qualifying or disqualifying each of the bidders. To obtain the desired prequalification results and the consequent quality delivery of a project, both selecting the factors and determining the limits for each factor are crucial and must be given careful attention with due consideration of the prevailing environment (including market conditions, deadlines, need for technology transfer, etc.). In this study it was found that an improper design of prequalification requirements seriously affected the progress and cost of projects, provided opportunities for collusion, and encouraged the obtaining of contracts through improper practices. Based on an analysis of data from 30 Taipei Mass Rapid Transit projects, together with information gleaned from numerous interviews with contractors, consultants, and clients, it is shown that a risk-taking attitude by the Government and the establishment of relatively low prequalification requirements would be more conducive to achieving a desirable balance among (a) satisfying the schedule and sequence of contracting, (b) obtaining lower prices by an increase in competition, (c) procuring the timely delivery of a quality project, and (d) fostering the growth of local contractors. Journal: Construction Management and Economics Pages: 603-612 Issue: 5 Volume: 17 Year: 1999 Keywords: Prequalification Requirements, Taipei Mass Rapid Transit, Economic Development, Government Policies, Growth Of Local Contractors, X-DOI: 10.1080/014461999371213 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371213 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:5:p:603-612 Template-Type: ReDIF-Article 1.0 Author-Name: Malik Ranasinghe Author-X-Name-First: Malik Author-X-Name-Last: Ranasinghe Title: Private sector participation in infrastructure projects: a methodology to analyse viability of BOT Abstract: Many developing countries are now attempting to finance new infrastructure projects through private sector participation. This paper outlines a methodology based on financial and risk analyses that a government or a government utility can use to analyse the viability of private sector participation in new infrastructure projects. The water supply projects in Sri Lanka are used for the case study to outline the methodology. Financial analyses of a bulk water supply project and a water distribution project are carried out to estimate subsidy percentages that are required to make the projects viable, using a model developed for the investment analysis of all types of infrastructure project. This analysis looks at four pricing options for the bulk supply project, and sixteen procurement options for the distribution project, from the view point of the utility, for three cases of non-revenue water (35% as base case, 50% and 25% as extreme cases). The risk analysis takes into account the risk and uncertainty in non-revenue water, cost and demand estimates, rate of debt and forecasts of escalation. These analyses show that the best option for the utility is to obtain both bulk supply and distribution projects through private sector participation using BOT arrangements. Journal: Construction Management and Economics Pages: 613-623 Issue: 5 Volume: 17 Year: 1999 Keywords: Infrastructure, Bot, Financial Analysis, Risk Analysis, Water Supply, Utility, Investments, Developing Countries, X-DOI: 10.1080/014461999371222 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371222 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:5:p:613-623 Template-Type: ReDIF-Article 1.0 Author-Name: Raymond Tse Author-X-Name-First: Raymond Author-X-Name-Last: Tse Author-Name: C. W. Ho Author-X-Name-First: C. W. Author-X-Name-Last: Ho Author-Name: S. Ganesan Author-X-Name-First: S. Author-X-Name-Last: Ganesan Title: Matching housing supply and demand: an empirical study of Hong Kong's market Abstract: This paper has the objective of improving on the issue of forecasting new housing construction, and highlights differences between space demand and investment demand in housing markets. Further, it indicates how these differences will affect construction decisions. The first step is to identify the factors associated with estimating residential property prices in Hong Kong, based on a demand-supply adjustment process. Specifically, this study examines the role of population growth, transaction volume, inflation and interest rate in determining house prices. Second, based on these estimations, a methodology is developed to estimate the investment demand schedule and new construction of residential property. Journal: Construction Management and Economics Pages: 625-633 Issue: 5 Volume: 17 Year: 1999 Keywords: Construction, Transaction Volume, Housing Demand, House Price, Hong Kong, X-DOI: 10.1080/014461999371231 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371231 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:5:p:625-633 Template-Type: ReDIF-Article 1.0 Author-Name: John Gunner Author-X-Name-First: John Author-X-Name-Last: Gunner Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Comparative analysis of pre-bid forecasting of building prices based on Singapore data Abstract: An analysis is described of a sample of pre-bid forecasts for 181 Singapore building contracts awarded between 1980 and 1991 in comparison with previous research results in this topic. Despite the apparent contradictions that occur between findings, it is shown that such differences could be illusionary due to a general lack of reported significance levels together with, in some cases, small sample sizes. As a result it is suggested that a general commonality in outcomes may exist in the form of a single underlying variable. Journal: Construction Management and Economics Pages: 635-646 Issue: 5 Volume: 17 Year: 1999 Keywords: Accuracy, Building, Estimating, Pre-bid Estimates, Statistical Analysis, X-DOI: 10.1080/014461999371240 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371240 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:5:p:635-646 Template-Type: ReDIF-Article 1.0 Author-Name: Mohammed Al-Khalil Author-X-Name-First: Mohammed Author-X-Name-Last: Al-Khalil Author-Name: Mohammed Al-Ghafly Author-X-Name-First: Mohammed Author-X-Name-Last: Al-Ghafly Title: Important causes of delay in public utility projects in Saudi Arabia Abstract: This study was conducted to determine the most important causes of delay in public utility projects, based on the frequency and severity of the causes. A survey of randomly selected samples of contractors, consultants, and owners was carried out to assess the frequency of occurrence and the severity of impact of sixty potential delay causes. A frequency index and a severity index were determined for each cause. An importance index for each cause was then computed as the product of the frequency and severity indices. The results showed that the three parties surveyed generally agree on the importance ranking of delay causes. The causes were grouped also into six major categories of delay. The analysis showed lack of agreement among the parties on the ranking of the major categories of delay. Journal: Construction Management and Economics Pages: 647-655 Issue: 5 Volume: 17 Year: 1999 Keywords: Claims, Delay, Utility Projects, Time, Saudi Arabia, X-DOI: 10.1080/014461999371259 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371259 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:5:p:647-655 Template-Type: ReDIF-Article 1.0 Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Author-Name: Mok Sze Hui Author-X-Name-First: Mok Sze Author-X-Name-Last: Hui Title: The application of JIT philosophy to construction: a case study in site layout Abstract: The just-in-time (JIT) philosophy has been used in the manufacturing industry for some forty to fifty years. This system increased not only the productivity of the industry but also the quality of its products. Explorative studies have been completed in recent years to see how JIT can be applied into the construction industry to reap the benefits of the system. Most of these studies have concluded that it is possible to apply the techniques of JIT in the construction industry with some modifications. Taking into consideration that one of the key components of site management is concerned with waste management (i.e. bringing wastage down to the minimum), this study focuses on applying JIT for site layout to improve productivity and quality. By eliminating waste on site, controlling the movement of inventory coming into the site and within the site, and controlling the usage of mechanized plant and equipment, smooth work flow can be achieved. Journal: Construction Management and Economics Pages: 657-668 Issue: 5 Volume: 17 Year: 1999 Keywords: Just-in-time;Construction Management;Site Layout;Productivity;Quality, X-DOI: 10.1080/014461999371268 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371268 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:5:p:657-668 Template-Type: ReDIF-Article 1.0 Author-Name: John Miller Author-X-Name-First: John Author-X-Name-Last: Miller Author-Name: Roger Evje Author-X-Name-First: Roger Author-X-Name-Last: Evje Title: The practical application of delivery methods to project portfolios Abstract: The rebirth of design-build, design-build-operate, and build-operate-transfer as viable alternatives for the delivery of major capital projects is symptomatic of dynamic changes in the relationship between producers and clients throughout the construction industry. In the private sector, these delivery methods offer clients the chance to shift emphasis towards core functions and away from real estate development and operations. In the public sector, where capital budgets are constrained, delivery alternatives offer clients the chance to combine construction skills and technology to meet infrastructure needs in innovative ways. However, for those clients with numerous facilities and a steady flow of projects over long periods of time, a critical problem is emerging: how to effectively match each project in the portfolio to a preferred delivery method. This paper presents a tool called CHOICES©™, which permits convenient comparisons of alternative delivery scenarios for a portfolio of capital projects and services. CHOICES©™ is designed to help formulate a portfolio infrastructure strategy, test that strategy, and adjust it to meet strategic goals within capital constraints. Journal: Construction Management and Economics Pages: 669-677 Issue: 5 Volume: 17 Year: 1999 Keywords: Portfolio Management, Project Delivery Methods, Procurement, Choices Tm, X-DOI: 10.1080/014461999371277 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371277 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:5:p:669-677 Template-Type: ReDIF-Article 1.0 Author-Name: Jean Jinghan Chen Author-X-Name-First: Jean Jinghan Author-X-Name-Last: Chen Author-Name: David Chambers Author-X-Name-First: David Author-X-Name-Last: Chambers Title: Sustainability and the impact of Chinese policy initiatives upon construction Abstract: The environment has been perceived as an international issue, and ways of attaining sustainability are becoming important for countries seeking sustainable development. The international community has been active in developing policy frameworks towards achieving the sustainability, such as an ecological modernization approach and environment assessment. Developing countries deserve special attention in the effort to make sustainability an operative criterion in their development activities. Given the difficulties that developing countries are facing, their perceptions of the concept and principles of sustainability differ in various contexts from those of developed countries, and the attainment of sustainability is much more difficult. Therefore, the establishment of a global partnership is important for the vision of sustainability to be realized and operationalized in the world. The current stage of economic development in China provides an opportunity to incorporate environmental provisions into the national development strategies from a relatively early stage, rather than attempt retrofit to strategies. However, at present China's policy initiatives expressed in its Agenda 21 remains only a visionary concept. A comprehensive policy framework and realistic implementation measures are needed. The environmental impacts of the construction industry are extensive, particularly in developing countries. However, as in many developing countries, China's sustainable construction is still at its primary stage and current practice is unsatisfactory. Journal: Construction Management and Economics Pages: 679-687 Issue: 5 Volume: 17 Year: 1999 Keywords: Sustainable Development, Policy, Construction, China, X-DOI: 10.1080/014461999371286 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371286 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:5:p:679-687 Template-Type: ReDIF-Article 1.0 Author-Name: M. Loosemore Author-X-Name-First: M. Author-X-Name-Last: Loosemore Title: Responsibility, power and construction conflict Abstract: Responsibilities in construction projects are not entirely predetermined by construction contracts. Many emerge arbitrarily from the resolution of power struggles between opposing interest groups who are trying to minimize their exposure to an unexpected resourcing demand. These struggles contain the seeds of conflict because those with relatively little power tend to emerge with relatively high levels of responsibility. For the weak, this inequality causes financial strain, anxiety, resentment, frustration and malevolence. Journal: Construction Management and Economics Pages: 699-709 Issue: 6 Volume: 17 Year: 1999 Keywords: Conflict, Responsibility, Power, Risk, Authority, Contracts, Behaviour, X-DOI: 10.1080/014461999371042 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371042 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:6:p:699-709 Template-Type: ReDIF-Article 1.0 Author-Name: Neil Eldin Author-X-Name-First: Neil Author-X-Name-Last: Eldin Title: Impact of employee, management, and process issues on constructability implementation Abstract: This paper reports the findings of a study that examined five projects in which implementation of constructability concepts was viewed as a schedule reduction tool. The study attempted to determine the benefits, success factors, and implementation barriers across the case studies. The data suggested that adopting constructability concepts has the potential for significantly reducing the project delivery time compared with the historical performance of the participating companies. Success factors, implementation barriers, and lessons learned were viewed as management, employee, and process-related issues. These issues were ranked further according to their apparent significance in the cases studied. When such a ranking is verified by additional studies, the efforts of present and future implementations will focus on the issues that yield the highest payoffs. Journal: Construction Management and Economics Pages: 711-720 Issue: 6 Volume: 17 Year: 1999 Keywords: Constructability, Schedule Reduction Tools, Value Engineering, Project Management, Project Delivery, Time, Time To Market, Schedule Compression, X-DOI: 10.1080/014461999371051 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371051 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:6:p:711-720 Template-Type: ReDIF-Article 1.0 Author-Name: Awad Hanna Author-X-Name-First: Awad Author-X-Name-Last: Hanna Author-Name: Jeffrey Russell Author-X-Name-First: Jeffrey Author-X-Name-Last: Russell Author-Name: Paul Vandenberg Author-X-Name-First: Paul Author-X-Name-Last: Vandenberg Title: The impact of change orders on mechanical construction labour efficiency Abstract: Change orders impact many areas of a construction project. However, the impacts that change orders have on labour efficiency are much harder to quantify than other impacts and therefore are a significant risk to contractors. Little research has been completed in the past quantifying these impacts, so disputes are common between owners and contractors regarding the actual cost of change. This study used data from 43 projects to develop a linear regression model that predicts the impact of change orders on labour efficiency. The input factors needed for the model are (1) total actual project hours, (2) total estimated change hours, (3) impact classification, and (4) timing of change. The model calculates the labour loss in efficiency for a particular project so that owners and contractors will better understand the true impact of change on labour efficiency. The research is limited to the mechanical trade, but does include specific work in plumbing, HVAC, process piping, and fire protection. Journal: Construction Management and Economics Pages: 721-730 Issue: 6 Volume: 17 Year: 1999 Keywords: Labour Efficiency, Productivity, Impacts, Change Orders, Mechanical Contractors, X-DOI: 10.1080/014461999371060 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371060 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:6:p:721-730 Template-Type: ReDIF-Article 1.0 Author-Name: K. Yogeswaran Author-X-Name-First: K. Author-X-Name-Last: Yogeswaran Author-Name: M. M. Kumaraswamy Author-X-Name-First: M. M. Author-X-Name-Last: Kumaraswamy Title: To instruct or not? The engineer's dilemma Abstract: A recent research project explored the sources of relatively higher value and/or more frequent construction claims in civil engineering projects in Hong Kong. Fourteen common sources of claims were cited to seek views from the industry as to the perceived frequencies, magnitudes and avoidabilities of claims from such sources. One of the significant sources was identified as 'instructions not being issued', with reference to the provision in most standard civil engineering contracts that 'the engineer' shall issue necessary instructions for the purposes of completion of the Works. The study reported here focuses on the possible responses of 'the engineer' when the contractor requests instructions/information. Also the study examines the possible generation of construction claims therefrom. Eleven practitioners who were familiar with such matters were issued a questionnaire which described ten typical construction problem scenarios (cases) where contractors may request instructions. The responses are summarized and the basis for reaching each of these decisions is analysed. An example of the eleven detailed responses to one of the cases is presented to demonstrate the divergence of perceptions on each issue and the consequent different recommendations. Strategies to minimize the claims and disputes arising from such scenarios are developed, based on resolving the evident conflicts between the reasons for such divergences. Journal: Construction Management and Economics Pages: 731-743 Issue: 6 Volume: 17 Year: 1999 Keywords: Claims, Sources, Minimize, Instructions, Hong Kong, X-DOI: 10.1080/014461999371079 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371079 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:6:p:731-743 Template-Type: ReDIF-Article 1.0 Author-Name: A. H. Boussabaine Author-X-Name-First: A. H. Author-X-Name-Last: Boussabaine Author-Name: Taha Elhag Author-X-Name-First: Taha Author-X-Name-Last: Elhag Title: Applying fuzzy techniques to cash flow analysis Abstract: Construction managers are interested in the direction of movement of cash flow at valuation periods rather than its forecast value, and fuzzy set theory applied to decision making might help in this process. Fuzzy models are particularly suited to making decisions involving new technologies where uncertainties inherent in the situation are complex. The problem of healthy cash flow at valuation periods relates to the proper estimation of cash in and out flows and project progress. The paper presents an alternative approach to cash flow analysis for construction projects. This project is based on the assumption that cash flow at particular valuation stages of a project is ambiguous. The paper discusses the weaknesses of existing methods for cash flow and establishes the need for an alternative approach. Using an example of 30 cash flow curves, the advantage of fuzzy cash flow analysis is demonstrated. Results of the analysis are presented and discussed. The model can be used to analyse the cash flow curve of projects at any progress period to make sure it is reasonable. Journal: Construction Management and Economics Pages: 745-755 Issue: 6 Volume: 17 Year: 1999 Keywords: Fuzzy, Cash Flow, Valuation, Fuzzy Techniques, Progress, X-DOI: 10.1080/014461999371088 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371088 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:6:p:745-755 Template-Type: ReDIF-Article 1.0 Author-Name: Penny Brooker Author-X-Name-First: Penny Author-X-Name-Last: Brooker Title: Survey of construction lawyers' attitudes and practice in the use of ADR in contractors' disputes Abstract: Continuing a survey of contractors' perceptions about alternative dispute resolution (ADR) this paper seeks to report an investigation of the level of involvement of legal advisors to the construction industry in the dispute resolution process and the perceptions that legal professionals have about the use of ADR in construction disputes. The research findings are that contractors are likely to involve lawyers in the dispute resolution procedure, particularly when disputes concern a legal issue, when the parties to the dispute are entrenched in their argument, or when the other party insists on using legal professional assistance. In these defined circumstances, legal advisors will be influential in determining the potential use of ADR. The paper concludes that lawyers are unlikely to recommend ADR for most disputes between contractors, particularly if the dispute resolution process is perceived to involve the use of delay by main contractors, if the parties are fixed in their arguments or if they are exhibiting adversarial behaviour in their approach to the dispute. In these circumstances lawyers and their clients prefer the force of the formal systems over conciliatory ADR procedures. Journal: Construction Management and Economics Pages: 757-765 Issue: 6 Volume: 17 Year: 1999 Keywords: Alternative Dispute Resolution, Contractors, Dispute Resolution, Lawyers, X-DOI: 10.1080/014461999371097 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371097 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:6:p:757-765 Template-Type: ReDIF-Article 1.0 Author-Name: Sou-Sen Leu Author-X-Name-First: Sou-Sen Author-X-Name-Last: Leu Author-Name: Chung-Huei Yang Author-X-Name-First: Chung-Huei Author-X-Name-Last: Yang Title: A genetic-algorithm-based resource-constrained construction scheduling system Abstract: Resources for construction activities are limited in the real construction world. To avoid waste and shortage of resources on a construction jobsite, scheduling must include resource allocation. A new resourceconstrained construction scheduling system is proposed in this paper. A GA-based searching technique is adopted in the system. In this paper, new GA crossover and mutation operators, UX3 and UM3, are presented. These new operators overcome the drawback of traditional GA operators for sequencing problems. The system effectively can provide the optimal combination of construction duration, resource quantities and minimum project duration under the constraint of limited resources. Journal: Construction Management and Economics Pages: 767-776 Issue: 6 Volume: 17 Year: 1999 Keywords: Resource Constraint, Genetic Algorithms, Scheduling, Resource Allocation, Multiple-objective, Programming, X-DOI: 10.1080/014461999371105 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371105 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:6:p:767-776 Template-Type: ReDIF-Article 1.0 Author-Name: R. Roy Author-X-Name-First: R. Author-X-Name-Last: Roy Author-Name: S. P. Cochrane Author-X-Name-First: S. P. Author-X-Name-Last: Cochrane Title: Development of a customer focused strategy in speculative house building Abstract: The UK housing industry has been slow to adopt new working practices which have brought improvements in product quality and customer focused operations to many sectors of manufacturing industry. Instead, the dominant business driver has been land and house price inflation, with the market characterized by pronounced boom-and-bust cycles. Reports on the sector often have highlighted the need for research and action aimed at bringing about fundamental changes in its operations, both to satisfy social needs and benefit the companies in the industry. This paper examines the drivers needed for implementing new customer focused business processes in the sector. Of particular importance is the development of a product strategy based on an understanding and analysis of the market. Results are presented from a large market survey that was carried out, and their implications for the industry are discussed. Journal: Construction Management and Economics Pages: 777-787 Issue: 6 Volume: 17 Year: 1999 Keywords: House Building, Strategy, Product Development, Mass Customization, Market Research, X-DOI: 10.1080/014461999371114 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371114 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:6:p:777-787 Template-Type: ReDIF-Article 1.0 Author-Name: Campbell Fraser Author-X-Name-First: Campbell Author-X-Name-Last: Fraser Title: A non-results-based effectiveness index for construction site managers Abstract: A method is presented for non-results-based effectiveness indexing of construction site managers (CSMs). The 52 competence element index is based on previous research on construction-specific competency elements and stakeholder assessment systems. The method was qualitatively assessed through industry focus groups and quantitatively validated through an empirical study. The performance of 61 Australian CSMs was evaluated by 329 peers, superiors and subordinates. The measurement tool successfully measured each individual's level of ability on each competence element and produced an individual effectiveness score for each CSM. The application of the method resulted in the identification of three levels of effectiveness: a distinct and homogeneous 'elite' group of very effective CSMs; a very low performing control group of former CSMs; and a group of CSMs that are adequately effective. The development and validation of the method are provided, plus some insights into the characteristics of each of the groups identified. Journal: Construction Management and Economics Pages: 789-798 Issue: 6 Volume: 17 Year: 1999 Keywords: Site Managers, Effectiveness, Competence, Index, Stakeholders, X-DOI: 10.1080/014461999371123 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371123 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:6:p:789-798 Template-Type: ReDIF-Article 1.0 Author-Name: Abdulaziz Bubshait Author-X-Name-First: Abdulaziz Author-X-Name-Last: Bubshait Author-Name: Gulam Farooq Author-X-Name-First: Gulam Author-X-Name-Last: Farooq Author-Name: M. Osama Jannadi Author-X-Name-First: M. Osama Author-X-Name-Last: Jannadi Author-Name: Sadi Assaf Author-X-Name-First: Sadi Author-X-Name-Last: Assaf Title: Quality practices in design organizations Abstract: Design organizations play a major role in the construction industry: they are the media that transfer the requirements of the client to the contractor and ensure that they are met. Thus they need to provide a high quality of service to ensure that their client's project achieves the best possible standards of cost, time and quality. Seventy quality practices (QP) were identified as having a bearing on the quality of service provided by the local design organizations. These quality practices were grouped into fifteen sections termed quality sections (QS). The prevalence of these practices among the local design organizations was surveyed and determined. The results indicate a significant need for improvement in the quality sections 'working relationship', 'employee training and education', and 'performance quality audit'. The study reveals the need for the establishment of a design code, and evaluation standards for local design organizations. Journal: Construction Management and Economics Pages: 799-809 Issue: 6 Volume: 17 Year: 1999 Keywords: Design Organizations, Quality Practices, Saudi Arabia, X-DOI: 10.1080/014461999371132 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461999371132 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:17:y:1999:i:6:p:799-809 Template-Type: ReDIF-Article 1.0 Author-Name: G. J. Treloar Author-X-Name-First: G. J. Author-X-Name-Last: Treloar Author-Name: P. E. D. Love Author-X-Name-First: P. E. D. Author-X-Name-Last: Love Author-Name: O. O. Faniran Author-X-Name-First: O. O. Author-X-Name-Last: Faniran Author-Name: U. Iyer-Raniga Author-X-Name-First: U. Author-X-Name-Last: Iyer-Raniga Title: A hybrid life cycle assessment method for construction Abstract: Life cycle assessments (LCAs) are used to evaluate the environmental impacts attributable to products and processes. For construction projects, LCAs can be used to assess the pollution associated with the manufacture of building materials for the construction process. Despite the reliability of traditional LCA data, many upstream processes are excluded, which adversely affects overall reliability. Input-output analysis is systemically complete, but is subject to inherent errors when applied to the LCA of specific products. Analysis of an input-output LCA model provides a basis for more informed decision making regarding processes which can be ignored during the collection of traditional LCA data. This paper proposes a hybrid LCA method for construction in which national input-output data fill those 'gaps' not accounted for by traditional LCA data. Regardless of the level of detail at which data are collected, LCAs can now be performed at similar overall levels of framework completeness. Journal: Construction Management and Economics Pages: 5-9 Issue: 1 Volume: 18 Year: 2000 Keywords: Life Cycle Assessment, Input-output Analysis, Hybrid Lca, Construction, X-DOI: 10.1080/014461900370898 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370898 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:1:p:5-9 Template-Type: ReDIF-Article 1.0 Author-Name: Will Hughes Author-X-Name-First: Will Author-X-Name-Last: Hughes Author-Name: Patricia Hillebrandt Author-X-Name-First: Patricia Author-X-Name-Last: Hillebrandt Author-Name: John Murdoch Author-X-Name-First: John Author-X-Name-Last: Murdoch Title: The impact of contract duration on the cost of cash retention Abstract: Cash retention is a common means of protecting an employer from a contractor's insolvency as well as ensuring that contractors finish the work that they start. Similarly, contractors withhold part of payments due to their sub-contractors. Larger contracts tend to be subjected to smaller rates of retention. By calculating the cost of retention as an amount per year of a contract, it is shown that retention is far more expensive for firms whose work consists of short contracts. The extra cost is multiplied when the final payment is delayed, as it often is for those whose work takes place at the beginning of a project. This may explain why it is that main contractors are a lot less interested than sub-contractors in alternatives to cash retention, such as retention bonds. Journal: Construction Management and Economics Pages: 11-14 Issue: 1 Volume: 18 Year: 2000 Keywords: Bonds, Cash Flow, Contract, Finance, Retention, X-DOI: 10.1080/014461900370906 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370906 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:1:p:11-14 Template-Type: ReDIF-Article 1.0 Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Author-Name: Krishna Mochtar Author-X-Name-First: Krishna Author-X-Name-Last: Mochtar Title: Trends in productivity improvement in the US construction industry Abstract: Surveys of the top 400 US contractors were conducted in 1979, 1983 and 1993 to identify the areas with potential for productivity improvement in the construction industry. The trends in the findings of these surveys are observed and interpreted. The results indicate that cost control, scheduling, design practices, labour training, and quality control are the functions that consistently over the years are perceived as having considerable room for productivity improvement, whereas materials packaging and foreign developments in construction technologies are perceived consistently as functions that do not have much effect on improving construction productivity. The functions that were identified as needing more improvement in 1993 compared with the previous surveys were prefabrication, new materials, value engineering, specifications, labour availability, labour training, and quality control, whereas those that were identified as needing less improvement than in the previous surveys were field inspection and labour contract agreements. Also, respondents indicated consistently over the years that they are willing to participate in activities related to improving construction productivity but are not interested in funding any such activities. Journal: Construction Management and Economics Pages: 15-27 Issue: 1 Volume: 18 Year: 2000 Keywords: Construction Productivity, Construction Industry, Productivity Trends, Usa, X-DOI: 10.1080/014461900370915 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370915 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:1:p:15-27 Template-Type: ReDIF-Article 1.0 Author-Name: Campbell Fraser Author-X-Name-First: Campbell Author-X-Name-Last: Fraser Title: The influence of personal characteristics on effectiveness of construction site managers Abstract: It has been suggested that construction site managers' career progression may be affected because of the existence of certain personal characteristics that conform to industry stereotypes. These stereotypes need to be identified and examined in a systematic manner to ensure that the rationality of human resource management policy is indeed justifiable. A set of 26 personal characteristics believed to influence the effectiveness of construction site managers is identified by senior construction managers using the nominal group technique. These characteristics are tested for correlation with effectiveness using a non-results-based effectiveness index. A questionnaire survey was completed by 61 site managers for this purpose. The results suggest that of 26 identified personal factors believed to be important the only ones which may actually be related to effectiveness are: involvement in continuing professional development, number of firms worked for, use of addictive substances, education level, membership of professional bodies, job satisfaction, motivation level, career aspiration, stress level, leadership style and the need to work. The findings will assist those recruiting, retaining or promoting site managers to make a more informed judgement of key factors influencing effectiveness. Journal: Construction Management and Economics Pages: 29-36 Issue: 1 Volume: 18 Year: 2000 Keywords: Site Management, Effectiveness, Influences, Personal Characteristics, X-DOI: 10.1080/014461900370924 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370924 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:1:p:29-36 Template-Type: ReDIF-Article 1.0 Author-Name: Anthony Walker Author-X-Name-First: Anthony Author-X-Name-Last: Walker Author-Name: Robert Newcombe Author-X-Name-First: Robert Author-X-Name-Last: Newcombe Title: The positive use of power on a major construction project Abstract: Although reasonably well developed in the general management literature, the source and use of power in organizations has received little attention in relation to its effect on the management of construction projects. This paper reviews the literature on power and its relationship to both formal and informal authority, and its manifestation as organizational politics, and relates them to construction projects in general. Reward, coercive, expert and referent (prestige) power and the role of resources are covered in this general review. A closer examination is then made of power through a case study of the development of the Hong Kong University of Science and Technology, which identifies the positive use of power and its implications for the outcome of the project. Journal: Construction Management and Economics Pages: 37-44 Issue: 1 Volume: 18 Year: 2000 Keywords: Authority, Power, Project Organization, Hong Kong, Case Study, X-DOI: 10.1080/014461900370933 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370933 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:1:p:37-44 Template-Type: ReDIF-Article 1.0 Author-Name: Jae-Chan Kim Author-X-Name-First: Jae-Chan Author-X-Name-Last: Kim Author-Name: Dae-Ho Kim Author-X-Name-First: Dae-Ho Author-X-Name-Last: Kim Author-Name: Jae-Jun Kim Author-X-Name-First: Jae-Jun Author-X-Name-Last: Kim Author-Name: Jong-Suk Ye Author-X-Name-First: Jong-Suk Author-X-Name-Last: Ye Author-Name: Hyun-Soo Lee Author-X-Name-First: Hyun-Soo Author-X-Name-Last: Lee Title: Segmenting the Korean housing market using multiple discriminant analysis Abstract: The business environment of the Korean housing industry has changed recently from a supplier's market to a buyer's. Establishing and implementing proper marketing strategies has increasingly become an important part of the managerial process. This research attempts to offer a characteristics profile and a forecasting model that classify the housing purchase consumers into three groups: a single-family housing purchase group, an apartment housing purchase group, and a non-purchase group. These groups can be classified and predicted by using the discriminant function: a linear combination of demographic, socio-economic, and residential characteristics. Findings in this research can provide valuable information for future efforts in identifying distinct target segments of the Korean housing market. Journal: Construction Management and Economics Pages: 45-54 Issue: 1 Volume: 18 Year: 2000 Keywords: Korean Housing Industry, Market Segmentation, Target Marketing Strategy, Multiple Discriminant Analysis, X-DOI: 10.1080/014461900370942 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370942 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:1:p:45-54 Template-Type: ReDIF-Article 1.0 Author-Name: Naomi Garnett Author-X-Name-First: Naomi Author-X-Name-Last: Garnett Author-Name: Simone Pickrell Author-X-Name-First: Simone Author-X-Name-Last: Pickrell Title: Benchmarking for construction: theory and practice Abstract: The UK construction industry has identified benchmarking as one of a number of initiatives to assist in the drive for major improvements in efficiency and economy. At the outset, the industry struggled to see how a technique based upon comparison of similar goods and processes could be used effectively in a project based industry where products, processes and teams changed regularly. This paper discusses the development and testing of a benchmarking model and study methodology for use in construction. The model was derived from an extensive literature review which considered the underlying theoretical basis of benchmarking. The case is made that, to be successful, the benchmarking process is as important as the benchmarks themselves, and that it is based upon constructivist foundations, rather than positivist. As such, any methodology for undertaking benchmarking must take place in a similar vein, i.e. be interactive, team based and flexible but with an underlying rigour provided by the benchmarking model. The paper outlines two case studies to test the benchmarking model and study methodology, discusses the learning and benefits that accrued and introduces further developments. Journal: Construction Management and Economics Pages: 55-63 Issue: 1 Volume: 18 Year: 2000 Keywords: Benchmarking Methodology, Process Mapping, Case Studies, Social Constructivism, X-DOI: 10.1080/014461900370951 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370951 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:1:p:55-63 Template-Type: ReDIF-Article 1.0 Author-Name: David Edwards Author-X-Name-First: David Author-X-Name-Last: Edwards Author-Name: Gary Holt Author-X-Name-First: Gary Author-X-Name-Last: Holt Author-Name: Frank Harris Author-X-Name-First: Frank Author-X-Name-Last: Harris Title: A model for predicting plant maintenance costs Abstract: A model is presented that predicts the total cost of plant maintenance (i.e. direct cost of maintenance plus indirect cost of lost production) and is derived studying a random sample of tracked hydraulic excavators. Analysis is based on the machine history file data of 33 plant items, modelled using multiple regression (MR) analysis. Validation of the model was determined via the combination of an observed high R 2 at 0.94 and various statistical tests which confirmed the prerequisites of a rigorous MR analysis. Machine weight, type of industry and company attitude towards predictive maintenance were found to be the best predictor variables of total plant maintenance cost. The paper also discusses reasons underlying the inclusion of predictor variables in the final model, and concludes with clear directions for future research in this field. Journal: Construction Management and Economics Pages: 65-75 Issue: 1 Volume: 18 Year: 2000 Keywords: Plant Maintenance Cost, Tracked Hydraulic Excavators, Construction Plant, Plant Downtime, X-DOI: 10.1080/014461900370960 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370960 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:1:p:65-75 Template-Type: ReDIF-Article 1.0 Author-Name: Akintola Akintoye Author-X-Name-First: Akintola Author-X-Name-Last: Akintoye Title: Analysis of factors influencing project cost estimating practice Abstract: Although extensive research has been undertaken on factors influencing the decision to tender and mark-up and tender price determination for construction projects, very little of this research contains information appropriate to the factors involved in costing construction projects. The object of this study was to gain an understanding of the factors influencing contractors' cost estimating practice. This was achieved through a comparative study of eighty-four UK contractors classified into four categories, namely, very small, small, medium and large firms. The initial analysis of the 24 factors considered in the study shows that the main factors relevant to cost estimating practice are complexity of the project, scale and scope of construction, market conditions, method of construction, site constraints, client's financial position, buildability and location of the project. Analysis of variance, which tests the null hypothesis that the opinions of the four categories of companies are not significantly different, shows that except for the procurement route and contractual arrangement factor there is no difference of opinion, at the 5% significance level, on the factors influencing cost estimating. Further analysis, based on a factor analysis technique, shows that the variables could be grouped into seven factors; the most important factor grouping being project complexity followed by technological requirements, project information, project team requirement, contract requirement, project duration and, finally, market requirement. Journal: Construction Management and Economics Pages: 77-89 Issue: 1 Volume: 18 Year: 2000 Keywords: Cost Estimate, Factor Analysis, Tendering, Cost Estimators, X-DOI: 10.1080/014461900370979 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370979 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:1:p:77-89 Template-Type: ReDIF-Article 1.0 Author-Name: Ron Craig Author-X-Name-First: Ron Author-X-Name-Last: Craig Title: Re-engineering the tender code for construction works Abstract: The UK's NJCC Code of Procedure for Single Stage Selective Tendering (now withdrawn) and its successor, the CIB's Code of Practice for the Selection of Main Contractors are criticized in the light of decisions of the common law courts with regard to regulation of the tendering process. It is argued that a new 'Tendering Code' should be produced in the style and format of a contract document which reflects not only the statutory regulation imposed on public bodies, but common law decisions of the courts. The nature of this tendering contract is explained as a means of regulating the tendering process. Issues discussed are: dealing with errors and irregularities found in tenders; dealing with non-compliant tenders; dealing with tender withdrawal prior to its acceptance or rejection; making provisions as to time for submission of tenders and dealing with late tenders; making provision for submission of tender by fax or other electronic means; making provision for evaluation of tenders received; and imposing or negotiating reductions in price with tenderers prior to acceptance. The paper concludes that the common law obligations placed on the owner to treat all tenderers equally and fairly and to apply the tender conditions when evaluating tenders and awarding contracts seems to be good common sense and of commercial advantage, not only to the immediate parties concerned but also to the wider community. Journal: Construction Management and Economics Pages: 91-100 Issue: 1 Volume: 18 Year: 2000 Keywords: Tendering, Contract, Fair-dealing, Equality Of Opportunity, Law, X-DOI: 10.1080/014461900370988 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370988 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:1:p:91-100 Template-Type: ReDIF-Article 1.0 Author-Name: Anna Zarkada-Fraser Author-X-Name-First: Anna Author-X-Name-Last: Zarkada-Fraser Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Decisions with moral content: collusion Abstract: Morality is fast becoming an integral part of the mandate for business through both societal and regulatory pressures. Collusive tendering is one of the moral choices facing decision-makers in the construction industry. This paper describes an empirical investigation of the attitudes and behavioural intent towards collusive tendering of key individuals in the tendering process. It also explores the factors that determine these attitudes. The results of the empirical investigation indicate that there is a minority of decision-makers that admit they would consider participating in some form of collusive tendering agreement under certain circumstances. These people form a distinct group in their demographic as well as decision-making profile. Journal: Construction Management and Economics Pages: 101-111 Issue: 1 Volume: 18 Year: 2000 Keywords: Tendering, Moral Decision Making, Ethics, Collusion, Australia, X-DOI: 10.1080/014461900370997 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370997 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:1:p:101-111 Template-Type: ReDIF-Article 1.0 Author-Name: Sandra Fielden Author-X-Name-First: Sandra Author-X-Name-Last: Fielden Author-Name: Marilyn Davidson Author-X-Name-First: Marilyn Author-X-Name-Last: Davidson Author-Name: Andrew Gale Author-X-Name-First: Andrew Author-X-Name-Last: Gale Author-Name: Caroline Davey Author-X-Name-First: Caroline Author-X-Name-Last: Davey Title: Women in construction: the untapped resource Abstract: Currently there are over 11 million women employed in the UK, accounting for 49.5% of the workforce. However, despite increases in the number of women employed in the construction industry over the past decade, they still constitute only 13% of the industry's workforce. This means that construction continues to be the most male dominated of all the major industrial groups. A review is presented of the literature relating to the current position of women in the construction industry. It identifies and examines the barriers preventing women's entry into the industry, the subsequent barriers faced by those working within the construction industry, and initiatives committed to promoting equality for women and men in construction. These barriers arise from a number of sources including: the construction industry's image; career knowledge amongst children and adults; selection criteria and male dominated courses; recruitment practices and procedures; sexist attitudes; male dominated culture; and the work environment. Journal: Construction Management and Economics Pages: 113-121 Issue: 1 Volume: 18 Year: 2000 Keywords: Women, Construction, Equality, Barriers, Initiatives, X-DOI: 10.1080/014461900371004 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900371004 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:1:p:113-121 Template-Type: ReDIF-Article 1.0 Author-Name: Wong Kwok-Chun Author-X-Name-First: Wong Author-X-Name-Last: Kwok-Chun Author-Name: Anthony Walker Author-X-Name-First: Anthony Author-X-Name-Last: Walker Title: Property rights implications of public-private joint ventures Abstract: When a public institution contracts with a developer for a co-development project, there are two main options for arrangements: the equity or the cooperative joint venture. Equity is basically a shareholding arrangement, whereby inputs are valued at market worth in exchange for respective shares of ownership of the joint development. Under cooperative joint ventures, however, shares of ownership are not necessarily based on the values of the inputs. The partners simply draw up a contract that defines the inputs and apportions the outputs of the joint development. This paper argues that a cooperative joint venture between a public institution and a private developer is basically an arrangement to reduce dissipation of rent under public ownership. Unlike the equity arrangement, cooperative joint ventures necessarily lead to an apparent transfer of shares from the public institution to the private developer. Evidence found thus far in Hong Kong and China is consistent with this hypothesis. Variations of the cooperative joint venture are discussed together with examples. Journal: Construction Management and Economics Pages: 131-138 Issue: 2 Volume: 18 Year: 2000 Keywords: Property Rights, Joint Ventures, China, Hong Kong, Rent, Public Ownership, Developers, X-DOI: 10.1080/014461900370762 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370762 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:2:p:131-138 Template-Type: ReDIF-Article 1.0 Author-Name: P. E. D. Love Author-X-Name-First: P. E. D. Author-X-Name-Last: Love Author-Name: H. Li Author-X-Name-First: H. Author-X-Name-Last: Li Title: Overcoming the problems associated with quality certification Abstract: Serendipitous findings are reported from an on-going research project that seeks to determine the effectiveness of quality assurance systems certified under the ISO 9000 series in Australian contracting organizations. In Australia, certification has become mandatory for all organizations wishing to do business with government agencies and major private companies. While certification was designed so that purchasers could have confidence in the quality of the vendor's product or service, not all organizations have been able to implement certification processes in a way that supports this original intent. Instead, most construction organizations have opted to go through the motions without an underlying sustainable continuous improvement philosophy. They simply wish to gain marketing benefits, while others have been overcome by the mass of paperwork required for achieving the quality 'seal of approval'. This paper uses a case study to examine the experiences of a major building and engineering contractor threatened by the paperwork dilemma. However, by adopting a radical shift in the management of the certification programme the contractor was able to implement a quality system that reduced rework significantly and brought about marketing benefits. This case study is used to present a company's experiences in solving problems associated with the certification process, and offers a learning opportunity for other organizations facing similar difficulties. Journal: Construction Management and Economics Pages: 139-149 Issue: 2 Volume: 18 Year: 2000 Keywords: Quality Certification, Iso 9000, Documentation, Rework, Continuous Improvement, X-DOI: 10.1080/014461900370771 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370771 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:2:p:139-149 Template-Type: ReDIF-Article 1.0 Author-Name: Roberto Pietroforte Author-X-Name-First: Roberto Author-X-Name-Last: Pietroforte Author-Name: Ranko Bon Author-X-Name-First: Ranko Author-X-Name-Last: Bon Author-Name: Tullio Gregori Author-X-Name-First: Tullio Author-X-Name-Last: Gregori Title: Regional development and construction in Italy: an input-output analysis, 1959-1992 Abstract: Using two sets of input-output tables, this paper analyses the role of the construction sector in the North and South regions of Italy, from 1959 to 1992. As expected, the sector has had differing impacts on the two regional economies over the years. In the highly developed North its importance has been declining, similarly to the case of other highly developed countries. In the less developed South, instead, construction has a relatively higher propulsive role in the creation of goods and income. This role is significantly diminished since most of the construction inputs are imported. Some differences are reported in the sector's input and output profiles of the two regions. From the technological and organizational points of view, in the South construction projects appear to be less complex than those in the North. Journal: Construction Management and Economics Pages: 151-159 Issue: 2 Volume: 18 Year: 2000 Keywords: Input-output Analysis, Backward And Forward Linkage Indicators, Construction Technology, Construction, Economic Development, X-DOI: 10.1080/014461900370780 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370780 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:2:p:151-159 Template-Type: ReDIF-Article 1.0 Author-Name: Akintola Akintoye Author-X-Name-First: Akintola Author-X-Name-Last: Akintoye Author-Name: Eamon Fitzgerald Author-X-Name-First: Eamon Author-X-Name-Last: Fitzgerald Title: A survey of current cost estimating practices in the UK Abstract: The results are documented of an investigation into current cost estimating practices of contractors for construction projects. A questionnaire survey of contractors was undertaken, in which the respondents are classified into four groups based on their turnover namely: very small, small, medium and large firms. The survey indicates that contractors, irrespective of size, continue to undertake cost estimating predominantly for construction planning purposes, including the preparation of tenders and cost control of projects during the execution stage and, to a lesser extent, for construction project evaluation. Recent developments in cost estimating methods and tools that consider risks and variability in cost estimates, such as the use of range estimating and parametric estimating techniques, have not been adopted by contractors. The practice of cost estimating does not differ from conventional techniques based on the use of labour and material constants to obtain prices for bills of quantities items on an item by item basis. The study shows that the major causes of inaccuracy in cost estimating continue to be the lack of practical knowledge of the construction process by those responsible for the estimating function, insufficient time to prepare cost estimates, poor tender documentation and the wide variability of subcontractors' prices. Journal: Construction Management and Economics Pages: 161-172 Issue: 2 Volume: 18 Year: 2000 Keywords: Cost Estimate, Tendering, Performance Appraisal, Estimating Techniques, Analysis Of Variance, X-DOI: 10.1080/014461900370799 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370799 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:2:p:161-172 Template-Type: ReDIF-Article 1.0 Author-Name: Simon Austin Author-X-Name-First: Simon Author-X-Name-Last: Austin Author-Name: Andrew Baldwin Author-X-Name-First: Andrew Author-X-Name-Last: Baldwin Author-Name: Baizhan Li Author-X-Name-First: Baizhan Author-X-Name-Last: Li Author-Name: Paul Waskett Author-X-Name-First: Paul Author-X-Name-Last: Waskett Title: Analytical design planning technique (ADePT): a dependency structure matrix tool to schedule the building design process Abstract: Current planning practice takes little account of the interdisciplinary, iterative nature of the building design process. This leads to a compromised design process containing inevitable cycles of rework together with associated time and cost penalties in both design and construction. The analytical design planning technique (ADePT) is a planning methodology which helps to overcome these difficulties. The central part of ADePT is a dependency structure matrix (DSM). This paper describes DSM techniques and a tool developed to optimize the design process. Journal: Construction Management and Economics Pages: 173-182 Issue: 2 Volume: 18 Year: 2000 Keywords: Adept, Design, Planning, Design Management, Matrix Analysis, X-DOI: 10.1080/014461900370807 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370807 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:2:p:173-182 Template-Type: ReDIF-Article 1.0 Author-Name: Anna Sobotka Author-X-Name-First: Anna Author-X-Name-Last: Sobotka Title: Simulation modelling for logistics re-engineering in the construction company Abstract: Much attention is being paid to the significant role of logistics in the construction industry, with reference both to the total supply chain and to its individual links, called the 'internal logistic system'. Rationalization of activity in the logistics sphere leads to lowered production costs and increased quality. However, rationalization of logistic processes often involves re-engineering, i.e. reconstruction or making changes, for instance in the structure of supply chains, in the organization of physical and information flows, in ways of taking up decisions, etc. This paper describes the effectiveness of a simulation modelling approach in improving logistic systems in construction, by applying information collected from Polish construction practice. Graphical and analytical models of company logistic systems are the basis for making simulators using GPSS World™. Two models of different structures from the point of view of physical and information flow were chosen, several different strategies for controlling these flows were worked out, values of particular parameters of the model were defined and the optimum solution was sought. The assumed optimization criterion is minimizing logistics costs. An analysis of the research results can be used to indicate re-engineering needs for the internal models of the logistic systems investigated. Journal: Construction Management and Economics Pages: 183-195 Issue: 2 Volume: 18 Year: 2000 Keywords: Internal Logistic System;Building Materials;Simulation Research;Re-engineering, X-DOI: 10.1080/014461900370816 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370816 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:2:p:183-195 Template-Type: ReDIF-Article 1.0 Author-Name: S. Q. Wang Author-X-Name-First: S. Q. Author-X-Name-Last: Wang Author-Name: Robert Tiong Author-X-Name-First: Robert Author-X-Name-Last: Tiong Author-Name: S. K. Ting Author-X-Name-First: S. K. Author-X-Name-Last: Ting Author-Name: D. Ashley Author-X-Name-First: D. Author-X-Name-Last: Ashley Title: Evaluation and management of foreign exchange and revenue risks in China's BOT projects Abstract: China is actively investigating ways to introduce project financing, specifically through the build-operate-transfer (BOT) scheme to meet the needs for the country's infrastructure and to be attractive to foreign investors and lenders. The advent of concession agreements, backed by new BOT laws, will be a positive move forward to achieving project-financed infrastructure projects. There are thus opportunities especially in the power sector for foreign investors. However, it is important to identify and manage the unique or critical risks associated with China's BOT projects. This is especially so after policies were introduced in late 1996 when the first state-approved BOT project, the US$650 million 2 × 350 megawatt (MW) coal-fired Laibin B Power Plant (Laibin B), was awarded. They include a competitive tendering process and 100% foreign ownership of the operating company. This paper is based on the findings from an international survey on risk management of BOT projects in developing countries, with emphasis on power projects in China. It discusses specifically the criticality of foreign exchange and revenue risks which include exchange rate and convertibility risk, financial closing risk, dispatch constraint risk and tariff adjustment risk. The measures for mitigating each of these risks are discussed also. Journal: Construction Management and Economics Pages: 197-207 Issue: 2 Volume: 18 Year: 2000 Keywords: Build-operate-transfer Bot Project, Risk Management, Foreign Exchange, Currency Convertibility Risk, X-DOI: 10.1080/014461900370825 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370825 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:2:p:197-207 Template-Type: ReDIF-Article 1.0 Author-Name: Goh Bee-Hua Author-X-Name-First: Goh Author-X-Name-Last: Bee-Hua Title: Evaluating the performance of combining neural networks and genetic algorithms to forecast construction demand: the case of the Singapore residential sector Abstract: In recent years, forecasting demand for residential construction in Singapore has become more vital, since it is widely perceived that the next trough of the real estate cycle is approaching. This paper evaluates the use of a combination of neural networks (NNs) and genetic algorithms (GAs) to forecast residential construction demand in Singapore. Successful applications of NNs, especially in solving complex non-linear problems, have since stimulated interest in exploring the capabilities of other biological-based methods such as GAs, and in exploiting the synergy of these two techniques to create more problem-solving power. In the study, a basic NN model is used as a benchmark to gauge the performance of the combined NN-GA model. A relative measure of forecasting accuracy, known as the mean absolute percentage error (MAPE), is used for the comparison. The models are checked also for internal validity by allowing each to be trained twice and having a set of forecasts generated after each training. Both models are found to produce accurate forecasts, because their MAPE values consistently fall within the acceptable limit of 10%. However, the combined model out-performs the basis model remarkably by reducing the average MAPE from about 6% to a mere 1%. For each model, the marginal difference in the MAPE values (i.e., 0.5% for the NN model and 0.06% for the NN-GA model) of its two forecasts indicates consistency in performance, hence establishing internal validity as well. The findings reinforce the reliability of using NNs to model construction demand and reveal the benefit of combining NNs and GAs to produce more accurate models. Journal: Construction Management and Economics Pages: 209-217 Issue: 2 Volume: 18 Year: 2000 Keywords: Neural Networks, Genetic Algorithms, Construction Demand, Forecasting, Accuracy, X-DOI: 10.1080/014461900370834 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370834 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:2:p:209-217 Template-Type: ReDIF-Article 1.0 Author-Name: Simon Smith Author-X-Name-First: Simon Author-X-Name-Last: Smith Author-Name: Graeme Wood Author-X-Name-First: Graeme Author-X-Name-Last: Wood Author-Name: Martin Gould Author-X-Name-First: Martin Author-X-Name-Last: Gould Title: A new earthworks estimating methodology Abstract: Earthworks and earthmoving operations are a major part of many civil engineering construction projects. Because of their labour and plant intensity, the planning and estimating of such operations is crucial to both the cost and duration of the project; earthworks are considered by many practitioners to be indicators to the success or failure of the project as a whole. Traditionally, a mixture of manufacturers' data (through published charts or computer databases) and historical company data are used in the estimating of earthworks. This process has two main drawbacks. First, plant haul velocity is dependent on the rolling resistance at the soil-wheel interface, which is notoriously difficult to determine; second, the stochastic interface between types of plant provides a non-deterministic system, resulting in estimates of output which may be unrealistically high. An alternative system of earthworks estimating is presented based on a combination of work undertaken in both the soil/vehicle and stochastic estimating fields. This system is demonstrated via a case study based on an actual highway project. The main conclusion to be drawn is that the traditional estimating approach results in a scheme costed well below realistic values. Journal: Construction Management and Economics Pages: 219-228 Issue: 2 Volume: 18 Year: 2000 Keywords: Earthworks, Hauling, Rolling Resistance, Earthmoving Plant, Plant Cycle Times, X-DOI: 10.1080/014461900370843 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370843 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:2:p:219-228 Template-Type: ReDIF-Article 1.0 Author-Name: Mike Bresnen Author-X-Name-First: Mike Author-X-Name-Last: Bresnen Author-Name: Nick Marshall Author-X-Name-First: Nick Author-X-Name-Last: Marshall Title: Partnering in construction: a critical review of issues, problems and dilemmas Abstract: Partnering in construction has been presented as a potentially important way of improving construction project performance through the direct benefits it can bring to both clients and contractors. However, there is still considerable debate about the nature and merits of a partnering approach. This paper attempts to contribute towards this debate by exploring the presumed link between partnering and cultural change within the industry, at both organizational and interorganizational levels of analysis. To do so, it draws upon theory and research from the social sciences (especially organizational theory) to explore some of the issues, problems and dilemmas which emerge when full and proper account is taken of the complexities of organizations, as well as some of the subtleties and intricacies of the concept of organizational culture. The paper concludes that it is only by fully appreciating the effects of such complexity that a more realistic and practical approach to the development and implementation of partnering will emerge. Journal: Construction Management and Economics Pages: 229-237 Issue: 2 Volume: 18 Year: 2000 Keywords: Partnering, Alliancing, Culture, X-DOI: 10.1080/014461900370852 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370852 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:2:p:229-237 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: Barbara Bagilhole Author-X-Name-First: Barbara Author-X-Name-Last: Bagilhole Author-Name: Richard Neale Author-X-Name-First: Richard Author-X-Name-Last: Neale Title: A grounded theory of women's career under-achievement in large UK construction companies Abstract: In response to impending skills shortages and changing employment patterns, the UK construction industry recently has made considerable efforts to attract more women to its professions. However, despite their increasing representation, there are indications that women experience difficulties in developing their careers within the industry. This research investigated the careers of men and women working for large construction companies, in order to establish the gender determined influences on women's career progression. A primarily qualitative methodology was employed for the research, in which career profiles were developed through ethnographic interviews with 41 matched pairs of male and female employees. This allowed the gender specific determinants of careers to be established across a range of different organizations, and from informants at different vocational and life-cycle stages. The analysis resulted in the formulation of a set of eight interrelated theoretical models, from which a theory of women's career development was constructed. The theory reflects the belief that the construction workplace is a competitive and conflictual environment, where women are overtly and covertly discriminated against by men, who use structural systems to undermine their participation. The women interviewed were found to have dealt with these barriers in a way which perpetuated existing work cultures. If reflected throughout the industry, this would suggest the existence of a self-fulfilling cycle of women's continued under-achievement. The paper puts forward the radical proposition that women should not be attracted to the industry unless steps are taken to moderate its exclusionary and discriminatory culture. Journal: Construction Management and Economics Pages: 239-250 Issue: 2 Volume: 18 Year: 2000 Keywords: Women, Career Development, Discrimination, Hrm, Grounded Theory, X-DOI: 10.1080/014461900370861 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370861 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:2:p:239-250 Template-Type: ReDIF-Article 1.0 Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Title: Globalization and construction industry development: research opportunities Abstract: Raftery, J., Pasadilla, B., Chiang, Y. H., Hui, E. C. M. and Tang, B. S. (1998) Construction Management and Economics, 16, 729-37 review recent developments in the construction industries in Asia. They discuss the main causes and effects of key trends in globalization and their impact on the industries. This paper considers some of the points raised by Raftery et al. It starts with an overall review of their paper. It then considers construction industry development in general, technology transfer and joint ventures, and the impact of policy reform on the industries. It suggests additional relevant issues, and highlights some areas where further research would be appropriate. Journal: Construction Management and Economics Pages: 257-262 Issue: 3 Volume: 18 Year: 2000 Keywords: Globalization Construction Industry Development Developing Countries, X-DOI: 10.1080/014461900370627 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370627 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:3:p:257-262 Template-Type: ReDIF-Article 1.0 Author-Name: Denise Bower Author-X-Name-First: Denise Author-X-Name-Last: Bower Title: A systematic approach to the evaluation of indirect costs of contract variations Abstract: A mechanism is proposed for the evaluation of compensation due in the event of a variation order under contracts for construction work. It demonstrates how the indirect costs of a variation can be derived by the use of influence curves. Commonly it is accepted that such costs are very difficult to evaluate systematically, and hence the parties to the contract have been left to argue over the cost and time effects of a variation and the compensation due. The technique suggested provides a simple solution to this problem. Journal: Construction Management and Economics Pages: 263-268 Issue: 3 Volume: 18 Year: 2000 Keywords: Contracts Changes Variations, X-DOI: 10.1080/014461900370636 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370636 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:3:p:263-268 Template-Type: ReDIF-Article 1.0 Author-Name: E. Sarah Slaughter Author-X-Name-First: E. Sarah Author-X-Name-Last: Slaughter Author-Name: Hikaru Shimizu Author-X-Name-First: Hikaru Author-X-Name-Last: Shimizu Title: 'Clusters' of innovations in recent long span and multi-segmental bridges Abstract: The system-level impacts of innovations often can be more significant than the direct, primary impacts in certain industries. In particular, these system interactions can be seen with large, complex multi-system constructed facilities. Approximately half of the 200 specific innovations identified in eleven recent long span and multi-segmental bridges are linked to other innovations. Three general types of 'cluster' interaction are system, actualizing, and complementary links. The system interactions are nurtured through coordinated innovation development programmes. The actualizing links connect one set of innovations to another set, to aid in their realization of the innovation and project objectives. The complementary links provide additional benefits through the joint use of multiple innovations. The results of these analyses provide significant new insight for innovation theory into the system-level interactions of innovations. Since the frequency of the linkages among the innovations appears to reflect the relative stability of the design and construction parameters, recent innovation trajectories may be more difficult to link effectively to other innovations. These innovation interactions can provide critical capabilities for achieving the project objectives, but must be identified and managed effectively to achieve desired performance levels. Journal: Construction Management and Economics Pages: 269-280 Issue: 3 Volume: 18 Year: 2000 Keywords: Construction Innovations Long Span Bridge Design And Construction System Interactions, X-DOI: 10.1080/014461900370645 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370645 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:3:p:269-280 Template-Type: ReDIF-Article 1.0 Author-Name: S. O. Cheung Author-X-Name-First: S. O. Author-X-Name-Last: Cheung Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Author-Name: I. Ndekugri Author-X-Name-First: I. Author-X-Name-Last: Ndekugri Author-Name: F. C. Harris Author-X-Name-First: F. C. Author-X-Name-Last: Harris Title: Factors affecting clients' project dispute resolution satisfaction in Hong Kong Abstract: The use of project dispute resolution satisfaction (DRS) as a project success measurement responds to the increasing concern over the spread of the dispute epidemic within the construction industry in Hong Kong. The DRS of a project is considered as favourable where disputes are resolved within the site level. With the use of 48 project data sets and the technique of multivariate discriminant analysis, a discriminant model function was derived to classify projects into favourable DRS and adverse DRS. The multivariate discriminant analysis model function identified eight discriminating variables, among which the degree of design changes offered the highest separation power. The reliability of the discrminating variables was reinforced by a separate relative importance index study. Through the use of principal component factor analysis, these variables were grouped into three factors generically described as substantive influence, facilitation and indirect influence. Journal: Construction Management and Economics Pages: 281-294 Issue: 3 Volume: 18 Year: 2000 Keywords: Construction Disputes Project Discriminant Analysis Hong Kong, X-DOI: 10.1080/014461900370654 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370654 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:3:p:281-294 Template-Type: ReDIF-Article 1.0 Author-Name: Alan Hooper Author-X-Name-First: Alan Author-X-Name-Last: Hooper Author-Name: Chris Nicol Author-X-Name-First: Chris Author-X-Name-Last: Nicol Title: Design practice and volume production in speculative housebuilding Abstract: The design of new residential development in the UK is castigated routinely in both the technical and broadsheet press, and has in the past few years become the focus of governmental policy initiatives intended to improve the overall standard of design in new housebuilding. Remarkably, however, there has been very little empirical research into the process of housing design in the private sector, and hence even academic commentaries have had to extrapolate from a hitherto very limited number of research studies. Moreover, the private sector housebuilding industry has undergone significant change in the last two decades, with considerable concentration and hence domination of production by large firms. With the private housebuilding sector responsible for over 80% of new production in the 1990s, it is timely to revisit the design practices of large speculative housebuilding firms, in order to better understand current practices and the system of constraints and opportunities in which these practices are situated. Furthermore, it is necessary to place design practice in the context of construction technology, for design criticism all too often abstracts from the technology of building practice and innovation. Therefore, this study examines, by means of a nationally representative questionnaire survey of housebuilding firms, the dominant design practices currently utilized in the industry. The focus is the extent to which volume housebuilding firms (defined as those producing in excess of 1000 units per annum) utilize standard designs, and the interrelationship between such designs and the construction technology employed. In-depth interviews with a representative sample of senior personnel from leading housebuilding companies complement the national survey, and provide insights into the system of constraints and opportunities which the housebuilding industry faces. At the heart of current debates is the conflict between the alleged prominence of the criterion of buildability in private sector housebuilding, at the expense of individuality in design, regard for the overall design context and the requirements of the housing consumer. Each of these issues is investigated in the context of the prevailing practice in the private sector housebuidling industry in the UK in the 1990s. Journal: Construction Management and Economics Pages: 295-310 Issue: 3 Volume: 18 Year: 2000 Keywords: Design Volume Housebuilding Private Sector, X-DOI: 10.1080/014461900370663 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370663 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:3:p:295-310 Template-Type: ReDIF-Article 1.0 Author-Name: Shou Qing Wang Author-X-Name-First: Shou Qing Author-X-Name-Last: Wang Author-Name: Robert Tiong Author-X-Name-First: Robert Author-X-Name-Last: Tiong Author-Name: S. K. Ting Author-X-Name-First: S. K. Author-X-Name-Last: Ting Author-Name: D. Ashley Author-X-Name-First: D. Author-X-Name-Last: Ashley Title: Foreign exchange and revenue risks: analysis of key contract clauses in China's BOT project Abstract: Despite the Asian financial crisis, there was still growing international interests by sponsors in China's infrastructure projects financed on build-operate-transfer (BOT) concession contracts. With the closure of the Guangdong International Trust and Investment Corporation (GITIC), foreign banks have become cautious towards new loan applications by Chinese companies and they were confused about government support and guarantees. Therefore it is important to analyse and manage the unique or critical risks associated with China's BOT projects. This is especially so after new policies were introduced in late 1996 when the first state-approved BOT project, the US$650 million 2 X 350 megawatt coal-fired Laibin B Power Plant (Laibin B), was awarded. The findings are reported from an international survey on risk management of BOT projects, with emphasis on power projects in China, with a discussion of the adequacy of the key contract clauses used in the Laibin B's concession agreement (CA) in addressing the foreign exchange and revenue risks, which include exchange rate and convertibility risk, financial closing risk, dispatch constraint risk and tariff adjustment risk. Areas for improvements to these contract clauses are suggested. Journal: Construction Management and Economics Pages: 311-320 Issue: 3 Volume: 18 Year: 2000 Keywords: Build-OPERATE-TRANSFER Botproject Risk Management Foreign Exchange Currency Convertibility, X-DOI: 10.1080/014461900370672 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370672 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:3:p:311-320 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Love Author-X-Name-First: Peter Author-X-Name-Last: Love Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Author-Name: Zahir Irani Author-X-Name-First: Zahir Author-X-Name-Last: Irani Author-Name: Olusegun Faniran Author-X-Name-First: Olusegun Author-X-Name-Last: Faniran Title: Total quality management and the learning organization: a dialogue for change in construction Abstract: Many construction organizations have misunderstood the reality that total quality management (TQM) based on continuous improvement requires a commitment to learning and that essentially it is the means to a learning organization. The paper argues that if the construction industry is to improve its performance and competitiveness, then there needs to be a cultural and behavioural shift in the mind-set of practitioners, academics and the professional institutions. Their focus should be on re-thinking their approaches to TQM so that learning becomes the norm. It is demonstrated that a relationship exists between the constructs of TQM, organizational learning, and the learning organization. Based on a review of existing literature, a conceptual model for a learning organization in construction is presented and discussed. The paper proposes some refinements to the concept of the learning organization, directed at clearly positioning the critical focus of learning at the organizational level in construction. Journal: Construction Management and Economics Pages: 321-331 Issue: 3 Volume: 18 Year: 2000 Keywords: Total Quality Management Organizational Learning Learning Organization Change, X-DOI: 10.1080/014461900370681 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370681 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:3:p:321-331 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Rogers Author-X-Name-First: Martin Author-X-Name-Last: Rogers Title: Using Electre III to aid the choice of housing construction process within structural engineering Abstract: The Electre III model may be considered as a decision-aid technique suited to the appraisal of complex civil/structural engineering projects. This conclusion is based on an assessment that the model permits a general ordering of alternatives, even when individual pairs of options remain uncompared where there is insufficient information to distinguish between them. Also, the technique is capable of dealing with the mix of both quantitative and qualitative information obtained within an engineering project appraisal. Electre III is applied to the evaluation of 11 alternative multi-family housing systems on the basis of 7 criteria covering labour, material and energy demand. Using this case study, the benefits of Electre III over other decision models in the selection process concerned are emphasized. Journal: Construction Management and Economics Pages: 333-342 Issue: 3 Volume: 18 Year: 2000 Keywords: Structural Engineering Electre Iii Multi-CRITERIA Decision Analysis Mcda, X-DOI: 10.1080/014461900370690 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370690 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:3:p:333-342 Template-Type: ReDIF-Article 1.0 Author-Name: Irem Dikmen Ozdoganm Author-X-Name-First: Irem Dikmen Author-X-Name-Last: Ozdoganm Author-Name: M. Talat Birgonul Author-X-Name-First: M. Talat Author-X-Name-Last: Birgonul Title: A decision support framework for project sponsors in the planning stage of build-operate-transfer (BOT) projects Abstract: Every decision-making problem is oriented towards the selection of the correct strategies for achieving objectives, and depends on the assumptions associated with different scenarios. Project planning in a buildoperate-transfer (BOT) project is a complicated decision-making problem because the model has a complex financial and organizational structure which is influenced also by the socio-economic environment in a country. A decision support framework is reported, as used in the planning stage of a hydropower plant project in Turkey, which helped the project company to check project viability against some predefined critical success factors, define the risk sharing scenarios under which a project becomes viable, incorporate risks into cash flow analysis and, finally, define effective risk mitigation strategies. Key challenges in the realization of BOT projects, particularly in developing countries, are discussed together with possible risk sharing principles between the private and public sector participants. Journal: Construction Management and Economics Pages: 343-353 Issue: 3 Volume: 18 Year: 2000 Keywords: Build-OPERATE-TRANSFER Bot Model Risk Management Monte Carlo Simulation, X-DOI: 10.1080/014461900370708 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370708 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:3:p:343-353 Template-Type: ReDIF-Article 1.0 Author-Name: Lawrence Wai Chung Lai Author-X-Name-First: Lawrence Wai Chung Author-X-Name-Last: Lai Title: The Coasian market-firm dichotomy and subcontracting in the construction industry Abstract: This is a contribution to the debate on the contractual nature of subcontracting in the construction industry by arguing, contrary to certain views in the literature on institutional and construction economics, that the Coasian firm-market dichotomy is not blurred or pointless. By reference to the type and number of contracts, the study offers a way to distinguish the firm from the market as well as the precise nature of subcontracting in terms of such distinction. Subcontracting is shown to be a nexus of Coasian firms interacting through the main contractor with a monopsony consumer in a Coasian market. Journal: Construction Management and Economics Pages: 355-362 Issue: 3 Volume: 18 Year: 2000 Keywords: Transaction Costs Ambiguity Of The Firm Subcontracting Coasian Firm Coasian Market, X-DOI: 10.1080/014461900370717 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370717 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:3:p:355-362 Template-Type: ReDIF-Article 1.0 Author-Name: Shou Qing Wang Author-X-Name-First: Shou Qing Author-X-Name-Last: Wang Author-Name: Michael Anson Author-X-Name-First: Michael Author-X-Name-Last: Anson Title: Comparison of the concreting productivities in Hong Kong and Beijing and a proposed comparison methodology Abstract: The ready mixed concrete (RMC) industry is an important sector of the construction industry in many places. Its level of development in terms of size and performance may be taken as an index representative of the development level of a particular construction industry taken as a whole. Therefore comparisons between different places are of interest, and of potential economic benefit. As part of a larger research study in Hong Kong on the productivity of concreting, data have been obtained on the RMC industries in Hong Kong (HK) and Beijing (BJ). Both are large cities at different stages of economic development. The study involved close observation in the early 1990s of 154 pours on building construction sites in HK and 38 days spent at 38 RMC plants, one day at each, together with 34 site pours and 20 days at RMC plants in BJ. Much detailed performance information has been derived, and a comparison methodology is proposed which could have general application in this industry. It is demonstrated that the RMC industry in HK is more productive than the industry in BJ. Journal: Construction Management and Economics Pages: 363-372 Issue: 3 Volume: 18 Year: 2000 Keywords: Performance Benchmark Concrete Placing Ready Mixed Concrete Construction, X-DOI: 10.1080/014461900370726 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900370726 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:3:p:363-372 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Peter Graham Author-X-Name-First: Peter Author-X-Name-Last: Graham Author-Name: Guinevere Smithers Author-X-Name-First: Guinevere Author-X-Name-Last: Smithers Title: Employee perceptions of the solid waste management system operating in a large Australian contracting organization: implications for company policy implementation Abstract: A survey of employees' perceptions of a large contracting firm's waste management system was conducted. Results were factor analysed and an eight-factor model of the waste management climate was identified. Perceptions were found to differ between employee groupings. Managerial staff had a less positive perception of the waste management climate than did site workers. Qualitative interview data were analysed using a content analysis approach. Managers were found to perceive environmental issues as being less important than cost, time or quality objectives. Construction workers believed environmental issues to be of greater importance than these other objectives. Differences in perceptions of managers and site workers have implications for the implementation of any company waste management policy. There is a need to involve workers in identifying waste management solutions, to provide more information to all employees about practical aspects of waste management, and for managers visibly to demonstrate commitment to waste management policy objectives. Journal: Construction Management and Economics Pages: 383-393 Issue: 4 Volume: 18 Year: 2000 Keywords: Construction And Demolition Waste Organizational Climate Solid Waste Management, X-DOI: 10.1080/01446190050024806 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190050024806 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:4:p:383-393 Template-Type: ReDIF-Article 1.0 Author-Name: Malik Ranasinghe Author-X-Name-First: Malik Author-X-Name-Last: Ranasinghe Title: Impact of correlation and induced correlation on the estimation of project cost of buildings Abstract: Treatment of correlation between variables is necessary for deriving any theoretical distribution of the project cost of buildings. This paper highlights some often ignored theoretical requirements necessary for a rigorous treatment of correlations. The condition for a positive definite correlation matrix is described, along with an analytical procedure and a computer program developed to verify the positive definite condition when correlation coefficients between input variables are estimated using historical data. The analytical procedure and the developed computer program can be used in any application that obtains correlation information from historical data or as subjective judgements to be used in a functional relationship. A new concept called induced correlation is suggested to define and to treat correlation between derived variables that arise from the common (shared) primary variables in their functional forms. A published numerical example is used to highlight the stages where correlation between variables can have an impact on the estimation of moments (estimated expected value and estimated standard deviation) for the project cost of buildings, and to demonstrate the improvement in the estimation of the standard deviation of project cost as a result of treating correlations in risk analysis. Journal: Construction Management and Economics Pages: 395-406 Issue: 4 Volume: 18 Year: 2000 Keywords: Project Cost Quantity Correlation Coefficient Correlation Matrix Probability, X-DOI: 10.1080/01446190050024815 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190050024815 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:4:p:395-406 Template-Type: ReDIF-Article 1.0 Author-Name: Eric Wong Author-X-Name-First: Eric Author-X-Name-Last: Wong Author-Name: George Norman Author-X-Name-First: George Author-X-Name-Last: Norman Author-Name: Roger Flanagan Author-X-Name-First: Roger Author-X-Name-Last: Flanagan Title: A fuzzy stochastic technique for project selection Abstract: The comparison of two or more risky projects is more of a challenge than the evaluation of one project in isolation. In the numerous decision models and methods suggested in the literature, often it is assumed that the criteria as well as the decision maker's preference or utility function can be crisply defined. Multi-attribute decision aids that permit the consideration of both multi-variables and risks generally have been associated with complex mathematics and heavy consumption of resources. This paper shows how project selection problems can be dealt with when some project attributes are subject to random variations. The method incorporates fuzzy analysis into multi-attribute utility theory. The aggregate utility function for an individual project is derived as a fuzzy number (or interval) which, in turn, yields probabilistic information for stochastic dominance tests. A unique feature of the approach is that it dispenses with the task of selecting probability distributions for aggregate utility functions. A comparison of the proposed method with the expected utility approach was made and the findings showed agreement between the results. Journal: Construction Management and Economics Pages: 407-414 Issue: 4 Volume: 18 Year: 2000 Keywords: Project Risk Multi-ATTRIBUTE Utility Theory Fuzzy Analysis Stochastic Dominance, X-DOI: 10.1080/01446190050024824 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190050024824 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:4:p:407-414 Template-Type: ReDIF-Article 1.0 Author-Name: Mohan Manavazhi Author-X-Name-First: Mohan Author-X-Name-Last: Manavazhi Title: Hybrid modelling framework for synthesizing virtual structures Abstract: Erecting a structure in a construction project involves the use of a number of complex, interacting processes. Systematic analysis of these processes is essential for ensuring that they are executed in the most efficient way possible. However, traditional tools like CPM and PERT and other analytical and mathematical approaches cannot capture the dynamics of construction processes. These problems could be overcome by conducting experiments on the real-world processes themselves but such experiments can be prohibitively expensive. Thus, a more feasible approach that can overcome these drawbacks is required. This paper presents a framework-based approach for facilitating the analyses of the operations required for the construction of a structure with a specific configuration by building the structure virtually in a digital computer using discrete-event simulation. The approach utilizes a hybrid framework that combines the flexibility and simplicity of semantic networks with the power of object-orientation to facilitate discrete-event simulation. A predominantly product-centric modelling approach is used in the development of the framework. A sample application is given illustrating the application of the framework-based approach for the analyses of the operations required for the construction of the structure. Journal: Construction Management and Economics Pages: 415-426 Issue: 4 Volume: 18 Year: 2000 Keywords: Discrete-EVENT Simulation Object-ORIENTED Simulation Product Synthesis Product Modelling Semantic Networks, X-DOI: 10.1080/01446190050024833 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190050024833 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:4:p:415-426 Template-Type: ReDIF-Article 1.0 Author-Name: David Edwards Author-X-Name-First: David Author-X-Name-Last: Edwards Author-Name: Gary Holt Author-X-Name-First: Gary Author-X-Name-Last: Holt Author-Name: Frank Harris Author-X-Name-First: Frank Author-X-Name-Last: Harris Title: Estimating life cycle plant maintenance costs Abstract: The financial success or otherwise of a maintenance strategy can be determined realistically only when actual costs are compared with target 'predicted' values. This is because, in the absence of accurate cost control mechanisms, maintenance expenditure can exceed capital cost. In order to address this problem, a methodology is presented for predicting life cycle maintenance expenditure over the useful life of tracked hydraulic excavators. First, time series analysis (using a moving centred average) illustrates that the trend in maintenance cost expenditure is difficult to isolate due to large perturbations in periodic unscheduled maintenance. Such expenditure accounts for 92% of total maintenance cost. Second, cumulative costs of maintenance are modelled using a cubic equation, with time (in hours) as the predictor (xn) variable. Model performance is robust with a coefficient of determination (R2) of 0.99 and a mean percentage error (MPE) of minus 3.94. The paper concludes with direction for future research in this field, particularly with respect to expanding the model's application to machines of various weights, manufacturers and machines operating in other industries, and determination of criteria with which to predict when a plant item will reach the end of its useful life. Journal: Construction Management and Economics Pages: 427-435 Issue: 4 Volume: 18 Year: 2000 Keywords: Construction Plant Maintenance Machine Cost Estimation Time Series Analysis Cubic Equation Financial Management, X-DOI: 10.1080/01446190050024842 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190050024842 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:4:p:427-435 Template-Type: ReDIF-Article 1.0 Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Author-Name: Z. M. Deng Author-X-Name-First: Z. M. Author-X-Name-Last: Deng Author-Name: S. X. Zeng Author-X-Name-First: S. X. Author-X-Name-Last: Zeng Author-Name: C. S. Ho Author-X-Name-First: C. S. Author-X-Name-Last: Ho Title: Quest for continuous quality improvement for public housing construction in Hong Kong Abstract: With mandatory implementation of the ISO 9000 quality system by the Housing Authority in Hong Kong, most construction firms there now claim to have initiated quality systems in their processes as defined in their quality manuals. In addition, an objective quality measuring yardstick, the Performance Assessment Scoring Scheme (PASS), has been administered by the Housing Authority of Hong Kong to monitor the performance quality of contractors. These two measures, coupled with the two other contractual requirements stipulating the use of mechanized formwork and precast facade units, are directed towards achievement of a desired quality standard. However, the PASS analysis has revealed that the general level of quality has not improved significantly and the expected continuous improvement in construction quality has not been realized over a specific time period. Quality appears far better on paper than does the actual work on site. This suggests that quality management in the construction setting is far more difficult to achieve than it is in other industries. This paper explores possible reasons for failure in the quest for quality in public housing construction, and proposes changes needed before the vision of continuous quality improvement can be realized. Journal: Construction Management and Economics Pages: 437-446 Issue: 4 Volume: 18 Year: 2000 Keywords: Public Housing Construction Quality Management Iso 9000 Quality Assessment, X-DOI: 10.1080/01446190050024851 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190050024851 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:4:p:437-446 Template-Type: ReDIF-Article 1.0 Author-Name: M. Loosemore Author-X-Name-First: M. Author-X-Name-Last: Loosemore Author-Name: B. T. Nguyen Author-X-Name-First: B. T. Author-X-Name-Last: Nguyen Author-Name: N. Denis Author-X-Name-First: N. Author-X-Name-Last: Denis Title: An investigation into the merits of encouraging conflict in the construction industry Abstract: Considerable energy is being directed towards an indiscriminate policy of conflict reduction in the construction industry but the problem of construction conflict may be in its management rather than in its incidence. Conflict reduction is a response to the industry's inability to manage conflict constructively, and it may be more productive to focus upon building skills in this area as a basis for encouraging conflict. This paper explores the merits of this idea. It does so by discussing the results of a survey which used two psychometric tests to investigate whether the industry has an attitudinal and socio-structural base which is receptive to such efforts. Journal: Construction Management and Economics Pages: 447-456 Issue: 4 Volume: 18 Year: 2000 Keywords: Conflict Dispute Social Systems Attitudes Organizational Structure, X-DOI: 10.1080/01446190050024860 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190050024860 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:4:p:447-456 Template-Type: ReDIF-Article 1.0 Author-Name: M. Wanous Author-X-Name-First: M. Author-X-Name-Last: Wanous Author-Name: A. H. Boussabaine Author-X-Name-First: A. H. Author-X-Name-Last: Boussabaine Author-Name: J. Lewis Author-X-Name-First: J. Author-X-Name-Last: Lewis Title: To bid or not to bid: a parametric solution Abstract: One of the most important decisions that has to be made by construction companies/contractors is whether or not to bid for a new project when an invitation has been received. It would be of great help if a structured model could be developed that deals systematically with different bidding situations. A simple parametric solution for the ';bid/no bid' decision is reported in this paper. This solution is based on the findings of six semi-structured interviews and a formal questionnaire through which 38 factors that affect the bid/no bid decision were identified and ranked according to their importance to contractors operating in Syria. Only the most influential factors were considered in the development process. The model was optimized using data about 162 real bidding situations. Then the optimized model was tested using another 20 real projects. It proved 85% accurate in simulating the actual decisions. Although, the proposed model is based on data from the Syrian construction industry it could be modified very easily to suit other countries. Journal: Construction Management and Economics Pages: 457-466 Issue: 4 Volume: 18 Year: 2000 Keywords: Bidno Bid Criteria Parametric Bidding Model, X-DOI: 10.1080/01446190050024879 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190050024879 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:4:p:457-466 Template-Type: ReDIF-Article 1.0 Author-Name: Aviad Shapira Author-X-Name-First: Aviad Author-X-Name-Last: Shapira Author-Name: Dov Goldfinger Author-X-Name-First: Dov Author-X-Name-Last: Goldfinger Title: Work-input model for assembly and disassembly of high shoring towers Abstract: High shoring towers, the common shoring solution for high clearance construction, cause the entire formwork system to account for a remarkably high percentage of the cost of the constructed concrete element. However, data on work inputs in assembly and disassembly of high towers are scarce, and the reason lies in the difficulty in conducting the numerous work studies that would be needed to cover the wide variety of tower types offered by the market and the extensive range of heights to which towers are erected. A model is presented, based on a limited number of work studies, for the prediction of work inputs in the assembly and disassembly of shoring towers of two configurations, rising to heights of up to 30 m. Results of actual measured work input data for three tower models representing three tower types widely used on construction sites are presented. An insight is provided into the anatomy of tower erection, which should make possible use of the proposed methodology for the development of similar models for additional tower types. Journal: Construction Management and Economics Pages: 467-477 Issue: 4 Volume: 18 Year: 2000 Keywords: Construction Formwork Shoring Towers Work Inputs Work Studies, X-DOI: 10.1080/01446190050024888 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190050024888 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:4:p:467-477 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Love Author-X-Name-First: Peter Author-X-Name-Last: Love Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Title: Quantifying the causes and costs of rework in construction Abstract: Very few construction companies and consulting firms in Australia measure their costs of quality. Consequently, it is difficult for them to prove that systems for preventing quality failures are cost-effective. Although the direct costs of a quality system can be quantified with some accuracy (salaries, costs of documentation, audits, etc.), the corresponding benefits are far more difficult to assess. Indeed quality failures have become an endemic feature of the procurement process in construction and invariably lead to time and cost overruns in projects. Thus, in order to improve the performance of projects it is necessary to identify the causes and costs rework. The research presented in this paper quantifies the causes, magnitude and costs of rework experienced in two construction projects that were procured using different contractual arrangements. The causes and costs of rework projects are analysed and discussed. The findings reveal that the cost of rework for the case study projects was 3.15% and 2.40% of their project contract value. Changes initiated by the client and end-user together with errors and omissions in contract documentation were found to be the primary causes of rework. It is recommended that construction companies and consultant firms (particularly design consultants) implement quality management practices as well as place emphasis on coordinating project documentation during the design development process so that the amount of rework in projects can be reduced or even eliminated. Journal: Construction Management and Economics Pages: 479-490 Issue: 4 Volume: 18 Year: 2000 Keywords: Australia Quality Costs Prevention Rework, X-DOI: 10.1080/01446190050024897 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190050024897 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:4:p:479-490 Template-Type: ReDIF-Article 1.0 Author-Name: J. H. M. Tah Author-X-Name-First: J. H. M. Author-X-Name-Last: Tah Author-Name: V. Carr Author-X-Name-First: V. Author-X-Name-Last: Carr Title: A proposal for construction project risk assessment using fuzzy logic Abstract: The construction industry is plagued by risk and often has suffered poor performance as a result. There are a number of risk management techniques available to help alleviate this, but usually these are based on operational research techniques developed in the 1960s, and for the most part have failed to meet the needs of project managers. In this paper, a hierarchical risk breakdown structure representation is used to develop a formal model for qualitative risk assessment. A common language for describing risks is presented which includes terms for quantifying likelihoods and impacts so as to achieve consistent quantification. The relationships between risk factors, risks and their consequences are represented on cause and effect diagrams. These diagrams and the concepts of fuzzy association and fuzzy composition are applied to identify relationships between risk sources and the consequences for project performance measures. A methodology for evaluating the risk exposure, considering the consequences in terms of time, cost, quality, and safety performance measures of a project based on fuzzy estimates of the risk components is presented. Journal: Construction Management and Economics Pages: 491-500 Issue: 4 Volume: 18 Year: 2000 Keywords: Construction Projects Common Language Fuzzy Logic Project Performance Qualitative Risk Assessment, X-DOI: 10.1080/01446190050024905 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190050024905 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:4:p:491-500 Template-Type: ReDIF-Article 1.0 Author-Name: Anne Landin Author-X-Name-First: Anne Author-X-Name-Last: Landin Title: ISO 9001 within the Swedish construction sector Abstract: This study analysed how the ISO 9000 framework could be employed in the construction process. Interviews were conducted at twelve companies in Sweden that utilized the quality system standard ISO 9001. Many of the concepts contained in the quality system standard were experienced as being too abstract and too difficult to comprehend. Frequently quality mangement was considered as serving the function of improving the company's competitiveness and allowing the company to be more efficient. It appeared difficult, however, in view of the many stages the construction process encompasses and the diverging interests represented, to meet the needs of the construction sector by the use of ISO 9001 alone. Some of the paragraphs it contains also tended to be confused with one another and to be misinterpreted. Others, although useful elsewhere, appeared scarcely to find application in the construction sector. Developments in the area appear to be going in the direction away from using large bureaucratic inspection systems and quality handbooks aimed at impressing customers and towards employing more diversified systems. Certification was found to be a matter of concern to all of the companies investigated. Journal: Construction Management and Economics Pages: 509-518 Issue: 5 Volume: 18 Year: 2000 Keywords: Quality Management Construction Certification Iso 9000, X-DOI: 10.1080/014461900407310 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900407310 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:5:p:509-518 Template-Type: ReDIF-Article 1.0 Author-Name: Henry Odeyinka Author-X-Name-First: Henry Author-X-Name-Last: Odeyinka Title: An evaluation of the use of insurance in managing construction risks Abstract: One of the major methods of managing construction risks in the Nigerian construction industry is the insurance method. On the basis of data from some selected construction sites in Nigeria, this paper evaluates the effectiveness of the method. Also it identifies, through a questionnaire survey, the various insurable construction risks perceived to be encountered in the Nigerian construction industry and the types of insurance policy employed in managing them. High importance is placed by the construction industry on site security, construction risk, and health and welfare requirements, and the use of an all-risk insurance policy is the most prominent method for managing the identified risks. Finally it is concluded that there is a correlation between insured sum and actual replacement cost when there are losses or damages. However, the insurance claims settled could cater for only 61.1% of the replacement cost of on-going construction works studied. Journal: Construction Management and Economics Pages: 519-524 Issue: 5 Volume: 18 Year: 2000 Keywords: Insurance Construction Risk Contractors Construction Industry Nigeria, X-DOI: 10.1080/014461900407329 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900407329 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:5:p:519-524 Template-Type: ReDIF-Article 1.0 Author-Name: Mats Holm Author-X-Name-First: Mats Author-X-Name-Last: Holm Title: Service management in housing refurbishment: a theoretical approach Abstract: It is unusual to find that housing refurbishment projects have been undertaken with a clear focus on customer orientation directed towards the tenants, or owners of cooperative flats or condominiums. Only recently have researchers in construction management begun to look closer at the relationship between contractors and customers. To assess the scope for customer orientation in the refurbishment industry, current thinking in service management is reviewed here in an attempt to identify principles with implications for housing refurbishment. There is a consensus among service management investigators that services are intangible; other often mentioned characteristics are heterogeneity, perishability, and the inseparability of production and consumption. Except for inseparability these characteristics are valid for refurbishment. Nevertheless, features such as the long turn-round time, the number of participants, the complexity and the uncertainty, distinguish housing refurbishment from most services. There is strong empirical support for the claim that customer satisfaction increases customer loyalty and gives the service producer a positive reputation, ultimately increasing profitability. It is concluded that this insight can be interpreted operationally for housing refurbishment projects, bearing in mind that the tenant or the owner of a cooperative flat is the customer's customer. Journal: Construction Management and Economics Pages: 525-533 Issue: 5 Volume: 18 Year: 2000 Keywords: Housing Refurbishment Customer Satisfaction Service Quality, X-DOI: 10.1080/014461900407338 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900407338 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:5:p:525-533 Template-Type: ReDIF-Article 1.0 Author-Name: J. Nicholas Author-X-Name-First: J. Author-X-Name-Last: Nicholas Author-Name: G. D. Holt Author-X-Name-First: G. D. Author-X-Name-Last: Holt Author-Name: M. Mihsein Author-X-Name-First: M. Author-X-Name-Last: Mihsein Title: Contractor financial credit limits; their derivation and implications for materials suppliers Abstract: Current methodologies for 'calculating' contractors' credit limits (for supply of construction materials) are discussed and critically appraised. It is highlighted that credit limit imposition should be a function of a supplier's financial characteristics as well as potential debtors' probability of defaulting upon repayment. A conceptually new approach is presented to identify whether an additional contractor's trade results in a worthwhile gain in utility for the supplier. It is identified, inter alia, that (i) allowing very few contractors credit facilities that account for a large proportion of suppliers' potential profits, (ii) having inaccurate creditworthiness evaluation procedures, and (iii) operating on low targeted profit margins are the characteristics that inflict maximum financial risk upon materials suppliers. Journal: Construction Management and Economics Pages: 535-545 Issue: 5 Volume: 18 Year: 2000 Keywords: Contractors' Credit Limits Debtors Materials Suppliers Risk Utility Theory, X-DOI: 10.1080/014461900407347 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900407347 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:5:p:535-545 Template-Type: ReDIF-Article 1.0 Author-Name: Patrick Sik-Wah Fong Author-X-Name-First: Patrick Sik-Wah Author-X-Name-Last: Fong Author-Name: Sonia Kit-Yung Choi Author-X-Name-First: Sonia Kit-Yung Author-X-Name-Last: Choi Title: Final contractor selection using the analytical hierarchy process Abstract: Some contractor selection methods currently in existence are criticized as incomplete and biased, and lacking consideration in terms of the contractor's ability to achieve simultaneously, time, cost, quality and safety standards. This research examines an alternative contractor selection model called the analytical hierarchy process (AHP), which will help construction clients to identify contractors with the best potential to deliver satisfactory outcomes in a final contractor selection process which is not based simply on the lowest bid. The AHP comprises three parts: hierarchic structure, prioritization procedure, and calculation of results. This model is tested by a hypothetical scenario where three contractor candidates are evaluated. The criteria used for contractor selection in the model have been identified, and the significance of each criterion has been arrived at by conducting a questionnaire survey in public organizations in Hong Kong. Comparisons are made by ranking the aggregate scores of each candidate with regard to their performance against each of the criteria, and the candidate associated with the highest scores is the best contractor on this occasion. Journal: Construction Management and Economics Pages: 547-557 Issue: 5 Volume: 18 Year: 2000 Keywords: Analytical Hierarchy Process Contractor Selection Prequalification Final Selection Tender Price, X-DOI: 10.1080/014461900407356 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900407356 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:5:p:547-557 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Chin Chin Tan Author-X-Name-First: Chin Chin Author-X-Name-Last: Tan Title: Occupational stereotypes in the construction industry Abstract: An investigation of occupational stereotypes in the construction industry provides insights into the perceptions and expectations which different occupational groups have of each other. The results are valuable in the reduction of uncertainty, misunderstanding and conflict within construction projects and do not support the widely held view of institutionalized confrontational relationships. Instead, there appears to be a natural degree of goodwill underlying interpersonal relationships although it is delicate, precarious and easily destroyed by insensitive managerial practices. Journal: Construction Management and Economics Pages: 559-566 Issue: 5 Volume: 18 Year: 2000 Keywords: Stereotypes Culture Values Attitudes Beliefs Communication Conflict, X-DOI: 10.1080/014461900407365 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900407365 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:5:p:559-566 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Love Author-X-Name-First: Peter Author-X-Name-Last: Love Author-Name: Purnendu Mandal Author-X-Name-First: Purnendu Author-X-Name-Last: Mandal Author-Name: Jim Smith Author-X-Name-First: Jim Author-X-Name-Last: Smith Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Title: Modelling the dynamics of design error induced rework in construction Abstract: Rework that is experienced in construction projects is often caused by errors made during the design process. Factors that contribute to design errors are identified and used to design and develop a systems dynamics model, which is used to simulate a number of practical scenarios that can be used to reduce design errors and rework. The model presented in this paper can enable design and project managers to understand better the process of design documentation and how design errors occur in construction projects. Journal: Construction Management and Economics Pages: 567-574 Issue: 5 Volume: 18 Year: 2000 Keywords: System Dynamics Design Management Time Boxing Design Errors Rework, X-DOI: 10.1080/014461900407374 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900407374 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:5:p:567-574 Template-Type: ReDIF-Article 1.0 Author-Name: A. K. Munns Author-X-Name-First: A. K. Author-X-Name-Last: Munns Author-Name: K. M. Al-Haimus Author-X-Name-First: K. M. Author-X-Name-Last: Al-Haimus Title: Estimating using cost significant global cost models Abstract: Cost significant models have been suggested as one way of overcoming criticisms of the amount of detail contained within the traditional bill of quantities. Recent research into these models reveals a lack of formal rules for the selection of work packages to be used within the models, and a potential to overestimate the cost of projects. This paper presents a methodology for selecting work packages, and recommends a refinement to the technique that reduces the variability in estimates produced using cost significance. Estimates are produced using both the traditional method of producing cost significant models, and a refined global cost methodology. Both techniques are tested against unpriced bills to measure the difference in results, with significant improvements being achieved with the new technique. Journal: Construction Management and Economics Pages: 575-585 Issue: 5 Volume: 18 Year: 2000 Keywords: Bill Of Quantities Cost Estimating Cost Modelling Cost Significance, X-DOI: 10.1080/014461900407383 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900407383 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:5:p:575-585 Template-Type: ReDIF-Article 1.0 Author-Name: Mike Bresnen Author-X-Name-First: Mike Author-X-Name-Last: Bresnen Author-Name: Nick Marshall Author-X-Name-First: Nick Author-X-Name-Last: Marshall Title: Motivation, commitment and the use of incentives in partnerships and alliances Abstract: The use of incentives in partnering and alliancing has been seen as an important way of reinforcing collaboration in the short term and helping to build trust between clients and contractors in the long term. Yet only rarely has the impact of incentives on such relationships been discussed, let alone subjected to systematic investigation. This is despite a wealth of theory and research which brings into question the use of incentives and reinforcers as ways of generating motivation and commitment. Drawing upon this theoretical knowledge base and using evidence from a number of case studies of partnerships and alliances, this paper demonstrates how a number of important cognitive and social dimensions affect the use and impact of incentives, sometimes in ways contrary to those intended. The conclusion drawn is that there are important limitations to the use of incentives as means of reinforcing collaboration and developing commitment and trust, and that this raises questions more generally about the assumptions that underlie many of the practical 'tools and techniques' commonly associated with partnering and alliancing. Journal: Construction Management and Economics Pages: 587-598 Issue: 5 Volume: 18 Year: 2000 Keywords: Partnering Alliancing Incentives Motivation Commitment, X-DOI: 10.1080/014461900407392 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900407392 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:5:p:587-598 Template-Type: ReDIF-Article 1.0 Author-Name: Michael Hoxley Author-X-Name-First: Michael Author-X-Name-Last: Hoxley Title: Are competitive fee tendering and construction professional service quality mutually exclusive? Abstract: It is a little more than 15 years since the associations representing construction professionals in the UK surrendered to government pressure and abolished mandatory fee scales, predicting as they did so that inevitably abolition would lead to a decline in the standard of service provided to clients. Initially the abolition of fee scales had little impact on fee levels - in the UK economic and property boom of the late 1980s demand from clients in all sectors was high and fee levels remained at, or close to, pre-abolition levels. However, in the recession that followed, fee levels fell to unprecedentedly low levels, causing many commentators to be concerned that the quality of service provided to clients would fall. The main aim of this research is to establish whether clients' perceptions of service quality have declined as a result of lower fee scales. Following a literature search five hypotheses are presented namely, that clients' perceptions of service quality are: lower for fee tendered commissions; lower when the fee bid is particularly competitive; higher when the service is adequately specified by the client; higher when care has been taken with preselection of tenderers; and higher when adequate weighting to ability is given in the final selection process. The hypotheses have been tested by collecting data from 244 clients who anonymously assessed consultants, 60% of whom were chartered surveyors (just over half of these were quantity surveyors). Over half of the consultants were appointed by competitive fee tender, and although the service quality scores were lower for these consultants this result was not statistically significant. Therefore, the main hypothesis is not supported by the data but the fourth and fifth hypotheses are both supported by the study. Journal: Construction Management and Economics Pages: 599-605 Issue: 5 Volume: 18 Year: 2000 Keywords: Construction Professionals Fee Tendering Service Quality, X-DOI: 10.1080/014461900407400 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900407400 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:5:p:599-605 Template-Type: ReDIF-Article 1.0 Author-Name: Goh Bee Hua Author-X-Name-First: Goh Bee Author-X-Name-Last: Hua Author-Name: Teo Ho Pin Author-X-Name-First: Teo Ho Author-X-Name-Last: Pin Title: Forecasting construction industry demand, price and productivity in Singapore: the Box-Jenkins approach Abstract: In academic research, the traditional Box-Jenkins approach is widely acknowledged as a benchmark technique for univariate methods because of its structured modelling basis and acceptable forecasting performance. This study examines the versatility of this approach by applying it to analyse and forecast three distinct variables of the construction industry, namely, tender price, construction demand and productivity, based on case studies of Singapore. In order to assess the adequacy of the Box-Jenkins approach to construction industry forecasting, the models derived are evaluated on their predictive accuracy based on out-of-sample forecasts. Two measures of accuracy are adopted, the root mean-square-error (RMSE) and the mean absolute percentage error (MAPE). The conclusive findings of the study include: (1) the prediction RMSE of all three models is consistently smaller than the model's standard error, implying the models' good predictive performance; (2) the prediction MAPE of all three models consistently falls within the general acceptable limit of 10%; and (3) among the three models, the most accurate is the demand model which has the lowest MAPE, followed by the price model and the productivity model. Journal: Construction Management and Economics Pages: 607-618 Issue: 5 Volume: 18 Year: 2000 Keywords: Box-JENKINS Approach Forecasting Construction Demand Tender Price Productivity Accuracy, X-DOI: 10.1080/014461900407419 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900407419 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:5:p:607-618 Template-Type: ReDIF-Article 1.0 Author-Name: David Crosthwaite Author-X-Name-First: David Author-X-Name-Last: Crosthwaite Title: The global construction market: a cross-sectional analysis Abstract: Construction is a major industry throughout the world accounting for a sizeable proportion of most countries gross domestic product (GDP). According to a recent survey, total world construction spending in 1998 was over $3 trillion. Furthermore the importance of the construction sector is related not only to its size but also to its role in economic development. This paper examines the extent of international construction activity, and is based on a cross-sectional analysis of published data pertaining to global construction spending. The principal findings suggest that the role of construction changes as economic development proceeds. It was found that the share of construction spending in GDP first grows during less developed country (LDC) status, peaks during newly industrializing country (NIC) status and then declines as countries move from NIC to advanced industrialized country (AIC) status. The research identifies the importance of construction within NICs. The regions of Asia and Latin America and the countries of China, Mexico, Argentina and Egypt are considered noteworthy in regard to various indicators concerned with construction and economic activity. However, the conclusion is that as economic development proceeds from NIC to AIC status construction fails to maintain its share of GDP and therefore declines in importance. Journal: Construction Management and Economics Pages: 619-627 Issue: 5 Volume: 18 Year: 2000 Keywords: Global Construction Activity Cross-SECTIONAL Analysis Economic Development Regional Markets National Markets, X-DOI: 10.1080/014461900407428 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900407428 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:5:p:619-627 Template-Type: ReDIF-Article 1.0 Author-Name: Lars Huemer Author-X-Name-First: Lars Author-X-Name-Last: Huemer Author-Name: Katarina Östergren Author-X-Name-First: Katarina Author-X-Name-Last: Östergren Title: Strategic change and organizational learning in two 'Swedish' construction firms Abstract: The two largest construction companies in Sweden, NCC and Skanska, previously have acted according to what here is called a multi-domestic strategy. Such a strategy implies that each market is treated essentially in isolation. Due to perceived pressures for local responsiveness, the firms have focused on utilizing local knowledge and experience, while failing to obtain economies of scale and to learn from the different localities. A combination of changing perceptions of being local and a growing number of home markets makes possible a strategic approach that is inter-domestic in nature. This approach stresses the importance of learning and of coordinating the experience a construction firm achieves in many different localities. Therefore learning is seen not only as a process of adaptation to the environment, but also as an evolutionary process built on an organization's identity, which is created by both structural and individual factors. The identity of an organization helps us to understand its ability to learn. Journal: Construction Management and Economics Pages: 635-642 Issue: 6 Volume: 18 Year: 2000 Month: 12 X-DOI: 10.1080/014461900414682 File-URL: http://hdl.handle.net/10.1080/014461900414682 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:6:p:635-642 Template-Type: ReDIF-Article 1.0 Author-Name: Sihem Ben Mahmoud-Jouini Author-X-Name-First: Sihem Ben Author-X-Name-Last: Mahmoud-Jouini Title: Innovative supply-based strategies in the construction industry Abstract: In the construction industry demand drives the design process and as a result design is structured in order to respond to this demand. However, what happens when this demand breaks down, when traditional markets are saturated, and no feasible alternative arises? Will this sector be capable of refocusing their efforts on creating new products to offer? Is it possible for industry participants to adopt a proactive strategy? These questions are investigated and it is seen that the French construction industry, and in particular major contractors, illustrate the problem perfectly. Examples are analysed of innovative offerings in this industry, two groups of which could be developed further. Journal: Construction Management and Economics Pages: 643-650 Issue: 6 Volume: 18 Year: 2000 Month: 12 X-DOI: 10.1080/014461900414691 File-URL: http://hdl.handle.net/10.1080/014461900414691 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:6:p:643-650 Template-Type: ReDIF-Article 1.0 Author-Name: Ezio Micelli Author-X-Name-First: Ezio Author-X-Name-Last: Micelli Title: Mobilizing the skills of specialist firms to reduce costs and enhance performance in the European construction industry: two case studies Abstract: Analyses are made of procurement strategies capable of leading to cost reduction and higher quality through the contribution of specialized firms. An exploration is made of the literature concerning the procurement of manufactured goods and progress by analysing two case studies: the East Bridge of the Storebælt link and the Grand Canal Maritime bridge. Both these projects adopted procurement systems that led to a learning process capable of enhancing performance and reducing overall costs. It is evident that the success of learning-oriented procurement strategies relies on two major conditions. First, the client's tender must be issued with an open design demanding an active contribution from the firms involved in the construction process. Second, the firms bidding for the job must be able to manage two distinct sets of skills: the technical skills relating to a specific production process and the ability to connect these skills to the client's needs through a co-design process, or what is known as the strategic intermediation function. Journal: Construction Management and Economics Pages: 651-656 Issue: 6 Volume: 18 Year: 2000 Month: 12 X-DOI: 10.1080/014461900414709 File-URL: http://hdl.handle.net/10.1080/014461900414709 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:6:p:651-656 Template-Type: ReDIF-Article 1.0 Author-Name: D. G. Proverbs Author-X-Name-First: D. G. Author-X-Name-Last: Proverbs Author-Name: G. D. Holt Author-X-Name-First: G. D. Author-X-Name-Last: Holt Title: A theoretical model for optimum project (time) performance based on European best practice Abstract: The authors have over recent years performed extensive empirical research into European (UK, French and German) construction contractor performance. This paper represents the culmination of that research, by presenting a model for achieving optimum project time performance based on European best practice. By removing or neutralizing the impact of external factors (e.g. procurement method), the research concentrated on contractor practices and their direct impact on construction time performance. A variety of European contractor performance data were analysed to identify optimum solutions (i.e. contractors, construction practices) for achieving fastest project completion. The principal theme of the paper is graphical presentation and description of a theoretical model for optimum project (time) performance based on European best practice. Further, characteristics of UK, French and German variants of the model are presented. The application of multiple regression analysis to the data suggests that there are other factors, not embraced by the model, that may also impact significantly upon construction time performance. European contractors and clients may wish to consider the characteristics of these model(s) in striving to achieve earliest project completion. Journal: Construction Management and Economics Pages: 657-665 Issue: 6 Volume: 18 Year: 2000 Month: 12 X-DOI: 10.1080/014461900414718 File-URL: http://hdl.handle.net/10.1080/014461900414718 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:6:p:657-665 Template-Type: ReDIF-Article 1.0 Author-Name: Eric Henry Author-X-Name-First: Eric Author-X-Name-Last: Henry Title: Quality management standardization in the French construction industry: singularities and internationalization prospects Abstract: Over the last 10 years quality management in the French construction industry has triggered a range of innovative ideas spanning all professions, ideas that have been developed further through action-research. The creation of quality clubs is one of the first examples of this, followed by the setting up of professional quality assurance references based on the ISO 9002 Standard, to be used first and foremost by construction contractors (QUALIBAT), but also by architects (AQC and QUALIARCH), and finally clients (QUALIMO). The clubs and QUALIBAT are today experiencing either a decrease in activity or a growth-caused crisis, made all the worse by the devastating effects of a long, drawn-out activity crisis which lasted from 1993 until 1998 and led to widespread abnormally low prices. A new impetus has been given to the sector by the Construction Branch of the French Movement for Quality (MFQ) through the combined force of the clubs experience and the development of professional quality references. The innovation consists of drawing up an experimental standard for quality management in the construction industry and actively participating in revising the ISO 9000 Standards for the year 2000. Although specifically French, other countries in southern Europe and Latin America with whom there has been regular contact since 1996 are interested in this initiative. Journal: Construction Management and Economics Pages: 667-677 Issue: 6 Volume: 18 Year: 2000 Month: 12 X-DOI: 10.1080/014461900414727 File-URL: http://hdl.handle.net/10.1080/014461900414727 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:6:p:667-677 Template-Type: ReDIF-Article 1.0 Author-Name: Jean-Luc Guffond Author-X-Name-First: Jean-Luc Author-X-Name-Last: Guffond Author-Name: Gilbert Leconte Author-X-Name-First: Gilbert Author-X-Name-Last: Leconte Title: Developing construction logistics management: the French experience Abstract: To recover from the construction crisis, major French construction firms started developing 'package building' strategies at the beginning of the 1990s. Today, their desire to open up continues, but they have also shown renewed interest in the management of construction site activities and production engineering, as witnessed by the practices of 'logistics management'. How can we justify this inward-looking attitude to construction? What place is there for innovation? Along what lines must this new approach to production management develop? These questions are addressed with reference to the analysis recently produced by a panel of experts led by the authors. The study of various experimental construction sites shows that although it may not yet be well established, this approach has resulted in significant changes in the way construction projects are organized. It places the emergence of new forms of coordination both within and between firms right at the heart of the quest for production efficiency. Journal: Construction Management and Economics Pages: 679-687 Issue: 6 Volume: 18 Year: 2000 Month: 12 X-DOI: 10.1080/014461900414736 File-URL: http://hdl.handle.net/10.1080/014461900414736 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:6:p:679-687 Template-Type: ReDIF-Article 1.0 Author-Name: Linda Clarke Author-X-Name-First: Linda Author-X-Name-Last: Clarke Author-Name: Christine Wall Author-X-Name-First: Christine Author-X-Name-Last: Wall Title: Craft versus industry: the division of labour in European housing construction Abstract: Two distinct divisions and concepts of labour are apparent from an analysis of social housebuilding sites in the UK, Germany and the Netherlands: the craft form, based on controlling the output of labour; and the industry form, based on the quality of labour input. These are associated with different work processes, skills and training, and also different levels of mechanization and component prefabrication. In the UK, which is craft-based, low levels of mechanization and prefabrication were found compared with Germany and the Netherlands, and the range of activities for the separate trades in assembling superstructure elements was simpler. Labourers are distinct from craftsmen and remain a significant group. Skills are narrow and training provision low. A high proportion of the labour force remains self-employed, under labour-only subcontractors, working to price or output. In comparison, in Germany and the Netherlands labour is employed directly and work processes are more complex, with more specialisms at the interfaces. The division of labour is industry-wide, training provision is extensive, and skills are broad and integrated into the grading structure. Greater speed, higher productivity and lower levels of supervision are associated with industry-wide systems compared with traditional craft forms. Journal: Construction Management and Economics Pages: 689-698 Issue: 6 Volume: 18 Year: 2000 Month: 12 X-DOI: 10.1080/014461900414745 File-URL: http://hdl.handle.net/10.1080/014461900414745 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:6:p:689-698 Template-Type: ReDIF-Article 1.0 Author-Name: Jan Druker Author-X-Name-First: Jan Author-X-Name-Last: Druker Author-Name: Richard Croucher Author-X-Name-First: Richard Author-X-Name-Last: Croucher Title: National collective bargaining and employment flexibility in the European building and civil engineering industries Abstract: Change in employment practice in the European construction industry is reviewed with particular attention to the effects of flexible working on established arrangements for national collective bargaining. Data derive from European survey research coordinated by Cranfield School of Management in 1995 and from interviews with trade union and employers association representatives in the same period. Membership and support for trade unions and employers associations has weakened, although there are significant differences between countries. The most significant changes in employment practice in construction are found in the increased use of temporary, short term and fixed term contracts; in subcontracting, and in the use of overtime. These changing working practices tend to fragment the workforce and to undermine established systems of institutional interest representation. The distinctive commitment of UK employers to temporary or casual work and to subcontracting is confirmed. The changes contribute to pressure on arrangements established through multi-employer bargaining, although employers and trade union representatives remained committed, at the time of our research, to multi-employer collective agreements. Journal: Construction Management and Economics Pages: 699-709 Issue: 6 Volume: 18 Year: 2000 Month: 12 X-DOI: 10.1080/014461900414754 File-URL: http://hdl.handle.net/10.1080/014461900414754 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:6:p:699-709 Template-Type: ReDIF-Article 1.0 Author-Name: ]ÖRN JANSSEN Author-X-Name-First: ]ÖRN Author-X-Name-Last: JANSSEN Title: The European construction industry and its competitiveness: a construct of the European Commission Abstract: The 'European construction industry' is a fiction that tends to obscure its heterogeneous character and to mar studies and policies of the European Commission aimed at improving the internal and external 'competitiveness' of the sector. In order to assess the process of integration in Europe under the impact of its own dynamics as well as Union policies, this paper looks at the dynamics of the sector from three different aspects: as investment, production and labour process. It shows, in particular, the persistent regional and social disparities dividing the industry into separate entities. Political attention tends to focus on a small number of construction companies competing for a few projects which represent the European dimension. Yet, these companies still rely on their respective national bases and local labour from the place where construction is carried out. Persistent divisions between the states are also reflected in the low level of transnational organization of the construction industry. The policy of the European Commission generally ignores these divisions and attempts to establish principles intended to make a whole sector more 'competitive', while its component parts, operating at hugely different levels of productivity, do not even meet on the same market. This paper argues that, instead of trying in vain to introduce a 'knock-out' system of competition in the EU Member States, a targeted approach might help raise productivity in lagging regions and thus improve the basis of competitiveness on global markets. Journal: Construction Management and Economics Pages: 711-720 Issue: 6 Volume: 18 Year: 2000 Month: 12 X-DOI: 10.1080/01446193.2000.10800483 File-URL: http://hdl.handle.net/10.1080/01446193.2000.10800483 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:6:p:711-720 Template-Type: ReDIF-Article 1.0 Author-Name: Paolo Tombesi Author-X-Name-First: Paolo Author-X-Name-Last: Tombesi Title: Modelling the dynamics of design error induced rework in construction: comment Abstract: The bridging of different research disciplines such as computer modelling and design practice requires full understanding of both. Privileging one area of investigation while simplifying the other is not a feasible option. This approach is likely to produce work that scarcely reflects the actual complexity of the phenomena discussed. Journal: Construction Management and Economics Pages: 727-732 Issue: 7 Volume: 18 Year: 2000 Keywords: Design Research Design Management Design Process Design Documentation Design Labour, X-DOI: 10.1080/014461900433014 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900433014 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:7:p:727-732 Template-Type: ReDIF-Article 1.0 Author-Name: Michael Ball Author-X-Name-First: Michael Author-X-Name-Last: Ball Author-Name: Mahtab Farshchi Author-X-Name-First: Mahtab Author-X-Name-Last: Farshchi Author-Name: Maurizio Grilli Author-X-Name-First: Maurizio Author-X-Name-Last: Grilli Title: Competition and the persistence of profits in the UK construction industry Abstract: An examination has been made of the performance of a range of medium-size publicly quoted construction firms over the five-year period 1990-1994 including evidence on the competitive nature of construction markets. The results suggest that construction markets are price competitive with mark-ups that vary positively with the construction cycle. Common arguments that competition in construction is excessive and that firms can gain from firm specific strategies are not supported by the analysis. Journal: Construction Management and Economics Pages: 733-745 Issue: 7 Volume: 18 Year: 2000 Keywords: Competition Medium-SIZE Price Competitive Excessive, X-DOI: 10.1080/014461900433023 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900433023 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:7:p:733-745 Template-Type: ReDIF-Article 1.0 Author-Name: Maggie Davidson Author-X-Name-First: Maggie Author-X-Name-Last: Davidson Author-Name: Philip Leather Author-X-Name-First: Philip Author-X-Name-Last: Leather Title: Choice or necessity? A review of the role of DIY in tackling housing repair and maintenance Abstract: Do-it-yourself (DIY) is a staple element of the spare time activities of many households, but little is known about the extent to which basic repair work is carried out through DIY and about the quality of this work. Through secondary analyses of UK government data (English House Condition Survey and Family Expenditure Survey), this paper examines the scale of DIY work by owner-occupiers, how work is organized, the interrelationship of DIY work, the use of unpaid help, and the use of contractors. It considers the types of work carried out, the characteristics of those who tackle DIY or use unpaid help, the dwelling types most likely to experience DIY work, and the motivations of and constraints on those home-owners who do it. The paper concludes with a discussion on the policy implications of these findings for government and the building industry. Although most DIY work is cosmetic and does not deal with basic repair and maintenance, the sheer scale of DIY ensures that it makes a contribution to improving housing conditions. The provision of more advice, information and education by government, local authorities and the private sector could ensure that more DIY work is of better quality and that home owners give priority to essential repairs whether or not they tackle these themselves. Journal: Construction Management and Economics Pages: 747-756 Issue: 7 Volume: 18 Year: 2000 Keywords: Building Do-IT-YOURSELF Housing Maintenance Repair, X-DOI: 10.1080/014461900433032 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900433032 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:7:p:747-756 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Chin Chin Tan Author-X-Name-First: Chin Chin Author-X-Name-Last: Tan Title: Occupational bias in construction management research Abstract: Biased research results occur when allowances are not made for the cultural perspectives of researchers and respondents. Occupation is a strong source of cultural differentiation in the construction industry, and this paper investigates the potential for bias to arise from people's association with a particular group. A model of occupational stereotypes is presented which expands our current understanding of how different professions perceive each other. This is useful in a research context because it provides a firmer foundation for the interpretation of past research results. Furthermore, it enables researchers to understand the potential for bias to arise from their own occupational backgrounds and to acknowledge these in their research results. A series of suggestions are made which may help researchers reduce occupational bias in their research. Journal: Construction Management and Economics Pages: 757-766 Issue: 7 Volume: 18 Year: 2000 Keywords: Research Bias Occupation Culture Beliefs Attitudes Stereotypes, X-DOI: 10.1080/014461900433041 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900433041 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:7:p:757-766 Template-Type: ReDIF-Article 1.0 Author-Name: Chee Wong Author-X-Name-First: Chee Author-X-Name-Last: Wong Author-Name: Gary Holt Author-X-Name-First: Gary Author-X-Name-Last: Holt Author-Name: Patricia Cooper Author-X-Name-First: Patricia Author-X-Name-Last: Cooper Title: Lowest price or value? Investigation of UK construction clients' tender selection process Abstract: There is a growing urge for a shift from 'lowest-price wins' to 'multi-criteria selection' practices in the contractor selection process. The rationale is to achieve best value (for money) for the client. Earlier investigations have found that the tender price (i.e. capital cost) still dominates the final selection decision despite increased emphases on the need for contractor selection based on 'value'. This paper provides insights into the evaluation of contractors' attributes, particularly for project-specific criteria (PSC), that is, criteria against which tendering contractors may be considered. The importance attached by clients to the 'lowestprice wins' philosophy is also reported. The perceived importance of PSC (i.e. their influence on final selection choice) is determined through a structured questionnaire survey of UK construction clients. The results show an increasing use of PSC. It is also found that 'lowest-price' is not now necessarily the client's principal selection criterion, but rather, the realization that cost has to be tempered with evaluation of PSC in any attempt to identify value for money. Journal: Construction Management and Economics Pages: 767-774 Issue: 7 Volume: 18 Year: 2000 Keywords: Contractor Selection Lowest-PRICE Tender Multi-CRITERIA Selection Project-SPECIFIC Criteria Tender Evaluation, X-DOI: 10.1080/014461900433050 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900433050 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:7:p:767-774 Template-Type: ReDIF-Article 1.0 Author-Name: D. A. Langford Author-X-Name-First: D. A. Author-X-Name-Last: Langford Author-Name: H. El-Tigani Author-X-Name-First: H. Author-X-Name-Last: El-Tigani Author-Name: M. Marosszeky Author-X-Name-First: M. Author-X-Name-Last: Marosszeky Title: Does quality assurance deliver higher productivity? Abstract: This paper seeks to assess whether the implementation of formal quality schemes in the construction industry delivers higher productivity when measured at site level. The work reports an experiment in which the resources used by construction contractors to build housing association houses varied in accordance with the level of formal quality certification held by the contractors. It concludes that formally assured organizations use fewer resources to create the same output. Journal: Construction Management and Economics Pages: 775-782 Issue: 7 Volume: 18 Year: 2000 Keywords: Quality Assurance Housebuilding Productivity, X-DOI: 10.1080/014461900433069 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900433069 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:7:p:775-782 Template-Type: ReDIF-Article 1.0 Author-Name: Mohan Kumaraswamy Author-X-Name-First: Mohan Author-X-Name-Last: Kumaraswamy Author-Name: Sunil Dissanayaka Author-X-Name-First: Sunil Author-X-Name-Last: Dissanayaka Title: ISO 9000 and beyond: from a Hong Kong construction perspective Abstract: Client driven 'pushes' for ISO 9000 certification in Hong Kong are observed to have overtaken any spontaneous 'pull factors' (motivators) towards quality improvements 'for their own sake'. For example, the need for ISO 9000 certification as a prerequisite for even being considered for public sector construction works appears to have distracted some organizations from a more comprehensive organization-specific development of their quality management systems. Both positive (beneficial) and negative (detrimental) outcomes from ISO 9000 certification, as observed from relevant previous studies, are summarized herein. These provide a useful background against which to present perceptions derived from the current study in Hong Kong construction. The target groups were predominantly from consultants in the initial survey and all from contractors in the second and more comprehensive survey. The more significant positive and negative outcomes from ISO 9000 certification as derived from the two current surveys are identified. Recommendations are made for realigned approaches to ISO 9000 certification and for seamless integration with other quality management approaches such as TQM, as well as with other management subsystems, such as for productivity improvement and dispute minimization. Journal: Construction Management and Economics Pages: 783-796 Issue: 7 Volume: 18 Year: 2000 Keywords: Hong Kong Integration Iso 9000 Tqm Quality Management, X-DOI: 10.1080/014461900433078 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900433078 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:7:p:783-796 Template-Type: ReDIF-Article 1.0 Author-Name: E. S. Wong Author-X-Name-First: E. S. Author-X-Name-Last: Wong Author-Name: Danny Then Author-X-Name-First: Danny Author-X-Name-Last: Then Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Antecedents of trust in intra-organizational relationships within three Singapore public sector construction project management agencies Abstract: This paper examines the role and nature of trust in construction project management performance. Three causes, or antecedents, of trust are identified: results, integrity and concern. A questionnaire survey of construction project team members employed by three public sector infrastructure organizations in Singapore is described. The results confirm the expected correlations. Concluding remarks suggest that enlightened management is needed to keep the three antecedents in reasonable balance. Journal: Construction Management and Economics Pages: 797-806 Issue: 7 Volume: 18 Year: 2000 Keywords: Trust Results Integrity Concern Performance, X-DOI: 10.1080/014461900433087 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900433087 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:7:p:797-806 Template-Type: ReDIF-Article 1.0 Author-Name: Graham Winch Author-X-Name-First: Graham Author-X-Name-Last: Winch Title: Innovativeness in British and French construction: the evidence from Transmanche-Link Abstract: This paper addresses the 'innovativeness' (the extent to which the design of the organization facilitates or inhibits innovation) of French and British project organizations. Following a review of the literature on organization design and innovativeness, data from a comparative organizational assessment of the British and French approaches to managing the Channel Tunnel construction project by Transmanche-Link are presented. These show that the British approach could well have less capacity for innovation than the French. The available evidence on the relative levels of innovation on the two sides of the Channel Tunnel are reviewed, showing that the predicted effects are found. Journal: Construction Management and Economics Pages: 807-817 Issue: 7 Volume: 18 Year: 2000 Keywords: French Construction British Construction Channel Tunnel Major Projects Construction Innovation, X-DOI: 10.1080/014461900433096 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900433096 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:7:p:807-817 Template-Type: ReDIF-Article 1.0 Author-Name: Mike Bresnen Author-X-Name-First: Mike Author-X-Name-Last: Bresnen Author-Name: Nick Marshall Author-X-Name-First: Nick Author-X-Name-Last: Marshall Title: Building partnerships: case studies of client-contractor collaboration in the UK construction industry Abstract: Despite the enormous groundswell of interest in partnering and alliancing in recent years, there has been comparatively little research that has set out to investigate systematically the nature, feasibility, benefits and limitations of forms of client-contractor collaboration. This is despite the growing recognition that conditions conducive to partnering may well vary considerably and that partnering may not be the solution for problems within the industry that many commentators have taken it to be. This paper sets out to add to the growing literature and empirical database on partnering by reporting the findings of a research project designed to explore the economic, organizational and technological factors that encourage or inhibit collaboration in practice. The paper follows on from an earlier review and critique of the literature on partnering (Bresnen, M. and Marshall, N. 2000, Construction Management and Economics, 18 (2) 229-237). It includes as its database nine case studies of medium-to-large-scale projects, selected from across the industry, on which processes of collaboration are examined from the viewpoints of clients, contractors, designers and subcontractors. In contrast to much of the prescriptive work in this area, the analysis of the data and the paper's conclusions stress some of the practical problems, limitations and paradoxes of partnering and alliancing when the effects of important economic, organizational and psychological factors are taken into account. Journal: Construction Management and Economics Pages: 819-832 Issue: 7 Volume: 18 Year: 2000 Keywords: Management Partnering Alliancing Clients, X-DOI: 10.1080/014461900433104 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900433104 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:7:p:819-832 Template-Type: ReDIF-Article 1.0 Author-Name: Guinevere Smithers Author-X-Name-First: Guinevere Author-X-Name-Last: Smithers Author-Name: Derek Walker Author-X-Name-First: Derek Author-X-Name-Last: Walker Title: The effect of the workplace on motivation and demotivation of construction professionals Abstract: Investigations have been carried out which suggest that motivation of employees in all industries is affected by the environment or culture in which they work. Research undertaken in Melbourne, Australia investigated the effect of the workplace environment encountered on a construction site on motivation and demotivation of construction professionals. The data collected supported the hypothesis that the environment of a construction site does affect demotivation levels of site personnel. Specifically, several variables were significantly linked to this result, including long hours, chaos, non-recognition for work done and colleagues' aggressive management style. The results provide a valuable basis for indicating how the construction industry can create a more attractive workplace environment for professional site staff. Journal: Construction Management and Economics Pages: 833-841 Issue: 7 Volume: 18 Year: 2000 Keywords: Culture Motivation Demotivation Management Workplace, X-DOI: 10.1080/014461900433113 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900433113 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:7:p:833-841 Template-Type: ReDIF-Article 1.0 Author-Name: S. Thomas Ng Author-X-Name-First: S. Thomas Author-X-Name-Last: Ng Author-Name: Sai On Cheung Author-X-Name-First: Sai On Author-X-Name-Last: Cheung Author-Name: R. Martin Skitmore Author-X-Name-First: R. Martin Author-X-Name-Last: Skitmore Author-Name: Ka Chi Lam Author-X-Name-First: Ka Chi Author-X-Name-Last: Lam Author-Name: Lai Yi Wong Author-X-Name-First: Lai Yi Author-X-Name-Last: Wong Title: Prediction of tender price index directional changes Abstract: A multivariate discriminant analysis is described, aimed at predicting the direction of changes in the Hong Kong tender price index by utilizing the patterns of change in eight leading economic indicators. Two discriminant functions are derived which distinguish between 'upward', 'constant' and 'downward' index trends with a high degree of success. The predictive power of the discriminant model is tested by means of a simulated ex post holdout sample of eight index values. By comparing the group centroids, seven of the cases are correctly classified. The hit rate of the 'upward' and 'constant' groups is 100%, while the 'downward' group has a hit rate of 75%, suggesting the 'downward' trend to be a more difficult movement to predict. Despite this, the overall predictive results are considerably better than those that would have occurred by chance alone. Journal: Construction Management and Economics Pages: 843-852 Issue: 7 Volume: 18 Year: 2000 Keywords: Tender Price Index Economic Indicators Trend Multivariate Discriminant Analysis Forecasts, X-DOI: 10.1080/014461900433122 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900433122 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:7:p:843-852 Template-Type: ReDIF-Article 1.0 Author-Name: S. MacKenzie Author-X-Name-First: S. Author-X-Name-Last: MacKenzie Author-Name: A. R. Kilpatrick Author-X-Name-First: A. R. Author-X-Name-Last: Kilpatrick Author-Name: A. Akintoye Author-X-Name-First: A. Author-X-Name-Last: Akintoye Title: UK construction skills shortage response strategies and an analysis of industry perceptions Abstract: The construction industry is heavily dependent on the adequate supply of a skilled labour force, and as a result the skilled labour shortage in the UK has received considerable attention in recent years. With the current economic recovery the industry is expected to experience considerable skills shortages in both traditional and new skills areas. This paper analyses the views of construction employers in relation to the response strategies promoted by industry and government and identified in previous research which tackle elements of the skills shortage problem within the UK construction industry. The paper describes seven existing industry and government schemes, and a further nine alternative response strategies to the construction skills shortage. The survey analysis demonstrates that construction employers support: (i) the Construction Skills Certification Scheme, (ii) the Investors in People standard, (iii) economic stability within the industry; (iv) long term industry-wide training plans, (v) a return to direct employment; and (vi) the development of new technologies and construction techniques. It is concluded that the effectiveness of alternative response strategies is linked to the traditional approach of most contractors. Journal: Construction Management and Economics Pages: 853-862 Issue: 7 Volume: 18 Year: 2000 Keywords: Labour Shortage Skills Response Strategies, X-DOI: 10.1080/014461900433131 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900433131 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:7:p:853-862 Template-Type: ReDIF-Article 1.0 Author-Name: Albert Chan Author-X-Name-First: Albert Author-X-Name-Last: Chan Title: Evaluation of enhanced design and build system - a case study of a hospital project Abstract: This study involves an investigation of a hospital project which adopted an 'enhanced design and build' form of building procurement. The paper assesses the procurement system from the perspectives of the client, client's consultants, contractor, contractor's consultants, and contractor's subcontractors. A detailed case study of North District Hospital is described to illustrate the process of this procurement system. All the interviewees generally agreed that the hospital project was successful in meeting the time, cost, quality, functional and safety requirements set by the client. As the first project adopting the 'enhanced design-build' procurement system in Hong Kong, the benefits of applying this innovative procurement system were demonstrated. Journal: Construction Management and Economics Pages: 863-871 Issue: 7 Volume: 18 Year: 2000 Keywords: Enhanced Design Build Procurement System Hospital Projects, X-DOI: 10.1080/014461900433140 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900433140 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:7:p:863-871 Template-Type: ReDIF-Article 1.0 Author-Name: Chiel Boonstra Author-X-Name-First: Chiel Author-X-Name-Last: Boonstra Author-Name: Marjo Knapen Author-X-Name-First: Marjo Author-X-Name-Last: Knapen Title: Knowledge infrastructure for sustainable building in The Netherlands Abstract: The article describes the development and expected future direction of knowledge infrastructure pertaining to sustainable building in The Netherlands with particular reference to two computer programs based on lifecycle analyses: Eco-Quantum Residential and Eco-Quantum Research. The first is a tool for architects to identify the environmental consequences of different options, while Eco-Quantum Research allows for in-depth analyses and therefore can be used for developing innovative designs. The programs were made commercially available in November 1999 after testing by practitioners and municipalities in The Netherlands. An example of the design of an office building guided by Eco-Quantum is also given. Journal: Construction Management and Economics Pages: 885-891 Issue: 8 Volume: 18 Year: 2000 Keywords: Building Code Construction Products Demolition Dismantling, X-DOI: 10.1080/01446190010001193 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010001193 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:8:p:885-891 Template-Type: ReDIF-Article 1.0 Author-Name: Anthony Lavers Author-X-Name-First: Anthony Author-X-Name-Last: Lavers Author-Name: David Shiers Author-X-Name-First: David Author-X-Name-Last: Shiers Title: Construction law and environmental harm: the liability interface Abstract: Construction professionals are increasingly exposed to risk deriving from legal responsibility for environmental harm. To assess the levels of exposure to this risk, those involved in property need to understand the impact of environmental issues upon construction law. Construction law literature and specialist environmental law sources on construction can provide a basis for study. The main themes found in these sources are planning law, environmental protection, waste and waste management and contamination, including water pollution, and these are reviewed. A study of the litigation reported in the principal specialist construction law sources reinforces the significance of these themes through the identification of the case law embodying them. There are other areas of impact and potential impact: visual/aesthetic harm, harm to acoustic amenity, the use and removal of deleterious materials (such as asbestos) and other 'indirect' risks. Journal: Construction Management and Economics Pages: 893-902 Issue: 8 Volume: 18 Year: 2000 Keywords: Environment Environmental Harm Liability Construction Law, X-DOI: 10.1080/01446190010001201 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010001201 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:8:p:893-902 Template-Type: ReDIF-Article 1.0 Author-Name: Charles Kibert Author-X-Name-First: Charles Author-X-Name-Last: Kibert Author-Name: Jan Sendzimir Author-X-Name-First: Jan Author-X-Name-Last: Sendzimir Author-Name: Brad Guy Author-X-Name-First: Brad Author-X-Name-Last: Guy Title: Construction ecology and metabolism: natural system analogues for a sustainable built environment Abstract: Applying the principles of sustainability to human activities ultimately must result in the scrutiny of all sectors of economic activity to assess the changes required to provide for a high quality of life for future generations. A high priority for evaluation, in the light of its impacts on environmental quality and resources, is industrial activity in general and the construction industry specifically. The construction sector consumes 40% of all extracted materials in the USA, and accounts for 30% of national energy consumption for its operation. The sustainability of this industrial sector is dependent on a fundamental shift in the way resources are used, from non-renewables to renewables, from high levels of waste to high levels of reuse and recycling, and from products based on lowest first cost to those based on life-cycle costs and full cost accounting, especially as applied to waste and emissions from the industrial processes that support construction activity. The emerging field of industrial ecology provides some insights into sustainability in the built environment or sustainable construction. Construction, like other industries, would benefit from observing the metabolic behaviour of natural systems where sustainability is built in. This paper describes a view of the construction industry based on natural systems and industrial ecology for the purpose of beginning the discovery of how to shift the construction industry and its supporting materials industries onto a path much closer to the ideals of sustainability. Journal: Construction Management and Economics Pages: 903-916 Issue: 8 Volume: 18 Year: 2000 Keywords: Sustainability Resource Efficiency Sustainable Construction Industrial Ecology Industrial Metabolism Design For The Environment Construction Ecology Construction Metabolism, X-DOI: 10.1080/014461900446867 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900446867 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:8:p:903-916 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Graham Author-X-Name-First: Peter Author-X-Name-Last: Graham Title: Building education for the next industrial revolution: teaching and learning environmental literacy for the building professions Abstract: Resource efficient design and construction, i.e. doing more with less, contributes to decreasing the negative environmental implications of resource consumption. However, the environmental effects of buildings arise from the combination of many design and management decisions, and good environmental design and construction can avoid more than just the damage that flows from resource use. It is therefore important that students of building professions learn how the many decisions they make can help create ecology sustaining buildings, and this awareness begins in the classroom. This paper proposes a model for teaching and learning environmental literacy for tertiary students of building professions. It also argues that, in comparison with a well recognized theory for language learning, some of the conditions required for learning environmental literacy may not be present in Australian tertiary institutions. This work was commissioned for the Australian Council of Building Design Professions for the Environment Design Guide and funded by EcoRecycle Victoria. Journal: Construction Management and Economics Pages: 917-925 Issue: 8 Volume: 18 Year: 2000 Keywords: Environmental Literacy Building Professionals Teaching Learning Resource Efficiency Resource Awareness Sustainability, X-DOI: 10.1080/014461900446876 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900446876 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:8:p:917-925 Template-Type: ReDIF-Article 1.0 Author-Name: Lu Aye Author-X-Name-First: Lu Author-X-Name-Last: Aye Author-Name: Nick Bamford Author-X-Name-First: Nick Author-X-Name-Last: Bamford Author-Name: Bill Charters Author-X-Name-First: Bill Author-X-Name-Last: Charters Author-Name: Jon Robinson Author-X-Name-First: Jon Author-X-Name-Last: Robinson Title: Environmentally sustainable development: a life-cycle costing approach for a commercial office building in Melbourne, Australia Abstract: A range of property and construction options is analysed using standard life-cycle costing methodology. The options are to renovate the existing building, buy an alternative building and renovate, and buy a development site and construct a new building. The do-nothing option and a hypothetical option to construct a new building on an ideal site are analysed as benchmarks. The results show that the optimum option is to buy a suitable site and construct a new building and that the least sustainable option, in the case study, is to stay in the existing property and renovate the building. Although staying in the existing building and doing nothing carries the lowest financial cost, energy consumption and greenhouse emissions are significantly worse than for the alternative options. Journal: Construction Management and Economics Pages: 927-934 Issue: 8 Volume: 18 Year: 2000 Keywords: Building Accommodation Options Energy Efficiency Greenhouse Gas Emissions Life-CYCLE Costing, X-DOI: 10.1080/014461900446885 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900446885 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:8:p:927-934 Template-Type: ReDIF-Article 1.0 Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Author-Name: Clive Briffett Author-X-Name-First: Clive Author-X-Name-Last: Briffett Author-Name: Gu Gang Author-X-Name-First: Gu Author-X-Name-Last: Gang Author-Name: Malik Ranasinghe Author-X-Name-First: Malik Author-X-Name-Last: Ranasinghe Title: Impact of ISO 14000 on construction enterprises in Singapore Abstract: As construction activity has a significant impact on the environment it is vital to consider how to improve the environmental performance of organizations in the construction industry. The ISO 14000 series of standards on environmental management provides construction enterprises with the tool to address in a structured manner the adverse impacts of their operations and to attain sustainable construction. In this study, a survey was conducted to ascertain the perceptions of construction enterprises in Singapore on the impact of the implementation of ISO 14000 on their operations. Major problems were identified, and recommendations are made for the future development of environmental management systems (EMS) in the Singapore construction industry. Journal: Construction Management and Economics Pages: 935-947 Issue: 8 Volume: 18 Year: 2000 Keywords: Construction Enterprises Environmental Impact Environmental Management Singapore Sustainable Construction, X-DOI: 10.1080/014461900446894 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900446894 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:8:p:935-947 Template-Type: ReDIF-Article 1.0 Author-Name: Raymond Cole Author-X-Name-First: Raymond Author-X-Name-Last: Cole Title: Building environmental assessment methods: assessing construction practices Abstract: This paper focuses on the environmental issues associated with the building construction process and the way in which they are currently represented in building environmental assessment methods. The primary goal is to identify the practical and methodological reasons for their scant inclusion and to offer arguments to redress this situation. Despite the difficulties of assessing management practices, their inclusion within building environmental assessment methods is critical from the standpoint of reinforcing the relationship between building design and building operation. Similar arguments relate to the importance of including construction processes. The paper argues that construction issues should be included, organized into consistent categories (e.g. resource use, ecological loadings and health issues) and clearly partitioned within the structure of assessment methods. If there are environmental benefits in engaging a broader range of players earlier in the design process, then this notion can logically be extended to include the contractor. Journal: Construction Management and Economics Pages: 949-957 Issue: 8 Volume: 18 Year: 2000 Keywords: Best-PRACTICE Construction Practices Environment Environmental Assessment Environmental Management Systems Resource Use Ecological Loadings Health, X-DOI: 10.1080/014461900446902 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900446902 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:8:p:949-957 Template-Type: ReDIF-Article 1.0 Author-Name: C. K. Chau Author-X-Name-First: C. K. Author-X-Name-Last: Chau Author-Name: W. L. Lee Author-X-Name-First: W. L. Author-X-Name-Last: Lee Author-Name: F. W. H. Yik Author-X-Name-First: F. W. H. Author-X-Name-Last: Yik Author-Name: J. Burnett Author-X-Name-First: J. Author-X-Name-Last: Burnett Title: Towards a successful voluntary building environmental assessment scheme Abstract: Voluntary building assessment schemes have emerged worldwide to help assess the environmental performance of buildings. As building environmental assessment is a rapidly evolving field, the scope and details of such assessment schemes are continuously undergoing updating and refinement. Substantial efforts have been devoted to the design and improvement of the assessment schemes to make them capable of defining an objective building profile. Although most of the existing schemes are voluntary, many fail to encourage participation of the building investors and designers. In order to widen acceptance, the design of the scheme should be oriented towards the manner in which investors make decisions. This paper provides an overview of the vital elements and changes needed, so as to make a voluntary building environmental assessment scheme more attractive and successful, and will include reforms not only in the scope and the credit weighting philosophy but also in its nature. Journal: Construction Management and Economics Pages: 959-968 Issue: 8 Volume: 18 Year: 2000 Keywords: Building Assessment Schemes Credit Weighting Scale Voluntary Schemes Sustainability, X-DOI: 10.1080/014461900446911 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461900446911 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:18:y:2000:i:8:p:959-968 Template-Type: ReDIF-Article 1.0 Author-Name: David Greenwood Author-X-Name-First: David Author-X-Name-Last: Greenwood Title: Subcontract procurement: are relationships changing? Abstract: Recent publicity shows a shift in the attitude of main contractors to subcontract procurement in the UK. However, a survey of the specialist contractors' sector shows that this impression should be approached with caution: the typical contractor - subcontractor relationship is still traditional, cost-driven, and potentially adversarial. Nevertheless, the co-existence of the two approaches is consistent with the institutional theory of organizational strategy. Journal: Construction Management and Economics Pages: 5-7 Issue: 1 Volume: 19 Year: 2001 Month: 1 X-DOI: 10.1080/01446190010003380 File-URL: http://hdl.handle.net/10.1080/01446190010003380 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:1:p:5-7 Template-Type: ReDIF-Article 1.0 Author-Name: Raymond Y.C. Tse Author-X-Name-First: Raymond Y.C. Author-X-Name-Last: Tse Author-Name: John Raftery Author-X-Name-First: John Author-X-Name-Last: Raftery Title: The effects of money supply on construction flows Abstract: It is argued that money/credit supply is neutral with respect to the real sector. Existing studies have focused on the relationship between money supply and national output. However, this paper using data from Hong Kong (first quarter 1983-second quarter 1997) examines the extent to which fluctuations in the money supply cause (or Granger-cause) fluctuations in real construction activity. Specifically, it is found that: (i) construction activity flows and construction loans are cointegrated, but their lead-lag relationship cannot be established; (ii) there is a specific and strong causal relationship between the construction activity and the broadly defined money supply M3; and (iii) positive money-supply shocks have a larger effect on construction output than negative money-supply shocks. Journal: Construction Management and Economics Pages: 9-17 Issue: 1 Volume: 19 Year: 2001 Month: 1 X-DOI: 10.1080/014461901452049 File-URL: http://hdl.handle.net/10.1080/014461901452049 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:1:p:9-17 Template-Type: ReDIF-Article 1.0 Author-Name: Linda Fan Author-X-Name-First: Linda Author-X-Name-Last: Fan Author-Name: Christabel Ho Author-X-Name-First: Christabel Author-X-Name-Last: Ho Author-Name: Vincent Ng Author-X-Name-First: Vincent Author-X-Name-Last: Ng Title: A study of quantity surveyors' ethical behaviour Abstract: Several contemporary theories of ethics are reviewed and then linked to professional ethics. A questionnaire survey was conducted to collect primary data regarding quantity surveyors' attitudes towards professional ethics. The subjects were members of the Hong Kong Institute of Surveyors (HKIS). Systematic multivariate statistical analyses, such as ANOVA, F-distribution, and test for significance, were used to draw insight from the survey results. A discrepancy in the standards of professional ethics between senior and junior surveyors was found in the survey. In addition, wide and significant variances towards ethical concepts and decisionmaking considerations were found between senior and young practitioners. The results also show that the respondents attach great importance to the interest of their employers, their clients and themselves, which is not in line with the expectations of the general public. These findings provide useful information for researchers in studying specific ethical decision-making models as well as drafting more theoretically based rules of conduct. Journal: Construction Management and Economics Pages: 19-36 Issue: 1 Volume: 19 Year: 2001 Month: 1 X-DOI: 10.1080/014461901452058 File-URL: http://hdl.handle.net/10.1080/014461901452058 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:1:p:19-36 Template-Type: ReDIF-Article 1.0 Author-Name: Davide Nicolini Author-X-Name-First: Davide Author-X-Name-Last: Nicolini Author-Name: Richard Holti Author-X-Name-First: Richard Author-X-Name-Last: Holti Author-Name: Mark Smalley Author-X-Name-First: Mark Author-X-Name-Last: Smalley Title: Integrating project activities: the theory and practice of managing the supply chain through clusters Abstract: Building on the results of two demonstration projects carried out in the UK, this paper develops the notion of 'work clusters' as an organizational approach to supply chain integration and the application of concurrent engineering principles. The organizational design principles are presented together with the process used to set up clusters at project level, and the impact of the clustering arrangement on the re-engineering of the design and construction process is discussed. It is argued that the clustering arrangement successfully supported efforts to improve value, eliminate inefficiencies, and reduce costs in the project. Evidence concerning the difficulties, barriers and costs associated with the implementation of the clustering approach is also addressed. The paper concludes with some reflections on the use of clusters and on issues for future research. Journal: Construction Management and Economics Pages: 37-47 Issue: 1 Volume: 19 Year: 2001 Month: 1 X-DOI: 10.1080/014461901452067 File-URL: http://hdl.handle.net/10.1080/014461901452067 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:1:p:37-47 Template-Type: ReDIF-Article 1.0 Author-Name: Graham J. Treloar Author-X-Name-First: Graham J. Author-X-Name-Last: Treloar Author-Name: Peter E.D. Love Author-X-Name-First: Peter E.D. Author-X-Name-Last: Love Author-Name: Gary D. Holt Author-X-Name-First: Gary D. Author-X-Name-Last: Holt Title: Using national input/output data for embodied energy analysis of individual residential buildings Abstract: Embodied energy (EE) analysis has become an important area of energy research, in attempting to trace the direct and indirect energy requirements of products and services throughout their supply chain. Typically, input-output (I-O) models have been used to calculate EE because they are considered to be comprehensive in their analysis. However, a major deficiency of using I-O models is that they have inherent errors and therefore cannot be reliably applied to individual cases. Thus, there is a need for the ability to disaggregate an I-O model into its most important 'energy paths', for the purpose of integrating case-specific data. This paper presents a new hybrid method for conducting EE analyses for individual buildings, which retains the completeness of the I-O model. This new method is demonstrated by application to an Australian residential building. Only 52% of the energy paths derived from the I-O model were substituted using case-specific data. This indicates that previous system boundaries for EE studies of individual residential buildings are less than optimal. It is envisaged that the proposed method will provide construction professionals with more accurate and reliable data for conducting life cycle energy analysis of buildings. Furthermore, by analysing the unmodified energy paths, further data collection can be prioritized effectively. Journal: Construction Management and Economics Pages: 49-61 Issue: 1 Volume: 19 Year: 2001 Month: 1 X-DOI: 10.1080/014461901452076 File-URL: http://hdl.handle.net/10.1080/014461901452076 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:1:p:49-61 Template-Type: ReDIF-Article 1.0 Author-Name: K. C. Lam Author-X-Name-First: K. C. Author-X-Name-Last: Lam Author-Name: A.T.P. So Author-X-Name-First: A.T.P. Author-X-Name-Last: So Author-Name: Tiesong Hu Author-X-Name-First: Tiesong Author-X-Name-Last: Hu Author-Name: Thomas Ng Author-X-Name-First: Thomas Author-X-Name-Last: Ng Author-Name: R. K. K. Yuen Author-X-Name-First: R. K. K. Author-X-Name-Last: Yuen Author-Name: S. M. Lo Author-X-Name-First: S. M. Author-X-Name-Last: Lo Author-Name: S. O. Cheung Author-X-Name-First: S. O. Author-X-Name-Last: Cheung Author-Name: Hongwei Yang Author-X-Name-First: Hongwei Author-X-Name-Last: Yang Title: An integration of the fuzzy reasoning technique and the fuzzy optimization method in construction project management decision-making Abstract: Most real world decision-making combines quantitative and qualitative (linguistic) variables. Conventional mathematics that combines qualitative and quantitative concepts exhibits difficulty in modelling actual problems. The research presented in this paper illustrates a mathematical approach to the solution of decision-making problems that combine qualitative and quantitative objectives. A methodical system for construction project management decision-making was developed using a combination of fuzzy multiple-objective decision-making theory and the fuzzy reasoning technique. The mathematical model can be applied to construction project management problems by suggesting an optimal path of corporate cash flow that results in the minimum use of resources. The information provided by the mathematical model allows the planner to eliminate excess use, or idleness, of resources during the construction of a project. Such information is indispensable for decision-makers in analysing the best time to invest in a new project. A case study is demonstrated to illustrate the application to a management decision problem. Journal: Construction Management and Economics Pages: 63-76 Issue: 1 Volume: 19 Year: 2001 Month: 1 X-DOI: 10.1080/014461901452085 File-URL: http://hdl.handle.net/10.1080/014461901452085 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:1:p:63-76 Template-Type: ReDIF-Article 1.0 Author-Name: TIANJI XU Author-X-Name-First: TIANJI Author-X-Name-Last: XU Author-Name: ROBERT L.K. TIONG Author-X-Name-First: ROBERT L.K. Author-X-Name-Last: TIONG Title: Risk assessment on contractors' pricing strategies Abstract: TIn a competitive tender, pricing strategies are often used by contractors to facilitate their cash flows. Usually, the decisions are based on contractors' experience, intuition, and personal bias. The existing mark-up or cash-flow forecasting models simulate the pricing strategies in a simplified manner which may depart from real situation and therefore could lead to inaccurate cash-flow forecasting. There is a lack of practical models that could quantify risks associated with pricing strategies. For construction projects, the quantity values of break-down cost items are random variables. A new approach to the risk assessment of contractors' pricing strategies is presented. By using the quantities as random variables, the approach developed in this paper enables the contractor to find the global optimal pricing through the stochastic programming model. The risks caused by contractors' pricing strategies are then assessed in a quantitative manner. A real case analysis using the approach is demonstrated. Journal: Construction Management and Economics Pages: 77-84 Issue: 1 Volume: 19 Year: 2001 Month: 1 X-DOI: 10.1080/01446190010002561 File-URL: http://hdl.handle.net/10.1080/01446190010002561 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:1:p:77-84 Template-Type: ReDIF-Article 1.0 Author-Name: Michail Kagioglou Author-X-Name-First: Michail Author-X-Name-Last: Kagioglou Author-Name: Rachel Cooper Author-X-Name-First: Rachel Author-X-Name-Last: Cooper Author-Name: Ghassan Aouad Author-X-Name-First: Ghassan Author-X-Name-Last: Aouad Title: Performance management in construction: a conceptual framework Abstract: This paper presents a review of the literature on performance management and measurement in various industries with the aim of transferring best practice into construction. A framework is presented which ensures that effective strategies are deployed to form the performance management system that construction organizations can adopt. The performance measurement process (conceptual) framework (PMPF) adopts the balanced scorecard (BSC) with the addition of a number of elements and perspectives. It rationalizes the relationships between performance measures and goals derived from strategy, so the impact of those measures on an organization's performance can be examined and analysed to indicate potential areas for improvement Journal: Construction Management and Economics Pages: 85-95 Issue: 1 Volume: 19 Year: 2001 Month: 1 X-DOI: 10.1080/01446190010003425 File-URL: http://hdl.handle.net/10.1080/01446190010003425 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:1:p:85-95 Template-Type: ReDIF-Article 1.0 Author-Name: I. M. Johnstone Author-X-Name-First: I. M. Author-X-Name-Last: Johnstone Title: Periodic refurbishment and reductions in national costs to sustain dwelling services Abstract: This paper uses a simulation model to make exploratory estimates of current and potential reductions in national costs to sustain dwelling services due to refurbishment. Data and parameters are based on a typical New Zealand dwelling of lightweight timber framed construction. Dwelling service years provided by a dwelling over one year adjusted for depreciation serve as a proxy for benefits. The costs to construct one dwelling and fractions thereof serve as a proxy for the costs of maintenance, refurbishment, replacement, and new construction. Current levels of refurbishment reduce national average costs to sustain dwelling services by a magnitude of 15%. Potential reductions in national costs are modest (5%) should the housing stock be stationary, but are negligible when the expansion rate of the housing stock is as high as 2.0% per year. A decline in the expansion rate of a housing stock has a greater impact on reducing national costs than an increase in the number of cycles of refurbishment. Journal: Construction Management and Economics Pages: 97-108 Issue: 1 Volume: 19 Year: 2001 Month: 1 X-DOI: 10.1080/01446190010003434 File-URL: http://hdl.handle.net/10.1080/01446190010003434 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:1:p:97-108 Template-Type: ReDIF-Article 1.0 Author-Name: Jun Luo Author-X-Name-First: Jun Author-X-Name-Last: Luo Title: Assessing management and performance of Sino-foreign construction joint ventures Abstract: Since the early 1990s, construction joint ventures are developing and evolving rapidly in China. However, there has been relatively little empirical research into Sino-foreign JVs in China's construction industry. This study investigates the management and operating performance of Sino-foreign construction joint ventures, and the relationships between ownership, management control and JV performance. It is found that dominant management control over JVs by Chinese partners is the major form of management. Sino-foreign construction JVs perform well. Positive and significant correlations were found to exist between three variables - ownership, management control and JV performance. A valid measure is developed in assessing JV's performance in terms of JV's social role in developing countries. The relationship between partner's participation in daily operational management of JV and the level of control over JV exercised by their parent company, and the relationship between partner's strategic objectives and the selection of JV organizational structure are also discussed. Journal: Construction Management and Economics Pages: 109-117 Issue: 1 Volume: 19 Year: 2001 Month: 1 X-DOI: 10.1080/01446190010009997 File-URL: http://hdl.handle.net/10.1080/01446190010009997 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:1:p:109-117 Template-Type: ReDIF-Article 1.0 Author-Name: Zeynep Sozen Author-X-Name-First: Zeynep Author-X-Name-Last: Sozen Author-Name: Olcay Kayahan Author-X-Name-First: Olcay Author-X-Name-Last: Kayahan Title: Correlates of the length of the relationship between main and specialist trade contractors in the construction industry Abstract: Although there is a growing literature on the factors associated with the length of interorganizational relationships, there seem to be few empirical studies related to the subject in project-based industries such as construction. In this study we looked for correlations among the length of the relationship between main and specialist trade contractors, control methods and the number of rival speciality contractors in the Turkish construction industry, drawing on the data provided by a study of 27 specialist trade contractors. Correlation analysis was used to investigate the relationship. The results demonstrate that the length of the relationship between main and speciality contractors is inversely related to the number of rival specialist trade contractors, but directly related to the flexibility of control exercised by the main contractor. Journal: Construction Management and Economics Pages: 131-133 Issue: 2 Volume: 19 Year: 2001 Keywords: Interorganizational Relationships Main-SPECIALITY Contractor Relationship Strategic Alliances, X-DOI: 10.1080/01446190010000185 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010000185 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:2:p:131-133 Template-Type: ReDIF-Article 1.0 Author-Name: Ozlem Oz Author-X-Name-First: Ozlem Author-X-Name-Last: Oz Title: Sources of competitive advantage of Turkish construction companies in international markets Abstract: Michael Porter's diamond framework, a relatively recent attempt to improve our existing knowledge on the sources of competitive advantage, is applied to the Turkish construction industry. The results of this undertaking challenge a common approach that attributes Turkish contractors' success in international markets to labour cost advantages and geographic and cultural proximity to several promising markets. In the light of the diamond framework, Turkish contractors' advantages are found not to be limited to these 'factor conditions' and 'chance' events. There are other important advantages behind their success, such as the existence of a dynamic home market, favourable entrepreneurial variables, and pressures to upgrade stemming from intense domestic rivalry. The analysis also points to the areas in which they face troubles, including problems induced by the government, financing difficulties and the weak international position of the Turkish design engineering and consultancy services industry. Journal: Construction Management and Economics Pages: 135-144 Issue: 2 Volume: 19 Year: 2001 Keywords: Turkish Construction Industry Competitive Advantage International Competitiveness Diamond Framework, X-DOI: 10.1080/01446190010009988 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010009988 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:2:p:135-144 Template-Type: ReDIF-Article 1.0 Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Author-Name: Chan Swee Lean Author-X-Name-First: Chan Swee Author-X-Name-Last: Lean Title: Factors influencing development of construction enterprises in Singapore Abstract: The literature stresses the importance of improvements in the effectiveness and efficiency of contractors if the construction industry is to fulfil its tasks in a cost-effective, timely and safe manner. Various factors are considered to be instrumental in the development of contractors. If the most important influencing factors in any country can be identified, measures can be taken to apply them in order to upgrade the contractors. The results of a study on the factors which have been important in the development of construction enterprises in Singapore are presented. A mailed questionnaire survey provided the basis for the study. The targeted respondents were local contractors, foreign contractors, and clients and consultants. It was found that the key factors could be grouped into four main categories: contractors' role; government's and institutions' help; practitioners' help and financial support; and clients' help. Recommendations are offered on measures which can improve the performance of contractors. Journal: Construction Management and Economics Pages: 145-154 Issue: 2 Volume: 19 Year: 2001 Keywords: Construction Firms Singapore Development Factors Foreign Contractors Government, X-DOI: 10.1080/01446190150505072 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190150505072 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:2:p:145-154 Template-Type: ReDIF-Article 1.0 Author-Name: John Raftery Author-X-Name-First: John Author-X-Name-Last: Raftery Author-Name: Josephine Csete Author-X-Name-First: Josephine Author-X-Name-Last: Csete Author-Name: Sammy Hui Author-X-Name-First: Sammy Author-X-Name-Last: Hui Title: Are risk attitudes robust? Qualitative evidence before and after a business cycle inflection Abstract: Attitudes to the monetary risks associated with business decisions are thought to vary in response to at least three identifiable stimuli: the amount of money involved, background economic conditions and the framing of the decision. This paper reports a study of peoples' attitude to risk before and after a real turning point in the real business cycle. This work sheds light on the extent to which (i) risk attitudes remain robust when economic conditions change, (ii) risk attitude is influenced by whether the choice problem is concerned with losses or with gains, and (iii) risk attitude may be subordinated to some other dominating objective. Journal: Construction Management and Economics Pages: 155-164 Issue: 2 Volume: 19 Year: 2001 Keywords: Risk Attitude Business Cycles, X-DOI: 10.1080/01446190150505081 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190150505081 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:2:p:155-164 Template-Type: ReDIF-Article 1.0 Author-Name: S. Thomas Ng Author-X-Name-First: S. Thomas Author-X-Name-Last: Ng Author-Name: Michael Mak Author-X-Name-First: Michael Author-X-Name-Last: Mak Author-Name: R. Martin Skitmore Author-X-Name-First: R. Martin Author-X-Name-Last: Skitmore Author-Name: Ka Chi Lam Author-X-Name-First: Ka Chi Author-X-Name-Last: Lam Author-Name: Mark Varnam Author-X-Name-First: Mark Author-X-Name-Last: Varnam Title: The predictive ability of Bromilow's time-cost model Abstract: Bromilow's log-log time-cost (BTC) model is tested and refitted with a new set of data for Australian construction projects completed between 1991 and 1998. It is shown that, as anticipated by earlier research, different parameter estimates are needed for different project types, with smaller industrial projects taking less time to complete than the smaller educational and residential projects. This results in the development of two separate models, one for industrial projects and one for non-industrial projects. No changes in parameter estimates are needed for projects with different client sectors, contractor selection methods and contractual arrangements. Alternatives to the log-log model failed to produce any improved fit. Finally, the results are compared with previous work to indicate the extent of changes in time-cost relationships in Australian construction projects over the last 40 years. This indicates a clear improvement in construction speed over the period. Furthermore, the 'public' sector group in particular has exhibited a greater variation (up to 132%) over the years. Journal: Construction Management and Economics Pages: 165-173 Issue: 2 Volume: 19 Year: 2001 Keywords: Cost Time Duration Time-COST Bromilow Model Linear Regression Speed Productivity, X-DOI: 10.1080/01446190150505090 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190150505090 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:2:p:165-173 Template-Type: ReDIF-Article 1.0 Author-Name: K. C. Lam Author-X-Name-First: K. C. Author-X-Name-Last: Lam Author-Name: Tiesong Hu Author-X-Name-First: Tiesong Author-X-Name-Last: Hu Author-Name: S. Thomas Ng Author-X-Name-First: S. Thomas Author-X-Name-Last: Ng Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: S. O. Cheung Author-X-Name-First: S. O. Author-X-Name-Last: Cheung Title: A fuzzy neural network approach for contractor prequalification Abstract: Non-linearity, uncertainty and subjectivity are the three predominant characteristics of contractors prequalification which lead to the process being more of an art than a scientific evaluation. A fuzzy neural network (FNN) model, amalgamating both the fuzzy set and neural network theories, has been developed aiming to improve the objectiveness of contractor prequalification. Through FNN theory, the fuzzy rules as used by the prequalifiers can be identified and the corresponding membership functions can be transformed. Eightyfive cases with detailed decision criteria and rules for prequalifying Hong Kong civil engineering contractors were collected. These cases were used for training (calibrating) and testing the FNN model. The performance of the FNN model was compared with the original results produced by the prequalifiers and those generated by the general feedforward neural network (GFNN, i.e. a crisp neural network) approach. Contractors' ranking orders, the model efficiency (R2) and the mean absolute percentage error (MAPE) were examined during the testing phase. These results indicate the applicability of the neural network approach for contractor prequalification and the benefits of the FNN model over the GFNN model. The fuzzy neural network is a practical approach for modelling contractor prequalification. Journal: Construction Management and Economics Pages: 175-188 Issue: 2 Volume: 19 Year: 2001 Keywords: Fuzzy Reasoning Neural Network Contractor Prequalification, X-DOI: 10.1080/01446190150505108 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190150505108 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:2:p:175-188 Template-Type: ReDIF-Article 1.0 Author-Name: Sun Sheng Han Author-X-Name-First: Sun Sheng Author-X-Name-Last: Han Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Title: Construction industry in China's regional economy, 1990-1998 Abstract: Construction has been perceived as a pillar industry in China's economic revitalization. Policies and programmes have been implemented by the central and local governments to promote the development of the national and local construction industries, in the hope of driving the growth of the economy. Developments in China's economy and in particular, in different regions, can be used to test the hypotheses on the relationship between construction and economic development. This paper examines the geographical distribution of construction in the provinces of China, and the relationship between construction and regional economic growth. It also studies different types of projects, ownership patterns, and levels of technology applied. The study provides useful insights into the relationships between the construction industry, and the economy and development especially at the regional level. Journal: Construction Management and Economics Pages: 189-205 Issue: 2 Volume: 19 Year: 2001 Keywords: Construction Industry Economic Development Turin Model China Regional Distribution, X-DOI: 10.1080/01446190010010003 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010010003 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:2:p:189-205 Template-Type: ReDIF-Article 1.0 Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Author-Name: Thomas Tong Author-X-Name-First: Thomas Author-X-Name-Last: Tong Author-Name: S. O. Cheung Author-X-Name-First: S. O. Author-X-Name-Last: Cheung Author-Name: Albert Chan Author-X-Name-First: Albert Author-X-Name-Last: Chan Title: Genetic algorithm model in optimizing the use of labour Abstract: The construction industry is characterized by the existence of multiple trades and crafts. With the existence of multiple-tiers of labour-only-subcontracting in Hong Kong, tradesmen are normally assigned to tasks of a narrowly defined skill. Lately, there has been a call for the adoption of a directly employed labour scheme by the Hong Kong Housing Authority and the public works departments in Hong Kong in order to improve both safety and quality. However, current industry practice has hindered the adoption of directly employed labour, which requires assigning tradesmen to broadly defined task groupings. In implementing the scheme, the first thing to be resolved is how to maximize the levels of use of workers, because that is the major financial incentive to encourage contractors to adopt the directly employed labour policy. This coupled with the shortage of some skilled craft workers call into question the traditionally accepted 'single-skilled' or 'single-task' approach in labour deployment. A genetic algorithm model is developed to optimize the labour deployment and practical examples are presented. The optimization results are very promising, confirming the practical application value of the model. Journal: Construction Management and Economics Pages: 207-215 Issue: 2 Volume: 19 Year: 2001 Keywords: Multi-SKILL Genetic Algorithms Subcontracting Labour Deployment, X-DOI: 10.1080/01446190150505126 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190150505126 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:2:p:207-215 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Noni Holmes Author-X-Name-First: Noni Author-X-Name-Last: Holmes Title: Understandings of occupational health and safety risk control in small business construction firms: barriers to implementing technological controls Abstract: The construction industry poses a particular challenge for the making of occupational health and safety (OHS) risk control decisions which are equitable to all parties involved in the construction process. Typically, small business construction firms are engaged as subcontractors in the construction industry and are located at the lower end of the inter-organizational hierarchy in a construction project. As such, their ability to exert an influence on decision-making in the construction process is limited, despite their employees' day to day exposure to OHS risks. A qualitative study of understandings of OHS risk control was conducted among a sample of small businesses engaged in the Australian construction industry. Two OHS risks relevant to the construction industry were selected for study. One risk (falls from height) represented an immediate consequence while the other (occupational skin disease) represented a long-term health effect. Understandings of control for these OHS risks were explored during in-depth interviews. The results suggest that, at the small business end of the industry, there is a fatalistic resignation to OHS risks being an unavoidable part of the job. This leads to an emphasis on individual rather than technological controls for OHS risk. The implication of these findings for the effective management of OHS risk is discussed. Journal: Construction Management and Economics Pages: 217-226 Issue: 2 Volume: 19 Year: 2001 Keywords: Occupational Health And Safety Risk Control Small Business, X-DOI: 10.1080/01446190010002570 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010002570 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:2:p:217-226 Template-Type: ReDIF-Article 1.0 Author-Name: Anil Sawhney Author-X-Name-First: Anil Author-X-Name-Last: Sawhney Author-Name: Andre Mund Author-X-Name-First: Andre Author-X-Name-Last: Mund Title: IntelliCranes: an integrated crane type and model selection system Abstract: The importance of the utilization of cranes in construction operations has resulted in the development of structured methods for crane selection. Most of these methods are for crane model selection and require the user to stipulate the type of crane to be used for the construction operation under consideration. Availability of a structured method for crane type selection will greatly benefit the overall crane selection process. This paper describes a prototype integrated crane selection tool, called IntelliCranes, designed to assist in both crane type and crane model selection. The key feature of IntelliCranes is the systematic incorporation of subjective and qualitative criteria in crane type and model selection. Journal: Construction Management and Economics Pages: 227-237 Issue: 2 Volume: 19 Year: 2001 Keywords: Crane Selection Neural Networks Adaptive Probabilistic Neural Networks Expert Systems Lifting Hoisting, X-DOI: 10.1080/01446190010008079 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010008079 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:2:p:227-237 Template-Type: ReDIF-Article 1.0 Author-Name: Steven Groak Author-X-Name-First: Steven Author-X-Name-Last: Groak Title: Representation in building Abstract: Journal: Construction Management and Economics Pages: 249-253 Issue: 3 Volume: 19 Year: 2001 X-DOI: 10.1080/01446190010020345 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010020345 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:3:p:249-253 Template-Type: ReDIF-Article 1.0 Author-Name: Ranko Bon Author-X-Name-First: Ranko Author-X-Name-Last: Bon Title: The future of building economics: a note Abstract: Building economics has been long in emerging because it still lacks solid theoretical foundations. The notion of 'building process' should play a central role in this regard, as it points at the fundamental indeterminacy underlying building activity from conception to demolition. This indeterminacy stems from the length of time that usually separates these two events. Building economics needs to shift its focus from investment decisions to problems of managing building portfolios in their entirety. The professional basis for this development is in corporate real estate and facilities management. Journal: Construction Management and Economics Pages: 255-258 Issue: 3 Volume: 19 Year: 2001 Keywords: Building Process Real Estate Portfolio Corporate Real Estate Facilities Management Chief Real Estate Officer, X-DOI: 10.1080/01446190010020354 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010020354 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:3:p:255-258 Template-Type: ReDIF-Article 1.0 Author-Name: James Meikle Author-X-Name-First: James Author-X-Name-Last: Meikle Title: A review of recent trends in house construction and land prices in Great Britain Abstract: Over the last few decades, house prices in the UK have risen at a higher rate than general prices, as measured by, for example, the retail price index. Construction prices, on the other hand, tend to have risen broadly in line with general prices. Assuming the same things are being measured in each case, this implies that, over the period, the price of land, the most significant non-construction element of house prices, has risen at a faster rate than house prices and a much higher rate than construction prices. This paper reviews past price trends and concludes that not only have house prices risen faster than construction prices but also that, as a result, construction prices represent a smaller proportion of house prices. The paper also considers briefly what might be the implications if that trend continued- or if it did not. Journal: Construction Management and Economics Pages: 259-265 Issue: 3 Volume: 19 Year: 2001 Keywords: Construction Prices Land Prices House Prices Trends Allow Approx Picas, X-DOI: 10.1080/01446190010020499 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010020499 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:3:p:259-265 Template-Type: ReDIF-Article 1.0 Author-Name: Jill Wells Author-X-Name-First: Jill Author-X-Name-Last: Wells Title: Construction and capital formation in less developed economies: unravelling the informal sector in an African city Abstract: Sub-Saharan Africa is the poorest and least developed region in the world today. It is also the most rapidly urbanizing, with the greatest need for investment in new infrastructure and buildings. In Kenya, as well as in a number of other countries, the adoption of economic adjustment programmes has led to a sharp decline in publicly funded construction projects. What activity there is takes place in the private sector. The shift from public to private investment has been accompanied by a noticeable fall in the volume of work passing through the more formally organized construction system and an increase in activity in the 'informal' system. The informal construction system is characterized by a much closer relationship between building owners and building labour, with owners purchasing materials as and when they have the funds and engaging directly the services of small enterprises and self-employed workers. In Nairobi (Kenya) substantial multi-storey projects are now being implemented in this way by a myriad of small firms. This paper examines these devel8 opments and assesses their implications for our understanding of 'the construction industry' and the process of capital formation. Journal: Construction Management and Economics Pages: 267-274 Issue: 3 Volume: 19 Year: 2001 Keywords: Africa Building Construction Informal Sector Nairobi, X-DOI: 10.1080/01446190010020363 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010020363 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:3:p:267-274 Template-Type: ReDIF-Article 1.0 Author-Name: R. T. McCutcheon Author-X-Name-First: R. T. Author-X-Name-Last: McCutcheon Title: Employment generation in public works: recent South African experience Abstract: Unemployment remains one of South Africa's most pressing problems while at the same time there is a great need for physical infrastructure in both urban and rural areas. Concurrently there is also a lack of individual skills and institutional capacity. From a theoretical perspective, substantiated by large scale experience elsewhere in Africa (and research and development in South Africa) there are reasons for advocating the establishment of carefully formulated, long term programmes using employment-intensive methods for the construction and maintenance of the required infrastructure. These programmes have also improved institutional capacities and developed individual skills. Proper employment-intensive construction results in a significant increase in employment generated per unit of expenditure. It can be financially competitive with conventional (equipment-based) construction and can produce the same quality of product within the same time. From a development perspective there are additional socio-economic benefits to be gained such as the development of individual skills and institutional capacities and a contribution to the alleviation of poverty. The concepts and principles, taken together with the processes and results of successful long term, large scale programmes provide criteria by which to evaluate other projects and programmes. In 1994 the South African National Public Works Programme (NPWP) was launched based on the principles outlined above. This paper briefly describes the NPWP and evaluates progress in satisfying its objectives. Journal: Construction Management and Economics Pages: 275-284 Issue: 3 Volume: 19 Year: 2001 Keywords: Development Employment Labour Skills South Africa Allow Approx Picas, X-DOI: 10.1080/01446190010020381 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010020381 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:3:p:275-284 Template-Type: ReDIF-Article 1.0 Author-Name: Denis Towill Author-X-Name-First: Denis Author-X-Name-Last: Towill Title: The idea of building business processes: the responsive housebuilder Abstract: In many market sectors there has recently been an apparent step change for the better in how companies perform their core business. The result has been increased competitive advantage for companies in the electronic products, automotive, insurance, banking and mechanical sectors. Careful research has shown that the way forward for the construction sector to similarly benefit from the new methodology is to apply well established 'business systems engineering7rsquo; (BSE) principles. But business systems engineering is concerned with both engineering and integrating the technological, financial, organizational and cultural aspects of business processes. The responsive housebuilder is the particular example selected herein to demonstrate the power of the approach. By re-engineering the design, financing, and production processes, the housebuilder first learns to survive economic turbulence. However, second it grows by increasing market share via the exploitation of new opportunities enabled by much reduced delivery times. The outcome is therefore a welcome addition to the construction sector survivability categories originally listed by Steven Groak in The Idea of Building. Journal: Construction Management and Economics Pages: 285-293 Issue: 3 Volume: 19 Year: 2001 Keywords: Benchmarking Business Systems Engineering Process Change Models Lean Construction, X-DOI: 10.1080/01446190010020408 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010020408 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:3:p:285-293 Template-Type: ReDIF-Article 1.0 Author-Name: Shigeaki Iwashita Author-X-Name-First: Shigeaki Author-X-Name-Last: Iwashita Title: Custom made housing in Japan and the growth of the super subcontractor Abstract: This paper considers the relationship between the major Japanese industrialized housing suppliers and their subcontractors. It describes the different types of contractor and subcontractor, indicating their role in customer liaison, design and delivery on site. It explains the different supply networks for materials supply, and it concludes with a description of the emergent role of what have been called 'super subcontractors'. These super subcontractors are offering a more efficient route to the delivery of works on site for both industrialized and traditional housing producers. Their role appears to be transforming the organization and costs of delivery. Journal: Construction Management and Economics Pages: 295-300 Issue: 3 Volume: 19 Year: 2001 Keywords: Subcontractors Made-TO-ORDER Housing Japanese Housing Housing Innovation Supply Chains Customization, X-DOI: 10.1080/01446190010020417 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010020417 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:3:p:295-300 Template-Type: ReDIF-Article 1.0 Author-Name: Tomonari Yashiro Author-X-Name-First: Tomonari Author-X-Name-Last: Yashiro Title: A Japanese perspective on the decline of robust technologies and changing technological paradigms in housing construction: issues for construction management research Abstract: Based on the concept of construction as a project-based economic activity, Steven Groak offered the idea of a technological paradigm to represent project-based technology fusion that is adaptive to the uncertainties embodied within construction projects. This paper discusses further research topics raised by the idea of the technological paradigm from a Japanese perspective. It verifies the effectiveness of Groak's notion by exemplifying phenomena identified in Japanese construction practices. First, the paper confirms how declining robust technologies are generating innovative activities in construction projects. Second, a 'horizontal evolution' case study is presented as evidence that the strategies engendered by the technological paradigm outperform those from the industrial paradigm. Then the paper identifies and focuses on the informality of project-based technology fusion. Relevant research topics are discussed, such as the unpredictability of system configuration, the integration of knowledge and know-how, and the regulatory framework for extending positive informality. It is concluded that the following topics have considerable significance for construction management research: (a) methodology to evaluate 'robust limits'; (b) the process of project-to-project technology transfer and evolution; (c) organization formation of project-based technology fusion; and (d) regulatory framework that embodies informality to activate project-based technology fusion. Journal: Construction Management and Economics Pages: 301-306 Issue: 3 Volume: 19 Year: 2001 Keywords: Technological Paradigm Project-BASED Technology Fusion Robust Technology Organizational Learning, X-DOI: 10.1080/01446190010020426 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010020426 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:3:p:301-306 Template-Type: ReDIF-Article 1.0 Author-Name: Alistair Gibb Author-X-Name-First: Alistair Author-X-Name-Last: Gibb Title: Standardization and pre-assembly- distinguishing myth from reality using case study research Abstract: Standardization and pre-assembly (S&P) are not new, but their application and their drivers, pragmatism and perception, need to be considered in the light of current technology and management practice. There are lessons to be learned from a historical review, but there are also numerous myths that must be dispelled: houses are not cars; maximum standardization is not always the answer; and, S&P do not have to cost more. Steven Groak worked with the author on the research project 'Adding value to construction projects through standardisation and pre-assembly' funded by CIRIA (Construction Industry Research and Information Association). The CIRIA project, which forms the basis of this paper, aimed to produce a review of the subject and guidance for clients and project teams through a comprehensive literature review, expert work5 shops and case study research. The paper defines S&P, discusses past, present and future applications (providing case study evidence) and presents the key benefits and implications of the optimized use of standardization and pre-assembly. Journal: Construction Management and Economics Pages: 307-315 Issue: 3 Volume: 19 Year: 2001 Keywords: Standardization Pre-ASSEMBLY Drivers Benefits Implications, X-DOI: 10.1080/01446190010020435 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010020435 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:3:p:307-315 Template-Type: ReDIF-Article 1.0 Author-Name: Shuichi Matsumura Author-X-Name-First: Shuichi Author-X-Name-Last: Matsumura Title: Perspectives on component-based design in Japanese construction Abstract: The industrialization of building production was the subject of heated debate in Japan during the 1960s and into the 1970s. Various concepts of 'component-based design' were introduced with the purpose of stimulating innovation and creating a more efficient building process. In this paper these concepts are reviewed from today's perspectives, and the necessary revisions are examined that might make them more useful in contributing to the future development of the Japanese construction industry. Journal: Construction Management and Economics Pages: 317-319 Issue: 3 Volume: 19 Year: 2001 Keywords: Component-BASED Design Flexible Manufacturing System Information Technology Decision-MAKING, X-DOI: 10.1080/01446190010020471 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010020471 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:3:p:317-319 Template-Type: ReDIF-Article 1.0 Author-Name: David Gann Author-X-Name-First: David Author-X-Name-Last: Gann Title: Putting academic ideas into practice: technological progress and the absorptive capacity of construction organizations Abstract: This paper focuses on how knowledge is produced by academics and on mechanisms for and constraints upon absorbing new ideas within the construction sector. It draws upon two bodies of work: Cohen and Levinthal's concept of 'absorptive capacity' and Gibbons and coworkers' 'new production of knowledge'. Much of Steven Groak's work was concerned with technology transfer and how ideas generated during research could be put into practice. He developed the concept of 'practitioner-researcher' to illustrate the ways in which many built environment professionals approach their work. The paper suggests that a few construction firms have the capabilities to absorb and act directly upon the results of academic research in the UK. These firms are likely to employ a critical mass of professionally qualified practitioners and they usually compete for work in technically demanding and often specialist areas. They probably have a track record of collaboration with university researchers, and are likely to have their own internal technical support infrastructure which assists in learning between projects. However, the majority of construction organizations learn of new ideas through a range of different published media and by participating in complex sets of interactions in a wide range of networks. The role of professional institutions is important, acting as repositories of knowledge. But these institutions may also constrain development when they adhere to outmoded notions of narrowly defined discipline-based activities. Governments can play a part in putting ideas into practice as catalysts in bringing academic research and industrial practitioner communities together through sponsorship of collaborative research projects. The paper concludes that construction organizations could improve their absorptive capacity by developing better feedback and life-long learning mechanisms, education and training. Journal: Construction Management and Economics Pages: 321-330 Issue: 3 Volume: 19 Year: 2001 Keywords: Knowledge Production Absorption Capacity Innovation Construction Research Academic Research Technology Transfer Professionalization Construction Organizations, X-DOI: 10.1080/01446190010020480 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010020480 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:3:p:321-330 Template-Type: ReDIF-Article 1.0 Author-Name: Timothy Fisher Author-X-Name-First: Timothy Author-X-Name-Last: Fisher Author-Name: Malik Ranasinghe Author-X-Name-First: Malik Author-X-Name-Last: Ranasinghe Title: Culture and foreign companies' choice of entry mode: the case of the Singapore building and construction industry Abstract: Recent studies have shown that culture has an effect on the choice of foreign investment venture structure. Cultural distance has been identified as a primary determinant in the selection of shared control over wholly foreign owned investment. The data from these studies indicate, however, that individual cultural characteristics of investor countries may be more important than the difference in culture. In this study, a sample of Singaporean building and construction firms is utilized to explore whether joint venture (JV) formations correspond more to the uncertainty avoidance dimension of the investor's culture than to cultural distance. The results show that an investor's cultural aversion to risk may be more influential in explaining the propensity for firms from certain countries to engage in JVs, rather than other cultural factors. Journal: Construction Management and Economics Pages: 343-353 Issue: 4 Volume: 19 Year: 2001 Keywords: Culture Joint Ventures Partner Selection Foreign Investment Entry Mode Technology Transfer Regionalization, X-DOI: 10.1080/01446190010001193a File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010001193a File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:4:p:343-353 Template-Type: ReDIF-Article 1.0 Author-Name: Chan Swee Lean Author-X-Name-First: Chan Swee Author-X-Name-Last: Lean Title: Empirical tests to discern linkages between construction and other economic sectors in Singapore Abstract: The construction industry makes significant contributions to the socio-economic development process in most countries. Its importance in the economy is due largely to the direct and indirect impact it has on the national economy. It stimulates the growth of other sectors through a complex system of linkages. Interest in multi-sectoral linkages was generated following Hirschman's work that investigated the relationship between unbalanced sectoral growth and economic development. Most of the past research work had used Leontief's input-output analysis to gauge the backward and forward linkages between industries. This paper proposes an econometric procedure that can be used for determining the construction output linkages. This involves unit-root testing and Granger causality testing. The main purpose is to determine the impact of a fluctuation in construction output on the sectoral production and the economy of Singapore. This helps to assess the role of the construction industry and how it is affected by the changes in the other economic sectors. Journal: Construction Management and Economics Pages: 355-363 Issue: 4 Volume: 19 Year: 2001 Keywords: Construction Linkages Economic Sectors Granger Causality, X-DOI: 10.1080/01446190010022686 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010022686 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:4:p:355-363 Template-Type: ReDIF-Article 1.0 Author-Name: Ramesh Marasini Author-X-Name-First: Ramesh Author-X-Name-Last: Marasini Author-Name: Nashwan Dawood Author-X-Name-First: Nashwan Author-X-Name-Last: Dawood Author-Name: Brian Hobbs Author-X-Name-First: Brian Author-X-Name-Last: Hobbs Title: Stockyard layout planning in precast concrete products industry: a case study and proposed framework Abstract: Management of the stockyard layout in the precast concrete products industry is very important for efficient storage and dispatch of the concrete products. The industry uses the make-to-stock principle in production to meet the seasonal demand (high in summer and low in winter) from the construction industry. In order to stabilize production output and cater for the huge demand in summer, stock is built up during the winter and spring period. The concrete products are kept in stock for 4-5 months. As 2000≈3000 different precast concrete products are produced, and the products have different size, weight and handling requirements, determination of appropriate stockyard location for the products constitutes a complex process. This paper describes some ongoing research that is focused on identifying the appropriate methodology for designing and managing the stockyard layout that ensures efficient storage and dispatch of products, and provides ease of rotation of products within the yard. An integrated simulation model employing artificial intelligence methods has been proposed to evaluate 'what-if' scenarios and recommend a suitable methodology for the management of stockyard space for precast concrete products. This paper presents the findings from a case study, which includes work-study, frequency analysis of historical order data. The paper also introduces the specifications, processes and outline prototype of the proposed model. A general purpose simulation language (SIMAN) based software, 'Arena 4.0' (Systems Modelling Corporation), has been selected to develop the prototype simulation model and ILOG views and rules have been considered to generate a knowledge-based stockyard layout. Journal: Construction Management and Economics Pages: 365-377 Issue: 4 Volume: 19 Year: 2001 Keywords: Stockyard Layout Precast Concrete Products Simulation, X-DOI: 10.1080/01446190110035636 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110035636 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:4:p:365-377 Template-Type: ReDIF-Article 1.0 Author-Name: Mohan Raj Manavazhi Author-X-Name-First: Mohan Raj Author-X-Name-Last: Manavazhi Author-Name: Zhang Xunzhi Author-X-Name-First: Zhang Author-X-Name-Last: Xunzhi Title: Productivity oriented analysis of design revisions Abstract: This paper presents a structured, two-pronged approach to the development of a framework for assessing the severity of occurrence of design revisions and determining the causes of these revisions. The development of the framework involves the identification of a causal taxonomy consisting of categories of the causes of design revisions and the formalization of a set of indices for measuring and comparing the magnitudes of designer-times expended on design revisions. The framework could be used both as a diagnostic instrument to determine the health of the design phase and also as a forecasting tool for the estimation of designer resources required for a construction project. The framework was tested using data obtained from twelve building projects in China. The category that caused the maximum expenditure of designer time on design revisions in the building projects surveyed was found to be owner-initiated changes. Journal: Construction Management and Economics Pages: 379-391 Issue: 4 Volume: 19 Year: 2001 Keywords: Design Revisions Design Process Design Productivity, X-DOI: 10.1080/01446190010017141 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010017141 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:4:p:379-391 Template-Type: ReDIF-Article 1.0 Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Author-Name: Ivan Fung Author-X-Name-First: Ivan Author-X-Name-Last: Fung Author-Name: Albert Chan Author-X-Name-First: Albert Author-X-Name-Last: Chan Title: Study of attitude changes in people after the implementation of a new safety management system: the supervision plan Abstract: The construction industry of Hong Kong has a very poor site safety record. The overall accident rate has gone down a little during the last few years, but the number of fatalities has risen dramatically. In the past, the Hong Kong Government adopted a laissez-faire approach in managing construction safety, hoping that market forces would regulate the safety performance. However, the approach has proved to be ineffective. Since 1986, the Government has taken a proactive approach in combating construction site safety, and has introduced a series of safety programmes, which consist of encouraged and mandatory schemes aiming at nourishing a proper safety culture in the construction industry. Recently, the Government decided to criminalize site accident cases by introducing a so-called 'Supervision Plan', aiming at changing the safety attitude and culture of construction practitioners. This paper applies an attitude-changing model, 'reinforcement theory', to predict the changing attitude of people in the construction industry. The results show that the attitude of construction practitioners in Hong Kong will change to be more positive when they receive more messages to confirm that people really are put into jail for negligence under the Supervision Plan. Journal: Construction Management and Economics Pages: 393-403 Issue: 4 Volume: 19 Year: 2001 Keywords: Site Safety Supervision Plan Attitudinal Change Reinforcement Theory, X-DOI: 10.1080/01446190010027591 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010027591 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:4:p:393-403 Template-Type: ReDIF-Article 1.0 Author-Name: Krishna Mochtar Author-X-Name-First: Krishna Author-X-Name-Last: Mochtar Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Title: Pricing strategy in the US construction industry Abstract: This paper presents several issues related to pricing in construction. First, problems with current pricing strategy in construction are explored. Second, pricing strategies based on a market-based approach are proposed. Third, survey findings of the top 400 US contractors are presented regarding their current pricing practices and the applicability of the proposed pricing strategies. In conclusion, the belief that current pricing strategy in construction is predominantly cost-based is confirmed by the survey findings; indeed, in setting the markup, most contractors rely on their intuition after subjectively assessing the competition. The three internal pricing variables that have the largest statistically significant contingency coefficients with pricing strategy are 'marketing intelligence capabilities', 'annual contract value', and 'the type of client in most projects'. 'Owner's characteristics', 'competitors'characteristics', and 'market demand' are statistically significant external variables in making pricing strategy decisions. A change of bidding procedure is proposed so that all parties in construction can maximize the benefits of market-based pricing strategies. Journal: Construction Management and Economics Pages: 405-415 Issue: 4 Volume: 19 Year: 2001 Keywords: Cost-BASED Pricing Market-BASED Pricing Pricing Variables Bidding Procedure, X-DOI: 10.1080/01446190010020372 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010020372 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:4:p:405-415 Template-Type: ReDIF-Article 1.0 Author-Name: roy J. Le Isidore Author-X-Name-First: roy J. Le Author-X-Name-Last: Isidore Author-Name: W. Edward Back Author-X-Name-First: W. Edward Author-X-Name-Last: Back Author-Name: Gary Fry Author-X-Name-First: Gary Author-X-Name-Last: Fry Title: Integrated probabilistic schedules and estimates from project simulated data Abstract: Risk management, as it relates to construction, is vital to the successful undertaking and completion of any construction project. One way to manage project risk effectively is to develop more reliable means of accounting for the time and cost variability existing in construction operations. Recent attempts to more reliably quantify the risk inherent in construction projects has focused on range estimating and stochastic scheduling (also referred to as probabilistic estimating and probabilistic scheduling). It is common knowledge in the construction industry that the cost associated with a project is affected greatly by the schedule selected to complete that project. Additionally, the percentile level associated with both of these tools is of significance when they are considered stochastically. This paper looks at the integration of range estimating and probabilistic scheduling, using a new procedure called the empirical cumulative density function technique (ECDF) as a means of further controlling the risk associated with the undertaking of construction projects. In addition to providing a reliable means of relating the results of range estimating and probabilistic scheduling, this technique is graphically based, and has the advantage of not requiring any assumptions regarding the underlying data distributions. Journal: Construction Management and Economics Pages: 417-426 Issue: 4 Volume: 19 Year: 2001 Keywords: Integrated Cost And Schedule Monte Carlo Simulation Range Estimating Probabilistic Estimating Probabilistic Scheduling, X-DOI: 10.1080/01446190010022677 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010022677 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:4:p:417-426 Template-Type: ReDIF-Article 1.0 Author-Name: Sai-On Cheung Author-X-Name-First: Sai-On Author-X-Name-Last: Cheung Author-Name: Tsun-Ip Lam Author-X-Name-First: Tsun-Ip Author-X-Name-Last: Lam Author-Name: Mei-Yung Leung Author-X-Name-First: Mei-Yung Author-X-Name-Last: Leung Author-Name: Yue-Wang Wan Author-X-Name-First: Yue-Wang Author-X-Name-Last: Wan Title: An analytical hierarchy process based procurement selection method Abstract: Procurement selection continues to be topical, and several advanced studies have been reported. One of the key concerns of procurement selection is how to enhance objectivity. A selection method developed using multi-attribute utility technology (MAUT) and the analytical hierarchy process (AHP) is proposed. With the input of industrial experts, critical procurement selection criteria and procurement strategies commonly used in Hong Kong were identified. Against these criteria, utility factors corresponding to various procurement strategies were then assigned by the experts to create a utility factor table. To cater for individual project characteristics, the relative importance weightings of the selection criteria were assessed using the analytical hierarchy process. Final selection was then based on the highest utility value derived from the procurement strategies, taking into account the relative importance of the selection criteria. The use of the model is illustrated with actual data. Journal: Construction Management and Economics Pages: 427-437 Issue: 4 Volume: 19 Year: 2001 Keywords: Multi-ATTRIBUTE Utility Technology Analytical Hierarchy Process Procurement Selection, X-DOI: 10.1080/014461901300132401 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461901300132401 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:4:p:427-437 Template-Type: ReDIF-Article 1.0 Author-Name: Nicola Costantino Author-X-Name-First: Nicola Author-X-Name-Last: Costantino Author-Name: Roberto Pietroforte Author-X-Name-First: Roberto Author-X-Name-Last: Pietroforte Author-Name: Peter Hamill Author-X-Name-First: Peter Author-X-Name-Last: Hamill Title: Subcontracting in commercial and residential construction: an empirical investigation Abstract: Some twenty years ago Robert Eccles argued for the theoretical existence of the quasifirm, a semi-integrated form of production in the construction industry, following a field study of home building firms in the USA. The study was aimed at substantiating some aspects of Williamson's transaction cost theory. The present work has similar intents, and illustrates the results of two recent field studies of homebuilders and commercial contractors, and the specific features of their subcontracting practice. Given the difficulty of an effective measurement of transaction costs in construction, Williamson's concept of atmosphere is suggested to explain the different approaches observed in subcontracting. Journal: Construction Management and Economics Pages: 439-447 Issue: 4 Volume: 19 Year: 2001 Keywords: Quasifirm Transaction Costs Subcontracting Construction Market Homebuilders General Contractors, X-DOI: 10.1080/01446190010020390 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010020390 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:4:p:439-447 Template-Type: ReDIF-Article 1.0 Author-Name: Hedley Smyth Author-X-Name-First: Hedley Author-X-Name-Last: Smyth Title: Reply Abstract: Journal: Construction Management and Economics Pages: 449-450 Issue: 4 Volume: 19 Year: 2001 X-DOI: 10.1080/01446190010026114 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190010026114 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:4:p:449-450 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: NG Thomas Author-X-Name-First: NG Author-X-Name-Last: Thomas Title: Australian project time-cost analysis: Statistical analysis of intertemporal trends Abstract: In statistical analysis of intertemporal movements in time-cost relationships via the Bromilow model it is shown that for Ng et al.'s (2001) Australian data, the K value is not significantly different from unity. This is utilized to develop a new and simpler ratio measure of the time-cost relationship, which has the advantage of being obtainable for each project. A scatter plot and a statistical analysis of the project ratios indicate significant yearly fluctuations but no underlying trend. Assuming similar characteristics of the data from previous studies, equivalent average ratios are estimated and plotted, confirming Ng et al.'s visual appearance of a possible downward trend. However, the statistical analysis is inconclusive on the issue, there being insufficient data (six points) for a full analysis. Journal: Construction Management and Economics Pages: 455-458 Issue: 5 Volume: 19 Year: 2001 Keywords: Time, cost, model, trend, Bromilow, intertemporal, nonlinear, X-DOI: 10.1080/01446193.2001.9709621 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2001.9709621 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:5:p:455-458 Template-Type: ReDIF-Article 1.0 Author-Name: Zhaoxia Li Author-X-Name-First: Zhaoxia Author-X-Name-Last: Li Author-Name: Michael Anson Author-X-Name-First: Michael Author-X-Name-Last: Anson Author-Name: Guangming Li Author-X-Name-First: Guangming Author-X-Name-Last: Li Title: A procedure for quantitatively evaluating site layout alternatives Abstract: Construction site layout decisions affect the effort involved in materials handling, an activity which occupies a substantial portion of working time. Much computer software has been developed enabling construction managers to plan and visualize the layout of a construction site, but at present the lack of an accepted practical technique for evaluating the efficiency of a chosen site layout makes it difficult to choose objectively between possibilities, in the search for a better layout design. The research described in this paper explores the practicability of an evaluation procedure intended to help improve this situation, and effectively describes the use of a quantitative material flow network model as the basis for evaluating the efficiency of a given site layout option. The evaluation measure, 'total material flow time', is calculated as part of an evaluation procedure. A site trial of the procedure is described, and its necessary development into a computer assisted procedure is discussed. Journal: Construction Management and Economics Pages: 459-467 Issue: 5 Volume: 19 Year: 2001 Keywords: Site layout, quantitative evaluation, material flow, X-DOI: 10.1080/01446193.2001.9709622 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2001.9709622 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:5:p:459-467 Template-Type: ReDIF-Article 1.0 Author-Name: Paulo Barbosa Author-X-Name-First: Paulo Author-X-Name-Last: Barbosa Author-Name: Priscilla Pimentel Author-X-Name-First: Priscilla Author-X-Name-Last: Pimentel Title: A linear programming model for cash flow management in the Brazilian construction industry Abstract: A linear programming model has been developed for optimal cash flow management addressing specific cash flow issues related to the construction industry. These include typical financial transactions, possible delays on payments, use of available credit lines, effect of changing interest rates, and budget constraints that often occur in the construction industry. A small size project from the Brazilian construction industry is provided as a case study, aiming at evaluating the potential benefits from using the model. Different changes to the basic structure of the model allow and establish the consistency of the results. Alternative formulations are suggested to deal with uncertainties, longer planning horizons, and multiple subcontractors and suppliers. In addition to the tangible financial earnings derived from the optimization process, the simple structure of the model, as a network flow and corresponding equations, provides much visual insight concerning the relationships between the external inputs and the variables of the problem. Optimal results have yet to be achieved in a real life situation, but a better view of whole cash flow management is provided when using the model. Journal: Construction Management and Economics Pages: 469-479 Issue: 5 Volume: 19 Year: 2001 Keywords: Cash flow management, financial planning, linear optimization, X-DOI: 10.1080/01446193.2001.9709623 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2001.9709623 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:5:p:469-479 Template-Type: ReDIF-Article 1.0 Author-Name: Raymond Nkado Author-X-Name-First: Raymond Author-X-Name-Last: Nkado Author-Name: Terry Meyer Author-X-Name-First: Terry Author-X-Name-Last: Meyer Title: Competencies of professional quantity surveyors: A South African perspective Abstract: A competency-based review of professional quantity surveying is important for service excellence and has continuing relevance in the built environment of the 21st century. A survey of quantity surveyors in professional practice in South Africa has provided a new perspective on the relative importance of competencies required for current and future quantity surveying services, and revealed notable gaps between the important competencies and current proficiency levels among practitioners. The survey was based on a structured questionnaire reflecting 23 defined competencies, which were derived from the literature and from in-depth interviews with selected practitioners. The results indicated that technically orientated competencies were rated of highest importance for current services, while management orientated competencies were rated of higher importance for future services. The profession was rated as deploying below average proficiency levels in marketing, advanced financial management, leadership and general management, and project management, although these received high current and future importance ratings. The findings suggest that initial and continuing education and training of professional quantity surveyors should emphasize the development of management-orientated competencies. Journal: Construction Management and Economics Pages: 481-491 Issue: 5 Volume: 19 Year: 2001 Keywords: Competencies, ranking, quantity surveyors, South Africa, X-DOI: 10.1080/01446193.2001.9709624 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2001.9709624 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:5:p:481-491 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Fox Author-X-Name-First: Stephen Author-X-Name-Last: Fox Author-Name: Laurence Marsh Author-X-Name-First: Laurence Author-X-Name-Last: Marsh Author-Name: Graham Cockerham Author-X-Name-First: Graham Author-X-Name-Last: Cockerham Title: Design for manufacture: A strategy for successful application to buildings Abstract: Building designers' counterparts in the manufacturing industry use proprietary methodologies described by the term 'design for manufacture' (DFM). Their use has resulted in radical improvements to productivity and quality. The potential benefits of applying DFM to buildings are widely recognized. However, there are differences between design in the manufacturing industry and in the construction industry. An analysis is provided here of how building design information and activities could affect successful application of DFM in the construction industry. The paper presents a review of DFM literature and a field survey of construction manufacturers, assemblers and consultants. The results suggest that information and activities prevalent in building design are barriers to the successful application of existing DFM methodologies. However, it may be possible to apply the fundamental principles of DFM to buildings. A strategy to achieve this is introduced and discussed. Journal: Construction Management and Economics Pages: 493-502 Issue: 5 Volume: 19 Year: 2001 Keywords: Design for manufacture (DFM), design rules, design metrics, methodology, X-DOI: 10.1080/01446193.2001.9709625 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2001.9709625 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:5:p:493-502 Template-Type: ReDIF-Article 1.0 Author-Name: Derek Drew Author-X-Name-First: Derek Author-X-Name-Last: Drew Author-Name: Liwina Ho Author-X-Name-First: Liwina Author-X-Name-Last: Ho Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Analysing a consultant's competitiveness in two-envelope fee tendering Abstract: A method for analysing the competitiveness of a consultant's two-envelope fee tendering history is proposed and illustrated in an application to one of Hong Kong's larger quantity surveying practices. Separate measures for determining consultants' fee, quality score and overall competitiveness are considered to accommodate the special nature of the Hong Kong system, which makes cross-auction comparisons impossible. Maximum fee competitiveness is assumed to be the lowest submitted tender fee, while maximum quality score competitiveness is taken to be the highest quality score attained by a competing consultant. Fees and quality score are then expressed as separate competitiveness ratios relative to these maximums and aggregated for determining overall competitiveness. In analysing bidding performance it was found that this consultant's fee, quality score and overall competitiveness are all above the competitor average. These competitiveness measures reveal large differences in variability between quality score and fees, with quality score variability being considerably lower. Such a large imbalance in competitiveness variability effectively discounts quality and promotes the influence of the fee, since competitiveness ratio differences between fees are much larger than the competitiveness ratio differences between quality scores. Journal: Construction Management and Economics Pages: 503-510 Issue: 5 Volume: 19 Year: 2001 Keywords: bidding, competitiveness, consultant, fee, quality, tendering, X-DOI: 10.1080/01446193.2001.9709626 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2001.9709626 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:5:p:503-510 Template-Type: ReDIF-Article 1.0 Author-Name: Alex Eyiah Author-X-Name-First: Alex Author-X-Name-Last: Eyiah Title: An integrated approach to financing small contractors in developing countries: A conceptual model Abstract: Lack of access to bank finance is one of the major constraints on the development of small contractors in developing countries. Efforts by governments and interested donor agencies to mitigate the problem have achieved little. Banks perceive that the risk and transaction costs involved in dealing with small businesses in general are high. They also lack information about small business owner-managers and their businesses to better evaluate their loan proposals. Furthermore, several factors make it difficult to acquire adequate collateral to compensate for the risk. Theoretical and empirical analysis has recognized the importance of developing a closer working relationship between the bank and the small business in addressing the problem and, hence, improving the latter's access to bank loans. Microcredit schemes, which dwell on the principles of small business-bank relationships, have been successful in this respect. This paper reviews the factors affecting bank financing of small businesses and examines their implications for small contractors in developing countries. Based on the concept of microcredit, a model for financing small contractors in developing countries has been developed. Journal: Construction Management and Economics Pages: 511-518 Issue: 5 Volume: 19 Year: 2001 Keywords: Developing countries, contractor development, small contractors, bank finance, microcredit, X-DOI: 10.1080/01446193.2001.9709627 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2001.9709627 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:5:p:511-518 Template-Type: ReDIF-Article 1.0 Author-Name: Graham Winch Author-X-Name-First: Graham Author-X-Name-Last: Winch Author-Name: Brid Carr Author-X-Name-First: Brid Author-X-Name-Last: Carr Title: Processes, maps and protocols: Understanding the shape of the construction process Abstract: Process mapping and benchmarking are becoming widely recognized as important management tools for understanding how value is delivered for customers, and their use in the construction industry is growing rapidly. Influenced by research on design project management, and the requirements of developing inter-firm IT systems, this work has focused renewed attention on the role of process protocols. The aim of this paper is to explore empirically the use of process maps and protocols within one retail client with a large programme of retail development projects. Journal: Construction Management and Economics Pages: 519-531 Issue: 5 Volume: 19 Year: 2001 Keywords: Process mapping, process protocol, benchmarking, key performance indicators, retail clients, X-DOI: 10.1080/01446193.2001.9709628 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2001.9709628 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:5:p:519-531 Template-Type: ReDIF-Article 1.0 Author-Name: Alan Griffith Author-X-Name-First: Alan Author-X-Name-Last: Griffith Author-Name: Nick Phillips Author-X-Name-First: Nick Author-X-Name-Last: Phillips Title: The influence of the Construction (Design and Management) Regulations 1994 upon the procurement and management of small building works Abstract: This paper, which focuses on the impact of the Construction (Design and Management) Regulations 1994 on the management of small building works, adds new data and analysis to the further development of a subset of findings from a major research study, supported by governmental and industry based sources, which investigated the efficiency and effectiveness of procurement methods, organizational systems and management approaches to small building works and minor maintenance projects. Within this industry subsector there has been and continues to be an apparent culture of misunderstanding in the application of the CDM Regulations. However, commonly such works are undertaken in active environments where buildings are occupied or are operational. This raises many issues and considerations which are key to the satisfactory implementation of the CDM Regulations. The application of the Regulations is examined explicitly in the context of managing small building works. The findings indicate that the CDM Regulations have left ambiguities, primarily through specified exclusions to application, through which health and safety responsibilities may be downplayed or even simply disregarded. Effective implementation of the CDM Regulations during the management of small building works requires that legislation be unambiguously translated into contract documentation, and also that there must be clear understanding by project participants of their committed and onerous responsibilities for project health and safety under the CDM Regulations. Journal: Construction Management and Economics Pages: 533-540 Issue: 5 Volume: 19 Year: 2001 Keywords: Small works, maintenance, management, health and safety, CDM Regulations, X-DOI: 10.1080/01446193.2001.9709629 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2001.9709629 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:5:p:533-540 Template-Type: ReDIF-Article 1.0 Author-Name: Serdar Kale Author-X-Name-First: Serdar Author-X-Name-Last: Kale Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Title: General contractors' relationships with subcontractors: A strategic asset Abstract: The general contractor-subcontractor relationship has been a focus of interest in the literature and yet its impact on a general contractor's economic performance remains a virtually unexplored area in the construction management literature. This research presents the findings of a questionnaire survey administered to 500 large US general contractors to explore this issue. The findings reveal that maintaining a relationship of high quality with subcontractors is positively and strongly associated with the perceived performance of general contractors responding to the survey. Journal: Construction Management and Economics Pages: 541-549 Issue: 5 Volume: 19 Year: 2001 Keywords: Transactions, general contractors, subcontractors, relationship quality, social embeddedness, and economic performance, X-DOI: 10.1080/01446193.2001.9709630 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2001.9709630 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:5:p:541-549 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Lemer Author-X-Name-First: Andrew Author-X-Name-Last: Lemer Title: Book review Abstract: Construction - The Third Way: Managing Cooperation and Competition in Construction John Bennett, Butterworth Heinemann, 2000, ISBN 0 7506 3093 0, 224 pp., £19.99 Journal: Construction Management and Economics Pages: 551-552 Issue: 5 Volume: 19 Year: 2001 X-DOI: 10.1080/01446193.2001.9709631 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2001.9709631 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:5:p:551-552 Template-Type: ReDIF-Article 1.0 Author-Name: David Moore Author-X-Name-First: David Author-X-Name-Last: Moore Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Title: Intra-team boundaries as inhibitors of performance improvement in UK design and build projects: a call for change Abstract: The success of the design and build (D&B) procurement route could be undermined by issues arising from the rigid professional cultures of individual participants within project workgroups. These have the potential to inhibit the achievement of a key espoused benefit of D&B procurement, i.e. that it promotes the integration of the design and construction processes for improved project performance. Cultural non-interoperability is identified as a significant potential barrier to effective change management, and to the achievement of innovation within the design and construction processes. This note argues that project responsibilities, which currently are delineated along professional identity lines, produce design and construction solutions that fail to fulfil the potential of D&B procurement. It is suggested that addressing cultural interoperability will require a fundamental and long term reshaping of the industry's structure, beginning with the professional bodies and the higher education system that underpins their future membership. Journal: Construction Management and Economics Pages: 559-562 Issue: 6 Volume: 19 Year: 2001 Keywords: Professional Cultures Interoperability Performance Improvement Design And Build Allow Approx Picas, X-DOI: 10.1080/01446190110055508 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110055508 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:6:p:559-562 Template-Type: ReDIF-Article 1.0 Author-Name: Said Boukendour Author-X-Name-First: Said Author-X-Name-Last: Boukendour Author-Name: Rahim Bah Author-X-Name-First: Rahim Author-X-Name-Last: Bah Title: The guaranteed maximum price contract as call option Abstract: Due to increasing constraints on project duration and costs, together with the increasing implication of contractors in the design process, guaranteed maximum price (GMP) contracts are likely to become common in the future. This paper explores a new approach for evaluating the remuneration of the contractor. The GMP contract is considered as a hybrid arrangement consisting of a cost reimbursement contract and a call option on a fixed price contract. The option pricing theory is used as a conceptual framework to assess the GMP contract and the contractors' remuneration. Journal: Construction Management and Economics Pages: 563-567 Issue: 6 Volume: 19 Year: 2001 Keywords: Guaranteed Maximum Price Fixed Price Cost Reimbursement Call Option, X-DOI: 10.1080/01446190110049848 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110049848 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:6:p:563-567 Template-Type: ReDIF-Article 1.0 Author-Name: K. C. Lam Author-X-Name-First: K. C. Author-X-Name-Last: Lam Author-Name: G. Runeson Author-X-Name-First: G. Author-X-Name-Last: Runeson Author-Name: S. T. Ng Author-X-Name-First: S. T. Author-X-Name-Last: Ng Author-Name: T. S. Hu Author-X-Name-First: T. S. Author-X-Name-Last: Hu Author-Name: S. O. Cheung Author-X-Name-First: S. O. Author-X-Name-Last: Cheung Author-Name: Z. M. Deng Author-X-Name-First: Z. M. Author-X-Name-Last: Deng Title: Capital budget planning practices of building contractors in Hong Kong Abstract: This paper explores the current practice of capital budget planning and control in the Hong Kong (HK) construction industry, based on two surveys undertaken in 1994 and 1999. The aims of these surveys were to uncover the financial planning, monitoring and control procedures used by building engineering contractors in HK. The results of the current survey reveal that less than half of the respondents undertook any form of capital budget planning. The most common form of capital budget planning was a review of the minimum rate of return. Despite the low prevalence of planning, most respondents adopted some method of capital budget control, especially by way of monitoring project performance. The 1999 study was compared with a similar survey conducted in 1994. The results indicate that there was no significant improvement in capital budget planning practices over the five year period. In addition to these findings, this paper concludes with a classification of firms, according to their capital budget planning behaviour, using discriminant function analysis. Journal: Construction Management and Economics Pages: 569-576 Issue: 6 Volume: 19 Year: 2001 Keywords: Capital Budgeting Planning And Control Discriminant Analysis Allow Approx Picas, X-DOI: 10.1080/01446190110054112 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110054112 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:6:p:569-576 Template-Type: ReDIF-Article 1.0 Author-Name: Graham Winch Author-X-Name-First: Graham Author-X-Name-Last: Winch Author-Name: Brid Carr Author-X-Name-First: Brid Author-X-Name-Last: Carr Title: Benchmarking on-site productivity in France and the UK: a CALIBRE approach Abstract: Construction is an increasingly global industry, and benchmarking initiatives that are restricted to a single country run the risk of complacency, as national best practice falls out of line with international best practice. The aim of this article is to report the results of a detailed comparative analysis of the on-site performance of the UK and French divisions of a major UK construction corporation. It focuses on structural concrete because this is potentially a major element in the budget and programme of any construction project, and an area of known French strength. It deploys an innovative computerized productivity measurement tool based on activity sampling, 'CALIBRE', in order to provide detailed comparative data. The results show that the UK productivity performance is poorer than in France, and that the poor UK performance compared with the French is explained by elaborate divisions of labour, lack of investment in plant, and less effective work organization. However, as will be argued in the conclusions, these differences cannot be understood without reference to the overall contracting system and the constraints upon action that it imposes. Journal: Construction Management and Economics Pages: 577-590 Issue: 6 Volume: 19 Year: 2001 Keywords: Productivity Benchmarking Activity Sampling France Structural Concrete Site Organization, X-DOI: 10.1080/01446190110062465 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110062465 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:6:p:577-590 Template-Type: ReDIF-Article 1.0 Author-Name: Mohammed Fadhil Dulaimi Author-X-Name-First: Mohammed Fadhil Author-X-Name-Last: Dulaimi Author-Name: Tan Fu Hwa Author-X-Name-First: Tan Fu Author-X-Name-Last: Hwa Title: Developing world class construction companies in Singapore Abstract: The construction industry in Singapore is under pressure to improve its performance and the quality of its products and services. The Government is looking to see Singapore develop into a knowledge-based economy, and construction cannot be left behind. A recently published report about re-inventing construction has called on the industry to become a world-class industry. This study examines the attitudes and views of contractors, operating in Singapore, on how and where developments should be focused to bring about such a transformation. The results show that local contractors are not overly enthusiastic about becoming worldclass. The study found also that contractors expect the development to be Government led, with policies and incentives to support such an effort. At the same time there is a feeling that current Government policies are not effective in enabling the industry to become world-class. Journal: Construction Management and Economics Pages: 591-599 Issue: 6 Volume: 19 Year: 2001 Keywords: World Class Construction Development Government Policies Competitive Advantage Allow Approx Picas, X-DOI: 10.1080/01446190110050945 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110050945 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:6:p:591-599 Template-Type: ReDIF-Article 1.0 Author-Name: Thomas Tong Author-X-Name-First: Thomas Author-X-Name-Last: Tong Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Author-Name: Albert Chan Author-X-Name-First: Albert Author-X-Name-Last: Chan Title: Genetic algorithm optimization in building portfolio management Abstract: A significant proportion of building investment expenditure goes to replacement expenditure for organizations owning a large building stock or portfolio. Over the years, researchers have attempted to develop asset replacement models to aid decision-making in building portfolio management, based upon' a statistical or an heuristic approach. This study attempts to use genetic algorithms to develop models for forecasting long term asset replacement strategies, aiming at smoothing fluctuations of expenditure and resource requirements, and most importantly minimizing the total maintenance and replacement costs. Scenarios are presented to demonstrate how these can be achieved. Further refinement for practical application of the models is also presented. Journal: Construction Management and Economics Pages: 601-609 Issue: 6 Volume: 19 Year: 2001 Keywords: Building Portfolio Management Genetic Algorithms Asset Replacement, X-DOI: 10.1080/01446190110062096 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110062096 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:6:p:601-609 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Title: The effect of first aid training on objective safety behaviour in Australian small business construction firms Abstract: A 24 week experiment was conducted to determine the effect of first aid training on the occupational health and safety behaviour of participants in small business construction firms in Australia. A purposeful sample of 22 small business construction industry participants was identified. A simplified multiple baseline across workplace settings experimental design was used to introduce first aid training to workplace settings on a staggered basis. Objective measurement of occupational health and safety behaviour was conducted, by a researcher directly observing the workplace, before and after participants received first aid training. Individual performance was measured using a 14-item 'individual safety measure' (ISM) and global safety performance was measured using a 21-item 'global site safety measure' (GSSM). Pre-training and post-training performance scores for each category of safety performance were analysed using paired samples t-tests. The results were mixed. Performance improved in three of the four categories of safety performance measured by both the GSSM and ISM. The statistical significance of these improvements varied between performance categories. The results suggest that first aid training has a positive effect on occupational health and safety behaviour in Australian construction industry small businesses in the categories of personal protective equipment and housekeeping. Journal: Construction Management and Economics Pages: 611-618 Issue: 6 Volume: 19 Year: 2001 Keywords: First Aid Occupational Health And Safety Behaviour Construction Small Business, X-DOI: 10.1080/01446190110049820 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110049820 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:6:p:611-618 Template-Type: ReDIF-Article 1.0 Author-Name: Ang Yee Kwan Author-X-Name-First: Ang Yee Author-X-Name-Last: Kwan Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Title: Chinese culture and successful implementation of partnering in Singapore's construction industry Abstract: Partnering is based on the principles of trust, mutual respect and cooperation towards the achievement of a common goal. Although partnering can help to resolve the problems of Singapore's construction industry, its usage is relatively low. This paper examines whether Chinese culture can facilitate partnering implementation in Singapore's construction industry. This is because Chinese culture contains some values that are important determinants of success of partnering. A postal survey on Chinese-owned large contractors in Singapore was undertaken to ascertain how Chinese culture influences their way of conducting business and the implementation of partnering. The study showed that Chinese contractors understand their culture as comprising certain core values that influence the operations of their businesses and their relationships with others, and that Chinese culture aids the implementation of partnering. It is suggested that Chinese construction entrepreneurs should apply the elements of their culture to formulate appropriate business practices, and to implement partnering. Journal: Construction Management and Economics Pages: 619-632 Issue: 6 Volume: 19 Year: 2001 Keywords: Partnering Chinese Culture Business Practices Construction Industry Singapore, X-DOI: 10.1080/01446190110062087 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110062087 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:6:p:619-632 Template-Type: ReDIF-Article 1.0 Author-Name: Carl Haas Author-X-Name-First: Carl Author-X-Name-Last: Haas Author-Name: Ana Maria Rodriguez Author-X-Name-First: Ana Maria Author-X-Name-Last: Rodriguez Author-Name: Robert Glover Author-X-Name-First: Robert Author-X-Name-Last: Glover Author-Name: Paul Goodrum Author-X-Name-First: Paul Author-X-Name-Last: Goodrum Title: Implementing a multiskilled workforce Abstract: Recent studies show the construction industry in the USA is facing a long term labour shortage. Multiskilling has been suggested as a strategy to address this issue by utilizing existing workers more efficiently. Multiskilling decreases the number of workers hired for a project and can improve productivity. Additional benefits include higher income and increased employability of the workforce. To take full advantage of these benefits, the workforce strategy and the planning and scheduling processes of a construction project must be adapted to use multiskilling effectively and efficiently. The multiskilled workforce should be scheduled and organized to maximize the duration of employment for workers, reduce the overall labour requirements and cover the skills combinations required by the project. This research synthesizes and formalizes the methods that successful construction companies are currently applying to implement a multiskilled workforce. A methodology for implementing multiskilling is outlined as well. Journal: Construction Management and Economics Pages: 633-641 Issue: 6 Volume: 19 Year: 2001 Keywords: Labour Workforce Scheduling Planning Multiskilling Worker Utilization Allow Approx Picas, X-DOI: 10.1080/01446190110050936 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110050936 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:6:p:633-641 Template-Type: ReDIF-Article 1.0 Author-Name: Zhang Hong Author-X-Name-First: Zhang Author-X-Name-Last: Hong Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Author-Name: Jonathan Shi Author-X-Name-First: Jonathan Author-X-Name-Last: Shi Title: Resource allocation heuristic in construction simulation Abstract: The quantity of some resources is limited because of project cost constraints. These resources may be required by multiple activities simultaneously during a construction process. In a discrete simulation that models the construction process, tracing and controlling such entities, e.g. resources, is crucial to simulation. This paper presents a resource allocation point (RAP) heuristic that takes into account the dynamic and stochastic charateristics of simulation to enable the activity-based construction simulation system to process a decision-making ability, i.e. allocating the limited resources to the multiple computing activites during simulation. In addition, this paper introduces an activity object-orientated approach that implements the RAP heuristic and speeds up the simulation experimentation through initiating and checking only related activity objects instead of scanning all activities as in a pure activity scanning (AS) simulation strategy. Journal: Construction Management and Economics Pages: 643-651 Issue: 6 Volume: 19 Year: 2001 Keywords: Resource Allocation Heuristic Construction Simulation Decision-MAKING Simulation Strategy Object Oriented Approach, X-DOI: 10.1080/01446190110063473 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110063473 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:6:p:643-651 Template-Type: ReDIF-Article 1.0 Author-Name: Raymond Tse Author-X-Name-First: Raymond Author-X-Name-Last: Tse Author-Name: Peter Love Author-X-Name-First: Peter Author-X-Name-Last: Love Title: Property rights implications of public-private joint ventures: a comment Abstract: Wong, K. C. and Walker, A. (2000) Construction Management and Economics, 18 (2), 131-138 have argued that co-operative joint venture arrangements (with state enterprises in the People's Republic of China) reduce the dissipation of rent under public ownership, which leads to an apparent transfer of shares from the public institution to the private developer. This proposition is challenged, and it is demonstrated using economic analysis that co-operative joint ventures between Hong Kong and China are a feasible option for developers and public institutions. Journal: Construction Management and Economics Pages: 663-668 Issue: 7 Volume: 19 Year: 2001 Keywords: Joint Ventures Hong Kong China Property Development, X-DOI: 10.1080/01446190110065714 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110065714 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:7:p:663-668 Template-Type: ReDIF-Article 1.0 Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Title: Matrix organizational structure, culture and commitment: a Hong Kong public sector case study of change Abstract: This paper reports on the impact of organizational change on a government department in Hong Kong. It focuses on the perceptions of professional personnel of the organizational culture developed in the depart4 ment and its mismatch with their expectations. The commitment of the professionals to their organization was measured, and found to be limited solely to a level of continuance commitment. The results of the study are discussed and explained in part by reference to Hofstede's cultural concepts of power distance and individualism, and by reference to traditional Chinese cultural values. Journal: Construction Management and Economics Pages: 669-673 Issue: 7 Volume: 19 Year: 2001 Keywords: Organizational Change Organizational Culture Commitment Matrix Organization Cultural Values, X-DOI: 10.1080/01446190110066137 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110066137 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:7:p:669-673 Template-Type: ReDIF-Article 1.0 Author-Name: Yat-Hung Chiang Author-X-Name-First: Yat-Hung Author-X-Name-Last: Chiang Author-Name: Bo-Sin Tang Author-X-Name-First: Bo-Sin Author-X-Name-Last: Tang Author-Name: Wing-Yu Leung Author-X-Name-First: Wing-Yu Author-X-Name-Last: Leung Title: Market structure of the construction industry in Hong Kong Abstract: This study examines the market structure of four different sectors within the construction industry in Hong Kong. Market concentrations, expressed in terms of Herfindahl-Hershamann indices (HHIs) and number equivalents (HNEs), are calibrated for the top five contractors and compared with those of the local property industry. The study reveals the following ascending order of market concentrations: private building, public building, property development, and civil engineering. Our explanation is that technological and capital requirements have imposed a strong barrier to entry into the civil engineering sector, resulting in a concentrated market. Conversely, the lack of technological demand and supply in the private building sector has led to easy market entry and exit. Building contractors thus compete intensely on cost reduction rather than technology improvement, leading to poor construction safety and product quality. The paper concludes that the Government, being a major client of construction works and regulator of the industry, can assume a more active role in promoting the overall competitiveness of indigenous local contractors in Hong Kong. Journal: Construction Management and Economics Pages: 675-687 Issue: 7 Volume: 19 Year: 2001 Keywords: Construction Market Structure Herfindahl-HERSHAMANN Indices Hong Kong, X-DOI: 10.1080/01446190110067046 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110067046 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:7:p:675-687 Template-Type: ReDIF-Article 1.0 Author-Name: Emad Elbeltagi Author-X-Name-First: Emad Author-X-Name-Last: Elbeltagi Author-Name: Tarek Hegazy Author-X-Name-First: Tarek Author-X-Name-Last: Hegazy Author-Name: Abdel Hady Hosny Author-X-Name-First: Abdel Hady Author-X-Name-Last: Hosny Author-Name: Adel Eldosouky Author-X-Name-First: Adel Author-X-Name-Last: Eldosouky Title: Schedule-dependent evolution of site layout planning Abstract: The appropriate layout of temporary facilities on a construction site has a large impact on construction safety and productivity. For the duration of a project the site layout may need to be efficiently re-organized at various intervals to satisfy the schedule requirements and to maintain site efficiency. This paper presents a practical model for schedule-dependent site layout planning in construction. The proposed model uses a combination of artificial intelligence tools (knowledge-based systems, fuzzy logic, and genetic algorithms) to generate, optimize, and re-organize the site layout plan at frequent intervals during the project. The model incorporates flexible representation of irregular site shapes and several options for placing facilities. Based on the proposed model, an automated system is developed, fully integrated with widely used scheduling software. At each schedule interval, the system recalculates the space requirements and, for the convenience of congested sites, can utilize parts of the constructed space to accommodate temporary facilities. Details of the schedule-dependent model are described, and its application in an actual case study project is presented to demonstrate its capabilities. Journal: Construction Management and Economics Pages: 689-697 Issue: 7 Volume: 19 Year: 2001 Keywords: Site Layout Quantitative Evaluation Material Flow, X-DOI: 10.1080/01446190110066713 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110066713 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:7:p:689-697 Template-Type: ReDIF-Article 1.0 Author-Name: Albert Chan Author-X-Name-First: Albert Author-X-Name-Last: Chan Author-Name: Esther Yung Author-X-Name-First: Esther Author-X-Name-Last: Yung Author-Name: Patrick Lam Author-X-Name-First: Patrick Author-X-Name-Last: Lam Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Author-Name: S. O. Cheung Author-X-Name-First: S. O. Author-X-Name-Last: Cheung Title: Application of Delphi method in selection of procurement systems for construction projects Abstract: A number of procurement selection systems have been developed over the last decade. The use of multi-attribute decision analysis has been considered the foremost technique for examining client needs and the weightings of preferences from experts for each procurement system in the most objective way available. However, the major difficulty of these selection models lies in the lack of consensus among the experts on the utility factor of the selection criteria. To overcome these deficiencies, a Delphi technique was adopted to develop a multi-attribute model. Four rounds of Delphi surveys were conducted. A statistically significant consensus on the weighting of the utility factors for each procurement system was obtained from eight experts. The results vividly reveal that the Delphi method is a powerful and appropriate technique for deriving objective opinions in a rather subjective area such as the multi-attribute model for the selection of procurement system. Journal: Construction Management and Economics Pages: 699-718 Issue: 7 Volume: 19 Year: 2001 Keywords: Procurement System Multi-ATTRIBUTE Selection Model Delphi Method, X-DOI: 10.1080/01446190110066128 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110066128 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:7:p:699-718 Template-Type: ReDIF-Article 1.0 Author-Name: Gladys Kim Wan Siu Author-X-Name-First: Gladys Kim Wan Author-X-Name-Last: Siu Author-Name: Adrian Bridge Author-X-Name-First: Adrian Author-X-Name-Last: Bridge Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Assessing the service quality of building maintenance providers: mechanical and engineering services Abstract: This study investigates the service quality in the maintenance of mechanical and engineering services. The determinants of service quality are identified and their means of evaluation are examined. A method of assessment is devised based on the SERVQUAL approach, and its use is then illustrated using a small empirical survey of clients and service providers and the 'Gap' model used to quantify the relationships between customer satisfaction, expected service, perceived service and service quality gap. Journal: Construction Management and Economics Pages: 719-726 Issue: 7 Volume: 19 Year: 2001 Keywords: Client Service Provider Service Quality Expectation Perception Satisfaction, X-DOI: 10.1080/01446190110062104 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110062104 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:7:p:719-726 Template-Type: ReDIF-Article 1.0 Author-Name: Mark Hall Author-X-Name-First: Mark Author-X-Name-Last: Hall Author-Name: Cyril Tomkins Author-X-Name-First: Cyril Author-X-Name-Last: Tomkins Title: A cost of quality analysis of a building project: towards a complete methodology for design and build Abstract: A number of studies have been published that claim to carry out cost of quality (COQ) studies on construction projects. These studies, however, have largely ignored the contribution of prevention and appraisal costs to COQ, and have limited their analysis to the impact of quality failures on the main contractor. This paper presents a methodology for assessing the 'complete' COQ for construction projects and reports on the findings of a building project in the UK on which the methodology was piloted. The company that applied this approach has now extended it to other projects. Journal: Construction Management and Economics Pages: 727-740 Issue: 7 Volume: 19 Year: 2001 Keywords: Quality Management Cost Of Quality Cost Of Nonconformance Building Design And Build, X-DOI: 10.1080/01446190110066146 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110066146 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:7:p:727-740 Template-Type: ReDIF-Article 1.0 Author-Name: M. M. M. Teo Author-X-Name-First: M. M. M. Author-X-Name-Last: Teo Author-Name: M. Loosemore Author-X-Name-First: M. Author-X-Name-Last: Loosemore Title: A theory of waste behaviour in the construction industry Abstract: Levels of waste within the construction industry need to be reduced for environmental and economic reasons. Changing people's wasteful behaviour can make a significant contribution. This paper describes a research project that used Ajzen's 'theory of planned behaviour' to investigate the attitudinal forces that shape behaviour at the operative level. It concludes that operatives see waste as an inevitable by-product of construction activity. Attitudes towards waste management are not negative, although they are pragmatic and impeded by perceptions of a lack of managerial commitment. Waste management is perceived as a low project priority, and there is an absence of appropriate resources and incentives to support it. A theory of waste behaviour is proposed for the construction industry, and recommendations are made to help managers improve operatives' attitudes towards waste. Journal: Construction Management and Economics Pages: 741-751 Issue: 7 Volume: 19 Year: 2001 Keywords: Attitudes Waste Behaviour Operatives Environment Sustainability, X-DOI: 10.1080/01446190110067037 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110067037 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:7:p:741-751 Template-Type: ReDIF-Article 1.0 Author-Name: Russell Kenley Author-X-Name-First: Russell Author-X-Name-Last: Kenley Title: The predictive ability of Bromilow's time-cost model: a comment Abstract: The study of the relationship between construction time and cost has a long history. This paper reviews the report of Ng, S.T., Mak, M., Skitmore, R.M., Lam, K.C. and Varnam, M. (2001) Construction Management and Economics, 19, 165, and reveals they have made a substantial contribution to the method of analysis but that they have not sufficiently justified their case in light of the literature, and have not understood the role of sample sizes and confidence limits in the interpretation of their results. In particular, the present paper challenges their conclusion that a long term trend of improvement has been identified. This debate raises important epistemological questions for forecasting and modelling trends using generic time-cost models. Journal: Construction Management and Economics Pages: 759-764 Issue: 8 Volume: 19 Year: 2001 Keywords: Time Cost Construction Performance, X-DOI: 10.1080/01446190110073490 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110073490 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:8:p:759-764 Template-Type: ReDIF-Article 1.0 Author-Name: Seung Han Author-X-Name-First: Seung Author-X-Name-Last: Han Author-Name: James Diekmann Author-X-Name-First: James Author-X-Name-Last: Diekmann Title: Making a risk-based bid decision for overseas construction projects Abstract: The globalization of international construction markets provides tremendous opportunities for contractors to expand into new foreign markets. However, entry decisions for international construction markets are very risky and more difficult than those for domestic markets, due to the wide variety of uncertainties and complexities associated with the international construction domain. This paper focuses on developing and testing a 'risk-based go/no-go decision-making model' for contractors who wish to expand into international construc5 tion markets. The go/no-go decision model applies the cross-impact analysis (CIA) method to assess the various uncertainties associated with international construction. This research draws significant findings regarding the benefits of this go/no-go decision model from experimental studies involving 56 participants. Journal: Construction Management and Economics Pages: 765-776 Issue: 8 Volume: 19 Year: 2001 Keywords: International Projects Risk Analysis Risk-BASED Entry Decision Model Cross-IMPACT Analysis Experimental Case Studies, X-DOI: 10.1080/01446190110072860 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110072860 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:8:p:765-776 Template-Type: ReDIF-Article 1.0 Author-Name: Kerry London Author-X-Name-First: Kerry Author-X-Name-Last: London Author-Name: Russell Kenley Author-X-Name-First: Russell Author-X-Name-Last: Kenley Title: An industrial organization economic supply chain approach for the construction industry: a review Abstract: Understanding industries in terms of the concepts of chains, clusters and networks is becoming increasingly important in economies around the world. Supply chain management for an individual organization is an emerging field of research in the construction management discipline, but less attention has been devoted to investigating the nature of the construction supply chains and their industrial organizational economic environment. This selected review of construction and mainstream management supply chain literature is organized around four themes; distribution, production, strategic procurement management and industrial organization economics, and highlights the need to develop an industrial organization economic supply chain framework for construction. The merging of the supply chain concept with the industrial organization model as a methodology for understanding firm conduct and industry structure and performance is an important contribution to both construction supply chain and construction economic theory. Much of the industrial organization supply chain literature has tended to focus upon manufacturing industries, where typically firms are permanent organizations. This raises issues as to the differences between industries founded upon temporary compared with permanent organizations. There is potential for the development of an industrial organization methodology applicable to the project based industry. Ultimately industrial organization research seeks to have direct implications for industry performance and government policies. Journal: Construction Management and Economics Pages: 777-788 Issue: 8 Volume: 19 Year: 2001 Keywords: Supply Chain Theory Critical Review Construction Industry Industrial Organization Economics, X-DOI: 10.1080/01446190110081699 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110081699 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:8:p:777-788 Template-Type: ReDIF-Article 1.0 Author-Name: Abdul-Rashid Abdul-Aziz Author-X-Name-First: Abdul-Rashid Author-X-Name-Last: Abdul-Aziz Title: Foreign workers and labour segmentation in Malaysia's construction industry Abstract: One of the profound changes to have taken place over the last two decades in the construction industry in Malaysia is the emergence of foreign site operatives as an indispensable component of the labour force. This research shows that they have been exposed to some degree of discrimination at the hands of local employers. Labour segmentation has prevailed as a consequence of variability in country-specific traits. Schisms between the foreign nationals and local workers and between the various foreign nationals operate to the employers' advantage in that greater control can be exerted. Labour violations have always been an inexorable feature of the Malaysian construction industry, with little prospect of reform. As there seem to be no signs of the dependence on foreign workers attenuating, future waves of migrant workers can expect to be subjected to the same employer treatment, and hence labour segmentation. Journal: Construction Management and Economics Pages: 789-798 Issue: 8 Volume: 19 Year: 2001 Keywords: Labour Malaysia Segmentation Site Operatives Treatment, X-DOI: 10.1080/01446190110072022 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110072022 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:8:p:789-798 Template-Type: ReDIF-Article 1.0 Author-Name: Graham Winch Author-X-Name-First: Graham Author-X-Name-Last: Winch Title: Governing the project process: a conceptual framework Abstract: There has been considerable development in a process approach in construction management research in recent years. However, such work begs the question of how those processes are governed. Processes, be they flows of information or materials, need to be channelled in the desired direction as they are handed from team to team. This paper aims to present a conceptual framework for understanding the governance of construction project processes, drawing on transaction cost economics. Earlier attempts to apply this theoretical framework in construction management research have been partial, in that they have focused on only one type of transaction, typically that between client and principal contractor. This paper aims to be comprehensive in covering all the different transactions throughout the project lifecycle within one conceptual framework, and thereby it is hoped that more incisive empirical research can be developed and executed. Journal: Construction Management and Economics Pages: 799-808 Issue: 8 Volume: 19 Year: 2001 Keywords: Project Processes Project Lifecycle Transaction Costs Project Coalition Project Governance, X-DOI: 10.1080/01446190110074264 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110074264 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:8:p:799-808 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Guinevere Gilbert Author-X-Name-First: Guinevere Author-X-Name-Last: Gilbert Author-Name: Peter Graham Author-X-Name-First: Peter Author-X-Name-Last: Graham Title: Improving solid waste reduction and recycling performance using goal setting and feedback Abstract: A multiple-baseline experiment design across waste streams was used to determine the effectiveness of a goal setting and feedback intervention in bringing about improved solid waste management performance on a sports stadium construction site in Australia. A desktop method was used to measure the volume of timber and construction waste disposed as landfill and recycled. A general index of material usage efficiency and two recycling indices were calculated. Performance was measured each fortnight and formal goal setting and performance feedback were introduced to the timber and concrete waste streams. The intervention was effective in reducing the volume of waste disposed as landfill and increasing material usage efficiency, indicating that solid waste was reduced at source or re-used. Recycling performance did not improve significantly with the introduction of the intervention. This may be due to the way in which construction workers perceive the costs and benefits of recycling. Journal: Construction Management and Economics Pages: 809-817 Issue: 8 Volume: 19 Year: 2001 Keywords: Solid Waste Reduction Re-USE Recycling Motivation Construction Australia, X-DOI: 10.1080/01446190110070952 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110070952 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:8:p:809-817 Template-Type: ReDIF-Article 1.0 Author-Name: Mekdam Nima Author-X-Name-First: Mekdam Author-X-Name-Last: Nima Author-Name: Mohd Abdul-Kadir Author-X-Name-First: Mohd Author-X-Name-Last: Abdul-Kadir Author-Name: Mohd Jaafar Author-X-Name-First: Mohd Author-X-Name-Last: Jaafar Author-Name: Riadh Alghulami Author-X-Name-First: Riadh Author-X-Name-Last: Alghulami Title: Constructability implementation: a survey in the Malaysian construction industry Abstract: Twenty-three constructability concepts are identified. Based on these, an industry-wide questionnaire was administrated in Peninsular Malaysia. The respondents were the engineers working with owners, consultants, contractors, subcontractors and construction management firms. The importance, from the viewpoint of the Malaysian engineers, of the constructability concepts and the degree of the actual application of those concepts in the Malaysian Construction Industry is presented so that an insight on constructability implementation can be established. Fieldwork results revealed that the Malaysian engineers showed high acceptance of 22 concepts and rejected the one that relates to the fast-track method of construction. Those engineers accepted the constructability concepts from the theoretical point of view but generally they did not apply these concepts in their practices. The study also concludes that the Malaysian engineers show a wide understanding of the majority of the concepts. However, they did not link those concepts under the umbrella of constructability. Journal: Construction Management and Economics Pages: 819-829 Issue: 8 Volume: 19 Year: 2001 Keywords: Constructability Implementation Buildability Construction Management Construction Knowledge Fast Track, X-DOI: 10.1080/01446190110089709 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110089709 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:8:p:819-829 Template-Type: ReDIF-Article 1.0 Author-Name: Campbell Fraser Author-X-Name-First: Campbell Author-X-Name-Last: Fraser Author-Name: Anna Zarkada-Fraser Author-X-Name-First: Anna Author-X-Name-Last: Zarkada-Fraser Title: The philosophy, structure and objectives of research and development in Japan Abstract: This paper presents an overview of the philosophy, structure and key objectives of R&D activity in the Japanese construction industry. It argues that this unique model of a close partnership between industry, government and society is based on shared values, and delivers significant benefits not only for firms but for society at large. Additionally, the Japanese system acts as an efficient market entry barrier that protects the Japanese domestic market from foreign competition while concurrently providing the basis of Japan's competitive advantage in international markets. To illustrate how significantly different the Japanese model is from those of other advanced economies, an empirical comparison of the belief structures concerning responsibility for R&D of key players in the construction industries in Japan and Australia is presented. The results illustrate the point that, unlike Australia, Japanese contractors play a much more extensive role in society than do their Australian counterparts. This role incongruence may be the true barrier to penetration of the Japanese construction market. Journal: Construction Management and Economics Pages: 831-840 Issue: 8 Volume: 19 Year: 2001 Keywords: Research And Development Japan Australia Contractor International Marketing, X-DOI: 10.1080/01446190110074255 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110074255 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:8:p:831-840 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: Geoffrey Briscoe Author-X-Name-First: Geoffrey Author-X-Name-Last: Briscoe Author-Name: Sarah Millett Author-X-Name-First: Sarah Author-X-Name-Last: Millett Title: Subcontractor perspectives on supply chain alliances Abstract: Since the publication of the Egan report in 1998, there has been a strong and consistent emphasis on the need to integrate the project delivery process via partnering and strategic alliancing agreements throughout the UK construction industry. However, given the continued reliance on subcontracting within the sector, future performance improvement also requires an acceptance of the benefits of supply chain partnering and integration from the small-to-medium size businesses who carry out the majority of construction work. This paper presents the findings of a research project that examined subcontractor perspectives on supply chain alliances. The study has uncovered serious concerns among subcontractors that point towards a fundamental mistrust and scepticism within existing supply chain relationships. These have the potential to inhibit further improvements in the efficacy of the project delivery process. A range of attitudinal change requirements for integrating smaller companies into the drive for continuous improvement are identified. It is suggested that leading clients should take responsibility for engendering the necessary attitudinal change throughout their supplier networks if further performance improvement is to be realized within the sector. Journal: Construction Management and Economics Pages: 841-848 Issue: 8 Volume: 19 Year: 2001 Keywords: Subcontractors Supply Chain Management Partnering Integration Culture, X-DOI: 10.1080/01446190110089727 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110089727 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:19:y:2001:i:8:p:841-848 Template-Type: ReDIF-Article 1.0 Author-Name: Milan Radosavljevic Author-X-Name-First: Milan Author-X-Name-Last: Radosavljevic Author-Name: R. Malcolm Author-X-Name-First: R. Author-X-Name-Last: Malcolm Author-Name: W. Horner Author-X-Name-First: W. Author-X-Name-Last: Horner Title: The evidence of complex variability in construction labour productivity Abstract: The complex variability of the 12 construction labour productivity data sets has been examined by analysing the central moments of tendency, and applying the Kolmogorov-Smirnov and Anderson-Darling tests of normality. The results consistently show that the productivity is not normally distributed. In addition, undefined variance causes a failure of the central limit theorem, thus indicating that some basic statistical diagnostics like correlation coefficients and t statistics may give misleading results and are not applicable. A brief comparison with volatility studies in econometrics has revealed surprising similarity with Pareto distributions, which can model undefined or infinite variance. Such distributions are typical of chaotic systems like the logistic equation, whose properties also are described briefly. Therefore, it is suggested that future research should be focused on studying the applicability of chaos theory to construction labour. Journal: Construction Management and Economics Pages: 3-12 Issue: 1 Volume: 20 Year: 2002 Keywords: Construction, Labour Productivity, Normal Distribution, Tests, Chaos, X-DOI: 10.1080/01446190110098961 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110098961 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:1:p:3-12 Template-Type: ReDIF-Article 1.0 Author-Name: A. B. Idrus Author-X-Name-First: A. B. Author-X-Name-Last: Idrus Author-Name: J. B. Newman Author-X-Name-First: J. B. Author-X-Name-Last: Newman Title: Construction related factors influencing the choice of concrete floor systems Abstract: Designers have a wide choice of concrete floor systems for their buildings. They can choose from three basic types available: in situ, precast or hybrid construction. A survey was conducted within the UK construction industry to investigate, in particular, the construction related factors influencing the choice of concrete floor systems. The data collected were subjected to frequency and severity index analyses, Kendall's concordance test and the chi-squared tests to produce a rank ordering of 12 construction related factors. Five factors were identified as being the most important, namely 'appropriateness of use', 'cost', 'constructability', 'speed' and 'health and safety'. These five factors reflect current industry emphasis, and therefore could be adopted as the principal criteria for evaluating and selecting concrete floor systems during the design stage. They could also be used as assessment criteria for developing future systems. Journal: Construction Management and Economics Pages: 13-19 Issue: 1 Volume: 20 Year: 2002 Keywords: Concrete Floors, Frame Construction, Selection Factors, X-DOI: 10.1080/01446190110101218 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110101218 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:1:p:13-19 Template-Type: ReDIF-Article 1.0 Author-Name: Eva Sterner Author-X-Name-First: Eva Author-X-Name-Last: Sterner Title: 'Green procurement' of buildings: a study of Swedish clients' considerations Abstract: The results of a survey show that both public and private building clients in Sweden, to varying extents, include environmental requirements in their procurement documents. The requirements identified have been classified into six categories primarily related to building and demolition waste, building material, contractors' environmental work, ecological aspects, construction work and other. One conclusion is that requirements regarding the separation of waste and a contractor's environmental policy are considered important, since they are stipulated in the majority of projects. Another finding is that requirements related to operation and especially to energy use are not considered sufficiently. Structured interviews were conducted with three of the clients who at that time of the survey had developed the most complete procurement documents with regard to environmental requirements. The aim of the interviews was to investigate how the stipulation of requirements, the evaluation of environmental aspects and the verification of environmental requirements were carried out. The conclusion drawn is that Swedish clients find the stipulation of requirements relatively uncomplicated, but find the evaluation of environmental impact, mainly related to selection of materials, problematic due to inadequate evaluation models. Journal: Construction Management and Economics Pages: 21-30 Issue: 1 Volume: 20 Year: 2002 Keywords: Construction, Environmental Requirement, Sustainable Construction, Procurement, X-DOI: 10.1080/01446190110093560 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110093560 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:1:p:21-30 Template-Type: ReDIF-Article 1.0 Author-Name: Derek Walker Author-X-Name-First: Derek Author-X-Name-Last: Walker Author-Name: Yue Shen Author-X-Name-First: Yue Author-X-Name-Last: Shen Title: Project understanding, planning, flexibility of management action and construction time performance: two Australian case studies Abstract: Construction time performance (CTP) and flexibility in approaches to project time planning have been shown to be significantly associated. This raises interesting questions about how effective planning and control to facilitate flexibility in overcoming unexpected problems may be achieved. Case study data were used to explore links between planning and flexibility. This paper reports upon a recent study of two highly complex projects, a mental and forensic health hospital and a very large freeway/bridge/tunnel urban infrastructure project. The authors investigated planning flexibility using a framework of project team understanding and knowledge transfer to provide a model that contributes to our understanding of mechanisms and drivers that delivers flexible behaviour that may affect CTP. We conclude that both ability, supported by organizational and team competence, and commitment to explore construction method options in a flexible manner, i.e. responding to unanticipated problems, are necessary to facilitate good construction time performance. Journal: Construction Management and Economics Pages: 31-44 Issue: 1 Volume: 20 Year: 2002 Keywords: Construction Time Performance, Construction Planning, Agility, Flexibility, Project Complexity, Case Study, X-DOI: 10.1080/01446190110089691 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110089691 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:1:p:31-44 Template-Type: ReDIF-Article 1.0 Author-Name: M. Motiar Rahman Author-X-Name-First: M. Motiar Author-X-Name-Last: Rahman Author-Name: Mohan Kumaraswamy Author-X-Name-First: Mohan Author-X-Name-Last: Kumaraswamy Title: Joint risk management through transactionally efficient relational contracting Abstract: The appropriate contracting method and the contract documents for any construction project depend on the nature of the project, but an appropriate contracting method coupled with clear and equitable contract documents do not by themselves ensure project success where people work together in the face of uncertainty and complexity with diverse interests and conflicting agendas. The attitudes of the contracting parties and the co-operative relationships among the project participants are important for successful project delivery. These are examined in the light of transaction cost economics and relational contracting (RC) principles. It is found that RC may well be a useful route towards reduced transaction costs, while also fostering co-operative relationships and better teamwork that in turn facilitate joint risk management (JRM). The usefulness of the latter is reinforced by relevant observations from a recent Hong Kong-based survey, followed by a case study in Mainland China. A basic model is conceptualized for improved project delivery via JRM. This is also seen to be reinforceable by further transactional efficiencies that can be achieved through other RC-based approaches, such as partnering or alliancing. Journal: Construction Management and Economics Pages: 45-54 Issue: 1 Volume: 20 Year: 2002 Keywords: Co-OPERATIVE Teamwork, Joint Risk Management, Project Delivery, Relational Contracting, Transaction Cost Economics, X-DOI: 10.1080/01446190110089682 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110089682 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:1:p:45-54 Template-Type: ReDIF-Article 1.0 Author-Name: Huan Neng Chiu Author-X-Name-First: Huan Neng Author-X-Name-Last: Chiu Author-Name: Deng Maw Tsai Author-X-Name-First: Deng Maw Author-X-Name-Last: Tsai Title: An efficient search procedure for the resource-constrained multi-project scheduling problem with discounted cash flows Abstract: The main purposes of this study are to incorporate both the project delay penalty and early completion bonus into the objective function of the resource-constrained multi-project scheduling problem with discounted cash flows (RCMPSP-DCF) and to develop an efficient heuristic search scheduling rule. The effectiveness of the proposed heuristic rule is evaluated by comparing it with the optimal solution obtained by the optimal model for 42 small-scale problems. The result indicates that the solution obtained using the proposed heuristic rule is very close to the optimal solution, and that the proposed heuristic rule provides significant savings in computation time. Moreover, the proposed heuristic rule is also compared with four existing heuristic rules based on an experiment involving the single-project and multi-project scheduling problems. The results indicate that the proposed heuristic rule is superior to the four existing rules under the performance criteria of the average total project net present value and the average total project delay. In addition, the number of times that the proposed heuristic rule can obtain the best solution is also far more than that of any other rule considered in this paper under the two aforementioned performance criteria. Furthermore, this study has found that the performance of a heuristic scheduling rule is significantly affected by the number of projects. A rule that can lower the total project delay to the minimum is also able to maxi5 mize the total project net present value. Journal: Construction Management and Economics Pages: 55-66 Issue: 1 Volume: 20 Year: 2002 Keywords: Multi-PROJECT Scheduling, Project Management, Resource Constraints, Net Present Value, Heuristic Rules, X-DOI: 10.1080/01446190110089718 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110089718 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:1:p:55-66 Template-Type: ReDIF-Article 1.0 Author-Name: Derek Drew Author-X-Name-First: Derek Author-X-Name-Last: Drew Author-Name: Sandy Tang Author-X-Name-First: Sandy Author-X-Name-Last: Tang Author-Name: H. P. Lo Author-X-Name-First: H. P. Author-X-Name-Last: Lo Title: Developing a tendering strategy in two-envelope fee tendering based on technical score-fee variability Abstract: Consultants, in competing for work through two-envelope fee tendering, have been urged to consider variability differences between fees and technical scores, since the criterion with the greatest variability will influence which consultant is awarded the contract. Fee and technical score variability arising from different client fee tendering competitions is analysed in this paper, and a method proposed for determining whether a particular client's two-envelope fee tendering competition is likely to be dominated in terms of technical score or fee. Such information should be useful to consultants, as part of their bidding strategy, in deciding whether to aim for a higher technical score or submit a lower fee. Standard deviation is used to measure fee and technical score variability. Fee and technical score standard deviations are determined for each tendering competition, expressed as a ratio and aggregated over a series of competitions. A technical score-fee standard deviation ratio approximately equal to unity indicates that for future competitions consultants should adopt a balanced bidding strategy in putting equal emphasis on fee and technical score. A smaller ratio indicates that consultants should adopt a 'low fee' strategy whereas a larger ratio shows that consultants should adopt a 'high technical score' strategy. Fee tendering data from two large Hong Kong public sector clients were analysed. Fees were found to dominate the vast majority of tendering competitions, thereby indicating that consultants would be wise to adopt a low fee strategy in future competitions. Journal: Construction Management and Economics Pages: 67-81 Issue: 1 Volume: 20 Year: 2002 Keywords: Bidding, Consultant, Strategy, Technical Score, Tendering, X-DOI: 10.1080/01446190110096918 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110096918 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:1:p:67-81 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Raftery curve construction for tender price forecasts Abstract: John Raftery (1993), in his Inaugural Lecture at the University of Greenwich, suggested that project cost estimates be presented in the form of cumulative probability functions (termed here 'Raftery curves') rather than the current practice of single-point estimates. This paper describes a method for the empirical construction of Raftery curves for tender price forecasts, which then is applied to ten previously published data sets gathered throughout the world. In comparing the resulting curves, the most consistent feature is shown to be the shift associated with to the number of bidders entering bids for contracts. This is examined both in terms of bias and consistency. Contrary to some previous studies, no evidence is found of any trends related to the value size of projects. Journal: Construction Management and Economics Pages: 83-89 Issue: 1 Volume: 20 Year: 2002 Keywords: Cost, Time, Forecasting, Probability, Bidders, Range Estimates, X-DOI: 10.1080/01446190110093551 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110093551 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:1:p:83-89 Template-Type: ReDIF-Article 1.0 Author-Name: M. Loosemore Author-X-Name-First: M. Author-X-Name-Last: Loosemore Author-Name: D. W. Chau Author-X-Name-First: D. W. Author-X-Name-Last: Chau Title: Racial discrimination towards Asian operatives in the Australian construction industry Abstract: This paper investigates racial discrimination towards Asian operatives in the Australian construction industry. It explores the extent of this discrimination, the form it is taking, the impact it is having and how it is being managed. The paper reveals an assimilationist culture which largely ignores the needs of ethnic minority groups and fails to harness the positive attributes of multiculturalism. Ironically, in comparison with other industries, the construction industry is relatively well placed to benefit from cultural diversity, and a number of suggestions are made to help companies achieve this. These suggestions are of value to managers in other countries because racism is not a problem that is unique to the Australian construction industry. Journal: Construction Management and Economics Pages: 91-102 Issue: 1 Volume: 20 Year: 2002 Keywords: Racism, Discrimination, Asian, Culture, Diversity, Behaviour, Australia, X-DOI: 10.1080/01446190110090996 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110090996 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:1:p:91-102 Template-Type: ReDIF-Article 1.0 Author-Name: Graham Winch Author-X-Name-First: Graham Author-X-Name-Last: Winch Title: Book reviews Abstract: Journal: Construction Management and Economics Pages: 103-104 Issue: 1 Volume: 20 Year: 2002 X-DOI: 10.1080/01446190110091003 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110091003 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:1:p:103-104 Template-Type: ReDIF-Article 1.0 Author-Name: Job De Haan Author-X-Name-First: Job Author-X-Name-Last: De Haan Author-Name: Hans Voordijk Author-X-Name-First: Hans Author-X-Name-Last: Voordijk Author-Name: Geert-Jan Joosten Author-X-Name-First: Geert-Jan Author-X-Name-Last: Joosten Title: Market strategies and core capabilities in the building industry Abstract: The objective of this study is to show that the core competence approach has validity when applied to construction. The focus is on the analysis of the fit between market strategies of firms in the building industry and their core capabilities. Certain strategies require specific core capabilities and key external and internal conditions supporting these capabilities. The resource-based approach focuses on the conditions in a firm, the internal capabilities, and supports a core capability that is demanded. The network literature will be related to external conditions that support a core capability of a firm active in a certain market. In a multiple case study, firms are analysed that are involved in different stages of the building process. The case studies demonstrate firms with consistent patterns of market strategies, core capabilities, and supporting internal and external conditions. The specific core capability of the firm under investigation determines the types of external and internal conditions that are critical. Journal: Construction Management and Economics Pages: 109-118 Issue: 2 Volume: 20 Year: 2002 Keywords: Core Capability, Construction, Systems Approach, X-DOI: 10.1080/01446190110108662 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110108662 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:2:p:109-118 Template-Type: ReDIF-Article 1.0 Author-Name: Tien Foo Sing Author-X-Name-First: Tien Foo Author-X-Name-Last: Sing Title: Time to build options in construction processes Abstract: Time to build is a very important factor in a real estate development venture. Delay in completion of a project not only affects the financing costs and the rental revenue but also it may, on a more strategic note, determine the success or failure of a project. A time to build option model consisting of a stochastic rate of completion and a stochastic net project payoff is applied to the sequential construction process of a large scale construction project. The results of the sensitivity analysis show that the optimal payoff value, that triggers the exercise of the option to invest at a maximum rate, increases positively with the increases in cash flow volatility, input cost uncertainty, excess asset return per unit risk and maximum rate of investment. However, it has a negative relationship with the rental yield. In a case study involving a commercial project, the premium for hedging the payoff risks by pre-leasing a project was estimated at 11.29%, whereas the additional cost incurred for shielding a project against input cost risks in a design and build contract was estimated at 7.80%, where each is given as a percentage of the total construction costs. Journal: Construction Management and Economics Pages: 119-130 Issue: 2 Volume: 20 Year: 2002 Keywords: Time To Build Option, Project Payoff Uncertainty, Input Cost Uncertainty, Sequential Investment, Option Premium, X-DOI: 10.1080/0144619011010209 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619011010209 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:2:p:119-130 Template-Type: ReDIF-Article 1.0 Author-Name: Sou-Sen Leu Author-X-Name-First: Sou-Sen Author-X-Name-Last: Leu Author-Name: Tzung-Heng Hung Author-X-Name-First: Tzung-Heng Author-X-Name-Last: Hung Title: A genetic algorithm-based optimal resource-constrained scheduling simulation model Abstract: Resources for construction activities are limited in the real construction world so that scheduling must include resource allocation. Furthermore, activity duration is uncertain due to the variation in the outside environment, such as resource availabilities, weather, space congestion, etc. A new optimal resource-constrained construction scheduling simulation model is proposed in this paper, in which the effects of both uncertain activity duration and resource constraints are taken into account. Probability distribution is used to model the uncertainties of activity duration. An optimal schedule simulation model is then established in which a genetic algorithm-based search technique is adopted to search for the probabilistic optimal project duration under resource constraints. The model can effectively provide the optimal averaged project duration, cumulative project completion probabilities and the impact of influence factors on the probabilistic resource-constrained scheduling problem. Journal: Construction Management and Economics Pages: 131-141 Issue: 2 Volume: 20 Year: 2002 Keywords: Resource Allocation, Genetic Algorithms, Scheduling, Construction Simulation, X-DOI: 10.1080/01446190110109148 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110109148 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:2:p:131-141 Template-Type: ReDIF-Article 1.0 Author-Name: S. Ping Ho Author-X-Name-First: S. Ping Author-X-Name-Last: Ho Author-Name: Liang Liu Author-X-Name-First: Liang Author-X-Name-Last: Liu Title: An option pricing-based model for evaluating the financial viability of privatized infrastructure projects Abstract: Privatized infrastructure projects have to demonstrate their financial and technical viability before they are undertaken. Although it is relatively easy to demonstrate the technical viability of an infrastructure project, the evaluation of the financial viability of a privatized infrastructure project is complex and challenging, mainly because of the uncertainties involved due to the project's scale, long concession period and complexity. Traditional methods, such as net present value (NPV) analysis, fall short in reflecting the characteristics of privatized infrastructure projects and the risks involved. This paper presents an option pricing based model, the BOT option valuation (BOT-OV) model, for evaluating the financial viability of a privatized infrastructure project. This quantitative model considers the project characteristics explicitly and evaluates the project from the perspectives of the project promoter and of the government when the project is under bankruptcy risk. Moreover, the model can evaluate the impact of the government guarantee and the developer negotiation option on the project financial viability. Journal: Construction Management and Economics Pages: 143-156 Issue: 2 Volume: 20 Year: 2002 Keywords: Privatized Infrastructure, Option Pricing Theory, Financial Decision-MAKING, Investment Evaluation, X-DOI: 10.1080/01446190110110533 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110110533 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:2:p:143-156 Template-Type: ReDIF-Article 1.0 Author-Name: Derek Drew Author-X-Name-First: Derek Author-X-Name-Last: Drew Author-Name: Po Yin Lai Author-X-Name-First: Po Yin Author-X-Name-Last: Lai Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Author-Name: H. P. Lo Author-X-Name-First: H. P. Author-X-Name-Last: Lo Title: Correcting the fee-technical score variability imbalance in two-envelope fee tendering Abstract: Consultants' fees and technical submissions in two-envelope fee tendering are usually converted to scores. The fee scores and technical (quality) scores are then multiplied by predetermined weightings and aggregated. To preserve the desired influence of the predetermined weightings, the fee score and technical score variability differences need to be balanced, otherwise, when aggregated, one variable will end up dominating the other variable. Currently, such adjustments are not undertaken in the popular two-envelope fee tendering models. It seems that in many cases the consultant selection becomes biased in favour of the lowest fee rather than the quality. Important influences that contribute to the fee-technical score variability imbalance include suicidal fees and non-serious fees (which increases fee variability) and similar size consultant firms with similar experience and workload levels offering similar, if not identical, services (which reduces technical score variability). This paper offers four alternative approaches to the correction of the fee-technical score variability imbalance. If the client is able to distinguish between suicidal, serious and non-serious fees, then it is suggested that first the consultants submitting suicidal and non-serious fees should be disregarded. A normalization approach (in which the consultant's technical and fee scores are re-scaled to fall between unity and zero) should then be applied. If the client is unable or unwilling to distinguish between suicidal, serious and non-serious fees then aggregating on the basis of the consultants fee and technical score rankings appears to be the best method out of the three remaining approaches. Journal: Construction Management and Economics Pages: 157-166 Issue: 2 Volume: 20 Year: 2002 Keywords: Bidding, Consultant, Technical Score, Tendering, Two-ENVELOPE, Variability, X-DOI: 10.1080/01446190110098970 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110098970 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:2:p:157-166 Template-Type: ReDIF-Article 1.0 Author-Name: Davide Nicolini Author-X-Name-First: Davide Author-X-Name-Last: Nicolini Title: In search of 'project chemistry' Abstract: The paper aims to provide a language and a conceptual toolkit to deepen our understanding of the impact of relational and social issues on the success of construction projects. Building on several streams of literature, as well as on individual and group interviews with construction practitioners, the paper develops the notion of 'project chemistry' as a way of capturing some of the relational and behavioural dimensions and factors that may affect project success and effectiveness in construction. The paper introduces a provisional theoretical framework that (a) identifies a number of external and project level determinants of 'project chemistry', (b) suggests ways of measuring how and how well people interact, perceive, and work together in a project, and (c) relates these issues to broader economic and technical factors. The paper concludes with some reflections on the implications and challenges for future research and management practices raised by the notion of 'project chemistry'. Journal: Construction Management and Economics Pages: 167-177 Issue: 2 Volume: 20 Year: 2002 Keywords: Project Management, Project Success Factors, Human Resource Management, Behavioural Aspects, X-DOI: 10.1080/01446190110101217 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110101217 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:2:p:167-177 Template-Type: ReDIF-Article 1.0 Author-Name: Raymond Aoieong Author-X-Name-First: Raymond Author-X-Name-Last: Aoieong Author-Name: S. L. Tang Author-X-Name-First: S. L. Author-X-Name-Last: Tang Author-Name: Syed Ahmed Author-X-Name-First: Syed Author-X-Name-Last: Ahmed Title: A process approach in measuring quality costs of construction projects: model development Abstract: One of the most effective tools for evaluating the success of a quality management programme is the measurement of quality costs (prevention, appraisal and failure costs). The application of the concept of quality costs originated in the manufacturing industry in the early 1950s. As increasing attention has been given to improving the overall quality in the construction process since the early 1980s, the application of total quality management (TQM) practices in the construction industry has gained much popularity. A systematic approach is needed for measuring quality costs, especially in the construction industry, due to the great number and complexity of activities involved in a typical project. This paper describes how a simple methodology can be used to capture quality costs in construction projects. Pre-existing models for capturing construction quality costs, by Davis, by Abdul-Rahman, by Low and Yeo and by others, recognize quality cost components but do not address the causes or sources of unwanted deviations. This paper proposes an alternative approach, based on the process cost model and in conformance with BS6143 (1992), which is thought to better facilitate the fundamental goal of TQM, i.e. continual process improvement. A number of professionals involved in construction quality management were interviewed and responded favourably to the practicality of the proposed framework in the construction context. Journal: Construction Management and Economics Pages: 179-192 Issue: 2 Volume: 20 Year: 2002 Keywords: Construction, Quality Management, Quality Costs, Process Cost Model, X-DOI: 10.1080/01446190110109157 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110109157 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:2:p:179-192 Template-Type: ReDIF-Article 1.0 Author-Name: Khaled El-Rayes Author-X-Name-First: Khaled Author-X-Name-Last: El-Rayes Author-Name: Ramaneetharan Ramanathan Author-X-Name-First: Ramaneetharan Author-X-Name-Last: Ramanathan Author-Name: Osama Moselhi Author-X-Name-First: Osama Author-X-Name-Last: Moselhi Title: An object-oriented model for planning and control of housing construction Abstract: A practical object-oriented model for the planning and control of housing construction is presented that can generate efficient schedules and determine the time and cost performance of a housing project at three levels: (i) entire project, (ii) particular housing unit and (iii) an individual subcontractor. The model comprises five major components: (1) input module, (2) scheduling module, (3) database module, (4) control module and (5) reports module, and incorporates 18 classes that are designed to address the main requirements in planning and control of housing construction. The model is implemented as a user-friendly prototype software system using Visual C++ 6.0 and Microsoft Foundation Class (MFC). The prototype software is named 'Residential Planner', and runs in Windows 2000 and NT. An example of an application is analysed to illus8 trate the use of the developed model and demonstrate its practical features. Journal: Construction Management and Economics Pages: 201-210 Issue: 3 Volume: 20 Year: 2002 Keywords: Housing Construction, Repetitive Construction, Object-ORIENTED Modelling, Planning And Scheduling, Construction Control, X-DOI: 10.1080/01446190110115312 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110115312 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:3:p:201-210 Template-Type: ReDIF-Article 1.0 Author-Name: Firuzan Yasamis Author-X-Name-First: Firuzan Author-X-Name-Last: Yasamis Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Author-Name: Jamshid Mohammadi Author-X-Name-First: Jamshid Author-X-Name-Last: Mohammadi Title: Assessing contractor quality performance Abstract: This paper proposes a radical change in industry practice that will improve the quality of the construction process and the levels of customer satisfaction derived from it by evaluating the quality performance of the contractor. An alternative theory is developed of what constitutes quality, client satisfaction, performance, and their interrelationships in the context of the construction industry. It should be noted here that the term construction client includes both the owner (i.e. the agency or organization funding the project) and the end-user of the construction (i.e. the general public). A comprehensive view of construction quality is proposed that deals with both the service (as received by the owner) and product (as received by the end-user) aspects of the construction project as well as the corporate quality culture. Such a dissection of construction activity facilitates developing strategies to define, operationalize, measure and improve construction quality. A frame4 work for the assessment of a contractor's quality performance is established. This involves gathering a list of contractor quality performance (CQP) indicators that are derived from various quality-related practices of the contractor at the corporate and project level. Finally, a contractor quality performance (CQP) evaluation model is introduced that can be used in a contractor prequalification and/or selection system. The CQP indicators are operationalized within the theoretical framework of the CQP evaluation model. Journal: Construction Management and Economics Pages: 211-223 Issue: 3 Volume: 20 Year: 2002 Keywords: Contractor Quality Performance, Quality Control, Quality Assurance, Prequalification, Contractor Selection, X-DOI: 10.1080/01446190110113693 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110113693 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:3:p:211-223 Template-Type: ReDIF-Article 1.0 Author-Name: Trefor Williams Author-X-Name-First: Trefor Author-X-Name-Last: Williams Title: Predicting completed project cost using bidding data Abstract: Neural network and regression models have been developed to predict the completed cost of competitively bid highway projects constructed by the New Jersey Department of Transportation. Bid information was studied for inclusion as inputs to the models. Data studied included the low bid, median bid, standard devi9 ation of the bids, expected project duration and the number of bids. A natural log transformation of the data was found to improve the linear relationship between the low bid and completed cost. The stepwise regression procedure was applied, and yielded the best performing predictive model. This regression model used only the natural log of the low bid as independent variable to predict the natural log of the completed cost. Radial basis neural networks were also constructed to predict the final cost. The best performing regres4 sion model produced superior predictions to the best performing neural network model. Hybrid models that used a regression model prediction as an input to a neural network were also studied and were found to also produce reasonable predictions. The calculated models produced good predictions of the completed project cost, but were found to be deficient in predicting very large cost increases. Simple models using the natural log of the low bid as input produced the best results. From the analysis it may be concluded that additional information about the variability of the bids submitted does not provide useful information for predicting the final project outcome. Journal: Construction Management and Economics Pages: 225-235 Issue: 3 Volume: 20 Year: 2002 Keywords: Bidding, Project Costs, Neural Networks, Regression Analysis, X-DOI: 10.1080/01446190110112838 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110112838 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:3:p:225-235 Template-Type: ReDIF-Article 1.0 Author-Name: M. Anson Author-X-Name-First: M. Author-X-Name-Last: Anson Author-Name: S. L. Tang Author-X-Name-First: S. L. Author-X-Name-Last: Tang Author-Name: K. C. Ying Author-X-Name-First: K. C. Author-X-Name-Last: Ying Title: Measurement of the performance of ready mixed concreting resources as data for system simulation Abstract: Concrete is a very important construction industry material, and this is especially true in Hong Kong. The efficient organization of the supply of concrete from ready mixed concrete plants is beneficial to both concrete companies and contractors. It is also essential for an efficient construction industry, since a very high propor1 tion of the in situ concrete in Hong Kong is supplied ready mixed from an off-site plant. Whether concrete companies in Hong Kong are using their resources well and are able to satisfactorily match the timing of their deliveries to construction site needs are questions discussed in this paper, based on data collected by the authors. The data are planned for use in validating a simulation model of ready mixed concrete plant operations in Hong Kong. The third author spent 20 weeks in 1999-2000 at concrete batching plants in Hong Kong, studying their operations. Data on a sample of 15 typical operational days at four plants, which included 295 pours on sites and 1677 truckmixer trips, are presented. Truckmixer journey times for delivering concrete and journey times for returning to plants and their distributions have been found. Queuing statistics for truckmixers on site waiting to be unloaded, placing times when unloading concrete, washing out and waiting times on sites after unloading, and delays in the continuous delivery of concrete are also described. Service has been studied in terms of the matching achieved between site delivery timing require1 ments and the need to use truckmixers efficiently. For the 295 pours, the relationship is shown between gaps in the supply of concrete to site and the extent to which truckmixers are bunched in a queue on site. Matching was found to be good for only 17% of the 295 pours, the variability in service received by different sites is considerable, and the importance of studying the truckmixer scheduling problem is highlighted, so that this variability might be reduced and extreme cases eliminated. Journal: Construction Management and Economics Pages: 237-250 Issue: 3 Volume: 20 Year: 2002 Keywords: Concrete, Ready Mixed Concrete, Concrete Plant, Truckmixers, Simulation, X-DOI: 10.1080/01446190210121297 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210121297 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:3:p:237-250 Template-Type: ReDIF-Article 1.0 Author-Name: Richard Kirkham Author-X-Name-First: Richard Author-X-Name-Last: Kirkham Author-Name: A. Halim Boussabaine Author-X-Name-First: A. Halim Author-X-Name-Last: Boussabaine Author-Name: Belal Awwad Author-X-Name-First: Belal Author-X-Name-Last: Awwad Title: Probability distributions of facilities management costs for whole life cycle costing in acute care NHS hospital buildings Abstract: Whole life cycle costing (WLCC) can provide a valuable insight into the economic efficiency of National Health Service (NHS) acute care hospital buildings. The costs of the facilities management function form an integral part of that process. However, the nature of facilities management cost data collated by NHS Estates informs the analyst little about the relationship between the physical characteristics of hospital buildings and the facilities management costs. The data can only be used to benchmark trusts total facilities management spending, but what the NHS now requires is a way of being able to model the facilities management costs for particular buildings. The purpose of this paper is to demonstrate, using a case study, a methodology for modelling stochastically the facilities management costs in NHS acute care hospital buildings. The data used in this research were obtained from NHS Estates on the facilities management costs of over 450 acute care NHS Trusts in England and Wales. The data were analysed to obtain the parameters of the theoretical distributions that best describe the facilities management costs for a ward block building in a large university acute care teaching hospital. The accuracy of these distributions was then validated using various hypotheses and goodness-of-fit tests. The result of this work provides analysts with a framework whereby the facilities management costs in acute care hospital buildings can be modelled as stochastic assumptions in the modelling of WLCC. The paper also reveals that for acute care hospital buildings with a similar gross floor area to that of the building used in the case study (that is approximately 20% of the entire acute care hospital estate), the underlying distribution of costs is likely to belong to the loglogistic distribution Journal: Construction Management and Economics Pages: 251-261 Issue: 3 Volume: 20 Year: 2002 Keywords: Whole Life Cycle Costing, Probability Density Functions, Facilities Management Costs, National Health Service, Acute Care Hospital Buildings, X-DOI: 10.1080/01446190110113701 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110113701 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:3:p:251-261 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Title: The effect of first aid training on Australian construction workers' occupational health and safety knowledge and motivation to avoid work-related injury or illness Abstract: A 24 week experiment was conducted to assess the effect of first aid training on small business construction industry participants' understanding of occupational health and safety (OHS) risks and risk controls and their motivation to avoid occupational injuries and illnesses. Participants' subjective understandings of OHS risks, options for risk control and motivation to control OHS risks were explored during in-depth interviews before and after receipt of first aid training. Interview data revealed that, other than raising awareness of the risk of infectious diseases, the first aid training did not increase participants' understandings of the nature or severity of specific OHS risks relevant to their work. First aid training appeared to reduce participants' 'self-other' bias, making them more aware that their experience of OHS risks was not beyond their control but that their own behaviour was also an important factor in the avoidance of occupational injury and illness. First aid training also appeared to reduce participants' willingness to accept prevailing levels of OHS risk. Participants' understandings of methods by which OHS risks can be controlled were unchanged by the first aid training and are limited to individual controls. First aid training did appear to increase participants' perception of the probability that they would suffer a work related injury or illness and they also expressed greater concern about taking risks at work after receiving first aid training. It therefore appears that first aid training enhanced participants' motivation to avoid occupational injuries and illnesses. Journal: Construction Management and Economics Pages: 263-273 Issue: 3 Volume: 20 Year: 2002 Keywords: First Aid Training, Occupational Health And Safety, Risk Awareness, Risk Control, Motivation, Construc, Tion, Small Business, X-DOI: 10.1080/01446190110117617 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110117617 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:3:p:263-273 Template-Type: ReDIF-Article 1.0 Author-Name: Chen-Yu Chang Author-X-Name-First: Chen-Yu Author-X-Name-Last: Chang Author-Name: Graham Ive Author-X-Name-First: Graham Author-X-Name-Last: Ive Title: Rethinking the multi-attribute utility approach based procurement route selection technique Abstract: The multi-attribute utility approach (MAUA) provides a possibility of transforming subjective perception or evaluation into objective decision principles. However, as applied to procurement system selection, the advice derived from this approach can be problematical, if the nature of the procurement systems has not been examined carefully. The major weaknesses of the MAUA as applied in this field lie in its selection of priority variables and in some association of procurement routes with priority variables. This paper uses a transac2 tion cost perspective, in a setting of incomplete contracting, to develop these comments. Journal: Construction Management and Economics Pages: 275-284 Issue: 3 Volume: 20 Year: 2002 Keywords: Multi-ATTRIBUTE Utility Approach, Procurement Route, Incomplete Contracting, Transaction Costs, X-DOI: 10.1080/01446190110117608 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190110117608 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:3:p:275-284 Template-Type: ReDIF-Article 1.0 Author-Name: S. Thomas Ng Author-X-Name-First: S. Thomas Author-X-Name-Last: Ng Author-Name: Duc Thanh Luu Author-X-Name-First: Duc Thanh Author-X-Name-Last: Luu Author-Name: Swee Eng Chen Author-X-Name-First: Swee Eng Author-X-Name-Last: Chen Author-Name: Ka Chi Lam Author-X-Name-First: Ka Chi Author-X-Name-Last: Lam Title: Fuzzy membership functions of procurement selection criteria Abstract: Many researchers have advocated the development and application of a systematic approach to the selection of procurement processes. Different procurement selection models aimed at improving the decision making process have been proposed. These models generally fail to address the fuzziness of selection criteria used for procurement selection. The aim of this paper is to establish the fuzzy membership function of procurement selection criteria through an empirical study conducted in Australia. Seven procurement selection criteria were considered fuzzy in nature. They are speed, complexity, flexibility, responsibility, quality level, risk allocation, and price competition. The fuzzy membership functions for each of these seven fuzzy procurement selection criteria were derived through a modified horizontal approach. Journal: Construction Management and Economics Pages: 285-296 Issue: 3 Volume: 20 Year: 2002 Keywords: Procurement, Selection Criteria, Fuzzy Membership Function, X-DOI: 10.1080/01446190210121288 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210121288 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:3:p:285-296 Template-Type: ReDIF-Article 1.0 Author-Name: I. M. Shohet Author-X-Name-First: I. M. Author-X-Name-Last: Shohet Author-Name: M. Puterman Author-X-Name-First: M. Author-X-Name-Last: Puterman Author-Name: E. Gilboa Author-X-Name-First: E. Author-X-Name-Last: Gilboa Title: Deterioration patterns of building cladding components for maintenance management Abstract: Increasing demands are made on maintenance programmes to provide tools that will support maintenance planning. Among of the most important parameters affecting the efficiency of maintenance management are the precision and the reliability of the predicted service life (PSL) of building components. The main objective of this study was to develop a methodology for the establishment of databases listing deterioration patterns of building components based upon their actual condition. The methodology consists of four steps: (1) identification of failure patterns, (2) determination of the component performance (CP), (3) determination of the life expectancy of deterioration path (LEDP) and (4) evaluation of the predicted service life (PSL). The proposed methodology can be used for planning of maintenance activities, for evaluation of economic implications caused by intensive decay and for maintenance management. Journal: Construction Management and Economics Pages: 305-314 Issue: 4 Volume: 20 Year: 2002 Keywords: Maintenance Management, Deterioration, Predicted Service Life, Exterior Cladding, Performance, X-DOI: 10.1080/01446190210125563 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210125563 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:4:p:305-314 Template-Type: ReDIF-Article 1.0 Author-Name: Sevda Koraltan Author-X-Name-First: Sevda Author-X-Name-Last: Koraltan Author-Name: Attila Dikbas Author-X-Name-First: Attila Author-X-Name-Last: Dikbas Title: An assessment of the applicability of partnering in the Turkish construction sector Abstract: There are problems associated with the Turkish construction sector; some of these problems are implications of Government policy, restrictions imposed on public construction projects, bureaucratic procedures, contractual clauses incorporating unfair risk sharing and inadequacies in control mechanisms. Some problems can be attributed to inadequate technological knowhow, and/or lack of education and training incen1 tives in new technologies and management approaches. This paper presents findings from research that was aimed at investigating the applicability of partnering in the Turkish construction sector as an alternative approach in seeking solutions to some of the problems within this industry. The findings suggest that the partnering approach could help reduce some of the problems associated with the Turkish construction sector, although the implementation of this approach is likely to face complications, mainly in terms of cultural change requirements and the bureaucracies associated especially with the public construction process. The findings also suggest that if partnering were to be considered for Turkey, the private construction sector would offer more flexibility in the implementation of this approach, rather than reliance on the Government for the introduction of partnering into Turkey. Journal: Construction Management and Economics Pages: 315-321 Issue: 4 Volume: 20 Year: 2002 Keywords: Partnering, Procurement, Construction Trends, Organizational Development, Turkey, Construction Sector, X-DOI: 10.1080/01446190210125554 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210125554 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:4:p:315-321 Template-Type: ReDIF-Article 1.0 Author-Name: Mohammad Ammar Author-X-Name-First: Mohammad Author-X-Name-Last: Ammar Author-Name: Youssef Mohieldin Author-X-Name-First: Youssef Author-X-Name-Last: Mohieldin Title: Resource constrained project scheduling using simulation Abstract: Resource allocation is one of the most important issues of construction management. Two problems of resource allocation are of concern: resource levelling and resource scheduling. Traditionally, the resource scheduling problem is solved using either heuristic methods or optimization techniques. When heuristic methods are used, resource scheduling is treated as a subsequent problem for the CPM analysis. In this paper, the resource scheduling problem is handled using simulation, where logic dependence and resource availability limits are considered simultaneously during the time scheduling process. Simulation is applied to the resource scheduling problem at the project level. A simulation system called SIRBUS is used to schedule construction projects under resource constraints. Constant resource demand of activities is assumed, and the activity once started cannot be interrupted. Six example projects previously solved by different heuristic methods are re-solved using simulation. The results are compared with the latest heuristic models: current float technique and ranked positional weight method. In addition to the advantage that resource availability is considered during time scheduling as a starting point, which is an apparent feature of simulation, SIRBUS gives good results compared with existing heuristic methods. Journal: Construction Management and Economics Pages: 323-330 Issue: 4 Volume: 20 Year: 2002 Keywords: Construction Management, Resource Management, Resource Scheduling, Simulation, X-DOI: 10.1080/01446190210131098 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210131098 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:4:p:323-330 Template-Type: ReDIF-Article 1.0 Author-Name: Linda Tay Author-X-Name-First: Linda Author-X-Name-Last: Tay Author-Name: Neil Morgan Author-X-Name-First: Neil Author-X-Name-Last: Morgan Title: Antecedents and consequences of market orientation in chartered surveying firms Abstract: This study tests marketing theory concerning market orientation in the context of the chartered surveying industry. Using data collected in a mail survey from 179 UK general practice chartered surveying firms, it is found that firms with more risk tolerant senior managers and more formalized and specialized marketing organization structures have higher levels of market orientation. The data indicate also that market orientation positively impacts firms' business and marketing performance, and that this relationship is robust across different environments. Journal: Construction Management and Economics Pages: 331-341 Issue: 4 Volume: 20 Year: 2002 Keywords: Market Orientation, Management, Organization Structure, Business Performance, Surveying, X-DOI: 10.1080/01446190210123826 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210123826 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:4:p:331-341 Template-Type: ReDIF-Article 1.0 Author-Name: David Ford Author-X-Name-First: David Author-X-Name-Last: Ford Author-Name: Diane Lander Author-X-Name-First: Diane Author-X-Name-Last: Lander Author-Name: John Voyer Author-X-Name-First: John Author-X-Name-Last: Voyer Title: A real options approach to valuing strategic flexibility in uncertain construction projects Abstract: To maximize project value, managers of construction projects must recognize, plan for and strategically manage uncertainty. Current construction planning, estimating, and management practices regarding uncertainty can undervalue projects by failing to exploit opportunities to increase project value, as well as minimize risks. Dynamic uncertainties are described as project conditions that cannot be resolved adequately through improved description or planning for pre-project strategy selection. A real options approach is proposed for proactively using strategic flexibility to recognize and capture project values hidden in dynamic uncertainties. An example of a proposal for a toll road project demonstrates a method of valuing managerial flexibility to evaluate and select strategies. Impacts of real options in other domains, along with this example, are the basis for concluding that using a structured real options approach in construction management can increase returns through improved project planning and management. Potential impacts of the use of real options are discussed, and challenges in valuing real options in construction projects are identified as the basis for future research. Journal: Construction Management and Economics Pages: 343-351 Issue: 4 Volume: 20 Year: 2002 Keywords: Project Planning, Strategy, Risk Management, Real Options, Project Management, X-DOI: 10.1080/01446190210125572 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210125572 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:4:p:343-351 Template-Type: ReDIF-Article 1.0 Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Author-Name: Pirasak Sikangwan Author-X-Name-First: Pirasak Author-X-Name-Last: Sikangwan Author-Name: Onur Tokdemir Author-X-Name-First: Onur Author-X-Name-Last: Tokdemir Title: Scheduling system for high rise building construction Abstract: A computerized system to schedule high-rise building construction has been developed using line-of-balance technology assisted by an expert system. A review of the recent literature on the techniques available for scheduling and controlling construction projects of a repetitive nature shows that Gantt charts are inadequate, and that there are serious problems with using network methods in such circumstances. There is evidence that the construction of high rise buildings has a decidedly repetitive nature but differs in some respects from other repetitive projects such as pipelines or pavement construction. Two new concepts have been introduced into line-of-balance methodology to accommodate the special conditions encountered in high rise building construction. These two concepts, namely 'flexible' unit networks and 'multi-level' LOB diagrams have been coded into a scheduling module ('Lobplans'). A series of databases have been compiled regarding the productivity of resources. An expert system module (Lobex) has been developed to facilitate decision-making at network generation level. The scheduling module, the databases, and the expert system have been organized into an integrated system (Chriss) by means of communication and command routines that interface between the modules and the user input. A 16-storey building project has been used in testing Chriss' performance. The integrated system proved to be user friendly and reliable. Journal: Construction Management and Economics Pages: 353-364 Issue: 4 Volume: 20 Year: 2002 Keywords: Linear Scheduling Methods, Line-OF-BALANCE, Networks, High Rise Building Construction, Expert Systems, X-DOI: 10.1080/01446190210131647 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210131647 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:4:p:353-364 Template-Type: ReDIF-Article 1.0 Author-Name: Prapatpaow Awakul Author-X-Name-First: Prapatpaow Author-X-Name-Last: Awakul Author-Name: Stephen Ogunlana Author-X-Name-First: Stephen Author-X-Name-Last: Ogunlana Title: The effect of attitudinal differences on interface conflicts in large scale construction projects: a case study Abstract: Conflicts encountered in large scale construction projects occur in two categories: internal conflicts and interface conflicts. Internal conflicts are experienced among the project participants, whereas interface conflicts are between the construction project and groups outside the project. Many large scale construction projects often experience interface conflicts in the form of conflicting requirements from different social groups. This paper examines the attitudes of five groups of respondents on the factors leading to the interface conflicts experienced on the Yadana Natural Gas Pipeline Project (YNGPP) in Thailand as a case study. The study was conducted through questionnaire surveys of the five groups: the group affected by the project; the project participants; non-government organizations (NGOs) and interested organizations; academics and experts; and local government officials. The results show that these five groups have differences in attitudes towards the factors leading to the interface conflicts encountered on the project; and it is the differences in attitudes that generated the conflicts. The key variables were grouped into main categories and the degree of importance of each key factor leading to the interface conflicts was identified. Journal: Construction Management and Economics Pages: 365-377 Issue: 4 Volume: 20 Year: 2002 Keywords: Conflict, Attitudinal Differences, Project Management, Large Projects, Factor Analysis, X-DOI: 10.1080/01446190210133456 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210133456 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:4:p:365-377 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Li Author-X-Name-First: Helen Author-X-Name-Last: Li Author-Name: Qiping Shen Author-X-Name-First: Qiping Author-X-Name-Last: Shen Title: Supporting the decision-making process for sustainable housing Abstract: Wide acceptance of the concept of sustainable development has led to a demand for policies on sustainable housing. The issues of how sustainable housing can be measured or evaluated and how decision-making regarding sustainable housing can be facilitated are areas that require further research. This paper aims to introduce a conceptual approach in developing a decision-support tool for sustainable housing. An empirical decision-support model for sustainable housing indicators using fuzzy-set theory (SHIFT) is described, with particular focus on framing decision-making for multiple criteria or objectives. Journal: Construction Management and Economics Pages: 387-390 Issue: 5 Volume: 20 Year: 2002 Keywords: Sustainable Housing, Multicriteria Decision-MAKING, X-DOI: 10.1080/01446190210146812 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210146812 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:5:p:387-390 Template-Type: ReDIF-Article 1.0 Author-Name: Frank Schultmann Author-X-Name-First: Frank Author-X-Name-Last: Schultmann Author-Name: Otto Rentz Author-X-Name-First: Otto Author-X-Name-Last: Rentz Title: Scheduling of deconstruction projects under resource constraints Abstract: In many countries a large part of the building stock will have to be maintained, renovated, rehabilitated or even removed in the next few decades. Although profitability will be one of the major requirements to be met when these works are carried out, there will be more and more emphasis on the environmental requirements to be respected. To make the modernization of the building stock more efficient, dismantling with the aim of producing high quality recycling materials at reasonable costs is a promising approach. This paper presents an integrated approach to deconstruction site management that focuses on both economic and environmental goals. As a first step, material flow management aims at the closed-loop recycling of various construction materials. In a second step, resource constrained project planning models are used to evaluate strategies for optimized deconstruction site management. The approach offers high flexibility and can be adapted readily to different conditions. Results show that time and cost for deconstruction can be reduced by more than 50%, together with recycling quotas of more than 90%. Even when resources are strictly limited or when strong budget and time restrictions have to be respected, tremendous improvements in deconstruction site management can be achieved. Journal: Construction Management and Economics Pages: 391-401 Issue: 5 Volume: 20 Year: 2002 Keywords: Deconstruction, Optimization, Project Planning Models, Scheduling, X-DOI: 10.1080/01446190210135913 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210135913 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:5:p:391-401 Template-Type: ReDIF-Article 1.0 Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Author-Name: Edwi Fong Author-X-Name-First: Edwi Author-X-Name-Last: Fong Title: Preparations for ISO 9001:2000 - a study of ISO 9000:1994 certified construction firms Abstract: Many research studies have been completed on the effectiveness of ISO 9000:1994 in the construction industry. The new ISO 9001:2000 requires firms to have a completely different mindset about achieving quality. From merely compliance with requirements, firms who intend to obtain ISO 9001:2000 certification have to understand fully the new requirements and how they may 'fit' the new standards into their present quality management systems, instead of changing their original work procedures to suit the Standard's requirements. This study presents a survey of the preparation work undertaken by construction firms in Singapore in moving from ISO 9000:1994 to ISO 9001:2000. From the research findings, it was found that most firms are ready for the conversion to the new Standard with slight beefing up of their existing quality management systems. Journal: Construction Management and Economics Pages: 403-413 Issue: 5 Volume: 20 Year: 2002 Keywords: Quality, Construction Firms, Preparations, Transition, X-DOI: 10.1080/01446190210135922 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210135922 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:5:p:403-413 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Goodrum Author-X-Name-First: Paul Author-X-Name-Last: Goodrum Author-Name: Carl Haas Author-X-Name-First: Carl Author-X-Name-Last: Haas Author-Name: Robert Glover Author-X-Name-First: Robert Author-X-Name-Last: Glover Title: The divergence in aggregate and activity estimates of US construction productivity Abstract: Discrepancies exist between aggregate and activity productivity measurements in the US construction industry. Multiple studies using aggregate industry measures suggest that construction productivity has declined over the long term. A longstanding problem with the aggregate measures concerns the difficulty of controlling for inflation so as to accurately measure real output. As an alternative, average activity productivity, measured by individual work activities, indicates that construction productivity has increased over the same time period. Activity measurement data have been collected for 200 construction activities over a 22-year time period from commercial estimation manuals used by contractors and owners to estimate the cost and time requirements for construction. This paper examines the discrepancies between aggregate and activity measurements and suggests possible reasons for their existence. Journal: Construction Management and Economics Pages: 415-423 Issue: 5 Volume: 20 Year: 2002 Keywords: Labour, Productivity, Trends, Construction Industry, X-DOI: 10.1080/01446190210145868 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210145868 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:5:p:415-423 Template-Type: ReDIF-Article 1.0 Author-Name: Hong Xiao Author-X-Name-First: Hong Author-X-Name-Last: Xiao Author-Name: David Proverbs Author-X-Name-First: David Author-X-Name-Last: Proverbs Title: The performance of contractors in Japan, the UK and the USA: a comparative evaluation of construction cost Abstract: Globalization of the world economy demands that performance comparisons are undertaken at an international level. A new research protocol has been developed for comparing contractor performance internationally by combining the appropriate characteristics of two established approaches in order to balance the requirements of comparability and representativeness. This new approach is used to reveal some important international performance characteristics among Japanese, UK and US contractors. Building costs in the UK, when adjusted for exchange rate fluctuations, are significantly higher than those in Japan and the USA. Furthermore, cost certainty and client satisfaction are higher in Japan than in the UK, but there is no significant difference between Japan and the USA. Disparities in cost performance between the three countries are believed to originate from differences in the relationships between contractors and clients and also in the construction process. Journal: Construction Management and Economics Pages: 425-435 Issue: 5 Volume: 20 Year: 2002 Keywords: Construction Cost, Contractor Performance, Analysis Of Variance, X-DOI: 10.1080/01446190210145859 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210145859 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:5:p:425-435 Template-Type: ReDIF-Article 1.0 Author-Name: Gerhard Kreitl Author-X-Name-First: Gerhard Author-X-Name-Last: Kreitl Author-Name: Gerhard Urschitz Author-X-Name-First: Gerhard Author-X-Name-Last: Urschitz Author-Name: Wolfgang Oberndorfer Author-X-Name-First: Wolfgang Author-X-Name-Last: Oberndorfer Title: Corporate growth of engineering consulting firms: a European review Abstract: Corporate growth is understandably one of the hottest topics among researchers in management and managers themselves. Nonetheless, research in the sector of professional service firms, especially engineering consulting firms, has not yet led to a deeper understanding of how growth in this particular sector is achieved. This descriptive empirical study tries to provide some answers by reviewing the endeavours of the largest engineering consulting firms in Europe (top 100) within the timeframe 1990-1998. The findings suggest that the firms surveyed grew on average about 120% in terms of staff increase and about 170% in terms of revenue increase. This growth was largely achieved organically: growth through mergers and acquisitions (M&A) also contributed quite strongly whereas engaging in joint ventures played only a minor role. The same pattern emerged when analyzing the success of the different modes of growth, with organic growth being the most successful, followed by growth through M&As and joint ventures. Further, it could be shown that the firms' growth was strongly influenced by a focus on firm size, followed by a focus on market share and on profit, while focus on the firm's value was less significant. Journal: Construction Management and Economics Pages: 437-448 Issue: 5 Volume: 20 Year: 2002 Keywords: Corporate Growth, Engineering Consulting Firm, Europe, X-DOI: 10.1080/01446190210139487 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210139487 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:5:p:437-448 Template-Type: ReDIF-Article 1.0 Author-Name: Margaret Whittock Author-X-Name-First: Margaret Author-X-Name-Last: Whittock Title: Women's experiences of non-traditional employment: is gender equality in this area a possibility? Abstract: Currently, skills shortages are prompting the UK government to introduce initiatives intended to break down notions of stereotyped employment and attract women to non-traditional, male-dominated industries such as construction. Thus, it seems timely to revisit a study of the lived experience of non-traditionally employed women, conducted in Northern Ireland in the mid-1990s. Data from this study are presented here, specifically contextualized within R. M. Kanter's (American Journal of Sociology, 82, 965-90) framework of tokenism. Utilizing this framework, the paper examines the relationship that exists between the sexes (women as 'tokens' and males as 'dominants') in the non-traditional settings examined, indicating that barriers remain that women must surmount for gender equality to be achieved. The paper concludes by briefly examining one initiative working pro-actively to remove these barriers, providing women with greater opportunities to pursue non-traditional careers. Journal: Construction Management and Economics Pages: 449-456 Issue: 5 Volume: 20 Year: 2002 Keywords: Women, Non-TRADITIONAL Employment, Tokenism, Lived Experience, Stereotyping, X-DOI: 10.1080/01446190210140197 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210140197 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:5:p:449-456 Template-Type: ReDIF-Article 1.0 Author-Name: Margaret Emsley Author-X-Name-First: Margaret Author-X-Name-Last: Emsley Author-Name: David Lowe Author-X-Name-First: David Author-X-Name-Last: Lowe Author-Name: A. Roy Duff Author-X-Name-First: A. Roy Author-X-Name-Last: Duff Author-Name: Anthony Harding Author-X-Name-First: Anthony Author-X-Name-Last: Harding Author-Name: Adam Hickson Author-X-Name-First: Adam Author-X-Name-Last: Hickson Title: Data modelling and the application of a neural network approach to the prediction of total construction costs Abstract: Neural network cost models have been developed using data collected from nearly 300 building projects. Data were collected from predominantly primary sources using real-life data contained in project files, with some data obtained from the Building Cost Information Service, supplemented with further information, and some from a questionnaire distributed nationwide. The data collected included final account sums and, so that the model could evaluate the total cost to the client, clients' external and internal costs, in addition to construction costs. Models based on linear regression techniques have been used as a benchmark for evaluation of the neural network models. The results showed that the major benefit of the neural network approach was the ability of neural networks to model the nonlinearity in the data. The 'best' model obtained so far gives a mean absolute percentage error (MAPE) of 16.6%, which includes a percentage (unknown) for client changes. This compares favourably with traditional estimating where values of MAPE between 20.8% and 27.9% have been reported. However, it is anticipated that further analyses will result in the development of even more reliable models. Journal: Construction Management and Economics Pages: 465-472 Issue: 6 Volume: 20 Year: 2002 Keywords: Cost Modelling, Neural Networks, Linear Regression Analysis, X-DOI: 10.1080/01446190210151050 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210151050 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:6:p:465-472 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Ngai Author-X-Name-First: Stephen Author-X-Name-Last: Ngai Author-Name: Derek Drew Author-X-Name-First: Derek Author-X-Name-Last: Drew Author-Name: H. P. Lo Author-X-Name-First: H. P. Author-X-Name-Last: Lo Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: A theoretical framework for determining the minimum number of bidders in construction bidding competitions Abstract: A theoretical framework is proposed for determining the minimum number of bidders in competition for projects in the construction industry. This is based on the neo-classical micro-economic theory for price determination in construction and the assumption of random contractor-selection. Empirical analysis of the Hong Kong data set not only illustrates the applicability of the framework, but also supports the relevance of the microeconomic model for construction price determination. The main implication for clients is that, in order to obtain the most competitive bids for projects in the most cost-efficient way, they should vary the minimum number of bidders in competition according to market conditions. Journal: Construction Management and Economics Pages: 473-482 Issue: 6 Volume: 20 Year: 2002 Keywords: Construction Price Determination, Tendering Theory, Construction Economics, Number Of Bidders, X-DOI: 10.1080/01446190210151041 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210151041 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:6:p:473-482 Template-Type: ReDIF-Article 1.0 Author-Name: Jonathan Jingsheng Shi Author-X-Name-First: Jonathan Jingsheng Author-X-Name-Last: Shi Title: Three methods for verifying and validating the simulation of a construction operation Abstract: A simulation model must be verified to confirm that it describes correctly its intended real world process under study; moreover, the simulation results obtained must be a valid representation of the process. This study presents three activity-based white-box methods for assisting a user in verifying and validating construction simulations. The first method reports a simulation by listing all activities in the chronological order of their executions, so that a user can contrast the simulated progress against the actual progress in the real world. The second method summarizes the operating counts and mean durations of all activities over the simulated time period, to enable a user to evaluate whether all activities have been executed correctly during simulation. The third method generates an activity cycle report for any selected resource entity, so that a user can examine whether the entity is moving in the correct logical and chronological order during simulation. The three methods can be used jointly to debug a simulation model, so as to confirm that the simulation is correctly conducted and the obtained results are valid. The three methods are implemented in a simulation system in the form of corresponding reports. A concreting process is employed to illustrate these methods. Journal: Construction Management and Economics Pages: 483-491 Issue: 6 Volume: 20 Year: 2002 Keywords: Computer Simulation, Simulation Modelling, Validation, Verification, Construction Planning, Simulation Of Construction Operations, Construction Process, X-DOI: 10.1080/01446190210151032 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210151032 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:6:p:483-491 Template-Type: ReDIF-Article 1.0 Author-Name: J. S. Goulding Author-X-Name-First: J. S. Author-X-Name-Last: Goulding Author-Name: M. Alshawi Author-X-Name-First: M. Author-X-Name-Last: Alshawi Title: Generic and specific IT training: a process protocol model for construction Abstract: This paper considers the generic processes involved in structuring an information technology (IT) training strategy to meet a construction organization's business strategy. It identifies and discusses how generic and specific IT training needs can be affected by the availability and priority of resources, type of organizational infrastructure, degree of management commitment, and prevailing level of culture. It goes on to discuss the principles of the capability maturity model (CMM), developed at Carnegie Mellon University, and the concepts of the process protocol (PP), developed by Salford University. It builds upon these approaches to analyse the key sequential stages and links needed to satisfy (or close) the 'performance gap' between the business strategy and the IT training strategy. An IT training model is presented the remit of which can help managers assess the impact of IT training on their organization's business strategy. Journal: Construction Management and Economics Pages: 493-505 Issue: 6 Volume: 20 Year: 2002 Keywords: Business Strategy, Information Technology, Process Modelling, Training, X-DOI: 10.1080/01446190210151069 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210151069 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:6:p:493-505 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Anna Sublet Author-X-Name-First: Anna Author-X-Name-Last: Sublet Title: The impact of job and organizational demands on marital or relationship satisfaction and conflict among Australian civil engineers Abstract: The results of a survey of professional civil engineers working in the Australian construction industry are reported (n = 182). The survey examined the effect of a range of job and organizational demands on the marital or relationship satisfaction of respondents. The effect of demographic characteristics was also examined. The results of correlation and regression analyses provide support for linkages between demographic characteristics, job or organizational sources of work-related stress and marital/relationship satisfaction and conflict. Different variables were significantly correlated with three dimensions of relationship quality. The results suggest that the single most important factor in determining civil engineers' experiences of relationship quality is the number of hours they work each week. It is argued that the implementation of work-life balance initiatives by engineering organizations may benefit employees. However, for such initiatives to be successful, engineering organizations and their employees must deviate from the socially constructed norm of rigid, long work hours that prevails in the Australian construction industry. Journal: Construction Management and Economics Pages: 507-521 Issue: 6 Volume: 20 Year: 2002 Keywords: Construction, Job Demands, Relationship Satisfaction, Relationship Conflict, Work-LIFE Balance, X-DOI: 10.1080/01446190210156073 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210156073 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:6:p:507-521 Template-Type: ReDIF-Article 1.0 Author-Name: Swee-Lean Chan Author-X-Name-First: Swee-Lean Author-X-Name-Last: Chan Title: Responses of selected economic indicators to construction output shocks: the case of Singapore Abstract: The volume of construction output fluctuates in response to changes in demand and supply conditions. Due to the multiple linkages that the construction industry has with other economic sectors and the entire economy, the output shock is propagated through the economic system and reflected in several economic indicators, such as the outputs of other sectors, balance of payments and general prices. A study is reported on the short-term responses of some economic indicators in Singapore following a shock in the construction output, using the Granger causality approach, the impulse response function and variance decomposition analysis. Construction output shock had significant impact on the outputs of the commerce sector and 'other services'. The heavy reliance of the Singapore construction industry on imported inputs has a direct impact on the balance of payments. Journal: Construction Management and Economics Pages: 523-533 Issue: 6 Volume: 20 Year: 2002 Keywords: Construction Output Shock, Responses, Balance Of Payments, Sectoral Outputs, Prices, X-DOI: 10.1080/01446190210156091 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210156091 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:6:p:523-533 Template-Type: ReDIF-Article 1.0 Author-Name: Mohamed Marzouk Author-X-Name-First: Mohamed Author-X-Name-Last: Marzouk Author-Name: Osama Moselhi Author-X-Name-First: Osama Author-X-Name-Last: Moselhi Title: Simulation optimization for earthmoving operations using genetic algorithms Abstract: This paper presents a methodology for simulation optimization utilizing genetic algorithms and applies it to a newly developed simulation-based system for estimating the time and cost of earthmoving operations. The genetic algorithm searches for a near-optimum fleet configuration that reduces project total cost, and considers a set of qualitative and quantitative variables that influence earthmoving operations. Qualitative variables represent the models of equipment used in each fleet scenario, whereas quantitative variables represent the number of items of equipment involved in each scenario. Pilot simulation runs were carried out for all configurations generated by the developed algorithm, and a complete simulation analysis was then performed for the fleet recommended by the algorithm. The numerical example demonstrates the use of the proposed methodology and illustrates its essential features. Journal: Construction Management and Economics Pages: 535-543 Issue: 6 Volume: 20 Year: 2002 Keywords: Genetic Algorithms, Simulation Optimization, Earthmoving, Equipment Selection, X-DOI: 10.1080/01446190210156064 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210156064 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:6:p:535-543 Template-Type: ReDIF-Article 1.0 Author-Name: Les Ruddock Author-X-Name-First: Les Author-X-Name-Last: Ruddock Title: Measuring the global construction industry: improving the quality of data Abstract: In the context of a truly global market for construction, an international strategy is required to ensure that national and international statistical systems are able to provide accurate and valid information. In many parts of the world the collection of reliable national information on construction activity is not an easy task, and the measurement of comparable, cross-national data can be problematic. This paper considers possible strategies for the improvement of data collection systems in the context of user needs. Journal: Construction Management and Economics Pages: 553-556 Issue: 7 Volume: 20 Year: 2002 Keywords: Construction Activity, International Comparability, Statistical Systems, X-DOI: 10.1080/01446190210159908 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210159908 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:7:p:553-556 Template-Type: ReDIF-Article 1.0 Author-Name: Sai-On Cheung Author-X-Name-First: Sai-On Author-X-Name-Last: Cheung Author-Name: Henry Suen Author-X-Name-First: Henry Author-X-Name-Last: Suen Title: A multi-attribute utility model for dispute resolution strategy selection Abstract: Disputes are inevitable in construction projects. Skills in dispute resolution should be part of the toolkit of any practitioner in a managerial position. Dispute resolution procedures such as litigation, arbitration, mediation, dispute adviser and negotiation are widely practised. However, frequently the question is how to systematically determine which dispute resolution strategy to adopt given the nature of disputes. Even though the topic of dispute resolution has been widely discussed and heavily researched, few studies have been conducted with respect to this question. A decision-making model has been developed using the analytical hierarchy process (AHP) and multi-attribute utility technique (MAUT). The model comprises four parts: selection criteria, dispute resolution strategies, collection of utility factors and selection criteria weightings. These were developed from empirical data collected through an interview survey with selected experts in the field. The model is designed to identify in a systematic manner an appropriate dispute resolution strategy for a given dispute, rather than relying on subjective decisions. The model is tested using a hypothetical scenario in which three case studies are evaluated. Journal: Construction Management and Economics Pages: 557-568 Issue: 7 Volume: 20 Year: 2002 Keywords: Dispute Resolution Strategies, Selection Criteria, Analytical Hierarchy Process, Multi-ATTRIBUTE Utility Technique, Selection Model, X-DOI: 10.1080/01446190210157568 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210157568 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:7:p:557-568 Template-Type: ReDIF-Article 1.0 Author-Name: Franco Cheung Author-X-Name-First: Franco Author-X-Name-Last: Cheung Author-Name: Judy Leung Fung Kuen Author-X-Name-First: Judy Leung Fung Author-X-Name-Last: Kuen Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Multi-criteria evaluation model for the selection of architectural consultants Abstract: The selection of a competent architect is vital to the success of a development. Like in many developed countries, developers in Hong Kong select architects based on a set of criteria. Price is not the only consideration in the process, and decisions rely heavily on subjective judgement. By conducting a questionnaire survey, the research reported here identified the common criteria for selection and their relative importance for an objective selection. This involved the use of an evaluation method called the analytical hierarchy process (AHP). Survey data from projects with similar characteristics were used to compute the criteria weights. Multi-criteria models for seven out of 27 categories of project were built with reference to the computed weights derived from the survey. In addition, a computer program, called the Architectural Consultant Selection System (ACSS), was designed to illustrate a logical approach for the evaluation of prospective consultant architects based on the models constructed. Journal: Construction Management and Economics Pages: 569-580 Issue: 7 Volume: 20 Year: 2002 Keywords: Selection Criteria, Analytical Hierarchy Process, Consultant Architect, X-DOI: 10.1080/01446190210159818 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210159818 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:7:p:569-580 Template-Type: ReDIF-Article 1.0 Author-Name: David Edwards Author-X-Name-First: David Author-X-Name-Last: Edwards Author-Name: Gary Holt Author-X-Name-First: Gary Author-X-Name-Last: Holt Author-Name: Frank Harris Author-X-Name-First: Frank Author-X-Name-Last: Harris Title: Predicting downtime costs of tracked hydraulic excavators operating in the UK opencast mining industry Abstract: This paper describes the development of a model to predict the hourly cost of downtime (using regression equations) for tracked hydraulic excavators operating in the UK opencast mining industry. A three-stage process was utilized for the model's development. The first stage predicted machine cycle times, the second predicted hire costs per hour and the third used the outputs of the first two to forecast the cost of breakdown. Both cycle time and hire cost models were revealed to be good predictors, as exhibited by the 'high' R2 values of 0.86 and 0.95, respectively. A plant expert employed within the Defence Logistics Organisation, UK Ministry of Defence, validated these regression models and the process by which downtime costs were predicted. Future research work will aim to enhance the predictive ability of the models developed, expand the research to cover other machine types, and reproduce the findings in graphical and tabular format to improve the interpretation of information generated. Journal: Construction Management and Economics Pages: 581-591 Issue: 7 Volume: 20 Year: 2002 Keywords: Construction Plant, Machine Cycle Time, Productivity, Downtime Cost, Regression Analysis, X-DOI: 10.1080/01446190210163552 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210163552 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:7:p:581-591 Template-Type: ReDIF-Article 1.0 Author-Name: Willie Tan Author-X-Name-First: Willie Author-X-Name-Last: Tan Title: Construction and economic development in selected LDCs: past, present and future Abstract: This paper critically examines the changing relations between construction and economic development in selected less developed countries (LDCs) in the light of new development dynamics. Historically, the relationship was seen in Keynesian terms. By the 1980s, attention turned towards structuralist and political economy explanations amid a neoclassical revival towards structural adjustments and 'market friendly' reforms. Current explanations tend to focus on property rights and building institutional capabilities. The strengths and weaknesses of current explanations provide future directions for research. Journal: Construction Management and Economics Pages: 593-599 Issue: 7 Volume: 20 Year: 2002 Keywords: Construction And Economic Development, Structure, Political Economy, Institutions, X-DOI: 10.1080/01446190210159827 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210159827 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:7:p:593-599 Template-Type: ReDIF-Article 1.0 Author-Name: Mohammed Fadhil Dulaimi Author-X-Name-First: Mohammed Fadhil Author-X-Name-Last: Dulaimi Author-Name: Hon Guo Shan Author-X-Name-First: Hon Guo Author-X-Name-Last: Shan Title: The factors influencing bid mark-up decisions of large- and medium-size contractors in Singapore Abstract: The construction industry in Singapore is dominated by a competitive business environment that is being driven by a lowest cost mentality. The pressure on contractors' profit margins has further increased after a prolonged recession in this sector, which has seen construction demand and output shrinking significantly. This paper examines the factors that contractors perceive to be important when they are considering the size of their bid mark-up. The research hypothesis is that contractor size would have a significant bearing on the factors that would influence the bid mark-up decision. Forty factors were identified and a survey was conducted. The results showed that contractor size has a significant impact on their attitude towards bid mark-up decision-making. The analysis also showed that when deciding the size of a bid mark-up large contractors tend to be more concerned with the nature of the construction work while medium-size contractors are more concerned about the state of their own companies finance. Journal: Construction Management and Economics Pages: 601-610 Issue: 7 Volume: 20 Year: 2002 Keywords: Mark-UP, Tendering, Singapore, Contractor Size, Procurement, X-DOI: 10.1080/01446190210159890 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210159890 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:7:p:601-610 Template-Type: ReDIF-Article 1.0 Author-Name: Derek Drew Author-X-Name-First: Derek Author-X-Name-Last: Drew Author-Name: L. Y. Shen Author-X-Name-First: L. Y. Author-X-Name-Last: Shen Author-Name: Patrick Zou Author-X-Name-First: Patrick Author-X-Name-Last: Zou Title: Developing an optimal bidding strategy in two-envelope fee bidding Abstract: Two-envelope fee bidding is used frequently in allocating commissions to willing consultants such as architects, engineers and surveyors. Consultant fees and technical scores are normally aggregated to form a total score. The consultant obtaining the highest total score is usually awarded the commission. The consultant's objective is to get the highest total score possible because this maximizes the chance of winning. Consultants can submit to the procurer any of a number of different technical proposals which is then converted to a technical score. Only one technical score+fee combination will result in the highest total score, i.e. the optimum technical score+fee combination. This paper offers consultants an approach to better identify their optimum technical score+fee combination. In using this approach consultants need to develop a total score continuum based on (1) the consultant's original technical proposal and fee, (2) the absolute lowest fee and corresponding technical score, and (3) the absolute highest technical score and corresponding fee. The total score becomes the dependent variable and the fee the independent variable. Since the total score continuum is regressed on three points it will almost certainly be curvilinear in shape. Given that the optimum total score is at the highest point of the continuum, the optimum fee can be determined through differentiation. The corresponding technical score can then be found. After adjusting the original technical proposal to reflect the corresponding technical score, the optimum fee and adjusted technical proposal can then be submitted to the procurer. Journal: Construction Management and Economics Pages: 611-620 Issue: 7 Volume: 20 Year: 2002 Keywords: Bidding, Consultant, Fee, Strategy, Technical Score, Tendering, Two-ENVELOPE, X-DOI: 10.1080/01446190210160843 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210160843 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:7:p:611-620 Template-Type: ReDIF-Article 1.0 Author-Name: Anna Dubois Author-X-Name-First: Anna Author-X-Name-Last: Dubois Author-Name: Lars-Erik Gadde Author-X-Name-First: Lars-Erik Author-X-Name-Last: Gadde Title: The construction industry as a loosely coupled system: implications for productivity and innovation Abstract: Previous research suggests that the construction industry is characterized by (1) particular complexity factors owing to industry specific uncertainties and interdependences, and (2) inefficiency of operations. The aim of this study was to analyse the operations and behaviour of firms as a means of dealing with complexity. The observations made indicate that the industry as a whole is featured as a loosely coupled system. Taking this as a starting point, the couplings among activities, resources and actors were analysed in different dimensions. The pattern of couplings builds on two interdependent layers: tight couplings in individual projects and loose couplings based on collective adaptations in the permanent network. It is concluded that the pattern of couplings seems to favour short term productivity while hampering innovation and learning. Journal: Construction Management and Economics Pages: 621-631 Issue: 7 Volume: 20 Year: 2002 Keywords: Construction, Loosely Coupled System, Productivity, Innovation, X-DOI: 10.1080/01446190210163543 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210163543 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:7:p:621-631 Template-Type: ReDIF-Article 1.0 Author-Name: Bart Bossink Author-X-Name-First: Bart Author-X-Name-Last: Bossink Title: A Dutch public-private strategy for innovation in sustainable construction Abstract: Influenced by the sustainable construction policy of the authorities, organizations in The Netherlands are developing, designing and building sustainable areas and objects. The actions of the authorities, authority-related organizations and commercial organizations in the Dutch construction industry and the interaction between them contribute to the realization of goals that fit with the sustainability policy of the government. Research in the house building sector of the Dutch construction industry, covering a 10-year period, has found that action by and interaction between public and private organizations directed towards innovation in sustainable construction is part of a sector-wide strategy. In this strategy public and private organizations interactively develop and adopt sustainable construction innovations. Journal: Construction Management and Economics Pages: 633-642 Issue: 7 Volume: 20 Year: 2002 Keywords: Sustainable Construction, Sustainability Policy, Innovation Management, Strategic Management, X-DOI: 10.1080/01446190210163534 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190210163534 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:7:p:633-642 Template-Type: ReDIF-Article 1.0 Author-Name: Tan Sui Ling Gracia Author-X-Name-First: Tan Sui Ling Author-X-Name-Last: Gracia Title: Editorial Abstract: Journal: Construction Management and Economics Pages: 1-3 Issue: 1 Volume: 21 Year: 2003 X-DOI: 10.1080/0144619032000065063 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000065063 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:1:p:1-3 Template-Type: ReDIF-Article 1.0 Author-Name: Tan Sui Ling Gracia Author-X-Name-First: Tan Sui Ling Author-X-Name-Last: Gracia Title: Authors' Charter Abstract: Journal: Construction Management and Economics Pages: 5-5 Issue: 1 Volume: 21 Year: 2003 X-DOI: 10.1080/0144619032000065072 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000065072 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:1:p:5-5 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Fox Author-X-Name-First: Stephen Author-X-Name-Last: Fox Author-Name: Laurence Marsh Author-X-Name-First: Laurence Author-X-Name-Last: Marsh Author-Name: Graham Cockerham Author-X-Name-First: Graham Author-X-Name-Last: Cockerham Title: Assessing the capability of construction processes to realize building designs Abstract: The capability of processes should be assessed during their development. If assessment reveals that a process is not capable of meeting design requirements, that process should be improved until reassessment indicates that it is capable. This proactive approach can radically reduce non-conformances. Existing methods of assessment depend upon the sampling of process data. Such methods are well-established and well-documented. They provide the foundation for statistical process control (SPC) and can be applied to most processes including those used in the construction of buildings. However, there are several reasons why sampling data to assess construction process capability can be extremely difficult. In this paper, the limitations of existing assessment methods are outlined. Then, a new assessment method is introduced and results from a preliminary field study are reported. Next, the key features of the new method are discussed. In conclusion, guidelines for its successful introduction are provided. Journal: Construction Management and Economics Pages: 7-10 Issue: 1 Volume: 21 Year: 2003 Keywords: Construction Process Capability, Building Design Requirements, X-DOI: 10.1080/0144619021000026167 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619021000026167 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:1:p:7-10 Template-Type: ReDIF-Article 1.0 Author-Name: Mei-Yung Leung Author-X-Name-First: Mei-Yung Author-X-Name-Last: Leung Author-Name: Anita Liu Author-X-Name-First: Anita Author-X-Name-Last: Liu Title: Analysis of value and project goal specificity in value management Abstract: Value is a subjective term and is manifested in different ways such as attitude, belief, desire, preference, need and criteria. In this paper, a cognitive value management model for construction procurement is developed to examine how value is influenced by previous project outcomes and other environmental dynamics that affect project goal setting and conflict resolution in the value management process. The relationships among the variables of value specificity, goal specificity, conflict resolution and participant satisfaction are investigated in a behavioural model of value management. It is postulated that value-goal specificity and conflict resolution (integration) level in the value management process have a direct impact on satisfaction of project participants. The findings in a questionnaire survey indicate that more specific value and goal and higher conflict resolution (integration) level in the goal setting process can improve the participants' satisfaction. Journal: Construction Management and Economics Pages: 11-19 Issue: 1 Volume: 21 Year: 2003 Keywords: Value Management, Project Goal Specificity, Conflict Resolution, Satisfaction, X-DOI: 10.1080/0144619032000065081 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000065081 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:1:p:11-19 Template-Type: ReDIF-Article 1.0 Author-Name: Jakrapong Pongpeng Author-X-Name-First: Jakrapong Author-X-Name-Last: Pongpeng Author-Name: John Liston Author-X-Name-First: John Author-X-Name-Last: Liston Title: TenSeM: a multicriteria and multidecision-makers' model in tender evaluation Abstract: In tender evaluation, there appears to be a lack of a realistic working models capable of simultaneously (1) compiling multiple decision-makers' inputs, (2) incorporating risk and uncertainty, and (3) offering computer interaction that makes a model flexible to any change in situation. Thus, the research has developed a more realistic working model including the necessary capabilities mentioned. The vital theory behind the model was a combination of a utility function and a social welfare function. The model was divided into two main steps (step1: evaluating contractor ability and step2: evaluating tenders) consisting of three main processes: (1) the contractor ability criteria selection process; (2) the contractor ability criteria balancing/measuring process; and (3) bid price and contractor ability balancing/measuring process. The model incorporated computer interaction in which Microsoft Excel performed calculation tasks while Visual Basic for Application (VBA) was coded for user interaction. To obtain a realistic working product, the model was tested for user friendliness, verification, sensitivity analysis, and validation. The test has shown that the multicriteria and multidecision-makers' model, TenSeM, is a rational and realistic approach in solving a tender evaluation problem. Journal: Construction Management and Economics Pages: 21-30 Issue: 1 Volume: 21 Year: 2003 Keywords: Multicriteria, Multidecision-makers, Interactive Model, Tender Evaluation, Social Welfare Function, X-DOI: 10.1080/0144619032000065090 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000065090 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:1:p:21-30 Template-Type: ReDIF-Article 1.0 Author-Name: H. Zhang Author-X-Name-First: H. Author-X-Name-Last: Zhang Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Title: Fuzzy decision-making for dynamic resource allocation Abstract: For construction activities, timely resource allocation is crucial to avoid unnecessary waiting time of resources and delay of activities, especially under the condition of limited supply of resources. Timely resource allocation, i.e. determination of an activity that has the highest priority to obtain resources at that instant, is a dynamic decision-making process dependent on real-time information during a construction process. With the consideration of operational and stochastic characteristics of construction operations and the fuzziness of multiple-decision objectives for an appropriate allocation policy (due to imprecision or subjectivity in decision criteria), a fuzzy dynamic resource allocation (FDRA) based on the fuzzy decision-making approach is developed. In order to model the timely resource allocation decisions, the FDRA is built into a discreteevent simulation system with an activity scanning strategy. The benefit of FDRA on construction productivity is analysed through simulation experimentation by which comparisons among different allocation policies are made. Journal: Construction Management and Economics Pages: 31-41 Issue: 1 Volume: 21 Year: 2003 Keywords: Resource Allocation, Dynamic Decision-making, Simulation, Fuzzy Sets, X-DOI: 10.1080/0144619032000065108 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000065108 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:1:p:31-41 Template-Type: ReDIF-Article 1.0 Author-Name: Ho Man-Fong Christabel Author-X-Name-First: Ho Man-Fong Author-X-Name-Last: Christabel Author-Name: Ng Chi-Wai Vincent Author-X-Name-First: Ng Chi-Wai Author-X-Name-Last: Vincent Title: Quantity surveyors' background and training, and their ethical concepts, conceptions and interests considerations Abstract: In this paper, general and specific hypotheses concerning quantity surveyors' ethical perceptions as well as their personal background and professional training are derived from previous research studies (Fan et al., 2001a, 2001b). More rigorous statistical tests, such as Multivariate ANalysis Of VAriance (MANOVA) and Hierarchical Regression Analysis (HRA), are used to test these hypotheses and thus verify findings of the previous research. Salient discrepancies in ethical perceptions of professional quantity surveyors are found to exist among professional quantity surveyors of different ages, membership levels and work experience. In predicting ethical perceptions, it is confirmed that the more experienced and the higher the education level of quantity surveyors, the more optimistic they are concerning recent declines in ethical standards. This group of quantity surveyors (QS) is more willing to sacrifice its self-interest when facing ethical dilemmas. However, results of this study show also that 'background' variables are indeed moderating each other, which are contingent upon the specific ethical perceptions concerned. As a first step for the development of a knowledge base for future professional training and socialization, findings of this study suggest two directions for further research study. Firstly, a case study approach would elicit decisions made in the face of ethical dilemmas. Secondly, extensive surveys in reconciling professional service quality with the expectations of clients and the general public will further enrich the field. Journal: Construction Management and Economics Pages: 43-67 Issue: 1 Volume: 21 Year: 2003 Keywords: Professional Ethics, Socialization, Ethical Training, X-DOI: 10.1080/0144619032000065117 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000065117 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:1:p:43-67 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Title: The impact of individual and job characteristics on 'burnout' among civil engineers in Australia and the implications for employee turnover Abstract: A survey was undertaken to explore the experience of 'burnout' among engineers working in the Australian construction industry. The most widely recognized model of burnout, comprising emotional exhaustion, cynicism and a diminished sense of personal accomplishment was found to be valid. However, Australian engineers experience a strong sense of the social worth of their professional activity, independently of believing in their own individual competence as engineers. There was also a widespread belief that the rewards enjoyed by engineers as a result of their professional endeavours are not commensurate with their level of skill and responsibility. The results of the study also show that burnout cannot be attributed to a single cause but occurs as a result of a complex interaction of individual characteristics and issues in the work environment. As such, there is no single 'cure' for burnout and multiple intervention strategies are probably needed. However, the relative importance of job characteristics compared to personality characteristics in predicting burnout suggests that job re-design may be an effective preventive strategy. Cynicism and emotional exhaustion were strong predictors of engineers' intention to leave their jobs. This suggests that measures to prevent burnout could also help to reduce turnover and its associated costs. Journal: Construction Management and Economics Pages: 69-80 Issue: 1 Volume: 21 Year: 2003 Keywords: Burnout, Civil Engineering, Construction, Job Demands, Turnover, X-DOI: 10.1080/0144619032000065126 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000065126 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:1:p:69-80 Template-Type: ReDIF-Article 1.0 Author-Name: Javier Cuervo Author-X-Name-First: Javier Author-X-Name-Last: Cuervo Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Title: Ownership advantages/disadvantages of Singapore transnational construction corporations Abstract: Expanding beyond Singapore's boundaries has been a source of increased business for Singapore transnational construction corporations (STCCs). This paper analyses the significance of ownership advantage and disadvantage factors of STCCs in pursuing their international construction business, relative to other ASEAN contractors and contractors from developed countries. Moreover, this study examines if these ownership factors do vary significantly according to firm specific contextual variables in the STCCs such as size, international age, multinationality and extent of specialization/diversification. Based on responses from 22 STCCs, this study has found that the most important ownership advantage factors of STCCs were identified as coming from: (1) information, knowledge, technology and R&D capability; (2) the firm's name and reputation; and (3) management and organizational capability. Relative to established international contractors STCCs have a significant size disadvantage with reference to certain project types. Journal: Construction Management and Economics Pages: 81-94 Issue: 1 Volume: 21 Year: 2003 Keywords: Ownership Advantages And Disadvantages, Singapore Transnational Construction Corporation, International Construction, X-DOI: 10.1080/0144619032000065135 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000065135 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:1:p:81-94 Template-Type: ReDIF-Article 1.0 Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Title: Book Reviews Abstract: Journal: Construction Management and Economics Pages: 95-97 Issue: 1 Volume: 21 Year: 2003 X-DOI: 10.1080/0144619032000065144 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000065144 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:1:p:95-97 Template-Type: ReDIF-Article 1.0 Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Title: Forthcoming events Abstract: Journal: Construction Management and Economics Pages: 99-100 Issue: 1 Volume: 21 Year: 2003 X-DOI: 10.1080/713763900 File-URL: http://www.tandfonline.com/doi/abs/10.1080/713763900 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:1:p:99-100 Template-Type: ReDIF-Article 1.0 Author-Name: Margaret Whittock Author-X-Name-First: Margaret Author-X-Name-Last: Whittock Title: Editorial Abstract: Journal: Construction Management and Economics Pages: 101-102 Issue: 2 Volume: 21 Year: 2003 X-DOI: 10.1080/713763921 File-URL: http://www.tandfonline.com/doi/abs/10.1080/713763921 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:101-102 Template-Type: ReDIF-Article 1.0 Author-Name: Danny Myers Author-X-Name-First: Danny Author-X-Name-Last: Myers Title: The future of construction economics as an academic discipline Abstract: The contribution made by economic theory when studying construction-related subjects has a muddled history. This theme was carefully reviewed in Ofori (1994) where he bluntly concluded that: 'Construction economics cannot be regarded as a bona-fide subject' (p. 304). This short note takes a retrospective look at George Ofori's paper and suggests that during the subsequent period little has changed. This is despite the publication of government reports that stressed the importance of creating a culture of economic efficiency within construction and the need for the industry to become sustainable. This paper is informed by a brief survey of what is currently taught at British universities under the title of construction economics. Two points for debate emerge. The first is the worrying observation about the present state of play, as it seems that construction economics continues to lack any coherent conceptual structure. The second is the more promising suggestion that in the foreseeable future the sustainability agenda could provide the impetus necessary for construction economists to agree a common purpose and conceptual approach. Journal: Construction Management and Economics Pages: 103-106 Issue: 2 Volume: 21 Year: 2003 Keywords: Construction Economics, University Education, Economic Theory, Sustainable Construction, Academic Consensus, X-DOI: 10.1080/0144619032000056117 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000056117 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:103-106 Template-Type: ReDIF-Article 1.0 Author-Name: David Picken Author-X-Name-First: David Author-X-Name-Last: Picken Author-Name: Ben Ilozor Author-X-Name-First: Ben Author-X-Name-Last: Ilozor Title: Height and construction costs of buildings in Hong Kong Abstract: The majority of buildings in Hong Kong come into the multi-storey category. The conventional wisdom of construction economics suggests that the cost of construction per square metre increases as buildings become higher. This paper summarizes earlier research on the subject and adopts a descriptive approach to present investigations into the cost-height relationship of buildings constructed in Hong Kong. Initial findings seem to suggest a different situation in Hong Kong - arguably the epitome of a 'tall' built environment. Possibly, there are factors concerning the design economics of tall buildings that are specific to those urban locations where they are more common. This point would suggest that a different set of criteria should be applied in the judgement of how height affects cost depending on the context and commonality of tall buildings in the location under consideration. Journal: Construction Management and Economics Pages: 107-111 Issue: 2 Volume: 21 Year: 2003 Keywords: Building, Height-cost, Economics, Location, X-DOI: 10.1080/0144619032000079671 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000079671 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:107-111 Template-Type: ReDIF-Article 1.0 Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Title: Preparing Singapore's construction industry for the knowledge-based economy: practices, procedures and performance Abstract: Many post-industrial economies are deemed to have entered a stage where knowledge and innovation are the main determinants of corporate competitiveness and national growth and development. This 'knowledge-based economy' has implications for all business activities. Singapore has prepared inter-related concept plans to guide its socio-economic development in the new age. What challenges does the knowledge-based economy pose to the construction industry? How can Singapore develop its construction industry to meet these demands? This paper begins by discussing the features of the knowledge-based economy. It outlines Singapore's strategies for developing a knowledge-based economy, and measures being taken to prepare the construction industry for such an economy, focusing on improvement in practices, integration of the construction process and export of services. It is suggested that other aspects require attention, including corporate development, business networks and procurement arrangements, and that the industry should be more involved in the implementation of these initiatives. Journal: Construction Management and Economics Pages: 113-125 Issue: 2 Volume: 21 Year: 2003 Keywords: Knowledge-based Economy, Construction 21, Construction Practices, Integration, Globalization, X-DOI: 10.1080/0144619032000079680 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000079680 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:113-125 Template-Type: ReDIF-Article 1.0 Author-Name: Yu Hoe Tang Author-X-Name-First: Yu Hoe Author-X-Name-Last: Tang Author-Name: Stephen Ogunlana Author-X-Name-First: Stephen Author-X-Name-Last: Ogunlana Title: Modelling the dynamic performance of a construction organization Abstract: The Asian financial crisis has adversely affected many of the domestic construction organizations in Malaysia, bringing some organizations to the brink of insolvency. It demonstrates that a construction organization's performance is sensitive to the prevailing economic conditions. This paper seeks to model the dynamic performance of a publicly listed construction organization in Malaysia. First, a diagrammatic model consisting of two interconnected causal loop diagrams is developed to represent the organization's capacity and its financial balance sheet. The diagrams provide a clearer understanding of the interactions between the country's construction market and the organization's financial, technical and managerial capabilities. Next, the causal loop diagrams are converted into a mathematical model using specialized software. Simulation results from the model are validated against historical time series data. Graphical plots of the simulation model and results from sensitivity analysis indicate that the model is capable of replicating the general behaviour of the organization. Journal: Construction Management and Economics Pages: 127-136 Issue: 2 Volume: 21 Year: 2003 Keywords: Construction Company, Performance Modelling, System Dynamics, Malaysia, X-DOI: 10.1080/0144619032000079699 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000079699 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:127-136 Template-Type: ReDIF-Article 1.0 Author-Name: Rajat Roy Author-X-Name-First: Rajat Author-X-Name-Last: Roy Author-Name: Justine Brown Author-X-Name-First: Justine Author-X-Name-Last: Brown Author-Name: Chris Gaze Author-X-Name-First: Chris Author-X-Name-Last: Gaze Title: Re-engineering the construction process in the speculative house-building sector Abstract: The UK house-building industry has often been criticized for failing to meet the housing needs of the country. The traditional craft-based build process is labour intensive with a long lead-time and is difficult to control for product quality. It is also not suitable for configurable designs that would help to customize the home, and the industry has been criticized for excessive standardization of its products. Attempts at industrialization, usually employing frame or panel-based build methods seen in many countries, have failed due mainly to lack of clear objectives. A change in build technology is also only one step in addressing the concerns of poor quality and lack of product variety. The paper presents a programme of work that is being carried out with a major house builder towards re-engineering of the build process through a combination of new technology, product engineering and changes in working practices. Journal: Construction Management and Economics Pages: 137-146 Issue: 2 Volume: 21 Year: 2003 Keywords: House Building, Industrialized Housing, Process Re-engineering, Mass Customization, Supply Chain Management, X-DOI: 10.1080/0144619032000049674 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000049674 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:137-146 Template-Type: ReDIF-Article 1.0 Author-Name: Anita Liu Author-X-Name-First: Anita Author-X-Name-Last: Liu Title: The quest for quality in public housing projects: a behaviour-to-outcome paradigm Abstract: This paper investigates the pursuit of quality in public housing projects through the implementation of ISO 9000 in the last decade in Hong Kong. A behaviour-to-performance-to-outcome paradigm is adopted to examine the process of this quality pursuit. The research was carried out in three stages to examine (1) the 'outcome' of the building product as assessed by the occupants by means of post-occupancy evaluation, (2) the 'performance' of the building product by analysing the buildings' defects lists and housing managers' perceptions of residents' feedback, and (3) the 'behaviour' of the contractors by investigating their awareness and adoption of total quality management. Journal: Construction Management and Economics Pages: 147-158 Issue: 2 Volume: 21 Year: 2003 Keywords: Behaviour, Housing Quality, Iso 9000, Performance, Post-occupancy Evaluation, Project Outcome, X-DOI: 10.1080/0144619032000049700 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000049700 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:147-158 Template-Type: ReDIF-Article 1.0 Author-Name: J. R. M. Ameen Author-X-Name-First: J. R. M. Author-X-Name-Last: Ameen Author-Name: R. H. Neale Author-X-Name-First: R. H. Author-X-Name-Last: Neale Author-Name: M. Abrahamson Author-X-Name-First: M. Author-X-Name-Last: Abrahamson Title: An application of regression analysis to quantify a claim for increased costs Abstract: This paper is a case study of the use of multiple linear regression analysis to quantify a claim for extra payment to a subcontractor for work on a substantial construction earth-moving project. The basis of the claim was that the client and main contractor required the work to be executed in ways other than that originally planned by the subcontractor, reducing efficiency and so increasing costs. The authors of this paper represented the earth-moving subcontractor in a legal arbitration, in which this application of multiple linear regression analysis was fundamental to quantifying the amount claimed in the case. The analysis determined the time required to perform earth-moving tasks, based on a set of explanatory variables, using data sets recorded on-site. The same equation was then applied to the plan of work used for the tender and was used to show that the comparative efficiency between tender and actual was as low as 25%. The claim was successful, and the calculations described in this paper were used to quantify a total additional payment of approximately £;380 000. Journal: Construction Management and Economics Pages: 159-165 Issue: 2 Volume: 21 Year: 2003 Keywords: Cost Estimation, Regression Analysis, Claim, Earth-moving Works, Efficiency, X-DOI: 10.1080/0144619032000049683 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000049683 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:159-165 Template-Type: ReDIF-Article 1.0 Author-Name: John Rooke Author-X-Name-First: John Author-X-Name-Last: Rooke Author-Name: David Seymour Author-X-Name-First: David Author-X-Name-Last: Seymour Author-Name: Richard Fellows Author-X-Name-First: Richard Author-X-Name-Last: Fellows Title: The claims culture: a taxonomy of attitudes in the industry Abstract: This paper presents an analysis of a familiar aspect of construction industry culture that we have dubbed 'the claims culture'. This is a culture of contract administration that lays a strong emphasis on the planning and management of claims. The principal elements of the analysis are two sets of distinctions. The first comprises economic and occupational orders, referring to two kinds of control that are exercised over the construct ion process; predicated respectively on economic ownership and occupational competence. The second refers to contrasting attitudes towards relationships and problem solving within these orders: respectively 'distributive' and 'integrative'. The concepts of economic and occupational order entail further sub-categories. The various attitudes associated with these categories and sub-categories are described. They are assessed as to their consequences for change initiatives in the industry. Journal: Construction Management and Economics Pages: 167-174 Issue: 2 Volume: 21 Year: 2003 Keywords: Culture, Claims Management, Procurement, Ethnography, Grounded Theory, X-DOI: 10.1080/0144619032000079707 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000079707 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:167-174 Template-Type: ReDIF-Article 1.0 Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Author-Name: Dong-Eun Lee Author-X-Name-First: Dong-Eun Author-X-Name-Last: Lee Title: Assessing the corporate service quality performance of design-build contractors using quality function deployment Abstract: The design-build (D/B) project delivery system has gained increased market share in the last few years. It is superior to traditional systems in some respects but some claim that it does not lend itself to effective quality assurance and control. D/B construction owners who are in the process of selecting a D/B firm for a project should therefore be well informed about the quality performance of potential D/B firms in their bidding list. Total quality consists of the corporate quality culture, the quality of the project service, and the quality of the constructed facility. This paper describes a tool that was developed to measure the corporate service quality of a D/B firm using quality function deployment (QFD). The service quality factors are ranked relative to construction owners' needs and expectations by means of a survey administered to construction owners. The components of quality management systems in place in D/B firms are ranked by D/B executives in a survey administered to senior D/B firms. The relationships between service quality factors and quality system requirements are established by a professional quality system assessor and all these attributes are integrated into one system called the Corporate Service a'House of Quality.' The tool developed can be used by construction owners to rank D/B firms relative to corporate service quality as well as by D/B firms to benchmark themselves against their competitors. Journal: Construction Management and Economics Pages: 175-185 Issue: 2 Volume: 21 Year: 2003 Keywords: Service Quality, Quality Management, Design-build Contracts, Quality Function Deployment, X-DOI: 10.1080/0144619032000079716 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000079716 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:175-185 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Fox Author-X-Name-First: Stephen Author-X-Name-Last: Fox Title: A matrix to indicate the utility of technologies Abstract: The development and performance of buildings and building components can be improved through better use of technology. However, identifying appropriate technologies can become more difficult as more options become available. Detailed descriptions of alternative technologies can be difficult to compare with each other. Yet, more superficial descriptions can be misleading and result in unnecessarily limited adoption of technologies. In other industries, simple diagrammatic tools such as matrices have proven to be an effective method of indicating the utility of technologies. These show the relevance of specific technologies to different types of products and product components. This paper proposes a matrix to indicate the relevance of technologies to different types of buildings and building components. First, the purpose of the technology matrix (TM) is defined. Then, the conceptual framework of the TM is explained. Next, factors to be considered when assessing the utility of technologies are described. Having introduced the TM, some illustrative examples are provided. These show that there are few technologies that can improve the development and performance of all buildings and building components. In many cases, there are barriers to feasibility, viability and/or practicability that need to be represented. In conclusion, guidelines for successful introduction of the TM are discussed. Journal: Construction Management and Economics Pages: 187-196 Issue: 2 Volume: 21 Year: 2003 Keywords: Feasibility, Matrix, Practic ability, Technology, Viability, X-DOI: 10.1080/0144619032000079725 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000079725 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:187-196 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Ekstrom Author-X-Name-First: Martin Author-X-Name-Last: Ekstrom Author-Name: Hans Bjornsson Author-X-Name-First: Hans Author-X-Name-Last: Bjornsson Author-Name: Clifford Nass Author-X-Name-First: Clifford Author-X-Name-Last: Nass Title: Accounting for rater credibility when evaluating AEC subcontractors Abstract: In consumer electronic markets, rating mechanisms are important facilitators of trust between market participants. This paper investigates whether source credibility theory can support the evaluation of bidders in architecture/engineering/construction (AEC) electronic market places. In contrast to consumer electronic marketplaces, the raters in AEC communities are skilled and connected, necessitating a reputation mechanism to account for the relationship between the user and the rater. To solve this problem, TrustBuilder, a prototype rating tool, facilitates information sharing between peer industry practitioners by calculating a weighted rating based on source credibility theory. An experiment shows that AEC industry practitioners who evaluate bidding subcontractors trusted the information provided by TrustBuilder significantly more than information from a standard unweighted rating tool. Journal: Construction Management and Economics Pages: 197-208 Issue: 2 Volume: 21 Year: 2003 Keywords: Reputation Mechanism, Electronic Commerce, Source Credibility, Bidding, Trust, Construction, X-DOI: 10.1080/0144619032000049656 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000049656 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:197-208 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: Mei-I Cheng Author-X-Name-First: Mei-I Author-X-Name-Last: Cheng Author-Name: David Moore Author-X-Name-First: David Author-X-Name-Last: Moore Title: Redefining performance measures for construction project managers: an empirical evaluation Abstract: Traditional success criteria for construction projects centre on the achievement of cost, programme and quality targets. In this paper, it is argued that these simple measures are too crude to be used for gauging managers' performance in the context of today's construction project environment, as many variables outside of the manager's control can impact on outturn performance and the demands on project managers are far broader than in the past. It is argued that the industry needs to define more appropriate performance criteria for measuring project managers' performance and encouraging their professional development. These must redefine traditional success parameters to consider the knowledge, skills and behavioural inputs which contribute to superior performance. These can then be used to engender a more appropriate set of management behaviours that lead to improved project outcomes. This study has developed such a framework by examining the views of members of project teams and other organizational stakeholders through a series of focus groups. Factor analysis was used to refine a range of nine performance criteria against which managers' performance can be evaluated. These have the potential to be used as a basis for developing more appropriate reward management approaches and as a starting point for developing competency-based performance management tools in the future. Journal: Construction Management and Economics Pages: 209-218 Issue: 2 Volume: 21 Year: 2003 Keywords: Contractors' Construction Project Managers, Performance Criteria, Performance Management, Competence Analysis, Factor Analysis, X-DOI: 10.1080/0144619032000049737 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000049737 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:209-218 Template-Type: ReDIF-Article 1.0 Author-Name: Igal Shohet Author-X-Name-First: Igal Author-X-Name-Last: Shohet Author-Name: Sarel Lavy-Leibovich Author-X-Name-First: Sarel Author-X-Name-Last: Lavy-Leibovich Author-Name: Dany Bar-On Author-X-Name-First: Dany Author-X-Name-Last: Bar-On Title: Integrated maintenance monitoring of hospital buildings Abstract: The performance of hospital buildings depends to a large degree on the efficiency of maintenance execution. The research objectives were to examine the efficiency of maintenance under alternative maintenance policies and alternative sources of labour (outsourcing vs. in-house). The research focused on maintenance of hospital buildings as a model for multi-system buildings operating in dynamic environments. The research used a systematic field survey followed by an in-depth statistical analysis. Four key performance indicators (KPIs) were developed. The first, the building performance indicator (BPI), indicates the physical-functional condition of buildings. The second, the manpower sources diagram (MSD), reflects the efficiency of using in-house labour vs. the outsourcing of labour. The third, the maintenance efficiency indicator (MEI), is based on the annual costs of maintenance, the building age coefficient and the building occupancy coefficient. This indicator reflects the efficiency of usage of the resources (labour, outsourcing, materials and spare parts) in maintenance. The fourth indicator deals with the organizational structure of the maintenance division. The proposed KPIs integrate four aspects of hospital facilities management: performance management, composition of labour, efficiency of main-tenance operations and organizational effectiveness. Efficient execution of maintenance management of hospital buildings may be obtained by the simultaneous implementation of the aforementioned KPIs. The proposed indicators may be adapted to other types of facilities, such as office buildings, industrial plants and infrastructure. Journal: Construction Management and Economics Pages: 219-228 Issue: 2 Volume: 21 Year: 2003 Keywords: Facilities Management, Key Performance Indicators, Life Cycle Costs, Maintenance Management, Outsourcing, Performance, X-DOI: 10.1080/0144619032000079734 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000079734 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:219-228 Template-Type: ReDIF-Article 1.0 Author-Name: Dany Bar-On Author-X-Name-First: Dany Author-X-Name-Last: Bar-On Title: Book Reviews Abstract: Journal: Construction Management and Economics Pages: 229-230 Issue: 2 Volume: 21 Year: 2003 X-DOI: 10.1080/0144619032000049728 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000049728 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:229-230 Template-Type: ReDIF-Article 1.0 Author-Name: Dany Bar-On Author-X-Name-First: Dany Author-X-Name-Last: Bar-On Title: Forthcoming events Abstract: Journal: Construction Management and Economics Pages: 231-232 Issue: 2 Volume: 21 Year: 2003 X-DOI: 10.1080/713763922 File-URL: http://www.tandfonline.com/doi/abs/10.1080/713763922 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:231-232 Template-Type: ReDIF-Article 1.0 Author-Name: Dany Bar-On Author-X-Name-First: Dany Author-X-Name-Last: Bar-On Title: Authors' Charter Abstract: Journal: Construction Management and Economics Pages: 233-233 Issue: 2 Volume: 21 Year: 2003 X-DOI: 10.1080/0144619032000079581 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000079581 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:2:p:233-233 Template-Type: ReDIF-Article 1.0 Author-Name: Dany Bar-On Author-X-Name-First: Dany Author-X-Name-Last: Bar-On Title: Editorial Abstract: Journal: Construction Management and Economics Pages: 235-236 Issue: 3 Volume: 21 Year: 2003 X-DOI: 10.1080/0144619032000093756 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000093756 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:3:p:235-236 Template-Type: ReDIF-Article 1.0 Author-Name: J. Nicholas Author-X-Name-First: J. Author-X-Name-Last: Nicholas Author-Name: D. J. Edwards Author-X-Name-First: D. J. Author-X-Name-Last: Edwards Title: A model to evaluate materials suppliers' and contractors' business interactions Abstract: A symbiotic business relationship exists between materials suppliers and construction contractors. Specifically, contractors must continually purchase materials on credit to complete projects, whilst suppliers exist on the profits made from selling such. In the absence of this indirect source of liquidity, many construction projects would not be completed. Despite the supplier incurring substantial financial risk when furnishing credit to contractors, there are currently no definitive or accurate means with which to measure and predict this risk. This paper presents the findings of a survey conducted throughout the UK that aimed to model the utility value that material suppliers experience when they interact with contractors. It is proposed that the (novel and new) methodological approach used will enable materials suppliers to enhance their decision-making process and subsequently boost business performance (and most notably, profit). Such improvements could ultimately be passed directly to good debtors in terms of lower materials costs, better delivery specifications, and improved creditor staff motivation. Subsequently, this could translate as more economical construction projects for clients. The paper concludes with direction for future works that would develop a more user-friendly software package and subsequently implement the research findings throughout the construction industry. Journal: Construction Management and Economics Pages: 237-245 Issue: 3 Volume: 21 Year: 2003 Keywords: Materials Suppliers, Credit And Debt, Creditworthiness, Construction Contractors, Financial Management, Utility, Business Relationships, X-DOI: 10.1080/0144619032000049692 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000049692 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:3:p:237-245 Template-Type: ReDIF-Article 1.0 Author-Name: Yu Hoe Tang Author-X-Name-First: Yu Hoe Author-X-Name-Last: Tang Author-Name: Stephen Ogunlana Author-X-Name-First: Stephen Author-X-Name-Last: Ogunlana Title: Selecting superior performance improvement policies Abstract: The changing trends in the Asian construction sector are creating both new opportunities for and threats to the domestic construction organizations. To improve the competitiveness of these organizations, senior managers are tasked with the responsibility of selecting and implementing improvement policies to enhance organizational performance. This study utilizes the system dynamics methodology to provide a careful and holistic evaluation of the policies. A model is built to represent an average performing construction organization listed on the Kuala Lumpur Stock Exchange. Long-term simulation of the validated model produces the forecasted organization performance. Three improvement policies recommended by CIDB (2000) that have different cost and benefit impact profiles are selected for evaluation. Taking into consideration the impact of the economy on the construction industry, simulated results of the policies and combination of the policies indicate that the implementation of short-term improvement policies produces superior improvement in organization performance when compared with other policies. Journal: Construction Management and Economics Pages: 247-256 Issue: 3 Volume: 21 Year: 2003 Keywords: Construction Company, Performance Evaluation, System Dynamics, Malaysia, X-DOI: 10.1080/0144619032000093765 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000093765 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:3:p:247-256 Template-Type: ReDIF-Article 1.0 Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Author-Name: Thomas Tong Author-X-Name-First: Thomas Author-X-Name-Last: Tong Title: GA-ANN model for optimizing the locations of tower crane and supply points for high-rise public housing construction Abstract: Site layout planning is a complicated issue due to the existence of a vast number of trades and inter-related planning constraints. In this paper, artificial neural networks are used to model the non-linear operations of a key site facility: a tower crane — for high-rise public housing construction. Then genetic algorithms are used to determine the locations of the tower crane, supply points and demand points by optimizing the transportation time and costs. The scope of this study confines to a defined area of construction: the structural concrete-frame construction stage of public housing projects. The developed genetic algorithm model for site facility layout and the artificial neural network model for predicting tower-crane operations are evaluated using a practical example. The optimization results of the example are very promising and it demonstrates the application value of the models. Journal: Construction Management and Economics Pages: 257-266 Issue: 3 Volume: 21 Year: 2003 Keywords: Site Layout, Genetic Algorithms, Tower Crane, Public Housing Construction, X-DOI: 10.1080/0144619032000049665 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000049665 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:3:p:257-266 Template-Type: ReDIF-Article 1.0 Author-Name: Jakrapong Pongpeng Author-X-Name-First: Jakrapong Author-X-Name-Last: Pongpeng Author-Name: John Liston Author-X-Name-First: John Author-X-Name-Last: Liston Title: Contractor ability criteria: a view from the Thai construction industry Abstract: Realizing that there is a lack of commonality in selecting criteria to evaluate contractor ability, the study aim was to develop a common set of contractor ability criteria for both government and private sectors. This included a standardized set of physical characteristics (hierarchical organizational units) of contractors. The Thai construction industry was surveyed as to the degrees of importance placed on a range of criteria and measures. Similarities and differences between the government and private sectors in selecting contractor ability criteria have been analysed by comparing the importance index and ranking order and comparing mean importance placed on criteria and measures. Relationships between all criteria and measures have also been explored by using correlation coefficients. Factor analysis has been applied to group all highly correlated measures together so as to develop a common set of contractor ability criteria. The result of analysing similarities and differences indicated only slight differences in the mean importance of criteria and measures between the government and private sectors. Thus, a common set of contractor ability criteria has been developed by applying factor analysis, namely, 'engineering/construction', 'procurement/contract', 'project managers', 'human resources', 'quality management systems', 'health and safety', 'plant/equipment', 'financial strength' and 'public relations'. Journal: Construction Management and Economics Pages: 267-282 Issue: 3 Volume: 21 Year: 2003 Keywords: Contractor Ability Criteria, Contractor Ability, Thai Construction Industry, Prequalification, Factor Analysis, X-DOI: 10.1080/0144619032000049647 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000049647 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:3:p:267-282 Template-Type: ReDIF-Article 1.0 Author-Name: Mohamed El-Haram Author-X-Name-First: Mohamed Author-X-Name-Last: El-Haram Author-Name: R. Malcolm Author-X-Name-First: R. Author-X-Name-Last: Malcolm Author-Name: W. Horner Author-X-Name-First: W. Author-X-Name-Last: Horner Title: Application of the principles of ILS to the development of cost effective maintenance strategies for existing building stock Abstract: Total spending on building maintenance in the UK has increased by 66% in the last 10 years (BMI, 1996). Total expenditure on maintenance in 1997 was £39.8 billion (BMI, 1998). Any significant reduction in building maintenance costs will therefore have a real impact on the national economy. This paper reports the results of a research project supported by the EPSRC at the University of Dundee, which sought to quantify the benefits of applying integrated logistics support (ILS) to the development of cost-effective maintenance strategies for existing building stock. ILS is a managerial and technical approach that ensures that the client/user will receive a building that will meet performance requirements (durability, reliability, maintainability, performance, etc.) at the lowest whole life cost. The principles of ILS are described and a systematic framework for selecting the most appropriate and cost-effective maintenance task for each individual element in a building is developed. The decision logic processes for identifying each failure consequence and for selecting the most applicable and cost-effective maintenance task are derived. The maintenance cost savings arising from the application of two ILS techniques - failure modes and effects analysis, and reliability centred maintenance - to a sample of 18 properties were calculated to be 18.5%. Journal: Construction Management and Economics Pages: 283-296 Issue: 3 Volume: 21 Year: 2003 Keywords: Integrated Logistics Support, Maintenance Strategy, Failure Consequences, Whole Life Costs, X-DOI: 10.1080/0144619032000093774 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000093774 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:3:p:283-296 Template-Type: ReDIF-Article 1.0 Author-Name: Takayuki Minato Author-X-Name-First: Takayuki Author-X-Name-Last: Minato Title: Representing causal mechanism of defective designs: a system approach considering human errors Abstract: Reducing design defects by proactive actions requires comprehensive understanding of how and why they happen. To achieve this, it is necessary to know the causal relationships of inherent factors, by which design defects arise. This paper represents a causal mechanism of defective design occurrence by considering interactions of underlying factors in designing process. The mechanism draws on the system approach to human errors to describe defects in design caused by designers' active failuresand failures of design reviews as defences to catch defects. It portrays the causal process of the failures with workplace factors and organizational factors as influencing factors. Workplace factors arise from designers' working conditions and include internal and external factors to the actors. Organizational factors comprise elements due to client and designer company's conditions. Then, two failure pathways are discussed to show how the factors lead to design defects. Two case studies are presented in this paper to clarify and explain the mechanism. Journal: Construction Management and Economics Pages: 297-305 Issue: 3 Volume: 21 Year: 2003 Keywords: Active Failures, Defective Design, Defences Failures, Human Error, Latent Factors, Mechanism, System Approach, X-DOI: 10.1080/0144619032000056135 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000056135 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:3:p:297-305 Template-Type: ReDIF-Article 1.0 Author-Name: Mohammed Fadhil Dulaimi Author-X-Name-First: Mohammed Fadhil Author-X-Name-Last: Dulaimi Author-Name: Florence Ling Author-X-Name-First: Florence Author-X-Name-Last: Ling Author-Name: Arun Bajracharya Author-X-Name-First: Arun Author-X-Name-Last: Bajracharya Title: Organizational motivation and inter-organizational interaction in construction innovation in Singapore Abstract: This paper examines the individual firm's motivation to adopt innovation in a construction project, and the inter-organizational interactions of relevant parties involved in innovation. Based on the theory of organizational motivation and inter-organizational relationships, seven hypotheses are set out. These hypotheses are tested using a structured questionnaire, and data were collected via a postal survey. From the results, it is concluded that an innovative proposal may be successfully implemented in the project if effort is put into carrying the innovation through, and there are high expected goals, favourable,results and high commitment. Firms need to be motivated to adopt the innovation, be optimistic about the results and exert additional effort. Incentives for the supporting parties need to be substantial to persuade them to participate in the innovation. In addition, the innovation should be designed such that it could draw all upstream and downstream parties together, and all their interests are looked after in the project. Journal: Construction Management and Economics Pages: 307-318 Issue: 3 Volume: 21 Year: 2003 Keywords: Construction Innovation, Organizational Motivation, Inter-organizational Interaction, Origin Organization, Support Organization, X-DOI: 10.1080/0144619032000056144 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000056144 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:3:p:307-318 Template-Type: ReDIF-Article 1.0 Author-Name: Roberto Pietroforte Author-X-Name-First: Roberto Author-X-Name-Last: Pietroforte Author-Name: Tullio Gregori Author-X-Name-First: Tullio Author-X-Name-Last: Gregori Title: An input-output analysis of the construction sector in highly developed economies Abstract: Using OECD input/output tables at current and constant prices, this paper analyses the performance of the construction sector of eight highly industrialized countries - Australia, Canada, Denmark, France, Germany, The Netherlands, Japan and the USA - in the 1970s and 1980s. First, the main characteristics of the data set with country and time coverage are briefly introduced. Then, a set of simple indicators is used for comparative purposes, namely to assess the construction sector's diminishing role in terms of share in gross output, value added and GNP. Analysis focuses also on technologies, with emphasis on the relative role of manufacturing and services inputs. Lastly, standard measures of linkages are used to determine the main sources of induced output that are created by the push and pull effects of the construction sector on the rest of the economy. Journal: Construction Management and Economics Pages: 319-327 Issue: 3 Volume: 21 Year: 2003 Keywords: Construction Technologies, Input/Output Analysis, Constant Prices, Linkages, X-DOI: 10.1080/0144619032000056153 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000056153 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:3:p:319-327 Template-Type: ReDIF-Article 1.0 Author-Name: Tullio Gregori Author-X-Name-First: Tullio Author-X-Name-Last: Gregori Title: Book Review Abstract: Journal: Construction Management and Economics Pages: 329-329 Issue: 3 Volume: 21 Year: 2003 X-DOI: 10.1080/0144619032000085052 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000085052 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:3:p:329-329 Template-Type: ReDIF-Article 1.0 Author-Name: Tullio Gregori Author-X-Name-First: Tullio Author-X-Name-Last: Gregori Title: Forthcoming events Abstract: Journal: Construction Management and Economics Pages: 331-332 Issue: 3 Volume: 21 Year: 2003 X-DOI: 10.1080/713763936 File-URL: http://www.tandfonline.com/doi/abs/10.1080/713763936 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:3:p:331-332 Template-Type: ReDIF-Article 1.0 Author-Name: Tullio Gregori Author-X-Name-First: Tullio Author-X-Name-Last: Gregori Title: Authors' Charter Abstract: Journal: Construction Management and Economics Pages: 333-333 Issue: 3 Volume: 21 Year: 2003 X-DOI: 10.1080/0144619032000093783 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000093783 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:3:p:333-333 Template-Type: ReDIF-Article 1.0 Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Title: Editorial Abstract: Journal: Construction Management and Economics Pages: 335-336 Issue: 4 Volume: 21 Year: 2003 X-DOI: 10.1080/0144619032000111223 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000111223 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:4:p:335-336 Template-Type: ReDIF-Article 1.0 Author-Name: Rob Shields Author-X-Name-First: Rob Author-X-Name-Last: Shields Author-Name: Kevin West Author-X-Name-First: Kevin Author-X-Name-Last: West Title: Innovation in clean-room construction: a case study of co-operation between firms Abstract: This study examines partnering between a large client, multinational contractors and specialist suppliers, and local subcontractors involved in a project to construct clean room facilities. An ethnographic approach is used, which demonstrates the changing attitudes, values and the new working arrangements that emerged. The social bond of a 'construction challenge' was the basis of trust and sharing risk in a 'quasi-fixed network'. In place of formal contracts, ongoing bargaining and continuous negotiation took place. However, the client was seen to dominate the construction process. Shared workspaces or 'liminal zones', betwixt and between firms, were created to allow collaboration. These are argued to be a practical organizational approach to sharing information and co-ordinating inter-firm activities. Among trades, agreements were struck to exchange training and apprenticeships for allowing foreign specialists and equipment to be imported by the high-purity gas supplier. Liminal zones appear to function as on-the-job classrooms for rapidly training workers in unfamiliar construction techniques and systems. Journal: Construction Management and Economics Pages: 337-344 Issue: 4 Volume: 21 Year: 2003 Keywords: Clean Rooms, Inter-organizational Innovation, Quasi-fixed Network, Risk, Partnering, Labour Relations, Canada, X-DOI: 10.1080/0144619032000111232 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000111232 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:4:p:337-344 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Horsley Author-X-Name-First: Andrew Author-X-Name-Last: Horsley Author-Name: Chris France Author-X-Name-First: Chris Author-X-Name-Last: France Author-Name: Barry Quatermass Author-X-Name-First: Barry Author-X-Name-Last: Quatermass Title: Delivering energy efficient buildings: a design procedure to demonstrate environmental and economic benefits Abstract: One of the most significant environmental impacts of buildings occurs through the consumption of energy during their operational lives. It is a well-known fact that buildings in the UK are only a fraction as efficient as current approaches and available technologies permit. The effective management of the design process is pivotal in the delivery of buildings with improved energy efficiency but, despite this, the monitoring of energy performance is not currently a typical part of the construction design process. This paper describes the development of a design management procedure in which energy performance is monitored from the earliest phases of building inception. The decision support tool gives guidance to design teams at a stage in the design process where there is currently a lack of information on project-specific energy performance issues, and their environmental and economic implications. Life cycle cost performance is captured through elemental life cycle costing, in which the implementation of systems to improve efficiency are considered as a function of additional and avoided life cycle costs. This procedure has been developed through public-sector private finance initiative (PFI) projects, which allow a longer-term view of both capital and operating costs, since the contractors are an integral part of the long-term management consortium. The much greater level of opportunity presented in these contracts and the potential to influence the wider marketplace could offer a breakthrough for the wider acceptance of environmentally sensitive building design. Journal: Construction Management and Economics Pages: 345-356 Issue: 4 Volume: 21 Year: 2003 Keywords: Energy Efficiency, Life Cycle Costing, Building Design, Private Finance Initiative, Sustainable Construction, X-DOI: 10.1080/0144619032000073505 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000073505 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:4:p:345-356 Template-Type: ReDIF-Article 1.0 Author-Name: Alex Eyiah Author-X-Name-First: Alex Author-X-Name-Last: Eyiah Author-Name: Paul Cook Author-X-Name-First: Paul Author-X-Name-Last: Cook Title: Financing small and medium-scale contractors in developing countries: a Ghana case study Abstract: Little success has been achieved in financing assistant programmes for contractors in developing countries. This paper focuses on the experience of the Bank for Housing and Construction (BHC) of Ghana. Factors accountable for underachievement of its programme include: contractor's lack of managerial and technical capability; inability to obtain contracts; persistent delayed payments by major clients; and the deliberate refusal to repay loans. Suggestions offered for improving the effectiveness of programmes, on the academic and practical front, relate well with developments in small and medium-size enterprise (SME) finance. A survey in Ghana found that there was a strong desire to establish a contractors' bank. There would be the need for the contractors association to reform before it could play a meaningful role in the proposed bank. The importance of effective governance in achieving success cannot be overemphasized, likewise the role of government and donors in encouraging the setting up of a conducive regulatory framework. Journal: Construction Management and Economics Pages: 357-367 Issue: 4 Volume: 21 Year: 2003 Keywords: Developing Countries, Ghana, Contractors, Sme, Finance, X-DOI: 10.1080/0144619032000111241 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000111241 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:4:p:357-367 Template-Type: ReDIF-Article 1.0 Author-Name: Enrique Claver Author-X-Name-First: Enrique Author-X-Name-Last: Claver Author-Name: Jose Molina Author-X-Name-First: Jose Author-X-Name-Last: Molina Author-Name: Juan Tari Author-X-Name-First: Juan Author-X-Name-Last: Tari Title: Strategic groups and firm performance: the case of Spanish house-building firms Abstract: A central theme in strategic management is the theoretical relationship between strategic groups and firm performance. However, the empirical evidence is conflicting. The aim of this research is to study this linkage by examining business strategies in the Spanish construction industry. This paper defines several groups based on Porter's generic strategies of 88 house-building firms, and studies performance differences between groups. The empirical findings demonstrate that significant differences in performance do not exist among groups. Implications of this research for Porter's generic strategies in construction are then discussed. Journal: Construction Management and Economics Pages: 369-377 Issue: 4 Volume: 21 Year: 2003 Keywords: Construction Industry, Strategic Groups, Firm Performance, Competitive Strategy, X-DOI: 10.1080/0144619032000111250 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000111250 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:4:p:369-377 Template-Type: ReDIF-Article 1.0 Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Title: Frameworks for analysing international construction Abstract: The international construction market is subject to many dynamic influences that can lead to changes in the volume, mix and distribution of demand and sources of competitiveness. The international construction firm faces several problems: physical, technological, financial, legal, socio-cultural and political. It is important that factors that contribute to the success of firms in this market are clearly understood. This paper considers relevant aspects of international construction. The international performance of construction firms in middle- and low-income countries is compared. The applicability of various analytical frameworks to international construction is then examined. Finally, the implications for future research are considered. Journal: Construction Management and Economics Pages: 379-391 Issue: 4 Volume: 21 Year: 2003 Keywords: Overseas Construction, Competitiveness, Conceptual Frameworks, Research Agenda, X-DOI: 10.1080/0144619032000049746 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000049746 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:4:p:379-391 Template-Type: ReDIF-Article 1.0 Author-Name: A. V. Thomas Author-X-Name-First: A. V. Author-X-Name-Last: Thomas Author-Name: Satyanarayana Kalidindi Author-X-Name-First: Satyanarayana Author-X-Name-Last: Kalidindi Author-Name: K. Ananthanarayanan Author-X-Name-First: K. Author-X-Name-Last: Ananthanarayanan Title: Risk perception analysis of BOT road project participants in India Abstract: Despite massive investment opportunities and the establishment of a framework for private sector participation in highway infrastructure development programmes in India, private investment (including foreign direct investment) in this sector is not up to the expected level. A high degree of risk exposure, disagreement on many risk issues among major stakeholders, and the absence of adequate government guarantees have been identified as some of the major reasons for this lukewarm response. This paper discusses the outcome of a risk perception analysis carried out to evaluate the risk criticality, risk management capability, risk allocation/sharing preference, and factors influencing risk acceptance of major stakeholders. A survey was conducted among senior project participants such as government officials, promoters, lenders and consultants of Indian BOT road projects. Eight types of risks have been identified as very critical in the Indian road sector under BOT set up with traffic revenue risk being the most critical. Though there is fair agreement among survey respondents with respect to the risk management capabilities of stakeholders, their preferences of allocations are divergent. The significant factors influencing the risk acceptance of each stakeholder are identified through regression analysis. The study reveals that the factors and their relative influence on the risk acceptance of stakeholders are considerably different. Journal: Construction Management and Economics Pages: 393-407 Issue: 4 Volume: 21 Year: 2003 Keywords: Highway Infrastructure, Bot Projects, Risk Perception, Risk Criticality, Risk Allocation, Risk Acceptance, Regression, Traffic Revenue Risk, India, X-DOI: 10.1080/0144619032000064127 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000064127 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:4:p:393-407 Template-Type: ReDIF-Article 1.0 Author-Name: Sudong Ye Author-X-Name-First: Sudong Author-X-Name-Last: Ye Author-Name: Robert Tiong Author-X-Name-First: Robert Author-X-Name-Last: Tiong Title: Tariff adjustment frameworks for privately financed infrastructure projects Abstract: Since privately financed infrastructure (PFI) projects are usually natural monopolies, their tariffs should be regulated to ensure socially desirable outcomes. In reality, the regulation is usually realized through tariff adjustment mechanisms. There are four basic tariff adjustment frameworks for PFI projects - adjustment based on sale price, revenue, operating income and profit after tax. They have different risk exposures and incentives. The adjustment based on the sale price provides the project company with the highest potential to increase profit but exposes it to the highest risk, while the adjustment based on the guaranteed ROR exposes the project company to the lowest risk but provides the least potential for increasing profit. Adjustments based on the revenue or the operating income are somewhere in between. In practice, a hybrid of two or more adjustment frameworks may be adopted to adapt to specific project environments. A well-designed tariff adjustment framework can create a 'win-win' solution for both the public and private sectors. Journal: Construction Management and Economics Pages: 409-419 Issue: 4 Volume: 21 Year: 2003 Keywords: Regulation, Tariff Adjustment Framework, Privately Financed Infrastructure, Bot, Risk Management, X-DOI: 10.1080/0144619032000073550 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000073550 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:4:p:409-419 Template-Type: ReDIF-Article 1.0 Author-Name: Michael Pitt Author-X-Name-First: Michael Author-X-Name-Last: Pitt Author-Name: Andrew Smith Author-X-Name-First: Andrew Author-X-Name-Last: Smith Title: An assessment of waste management efficiency at BAA airports Abstract: The issue of waste management within airports is becoming increasingly important with enormous increases in passenger numbers and is a key responsibility of the facilities manager. Airports are notoriously poor environmental performers and this growth in the industry is leading to increasing levels of waste production. The purpose of this paper is to assess the efficiency of waste management operations at BAA airports, with reference to best practices within airports in continental Europe. The paper presents the findings of a survey of waste management methods in a sample of UK airports. The analysis of numerical data is based on those airports in the BAA group. Many of these are among the busiest airports in Britain, and Heathrow and Gatwick are two of the world's busiest. Data constraints prevented a more detailed analysis of other airports outside BAA. The paper highlights some difficulties in measuring BAA's waste management efficiency based on the waste hierarchy and concludes that some European airports have achieved greater efficiency in waste management. The situation is now changing though and BAA is taking environmental management seriously. However, a more co-ordinated approach to environmental strategy is needed across the industry and this is best produced at government level. Journal: Construction Management and Economics Pages: 421-431 Issue: 4 Volume: 21 Year: 2003 Keywords: Airports, Facilities Management, Environment, Recycling, Waste, X-DOI: 10.1080/0144619032000089599 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000089599 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:4:p:421-431 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Smith Author-X-Name-First: Andrew Author-X-Name-Last: Smith Title: Book Reviews Abstract: Journal: Construction Management and Economics Pages: 433-437 Issue: 4 Volume: 21 Year: 2003 X-DOI: 10.1080/0144619032000072119 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000072119 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:4:p:433-437 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Smith Author-X-Name-First: Andrew Author-X-Name-Last: Smith Title: Forthcoming Events Abstract: Journal: Construction Management and Economics Pages: 439-440 Issue: 4 Volume: 21 Year: 2003 X-DOI: 10.1080/0144619032000111278 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000111278 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:4:p:439-440 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Smith Author-X-Name-First: Andrew Author-X-Name-Last: Smith Title: Authors' Charter Abstract: Journal: Construction Management and Economics Pages: 441-441 Issue: 4 Volume: 21 Year: 2003 X-DOI: 10.1080/0144619032000111269 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000111269 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:4:p:441-441 Template-Type: ReDIF-Article 1.0 Author-Name: A. Warszawski Author-X-Name-First: A. Author-X-Name-Last: Warszawski Title: Parametric analysis of the financing cost in a building project Abstract: A parametric model is presented for the evaluation of financing cost in a construction project. The cost can be assessed at a very early stage of the project's design. The main parameters that are examined are the duration of the project, its pattern of cost and sales distribution, the cost of owner's equity capital and of external debt. Three financing options are examined and their effect on the financing cost is evaluated. The influence on the cost of financing of the main decision variables, such as the construction duration or the profit margin, is also examined. Journal: Construction Management and Economics Pages: 447-459 Issue: 5 Volume: 21 Year: 2003 Keywords: Financing, construction, construction project, loan, credit line, construction loan, X-DOI: 10.1080/0144619032000049638 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000049638 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:5:p:447-459 Template-Type: ReDIF-Article 1.0 Author-Name: Akintola Akintoye Author-X-Name-First: Akintola Author-X-Name-Last: Akintoye Author-Name: Cliff Hardcastle Author-X-Name-First: Cliff Author-X-Name-Last: Hardcastle Author-Name: Matthias Beck Author-X-Name-First: Matthias Author-X-Name-Last: Beck Author-Name: Ezekiel Chinyio Author-X-Name-First: Ezekiel Author-X-Name-Last: Chinyio Author-Name: Darinka Asenova Author-X-Name-First: Darinka Author-X-Name-Last: Asenova Title: Achieving best value in private finance initiative project procurement Abstract: The wherewithal of achieving best value in private finance initiative (PFI) projects and the associated problems therein are documented. In the UK, PFI has offered a solution to the problem of securing necessary investment at a time of severe public expenditure restraint. In PFI schemes, the public sector clients must secure value for money, while the private sector service providers must genuinely assume responsibility for project risks. A broad-based investigation into PFI risk management informs the discussion in this paper. It is based on 68 interviews with PFI participants and a case study of eight PFI projects. The research participants comprised of contractors, financial institutions, public sector clients, consultants and facilities management organizations. The qualitative software Atlas.ti was used to analyse the textual data generated. The analysis showed that the achievement of best value requirements through PFI should hinge on: detailed risk analysis and appropriate risk allocation, drive for faster project completion, curtailment in project cost escalation, encouragement of innovation in project development, and maintenance cost being adequately accounted for. Factors that continue to challenge the achievement of best value are: high cost of the PFI procurement process, lengthy and complex negotiations, difficulty in specifying the quality of service, pricing of facility management services, potential conflicts of interests among those involved in the procurement, and the public sector clients' inability to manage consultants. Journal: Construction Management and Economics Pages: 461-470 Issue: 5 Volume: 21 Year: 2003 Keywords: Best value, risk management, procurement, facilities management, qualitative research, financial institution, risk allocation, value for money, X-DOI: 10.1080/0144619032000087285 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000087285 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:5:p:461-470 Template-Type: ReDIF-Article 1.0 Author-Name: Sudong Ye Author-X-Name-First: Sudong Author-X-Name-Last: Ye Author-Name: Robert Tiong Author-X-Name-First: Robert Author-X-Name-Last: Tiong Title: The effect of concession period design on completion risk management of BOT projects Abstract: The design of concession period for build-operate-transfer (BOT) projects is crucial to financial viability and completion risk management. A systematic analysis shows that concession period design involves the design of concession period structure, the determination of the concession period length and incentive schemes. The concession period may have a single-period structure or a two-period structure, its length may be fixed or variable, and it may be combined with incentive schemes. Different designs reflect different risk control strategies for completion time overruns. The single-period concession structure requires the project company to assume completion risk, while the two-period concession structure could, to some extent, reduce the completion risk exposure to the project company, depending on the incentive schemes. Through Monte Carlo simulation, this paper evaluates the mean net present value (NPV), variance and NPV-at-risk of different concession period structures so that both the government and the concessionaires can understand their risk exposure and rewards. The paper then analyses the influence of project characteristics on concession period design to evaluate the feasibility of the design. It is concluded that a well-designed concession period structure can create a 'win-win' solution for both project promoter and the host government. Journal: Construction Management and Economics Pages: 471-482 Issue: 5 Volume: 21 Year: 2003 Keywords: Concession period structure, incentive scheme, privately financed infrastructure, BOT, completion risk management, simulation, X-DOI: 10.1080/0144619032000073488 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000073488 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:5:p:471-482 Template-Type: ReDIF-Article 1.0 Author-Name: Farzad Khosrowshahi Author-X-Name-First: Farzad Author-X-Name-Last: Khosrowshahi Author-Name: Amir Alani Author-X-Name-First: Amir Author-X-Name-Last: Alani Title: A model for smoothing time-series data in construction Abstract: The understanding of the behaviour of time-series data has been a matter of concern to researchers and practitioners in a variety of fields ranging from social science and economics to engineering. Also, the behaviour of many phenomena within fields relating and peripheral to construction is described as a time series. Typically, the time-series analysis is carried out in order to forecast the future values of the series. These techniques, however, are also used to abstract the generalities within the series, hence facilitating the replication of the entire profile, reflecting only the main characteristics of the profile. There is a variety of techniques that can be applied to a set of time-related data. The choice of the technique is, therefore, dependent on the nature of the problem and the characteristics of the data. The diversity of available techniques is, on the one hand an advantage for all analysts. However, this diversity is also an indication that there is no universal technique that is applicable to a diversity of time-series data. This work fundamentally addresses the issue of smoothing and curve-fitting techniques rather than predicting and forecasting. A technique is offered which is tested against a set of criteria that are designed to focus on the accuracy of imitation and the practicality of operation: the ability to deal with a large number of time-series sets of data in a consistent, replicable and automated way. The viability of the technique is demonstrated by its application to expenditure profiles of a large number of construction projects. The size of the sample and the diversity in the profiles of the expenditure patterns provided an appropriate testing ground for the universality of the model. The results indicated that the model can effectively transform a jagged time series into a smooth pattern, while complying with a set of criteria many of which are common to several other research works relating to time-series data analysis. The proposed technique sequences a number of basic smoothing methods and the process involves the treatment and incorporation of the residual values. Journal: Construction Management and Economics Pages: 483-494 Issue: 5 Volume: 21 Year: 2003 Keywords: Smoothing, forecasting, time series, project expenditure pattern, X-DOI: 10.1080/0144619032000073541 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000073541 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:5:p:483-494 Template-Type: ReDIF-Article 1.0 Author-Name: M. F. Ng Author-X-Name-First: M. F. Author-X-Name-Last: Ng Author-Name: V. M. Rao Tummala Author-X-Name-First: V. M. Rao Author-X-Name-Last: Tummala Author-Name: Richard Yam Author-X-Name-First: Richard Author-X-Name-Last: Yam Title: A risk-based maintenance management model for toll road/tunnel operations Abstract: Preventive maintenance (PM) has long been recognized as a method to increase equipment reliability and availability. However, for equipment in complex plant installations like toll road/tunnel systems, to carry out PM on all components may not be feasible, or, may end up with excessive maintenance costs. This paper describes how a risk-based maintenance management model was formulated to systematically prioritize PM activities. The model was based on the five core elements of the risk management process (RMP): identification, measurement, assessment, valuation, and control and monitoring. This model was applied to a toll road/tunnel company in Hong Kong to enhance the PM operations of its lighting system. The improvements recommended in this case study show that the application of RMP in preventive maintenance could effectively identify and assess potential risks for equipment and facilities. The RMP results provide quantified information for decision-makers to select the best course of actions for implementing a more cost-effective risk-based PM system. Journal: Construction Management and Economics Pages: 495-510 Issue: 5 Volume: 21 Year: 2003 Keywords: Risk management process, preventive maintenance, toll road/tunnel, operations, X-DOI: 10.1080/0144619032000089616 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000089616 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:5:p:495-510 Template-Type: ReDIF-Article 1.0 Author-Name: Hans Voordijk Author-X-Name-First: Hans Author-X-Name-Last: Voordijk Author-Name: Arjen Van Leuven Author-X-Name-First: Arjen Author-X-Name-Last: Van Leuven Author-Name: Albertus Laan Author-X-Name-First: Albertus Author-X-Name-Last: Laan Title: Enterprise Resource Planning in a large construction firm: implementation analysis Abstract: In most large Dutch construction firms, Enterprise Resource Planning (ERP) systems have replaced non-integrated information systems with integrated and maintainable software. The implementation of ERP systems in such firms is a difficult task. So far, ERP implementations have yielded more failures than successes. This study tries to understand the factors that lead to the success or failure of ERP in large construction firms by focusing on the fits between the following pairs of elements in ERP implementations: business and IT strategy, maturity of the IT infrastructure and the strategic role of IT, and the implementation method and organizational change. The premise of this study is that for an ERP implementation to be successful these elements must somehow fit together. Empirical research was conducted through a case study of three ERP implementations in different business units of a Dutch-based construction firm. Implementing different systems within one company is typical of the way large construction firms in the Netherlands have dealt with ERP. The study shows that the success of ERP implementations depends on consistent patterns between: IT strategy and business strategy, IT maturity and the strategic role of IT, and the implementation method and organizational change. Journal: Construction Management and Economics Pages: 511-521 Issue: 5 Volume: 21 Year: 2003 Keywords: Enterprise Resource Planning, construction, information technology, X-DOI: 10.1080/0144619032000072155 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000072155 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:5:p:511-521 Template-Type: ReDIF-Article 1.0 Author-Name: Albert Chan Author-X-Name-First: Albert Author-X-Name-Last: Chan Author-Name: Daniel Chan Author-X-Name-First: Daniel Author-X-Name-Last: Chan Author-Name: Kathy Ho Author-X-Name-First: Kathy Author-X-Name-Last: Ho Title: An empirical study of the benefits of construction partnering in Hong Kong Abstract: Many construction companies have adopted partnering in their construction projects over the past 10-15 years due to favourable project outcomes achieved. Its use in construction projects has been increasing rapidly as its benefits become more apparent and pervasive. This paper reviews the partnering literature within the construction field and tries to portray the comprehensive picture of benefits for the partnering practice. Through partnering and the active involvement of all key project parties, the project is more likely to be completed within budget, on time, and with the least number of conflicts, claims and work defects. Also, this paper reports upon the findings of a questionnaire survey of partnering benefits in Hong Kong. Seventy-eight project participants completed a questionnaire to indicate the relative importance of partnering benefits. The perceived benefits were measured and ranked from the perspectives of the client, contractor and consultant for cross-comparison. The results revealed that 'Improved relationship amongst project participants', 'Improved communication amongst project participants' and 'More responsive to the short-term emergency, changing project or business needs' were the most significant benefits derived from the use of partnering. More partnering arrangements should be actively introduced into the construction procurement process so that every party can enjoy the full benefits of partnering. Journal: Construction Management and Economics Pages: 523-533 Issue: 5 Volume: 21 Year: 2003 Keywords: Partnering, benefits, construction projects, Hong Kong, X-DOI: 10.1080/0144619032000056162 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000056162 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:5:p:523-533 Template-Type: ReDIF-Article 1.0 Author-Name: Mohammad Ammar Author-X-Name-First: Mohammad Author-X-Name-Last: Ammar Title: Float analysis of non-serial repetitive activities Abstract: Floats and critical path(s) are important issues in construction management practice. In critical path method, activities not on the critical path(s) must have float. Float measures the amount of time an activity can be delayed before it becomes critical. Consecutive repetitive activities have production rates, which may vary considerably from one activity to another. This creates a different situation (from traditional non-repetitive activities) such that repetitive activities may have rate float, in addition to time float. In this paper, a proposed model for determining different types of floats for non-serial repetitive activities is developed. The traditional concept of time float is extended to repetitive activities. Rate float, which is an inherent property of repetitive activities, is also determined. Float analysis is performed in a very similar way to Critical Path Method (CPM) analysis, without the need for graphical aids. The analysis is based on a repetitive scheduling method, which utilizes a traditional CPM network of a typical unit, in which overlapping activities are used to model repetitive activities. A constant activity production rate is assumed and resource continuity is maintained. The method for determining time floats (total and free) and the rate float of non-critical activities and of non-controlling segments of controlling activities is described in detail. The proposed model was automated by a macro-program, which has been coded on a commercial scheduling software to facilitate float determination. Journal: Construction Management and Economics Pages: 535-542 Issue: 5 Volume: 21 Year: 2003 Keywords: Construction management, scheduling, CPM, non-serial repetitive activities, controlling path, time and rate floats, X-DOI: 10.1080/0144619032000073523 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000073523 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:5:p:535-542 Template-Type: ReDIF-Article 1.0 Author-Name: David Gann Author-X-Name-First: David Author-X-Name-Last: Gann Title: Guest editorial: innovation in the built environment Abstract: Journal: Construction Management and Economics Pages: 553-555 Issue: 6 Volume: 21 Year: 2003 X-DOI: 10.1080/0144619032000134084 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000134084 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:6:p:553-555 Template-Type: ReDIF-Article 1.0 Author-Name: Ritsuko Ozaki Author-X-Name-First: Ritsuko Author-X-Name-Last: Ozaki Title: Customer-focused approaches to innovation in housebuilding Abstract: Customer focus has become a catch phrase not only in the service industry but also in the housebuilding industry. Furthermore, UK speculative housebuilders have increasingly been searching for ways to be more customer focused. This study, through an analysis of the concept of customer satisfaction in the service industry, identifies three key aspects in customer focus that may be applied to the housebuilding industry: good service, customized house design on top of quality products, and good information flows between customers and the housebuilder and within the company. This paper explores how these key issues are dealt with in UK speculative housebuilding in two empirical studies to search for ways forward. Journal: Construction Management and Economics Pages: 557-564 Issue: 6 Volume: 21 Year: 2003 Keywords: Customer satisfaction, good service, good communication, customized house design, X-DOI: 10.1080/0144619032000134093 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000134093 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:6:p:557-564 Template-Type: ReDIF-Article 1.0 Author-Name: Jennifer Whyte Author-X-Name-First: Jennifer Author-X-Name-Last: Whyte Title: Innovation and users: virtual reality in the construction sector Abstract: Firms in the construction sector act as users of technologies produced outside the sector. This paper considers their role as users and explores their contribution to the 're-innovation' of an emerging information technology - virtual reality. An empirical study of virtual reality use within the construction sector has been conducted using the multiple case study method. Data was collected within 11 lead-user organizations (and four suppliers) and emerging patterns of use are explored. An analytic framework is developed to investigate how two aspects of project-based construction processes - project size and extent of design reuse - affect the technological requirements of users. Divergent requirements are found for the use of virtual reality on different types of projects and, through supplier interaction, these may lead to different families of solutions. Journal: Construction Management and Economics Pages: 565-572 Issue: 6 Volume: 21 Year: 2003 Keywords: Information technology, virtual reality, construction, users, innovation, X-DOI: 10.1080/0144619032000113690 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000113690 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:6:p:565-572 Template-Type: ReDIF-Article 1.0 Author-Name: Ammon Salter Author-X-Name-First: Ammon Author-X-Name-Last: Salter Author-Name: Richard Torbett Author-X-Name-First: Richard Author-X-Name-Last: Torbett Title: Innovation and performance in engineering design Abstract: This paper explores the experiences of engineering, design and construction organizations (EDOs) in developing innovative approaches to performance measurement in their design activities. It contrasts experiences of these firms with those of manufacturing organizations. It finds that performance measurement of engineering design activities is poorly understood in many industries, including construction. The development of new performance measures can provide a new opportunity for innovation in engineering, design and construction firms. At present, the measures used to assess design in construction are based on the financial performance of a project rather than other important objectives of the design process, such as quality and buildability. In manufacturing industries, firms rely on measures of new product development, but these indicators also say little about the measurement of engineering design activities, that is, those on-going and continuous. To realize the innovative potential of design and performance measures, EDOs need to take a broader perspective on the nature of design activities, and to look to the experiences of leading manufacturing firms to find new ways of measuring and understanding their design activities. Journal: Construction Management and Economics Pages: 573-580 Issue: 6 Volume: 21 Year: 2003 Keywords: Innovation, design, performance measurement, engineering, design and construction organizations, manufacturing, X-DOI: 10.1080/0144619032000134101 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000134101 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:6:p:573-580 Template-Type: ReDIF-Article 1.0 Author-Name: Denis Towill Author-X-Name-First: Denis Author-X-Name-Last: Towill Title: Construction and the time compression paradigm Abstract: The total cycle time (TCT) compression paradigm has already come of age in many market sectors, and is widely seen as the route whereby companies attain international competitiveness. However, it is essential that the relevant business processes are skilfully re-engineered to compress total cycle time if the potential benefits of implementing the paradigm are to be achieved in full. As the paper shows, reducing TCT in this way improves all the important business performance metrics. The paper concludes by describing the T40 construction programme, in which 25% cost reduction has been consistently achieved by re-engineering the relevant business process to compress total cycle times by 40%. Reduction in TCT achieved in this way does not compromise safety or quality. Journal: Construction Management and Economics Pages: 581-591 Issue: 6 Volume: 21 Year: 2003 Keywords: Total cycle time, business systems engineering, business processes, cost reduction, innovation in construction, X-DOI: 10.1080/0144619032000134110 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000134110 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:6:p:581-591 Template-Type: ReDIF-Article 1.0 Author-Name: Mohamed Naim Author-X-Name-First: Mohamed Author-X-Name-Last: Naim Author-Name: James Barlow Author-X-Name-First: James Author-X-Name-Last: Barlow Title: An innovative supply chain strategy for customized housing Abstract: There has recently been considerable interest in construction research in paradigms developed for the manufacturing sector. Using lean thinking and agile production as examples of innovative organizational and business process design, this paper explores their commonalities and differences. In this way, it is possible to judge which paradigm is the most appropriate for given market conditions. By presenting action research outputs from a project on the UK house-building industry, the paper indicates the potential application of both lean and agile construction from a supply chain perspective. The paper concludes that house-building supply chains have to be engineered according to whether the market objectives are low cost, flexibility or a combination of the two. Journal: Construction Management and Economics Pages: 593-602 Issue: 6 Volume: 21 Year: 2003 Keywords: Customization, house building, supply chain, lean and agile, process innovation, X-DOI: 10.1080/0144619032000134129 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000134129 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:6:p:593-602 Template-Type: ReDIF-Article 1.0 Author-Name: George Seaden Author-X-Name-First: George Author-X-Name-Last: Seaden Author-Name: Michael Guolla Author-X-Name-First: Michael Author-X-Name-Last: Guolla Author-Name: Jerome Doutriaux Author-X-Name-First: Jerome Author-X-Name-Last: Doutriaux Author-Name: John Nash Author-X-Name-First: John Author-X-Name-Last: Nash Title: Strategic decisions and innovation in construction firms Abstract: Current research on the process of innovation has focused attention on the crucial role of the business firm as the place where new ideas are developed and then implemented in the marketplace. Based on current knowledge, a model was developed which attempts to replicate the strategic decision-making process in a construction firm. It links perceived business environment variables to various business strategy variables (i.e. marketing, human resources and technology). These two sets of variables are linked to the innovativeness of the firm, measured by the number of advanced technologies and/or business practices currently used. Innovativeness is subsequently linked to outcomes (i.e. profitability, competitive advantage) to assess overall effectiveness. The model was tested empirically, using data from the Survey on Innovation, Advanced Technologies and Practices in the Construction and Related Industries carried out by Statistics Canada in 1999 with 1739 usable responses. The results generally support the proposed model; certain perceived business environment and business strategy variables are significantly related to firm innovativeness, however the link between innovativeness and outcomes requires further confirmation. Many construction firms introduce new approaches in information and construction technologies as well as in business practices. A large number of these were found to provide significant competitive advantage. In general, innovative behaviour varies with the size of the firm. Journal: Construction Management and Economics Pages: 603-612 Issue: 6 Volume: 21 Year: 2003 Keywords: Innovation, construction, business model, quantitative data, X-DOI: 10.1080/0144619032000134138 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000134138 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:6:p:603-612 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Sexton Author-X-Name-First: Martin Author-X-Name-Last: Sexton Author-Name: Peter Barrett Author-X-Name-First: Peter Author-X-Name-Last: Barrett Title: A literature synthesis of innovation in small construction firms: insights, ambiguities and questions Abstract: Construction firms are being challenged to be more adept at successful innovation to better meet client needs and to enhance business competitiveness. The substantial contribution that small construction firms make to the output of the industry signifies the importance for this body of firms to improve their innovation performance if the performance of the industry as a whole is to move forward. The literature on innovation in small construction firms is synthesized and structured around a generic model to provide a holistic picture of our current knowledge. Significant gaps in the understanding and practice of innovation in small construction literature are identified, which severely hamper understanding of the myriad complex and systemically interactive issues embodied within the theory and practice of innovation. The gaps identified by this literature synthesis are the basis for a number of important questions that, the authors propose, form an integrating agenda for future research. Journal: Construction Management and Economics Pages: 613-622 Issue: 6 Volume: 21 Year: 2003 Keywords: Construction, innovation, small firms, research agenda, X-DOI: 10.1080/0144619032000134147 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000134147 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:6:p:613-622 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Sexton Author-X-Name-First: Martin Author-X-Name-Last: Sexton Author-Name: Peter Barrett Author-X-Name-First: Peter Author-X-Name-Last: Barrett Title: Appropriate innovation in small construction firms Abstract: Innovation-led performance improvement in the construction industry is significantly influenced by the innovation performance of small firms. There is a dearth of research investigating innovation from the perspective of the small construction firm. This paper contributes to this underdeveloped area by offering relevant empirically based results. The findings stress the important role that owners of firms play in successful innovation. The type of innovation undertaken, and the different organizational factors which are brought into play, is shown to depend on the characteristics of the interaction environment in which the firm is operating. Small construction firms need to incrementally nurture, or identify and move into, supportive enabling interaction environments. This is achieved through an integrated development of a firm's business strategy and market positioning, organization of work, technology and people. The process of innovation is demonstrated to be subject to cyclical peaks and troughs as the progress of the innovation competes with day-to-day pressures. Small construction firms have their own distinctive characteristics, which are profoundly different from those of large construction firms. The implication for policy is that any initiatives geared toward improving appropriate innovation need to appreciate these differences. Journal: Construction Management and Economics Pages: 623-633 Issue: 6 Volume: 21 Year: 2003 Keywords: Construction, innovation, small firms, research results, X-DOI: 10.1080/0144619032000134156 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000134156 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:6:p:623-633 Template-Type: ReDIF-Article 1.0 Author-Name: Florence Yean Yng Ling Author-X-Name-First: Florence Yean Yng Author-X-Name-Last: Ling Title: Managing the implementation of construction innovations Abstract: This study investigates some factors that need to be considered in the management of innovation implementation within construction project organization. The main objective was to find explanatory variables that significantly affect the benefits of an innovation to project team members and the project as a whole. As part of a larger study on innovation in Singapore's construction industry, a survey was conducted and data from 58 projects that had adopted innovations in Singapore were collected via mailed questionnaire. The questionnaire requested respondents to provide specific data about their projects, the type of innovations adopted and the enablers and barriers to innovation. Four main categories of factors were found to significantly affect the extent to which an innovation will benefit project team members and the project. These are: the level of interest of project team members; working environment; formation of task groups; and the capabilities of the people involved in the innovation. Research questions relating to modelling innovation success are posed for further study. Journal: Construction Management and Economics Pages: 635-649 Issue: 6 Volume: 21 Year: 2003 Keywords: Construction innovation, innovation implementation, innovation management, X-DOI: 10.1080/0144619032000123725 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000123725 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:6:p:635-649 Template-Type: ReDIF-Article 1.0 Author-Name: Graham Winch Author-X-Name-First: Graham Author-X-Name-Last: Winch Title: How innovative is construction? Comparing aggregated data on construction innovation and other sectors - a case of apples and pears Abstract: This research note addresses the widespread perception that construction performs badly compared to other industrial sectors. The evidence for this perception is usually based on comparative industrial performance data. However, due to technical problems with the Standard Industrial Classifications used, like is not compared with like in these analyses, to the systematic disadvantage of the construction industry's comparative performance. In an effort to improve the performance of the industry, the auto industry is often held up as an exemplar. However, when that industry is compared on a like-for-like basis with construction, it proves to have a poor record of performance. Journal: Construction Management and Economics Pages: 651-654 Issue: 6 Volume: 21 Year: 2003 Keywords: Standard Industrial Classification, construction industry performance, auto industry performance, construction innovation, X-DOI: 10.1080/0144619032000113708 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000113708 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:6:p:651-654 Template-Type: ReDIF-Article 1.0 Author-Name: Jakrapong Pongpeng Author-X-Name-First: Jakrapong Author-X-Name-Last: Pongpeng Author-Name: John Liston Author-X-Name-First: John Author-X-Name-Last: Liston Title: A multicriteria model's survey: state of the art and some necessary capabilities of future models Abstract: To identify a state-of-the-art model and some necessary capabilities for developing future multicriteria models, the literature on multicriteria models in operations research was surveyed. All the models required subjective inputs from decision-makers. A utility function was regarded as the best model for including risk and uncertainty into the solution analysis. On the other hand, a social welfare function was found to be the most attractive in a democratic organization in handling the involvement of multiple decision-makers. Thus, a combination of both the functions can be described as state-of-the-art. In addition, the subjective inputs changed over time in relation to a particular circumstance. For this reason, computer interaction should be incorporated with this combination. Therefore, some capabilities of (1) incorporating subjective inputs of multiple decision-makers, (2) including elements of risk and uncertainty and (3) absorbing the changes of subjective inputs via computer interaction are necessary for future multicriteria models. Journal: Construction Management and Economics Pages: 665-670 Issue: 7 Volume: 21 Year: 2003 Keywords: Multicriteria, multicriteria models, optimization, decision-making, X-DOI: 10.1080/0144619032000093288 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000093288 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:7:p:665-670 Template-Type: ReDIF-Article 1.0 Author-Name: Youngha Cho Author-X-Name-First: Youngha Author-X-Name-Last: Cho Title: The organizational boundaries of housebuilding firms in Korea Abstract: This paper investigates the boundary of activities undertaken by Korean housebuilding firms. First, it examines the contractual relationships between housebuilding firms and contractors, focusing on the existence of quasi-firm type organization in the Korean housebuilding industry. Second, it looks at how far Korean housebuilding firms diversify into other activities outside the industry. Secondary data analysis and an interview survey, carried out over the period between 1980 and 1995, were used. The results show that Korean housebuilding firms depend on a traditional contractual relationship with contractors but that quasi-firm type organization is not established. On the other hand, housebuilding firms diversify into both related and unrelated business. This diversification could be a short-term 'survival strategy' under a regulated environment rather than a long-term 'growth strategy'. Journal: Construction Management and Economics Pages: 671-680 Issue: 7 Volume: 21 Year: 2003 Keywords: Organizational boundary, diversification, contracting, quasi-firm, housebuilding, X-DOI: 10.1080/0144619032000093297 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000093297 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:7:p:671-680 Template-Type: ReDIF-Article 1.0 Author-Name: Igal Shohet Author-X-Name-First: Igal Author-X-Name-Last: Shohet Title: Building evaluation methodology for setting maintenance priorities in hospital buildings Abstract: Condition-Based Maintenance (CBM) is a common solution for the maintenance of large complex facilities under tight economic conditions. Effective implementation of CBM requires the development of performance indicators for building components and systems. The objectives of the proposed methodology are: (1) to monitor the condition of building components, based on systematic performance scales; (2) to develop a parameter that ensures clear detection of building elements that are in failing condition; and (3) to provide a Key Performance Indicator, based on a unified scale, for the comparison of the performance of different buildings. Two rating scales are used: one for the individual components (Pn) and a second for the entire building - the Building Performance Indicator (BPI). The first scale combines criteria regarding the physical state, performance, fitness for use, and preventive maintenance of various building components. The second scale, the BPI, is a 100-point scale that covers 10 of the building's main systems. The proposed methodology was implemented in 17 public health care facilities in Israel. The survey results show that the overall state of the facilities is that of deterioration (BPI = 68.9). One building system, the communication and low voltage system, was consistently found to be in poor condition (Pn = 39.4), four systems (exterior envelope, interior finishing, water and waste-water, and HVAC) were in deteriorating condition (60d ≤ Pn < 70), and five were in satisfactory or higher condition. Validity of the methodology was tested by means of a survey executed by 14 trained surveyors on the same facility. The variance of the results was relatively slight. Journal: Construction Management and Economics Pages: 681-692 Issue: 7 Volume: 21 Year: 2003 Keywords: Facility management, Key Performance Indicator, Life Cycle Cost, maintenance, performance, priority setting, X-DOI: 10.1080/0144619032000115562 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000115562 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:7:p:681-692 Template-Type: ReDIF-Article 1.0 Author-Name: Ammar Kaka Author-X-Name-First: Ammar Author-X-Name-Last: Kaka Author-Name: John Lewis Author-X-Name-First: John Author-X-Name-Last: Lewis Title: Development of a company-level dynamic cash flow forecasting model (DYCAFF) Abstract: Current methods of predicting cash flow have a number of significant weaknesses. At the project level, previous models are simple and incorporate only some of the variables affecting cash flow. On the company level, budgeting is performed on an overall basis (i.e. no account is taken of individual contracts). This is mainly due to the fact that a considerable amount of any year's turnover is contributed by contracts that have yet to be won (or even known of) at the time of the budget. This approach, in addition to being inaccurate, precludes the role of budgeting as a tool for strategy evaluation. This paper presents a dynamic cash flow forecasting model that would assist contractors to effectively plan and manage the cash flow of individual projects and at a company level. The advances made in the model can be represented by three of its main features. First, the development of a more accurate and complex cash flow calculation mechanism. Second, the development of an information system that will help the contractor enter the data necessary for this mechanism. Third, the development of a company-level model that is based on individual projects, both known and unknown to the contractor at the time of the forecast. Journal: Construction Management and Economics Pages: 693-705 Issue: 7 Volume: 21 Year: 2003 Keywords: Financial planning, cash flow, management information systems, simulation, budgeting, X-DOI: 10.1080/0144619032000116561 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000116561 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:7:p:693-705 Template-Type: ReDIF-Article 1.0 Author-Name: Mao Zhi Author-X-Name-First: Mao Author-X-Name-Last: Zhi Author-Name: Goh Bee Hua Author-X-Name-First: Goh Bee Author-X-Name-Last: Hua Author-Name: Shou Qing Wang Author-X-Name-First: Shou Qing Author-X-Name-Last: Wang Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Title: Total factor productivity growth accounting in the construction industry of Singapore Abstract: Total factor productivity (TFP) determines long-term economic growth and is a comprehensive industry-level productivity measure. This paper proposes Jorgenson's method as an appropriate TFP measurement for the construction industry. The method is less restrictive than the conventional Chau's approach, as it does not impose the Hick Neutral Technical Change assumption. Jorgenson's method is then applied to estimate TFP growth in the construction industry of Singapore over 1984-1998. TFP growth is found down by 1.53% per annum over this period, indicating that the performance of TFP in the construction industry lags behind the rest of economy. TFP growth is also found to be fluctuating over time and tends to move in tandem with the construction business cycle. As a monitor of progress towards TFP achievement, factors influencing TFP growth in the construction industry of Singapore over 1984-1997 are identified. Seven factors are found to be significantly related to TFP growth. Among them, economies of scale, R&D by the industry, investment allowance granted and labour unions are leading contributors to TFP growth; while foreign worker, construction accidents and pre-cast are major hampers. The general methodology presented in this study can be applied to other countries. Future studies are required to find appropriate indicators for factors unquantified. Journal: Construction Management and Economics Pages: 707-718 Issue: 7 Volume: 21 Year: 2003 Keywords: Total factor productivity, growth accounting, Singapore, translog production function, indicators, X-DOI: 10.1080/0144619032000056126 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000056126 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:7:p:707-718 Template-Type: ReDIF-Article 1.0 Author-Name: Chen-Kang Su Author-X-Name-First: Chen-Kang Author-X-Name-Last: Su Author-Name: Chien-Yuan Lin Author-X-Name-First: Chien-Yuan Author-X-Name-Last: Lin Author-Name: Ming-Teh Wang Author-X-Name-First: Ming-Teh Author-X-Name-Last: Wang Title: Taiwanese construction sector in a growing 'maturity' economy, 1964-1999 Abstract: Using 12 input-output tables compiled in Taiwan between 1964 and 1999, the role of the construction sector in the development of the Taiwanese economy is examined and analysed in relationship to other economic sectors. Analytical results reveal a two-stage inverted U-shaped relationship between the share of construction in GNP versus GNP per capita. The 'pull effect' of the Taiwanese construction sector is approximately equal to that of the Japanese construction sector over time, demonstrating that construction is more closely linked to the wider economy in Taiwan than elsewhere, like Italy, the UK and the USA. The 'push effect' increases significantly over time, indicating that the M&R (maintenance and repair) construction expenditures are growing in Taiwan. Finally, the direct and total construction input from manufacturing initially increased from 1969 and then declined after 1981, while the input from the service sector has been steadily growing. These findings confirm the increasing 'maturity' of the Taiwanese economy, a trend that mirrors the economic development of other AICs like Italy, Japan, the UK and the USA. Journal: Construction Management and Economics Pages: 719-728 Issue: 7 Volume: 21 Year: 2003 Keywords: Input-output analysis, pull effect, push effect, Taiwanese construction sector, X-DOI: 10.1080/0144619032000064082 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000064082 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:7:p:719-728 Template-Type: ReDIF-Article 1.0 Author-Name: P. Perttula Author-X-Name-First: P. Author-X-Name-Last: Perttula Author-Name: J. Merjama Author-X-Name-First: J. Author-X-Name-Last: Merjama Author-Name: M. Kiurula Author-X-Name-First: M. Author-X-Name-Last: Kiurula Author-Name: H. Laitinen Author-X-Name-First: H. Author-X-Name-Last: Laitinen Title: Accidents in materials handling at construction sites Abstract: The aim of this study is to examine those occupational accidents at construction sites that are related to materials handling as compared with all reportable occupational accidents at construction sites. The main concern is to define the kinds of accidents that occur in materials handling. The data were gathered from two sources: a large Finnish construction company and the database of reports of serious occupational accidents (Sammio). One third of all the reported accidents in the studied construction company occurred during materials transfer and 36% of the absenteeism days resulted from these accidents. Materials handling thus caused more serious accidents than other work activities (t = -2.44, df = 351, p < 0.005). Minor accidents were mostly due to over-exertion whereas serious accidents were mostly falling from a height and injuries caused by falling and collapsing objects. The manual transfer of materials caused most of the materials transfer accidents in the company and mechanical transfer most of the serious materials handling accidents. Over-exertion can, therefore, be decreased by reducing manual materials handling. On the other hand, replacing manual transfers with mechanical transfers means that there arises a risk of serious accidents. Journal: Construction Management and Economics Pages: 729-736 Issue: 7 Volume: 21 Year: 2003 Keywords: Construction industry, occupational accident, manual materials handling, mechanical materials handling, X-DOI: 10.1080/0144619032000087294 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000087294 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:7:p:729-736 Template-Type: ReDIF-Article 1.0 Author-Name: Mohammed Wanous Author-X-Name-First: Mohammed Author-X-Name-Last: Wanous Author-Name: Halim Boussabaine Author-X-Name-First: Halim Author-X-Name-Last: Boussabaine Author-Name: John Lewis Author-X-Name-First: John Author-X-Name-Last: Lewis Title: A neural network bid/no bid model: the case for contractors in Syria Abstract: Despite the crucial importance of the 'bid/no bid' decision in the construction industry, it has been given little attention by researchers. This paper describes the development and testing of a novel bid/no bid model using the artificial neural network (ANN) technique. A back-propagation network consisting of an input buffer with 18 input nodes, two hidden layers and one output node was developed. This model is based on the findings of a formal questionnaire through which key factors that affect the 'bid/no bid' decision were identified and ranked according to their importance to contractors operating in Syria. Data on 157 real-life bidding situations in Syria were used in training. The model was tested on another 20 new projects. The model wrongly predicted the actual bid/no bid decision only in two projects (10%) of the test sample. This demonstrates a high accuracy of the proposed model and the viability of neural network as a powerful tool for modelling the bid/no bid decision-making process. The model offers a simple and easy-to-use tool to help contractors consider the most influential bidding variables and to improve the consistency of the bid/no bid decision-making process. Although the model is based on data from the Syrian construction industry, the methodology would suggest a much broader geographical applicability of the ANN technique on bid/no bid decisions. Journal: Construction Management and Economics Pages: 737-744 Issue: 7 Volume: 21 Year: 2003 Keywords: ANN, ANN bidding model, 'bid/no bid' criteria, construction, Syria, X-DOI: 10.1080/0144619032000093323 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000093323 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:7:p:737-744 Template-Type: ReDIF-Article 1.0 Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Author-Name: Ivan Fung Author-X-Name-First: Ivan Author-X-Name-Last: Fung Author-Name: Thomas Yeung Author-X-Name-First: Thomas Author-X-Name-Last: Yeung Author-Name: Karen Tung Author-X-Name-First: Karen Author-X-Name-Last: Tung Title: Relationship between construction safety signs and symbols recognition and characteristics of construction personnel Abstract: This study investigates the relationship between the characteristics of construction personnel and their degree of recognition of safety signs and symbols. The safety signs and symbols are split into categories of mandatory action signs, prohibition signs and warning symbols. Thirty safety signs and symbols printed in colour and in Chinese were distributed to 560 construction personnel working in eight different construction sites in Hong Kong. The results drawn from 388 respondents indicate that substantial problems exist in comprehending the signs and symbols that are posted in construction sites. The percentages of construction personnel who correctly identified mandatory action signs, prohibition signs and warning symbols are 90%, 61% and 55% respectively. Drinking habits, involvement in on-site safety promotion activities and their job positions play a determinant role in their ability of comprehending these construction safety symbols. These findings provide meaningful implications to the industry in the design, selection and positioning of safety symbols on site. Journal: Construction Management and Economics Pages: 745-753 Issue: 7 Volume: 21 Year: 2003 Keywords: Safety, signs, symbols, recognition, construction, personnel, X-DOI: 10.1080/0144619032000056171 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000056171 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:7:p:745-753 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Barrett Author-X-Name-First: Peter Author-X-Name-Last: Barrett Author-Name: Lucinda Barrett Author-X-Name-First: Lucinda Author-X-Name-Last: Barrett Title: Research as a kaleidoscope on practice Abstract: Insufficient attention is paid to the relationship between research and practice in construction. Those in industry want straightforward guidance, but inhabit a complex socially constructed world. As a result, they are often disappointed with the contribution of research, either because it is too theoretical or because the simple solutions suggested do not work. However, researchers have a valuable contribution to make owing to their opportunity for reflection, and it is proposed that this can be viewed in three different ways: as 'microscopes', 'telescopes' or 'periscopes' on practice. Each of these views involves different epistemologies and methodologies, but combining the three approaches in a Kaleidoscopic Research Model will allow differences to thrive and synergies to be sought. Only then will an effective dialogue develop where research impacts solidly and continuously on the improvement of practice, while at the same time practice constantly challenges and refreshes research. Journal: Construction Management and Economics Pages: 755-766 Issue: 7 Volume: 21 Year: 2003 Keywords: research, practice, policy, Kaleidoscopic Model, research typology, X-DOI: 10.1080/0144619032000093314 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000093314 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:7:p:755-766 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: David Edwards Author-X-Name-First: David Author-X-Name-Last: Edwards Title: The UK building education recruitment crisis: a call for action Abstract: Anecdotal evidence suggests that construction industry professions are facing an unprecedented recruitment crisis. In recent years many construction degree programmes have been withdrawn in response to falling recruitment across most built environment disciplines, whilst at the same time employers are reporting difficulties in recruiting a sufficient graduate intake to satisfy demand. In order to assess the potential impact of this decline, this paper presents an analysis of application and admissions data to UK higher education courses over a six-year period. The results reveal a significant decline in the number of graduates applying for, and accepting, places on building degree courses during the analysis period despite increased micro-economic activity. Curiously, the number of women graduates has remained fairly constant over this period. Total applications per annum were then modelled using a quadratic model equation. With an R2 at 0.98 and a mean percentage error of appropriately 1%, the model was deemed to be a good predictor. Forecasts generated using this model for the years 2001 to 2005 suggest a steady and continuous decline in building degree applications. Industry output forecasts for the same period show a steady growth which is likely to result in an increased demand for graduates and hence, skills shortages. Reasons are postulated as to why the image of the industry has led to such a steep decline in graduate enrolments over the last few years. It is concluded that industry practitioners, professional bodies and universities should embark upon a collaborative, immediate and sustained promotional campaign if they are to avoid severe recruitment difficulties in the future. Journal: Construction Management and Economics Pages: 767-775 Issue: 7 Volume: 21 Year: 2003 Keywords: Building degrees, graduates, demand, image, forecast, X-DOI: 10.1080/0144619032000072146 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000072146 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:7:p:767-775 Template-Type: ReDIF-Article 1.0 Author-Name: Florence Phua Author-X-Name-First: Florence Author-X-Name-Last: Phua Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Title: Cultural differences as an explanatory variable for adversarial attitudes in the construction industry: the case of Hong Kong Abstract: The procurement systems adopted in the construction industry are, by their very nature, fragmented and divided into sub-organizations distinguished by the various sentient stakeholders. The industry has come to be regarded as adversarial and one in which cooperation is expected to take place in a set of circumstances that are not wholly conducive. There are many reasons why the industry has developed in this fragmented and adversarial manner. This paper reviews some of these reasons and suggests that a new approach for analysing the way the industry operates is required. The authors argue that the perspective that should be adopted to identify the determinants of cooperation should logically stem from the individual level because cooperation is the result of individual efforts and interactions with each other. Using social identity theory, the authors advance a framework for analysing the cooperative behaviour of project participants based on their cultural orientation. As far as the authors are aware this is the first attempt within the construction industry to use such an approach to explain how the industry operates and this paper provides a review of how social identity theory can be used in construction research. Journal: Construction Management and Economics Pages: 777-785 Issue: 7 Volume: 21 Year: 2003 Keywords: Social identity theory, individualism, collectivism, inter-organizational cooperation, partnering, construction performance, X-DOI: 10.1080/0144619032000108245 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000108245 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:7:p:777-785 Template-Type: ReDIF-Article 1.0 Author-Name: David Langford Author-X-Name-First: David Author-X-Name-Last: Langford Title: Guest editorial Abstract: Journal: Construction Management and Economics Pages: 795-796 Issue: 8 Volume: 21 Year: 2003 X-DOI: 10.1080/0144619032000174495 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000174495 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:8:p:795-796 Template-Type: ReDIF-Article 1.0 Author-Name: Dave Langford Author-X-Name-First: Dave Author-X-Name-Last: Langford Author-Name: Vicky Langford Author-X-Name-First: Vicky Author-X-Name-Last: Langford Title: In Memoriam: Sydney Allendale Urry Abstract: Journal: Construction Management and Economics Pages: 797-798 Issue: 8 Volume: 21 Year: 2003 X-DOI: 10.1080/0144619032000174503 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000174503 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:8:p:797-798 Template-Type: ReDIF-Article 1.0 Author-Name: David Langford Author-X-Name-First: David Author-X-Name-Last: Langford Author-Name: Peter Robson Author-X-Name-First: Peter Author-X-Name-Last: Robson Title: The representation of the professions in the cinema: the case of construction engineers and lawyers Abstract: This paper considers how popular culture, especially the cinema, depicts two professions; namely, engineering and the law. It argues that despite the large number of engineers working in the developed economies their lives and their work are seldom portrayed in cinema. In contrast, the legal profession is ubiquitous in its presence in film. The paper seeks to use different forms of analysis, such as culturalism, Marxism, structuralism, feminism and post-modernism when applied to film theory in settings where engineers and lawyers are depicted. The paper makes a distinction between the presentation of the work of engineers and lawyers in 'real life' and cinematic form. The process of engineering in real life is visible yet in cinematic terms it is ignored. In contrast, the legal process is invisible in real life but has high dramatic content in the cinema. When considering the products of the two professions, engineering produces tangible products whilst law produces intangible yet highly cerebral discourses. Yet, in the cinema, the engineering product is a backcloth for other messages where in law the legal product provides a backcloth for a central and dominant message about the legal process. The conclusion is that engineers have to re-engineer themselves to be more visible in society if they are to be regarded as cinematic heroes. Journal: Construction Management and Economics Pages: 799-807 Issue: 8 Volume: 21 Year: 2003 Keywords: Cinema, construction, engineers, lawyers, X-DOI: 10.1080/0144619032000174512 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000174512 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:8:p:799-807 Template-Type: ReDIF-Article 1.0 Author-Name: Richard Fellows Author-X-Name-First: Richard Author-X-Name-Last: Fellows Author-Name: Anita Liu Author-X-Name-First: Anita Author-X-Name-Last: Liu Author-Name: Cheung Miu Fong Author-X-Name-First: Cheung Miu Author-X-Name-Last: Fong Title: Leadership style and power relations in quantity surveying in Hong Kong Abstract: The realization of construction projects brings together a diversity of individuals and organizations, variously forged into groups and teams, in which power is important in shaping leader/follower behaviour. Quantity surveyors, being primarily project cost consultants and procurement/contractual advisers, are employed both by the clients' and the contractors' organizations. This paper investigates aspects of leadership style and power within quantity surveying in both clients' and contractors' project 'teams'. The empirical work employed two questionnaires, developed from established instruments and completed by samples of team leaders and team members. Some differences emerged between quantity surveyors working for consultants' organizations (acting on behalf of the client) and those working for contractors' organizations. The results confirm the relationship orientation of clients' consultant quantity surveyors, who tend to adopt the supportive style of leadership. The directive style of leadership showed negative impact. Power distance was found to exceed that measured previously for Hong Kong and expert power was the most important power source. Journal: Construction Management and Economics Pages: 809-818 Issue: 8 Volume: 21 Year: 2003 Keywords: Culture, leadership, power, quantity surveying, X-DOI: 10.1080/0144619032000174521 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000174521 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:8:p:809-818 Template-Type: ReDIF-Article 1.0 Author-Name: Anita Liu Author-X-Name-First: Anita Author-X-Name-Last: Liu Author-Name: Richard Fellows Author-X-Name-First: Richard Author-X-Name-Last: Fellows Author-Name: Z. Fang Author-X-Name-First: Z. Author-X-Name-Last: Fang Title: The power paradigm of project leadership Abstract: The concept of leadership inevitably concerns power structuring in which power is distributed unevenly between individuals. Indeed, leadership styles are closely associated with power distribution and its exercise. Power, in its diverse guises, combines inter-personal and structural elements and may be enhanced through political manoeuvring. This paper develops a model of project leadership from a behaviour-performance-outcome approach to construction projects and concludes by stressing the motivational function of good leadership through managing power gap(s) by means of power-sharing and power-amassing. Journal: Construction Management and Economics Pages: 819-829 Issue: 8 Volume: 21 Year: 2003 Keywords: Leadership, motivation, power, X-DOI: 10.1080/0144619032000056199 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000056199 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:8:p:819-829 Template-Type: ReDIF-Article 1.0 Author-Name: D. A. Langford Author-X-Name-First: D. A. Author-X-Name-Last: Langford Author-Name: P. Kennedy Author-X-Name-First: P. Author-X-Name-Last: Kennedy Author-Name: J. Conlin Author-X-Name-First: J. Author-X-Name-Last: Conlin Author-Name: N. McKenzie Author-X-Name-First: N. Author-X-Name-Last: McKenzie Title: Comparison of construction costs on motorway projects using measure and value and alternative tendering initiative contractual arrangements Abstract: This paper reports the outcome of an investigation into the construction costs in 11 motorway projects. The projects formed one length of road and were of identical specification; five of the projects were undertaken by a traditional design, tender, construct method, and five were undertaken by a procurement system by which the contractor bid a lump sum for the work and so absorbed potential risks and benefits from changes in prices of resources or fluctuations in quantities of work necessary for the completion of the work. One project was undertaken by a design and build method. The results of the analysis indicate that in roadworks the construction cost per kilometre of road is some 11% less expensive when lump sum contracts are used. This benefit appears to be more pronounced in the case of bridge structures incorporated into the motorway. Of greater significance is the cost certainty that is afforded using the lump sum methods. The research showed that lump sum projects were much more likely to be completed within the budget. Finally the lump sum methods required less management by the client organization and delivered more harmonious working relationships between the client and contractor. Journal: Construction Management and Economics Pages: 831-840 Issue: 8 Volume: 21 Year: 2003 Keywords: Procurement, tendering, construction costs, variations, value for money, X-DOI: 10.1080/0144619032000056180 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000056180 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:8:p:831-840 Template-Type: ReDIF-Article 1.0 Author-Name: Robert Newcombe Author-X-Name-First: Robert Author-X-Name-Last: Newcombe Title: From client to project stakeholders: a stakeholder mapping approach Abstract: In contemporary management theory and practice the rise and role of stakeholders as major players in organizational dynamics are widely recognized and recorded. This pluralistic view of the identity of those who have an investment and an interest in an organization extends well beyond the traditional concept of shareholders to include employees, suppliers, customers, trade unions, communities, etc. The concept of stakeholders has been applied to projects in general but has not, to date, been extended to the context of construction projects although it is accepted that the traditional view of the client as a single entity does not reflect the reality of stakeholder configurations for most projects. Different stakeholders have different levels and types of investment and interest in construction projects and can be seen as multiple clients or customers for the project in which they are involved. This paper argues that the concept of client, which has prevailed throughout the twentieth century, is now obsolete and is being replaced by the reality of project stakeholders. A novel application of the technique of stakeholder mapping to a large construction project demonstrates the importance to project managers of conducting the analysis of the power, predictability and interest of key project stakeholders. Journal: Construction Management and Economics Pages: 841-848 Issue: 8 Volume: 21 Year: 2003 Keywords: Construction, projects, clients, stakeholders, stakeholder mapping, project management, X-DOI: 10.1080/0144619032000072137 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000072137 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:8:p:841-848 Template-Type: ReDIF-Article 1.0 Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Author-Name: David Yates Author-X-Name-First: David Author-X-Name-Last: Yates Title: nDCAD: a virtual change agent for professions and procurement systems? Abstract: Prof. Urry was always forward looking in his view of the industry and visionary in the way he drew ideas and concepts from other disciplines and applied them to construction. Coming, as an aeronautical engineer, with no baggage he was able to step back and look at how ideas and concepts could be 're-applied' in construction and how the nature, structure and ethos of the industry might be changed. The use of OR techniques from the 1950s onward drove the industry forward with a great leap into a more structured view of the construction process - current uses of IT in visualization and animation have the potential to stimulate a similar great leap forward. The driver for change identified here is multi-dimensional computer aided design (nDCAD); this is a technology that not only animates conventional 3DCAD but invests attributes in its elements, such as cost, structural design and even safety data. It is argued that nDCAD has the potential to become the change agent that will drive the industry participants towards relational contracting procurement systems and provide the basis for truly collaborative design, construction and facilities management. In so doing, the traditional roles played by professionals will be unfrozen, so producing the context within which the professions can embrace a sea change in the way that they are governed and sentient barriers can be broken down. Journal: Construction Management and Economics Pages: 849-857 Issue: 8 Volume: 21 Year: 2003 Keywords: nDCAD, visualization, procurement systems, change agent, professions, contract strategy, X-DOI: 10.1080/0144619032000174530 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000174530 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:21:y:2003:i:8:p:849-857 Template-Type: ReDIF-Article 1.0 Author-Name: D. A. Langford Author-X-Name-First: D. A. Author-X-Name-Last: Langford Title: Letter to the Editor Abstract: Journal: Construction Management and Economics Pages: 5-5 Issue: 1 Volume: 22 Year: 2004 X-DOI: 10.1080/0144619042000186004 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000186004 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:1:p:5-5 Template-Type: ReDIF-Article 1.0 Author-Name: Frens Pries Author-X-Name-First: Frens Author-X-Name-Last: Pries Author-Name: Andre Doree Author-X-Name-First: Andre Author-X-Name-Last: Doree Author-Name: Bas Van Der Veen Author-X-Name-First: Bas Author-X-Name-Last: Van Der Veen Author-Name: Ruben Vrijhoef Author-X-Name-First: Ruben Author-X-Name-Last: Vrijhoef Title: The role of leaders' paradigm in construction industry change Abstract: As in other industries, firms in the construction industry need to become more client- and market-oriented. In the last decade, several initiatives have been taken to change the construction industry in that direction. The changes, however, seem to be slower than other industries and less forthcoming than projected. Old practices and patterns die hard. Fundamental changes in orientation, strategy and strategy deployment require shifts in the management paradigms (i.e. the 'frames of mind' that steer individual and collective behaviour). Management is seen as a crucial factor in these change processes, but can the new business be created by old management paradigms? Can the leaders in the construction industry shake off the old paradigms? An explorative quantitative study shows that the mainstream paradigm of construction industry leaders today is much as it was in the past: technology- and project-oriented. Acting out of this paradigm, issues as social-organizational change and strategic focus on the client - regarded as important for the industry - will probably not be addressed properly. Change initiatives could gain in success, when they create wider awareness of existence and persistence of incumbent and prevailing paradigms. Journal: Construction Management and Economics Pages: 7-10 Issue: 1 Volume: 22 Year: 2004 Keywords: Construction industry, innovation, paradigms, barriers to change, construction management, X-DOI: 10.1080/0144619042000186013 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000186013 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:1:p:7-10 Template-Type: ReDIF-Article 1.0 Author-Name: M. Sohail Author-X-Name-First: M. Author-X-Name-Last: Sohail Author-Name: A. N. Baldwin Author-X-Name-First: A. N. Author-X-Name-Last: Baldwin Title: Performance indicators for 'micro-projects' in developing countries Abstract: The majority of public works contracts undertaken in developing countries have a total cost of less than US $15 000. They include the provision of enhanced water and sanitation, access ways and pavements, small community buildings and solid-waste related construction. These are termed 'micro-projects' and there is a general lack of information for such projects. This paper describes the development and testing of 67 performance indicators for use on micro-projects. They include not only general performance indicators but also indicators for inter-organizational and socio-economic issues. These indicators are based on data from over 800 micro-projects undertaken in developing countries. For each indicator, a statement of why the indicator was selected, the key sources of information and how to determine the indicator is provided. Examples of the use of the indicators are also presented. Journal: Construction Management and Economics Pages: 11-23 Issue: 1 Volume: 22 Year: 2004 Keywords: Urban infrastructure, performance indicators, developing countries, micro-contracts, X-DOI: 10.1080/0144619042000186022 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000186022 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:1:p:11-23 Template-Type: ReDIF-Article 1.0 Author-Name: Sarel Lavy Author-X-Name-First: Sarel Author-X-Name-Last: Lavy Author-Name: Igal Shohet Author-X-Name-First: Igal Author-X-Name-Last: Shohet Title: Integrated maintenance management of hospital buildings: a case study Abstract: Over the course of the past three decades, facilities management has become the subject of an increasing number of research and development efforts. The main objective of the present research was to examine the efficiency of maintenance under alternative maintenance policies and different sources of human resources. The research focused on the maintenance of public hospital buildings in Israel, with the objective of providing a model for multi-system facilities operating in a dynamic environment. This paper describes the last three stages of the research: the establishment of key performance indicators, the implementation of these indicators in a case study in order to appraise them, and the validation of the indicators. Four key performance indicators were developed, as follows: the Building Performance Indicator (BPI), the Manpower Sources Diagram (MSD), the Maintenance Efficiency Indicator (MEI) and the Managerial Span of Control (MSC). This paper illustrates a case study in which the four developed indicators were implemented in practice. Characteristics of the case study hospital are presented and analysed. Finally, the conclusions and recommendations drawn from the analysis of the hospital case study are discussed, validated and deliberated upon. The approach presented in this paper integrates performance, financial, human resources and organizational aspects to facilitate an improved evaluation method of the parameters affecting the execution of maintenance activities. Journal: Construction Management and Economics Pages: 25-34 Issue: 1 Volume: 22 Year: 2004 Keywords: Facilities management, key performance indicators, maintenance, outsourcing, performance-based building, X-DOI: 10.1080/0144619042000186031 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000186031 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:1:p:25-34 Template-Type: ReDIF-Article 1.0 Author-Name: Osama Moselhi Author-X-Name-First: Osama Author-X-Name-Last: Moselhi Author-Name: Ji Li Author-X-Name-First: Ji Author-X-Name-Last: Li Author-Name: Sabah Alkass Author-X-Name-First: Sabah Author-X-Name-Last: Alkass Title: Web-based integrated project control system Abstract: This paper presents a system that supports project time and cost control in an integrated manner. The system utilizes object-oriented modelling to represent the process of project delivery. A set of control objects is designed to map the process of project control. Eighteen key indicators are considered to represent the resources utilized in each control object and serve as sensors to highlight problematic areas associated with unfavourable performance. A Three-Tier Client/Sever computer system is designed to implement the developed system. Daily, weekly, monthly and/or yearly, period-by-period, and cumulative to-date project performance reports are generated to provide the status at project, control object and resource levels. An example drawn from the literature is analysed to allow for comparison with the results obtained using the proposed methodology. The example also serves the purpose of demonstrating the use of the proposed system and illustrating its essential features. Journal: Construction Management and Economics Pages: 35-46 Issue: 1 Volume: 22 Year: 2004 Keywords: Project control, earned value, progress reporting, web-based system, X-DOI: 10.1080/0144619042000186040 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000186040 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:1:p:35-46 Template-Type: ReDIF-Article 1.0 Author-Name: Mohan Raj Manavazhi Author-X-Name-First: Mohan Raj Author-X-Name-Last: Manavazhi Title: Assessment of the propensity for revisions in design projects through the dichotomous characterization of designer effort Abstract: This paper defines the concept of the propensity of a design project to encounter rework and discusses its significance within the context of the planning and estimation functions. A formalism for the representation of the concept of rework propensity that could be used in planning and estimation is developed. The representation is facilitated by embodying the notions of magnitude of designer effort and the corresponding probability of occurrence of a sequence of events in a design project that entails the use of a specific level of designer effort. The paper then discusses the mathematical theory that underpins the practical and simplified procedure proposed by this research for the estimation of the propensity of a project to encounter rework. A detailed procedure for the estimation of rework propensity involving the use of an approximated k-Rk (AKR) curve is presented. A sample application that demonstrates the use of the simplified procedure is also presented. Journal: Construction Management and Economics Pages: 47-54 Issue: 1 Volume: 22 Year: 2004 Keywords: Rework propensity, design rework, design revisions, design process, design planning, X-DOI: 10.1080/0144619042000186059 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000186059 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:1:p:47-54 Template-Type: ReDIF-Article 1.0 Author-Name: Zhen Chen Author-X-Name-First: Zhen Author-X-Name-Last: Chen Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Author-Name: Qiping Shen Author-X-Name-First: Qiping Author-X-Name-Last: Shen Author-Name: Wei Xu Author-X-Name-First: Wei Author-X-Name-Last: Xu Title: An empirical model for decision-making on ISO 14000 acceptance in the Shanghai construction industry Abstract: A remarkable disagreement/deviation between the rate of ISO 14001 registration and the rate of implementation of environmental impact assessment in the Chinese construction industry indicates that the contractors there might not have really applied environmental management (EM) in construction projects. This hypothesis has been tested in this paper by a mail questionnaire survey conducted to 72 main contractors in Shanghai, mainland China. The survey results indicate that there are five classes of factors influencing the acceptability of the ISO 14000 series of EM standards. Reasons why approximately 81% of contractors surveyed are indifferent to the ISO 14000 series are then analysed based on the critical classes. A linear discriminant model for decision-making for construction companies on whether to accept the ISO 14000 series is developed. Journal: Construction Management and Economics Pages: 55-73 Issue: 1 Volume: 22 Year: 2004 Keywords: ISO 14000 series, environmental management system, environmental impact assessment, empirical model, China, X-DOI: 10.1080/0144619042000186068 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000186068 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:1:p:55-73 Template-Type: ReDIF-Article 1.0 Author-Name: J. Rodney Turner Author-X-Name-First: J. Rodney Author-X-Name-Last: Turner Title: Farsighted project contract management: incomplete in its entirety Abstract: The purpose of project organization is to create a cooperative environment. Contracts are the method by which the owner creates a project organization to employ resources to achieve their development objectives. Contracts should aim to produce a cooperative organization, aligning the contractors' objectives with the owners. A three-dimensional vector (reward, risk, safeguard), adapted from the Transaction Cost Economics literature, is used to analyse the efficacy of contract types to do this. Contracts are also unavoidably incomplete. They need to respond to unforeseen circumstance. A four-dimensional vector (incentive intensity, adaptiveness, reliance on monitoring and control, reliance on the courts), also from the Transaction Costs Economics literature, is used to analyse the governance efficacy of contract types. The results are used to develop a contract selection strategy, depending on whether the uncertainty is controlled by the client or the contractor, the project is simple or complex, and the uncertainty is in the project's product, method of delivery or both. Journal: Construction Management and Economics Pages: 75-83 Issue: 1 Volume: 22 Year: 2004 Keywords: Contract selection, forms of contract, governance, incentivization, project organization, transaction costs, X-DOI: 10.1080/0144619042000186077 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000186077 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:1:p:75-83 Template-Type: ReDIF-Article 1.0 Author-Name: Zhenfeng Pan Author-X-Name-First: Zhenfeng Author-X-Name-Last: Pan Title: Commercial housing ownership predictors in urban China: an analysis of a national survey Abstract: China's housing reform has recently attracted notable academic interest due to the reform's crucial role in China's overall economic viability. Using nationally representative data, this paper examines predictors for ownership of commercial housing in urban China. This study confirms that the political and social biases associated with the old housing system have emerged in the process of commercial housing distribution. The housing reform so far has failed to achieve some of the most important goals of the commercialization of the housing market - to eliminate and remedy the corruption and the inefficiency of housing provision that were prevalent in the old housing system. Finally the outlook of the housing market in urban China is also discussed. Journal: Construction Management and Economics Pages: 85-91 Issue: 1 Volume: 22 Year: 2004 Keywords: Housing tenure choice, Chinese housing reform, China housing, urban housing in China, X-DOI: 10.1080/0144619042000186086 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000186086 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:1:p:85-91 Template-Type: ReDIF-Article 1.0 Author-Name: Bill Dunn Author-X-Name-First: Bill Author-X-Name-Last: Dunn Title: The regionalization of international contracting and its implications for models of construction spending Abstract: This paper documents an increasing regionalization of overseas contracting during the 1980s and 1990s. This involved a greater share within richer countries, particularly of intra-European work. This evidence challenges suggestions that middle-income countries are particularly appropriate destinations of overseas investment by developed country contractors. The paper therefore re-evaluates the model underlying such predictions, which relates construction spending to economic development. Reconsidering its empirical basis, it argues that the association between overall levels of per capita income and levels of construction spending is too weak to be of practical utility. It stresses the possibility of different routes to economic development and that this often remained an uncertain process and one within which levels of construction output varied widely. It therefore concludes that research should be informed by a broader political economy approach. Journal: Construction Management and Economics Pages: 93-100 Issue: 1 Volume: 22 Year: 2004 Keywords: International contracting, regionalization, economic development, construction spending, X-DOI: 10.1080/0144619042000186095 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000186095 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:1:p:93-100 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Predicting the probability of winning sealed bid auctions: the effects of outliers on bidding models Abstract: This paper is concerned with the effect of outliers on predictions of the probability of tendering the lowest bid in sealed bid auctions. Four of the leading models are tested relative to the equal probability model by an empirical analysis of three large samples of real construction contract bidding data via all-in (in-sample), one-out and one-on (out-of-sample) frames. Outliers are removed in a sequence of cut-off values proportional to the standard deviation of bids for each auction. A form of logscore is used to measure the ability to predict the probability of each bidder being the lowest. The results show that, although statistically significant in some conditions, all the models produce rather poor predictions in both one-out and one-on mode, with the effects of outliers being generally small. Journal: Construction Management and Economics Pages: 101-109 Issue: 1 Volume: 22 Year: 2004 Keywords: Bidding models, bidding theory, construction contracts, empirical tests, predicted probability, probability of lowest bid, sealed bid auctions, tendering theory, logscore test, outliers, X-DOI: 10.1080/0144619042000186103 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000186103 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:1:p:101-109 Template-Type: ReDIF-Article 1.0 Author-Name: Vernon Ireland Author-X-Name-First: Vernon Author-X-Name-Last: Ireland Title: Improving staff performance Abstract: Journal: Construction Management and Economics Pages: 121-121 Issue: 2 Volume: 22 Year: 2004 X-DOI: 10.1080/0144619042000201312 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000201312 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:2:p:121-121 Template-Type: ReDIF-Article 1.0 Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Author-Name: Dong-Eun Lee Author-X-Name-First: Dong-Eun Author-X-Name-Last: Lee Title: Service quality performance of design/build contractors using quality function deployment Abstract: This note describes a model that measures the quality of the project service of a D/B firm using quality function deployment (QFD). This model is an add-on to a model developed previously by the authors to measure the corporate service quality performance of D/B firms. The project service quality performance model makes use of 10 service quality factors and their relative weights (transferred from the corporate service quality performance model), three components of quality management systems in place in D/B projects (ranked by senior managers in D/B firms) and the relationships between service quality factors and quality system requirements (established by a professional quality system assessor). It uses QFD to calculate a quality performance index. The combined corporate and project service quality performance index can be used by D/B firms to benchmark themselves against their competitors or to monitor their own performance. It can also be used by owners to rank D/B firms relative to their service quality performance. Journal: Construction Management and Economics Pages: 123-127 Issue: 2 Volume: 22 Year: 2004 Keywords: Project service quality, design/build construction, quality function deployment, X-DOI: 10.1080/0144619042000201321 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000201321 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:2:p:123-127 Template-Type: ReDIF-Article 1.0 Author-Name: Natasha Haynes Author-X-Name-First: Natasha Author-X-Name-Last: Haynes Author-Name: Peter Love Author-X-Name-First: Peter Author-X-Name-Last: Love Title: Psychological adjustment and coping among construction project managers Abstract: Construction project managers work under conditions of uncertainty and high risk, and this can contribute to an excessive level of work-related stress being experienced. To date, there has been limited research that has examined how project managers cope with work-related stress. This paper investigates whether coping and affect (both negative and positive) influence adjustment (anxiety, depression and stress) among project managers. A sample of 100 male project managers from Australian contracting organizations completed a questionnaire that measured coping strategies, affect state and potential stressors. Hierarchical regression analyses demonstrated that specific work-related characteristics such as work experience, project size, age and level of education influenced the psychological adjustment of the project managers sampled. Further, those who engaged in a more problem-focused style of coping, such as active coping were found to be better adjusted than those who engaged in more emotion-focused styles of coping such as cognitive avoidance coping, social coping, accepting responsibility and self-controlling coping. In addition, it was revealed that increased adjustment of project managers was associated with positive affect. It is concluded that the psychological adjustment of project managers is influenced by specific work-related characteristics, the types of coping strategies they use and their affect state. Journal: Construction Management and Economics Pages: 129-140 Issue: 2 Volume: 22 Year: 2004 Keywords: Adjustment, anxiety, depression, stress, coping, project managers, X-DOI: 10.1080/0144619042000201330 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000201330 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:2:p:129-140 Template-Type: ReDIF-Article 1.0 Author-Name: Francis Ng Author-X-Name-First: Francis Author-X-Name-Last: Ng Author-Name: Hans Bjornsson Author-X-Name-First: Hans Author-X-Name-Last: Bjornsson Author-Name: Samuel Chiu Author-X-Name-First: Samuel Author-X-Name-Last: Chiu Title: Valuing a price cap contract for material procurement as a real option Abstract: This paper uses real option methodology to compare the cost of a long-term contract with a price cap to that of spot purchases in construction material procurement. In construction, material procurements are usually short-term, project-based and subject to high price volatility. These characteristics and the competitive nature of the industry lower the profit margin of contractors. We have observed that contractors purchase a stable amount of commodity materials such as concrete, structural steel and lumber year after year. For contractors, the price cap reduces the price volatility of materials without their being obliged to purchase a certain quantity; for suppliers, the price-cap contracts give them steady demand and a bigger market share. We evaluate this price-cap contract as a real option and find the contractor's optimal ordering policy. When materials are not frequently traded, we model price processes by using related market information and then evaluate the idiosyncratic uncertainties in a risk-neutral setting. Our methodology does not require market completeness and incorporates some of the results of the latest research in finance such as correlation pricing, option pricing and zero level pricing, as well as Monte Carlo simulation. Journal: Construction Management and Economics Pages: 141-150 Issue: 2 Volume: 22 Year: 2004 Keywords: Material procurement, real option, pricing, ordering policy, supply chain, X-DOI: 10.1080/0144619042000201349 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000201349 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:2:p:141-150 Template-Type: ReDIF-Article 1.0 Author-Name: Andy Steele Author-X-Name-First: Andy Author-X-Name-Last: Steele Author-Name: Dianne Sodhi Author-X-Name-First: Dianne Author-X-Name-Last: Sodhi Title: Black and minority ethnic contractors and consultants and UK housing associations' contracting power Abstract: Housing associations are the main providers of social housing within the UK and a major force in area regeneration initiatives. They also have a pivotal role to play in promoting equality of opportunity since a large proportion of their clients are from black and minority ethnic (BME) communities. However, few housing associations have recognized the potential of their purchasing power in terms of investment in construction and maintenance work in promoting equality or the business benefits of doing so. This paper presents the research findings of a study of housing associations' contracting practices in London. The study aimed to highlight and document current practices in the employment of BME contractors and consultants and identify the equal opportunity issues associated with their engagement. The findings suggest that there is a general lack of appreciation among housing associations of the importance of employing BME contractors and consultants from both an equal opportunity and a business perspective. In view of the Race Relations (Amendment) Act 2000 and government guidance on equal opportunities, the housing association sector has still to fully recognize its influential role in this area. Journal: Construction Management and Economics Pages: 151-157 Issue: 2 Volume: 22 Year: 2004 Keywords: Equality, construction, housing, ethnic and minorities, X-DOI: 10.1080/0144619042000201358 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000201358 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:2:p:151-157 Template-Type: ReDIF-Article 1.0 Author-Name: Tarcisio Saurin Author-X-Name-First: Tarcisio Author-X-Name-Last: Saurin Author-Name: Carlos Formoso Author-X-Name-First: Carlos Author-X-Name-Last: Formoso Author-Name: Lia Guimaraes Author-X-Name-First: Lia Author-X-Name-Last: Guimaraes Title: Safety and production: an integrated planning and control model Abstract: A safety planning and control model (SPC) has been integrated into the production planning and control process. The model integrates safety into three hierarchical levels of production control. Safety long-term planning starts with the preliminary hazard analysis (PHA) of construction processes. These plans are detailed and updated at both medium- and short-term planning levels. The main performance measure adopted for safety evaluation at the short-term level is the Percentage of Safe Work Packages (PSW). It monitors the degree in which work packages are safely carried out. The model also proposes a participatory mechanism that allows workers to point out existing risks as well as to evaluate risk controls. This paper discusses two empirical studies in which the model was implemented in industrial construction projects. Journal: Construction Management and Economics Pages: 159-169 Issue: 2 Volume: 22 Year: 2004 Keywords: Safety, production planning and control, performance measurement, risk management, X-DOI: 10.1080/0144619042000201367 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000201367 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:2:p:159-169 Template-Type: ReDIF-Article 1.0 Author-Name: David Heesom Author-X-Name-First: David Author-X-Name-Last: Heesom Author-Name: Lamine Mahdjoubi Author-X-Name-First: Lamine Author-X-Name-Last: Mahdjoubi Title: Trends of 4D CAD applications for construction planning Abstract: Since the early 1990s, there has been a growing interest in four-dimensional computer aided design (4D CAD) for construction project planning. Commercial 4D CAD applications are becoming more accessible and the use of this technology allows the construction planner to produce more rigorous schedules. A review of the technical competencies of these packages highlights that most of the commercially available packages concentrate on the use of 4D CAD simulations for aesthetic visualization purposes. Very few packages offer the ability to carry out analytical tasks on the developed simulation and this is often left to the interpretation of the user. A thorough appraisal of emerging research developments in 4D planning highlights that this technology is employed for various applications; however, the amount of detail required in a 4D simulation is still ambiguous. A model is proposed to determine the attributes required for use with each of the various applications of 4D CAD simulations. Finally, various lines of future research are highlighted, including the need for improved use of data exchange standards and the automation of linking the construction tasks to the 3D CAD model. Journal: Construction Management and Economics Pages: 171-182 Issue: 2 Volume: 22 Year: 2004 Keywords: Visualization, construction planning, simulation, four-dimensional CAD, X-DOI: 10.1080/0144619042000201376 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000201376 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:2:p:171-182 Template-Type: ReDIF-Article 1.0 Author-Name: Takayuki Minato Author-X-Name-First: Takayuki Author-X-Name-Last: Minato Title: Representing causal mechanism of defective designs: exploration through case studies Abstract: To learn lessons from past defective designs, it is best to analyse multiple past defect events using a common classification framework. This may reveal patterns of cause and effect that are rarely evident in single-case investigations. This paper aims to explore the causal mechanism of defective design by means of a case-studies approach. By analysing 119 defect cases from selected 101 projects, the paper presents which active failures and influencing factors that are recurrently responsible for the defective designs. More importantly, with the use of correspondence analysis it reveals five patterns of failure pathways that explain how and why defective design can occur. In the patterns, defective designs are classified into team, major, and minor errors, in which team and major errors are relatively influenced more by organizational factors, whereas minor errors by workplace factors. Countermeasures are recommended to manage the recurrent defective designs. Journal: Construction Management and Economics Pages: 183-192 Issue: 2 Volume: 22 Year: 2004 Keywords: Active failures, correspondence analysis, defective design, defences failures, human error, influencing factors, X-DOI: 10.1080/0144619042000201385 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000201385 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:2:p:183-192 Template-Type: ReDIF-Article 1.0 Author-Name: Geoffrey Briscoe Author-X-Name-First: Geoffrey Author-X-Name-Last: Briscoe Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: Sarah Millett Author-X-Name-First: Sarah Author-X-Name-Last: Millett Author-Name: Richard Neale Author-X-Name-First: Richard Author-X-Name-Last: Neale Title: Client-led strategies for construction supply chain improvement Abstract: Recent research into the UK construction industry has identified various drivers for change and prominent among these is the need for better client leadership. The aim of this research was to examine the role of the client in securing a greater degree of supply chain integration. It used three diverse case studies to examine the association between clients, the environmental factors that affect their businesses, the procurement decisions made and the level of supply chain integration that can be achieved. The results of this research provide independent empirical support for some of the recommendations of the recently released Accelerating Change report and some practical amplification. Clients are shown to be key drivers of performance improvement and innovation and are the most significant factor in achieving integration in the supply chain. Journal: Construction Management and Economics Pages: 193-201 Issue: 2 Volume: 22 Year: 2004 Keywords: Clients, environment, procurement, supply chain and integration, X-DOI: 10.1080/0144619042000201394 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000201394 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:2:p:193-201 Template-Type: ReDIF-Article 1.0 Author-Name: A. A. D. A. J. Perera Author-X-Name-First: A. A. D. A. J. Author-X-Name-Last: Perera Author-Name: K. Imriyas Author-X-Name-First: K. Author-X-Name-Last: Imriyas Title: An integrated construction project cost information system using MS Access™ and MS Project™ Abstract: The integration of time and cost management of construction projects has been recognized as the most effective way for close management. However, it has not been effectively used due to the presence of a large quantity of data with many complex interrelationships. Advanced software using current state-of-the-art could be developed to solve this problem. Nevertheless, construction organizations, especially those of small to medium size, cannot afford to procure such software due to the high cost involved in development and training. Probably, the maximum capability of small to medium size contractors is to purchase general applications - spreadsheet, database, etc. - and general time planning software. Thus, a computer solution for an existing problem using general software will have a higher potential for application. In this context, research was undertaken to establish the feasibility of the use of MS Access™ and MS Project™ to provide an integrated time and cost management information system encompassing estimating, scheduling, cost control, resource monitoring and costing, and financial control. First, through a literature review, documentary search in contractor organizations and interviews of professionals, the requirements of such a system were identified. Second, detail procedures were established by use of standard system design procedures. Third, a data modelling was developed and a relational database was established with data transfer mechanism between database and time planning software. The research proved that an effective integrated project cost management system could be developed using MS Project™ and MS Access™ as an economical solution for small to medium construction organizations. Journal: Construction Management and Economics Pages: 203-211 Issue: 2 Volume: 22 Year: 2004 Keywords: Integrated cost management, DBMS, time planning software, management information system, X-DOI: 10.1080/0144619042000201402 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000201402 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:2:p:203-211 Template-Type: ReDIF-Article 1.0 Author-Name: Qiping Shen Author-X-Name-First: Qiping Author-X-Name-Last: Shen Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Author-Name: Jacky Chung Author-X-Name-First: Jacky Author-X-Name-Last: Chung Author-Name: Pui-Yee Hui Author-X-Name-First: Pui-Yee Author-X-Name-Last: Hui Title: A framework for identification and representation of client requirements in the briefing process Abstract: The briefing process is critical to the successful delivery of construction projects. Although a number of briefing guides have been developed, attempting to address the problems of briefing, they are often criticized as being too general and implicit. This paper describes a structured framework for identifying and representing client requirements (CRs) in the briefing process. It integrates the value management (VM) methodology with function analysis system technique (FAST) and functional performance specification (FPS) to enable the client organization and project team to systematically identify, clarify and clearly represent CRs in the briefing process. It comprises four interrelated phases: preparation, information, analysis and evaluation. This paper starts with a critical review of previous work in briefing and function analysis, followed by an introduction to the research methodology and detailed illustration of the proposed framework. The use of this framework can facilitate and lead to systematic identification and clarification of client requirements and the formation of a more precise and explicit representation of these requirements. The limitations of the approach are also discussed in the paper. Journal: Construction Management and Economics Pages: 213-221 Issue: 2 Volume: 22 Year: 2004 Keywords: Briefing, value management, client requirements, function analysis, functional performance specification, X-DOI: 10.1080/0144619042000201411 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000201411 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:2:p:213-221 Template-Type: ReDIF-Article 1.0 Author-Name: Nicola Costantino Author-X-Name-First: Nicola Author-X-Name-Last: Costantino Author-Name: Roberto Pietroforte Author-X-Name-First: Roberto Author-X-Name-Last: Pietroforte Title: Production arrangements by US building and non-building contractors: an update Abstract: The paper presents the results of the first phase of a long-term study that addresses the determinants of the production arrangements by US building (commercial and residential construction) and non-building contractors (transportation, environmental and industrial construction). Empirical and census data are used to understand the subcontracting and self-performance practice of the considered contractors. The significant differences in their production arrangements are explained in terms of range of technological requirements and their relative importance within undertaken projects. Building contractors tend to subcontract much of their production, because of the relatively wider range of technological inputs of building projects and liability concerns. On the contrary, non-building contractors self-perform much of their production, because of the relatively narrower range of technological inputs of their projects and higher fixed investments in dedicated assets. Journal: Construction Management and Economics Pages: 231-235 Issue: 3 Volume: 22 Year: 2004 Keywords: US construction industry, subcontracting, self-performance, building contractors, non-building contractors, X-DOI: 10.1080/01446190310001649083 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190310001649083 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:3:p:231-235 Template-Type: ReDIF-Article 1.0 Author-Name: Shou Qing Wang Author-X-Name-First: Shou Qing Author-X-Name-Last: Wang Author-Name: Mohammed Fadhil Dulaimi Author-X-Name-First: Mohammed Fadhil Author-X-Name-Last: Dulaimi Author-Name: Muhammad Yousuf Aguria Author-X-Name-First: Muhammad Yousuf Author-X-Name-Last: Aguria Title: Risk management framework for construction projects in developing countries Abstract: It is important to manage the multifaceted risks associated with international construction projects, in particular in developing countries, not only to secure work but also to make profit. This research seeks to identify and evaluate these risks and their effective mitigation measures and to develop a risk management framework which the international investors/developers/contractors can adopt when contracting construction work in developing countries. A survey was conducted and twenty-eight critical risks were identified, categorized into three (country, market and project) hierarchical levels and their criticality evaluated and ranked. For each of the identified risks, practical mitigation measures have also been proposed and evaluated. Almost all mitigation measures have been perceived by the survey respondents as effective. A risk model, named Alien Eyes' Risk Model, which shows the hierarchical levels of the risks and the influence relationship among the risks, is also proposed. Based on the findings, a qualitative risk mitigation framework was finally proposed which will benefit the risk management of construction project in developing countries. Journal: Construction Management and Economics Pages: 237-252 Issue: 3 Volume: 22 Year: 2004 Keywords: Risk management, risk identification, risk mitigation, risk model, international construction project, developing countries, X-DOI: 10.1080/0144619032000124689 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000124689 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:3:p:237-252 Template-Type: ReDIF-Article 1.0 Author-Name: H. Giritli Author-X-Name-First: H. Author-X-Name-Last: Giritli Author-Name: G. Topcu Oraz Author-X-Name-First: G. Topcu Author-X-Name-Last: Oraz Title: Leadership styles: some evidence from the Turkish construction industry Abstract: The construction industry provides an interesting research alternative to other sectors because of its unique characteristics. For this reason, this paper aims to explore and compare the leadership styles of managerial personnel in the construction industry. The study focuses on the empirical evaluations of the similarities and differences in leadership styles of construction professionals. A managerial-style questionnaire is developed based on the review of relevant literature. Questionnaire data obtained from 43 respondents show that the authoritative style is more frequently performed than all other styles. Results also indicate differences in terms of gender and managerial hierarchy. Implications of the results are discussed. Journal: Construction Management and Economics Pages: 253-262 Issue: 3 Volume: 22 Year: 2004 Keywords: Leadership, construction industry, Turkey, X-DOI: 10.1080/01446190310001630993 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190310001630993 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:3:p:253-262 Template-Type: ReDIF-Article 1.0 Author-Name: S. L. Tang Author-X-Name-First: S. L. Author-X-Name-Last: Tang Author-Name: Raymond Aoieong Author-X-Name-First: Raymond Author-X-Name-Last: Aoieong Author-Name: Syed Ahmed Author-X-Name-First: Syed Author-X-Name-Last: Ahmed Title: The use of Process Cost Model (PCM) for measuring quality costs of construction projects: model testing Abstract: A 'Process Cost Model (PCM)' approach has been proposed previously (Aoieong et al., 2002) for measuring the quality costs of construction projects. The PCM is proposed because the traditional models on PAF (prevention, appraisal and failure) quality costs have been found to be unsuitable for the construction industry, although they may be successful in the manufacturing industry. The focus of PCM, unlike PAF model, is no longer on capturing the total quality costs of an entire project but the quality costs of a particular process. It is simple and more feasible to be applied in construction projects and is in line with the 'process approach' and 'continual improvement' concepts of the latest (year 2000) version of the ISO 9000 quality management system, which is a step closer to Total Quality Management (Aoieong and Tang, 2002). The current paper describes two case studies using the PCM to capture quality costs on two construction projects. The case studies reveal that the PCM is feasible, practicable and easy to use. It is also possible to use the model to achieve 'continual improvement' by referencing the quality costs of a particular construction process. The Process Cost Model (PCM) is therefore a better model than the traditional PAF model for application in the construction industry for measuring quality costs. Journal: Construction Management and Economics Pages: 263-275 Issue: 3 Volume: 22 Year: 2004 Keywords: Process cost model, PCM, PAF, quality, costs, construction, processes, TQM, Hong Kong, X-DOI: 10.1080/0144619032000064091 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000064091 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:3:p:263-275 Template-Type: ReDIF-Article 1.0 Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Author-Name: Jiang Hongbin Author-X-Name-First: Jiang Author-X-Name-Last: Hongbin Title: Estimation of international construction performance: analysis at the country level Abstract: The measurement or estimation of the degree of internationalization of multinational corporations (MNCs) remains lacking although many studies have been completed on MNCs in the construction industry. Dunning's Eclectic Paradigm suggests that the determinants of internationalization depends on the ownership (O), locational (L) and internalization (I) advantages of a firm. Another important factor relates to the involvement of a firm among specialized fields in the construction industry, i.e. the specialty (S) advantages. This paper proposes the OLI+S model for measuring/estimating the internationalization process of construction MNCs, according to nationalities, using the following ratios: O-IRTR, L-IBD, I-OMS and S-ISF. Major players in the international construction market were analysed using these ratios. The OLI+S model shows that construction MNCs from different nationalities demonstrated different patterns in the internationalization process depending on their business strategies, indigenous market situations, historical factors, etc. among others. Journal: Construction Management and Economics Pages: 277-289 Issue: 3 Volume: 22 Year: 2004 Keywords: internationalization, construction, ownership, locational, internalization, specialty, nationalities, X-DOI: 10.1080/0144619032000089607 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000089607 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:3:p:277-289 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Goodrum Author-X-Name-First: Paul Author-X-Name-Last: Goodrum Author-Name: Manish Gangwar Author-X-Name-First: Manish Author-X-Name-Last: Gangwar Title: The relationship between changes in equipment technology and wages in the US construction industry Abstract: The US construction industry has witnessed a drop in real wages since 1970. The decline in real wages may be attributed to a combination of socio-economic factors like migrant labourers, fringe benefits, safety procedures, union membership and worker skills. Another factor that may be impacting construction real wages is technological changes over the past couple of decades, including technological changes in construction equipment. This paper examines the relationship between changes in equipment technology and changes in construction wages with the help of five factors of equipment technology change: control, energy, ergonomics, functionality and information processing. Furthermore, data from the US Bureau of Labor Statistics' Current Population Survey is used to examine the effects of computer usage on wages among US hourly workers in construction. The research findings show significant relations exist between changes in equipment control, functionality and information processing with wages among non-supervisory workers. Another finding indicated that although non-supervisory construction workers who use computers at work earn higher hourly wages, there was no added wage benefit after controlling for the effects of experience, education and age. Journal: Construction Management and Economics Pages: 291-301 Issue: 3 Volume: 22 Year: 2004 Keywords: Construction, labour, equipment technology, wages, computer, X-DOI: 10.1080/0144619032000116543 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000116543 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:3:p:291-301 Template-Type: ReDIF-Article 1.0 Author-Name: Alan Wild Author-X-Name-First: Alan Author-X-Name-Last: Wild Title: Re-interpreting the Building Industry Communications Research Project Abstract: The archives of the Building Industry Communications Research Project (BICRP) 1963-66 are reviewed. Established by important construction interests, this project explored problems of co-ordination in UK construction. The research was undertaken by the Tavistock Institute of Human Relations. The archives record both an evolving appreciation of construction and the conflicts within the Communications Research Committee, which oversaw the research and represented construction and its dominant client, the public sector. The changing outer context and shifting interpretation of the researchers destabilized the BICRP. It became caught up in the turbulence of its environment, de-stabilizing the consensus which had led to the project. Schon's concept of the Situation, and systems ideas of under-boundedness and under-organization, underpin the re-interpretation and establish the current relevance of the BICRP. This exemplifies the recurring, institutional difficulties of UK construction. A suggestion for further inquiry is made including cross-cultural comparisons around themes of uncertainty and information. Journal: Construction Management and Economics Pages: 303-310 Issue: 3 Volume: 22 Year: 2004 Keywords: Communications research, reinterpretation, situation, uncertainty, under-boundedness, X-DOI: 10.1080/0144619032000103263 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000103263 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:3:p:303-310 Template-Type: ReDIF-Article 1.0 Author-Name: Kazunobu Minami Author-X-Name-First: Kazunobu Author-X-Name-Last: Minami Title: Whole life appraisal of the repair and improvement work costs of Post Office buildings in Japan Abstract: A complete enumerative study was made of the repair and improvement work costs of the 1255 general sorting post offices throughout Japan in 2000. This paper analyses the 2000 expenditure figures from both the national enumerative survey and the survey of the five post offices being monitored for twenty years after their completion. The results show that the average annual repair work cost is 665 yen per square metre, and the average annual improvement work cost is 4231 yen per square metre, which total an average annual cost of 4896 yen per square metre. The repair and improvement work cost reaches an accumulated total of around 50 000 yen per square metre 20 years after a building has been completed, and an accumulated total of around 250 000 yen per square metre 50 years after completion. After analysing the relationship between the rebuilding cycle, and rebuilding, repair and improvement costs, by changing the present rebuilding at age 40 to building additions at age 40 and rebuilding at age 60, it became apparent that we could expect a significant reduction in facilities investment costs. Journal: Construction Management and Economics Pages: 311-318 Issue: 3 Volume: 22 Year: 2004 Keywords: Whole life cost, post office, investment, repair, improvement, X-DOI: 10.1080/0144619032000108254 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000108254 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:3:p:311-318 Template-Type: ReDIF-Article 1.0 Author-Name: Mei-Yung Leung Author-X-Name-First: Mei-Yung Author-X-Name-Last: Leung Author-Name: S. Thomas Ng Author-X-Name-First: S. Thomas Author-X-Name-Last: Ng Author-Name: Sai-On Cheung Author-X-Name-First: Sai-On Author-X-Name-Last: Cheung Title: Measuring construction project participant satisfaction Abstract: Construction projects involve numerous stakeholders, and their satisfaction could directly influence the performance of subsequent projects. Driven by a desire to improve project success, the critical satisfaction factors pertinent to the construction management process should be identified. In this paper, an overall study regarding the behavioural management mechanisms amongst project participants is presented. Eleven behavioural management mechanisms are identified and 15 hypotheses are established for this study. The concepts of satisfaction, project goals, various management mechanisms and their interrelationships are discussed and investigated in relation to construction projects. The results indicate that management mechanisms rather than particular project goal could directly affect the participant satisfaction. Cooperation/participation, task/team conflict and goal commitment are the critical factors influencing the final outcome (satisfaction) in the complicated management process. Moreover, conflict on the task amongst the participants is the moderation mechanisms for the relationship between goal commitment and participant satisfaction. There is a significantly positive relationship between commitment and satisfaction in construction project management, while high level of conflict is stimulated in the goal setting process amongst the participants. Journal: Construction Management and Economics Pages: 319-331 Issue: 3 Volume: 22 Year: 2004 Keywords: Project management, participant satisfaction, conflict, commitment, co-operation/participation, X-DOI: 10.1080/01446190320000000000 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190320000000000 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:3:p:319-331 Template-Type: ReDIF-Article 1.0 Author-Name: C. Y. Yiu Author-X-Name-First: C. Y. Author-X-Name-Last: Yiu Author-Name: X. H. Lu Author-X-Name-First: X. H. Author-X-Name-Last: Lu Author-Name: M. Y. Leung Author-X-Name-First: M. Y. Author-X-Name-Last: Leung Author-Name: W. X. Jin Author-X-Name-First: W. X. Author-X-Name-Last: Jin Title: A longitudinal analysis on the relationship between construction output and GDP in Hong Kong Abstract: The relationship between construction output and economic growth has been well discussed by construction economists. Most of the previous studies found a positive correlation between gross domestic product (GDP) per capita and various measures of construction output. However, cross-sectional analysis was commonly adopted but longitudinal analysis has been called upon. Furthermore, recent research argued that non-linear relationship between GDP and construction output exists because of different stages of economic development in different countries. They explained the phenomenon by means of the change of the growth rates of construction output at different stages of economic development, but the argument has not yet been rigorously tested. With the availability of long time-series of data of Hong Kong construction industry, this paper attempts to test longitudinally the relationship between the real growth rate of construction output and the real growth rate of GDP. It was found that the growth rate of GDP led that of construction output, and as the growth rate of GDP increased, the growth rate of construction output was marginally diminishing. It agrees with the proposition that construction industry is relatively inefficient in productivity improvement and the accumulation of capital investment results in a marginally diminishing growth of construction output. Journal: Construction Management and Economics Pages: 339-345 Issue: 4 Volume: 22 Year: 2004 Keywords: Hong Kong construction industry, construction growth, GDP growth, economic development, X-DOI: 10.1080/0144619042000176465 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000176465 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:4:p:339-345 Template-Type: ReDIF-Article 1.0 Author-Name: Lam Yow Thim Author-X-Name-First: Lam Yow Author-X-Name-Last: Thim Author-Name: Chen Zonggui Author-X-Name-First: Chen Author-X-Name-Last: Zonggui Title: The development of the construction legal system in China Abstract: China has been developing at an amazing speed since it carried out reform and open-door policy in 1978. Construction industry is playing a leading role in the rapid Chinese economic development. At the same time, China has also worked hard to encourage overseas investors to expand their investment in the construction industry. With its development over the years, China has established a legal system for governing construction activities. To participate in such a major market in the world, it is important to understand the legal system governing it and the impact of China's joining the World Trade Organization. The Chinese construction laws and practice are still very different from the international norm. If foreign participants are to make a success out of doing business in China, they must understand the Chinese way of life. Particularly, they must prepare to adapt to an environment where new rules are created as circumstances and situations change. Journal: Construction Management and Economics Pages: 347-356 Issue: 4 Volume: 22 Year: 2004 Keywords: Construction laws, legal system, construction industry, China, foreign investment, foreign designers and contractors, World Trade Organization (WTO), X-DOI: 10.1080/0144619032000122177 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000122177 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:4:p:347-356 Template-Type: ReDIF-Article 1.0 Author-Name: Nick Blismas Author-X-Name-First: Nick Author-X-Name-Last: Blismas Author-Name: William Sher Author-X-Name-First: William Author-X-Name-Last: Sher Author-Name: Antony Thorpe Author-X-Name-First: Antony Author-X-Name-Last: Thorpe Author-Name: Andrew Baldwin Author-X-Name-First: Andrew Author-X-Name-Last: Baldwin Title: A typology for clients' multi-project environments Abstract: Construction management research and practice is dominated by a single project paradigm. This does not reflect the true nature of many construction clients who have large multi-project portfolios. Traditional single project management strategies are usually adopted for managing such portfolios - with limited success. The literature suggests that programmes, within portfolios, require different forms of management in order to optimize project delivery. In order to better understand these portfolios and thereby allow the exploration of new forms of management, a typology has been developed mapping out the various features of client's construction portfolios. The resultant typology provides a simple method for identifying the programme composition of a portfolio, highlighting the expected features of each programme type, and thereby directing management attention to the main aspects of each programme that can be optimized for efficiency. Six cases of client's construction project portfolios were studied using a highly structured, replication logic, case study methodology. A typology of clients' multi-project environments was developed and validated through literal and theoretical replication between cases. Three main types emerged as descriptive of programmes within client's construction portfolios: bounded programmes, target programmes and rolling programmes. The distinctive features of each type suggest that programme-specific approaches may be necessary for the successful delivery of projects within client's construction portfolios. Journal: Construction Management and Economics Pages: 357-371 Issue: 4 Volume: 22 Year: 2004 Keywords: Case studies, multi-projects, portfolio, programmes, typology, X-DOI: 10.1080/01446190310001649047 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190310001649047 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:4:p:357-371 Template-Type: ReDIF-Article 1.0 Author-Name: Michael Garvin Author-X-Name-First: Michael Author-X-Name-Last: Garvin Author-Name: Charles Cheah Author-X-Name-First: Charles Author-X-Name-Last: Cheah Title: Valuation techniques for infrastructure investment decisions Abstract: Public infrastructure owners are increasingly soliciting BOT arrangements to deliver needed infrastructure facilities. Such arrangements potentially preserve a public owner's capital capacity for allocation to projects that cannot support themselves by essentially 'pulling' projects from the private sector. Before soliciting these arrangements, however, owners should independently evaluate a project's economic viability to fully appraise the issues and variables involved. Unfortunately, project analysts often apply evaluation methods without regard for their assumptions and limitations. A case study of a toll road project in the USA provides the basis for examining the assumptions behind both traditional and option valuation models. The case demonstrates the use of an option pricing model to augment traditional project evaluation by capturing strategic considerations, in this case the value of project deferment. The presentation illustrates that the selection of a valuation model depends critically upon the characteristics of a project's variables and that informed judgment remains an integral part of the decision-making process. Journal: Construction Management and Economics Pages: 373-383 Issue: 4 Volume: 22 Year: 2004 Keywords: Valuation techniques, infrastructure investments, real options, risk neutrality, X-DOI: 10.1080/01446190310001649010 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190310001649010 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:4:p:373-383 Template-Type: ReDIF-Article 1.0 Author-Name: M. Loosemore Author-X-Name-First: M. Author-X-Name-Last: Loosemore Author-Name: A. S. Y. Lam Author-X-Name-First: A. S. Y. Author-X-Name-Last: Lam Title: The locus of control: a determinant of opportunistic behaviour in construction health and safety Abstract: Current research and practice in the field of risk management focus almost exclusively on the downside of risk, meaning that many opportunities for improved performance go unmissed. There is substantial evidence that opportunities demand a different management approach to problems and, that there is need to better understand this process. However, our understanding of opportunism has been hindered by the absence of research into the main forces that impede and drive opportunistic behaviour. This paper explores these forces and investigates one in particular - the locus of control (self perceived influence over decision-making). This investigation is conducted in a health and safety context because this is an area of particularly poor performance in the construction industry, where the locus of control is especially relevant. The paper concludes that the overall locus of control is high in relation to health and safety issues. However, there is considerable discrepancy in perceived levels of influence between different occupational, gender and ethnic groups, which need to be addressed if the industry is to improve its performance in this area. Journal: Construction Management and Economics Pages: 385-394 Issue: 4 Volume: 22 Year: 2004 Keywords: Opportunity management, risk management, behaviour, locus of control, empowerment, health and safety, gender, culture, discrimination, X-DOI: 10.1080/0144619042000239997 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000239997 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:4:p:385-394 Template-Type: ReDIF-Article 1.0 Author-Name: M. Y. L. Chew Author-X-Name-First: M. Y. L. Author-X-Name-Last: Chew Author-Name: S. S. Tan Author-X-Name-First: S. S. Author-X-Name-Last: Tan Title: A multivariate approach to maintenance prediction of wet areas Abstract: A regression model to predict the maintainability of wet areas was developed. The model was derived from comprehensive condition surveys, interviews with professionals and defect analysis of 96 buildings. The study showed that plumbing selection, access for fitting maintenance, material maintainability, usage and construction quality are the most significant parameters associated with the maintainability of wet areas. Journal: Construction Management and Economics Pages: 395-407 Issue: 4 Volume: 22 Year: 2004 Keywords: Maintainability, wet area, multiple regression analysis, maintenance prediction model, X-DOI: 10.1080/0144619032000124670 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000124670 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:4:p:395-407 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Jasmine Lin Author-X-Name-First: Jasmine Author-X-Name-Last: Lin Title: Career, family and work environment determinants of organizational commitment among women in the Australian construction industry Abstract: A survey of women in the Australian construction industry was undertaken to examine the relationship between career, family and work environment variables on women's organizational commitment. Questionnaires were distributed to three hundred women in construction occupations and 109 completed and usable questionnaires were returned. Career choice commitment, satisfaction with career progression, job involvement, supervisory support and perception of the organizational diversity climate were significantly correlated with respondents' organizational commitment. No demographic or family variables were correlated with organizational commitment. Neither did organizational commitment differ significantly between women with dependent children and childless women or women with non-dependent children. It is concluded that construction firms aiming to improve organizational commitment among female employees should ensure women have access to career development opportunities and ensure just processes are used in allocating organizational rewards. Construction firms are also recommended to implement diversity initiatives and educate employees, particularly supervisors, in supportive management for a diverse workforce. Journal: Construction Management and Economics Pages: 409-420 Issue: 4 Volume: 22 Year: 2004 Keywords: Women, construction, work-family conflict, career, organizational commitment, X-DOI: 10.1080/0144619032000122186 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000122186 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:4:p:409-420 Template-Type: ReDIF-Article 1.0 Author-Name: Jan Brochner Author-X-Name-First: Jan Author-X-Name-Last: Brochner Author-Name: Sara Rosander Author-X-Name-First: Sara Author-X-Name-Last: Rosander Author-Name: Fredrik Waara Author-X-Name-First: Fredrik Author-X-Name-Last: Waara Title: Cross-border post-acquisition knowledge transfer among construction consultants Abstract: Mergers and acquisitions among engineering consulting firms and other professional service organizations occur frequently. International acquisitions should pose challenges because of corporate and national barriers of culture. The purpose here has been to study the relative influences of technical and cultural heterogeneity on knowledge transfer in a post-merger situation where offices in two countries are involved. In 2001, the UK-based WSP Group - providing management and consultancy services to the property, land and construction sectors - acquired J&W, a leading engineering consultancy firm in Sweden. Two technical disciplines, rail and contaminated land, were selected for this survey. Four offices, two in each country, participated with eight consultants in each place. The survey shows occasional, two-way knowledge exchange taking place 16 months after acquisition. Face-to-face meetings, e-mail and technical business gatherings are perceived as the best transfer mechanisms. The presence of knowledgeable customers differs between disciplines and seems to explain differences between transfer patterns. Among metrics for knowledge transfer, the number of international joint projects is assigned the highest rank. Consequences for the choice of organization of knowledge transfer, as well as the measurement and communication of progress in knowledge transfer, are identified. Journal: Construction Management and Economics Pages: 421-427 Issue: 4 Volume: 22 Year: 2004 Keywords: Engineering, culture, knowledge transfer, acquisitions, professional services, X-DOI: 10.1080/0144619042000240003 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000240003 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:4:p:421-427 Template-Type: ReDIF-Article 1.0 Author-Name: Mohammed Kishk Author-X-Name-First: Mohammed Author-X-Name-Last: Kishk Title: Combining various facets of uncertainty in whole-life cost modelling Abstract: Estimates for various parameters in a whole-life costing (WLC) exercise are obtained from different sources each with its own level and type of uncertainty. A practical procedure is developed to handle statistically significant data and expert assessments within the same whole-life costing (WLC) model calculation. First, various methods used to combine random and subjective data are critically reviewed with emphasis on their suitability to WLC modelling. This is followed by the identification of an appropriate mathematical framework into which all information and data are transformed to a common representation making their integration a straightforward task. The proposed procedure is then implemented into a computational algorithm. The efficacy of the algorithm is explained in the context of a selected example application. Journal: Construction Management and Economics Pages: 429-435 Issue: 4 Volume: 22 Year: 2004 Keywords: Fuzzy set theory, whole-life costing, uncertainty combination, X-DOI: 10.1080/0144619042000176483 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000176483 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:4:p:429-435 Template-Type: ReDIF-Article 1.0 Author-Name: Florence Phua Author-X-Name-First: Florence Author-X-Name-Last: Phua Title: Modelling the determinants of multi-firm project success: a grounded exploration of differing participant perspectives Abstract: Existing approaches to multi-firm project success have been suggested as being overly normative and deductive. They can also be criticized for failing to accommodate the heterogeneous perspectives of respective participants in multi-firm projects that might be hypothesized intrinsically to differ by industry sector, size and other firm demographics. This research tests the extent to which the determinants of project success differ by sector, firm size and origin within the construction industry using an inductive, grounded approach to model building. Results confirm that project success factors differ significantly between project participants, and suggest the wider application of inductive methodologies to identify such heterogeneous factors. Journal: Construction Management and Economics Pages: 451-459 Issue: 5 Volume: 22 Year: 2004 Keywords: Project success, determinants of project success, grounded approach, modelling, X-DOI: 10.1080/0144619042000190243 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000190243 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:5:p:451-459 Template-Type: ReDIF-Article 1.0 Author-Name: C. S. Poon Author-X-Name-First: C. S. Author-X-Name-Last: Poon Author-Name: Ann Yu Author-X-Name-First: Ann Author-X-Name-Last: Yu Author-Name: L. Jaillon Author-X-Name-First: L. Author-X-Name-Last: Jaillon Title: Reducing building waste at construction sites in Hong Kong Abstract: The building industry is using a considerable amount of resources, but if the life cycle of the material on site is closely examined, it is generally known that there is a relatively large portion of the materials being wasted because of poor material control on building sites. The problem of material wastage is not an isolated issue on construction sites. It is also an environmental concern. Hong Kong is running out of both reclamation sites and landfill space for the disposal of construction & demolition (C&D) waste. Many resources can be conserved and the amount of C&D waste required to be disposed of should be greatly reduced if better management of materials is practiced on building sites. This paper reports on a recent study conducted in Hong Kong relating to material control on construction sites with high-rise multi-storey buildings. In the paper, the causes of building waste are identified and the wastage levels of various trades for public housing and private residential projects in Hong Kong are quantified. The role of material control in reducing building waste is then discussed in details under three headings, namely design, material procurement and handling, and site management and practices. Journal: Construction Management and Economics Pages: 461-470 Issue: 5 Volume: 22 Year: 2004 Keywords: building industry, construction waste, waste reduction, material control, Hong Kong, X-DOI: 10.1080/0144619042000202816 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000202816 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:5:p:461-470 Template-Type: ReDIF-Article 1.0 Author-Name: Francis Ng Author-X-Name-First: Francis Author-X-Name-Last: Ng Author-Name: Hans Bjornsson Author-X-Name-First: Hans Author-X-Name-Last: Bjornsson Title: Using real option and decision analysis to evaluate investments in the architecture, construction and engineering industry Abstract: Many architecture, engineering and construction (AEC) professionals would like to use real option (RO) and decision analysis (DA) to evaluate alternatives in investment in the face of uncertainty. However, they have difficulty deciding which one to use and many are not aware of the subtle differences in assumptions and techniques between the two methodologies. We explain how DA and RO can be applied in complete and incomplete markets and what implicit assumptions we need to be aware of in each scenario. Through a toll road example, it is shown that, in a complete market, DA and RO give the same valuation regardless of the choice of the utility function. A formula is provided for pricing any investment in a complete market. The paper also discusses why the values calculated using DA and RO differ in an incomplete market and when DA is more appropriate than RO and vice versa. Journal: Construction Management and Economics Pages: 471-482 Issue: 5 Volume: 22 Year: 2004 Keywords: Decision analysis, real option, investment evaluation, sequential decision-making, market, X-DOI: 10.1080/01446190310001649074 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190310001649074 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:5:p:471-482 Template-Type: ReDIF-Article 1.0 Author-Name: S. Thomas Ng Author-X-Name-First: S. Thomas Author-X-Name-Last: Ng Author-Name: Sai On Cheung Author-X-Name-First: Sai On Author-X-Name-Last: Cheung Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Toby Wong Author-X-Name-First: Toby Author-X-Name-Last: Wong Title: An integrated regression analysis and time series model for construction tender price index forecasting Abstract: Clients need to be informed in advance of their likely future financial commitments and cost implications as the design evolves. This requires the estimation of building cost based on historic cost data that is updated by a forecasted Tender Price Index (TPI), with the reliability of the estimates depending significantly on accurate projections being obtained of the TPI for the forthcoming quarters. In practice, the prediction of construction tender price index movement entails a judgemental projection of future market conditions, including inflation. Statistical techniques such as Regression Analysis (RA) and Time Series (TS) modelling provide a powerful means of improving predictive accuracy when used individually. An integrated RA-TS model is developed and its predictive power compared with the individual RA or TS models. The accuracy of the RA-TS model is shown to outperform the individual RA and TS models in both one and two-period forecasts, with the integrated RA-TS model accurately predicting (95% confidence level) one-quarter forecasts for all the 34 holdout periods involved, with only one period not meeting the confidence limit for two-quarter forecasts. Journal: Construction Management and Economics Pages: 483-493 Issue: 5 Volume: 22 Year: 2004 Keywords: Cost estimate, integrated forecasting model, tender price index forecast, time series modelling, regression analysis, X-DOI: 10.1080/0144619042000202799 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000202799 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:5:p:483-493 Template-Type: ReDIF-Article 1.0 Author-Name: Nuno Gil Author-X-Name-First: Nuno Author-X-Name-Last: Gil Author-Name: Iris Tommelein Author-X-Name-First: Iris Author-X-Name-Last: Tommelein Author-Name: Glenn Ballard Author-X-Name-First: Glenn Author-X-Name-Last: Ballard Title: Theoretical comparison of alternative delivery systems for projects in unpredictable environments Abstract: A project delivery process simulation is presented based upon empirical studies in the design-build environment of semiconductor fabrication facilities ('fabs'). The model captures key tasks and decisions in design, procurement and construction, as well as design criteria changes along the delivery of a R&D fab utility system. Simulation shows that to involve the specialty contractor from the project start on average expedites project delivery since it prevents delays caused by bidding and by contractors' unfamiliarity with the design product definition. Yet, in unpredictable project environments - environments in which design criteria are likely to change irrespectively of the project progress status - simulation reveals that the averages of construction rework and waste increase if design is prematurely frozen. Assuming that work methods do not change and design criteria remain uncertain, results indicate that a system that combines early contractor involvement with judicious postponement of the design start reduces the average duration of the fab utility delivery in relation to the expected duration if competitive bidding was used, with limited increase in the averages of construction rework and waste. Additional efficiency is gained when specialty contractors relax conservative assumptions on anticipated site conditions. An economic model uses simulation results to assess the tradeoffs between alternative project delivery systems for the case of R&D fabs. Journal: Construction Management and Economics Pages: 495-508 Issue: 5 Volume: 22 Year: 2004 Keywords: Specialty contractor, simulation, change, postponement, facility delivery compression, X-DOI: 10.1080/01446190310001649100 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190310001649100 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:5:p:495-508 Template-Type: ReDIF-Article 1.0 Author-Name: Chao-Hui Wu Author-X-Name-First: Chao-Hui Author-X-Name-Last: Wu Author-Name: Ting-Ya Hsieh Author-X-Name-First: Ting-Ya Author-X-Name-Last: Hsieh Author-Name: Wen-Lon Cheng Author-X-Name-First: Wen-Lon Author-X-Name-Last: Cheng Author-Name: Shih-Tong Lu Author-X-Name-First: Shih-Tong Author-X-Name-Last: Lu Title: Grey relation analysis of causes for change orders in highway construction Abstract: Change orders issued during the construction of the second national highway in Taiwan have been categorized depending on whether they originate from owner, design consultant, on-site contractor unit, or external parties. A total of 34 change order causes are found for this construction project. Grey relation analysis (GRA) was used in this study, and change orders in the second national highway construction project in Taiwan are characterized by the following conclusions: (1) poorly executed design drawings, policy changes and new management requirements are not important causes of change orders; and (2) more roadways should be designed as viaducts to avoid levying more land and negotiating with landowner. Journal: Construction Management and Economics Pages: 509-520 Issue: 5 Volume: 22 Year: 2004 Keywords: Change orders, entropy method, Grey relation analysis, highway construction, Taiwan, X-DOI: 10.1080/0144619042000202735 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000202735 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:5:p:509-520 Template-Type: ReDIF-Article 1.0 Author-Name: Linda Clarke Author-X-Name-First: Linda Author-X-Name-Last: Clarke Author-Name: Georg Herrmann Author-X-Name-First: Georg Author-X-Name-Last: Herrmann Title: Cost vs. production: disparities in social housing construction in Britain and Germany Abstract: The nature of the labour process in the British construction industry is different from that in Germany. The rationale of the British system is based on controlling costs through overseeing contract relations, themselves circumscribing a range of narrow, clearly defined and priced tasks. The production process has become secondary and production expertise restricted. In contrast, in Germany cost aspects are incorporated into, rather than separated from, the production system, built on the interaction of capital and labour and on a high level of production expertise. Employment relations rather than contract relations predominate and circumscribe a set of skills drawn from the potential of the labour force and dependent on broad-based vocational education. A detailed investigation of social housebuilding projects and the firms involved in Britain and Germany reveals the need for more skills, and a qualitatively different constellation of skills, professional and operative, in Britain. Journal: Construction Management and Economics Pages: 521-532 Issue: 5 Volume: 22 Year: 2004 Keywords: Germany, housebuilding, skills, training, comparison, X-DOI: 10.1080/01446190310001649119 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190310001649119 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:5:p:521-532 Template-Type: ReDIF-Article 1.0 Author-Name: Christopher Miller Author-X-Name-First: Christopher Author-X-Name-Last: Miller Author-Name: Gary Packham Author-X-Name-First: Gary Author-X-Name-Last: Packham Author-Name: David Pickernell Author-X-Name-First: David Author-X-Name-Last: Pickernell Author-Name: Mark Mcgovern Author-X-Name-First: Mark Author-X-Name-Last: Mcgovern Title: Building for the future: the potential importance of the construction industry in Welsh economic development policy Abstract: Government aid offered to Wales, and largely spent on attracting foreign direct investment, has yet to provide tangible benefits in terms of relative economic prosperity and sustained job creation. The present policy focus is therefore now concerned with creating innovative solutions led by local individuals, firms and communities. New economic strategic aims and objectives have failed to attach significance to the potential importance of the construction sector in assisting this economic regeneration of regions and, in particular, the benefits that can be derived from the development of the small construction enterprise (SCE). It is argued that for the SCE to survive and grow, it is necessary both to acknowledge the role of small firms and to develop beneficial training packages. Moreover, it is imperative that such new initiatives engender an inclusive culture that meet the needs of all contracting parties and aspires to the notion of increased profitability for all. Journal: Construction Management and Economics Pages: 533-540 Issue: 5 Volume: 22 Year: 2004 Keywords: Small construction enterprises, government policy, training and development, Wales, X-DOI: 10.1080/01446190310001649128 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190310001649128 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:5:p:533-540 Template-Type: ReDIF-Article 1.0 Author-Name: Timothy Michael Lewis Author-X-Name-First: Timothy Michael Author-X-Name-Last: Lewis Title: The construction industry in the economy of Trinidad & Tobago Abstract: The construction sector is generally one of the larger and more important sectors of a nation's economy. If economic policy is to achieve its desired objectives, it is necessary to have some understanding of how the economy will react to various changes that can be effected. Because the construction sector is large and responsive, it is a key sector for manipulating the economy and, hence, it is important to know what the role of the construction sector is in the economy. Some of the key issues here are the effect of changes in GDP on construction output and employment, as well as the effects of changes in money supply, inflation, expenditure on the public sector investment programme and the rate of approval of building plans. This paper sets out to see if there are relationships between these factors that justify further investigation and, as such, helps establish a research agenda for the industry, particularly in comparing developed and less-developed countries. Journal: Construction Management and Economics Pages: 541-549 Issue: 5 Volume: 22 Year: 2004 Keywords: Trinidad & Tobago, GDP, employment, inflation, public sector investment programme, X-DOI: 10.1080/0144619042000190234 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000190234 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:5:p:541-549 Template-Type: ReDIF-Article 1.0 Author-Name: Evia Wong Author-X-Name-First: Evia Author-X-Name-Last: Wong Author-Name: Robin Yip Author-X-Name-First: Robin Author-X-Name-Last: Yip Title: Promoting sustainable construction waste management in Hong Kong Abstract: Similar to many affluent cities found elsewhere in the world, Hong Kong is currently facing a great challenge to manage the wastes generated from its construction and demolition (C&D) activities that has wide-ranging impacts on the environment. To tackle this, the Hong Kong Special and Administrative Region (HKSAR) Government has signalled the required changes by sorting out the inert substances from C&D waste for reusing and recycling and using recycled building materials in construction through its role as both a construction client and contractor. The current practices and attitudes of local project participants towards C&D waste management were collected through questionnaires. A total of 69 questionnaires were received: 61% of the respondents stated that their projects did not take any measures to collect and separate C&D wastes and 64% of the projects did not use recycled building materials in construction. The prevailing problems of local construction industry are addressed through examinations of the constraints involved in improving C&D waste treatment and according to the results of the survey, to evaluate the practicability of increasing the capability and capacity of the industry to learn to be more sustainable. Journal: Construction Management and Economics Pages: 563-566 Issue: 6 Volume: 22 Year: 2004 Keywords: Construction and demolition waste, sorting, recycling, X-DOI: 10.1080/0144619042000226270 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000226270 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:6:p:563-566 Template-Type: ReDIF-Article 1.0 Author-Name: Bambang Trigunarsyah Author-X-Name-First: Bambang Author-X-Name-Last: Trigunarsyah Title: A review of current practice in constructability improvement: case studies on construction projects in Indonesia Abstract: The concept of constructability emerged in the late 1970s, evolved from studies into how improvement can be achieved to increase cost efficiency and quality in the construction industry. It is an approach that links the design and construction processes. The studies in the USA, UK and, later, in Australia have demonstrated that improved constructability has lead to significant savings in both cost and time required for completing construction projects. However, in implementing constructability improvement, it is important to consider the uniqueness of the construction industry in a specific country. To improve constructability in Indonesian construction projects, two main questions need to be answered: how is construction integrated into planning and design in existing practice and how can constructability be improved. Case studies indicate that the contractual relationships between the project team members determine the options for early involvement of construction personnel, and that the current constructability practices have had some positive impacts on project performance. In addition to a reduction in constructability problems, current constructability practices have enabled significant economic savings. Journal: Construction Management and Economics Pages: 567-580 Issue: 6 Volume: 22 Year: 2004 Keywords: Constructability improvement, Indonesia, project performance, construction industry, X-DOI: 10.1080/0144619042000202870 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000202870 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:6:p:567-580 Template-Type: ReDIF-Article 1.0 Author-Name: M. Y. L. Chew Author-X-Name-First: M. Y. L. Author-X-Name-Last: Chew Author-Name: Nayanthara De Silva Author-X-Name-First: Nayanthara Author-X-Name-Last: De Silva Author-Name: S. S. Tan Author-X-Name-First: S. S. Author-X-Name-Last: Tan Title: A neural network approach to assessing building facade maintainability in the tropics Abstract: A model was developed to assess the maintainability of facade using neural network techniques. Inputs were derived from comprehensive studies of 570 tall buildings (more than 12 stories) through detailed field evaluation and interviews with professionals in the whole building delivery process. Sensitivity analysis showed that the most significant factors associated with facade maintainability include the system selection, detailing, accessibility and material performance. Journal: Construction Management and Economics Pages: 581-594 Issue: 6 Volume: 22 Year: 2004 Keywords: Maintainability, facade, risk, building defect, neural network, sensitivity analysis, X-DOI: 10.1080/01446190310001631019 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190310001631019 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:6:p:581-594 Template-Type: ReDIF-Article 1.0 Author-Name: Man-Fong Ho Author-X-Name-First: Man-Fong Author-X-Name-Last: Ho Author-Name: Derek Drew Author-X-Name-First: Derek Author-X-Name-Last: Drew Author-Name: Denny Mcgeorge Author-X-Name-First: Denny Author-X-Name-Last: Mcgeorge Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: Implementing corporate ethics management and its comparison with the safety management system: a case study in Hong Kong Abstract: A case study of one general contracting construction organization in Hong Kong was undertaken. The study illustrates the current state of corporate ethics management in the implementation of a corporate code of ethics. The overall process of developing the corporate code of ethics from planning to implementation was investigated. It was found that the corporate management of the organization that was studied adopted a laissez-faire approach in implementing its code at the project level. This means that there was no formal and unified cross-organizational plan for implementing the code at the project level. The methods of communicating the corporate code of ethics to the members of the project team were left to the discretion of the individual project manager. The research findings also showed that different project managers adopted different methods of communication to disseminate the corporate code of ethics to members of their project team. Journal: Construction Management and Economics Pages: 595-606 Issue: 6 Volume: 22 Year: 2004 Keywords: corporate ethics management, corporate code of ethics, implementation models for management systems, case study, communication methods, X-DOI: 10.1080/0144619042000202861 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000202861 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:6:p:595-606 Template-Type: ReDIF-Article 1.0 Author-Name: I. M. Johnstone Author-X-Name-First: I. M. Author-X-Name-Last: Johnstone Title: Development of a model to estimate the benefit-cost ratio performance of housing Abstract: A simulation model based on classical population dynamics is developed to estimate the benefit-cost ratio performance of different typologies of housing with the purpose of identifying potential reductions in the total costs and hence resources used to sustain housing. A typical New Zealand dwelling constructed of lightweight timber framing is used as an example. Dwellings within the simulation model undergo periodic cycles of refurbishment based on best practices. When the simulated housing stock expands at the rate of 1.5% per year, an annual expenditure equivalent to the costs to construct one dwelling sustains the services provided by 26.7 dwellings after adjustment for economic depreciation. This benefit-cost ratio performance improves by 32.4% when the housing stock is stationary. Further improvements of 5.3% can be achieved by deferring refurbishment and accepting a higher level of economic depreciation of dwelling services. The results of all scenarios indicate that structural systems with a service life of only 50 years should not be used unless the costs of such systems are substantially less than the costs of traditional structural systems and that lightweight timber framed dwellings should not be sustained well beyond a service life of 90 years. Journal: Construction Management and Economics Pages: 607-617 Issue: 6 Volume: 22 Year: 2004 Keywords: sustainability, housing stock, simulation model, benefit-cost ratio, X-DOI: 10.1080/0144619042000202825 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000202825 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:6:p:607-617 Template-Type: ReDIF-Article 1.0 Author-Name: I-Tung Yang Author-X-Name-First: I-Tung Author-X-Name-Last: Yang Author-Name: Photios Ioannou Author-X-Name-First: Photios Author-X-Name-Last: Ioannou Title: Scheduling system with focus on practical concerns in repetitive projects Abstract: The line of balance (LOB) method has long been used to model construction projects with repetitive units. Critics, however, indicate two major shortcomings of applying LOB in the construction industry: (1) it has not yet been adapted to numerical computation as readily as network methods; and (2) it relies on restrictive assumptions and therefore cannot treat the practical concerns concluded in this paper. To treat all the practical concerns and provide necessary calculation power, a new scheduling system is proposed: the Repetitive Scheduling Method (RSM) and its computerized implementation, Repetitive Project Planner (RP2). RSM includes necessary modelling elements (i.e. activity and relationship types) and a set of computational algorithm to calculate the start time of every activity as well as the minimum project duration. RP2 automatically calculates and generates RSM diagrams that are particularly useful in serving as a test-bed for project managers to perform what-if analyses for different crew utilization strategies. A real-life pipeline project is used to demonstrate the application of RP2 and to compare that with the critical path method (CPM) and traditional LOB models. Journal: Construction Management and Economics Pages: 619-630 Issue: 6 Volume: 22 Year: 2004 Keywords: Repetitive project, work continuity, project management, what-if analysis, crew utilization strategy, X-DOI: 10.1080/01446190310001649065 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190310001649065 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:6:p:619-630 Template-Type: ReDIF-Article 1.0 Author-Name: Patricia Carrillo Author-X-Name-First: Patricia Author-X-Name-Last: Carrillo Title: Managing knowledge: lessons from the oil and gas sector Abstract: Knowledge management (KM) is of increasing interest to a number of leading UK construction organizations. Companies are keen to find out what other organizations are doing both within the construction and other industry sectors. There are important lessons to be learned from Canadian oil and gas organizations on how they manage their knowledge. A case study is used to explore the KM activities of eight leading organizations and investigate the opportunities for construction organizations to adopt some of their ideas. Three areas are covered: KM strategy and implementation, people aspects of KM and metrics for KM performance. There are several potential lessons for UK organizations: the need for KM to be driven by senior management if it is to have any notable success; the use of people-centred techniques for sharing tacit knowledge and IT tools for sharing explicit knowledge; the importance of selling solutions to project teams to obtain employee support for KM; peer recognition has a more sustainable impact than financial reward; and KM measurement should be considered as a way of improving its impact, rather than justifying expenditure. Journal: Construction Management and Economics Pages: 631-642 Issue: 6 Volume: 22 Year: 2004 Keywords: Knowledge management, construction, oil and gas sector, X-DOI: 10.1080/0144619042000226289 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000226289 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:6:p:631-642 Template-Type: ReDIF-Article 1.0 Author-Name: David Lowe Author-X-Name-First: David Author-X-Name-Last: Lowe Author-Name: Jamshid Parvar Author-X-Name-First: Jamshid Author-X-Name-Last: Parvar Title: A logistic regression approach to modelling the contractor's decision to bid Abstract: Significant factors in the decision to bid process are identified and a pro-forma to elicit a numerical assessment of these factors is developed and validated using the bid/no-bid decision-makers from a UK construction company. Using the pro-forma, data were collected from the collaborating company for historical bid opportunities. Statistical techniques are used to gain a better understanding of the data characteristics and to model the process. Eight variables have a significant relationship with the decision to bid outcome and for which the decision-makers are able to discriminate. Factor analysis is used to identify the underlying dimensions of the pro-forma and to validate functional decomposition of the factors. Finally, two logistic regression models of the decision to bid process are developed. While one model is ultimately rejected, the selected model is capable of classifying the total sample with an overall predictive accuracy rate of 94.8%. The results, therefore, demonstrate that the model functions effectively in predicting the bid/no-bid decision process. Journal: Construction Management and Economics Pages: 643-653 Issue: 6 Volume: 22 Year: 2004 Keywords: Bidding, construction, decision-making, decision to bid, X-DOI: 10.1080/01446190310001649056 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190310001649056 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:6:p:643-653 Template-Type: ReDIF-Article 1.0 Author-Name: John Rooke Author-X-Name-First: John Author-X-Name-Last: Rooke Author-Name: David Seymour Author-X-Name-First: David Author-X-Name-Last: Seymour Author-Name: Richard Fellows Author-X-Name-First: Richard Author-X-Name-Last: Fellows Title: Planning for claims: an ethnography of industry culture Abstract: Claims by contractors for additional payments have been identified by commentators as a major source of difficulty in the industry. Ethnographic research with industry members reveals some key features of planning practices that underlie such events. Claims are sometimes planned at tender stage and sometimes during the course of a project. One practice at tender stage is a pricing technique that minimizes the tender price while maximizing the out-turn cost of a contract by exploiting mistakes in the bill of quantities. Another is the programming of work to maximize its vulnerability to delay. More reactive techniques may be employed during the course of the project, often to make up for an unanticipated increase in costs. These and other similar practices may be reported as features of an integrated culture, defined in such a way as to encompass activity and reject Cartesian dualism. The unique adequacy requirements of methods are suitable criteria for the evaluation of such reports. The claims culture arises from economic conditions in the industry, which include low entry barriers and competitive tendering. However, removal of these conditions alone cannot guarantee that the practices will cease. Journal: Construction Management and Economics Pages: 655-662 Issue: 6 Volume: 22 Year: 2004 Keywords: Procurement, claims management, organizational culture, ethnography, ethnomethodology, X-DOI: 10.1080/014461904200026324 File-URL: http://www.tandfonline.com/doi/abs/10.1080/014461904200026324 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:6:p:655-662 Template-Type: ReDIF-Article 1.0 Author-Name: Chi Sun Poon Author-X-Name-First: Chi Sun Author-X-Name-Last: Poon Author-Name: Ann Tit Wan Yu Author-X-Name-First: Ann Tit Wan Author-X-Name-Last: Yu Author-Name: Sze Wai Wong Author-X-Name-First: Sze Wai Author-X-Name-Last: Wong Author-Name: Esther Cheung Author-X-Name-First: Esther Author-X-Name-Last: Cheung Title: Management of construction waste in public housing projects in Hong Kong Abstract: Waste management in the building industry in Hong Kong has become a major environmental issue in recent years. Of particular concern is the increasing amount of construction and demolition (C&D) waste being dumped at landfill sites. Greater consideration must be given to waste generation and management at the planning stage of a building development to reduce wastage levels. The causes and quantities of building construction waste generated on public housing building sites in Hong Kong have been analysed. Five public housing construction sites were selected for the study by regular site visits. Timber boards used in formwork were the most significant waste type requiring disposal followed by waste derived from wet trades. Waste generation could be significantly reduced by the use of precasting and system formworks. The major causes of wastes were improper preparation and handling, misuse, and incorrect processing. In general, little on-site waste sorting was carried out. Appropriate planning including the preparation of a detailed waste management plan is essential for effective waste minimization. At the construction stage, better house keeping and more vigorous on-site sorting of inert from non-inert materials are necessary. Waste indices calculated from waste monitoring data should be publicized and used for future waste estimations. Journal: Construction Management and Economics Pages: 675-689 Issue: 7 Volume: 22 Year: 2004 Keywords: Hong Kong, Construction Waste, Waste Recycling, Waste Management Plan, On-site Sorting, X-DOI: 10.1080/0144619042000213292 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000213292 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:7:p:675-689 Template-Type: ReDIF-Article 1.0 Author-Name: Gerhard Kreitl Author-X-Name-First: Gerhard Author-X-Name-Last: Kreitl Author-Name: Wolfgang Oberndorfer Author-X-Name-First: Wolfgang Author-X-Name-Last: Oberndorfer Title: Motives for acquisitions among engineering consulting firms Abstract: Many empirical studies across various industry sectors show a high failure rate of mergers and acquisitions (M&A), suggesting that this instrument of corporate development is rather risky. Since engineering consulting firms usually have a low tangible asset base as well as good educated and highly mobile professionals, carrying out an M&A transaction in this particular service sector creates an even higher risk. It is evident from the relevant construction and engineering literature that a large number of engineering consulting firms engage in M&A for their corporate development. Owing to the uniqueness of that service sector combined with the high failure rate of M&A, a survey among the top 100 engineering consulting firms in Europe was conducted to investigate the motives behind M&A transactions. Findings suggest that diversification into new service/client markets as well as the penetration into new geographic markets were the most important motives. Further, increasing the firm's market share and the acceleration of growth were the next most popularly rated motives, while tax reasons or spending the firm's excess cash were both seen as relatively unimportant motives. The results show that - compared to other industry sectors - engineering consulting firms had some very different motives or another emphasis was placed on those motives when conducting an M&A transaction. Results also show that some motives were just as important for engineering consulting firms as for firms of other industry sectors, for example the increase of market share or the acceleration of firm growth. Journal: Construction Management and Economics Pages: 691-700 Issue: 7 Volume: 22 Year: 2004 Keywords: Mergers And Acquisitions, Motive, Engineering, Consulting Firm, Europe, X-DOI: 10.1080/0144619042000241408 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000241408 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:7:p:691-700 Template-Type: ReDIF-Article 1.0 Author-Name: Mei-Yung Leung Author-X-Name-First: Mei-Yung Author-X-Name-Last: Leung Author-Name: Alice Chong Author-X-Name-First: Alice Author-X-Name-Last: Chong Author-Name: S. Thomas Ng Author-X-Name-First: S. Thomas Author-X-Name-Last: Ng Author-Name: Michael Cheung Author-X-Name-First: Michael Author-X-Name-Last: Cheung Title: Demystifying stakeholders' commitment and its impacts on construction projects Abstract: Construction projects are typified by the involvement of a number of participants. Each project team member has his/own expertise, and would contribute towards the success of the project. However, since their inputs are often interdependent, conflicts may arise in some circumstances. This is particularly evidenced when they are working within limited resources in terms of time and budget. One cannot expect a project team to attain the necessary synergy when common goals are not being visualized or observed. To improve the implementation performance of construction projects, it is necessary to investigate the goal commitment amongst temporary project team members. This research study aims to investigate the impacts of commitment amongst major project stakeholders. The results indicate that high affective commitment induces high performance and satisfaction, while the continuous commitment provokes intention to quit. Journal: Construction Management and Economics Pages: 701-715 Issue: 7 Volume: 22 Year: 2004 Keywords: Commitment, Performance, Satisfaction, Intention To Quit, Turnover, X-DOI: 10.1080/0144619042000300736 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000300736 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:7:p:701-715 Template-Type: ReDIF-Article 1.0 Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Author-Name: Hongbin Jiang Author-X-Name-First: Hongbin Author-X-Name-Last: Jiang Author-Name: Christopher Leong Author-X-Name-First: Christopher Author-X-Name-Last: Leong Title: A comparative study of top British and Chinese international contractors in the global market Abstract: While British contractors have one of the longest history and experience in the international construction market, Chinese contractors are relative newcomers where the global market is concerned. This study compares the performance of top British and Chinese contractors based on the OLI+S model, which incorporates the ownership (O), locational(L), internalization (I) and specialty (S) factors. The study suggests that the international involvement of top British contractors has declined from a peak in 1996, while that of the top Chinese contractors has grown steadily since the 1980s. All the OLI+S advantages of top British construction firms were higher than those of their Chinese counterparts even though the number of Chinese construction firms ranked in the top 225 international contractors by the US-based Engineering News Record was higher than that of the British firms. This study further recommends that the internalization and specialty advantages of top British firms and some of the ownership advantages of top Chinese firms may provide them with opportunities to work together in many areas. Journal: Construction Management and Economics Pages: 717-731 Issue: 7 Volume: 22 Year: 2004 Keywords: International Construction, Firms, Performance, Great Britain, China, X-DOI: 10.1080/0144619042000202780 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000202780 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:7:p:717-731 Template-Type: ReDIF-Article 1.0 Author-Name: H. S. Robinson Author-X-Name-First: H. S. Author-X-Name-Last: Robinson Author-Name: P. M. Carrillo Author-X-Name-First: P. M. Author-X-Name-Last: Carrillo Author-Name: C. J. Anumba Author-X-Name-First: C. J. Author-X-Name-Last: Anumba Author-Name: A. M. Al-Ghassani Author-X-Name-First: A. M. Author-X-Name-Last: Al-Ghassani Title: Developing a business case for knowledge management: the IMPaKT approach Abstract: There is a wealth of literature on the role of knowledge management (KM) in business improvement. Those with responsibility for implementing KM in organizations are often required to demonstrate its benefits. The need to convince senior management and other stakeholders about the business benefits is increasingly recognized as crucial in justifying a KM strategy and the resources to support its implementation. A three-stage approach (the IMPaKT framework) - underpinned by an industry survey and case study findings - is presented for developing a business case for KM. The framework facilitates: (1) an understanding of the strategic context of business problems and their knowledge management implications; (2) the planning and alignment of KM strategy to address business problems or objectives; and (3) an evaluation of the impact of KM on business performance in terms of effectiveness and efficiency. Key findings based on industrial application and further development of the framework are discussed. Evaluation shows that the framework could significantly facilitate the implementation of a KM strategy in construction organizations. Journal: Construction Management and Economics Pages: 733-743 Issue: 7 Volume: 22 Year: 2004 Keywords: Knowledge Management, Business Performance, Construction Organizations, X-DOI: 10.1080/0144619042000226306 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000226306 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:7:p:733-743 Template-Type: ReDIF-Article 1.0 Author-Name: Felipe Vazquez Author-X-Name-First: Felipe Author-X-Name-Last: Vazquez Author-Name: Stephen Allen Author-X-Name-First: Stephen Author-X-Name-Last: Allen Title: Private sector participation in the delivery of highway infrastructure in Central America and Mexico Abstract: A case study of private sector involvement in the provision of a roadway infrastructure network reviewed negative experiences in Mexico between 1989 and 1995. The aim of this case study was to identify improvements that must be considered for successful private sector participation on future transport infrastructure projects. The recommendations presented were developed as a result of a review of research and practice in Mexico, and in both developed and developing countries around the world where the private sector has been involved in the delivery of highway infrastructure. Key findings relate to the need for integrated infrastructure planning; the bundling of concession projects and possible use of shadow tolls to make them attractive to the private sector; and, the implementation of more robust financial models in developing countries. These findings have a broader applicability than highways in Central America and may relate to a variety of projects in other developing countries. Journal: Construction Management and Economics Pages: 745-754 Issue: 7 Volume: 22 Year: 2004 Keywords: Integrated Transport Infrastructure, Private Sector Participation, Private Finance, Central America, X-DOI: 10.1080/0144619042000226298 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000226298 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:7:p:745-754 Template-Type: ReDIF-Article 1.0 Author-Name: Rina Hayane Sumardi Author-X-Name-First: Rina Hayane Author-X-Name-Last: Sumardi Author-Name: Kwabena Asomanin Anaman Author-X-Name-First: Kwabena Asomanin Author-X-Name-Last: Anaman Title: Aggregate efficiency analysis of resource use and demand for labour by the construction industry in Brunei Darussalam Abstract: The construction industry is the third largest contributor to the gross domestic product (GDP) in Brunei Darussalam, the wealthiest Muslim country in the world based on per capita GDP. The construction industry in Brunei has been in a crisis since the Asian financial crisis of 1998 and the subsequent collapse in the same year of the Amedeo Company, the largest company dealing with construction-related business in Brunei. The objectives of this study are to gauge the overall aggregate level of inefficiency of the industry and to analyse the factors affecting aggregate labour demand in the industry. Econometric analysis, based on secondary time-series data of the construction industry from 1971 to 2001, was the main route used to fulfil these objectives. The technical inefficiency of the construction industry was undertaken using a stochastic frontier production function analysis. The results indicated that overall technical inefficiency of the industry was about 26.6%. The short-run demand for labour in the construction industry was estimated based on time-series secondary data using a partial expectation model. This particular analysis showed that construction firms were only getting about half of the desired increase in the workers that they wanted to employ. Journal: Construction Management and Economics Pages: 755-764 Issue: 7 Volume: 22 Year: 2004 Keywords: Brunei, Construction Industry, Economics Of Resource Use, Efficiency Analysis, Labour Demand, Southeast Asia, Stochastic Frontier Production Function, X-DOI: 10.1080/0144619042000202807 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000202807 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:7:p:755-764 Template-Type: ReDIF-Article 1.0 Author-Name: Viggo Nordvik Author-X-Name-First: Viggo Author-X-Name-Last: Nordvik Author-Name: Kim Robert Lisø Author-X-Name-First: Kim Robert Author-X-Name-Last: Lisø Title: A primer on the building economics of climate change Abstract: Climate change will entail new conditions for the construction industry. Knowledge about the implications of climate change on the built environment will be of the utmost importance to the industry in years to come. A building is a 'long lasting' durable asset that is changed over time due to exogenously imposed strains and by actions. The built environment has an expected lifetime varying from 60 to more than 100 years. Hence, the building economics of climate change should be treated within a dynamic analytical framework that explicitly allows for changes in the information sets over time. The building stock of the future consists of the building stock of today and of new construction. In the future, parts of the present building stock will be adapted to changes in the environment, while some parts will be kept as they are. Analysis of how building stock is affected by future climate change should handle this diversity. This can be done through the use of a putty-clay model. Uncertainty of what kind of climate regimes will prevail in the future enhances the profitability of actions that increase future flexibility. Hence, the real option approach to building economics is utilized. Journal: Construction Management and Economics Pages: 765-775 Issue: 7 Volume: 22 Year: 2004 Keywords: Building Economics, Global Warming, Climate Change, Putty-clay, Real Options, Building Stock, Building Enclosure Performance, X-DOI: 10.1080/0144619042000213256 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000213256 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:7:p:765-775 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen D. Pryke Author-X-Name-First: Stephen D. Author-X-Name-Last: Pryke Title: Analysing construction project coalitions: exploring the application of social network analysis Abstract: The construction industry is currently in transition as a result of innovations in procurement and project management approaches, in particular, the utilization of supply chain management, and technology or work clusters in the context of partnering relationships between project coalition actors and the client organization. These new strategies require an analytical method that deals with actor interdependence and provides an appropriate level of detail and quantitative data in relation to the non-linear, complex, iterative and interactive process that construction projects comprise. The construction project is conceptualized as a number information exchange networks, classified according to the principal project functions and supported by performance incentive and contractual relationship networks. The point centrality of the project actors within these various networks provides quantitative data and graphical representation of the governance of construction projects and the changes brought about by innovations in procurement and project management techniques. Social network analysis (SNA) provides an important new quantitative approach in the comparative analysis of procurement and project management of construction projects. SNA enables traditional project coalition management approaches to be compared with those associated with innovative management approaches. Quantitative analysis relates to the appropriateness and effectiveness of both financial incentives and contractual conditions involved in the governance of construction projects. Journal: Construction Management and Economics Pages: 787-797 Issue: 8 Volume: 22 Year: 2004 Month: 10 X-DOI: 10.1080/0144619042000206533 File-URL: http://hdl.handle.net/10.1080/0144619042000206533 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:8:p:787-797 Template-Type: ReDIF-Article 1.0 Author-Name: Chi Sun Poon Author-X-Name-First: Chi Sun Author-X-Name-Last: Poon Author-Name: Ann Tit Wan Yu Author-X-Name-First: Ann Tit Wan Author-X-Name-Last: Yu Author-Name: Siu Ching See Author-X-Name-First: Siu Ching Author-X-Name-Last: See Author-Name: Esther Cheung Author-X-Name-First: Esther Author-X-Name-Last: Cheung Title: Minimizing demolition wastes in Hong Kong public housing projects Abstract: Being one of the major housing developers in Hong Kong, the Hong Kong Housing Authority (HA) carries out a large number of construction and demolition projects. As a result, a large amount of construction and demolition waste is produced. As for demolition projects, demolition wastes usually contain a large amount of reusable materials. If sorted out properly, these materials could be better reused or recycled. Two case studies have been carried out on public housing projects to quantify the recovery rates of various types of demolition wastes in demolition projects and to assess the implementation of on-site sorting requirements. The current practices of demolition contractors in Hong Kong mainly focus on the working procedures and waste generation during the main demolition stage and sorting of waste is difficult due to cross contamination although on-site sorting has been stated as a requirement in the contract. The demolition method statement should include working details of both the salvaging and the demolition stages to affect waste sorting and recycling. Selective demolition should be considered to further improve the waste recycling rate but there is a need to develop recycling markets to provide outlets for the collected recyclables. Journal: Construction Management and Economics Pages: 799-805 Issue: 8 Volume: 22 Year: 2004 Month: 10 X-DOI: 10.1080/0144619042000213283 File-URL: http://hdl.handle.net/10.1080/0144619042000213283 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:8:p:799-805 Template-Type: ReDIF-Article 1.0 Author-Name: Adrian J Bridge Author-X-Name-First: Adrian J Author-X-Name-Last: Bridge Author-Name: Clem Tisdell Author-X-Name-First: Clem Author-X-Name-Last: Tisdell Title: The determinants of the vertical boundaries of the construction firm Abstract: In the last few years, transaction cost economics has become a popular theory within the construction research community. This approach has been singularly applied as a means to explain and predict phenomena concerning the construction firm, including its vertical boundaries. However, this is at a time when the chief proponents of transaction costs are urging researchers to take a pluralistic stance in relation to the theory of the firm. The aim of this paper is to develop a pluralistic approach to the vertical boundaries of the construction firm. In order to achieve this, an integrative framework is described, based on the development of the efficient boundaries problem and the capabilities approach to vertical integration. Specifically, this framework draws on the complementary strengths of transaction cost economics and the resource-based view. It is concluded that the potential relative merits of theoretical pluralism, in terms of the vertical boundaries of the construction firm, are sufficient grounds to motivate empirical testing of the predictions associated with the integrative framework of vertical integration presented. Journal: Construction Management and Economics Pages: 807-825 Issue: 8 Volume: 22 Year: 2004 Month: 10 X-DOI: 10.1080/01446190310001649038 File-URL: http://hdl.handle.net/10.1080/01446190310001649038 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:8:p:807-825 Template-Type: ReDIF-Article 1.0 Author-Name: Andr� G. Dor�e Author-X-Name-First: Andr� G. Author-X-Name-Last: Dor�e Author-Name: Elsebeth Holmen Author-X-Name-First: Elsebeth Author-X-Name-Last: Holmen Title: Achieving the unlikely: innovating in the loosely coupled construction system Abstract: Previous research suggests that a characteristic of the construction industry is a lack of technological innovation. Since this is seen as a problem, much theoretical development within construction management focuses on explaining the lack of innovation. Less effort has been expended on using such explanatory theories for investigating those rare exceptions in which construction firms succeed in the unlikely: successfully developing a new technology. This article makes use of the recently suggested framework by Dubois and Gadde. They describe the construction industry as a 'loosely coupled system' with four types of couplings, discuss why the particular mix of couplings in the construction system leads to a lack of innovation, and suggest types of couplings that construction firms should experiment with and change in order to boost innovation. A case study of a contractor developing a new technology is presented in terms of Dubois and Gadde's concepts and implications. The findings partly support and partly contradict their hypotheses. It seems that innovation is possible even if only a few of the existing couplings are changed. The most important changes relate to the tightening of intrafirm sequential inter-project couplings enabling learning from project to project, and contract-related couplings especially the design-construction interface. Journal: Construction Management and Economics Pages: 827-838 Issue: 8 Volume: 22 Year: 2004 Month: 10 X-DOI: 10.1080/0144619042000190225 File-URL: http://hdl.handle.net/10.1080/0144619042000190225 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:8:p:827-838 Template-Type: ReDIF-Article 1.0 Author-Name: C.M. Tam Author-X-Name-First: C.M. Author-X-Name-Last: Tam Author-Name: Thomas K.L. Tong Author-X-Name-First: Thomas K.L. Author-X-Name-Last: Tong Author-Name: Sharon L. Tse Author-X-Name-First: Sharon L. Author-X-Name-Last: Tse Title: Modelling hook times of mobile cranes using artificial neural networks Abstract: The hook times of mobile cranes are processes that are of non-linear and discrete nature. Artificial neural network is a data processing technique that lends itself to this kind of problem. Three common artificial neural network architectures - multi-layer feed-forward (MLFF), group method of data handling (GMDH) and general regression neural network (GRNN) - are compared. The results show that the GRNN model aided with genetic algorithm (GA) is most promising in describing the non-linear and discrete nature of the hook times. The MLFF model can also give a moderate level of accuracy in the estimation of hook travelling times of mobile cranes and is ranked second. The GMDH model is outperformed by the former two due to a less promising R-square. Journal: Construction Management and Economics Pages: 839-849 Issue: 8 Volume: 22 Year: 2004 Month: 10 X-DOI: 10.1080/0144619042000202771 File-URL: http://hdl.handle.net/10.1080/0144619042000202771 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:8:p:839-849 Template-Type: ReDIF-Article 1.0 Author-Name: Javier C. Cuervo Author-X-Name-First: Javier C. Author-X-Name-Last: Cuervo Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Title: Global performance measures for transnational construction corporations Abstract: The top transnational construction corporations (TCCs) are ranked according to their international revenues by the Engineering News Record. The amount or share of international revenues of a contractor however does not necessarily reflect the contractor's global performance. The geographic spread of works in different countries and regions of the world and the extent of liberalization or protection of markets do influence the global performance of TCCs. To account for these factors, new measures of global spread, global intensity and global intensity with domestic performance are proposed which measures the global performance of contractors. These measures of global performance were applied to the top 20 international contractors reported by the ENR. The ranking of the top 20 TCCs shifts when the new measures of global performance are applied to these companies. One salient finding is that not all TCCs belonging to the top five, in terms of international revenues, are truly global construction corporations based on new global performance indicators. A significant implication for future research work is to assess how managers of TCCs can transform global presence and performance, as reflected in these new measures, into global competitive advantages. Journal: Construction Management and Economics Pages: 851-860 Issue: 8 Volume: 22 Year: 2004 Month: 10 X-DOI: 10.1080/01446190410001673562 File-URL: http://hdl.handle.net/10.1080/01446190410001673562 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:8:p:851-860 Template-Type: ReDIF-Article 1.0 Author-Name: Bambang Trigunarsyah Author-X-Name-First: Bambang Author-X-Name-Last: Trigunarsyah Title: Project owners' role in improving constructability of construction projects: an example analysis for Indonesia Abstract: Constructability is an approach that links the design and construction processes, which can lead to significant savings in both cost and time required for completing construction projects. Improving constructability of construction projects is the responsibility of all project stakeholders: owners, designers and contractors. As the owners have the most authority in enforcing the implementation of constructability, the owners' awareness of the benefit of improved constructability is the most important. Project owners must be aware that the decisions that are made in the initial stages of planning and design are difficult and costly to change once construction begins. A questionnaire survey was used to gain information on the Indonesian construction project owners' understanding of constructability by assessing the current constructability practices and their impact on project performance. The study shows that project owners in Indonesia do have some understanding of the importance of constructability. However, the traditional approach to project delivery, which is the preferred method by most of them, limits their option for involving construction personnel in the pre-construction phases. Journal: Construction Management and Economics Pages: 861-876 Issue: 8 Volume: 22 Year: 2004 Month: 10 X-DOI: 10.1080/01446190410001678107 File-URL: http://hdl.handle.net/10.1080/01446190410001678107 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:8:p:861-876 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew R.J. Dainty Author-X-Name-First: Andrew R.J. Author-X-Name-Last: Dainty Author-Name: Mei-I Cheng Author-X-Name-First: Mei-I Author-X-Name-Last: Cheng Author-Name: David R. Moore Author-X-Name-First: David R. Author-X-Name-Last: Moore Title: A competency-based performance model for construction project managers Abstract: The role of competency-based performance management is growing in significance in many industries and sectors. Unlike functional competences, which measure performance against predetermined minimum occupational standards, competency-based systems are founded on the key behavioural competencies that underlie superior levels of performance. In order to identify the key behaviours leading to performance excellence amongst construction project managers, in-depth behavioural event interviews were used in which managers were asked to recount critical management incidents, decisions and actions from which their behavioural competencies could be identified. By delineating the sample according to their performance against a range of role-based criteria, the competencies defining superior management performance were determined. Statistical techniques were then used to develop a model that can be used to predict likely employee performance, which was subsequently validated on a second criterion sample. The research identifies 12 core behavioural competencies that underpin effective project management performance, of which two - 'composure' and 'team leadership' - were the most predictive. The paper explores the potential role and application of the framework in the drive for performance excellence within the industry, such as in selection, management development, succession planning, performance management and team deployment. It is argued that it offers an innovative alternative to normative micro-competence-based approaches that do little to engender performance excellence amongst the industry's key managers and professionals. Journal: Construction Management and Economics Pages: 877-886 Issue: 8 Volume: 22 Year: 2004 Month: 10 X-DOI: 10.1080/0144619042000202726 File-URL: http://hdl.handle.net/10.1080/0144619042000202726 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:8:p:877-886 Template-Type: ReDIF-Article 1.0 Author-Name: Olabosipo Fagbenle Author-X-Name-First: Olabosipo Author-X-Name-Last: Fagbenle Author-Name: Aderemi Adeyemi Author-X-Name-First: Aderemi Author-X-Name-Last: Adeyemi Author-Name: David Adesanya Author-X-Name-First: David Author-X-Name-Last: Adesanya Title: The impact of non-financial incentives on bricklayers' productivity in Nigeria Abstract: High productivity is regarded as a goal that ensures long-term survival of firms. In Nigeria's labour-intensive construction industry, firms are currently applying various non-financial incentive schemes aimed at improving operatives' productivity. A questionnaire survey involving the management and operatives of construction firms was conducted to determine the impact of these scheme on the productivity of bricklayers. The survey was complemented with on-site observation and measurement of bricklayers' output on 40 construction projects in order to determine the impact of non-financial incentive schemes on productivity. Comparative analysis of sites with and without incentives showed that non-financial incentive schemes significantly improved bricklayers' productive time and these schemes accounted for 6% to 26% of the variations in output between the two sets of sites on block laying and concreting activities measured. Journal: Construction Management and Economics Pages: 899-911 Issue: 9 Volume: 22 Year: 2004 Keywords: Non-financial incentive, motivation, productivity improvement, bricklayers, Nigeria, X-DOI: 10.1080/0144619042000241262 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000241262 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:9:p:899-911 Template-Type: ReDIF-Article 1.0 Author-Name: Florence Phua Author-X-Name-First: Florence Author-X-Name-Last: Phua Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Title: Operationalizing culture in construction management research: a social identity perspective in the Hong Kong context Abstract: A prevailing trend of opinion in construction management research revolves around the importance of instilling a positive partnering culture in order to improve overall project performance. Indeed, the culture part of the equation has often been taken as a given and this has led to many normative and, at best, prescriptive claims about culture's consequences in terms of individual behaviours and practices. Despite this trend, no systematic empirical work has so far been undertaken to objectively operationalize or test the real effects of culture. This study aims to fill this research gap. Grounded in the social identity framework, this study proposes an alternative approach for operationalizing and examining culture's effects using data derived from 398 local and foreign senior managers from construction firms in Hong Kong. Results suggest that the relationships between culture and individual behaviours are far more complex than alluded to by simple normative generalizations. The study underscores an urgent need for future research to adopt a more comprehensive framework for defining and measuring culture in construction management research. Journal: Construction Management and Economics Pages: 913-925 Issue: 9 Volume: 22 Year: 2004 Keywords: Culture, social identity theory, individualism-collectivism, co-operation, Hong Kong, X-DOI: 10.1080/01446190310001631000 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190310001631000 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:9:p:913-925 Template-Type: ReDIF-Article 1.0 Author-Name: Sai On Cheung Author-X-Name-First: Sai On Author-X-Name-Last: Cheung Author-Name: Chi Ming Tam Author-X-Name-First: Chi Ming Author-X-Name-Last: Tam Author-Name: Vivian Tam Author-X-Name-First: Vivian Author-X-Name-Last: Tam Author-Name: Kevin Cheung Author-X-Name-First: Kevin Author-X-Name-Last: Cheung Author-Name: Henry Suen Author-X-Name-First: Henry Author-X-Name-Last: Suen Title: A web-based performance assessment system for environmental protection: WePass Abstract: In response to the increasing public concern over the effects of construction waste on the environment, a performance assessment system has been designed to provide an instant, online assessment of how well a construction site performs environmentally, e.g. measuring the level of pollution generated from a construction site. Through the use of both Internet and database technologies, it is possible to collect and present data that are essential for environmental management online. To achieve this, a set of environmental performance parameters was derived through a postal questionnaire survey and interviews with experts in the field. A conceptual framework was developed, of which the key components were: template, knowledge base, output data and benchmark group. In combination, these factors provide a system that enables speedy assessment and effective management of environmental performance on construction sites, hence prompt decisions can be made and corrective actions can be taken before potential hazards turn into real disasters. Journal: Construction Management and Economics Pages: 927-935 Issue: 9 Volume: 22 Year: 2004 Keywords: Environmental protection, Internet, database, performance assessment, performance parameters, X-DOI: 10.1080/0144619042000202843 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000202843 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:9:p:927-935 Template-Type: ReDIF-Article 1.0 Author-Name: S. L. Tang Author-X-Name-First: S. L. Author-X-Name-Last: Tang Author-Name: K. C. Ying Author-X-Name-First: K. C. Author-X-Name-Last: Ying Author-Name: W. Y. Chan Author-X-Name-First: W. Y. Author-X-Name-Last: Chan Author-Name: Y. L. Chan Author-X-Name-First: Y. L. Author-X-Name-Last: Chan Title: Impact of social safety investments on social costs of construction accidents Abstract: Most contractors' financial losses associated with accidents, but not all, are also social costs. Some social costs are not incurred by contractors, but by society. Social costs of construction accidents have been gathered for years 1999-2001. The safety investments made by both contractors and society are also identified based on data assembled for these three years. These social costs and safety investments were identified from 119 construction projects involving 1414 accidents and from 18 government departments in Hong Kong. The data shows that there was an increasing trend in social safety investments and a decreasing trend in social costs of construction accidents from 1999 to 2001. During this period, for every extra $1 of social safety investments made, a reduction of $2.27 of social costs on construction accidents was achieved in Hong Kong. Journal: Construction Management and Economics Pages: 937-946 Issue: 9 Volume: 22 Year: 2004 Keywords: Safety, costs, investments, social impact, construction, accidents, Hong Kong, X-DOI: 10.1080/0144619042000226315 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000226315 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:9:p:937-946 Template-Type: ReDIF-Article 1.0 Author-Name: V. Chandra Author-X-Name-First: V. Author-X-Name-Last: Chandra Author-Name: M. Loosemore Author-X-Name-First: M. Author-X-Name-Last: Loosemore Title: Women's self-perception: an inter-sector comparison of construction, legal and nursing professionals Abstract: The issue of gender in the construction industry has received considerable attention. However, most of the research has been from a male perspective and has considered how male perceptions of females act as an impediment to women's career progression. An understanding of women's self-perception is important because it helps to explain how women make sense of the barriers and challenges they face in a male dominated culture and how they seek to attain positive outcomes for themselves. A comparison of women in the construction industry with women in other male-dominated (legal) and female-dominated (nursing) industries reveals little variation in self perceptions. Indeed, women in the construction industry emerge relatively positively, with the highest overall level of self-esteem. This is encouraging and surprising, given the considerable evidence of significant barriers to entry and career progression for women in the construction industry, compared to other industries. It indicates that the construction industry is not a special case and that support strategies used in other industries are directly transferable, although the culture of the construction industry may make them more difficult to implement. Journal: Construction Management and Economics Pages: 947-956 Issue: 9 Volume: 22 Year: 2004 Keywords: Professionals, gender, self, perception, equality, construction, nursing, lawyers, X-DOI: 10.1080/01446190410001673580 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190410001673580 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:9:p:947-956 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Author-Name: Per-Erik Josephson Author-X-Name-First: Per-Erik Author-X-Name-Last: Josephson Author-Name: Ingeborg Knauseder Author-X-Name-First: Ingeborg Author-X-Name-Last: Knauseder Title: Learning capabilities in organizational networks: case studies of six construction projects Abstract: Organizational learning is a key mechanism for adapting to changes in the organization's environment, sharing know-how and experiences, and for providing innovative solutions. Practices of organization learning are examined in six Swedish construction projects. In the Swedish construction industry, organization learning practices are in many cases underdeveloped and therefore mechanisms for sharing know-how, information, and experiences remain an organizational capability not fully exploited. Findings suggest that construction projects are primarily relying on informal and personal contacts rather than more formal reporting and computer-based management control systems. The implications for management in the industry are that new arenas wherein various professional groups can share knowledge and information would be beneficial for construction projects in terms of enabling for joint learning and a better use of the intellectual resources employed the project. Journal: Construction Management and Economics Pages: 957-966 Issue: 9 Volume: 22 Year: 2004 Keywords: Organizational learning, construction project, networks, X-DOI: 10.1080/0144619042000241417 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000241417 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:9:p:957-966 Template-Type: ReDIF-Article 1.0 Author-Name: Marcus Ahadzi Author-X-Name-First: Marcus Author-X-Name-Last: Ahadzi Author-Name: Graeme Bowles Author-X-Name-First: Graeme Author-X-Name-Last: Bowles Title: Public-private partnerships and contract negotiations: an empirical study Abstract: Despite the increasing popularity in the use of the public-private partnership concept as a procurement strategy, there have been reported cases of problems associated with the initial stages of the process in terms of unduly high bidding costs and pre-contract time overruns due mainly to the protracted nature of the negotiations. Empirical research conducted in the UK has focused on the extent of these pre-contract time and cost overruns. The key attributes of both the private sector consortia and the public sector organizations that have significant bearing on the efficiency of the pre-contract processes are: the nature and strength of the consortium, the quality of the technical proposals they produce for the bid, and the quality of their financial proposals. For the public sector organizations they are the organizational capabilities and technical capabilities. The financial capabilities of the public sector are ranked lowest in influencing the procurement process. Whilst there was broad agreement on the ranking of importance for the various descriptive attributes, differences between the two sectors are revealed relating to risk, previous experience, evaluation criteria in the bidding documents and effect of public opinion. A better understanding of what is important to each party in the negotiations is an important step in improving the PPP process. Journal: Construction Management and Economics Pages: 967-978 Issue: 9 Volume: 22 Year: 2004 Keywords: Public-private partnerships, negotiation, consortium, public sector, procurement, X-DOI: 10.1080/0144619042000241471 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000241471 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:9:p:967-978 Template-Type: ReDIF-Article 1.0 Author-Name: Patrick McCloughan Author-X-Name-First: Patrick Author-X-Name-Last: McCloughan Title: Construction sector concentration: evidence from Britain Abstract: For the first time, empirical estimates of concentration in the British construction sector are provided. The research adds value to published DETR/DTI data on the structure of British construction by applying a novel technique for estimating the concentration ratio proposed by McCloughan and Abounoori (MA) (2003). The MA method is applied because the data are grouped and simple summing of the largest market shares is not possible in this case. Results are provided on the trends in aggregate concentration (1971-99), concentration by main trades (1980-98) and concentration by specialist trades (1980-99). The first main finding is that aggregate concentration is low in British construction. This confirms the popular view, namely that construction is a fragmented sector, with the vast majority of private contractors operating at a small scale. The second main result is that concentration among main trades is also low. However, the same cannot be said of concentration among specialist trades - the third main result. The analysis shows that certain specialist trades (scaffolding specialists, asphalt and tar sprayers, constructional engineers, insulation specialists and demolition specialists) are relatively concentrated, even in the context of a national geographic market. These specialist trades experienced sharp rises in concentration in the latter half of the 1990s. The results suggest that the British construction sector is dynamic and comprises many diverse markets in terms of their levels and trends in concentration. Journal: Construction Management and Economics Pages: 979-990 Issue: 9 Volume: 22 Year: 2004 Keywords: construction, aggregate, market concentration, X-DOI: 10.1080/0144619042000209396 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000209396 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:9:p:979-990 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Valerie Francis Author-X-Name-First: Valerie Author-X-Name-Last: Francis Title: The work-life experiences of office and site-based employees in the Australian construction industry Abstract: A survey was conducted among employees of a large Australian construction firm. Comparisons were made between employees who differed by gender and work location. Male employees in site-based roles reported significantly higher levels of work to family conflict and emotional exhaustion than male employees who worked in the regional or head office. Site-based male employees were also less satisfied with their pay than male respondents who worked in the regional of head office. Few significant differences were found between women who worked in different locations. Neither were significant differences between men and women who worked in the same location reported. The results are explained in terms of women's tendency to work in administrative, secretarial or support services roles, which typically demand fewer hours. The paper concludes that the experiences of site-based construction employees, particularly men, warrant further attention to explore the sources of work-life imbalance and burnout. Journal: Construction Management and Economics Pages: 991-1002 Issue: 9 Volume: 22 Year: 2004 Keywords: Construction, work-family conflict, burnout, job satisfaction, social exchange, X-DOI: 10.1080/0144619042000241444 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000241444 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:9:p:991-1002 Template-Type: ReDIF-Article 1.0 Author-Name: A.H. BOUSSABAINE Author-X-Name-First: A.H. Author-X-Name-Last: BOUSSABAINE Author-Name: R.J. KIRKHAM Author-X-Name-First: R.J. Author-X-Name-Last: KIRKHAM Title: Simulation of maintenance costs in UK local authority sport centres Abstract: The costs of building maintenance, particularly in high-demand public sector facilities, can account for a significant proportion of the whole life cycle costs. The ability to accurately predict these maintenance costs can provide an essential management tool during the operational stages. A thorough investigation of existing techniques and metrics to predict these costs provides the basis of this research, which proposes an innovative simulation-based approach to maintenance costs modelling in UK local authority sports buildings. The results obtained show that gross floor area, swimming pool size, and the number of users are the critical factors influencing maintenance costs in sport centre buildings. Probabilistic representations of these variables are used in a stochastic cost-forecasting model, which reveals that the Weibull distribution is suitable for representing the maintenance cost function. The results are validated through the application of the Kolmogrov-Smirnov test, the importance of this test, and the data pre-analysis used in the construction and validation of the input probability distributions, are also discussed. Journal: Construction Management and Economics Pages: 1011-1020 Issue: 10 Volume: 22 Year: 2004 Month: 12 X-DOI: 10.1080/01446193.2004.10800485 File-URL: http://hdl.handle.net/10.1080/01446193.2004.10800485 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:10:p:1011-1020 Template-Type: ReDIF-Article 1.0 Author-Name: Eddie W. L. Cheng Author-X-Name-First: Eddie W. L. Author-X-Name-Last: Cheng Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Title: Contractor selection using the analytic network process Abstract: Contractor selection is one of the main activities of clients. Without a proper and accurate method for selecting the most appropriate contractor, the performance of the project will be affected. The multi-criteria decision-making (MCDM) is suggested to be a viable method for contractor selection. The analytic hierarchy process (AHP) has been used as a tool for MCDM. However, AHP can only be employed in hierarchical decision models. For complicated decision problems, the analytic network process (ANP) is highly recommended since ANP allows interdependent influences specified in the model. An example is demonstrated to illustrate how this method is conducted, including the formation of supermatrix and the limit matrix. Journal: Construction Management and Economics Pages: 1021-1032 Issue: 10 Volume: 22 Year: 2004 Month: 12 X-DOI: 10.1080/0144619042000202852 File-URL: http://hdl.handle.net/10.1080/0144619042000202852 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:10:p:1021-1032 Template-Type: ReDIF-Article 1.0 Author-Name: Florence T. T. Phua Author-X-Name-First: Florence T. T. Author-X-Name-Last: Phua Title: The antecedents of co-operative behaviour among project team members: an alternative perspective on an old issue Abstract: Poor project performance is generally attributed to a lack of co-operation between project participants. Much work is directed towards understanding the structural and organizational antecedents of co-operation, but little in understanding how socio-psychological factors affect individual co-operative behaviour. Using social identity theory, this study attempts to fill this research gap by arguing that individuals define their self-concepts through the organizations with which they identify and that these identity-based forces are the basis for the development of co-operative behaviour. Empirical findings using responses from 398 senior executives of construction firms substantiate this argument, as individuals with strong organizational identity are indeed more psychologically predisposed to behave co-operatively. There are grounds to propose that organizational identity should be used in conjunction with other tangible economic incentives as effective mechanisms for improving individual co-operation. Therefore, rigorous attempts by construction firms to foster such identity may prove fruitful to overall project performance. Further research is needed to explore how it may impact on other important aspects of co-operation such as decision making and problem solving processes within the construction industry. Journal: Construction Management and Economics Pages: 1033-1045 Issue: 10 Volume: 22 Year: 2004 Month: 12 X-DOI: 10.1080/01446190310001649092 File-URL: http://hdl.handle.net/10.1080/01446190310001649092 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:10:p:1033-1045 Template-Type: ReDIF-Article 1.0 Author-Name: Reay-Chen Wang Author-X-Name-First: Reay-Chen Author-X-Name-Last: Wang Author-Name: Tien-Fu Liang Author-X-Name-First: Tien-Fu Author-X-Name-Last: Liang Title: Project management decisions with multiple fuzzy goals Abstract: In real-world situations, the project managers must handle conflicting goals that govern the use of the resources within organizations. These conflicting goals must are required to be optimized simultaneously by the project managers in the framework of fuzzy aspiration levels. The multiple fuzzy goals programming model proposed herein helps project managers to minimize project total costs, total completion time, and total crashing costs considering direct costs, indirect costs, contractual penalty costs, duration of activities and total budget constraint. A numerical example illustrates the feasibility of applying the proposed model to a project management decision problem. Consequently, the proposed model yields an efficient compromise solution and the decision maker's overall degree of satisfaction with determined multiple fuzzy goals values. Moreover, the proposed model effectively provides a systematic decision-making framework, enabling a decision maker to interactively modify the fuzzy data and model parameters until a satisfactory solution is obtained. The significant characteristics that differentiate the proposed model from the other models include flexible decision-making processes, multiple objective functions, and wide-ranging decision information. Journal: Construction Management and Economics Pages: 1047-1056 Issue: 10 Volume: 22 Year: 2004 Month: 12 X-DOI: 10.1080/0144619042000241453 File-URL: http://hdl.handle.net/10.1080/0144619042000241453 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:10:p:1047-1056 Template-Type: ReDIF-Article 1.0 Author-Name: Linda Clarke Author-X-Name-First: Linda Author-X-Name-Last: Clarke Author-Name: Georg Herrmann Author-X-Name-First: Georg Author-X-Name-Last: Herrmann Title: Cost vs. production: labour deployment and productivity in social housing construction in England, Scotland, Denmark and Germany Abstract: Labour deployment on representative large-scale housing projects is analysed to reveal distinct differences between England, Germany, Scotland and Denmark. In the light of the debates on convergence/divergence of HRM systems and qualitatively different production systems, the paper is apposite in demonstrating structural differences in the organization of the construction process, their implications for efficiency and productivity, and their impact on employment and contract relations, innovation and skills. The effects of the overriding cost rationale of the British system are illustrated in terms of labour deployment and the efficiency and productivity of the site construction process. Labour deployment is based on the rationale of extensive subcontracting, with main contractors providing the management and cost function whilst their productive capacity rests on subcontracting supply chains. The main contractor has come to specialize in two areas, costing and the management of the process. Subcontractors provide all production personnel and thus the production knowledge for carrying out the work packages and stages. On the continent, in contrast, the economic rationale is different, as main contractors do not depend nearly as much on the production capacity of subcontracting. Journal: Construction Management and Economics Pages: 1057-1066 Issue: 10 Volume: 22 Year: 2004 Month: 12 X-DOI: 10.1080/0144619042000213300 File-URL: http://hdl.handle.net/10.1080/0144619042000213300 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:10:p:1057-1066 Template-Type: ReDIF-Article 1.0 Author-Name: Patrick T.I. Lam Author-X-Name-First: Patrick T.I. Author-X-Name-Last: Lam Author-Name: Mohan M. Kumaraswamy Author-X-Name-First: Mohan M. Author-X-Name-Last: Kumaraswamy Author-Name: S.Thomas Ng Author-X-Name-First: S.Thomas Author-X-Name-Last: Ng Title: The use of construction specifications in Singapore Abstract: Singapore announced its Construction 21 Blueprint in 1999, which included quality improvement as one of the many initiatives aimed at making the construction industry more competitive and efficient. This has culminated in the development of the National Productivity and Quality Specification (NPQS), which was meant to provide a benchmark of desirable quality standards for construction works in Singapore. A survey was carried out in late 2002 before the launch of the NPQS to investigate the use of specifications in the then Singapore construction industry. A representative cross section of samples was taken to include clients, consultants and contractors in both the public and private sectors. Whilst interestingly different perceptions of the respondents were captured, the survey results show that there is indeed scope for improvement from both the drafting and usage viewpoints. On the drafting side, lack of co-ordination, ambiguities, irrelevant clauses and inappropriate standards were the frequently cited problems. On the usage side, specifications were not used as rigorous as they should be for controlling quality of works on site. Clients, in particular, were concerned with the late approvals of alternative material proposals. These findings point to the need for extra care and attention on the preparation and use of specifications as important project control documents, which always form part of the contracts executed in Singapore. Journal: Construction Management and Economics Pages: 1067-1079 Issue: 10 Volume: 22 Year: 2004 Month: 12 X-DOI: 10.1080/0144619042000213265 File-URL: http://hdl.handle.net/10.1080/0144619042000213265 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:10:p:1067-1079 Template-Type: ReDIF-Article 1.0 Author-Name: Igal M. Shohet Author-X-Name-First: Igal M. Author-X-Name-Last: Shohet Author-Name: Monica Paciuk Author-X-Name-First: Monica Author-X-Name-Last: Paciuk Title: Service life prediction of exterior cladding components under standard conditions Abstract: An empirical method was developed for the prediction of the service life of building components, based on an evaluation of their actual performance and on the identification of failure mechanisms affecting their durability. The service life of exterior components subjected to normal service conditions is predicted. Four types of exterior claddings are exemplified: cementitious mortar, synthetic rendering, ceramic mosaic, and wet-fixing stone cladding. The proposed prediction models yield high degrees of fit to the data (R -super-2 in the range of 0.86 to 0.93 at a 0.0001 level of significance). Life cycle costs (LCC) analysis - following service-life prediction results - leads to the conclusion that maintenance and replacements costs account for 10-80% of initial capital costs. Synthetic rendering exhibited the highest LCC effectiveness, reflecting durability and low capital costs. The method can be used for planning preventive maintenance, evaluating economic implications of failures, and planning service life. Journal: Construction Management and Economics Pages: 1081-1090 Issue: 10 Volume: 22 Year: 2004 Month: 12 X-DOI: 10.1080/0144619042000213274 File-URL: http://hdl.handle.net/10.1080/0144619042000213274 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:10:p:1081-1090 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Andrew Saunders Author-X-Name-First: Andrew Author-X-Name-Last: Saunders Title: Occupational rehabilitation in the construction industry of Victoria Abstract: A survey of construction companies' secondary disability management practices was undertaken in the state of Victoria, Australia. The results indicate that formal rehabilitation and return-to-work programmes and practices are not adopted in many companies. Smaller construction firms were less likely to have adopted formal programmes or practices than medium-to-large firms. In particular, construction companies reported difficulties in the provision of suitable alternate or light duties for workers returning to work following an injury. Most companies regarded disability management practices to have increased operating costs while yielding little or no benefit in terms of reducing lost workdays. Strategies to overcome some of these impediments to rehabilitation and return-to-work in construction are recommended. Journal: Construction Management and Economics Pages: 1091-1101 Issue: 10 Volume: 22 Year: 2004 Month: 12 X-DOI: 10.1080/0144619042000241426 File-URL: http://hdl.handle.net/10.1080/0144619042000241426 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:22:y:2004:i:10:p:1091-1101 Template-Type: ReDIF-Article 1.0 Author-Name: Richard Kirkham Author-X-Name-First: Richard Author-X-Name-Last: Kirkham Title: Re-engineering the whole life cycle costing process Abstract: The application of Whole Life Cycle Costing (WLCC) within the construction industry is rapidly increasing; notwithstanding, the underlying methodology of many WLCC models is variable and inconsistent. The deficiency in detailed recording of decisions based on WLCC analyses is a particular concern and moreover, attempts to capture the data related to these decisions are not evident. Data capture is vital in facilitating the iterative and logical application of WLCC. In an attempt to re-engineer the WLCC design process, the evolving research described hereinafter reports on the development of the 'Logbook', a WLCC model decision-support software application. The application works simultaneously with a WLCC model to provide the designers of buildings with a repository of decision data (via the WLCC model), and a sequential, chronological record of the decisions made based on this data - from inception through to final design optimization. It is anticipated that the software will encourage the application of WLCC models as an iterative rather than retrospective process. Journal: Construction Management and Economics Pages: 9-14 Issue: 1 Volume: 23 Year: 2005 Keywords: whole life cycle costing, design process, data collection, decision-making, cost modelling, X-DOI: 10.1080/01446190410001678765 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190410001678765 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:1:p:9-14 Template-Type: ReDIF-Article 1.0 Author-Name: S. L. Tang Author-X-Name-First: S. L. Author-X-Name-Last: Tang Author-Name: K. C. Ying Author-X-Name-First: K. C. Author-X-Name-Last: Ying Author-Name: M. Anson Author-X-Name-First: M. Author-X-Name-Last: Anson Author-Name: M. Lu Author-X-Name-First: M. Author-X-Name-Last: Lu Title: RMCSIM: A simulation model of a ready-mixed concrete plant serving multiple sites using multiple truckmixers Abstract: A simulation computer program named RMCSIM has been developed to simulate a whole day of activities for a concrete plant with N mixing bays, M truckmixers (with two different capacities: 5 m3 and 7 m3) serving S sites, where sites are at variable distances D from the plant and variable quantities Q are required by the sites in which different placing methods are used. It is developed based on a set of data which has been reported earlier in another paper (Anson et al., 2002). An optimal number of truckmixers for a particular day's order size can be found from the results of the simulations. The optimal volume of concrete that a truckmixer carries on any one day is found to be about 27 m3 in Hong Kong situations. It is also found that a two mixing bay concrete plant always provides better services than a one mixing bay plant. The mix combinations of 5 m3 and 7 m3 truckmixers in the fleet have no significant effect on concreting service performance. Lastly, it can be deduced that the causes of unsatisfactory concrete delivery performance are most likely due to site managers' difficulties in precise planning rather than the scheduling at the concrete plant. Journal: Construction Management and Economics Pages: 15-31 Issue: 1 Volume: 23 Year: 2005 Keywords: Ready-mixed, concrete, plant, truckmixers, construction, sites, optimal, Monte Carlo, simulation, Hong Kong, X-DOI: 10.1080/0144619032000124661 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619032000124661 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:1:p:15-31 Template-Type: ReDIF-Article 1.0 Author-Name: Mei-Yung Leung Author-X-Name-First: Mei-Yung Author-X-Name-Last: Leung Author-Name: Thomas Ng Author-X-Name-First: Thomas Author-X-Name-Last: Ng Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Sai-On Cheung Author-X-Name-First: Sai-On Author-X-Name-Last: Cheung Title: Critical stressors influencing construction estimators in Hong Kong Abstract: The main task of contractors' estimators is to predict the likely costs involved in executing a future project. This is an onerous job as any errors made can undermine project success and ultimately reduce the contractors' profit margins. The inherent uncertainty of most construction work, however, together with the often very short time periods involved, make errors unavoidable. Unsurprisingly, therefore, estimation is considered to be a very stressful business. To identify the nature of the stress involved, a survey of construction estimators in Hong Kong was conducted. Using correlation analysis, regression analysis and structural equation modelling, the relationships amongst the causes (stressors or stress factors) and effects (stress) were examined and a causal structural model developed. The results indicate work overload, role conflict, job ambiguity, and working environment to be the most critical stressors, with work underload and distrust being the main indirectly influencing factors. These results are similar to those of a previous study with site managers, suggesting that job ambiguity and work overload are the common problem in the construction industry. The study of the manageability of stress is expected to inspire other similar research involving other professionals in the construction industry. This is expected to be of particular significance in the long-term development of stress management in the industry in general. Journal: Construction Management and Economics Pages: 33-44 Issue: 1 Volume: 23 Year: 2005 Keywords: Construction, cost estimators, Hong Kong, stress, stressors, structural equation modelling, X-DOI: 10.1080/01446190410001678099 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190410001678099 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:1:p:33-44 Template-Type: ReDIF-Article 1.0 Author-Name: Florence Phua Author-X-Name-First: Florence Author-X-Name-Last: Phua Title: Determining the relationship between fee structure and project performance between firms: an empirical study based on institutional and task environment perspectives Abstract: Construction firms, under the influence of different dynamic institutional and task environment forces, are likely to have differing perceptions about the determinants of project performance. To test this proposition, this study uses institutional and task environment frameworks to investigate specifically the relationship between fee structure and project performance across different construction firms. Despite anecdotal evidence suggesting that such a relationship exists, empirical results based on data collected from 398 construction firms in Hong Kong did not support this assertion. However, by further modelling the differences across firms, the results indicate that firms on the whole regard other task environment factors as more important to project performance compared to institutional factors. Based on follow-up interviews, suggestions as to why this may be the case point to the fact that firms feel they can exercise greater business control on the capitalization, enhancement, and management of various task environment resources than they can on institutional ones. The paper concludes by highlighting the need for researchers to be cognizant of the benefits of integrating both task environment and institutional factors and understand how they affect project performance. Journal: Construction Management and Economics Pages: 45-56 Issue: 1 Volume: 23 Year: 2005 Keywords: Institutional factors, task environment factors, fee, project performance, hierarchical regression modelling, X-DOI: 10.1080/0144619042000287796 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000287796 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:1:p:45-56 Template-Type: ReDIF-Article 1.0 Author-Name: Rajat Roy Author-X-Name-First: Rajat Author-X-Name-Last: Roy Author-Name: Margaret Low Author-X-Name-First: Margaret Author-X-Name-Last: Low Author-Name: John Waller Author-X-Name-First: John Author-X-Name-Last: Waller Title: Documentation, standardization and improvement of the construction process in house building Abstract: There is growing interest in the industrialization of house building methods in the UK. Much of the focus has been on the use of manufactured structural components, which addresses the inherent problems of reliance on 'wet trades' but not of the quality and efficiency of the assembly and 'fitting' processes on site. The house building process has tended to develop more through custom and practice rather than formal analysis of methods. There is a lack of standards, and of mechanisms for process review or sharing knowledge and good practice. The result is significant process variability on site. Process documentation is a rigorous description of a process, procedure or policy to facilitate training, and development of consistency of operations and standards. The paper presents work on a process documentation system, and discusses the organizational changes needed to create the cultural environment for process standardization and improvement. Journal: Construction Management and Economics Pages: 57-67 Issue: 1 Volume: 23 Year: 2005 Keywords: house building, build process, information system, change management, X-DOI: 10.1080/0144619042000287787 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000287787 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:1:p:57-67 Template-Type: ReDIF-Article 1.0 Author-Name: Rumit Mehta Author-X-Name-First: Rumit Author-X-Name-Last: Mehta Author-Name: Larry Bridwell Author-X-Name-First: Larry Author-X-Name-Last: Bridwell Title: Innovative construction technology for affordable mass housing in Tanzania, East Africa Abstract: Building affordable housing with adequate structural safety is very important in the developing world. New technology, specifically the Terra Block Fabricator, has the advantage of using local soil and labour to create high quality building blocks. An interesting country in which to examine the potential of this technology is Tanzania because it has had a fascinating history of evolving democratically from socialism to a market economy. Using environmentally appropriate technology can energize local sustainable economic growth by stimulating market demand for improved housing and raising the standard of living in low-income countries. Journal: Construction Management and Economics Pages: 69-79 Issue: 1 Volume: 23 Year: 2005 Keywords: housing, Africa, construction, X-DOI: 10.1080/0144619042000287769 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000287769 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:1:p:69-79 Template-Type: ReDIF-Article 1.0 Author-Name: Graeme Larsen Author-X-Name-First: Graeme Author-X-Name-Last: Larsen Author-Name: Tabarak Ballal Author-X-Name-First: Tabarak Author-X-Name-Last: Ballal Title: The diffusion of innovations within a UKCI context: an explanatory framework Abstract: The UK Construction Industry has been criticized for being slow to change and adopt innovations. The idiosyncrasies of participants, their roles in a social system and the contextual differences between sections of the UK Construction Industry are viewed as being paramount to explaining innovation diffusion within this context. Three innovation diffusion theories from outside construction management literature are introduced, Cohesion, Structural Equivalence and Thresholds. The relevance of each theory, in relation to the UK Construction Industry, is critically reviewed using literature and empirical data. Analysis of the data results in an explanatory framework being proposed. The framework introduces a Personal Awareness Threshold concept, highlights the dominant role of Cohesion through the main stages of diffusion, together with the use of Structural Equivalence during the later stages of diffusion and the importance of Adoption Threshold levels. Journal: Construction Management and Economics Pages: 81-91 Issue: 1 Volume: 23 Year: 2005 Keywords: awareness threshold, cohesion, diffusion of innovations, networks, polymorphic, structural equivalence, thresholds, X-DOI: 10.1080/0144619042000287750 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000287750 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:1:p:81-91 Template-Type: ReDIF-Article 1.0 Author-Name: Vacharapoom Benjaoran Author-X-Name-First: Vacharapoom Author-X-Name-Last: Benjaoran Author-Name: Nashwan Dawood Author-X-Name-First: Nashwan Author-X-Name-Last: Dawood Author-Name: Brian Hobbs Author-X-Name-First: Brian Author-X-Name-Last: Hobbs Title: Flowshop scheduling model for bespoke precast concrete production planning Abstract: Bespoke precast concrete products are particularly designed and custom made for a construction project. The production planning of these products is complicated that considers important concerns, i.e. the reliability of the product delivery programme, the short lead-time competitiveness, and the effective utilization of purpose-built precast moulds. The planning has a high impact on the success of the production. The characteristics of the bespoke precast production are formulated with the flowshop scheduling technique so that an effective production plan can be arranged to meet these concerns. Genetic algorithm is used in the scheduling optimization. Its multi-objective function includes total flowtime, total machine idle time, and total tardiness and earliness. After the model formulation, sensitivity analyses are conducted on the three model's parameters namely the number of mould availability, the processing time changes, and the weighting of the multi-objective function. The proposed model is anticipated to support the planners to arrange economic and efficient production plans. Also, it can be used to determine the suitable number of moulds, the accuracy of the processing time estimation, and the weighting strategy of the multi-objective optimization. Journal: Construction Management and Economics Pages: 93-105 Issue: 1 Volume: 23 Year: 2005 Keywords: flowshop scheduling, bespoke precast concrete, production planning, genetic algorithm, X-DOI: 10.1080/0144619042000287732 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000287732 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:1:p:93-105 Template-Type: ReDIF-Article 1.0 Author-Name: Theo Haupt Author-X-Name-First: Theo Author-X-Name-Last: Haupt Author-Name: Meenakshi Munshi Author-X-Name-First: Meenakshi Author-X-Name-Last: Munshi Author-Name: John Smallwood Author-X-Name-First: John Author-X-Name-Last: Smallwood Title: HIV and AIDS in South African construction: is age nothing but a number? Abstract: Recently the South African government introduced new legislation to regulate the construction industry and, in particular, redistribute the responsibility for construction worker safety and health to include all industry participants. Consequently, the need to maintain and promote construction workers' health and working capacity has been given an increased prominence. Considering that the highest rates of new infections are reportedly occurring on the African continent, the fight against HIV and AIDS in the workplace has become an African priority. A comparative assessment is carried out on the levels of knowledge, perceptions and beliefs, and behaviours of construction workers in South Africa relative to HIV infection and AIDS. The levels of knowledge and awareness of HIV and AIDS among construction workers younger than 40 years of age ('younger workers') are compared with those of workers older than 40 years ('older workers'). A regional exploratory study commenced in August 2002. Both age cohorts of construction workers generally had acceptable levels of knowledge, perceptions and attitudes on most issues relative to the disease. However, several areas are highlighted where they had deficient knowledge and attitudes or demonstrated high levels of uncertainty. Overall, younger workers had lower levels of uncertainty and deficient knowledge. There were several areas where these were common irrespective of age. These are the areas that deserve urgent employer driven interventions. Journal: Construction Management and Economics Pages: 107-119 Issue: 1 Volume: 23 Year: 2005 Keywords: HIV, AIDS, construction workers, South Africa, attitude, behaviour, X-DOI: 10.1080/0144619042000301366 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000301366 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:1:p:107-119 Template-Type: ReDIF-Article 1.0 Author-Name: K. C. Lam Author-X-Name-First: K. C. Author-X-Name-Last: Lam Author-Name: C. M. Tang Author-X-Name-First: C. M. Author-X-Name-Last: Tang Author-Name: W. C. Lee Author-X-Name-First: W. C. Author-X-Name-Last: Lee Title: Application of the entropy technique and genetic algorithms to construction site layout planning of medium-size projects Abstract: Genetic algorithms (GAs) have been introduced into site layout planning as reported in a number of studies. In these studies, the objective functions were defined so as to employ the GAs in searching for the optimal site layout. However, few studies have been carried out to investigate the actual closeness of relationships between site facilities; it is these relationships that ultimately govern the site layout. This study has determined that the underlying factors of site layout planning for medium-size projects include work flow, personnel flow, safety and environment, and personal preferences. By finding the weightings on these factors and the corresponding closeness indices between each facility, a closeness relationship has been deduced. Two contemporary mathematical approaches - fuzzy logic theory and an entropy measure - were adopted in finding these results in order to minimize the uncertainty and vagueness of the collected data and improve the quality of the information. GAs were then applied to searching for the optimal site layout in a medium-size government project using the GeneHunter software. The objective function involved minimizing the total travel distance. An optimal layout was obtained within a short time. This reveals that the application of GA to site layout planning is highly promising and efficient. Journal: Construction Management and Economics Pages: 127-145 Issue: 2 Volume: 23 Year: 2005 Keywords: Site-layout, entropy, genetic algorithm, decision-making, X-DOI: 10.1080/0144619042000202834 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000202834 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:2:p:127-145 Template-Type: ReDIF-Article 1.0 Author-Name: Javier Cuervo Author-X-Name-First: Javier Author-X-Name-Last: Cuervo Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Title: Significance of internalization factors for Singapore transnational construction corporations Abstract: Singapore Transnational Construction Corporations (STCCs) are engaged in foreign value-added construction-related activities in foreign markets. A survey was undertaken to assess the significant factors that serve as reasons for STCCs to benefit from their internalization advantages. The protection of the reputation of the firm and the quality of service to clients were the two related and more important reasons for internalization. STCCs with greater international presence also stressed on avoiding the costs of broken contracts and ensuing litigations as an incentive for internalization. Regardless of the size, years of international experience, or whether specialized or diversified, STCCs viewed the ranking order of seventeen internalization factors to be significantly the same. Besides controlling costs, managers of STCCs will do well by guaranteeing the quality of works to foreign clients to maintain and enhance further the reputation of the firm and contribute positively to the Singapore brand name. Journal: Construction Management and Economics Pages: 147-162 Issue: 2 Volume: 23 Year: 2005 Keywords: internalization factors, international construction, Singapore transnational construction corporations, X-DOI: 10.1080/0144609042000287723 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144609042000287723 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:2:p:147-162 Template-Type: ReDIF-Article 1.0 Author-Name: Ayirebi Dansoh Author-X-Name-First: Ayirebi Author-X-Name-Last: Dansoh Title: Strategic planning practice of construction firms in Ghana Abstract: In Ghana, the operating environment for construction firms is constantly changing in the face of a volatile economic environment, shifting political climate and a highly competitive market. Confronted with such instability, companies need strategic planning to combat the threat to their survival. A survey was conducted to determine how widespread strategic planning is used as a management tool by contractors in Ghana. Construction firms with classification A1B1, A2B2, D1 and D2 were used in the survey. Only 8.5% of D2 firms use strategic planning. The other firms have a combined average of 86.7%. Civil engineering contractors are far ahead of the building contractors in the practice of strategic planning. Strategic plans are drawn to cover an average of three years. There is an urgent need for contractors in the D2 class to be encouraged to seek insight into strategic planning and employ the technique to enhance their chances of surviving risks in the business environment. Journal: Construction Management and Economics Pages: 163-168 Issue: 2 Volume: 23 Year: 2005 Keywords: Strategic planning, construction, management, environment, X-DOI: 10.1080/0144619042000241435 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000241435 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:2:p:163-168 Template-Type: ReDIF-Article 1.0 Author-Name: Jacqueline Glass Author-X-Name-First: Jacqueline Author-X-Name-Last: Glass Title: A best practice process model for hybrid concrete construction Abstract: The term 'hybrid concrete construction' (HCC) is used to describe the combination of concrete construction methods, e.g. in-situ concrete and precast concrete, with one another or with other materials, e.g. steel. Although it could be argued that most buildings employ such combinations, HCC is the deliberate integration of different construction techniques to achieve a cost, speed or other performance benefit. UK government has been concerned that the construction industry suffers from poor management and exchange of tacit knowledge which can disappear after project teams 'break up'. The completion of several innovative and high profile HCC projects was considered to be a major opportunity to capture project teams' tacit knowledge in this area. The objective of the research was to compile a best practice process model, such that project teams could be better informed as to their roles and responsibilities and thus be better equipped to deliver a building to the client's satisfaction, by using HCC. Interviews and knowledge capture workshops were used to extract lessons that lay embedded in both individuals and teams. The main conclusions were that successful HCC projects were characterized for example, by the development of an ethos of trust, the early involvement of specialists (such as precasters) and the effective management of both tacit and explicit knowledge. The research builds on previous work in the area by identifying best practice information on design, specification and construction factors for HCC and, in addition, some transferable lessons on knowledge capture techniques. Journal: Construction Management and Economics Pages: 169-184 Issue: 2 Volume: 23 Year: 2005 Keywords: Construction, reinforced concrete, process, hybrid, knowledge capture, precast, X-DOI: 10.1080/0144619042000326756 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000326756 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:2:p:169-184 Template-Type: ReDIF-Article 1.0 Author-Name: Roger Hosein Author-X-Name-First: Roger Author-X-Name-Last: Hosein Author-Name: Timothy Michael Lewis Author-X-Name-First: Timothy Michael Author-X-Name-Last: Lewis Title: Quantifying the relationship between aggregate GDP and construction value added in a small petroleum rich economy - a case study of Trinidad and Tobago Abstract: The relationship between gross domestic product and the output of the construction industry is quantified, using as a case study the economy of Trinidad and Tobago (T&T). A historical perspective is used in order that anomalies can be set within the context of the relevant time and circumstances. Because the economy of Trinidad and Tobago is highly dependent on oil and gas revenues, the relationships between construction value added, GDP and oil and gas industry parameters are also included. In nearly all instances there are positive relationships between the parameters examined, and values for the various correlation coefficients have been obtained. An examination of causal factors obtained from a cumulative experience analysis also establishes that the direction of causality runs from the changes in GDP to the increase in construction value added, both at the aggregate level and at the per capita level. A similar positive relationship and direction of temporal causality is apparent between oil and gas revenues (and prices) and construction value added. These relationships are untypical, as smaller developing economies that do not have oil resources would be expected to show negative correlations for these relationships. Journal: Construction Management and Economics Pages: 185-197 Issue: 2 Volume: 23 Year: 2005 Keywords: Gross Domestic Product, Construction, Energy industries, Cumulative experience, correlation analysis, X-DOI: 10.1080/0144619042000287741 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000287741 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:2:p:185-197 Template-Type: ReDIF-Article 1.0 Author-Name: Wei-Chih Wang Author-X-Name-First: Wei-Chih Author-X-Name-Last: Wang Author-Name: Ren-Jye Dzeng Author-X-Name-First: Ren-Jye Author-X-Name-Last: Dzeng Title: Applying cluster identification algorithm and simulation to generate probabilistic network schedules for design projects Abstract: Scheduling of a design project is complex because design activities often have information dependencies between each other. This study proposes a network-based model to schedule design projects and generate probabilistic project durations. The proposed model applies a modified cluster identification algorithm to evaluate information dependencies between design activities to facilitate the establishment of a schedule network (and regroup activities to support the assignment of design work); it also uses a simulation approach to incorporate the effect on duration of the uncertain number of design iterations. The model is implemented in four stages, which are breaking down the design work; evaluating the dependencies; identifying concurrent activities; and estimating the durations of activities and simulating the duration of design project. The advantages of the proposed model are demonstrated through its application to an example project, which was reviewed by industrial practitioners. Practitioners felt that the generated detailed scheduling data could help them to control their design work more precisely than a bar chart. Additionally, the simulated probabilistic project duration provided them with an awareness of the risk involved in meeting the contractual deadline. Journal: Construction Management and Economics Pages: 199-213 Issue: 2 Volume: 23 Year: 2005 Keywords: Cluster identification algorithm, design schedule, information dependency, simulation, and project management, X-DOI: 10.1080/0144619042000301393 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000301393 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:2:p:199-213 Template-Type: ReDIF-Article 1.0 Author-Name: M. D. Mainul Islam Author-X-Name-First: M. D. Mainul Author-X-Name-Last: Islam Author-Name: Olusegun Faniran Author-X-Name-First: Olusegun Author-X-Name-Last: Faniran Title: Structural equation model of project planning effectiveness Abstract: Previous research studies investigating the impact of situational variables on project planning effectiveness have not examined how the situational variables work together to influence planning effectiveness. A structural equation model (SEM) has been developed for describing and quantifying the influence of situational factors in project environments and organizational characteristics of performing organizations on project planning effectiveness. The individual effects of directly-observable variables on the project planning process were evaluated using regression analysis. The SEM approach enables the modelling of multiple factors as latent not-directly-measurable variable sets, thus providing a theoretical insight into how individual influence factors work together to determine the effectiveness of project planning efforts. The project environment has a dominant significant influence on the potential effectiveness of project planning efforts. In contrast, the influence of organizational characteristics is relatively insignificant. Journal: Construction Management and Economics Pages: 215-223 Issue: 2 Volume: 23 Year: 2005 Keywords: Project management, project planning, planning effectiveness, structural equation modelling, Australia, X-DOI: 10.1080/0144619042000301384 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000301384 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:2:p:215-223 Template-Type: ReDIF-Article 1.0 Author-Name: Søren Spangenberg Author-X-Name-First: Søren Author-X-Name-Last: Spangenberg Author-Name: Harald Hannerz Author-X-Name-First: Harald Author-X-Name-Last: Hannerz Author-Name: Finn Tuchsen Author-X-Name-First: Finn Author-X-Name-Last: Tuchsen Title: Hospitalized injuries among bridge and tunnel construction workers Abstract: The aim of the present study was to compare relative risks for hospitalizing injuries among 7761 Danish workers engaged in the construction of different types of major tunnel and bridge traffic links during 1991-2000 in order to determine construction types with high injury risk. Standardized hospitalization ratios (SHR) for injuries were calculated by type of construction (low-level bridge, high-level bridge, bored tunnel and submerged tunnel). All employed males in the total population of Denmark were used as the standard population. Neither the SHR nor the distribution of injury types were independent of the construction type (p<0.05). The hospitalization ratio was highest for bored tunnel workers (SHR = 1.91; 95% CI: 1.65-2.21) and here toxic gases and smoke were a major problem, whereas head injuries were more frequent among workers engaged in other types of construction. The substantial variation in SHR values with construction type might be an argument for inclusion of workers safety in pre-project decision making. Journal: Construction Management and Economics Pages: 237-240 Issue: 3 Volume: 23 Year: 2005 Keywords: Bored tunnel, heavy construction, injury distribution, occupational risk assessment, pre-project decision, toxic gasses and smoke, X-DOI: 10.1080/01446190500041503 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500041503 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:3:p:237-240 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: Alan Bryman Author-X-Name-First: Alan Author-X-Name-Last: Bryman Author-Name: Andrew Price Author-X-Name-First: Andrew Author-X-Name-Last: Price Author-Name: Kay Greasley Author-X-Name-First: Kay Author-X-Name-Last: Greasley Author-Name: Robby Soetanto Author-X-Name-First: Robby Author-X-Name-Last: Soetanto Author-Name: Nicola King Author-X-Name-First: Nicola Author-X-Name-Last: King Title: Project affinity: the role of emotional attachment in construction projects Abstract: Although a wide range of human and organizational factors have been found to be important in the operation of projects, those determined by cultural variables are less well defined. One such influence concerns the notion of 'project affinity', the commitment and attachment by stakeholders and participants to projects and their outcomes. The temporal nature and transient involvement context provided by construction projects arguably presents a climate in which many participants are less likely to display commitment to its goals. This note is concerned with the issue of whether an attachment to a project's goals or to the completed product can lead to improved commitment among those involved. The concept of project affinity was developed in the course of a case study investigation in which operatives' attitudes towards the construction of a cancer research facility were explored. Because of the contribution of the facility to the future care of cancer sufferers, the concept of project affinity proved helpful in understanding a factor that appeared to be influencing the commitment of those involved. The results suggest a complementary concept to that of 'project chemistry' (c.f. Nicolini, 2002). Journal: Construction Management and Economics Pages: 241-244 Issue: 3 Volume: 23 Year: 2005 Keywords: organizational citizenship behaviour, performance, project affinity, project chemistry, X-DOI: 10.1080/01446190500040596 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500040596 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:3:p:241-244 Template-Type: ReDIF-Article 1.0 Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Author-Name: Thomas Tong Author-X-Name-First: Thomas Author-X-Name-Last: Tong Author-Name: Tony Lau Author-X-Name-First: Tony Author-X-Name-Last: Lau Author-Name: K. K. Chan Author-X-Name-First: K. K. Author-X-Name-Last: Chan Title: Selection of vertical formwork system by probabilistic neural networks models Abstract: A good formwork system enables speedy completion of the concrete structure, following which other subsequent trades can be started. However, the current intuitive judgment approach in the selection of formwork systems cannot assure an optimal and consistent result. Artificial neural networks may improve the selection process. Formwork represents a significant part of the cost of concrete structure construction. Most subsequent trades including internal finishing and external cladding depend on the completion of the building structure. A suitable formwork system is thus crucial for maintaining the smooth flow of the various trades and a proper working sequence of various work activities. Based on data collected from a previous study, it is clear that the key factors affecting the selection of a relevant formwork system include building height and structural system, concrete finish, site conditions, availability of equipment and building shape. Neural network models are developed for the selection of vertical formwork systems using the architecture of the probabilistic neural network (PNN) model. A case study verifies the validity of this approach. Journal: Construction Management and Economics Pages: 245-254 Issue: 3 Volume: 23 Year: 2005 Keywords: Formwork selection, PNN, probabilistic neural network, X-DOI: 10.1080/0144619042000205912 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000205912 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:3:p:245-254 Template-Type: ReDIF-Article 1.0 Author-Name: Cheng Lianyu Author-X-Name-First: Cheng Author-X-Name-Last: Lianyu Author-Name: Robert Tiong Author-X-Name-First: Robert Author-X-Name-Last: Tiong Title: Minimum feasible tariff model for BOT water supply projects in Malaysia Abstract: A key issue in implementing water supply projects based on the build, operate and transfer approach is risk allocation. Project risks should be allocated to the best competent party through proper contractual arrangements or through government support so as to achieve a low water tariff. The details of tariff design in BOT water supply projects are identified, and a minimum feasible tariff model is proposed for effective risk allocation arrangements. Risk analysis based on a real project in Malaysia is performed to demonstrate the application of the simulation model on the key factors of inflation, exchange rates and demand risk. The analysis shows that for inflation risk, a pre-set tariff adjustment formula is useful in lowering minimum feasible tariff. For exchange rate risk, the reference rate should be set lower than the best estimate. Lowering of minimum feasible tariff can also be achieved if the tariff for additional demand is lower than the tariff for guaranteed demand. Journal: Construction Management and Economics Pages: 255-263 Issue: 3 Volume: 23 Year: 2005 Keywords: BOT, water supply project, risk allocation, tariff-at-risk, minimum feasible tariff, X-DOI: 10.1080/0144619042000287778 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000287778 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:3:p:255-263 Template-Type: ReDIF-Article 1.0 Author-Name: Henry Hsieh Author-X-Name-First: Henry Author-X-Name-Last: Hsieh Title: The 1990s Taiwan residential construction boom: a supply side interpretation Abstract: An unprecedented boom in Taiwanese residential unit production is described and explained as a supply side phenomenon. Unit construction tripled from 1991 to 1993 and maintained that level for two years before falling back to normal levels. The existence of a peak in real production is identified from production data and considered as supply-side phenomenon. The evidence includes a strong growth in development loans (supply side) compared to house purchase loans (demand side), and a considerable rise in vacancy rates after the Peak. This supply side interpretation is further examined within single equation and simultaneous equation econometric models. This Peak is seen as precipitated by the interaction of the announcement of a new housing regulation (volume control) and an increase in development credit availability. These two events far outweighed demand side considerations for developers. An indirect method of estimation within a unit completions equation indicates that volume control significantly influenced construction. Conversely selling price was insignificant, consistent with the supply side interpretation. A construction approvals equation supports these conclusions. Other equations explain prices and vacancies. The model was cast in the form of a demand and supply for new completions rather than for total units in order to explain production. Journal: Construction Management and Economics Pages: 265-284 Issue: 3 Volume: 23 Year: 2005 Keywords: Developers, Taiwan, residential construction, supply side, the peak, X-DOI: 10.1080/0144619042000202717 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000202717 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:3:p:265-284 Template-Type: ReDIF-Article 1.0 Author-Name: P. A. Koushki Author-X-Name-First: P. A. Author-X-Name-Last: Koushki Author-Name: K. Al-Rashid Author-X-Name-First: K. Author-X-Name-Last: Al-Rashid Author-Name: N. Kartam Author-X-Name-First: N. Author-X-Name-Last: Kartam Title: Delays and cost increases in the construction of private residential projects in Kuwait Abstract: Time-delays and cost-increases associated with the construction of private residential projects in the State of Kuwait are determined. A person-interview survey of 450 randomly selected private residential project owners and developers in 27 representative districts in metropolitan Kuwait formed the database for the study. The socio-economic traits of the owners/developers, and the pre-construction family planning, the design, and the construction phases of the sample projects are presented. Estimates of time-delays and cost-increases are made, and their causes identified. The three main causes of time-delays included changing orders, owners' financial constraints and owners' lack of experience in the construction business. Regarding cost overruns, the three main causes were identified as contractor-related problems, material-related problems and, again, owners' financial constraints. A number of recommendations end the paper. The minimization of time delays and cost overruns in private residential projects would require: the availability of adequate funds, allocation of sufficient time and money at the design phase, and selection of a competent consultant and a reliable contractor to carry out the work. Journal: Construction Management and Economics Pages: 285-294 Issue: 3 Volume: 23 Year: 2005 Keywords: Delay, cost increase, residential projects, Kuwait, X-DOI: 10.1080/0144619042000326710 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000326710 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:3:p:285-294 Template-Type: ReDIF-Article 1.0 Author-Name: Swee Lean Chan Author-X-Name-First: Swee Lean Author-X-Name-Last: Chan Author-Name: Moonseo Park Author-X-Name-First: Moonseo Author-X-Name-Last: Park Title: Project cost estimation using principal component regression Abstract: Factors affecting construction project cost include project-specific factors and those reflecting the characteristics of the project team. Multiple regression is often used to estimate a project's cost, but independent variables with a high degree of correlation are likely be left out of such a model. As a result, only a limited number of factors are included in the estimate of project cost and predictions from such models will not be accurate. To overcome this technical inefficiency, the aims of this study are: to identify factors that contribute to project cost, to construct a predictive project cost model using the principal component technique and to assess the relative importance of determining factors. The data are obtained from a random sample survey comprised of Singapore building projects completed after 1992 costing more than US$5 million in value. Three main groups of variables are identified, pertaining to characteristics of the project, contractors and owner/consultants. Special project requirements such as high technological level; contractor's specialized skills; and public administered contract have significant effects on cost. Other factors include contractor's technical expertise; owner's level of construction sophistication and contractor's financial management ability. The model assesses the impact of individual factors on project cost and provides a decision support tool to estimate cost more accurately. Journal: Construction Management and Economics Pages: 295-304 Issue: 3 Volume: 23 Year: 2005 Keywords: factors, principal component regression model, project cost, X-DOI: 10.1080/01446190500039812 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500039812 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:3:p:295-304 Template-Type: ReDIF-Article 1.0 Author-Name: Nader Abdul-Hadi Author-X-Name-First: Nader Author-X-Name-Last: Abdul-Hadi Author-Name: Abdulsalam Al-Sudairi Author-X-Name-First: Abdulsalam Author-X-Name-Last: Al-Sudairi Author-Name: Saleh Alqahtani Author-X-Name-First: Saleh Author-X-Name-Last: Alqahtani Title: Prioritizing barriers to successful business process re-engineering (BPR) efforts in Saudi Arabian construction industry Abstract: Engaging in business process re-engineering (BPR) efforts could prove to be highly rewarding for construction companies in Saudi Arabia. However, BPR is risky and could be disastrous if not properly approached. To enable sound BPR efforts and increase success chances, thorough investigation of barriers is essential. This study presents 29 barriers, with their influence (strength) on the success of BPR initiatives. Additionally, these barriers are ranked according to the ease of overcoming each. Finally, a graphical aid is provided to enable decision makers to concentrate their efforts on the most influential (strongest), yet easiest to overcome barriers. Following inadequate approach, affected people not informed, culture of construction firms, using inappropriate tools, using external consultants, undefined core processes, and fear and resistance to change are the most important barriers to successful BPR endeavours. Journal: Construction Management and Economics Pages: 305-315 Issue: 3 Volume: 23 Year: 2005 Keywords: Business process re-engineering (BPR), barriers, construction, Saudi Arabia, X-DOI: 10.1080/0144619042000301375 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000301375 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:3:p:305-315 Template-Type: ReDIF-Article 1.0 Author-Name: Gerard Wood Author-X-Name-First: Gerard Author-X-Name-Last: Wood Author-Name: Robert Ellis Author-X-Name-First: Robert Author-X-Name-Last: Ellis Title: Main contractor experiences of partnering relationships on UK construction projects Abstract: Partnering provides a major opportunity for improving project performance, whilst offering direct benefits to the whole of the supply chain. Many research studies reinforce this assertion although there is less critical analysis examining the nature of partnering in practice and whether the claims made for it are consistently justified. The experiences of commercial surveyors and managers within the UK construction industry have been gathered in a pilot study, drawing on the opinions of 48 commercial managers employed by a leading national contractor. The perceptions and experiences of partnering relationships are generally positive, although the early optimism at the beginning of such arrangements is seldom sustained throughout the project lifecycle. Attitudes to partnering are similar whether the relationship is upstream (client/main contractor) or downstream (main contractor/subcontractor). The growth in popularity of alternative procurement methods and statutory adjudication are both regarded as having placed contracting parties on a more equal footing. However in today's competitive environment, contractors continue to operate on tight margins and, common to all project stakeholders, the financial imperative remains the commercial manager's principal consideration. Trust is hard-earned and relationships are still characterised by a cost driven agenda. Journal: Construction Management and Economics Pages: 317-325 Issue: 3 Volume: 23 Year: 2005 Keywords: partnering, commercial relationships, trust, procurement, X-DOI: 10.1080/0144619042000287714 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000287714 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:3:p:317-325 Template-Type: ReDIF-Article 1.0 Author-Name: Wen-Der Yu Author-X-Name-First: Wen-Der Author-X-Name-Last: Yu Author-Name: Shao-Shung Lo Author-X-Name-First: Shao-Shung Author-X-Name-Last: Lo Title: Time-dependent construction social costs model Abstract: Negative impacts of construction works on local traffic, environment and business have been pointed out by previous researchers. However, little work has been conductd on the quantification of such costs. A time-dependent construction social costs (COSCO) model is developed for quantifying the negative impacts that result from construction operations during the field execution phase. The COSCO model is a simplified but practical model that calculates the construction social costs in a conservative way. A roadwork construction project is used to show the applicability of the COSCO model. It is found that the daily social cost was US$18 188-5.52 times the project construction cost. This is a striking illustration of management techniques for mediating the social costs of construction projects. Journal: Construction Management and Economics Pages: 327-337 Issue: 3 Volume: 23 Year: 2005 Keywords: environmental impacts, project planning, road works, social costs, X-DOI: 10.1080/01446190500040281 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500040281 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:3:p:327-337 Template-Type: ReDIF-Article 1.0 Author-Name: S. L. Liu Author-X-Name-First: S. L. Author-X-Name-Last: Liu Author-Name: S. Y. Wang Author-X-Name-First: S. Y. Author-X-Name-Last: Wang Author-Name: K. K. Lai Author-X-Name-First: K. K. Author-X-Name-Last: Lai Title: A general multivariate analysis approach for determining bid mark-up strategy Abstract: In choosing a bidding strategy, the original multivariate approach cannot handle a more general and usual bidding situation when the mean value of the bid price for the strategic bidder is not zero. This problem is solved by extending the original approach, assuming that the cost estimate is normally distributed with a non-zero mean value. The new obtained formula for the probability of winning and the expected profit for the generalized approach are proved to be not influenced by the contract datum parameters and are suitable for determining the optimal mark-up strategy for a future construction contract. A supplementary model is proposed and combined with the original model to determine relevant parameters in the bid distribution and to justify the previously originally obtained estimation formula. Finally, the real data in the original approach is used to demonstrate the new multivariate analysis approach. Journal: Construction Management and Economics Pages: 347-353 Issue: 4 Volume: 23 Year: 2005 Keywords: Bid mark-up strategy, multivariate analysis, maximum likelihood estimation, sealed bid auctions, construction contract, X-DOI: 10.1080/0144619042000190216 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000190216 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:4:p:347-353 Template-Type: ReDIF-Article 1.0 Author-Name: J. P. Couto Author-X-Name-First: J. P. Author-X-Name-Last: Couto Author-Name: J. C. Teixeira Author-X-Name-First: J. C. Author-X-Name-Last: Teixeira Title: Using linear model for learning curve effect on highrise floor construction Abstract: The evolution of repetitive scheduling methods led to the introduction of the learning concept in construction planning. It is common knowledge that performing the same activity repeatedly, and in the same conditions, takes less and less time as the activity is repeated (Gates and Scarpa, 1972). This phenomenon is clear in many construction activities and is known as learning experience or learning effect. The increase in productivity is mainly due to the increasing knowledge acquired by work repetition. Graphic representation is through a learning curve that admits duration decreases as the activity is repeated, according to a predictable and constant learning rate. The Linear Model of logarithmic coordinates (log10Y  =  log10A - nlog10X) was applied to two repetitive construction processes, frequently used in Portuguese construction. The intent was to examine its applicability and efficiency in predicting future performances, and the interest in incorporating the model in new planning methodologies for repetitive construction. In both cases, learning processes were created. Journal: Construction Management and Economics Pages: 355-364 Issue: 4 Volume: 23 Year: 2005 Keywords: Learning effect, learning curve, linear model, planning construction, models, repetitive construction, X-DOI: 10.1080/01446190500040505 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500040505 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:4:p:355-364 Template-Type: ReDIF-Article 1.0 Author-Name: M. Motiar Rahman Author-X-Name-First: M. Motiar Author-X-Name-Last: Rahman Author-Name: Mohan Kumaraswamy Author-X-Name-First: Mohan Author-X-Name-Last: Kumaraswamy Title: Assembling integrated project teams for joint risk management Abstract: Exhaustive risk allocation cannot be achieved through contract conditions, because all risk items cannot be foreseen at the planning stage. Effective management of unforeseen risks/events at post-contract stage needs the collective efforts of all major contracting parties. The attitude and motivation of project participants are critical to such collaborative arrangements. Project 'partners' need to be conditioned, starting with their selection processes, by incorporating appropriate 'soft' or relational qualities as important selection criteria. They would then need to work under suitable teambuilding protocols, with flexible contract conditions and appropriate adjustment mechanisms that would all be tailored to suit each specific project. The theoretical construct so developed is examined through a series of recent Hong Kong based studies on 'joint risk management'. Results lead to the development of a framework for building a coalesced team that includes owners, consultants, contractors, subcontractors and suppliers. Journal: Construction Management and Economics Pages: 365-375 Issue: 4 Volume: 23 Year: 2005 Keywords: Integration, joint risk management, procurement, relational contracting, supply chain management, X-DOI: 10.1080/01446190500040083 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500040083 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:4:p:365-375 Template-Type: ReDIF-Article 1.0 Author-Name: Ahmed Hassanein Author-X-Name-First: Ahmed Author-X-Name-Last: Hassanein Author-Name: Osama Moselhi Author-X-Name-First: Osama Author-X-Name-Last: Moselhi Title: Accelerating linear projects Abstract: Scheduling linear repetitive construction projects, such as highways and pipelines, poses unique challenges due to maintaining crew work continuity. An efficient method is presented, developed to accelerate the delivery of this class of projects so as to meet a specified deadline with least associated cost. The method is simple and ensures crew work continuity. An iterative approach is employed, where, in each iteration, the project schedule is analysed and an activity is identified as the controlling activity. A controlling activity is an activity that if accelerated, would reduce project duration at least additional cost. Upon its identification, the method selects an expediting strategy that would reduce project duration, and the project is rescheduled. Several expediting strategies are considered, including working overtime, double shifts and weekends. The method is implemented in a prototype software that operates in a Windows® environment, providing a user-friendly graphical interface. It has an open architecture, enabling the user to actively participate in tailoring the generated schedule to suit the requirements of the project at hand. The proposed method accounts for incentives and liquidated damages to aid users in identifying the most cost-efficient schedule. A relational database model is implemented in Microsoft Access® to store typical crews and their associated productivity, as well as their availability dates. A project, drawn from the literature, is analysed to demonstrate the basic features of the proposed method and highlight its capabilities. Journal: Construction Management and Economics Pages: 377-385 Issue: 4 Volume: 23 Year: 2005 Keywords: Repetitive construction, acceleration, crew productivity, time-cost trade-off, X-DOI: 10.1080/01446190410001673571 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190410001673571 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:4:p:377-385 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: Stephen Ison Author-X-Name-First: Stephen Author-X-Name-Last: Ison Author-Name: Geoffrey Briscoe Author-X-Name-First: Geoffrey Author-X-Name-Last: Briscoe Title: The construction labour market skills crisis: the perspective of small-medium-sized firms Abstract: Reports abound of the detrimental effect of the construction skills crisis on the performance and future development of the UK construction industry. The industry's continued growth in output, coupled with its unpopularity as a career choice, has led to extreme pressure on its labour market capacity. There remains, however, a paucity of empirical research into the nature of its highly complex labour market. In particular, very little attention has been paid to the impacts being felt by the smaller firms who account for the vast majority of the industry's economic output and employment. This paper reports on research that has explored the perspectives of smaller employers with respect to the skills crisis. Using an inductive methodology, this research canvassed the opinions of representatives of small- and medium-sized (SME) firms in order to establish the impact of skills shortages on the operational efficiency of the industry. The paper reveals the complex interplay of factors which have combined to shape the industry's skills crisis in recent years and uncovers the practical implications for firms attempting to operate in increasingly tight labour market conditions. Journal: Construction Management and Economics Pages: 387-398 Issue: 4 Volume: 23 Year: 2005 Keywords: Construction, skills, labour market, SMEs, regional perspectives, policy planning, X-DOI: 10.1080/0144619042000326738 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000326738 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:4:p:387-398 Template-Type: ReDIF-Article 1.0 Author-Name: Issaka Ndekugri Author-X-Name-First: Issaka Author-X-Name-Last: Ndekugri Author-Name: Victoria Russell Author-X-Name-First: Victoria Author-X-Name-Last: Russell Title: Insolvency and resolution of construction contract disputes by adjudication in the UK construction industry Abstract: The Housing Grants, Construction and Regeneration Act 1996 provides that a party to a construction contract has a right, at any time, to refer any dispute under the contract for adjudication. This resolution method requires a neutral third party, the adjudicator, to determine the dispute within 28 days after receipt of the referral regardless of the complexity of the issues in dispute. The decision is to be implemented even if it is palpably wrong in fact or law. A key assumption of this legislation is that any mistakes made by an adjudicator can be corrected by reference of the same to litigation or arbitration. It is a major concern that restoration of the parties to their correct positions may become impossible where, after implementation of an adjudicator's mistaken decision, the beneficiary of the decision becomes insolvent. This article is a critical review of all the cases in which the courts have dealt with the effect of insolvency on the right to adjudicate and the enforceability of adjudicators' decisions. Two main conclusions are derived from the review. First, the court may decline to enforce an adjudicator's payment decision where there is strong evidence that, on account of formal insolvency, the payee would be unable to make repayment if final resolution of the dispute necessitates it. Second, the only exception so far to the general right to refer to adjudication arises where the other party is in administration. Journal: Construction Management and Economics Pages: 399-408 Issue: 4 Volume: 23 Year: 2005 Keywords: Construction, contracts, disputes, adjudication, insolvency, X-DOI: 10.1080/0144619042000326747 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000326747 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:4:p:399-408 Template-Type: ReDIF-Article 1.0 Author-Name: Wu Min Author-X-Name-First: Wu Author-X-Name-Last: Min Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Title: Economic order quantity (EOQ) versus just-in-time (JIT) purchasing: an alternative analysis in the ready-mixed concrete industry Abstract: The literature on the use of just-in-time (JIT) and economic order quantity (EOQ) purchasing has increasingly favoured JIT in recent years, especially when firms are purchasing to meet high and consistent levels of demand, and the JIT operation can take advantage of inventory physical plant space reduction. The theoretical advantages of JIT purchasing may have been overstated. Two new concepts are developed to underpin the idea that, even if the JIT approach can induce inventory physical plant space reduction, it is possible for EOQ to be more cost effective, as the inventory demand approaches the break-even point between the function of the annual holding capacity of an inventory facility and the function of the EOQ-JIT cost indifference point. The survey and case study conducted in the ready-mixed concrete industry in Singapore support this proposition. Journal: Construction Management and Economics Pages: 409-422 Issue: 4 Volume: 23 Year: 2005 Keywords: Break-even point, cost indifference point, EOQ, holding capacity, inventory facility, JIT, X-DOI: 10.1080/01446190500041339 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500041339 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:4:p:409-422 Template-Type: ReDIF-Article 1.0 Author-Name: Obaid Saad Al-Sobiei Author-X-Name-First: Obaid Saad Author-X-Name-Last: Al-Sobiei Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Author-Name: Gul Polat Author-X-Name-First: Gul Author-X-Name-Last: Polat Title: Predicting the risk of contractor default in Saudi Arabia utilizing artificial neural network (ANN) and genetic algorithm (GA) techniques Abstract: The construction project is subject to several risks, one of the most important of which is contractor default because contractor default may increase the final project cost considerably. In the US construction industry, owners commonly shield themselves from the risk of contractor default by transferring this risk to the contractor, who in turn transfers this risk to a surety company. On the other hand, the General Directorate of Military Works (GDMW) of the Kingdom of Saudi Arabia retains the risk of contractor default rather than transferring it to a third party. An artificial neural network (ANN) and a genetic algorithm (GA) are used in this study to predict the risk of contractor default in construction projects undertaken for the Saudi armed forces. Based on this prediction, the Saudi GDMW can make a decision to engage or not to engage the services of a contractor. In case the models are not able to generate reliable predictions (or generate contradictory outcomes), the GDMW will have to augment its budget with contingency funds to be used in the event of contractor default. The outcome of this study is of particular relevance to construction owners because it proposes an approach that can allow them to replace an indiscriminate blanket policy by a policy that is rational, effective, prudent and economical. Journal: Construction Management and Economics Pages: 423-430 Issue: 4 Volume: 23 Year: 2005 Keywords: Artificial neural networks, contractor default, genetic algorithms, prediction model, X-DOI: 10.1080/01446190500041578 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500041578 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:4:p:423-430 Template-Type: ReDIF-Article 1.0 Author-Name: Yiannis Xenidis Author-X-Name-First: Yiannis Author-X-Name-Last: Xenidis Author-Name: Demos Angelides Author-X-Name-First: Demos Author-X-Name-Last: Angelides Title: The financial risks in build-operate-transfer projects Abstract: The build-operate-transfer (BOT) approach for developing infrastructure projects is a technique that allows fast realization of public works in cases of a shortage of public funds. This process is full of risks, due mainly to the complexity and extend of the disciplines, public agencies and stakeholders involved. The identification, classification and presentation of a comprehensive list of this type of risks will provide BOT project practitioners with a useful tool in the effort of setting up successfully a BOT concession agreement. The approach presented provides a practical insight into 27 financial risks, which are associated with the BOT projects in their lifecycle. This is achieved through proper justification and description of the content of each risk. Furthermore, a categorization of the risks is presented, according to the stage at which they occur and the sources of their origin. The findings of this research would facilitate the risk analysis process that is being conducted by risk managers prior to bidding for a BOT project and during the negotiation period. Journal: Construction Management and Economics Pages: 431-441 Issue: 4 Volume: 23 Year: 2005 Keywords: BOT projects, finance, project management, risk, X-DOI: 10.1080/01446190500041552 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500041552 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:4:p:431-441 Template-Type: ReDIF-Article 1.0 Author-Name: John Chan Author-X-Name-First: John Author-X-Name-Last: Chan Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Author-Name: R. Cheung Author-X-Name-First: R. Author-X-Name-Last: Cheung Title: Monitoring financial health of contractors at the aftermath of the Asian economic turmoil: a case study in Hong Kong Abstract: The whole construction industry (contractors, consultants and suppliers) is suffering from business shrinking under the prevailing deflationary economy in Hong Kong. Local contractors are facing tremendous financial problems. The financial situation of a typical local contractor has been analysed for the years since 1997 - the Asian Economic Crisis. By using the financial ratios together with one of Altman's distress models, it is possible to monitor and assess the financial health of contractors. Based on the results of the case study, the financial health of the contractor under study is found satisfactory. In addition to this quantitative analysis, it is advisable for local contractors to conduct a strategic review for their construction industry and their business environment so as to improve their financial performance in both the near future and longer term. Journal: Construction Management and Economics Pages: 451-458 Issue: 5 Volume: 23 Year: 2005 Keywords: Contractors, financial health, monitoring, case study, Hong Kong, X-DOI: 10.1080/0144619042000190207 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000190207 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:5:p:451-458 Template-Type: ReDIF-Article 1.0 Author-Name: Bing Li Author-X-Name-First: Bing Author-X-Name-Last: Li Author-Name: A. Akintoye Author-X-Name-First: A. Author-X-Name-Last: Akintoye Author-Name: P. J. Edwards Author-X-Name-First: P. J. Author-X-Name-Last: Edwards Author-Name: C. Hardcastle Author-X-Name-First: C. Author-X-Name-Last: Hardcastle Title: Critical success factors for PPP/PFI projects in the UK construction industry Abstract: Public-private partnerships (PPPs) are increasingly used in the United Kingdom's public facilities and services provision through the Private Finance Initiative (PFI). Despite some casualties, PPP/PFI projects have been undertaken successfully, but the reasons for success are not entirely clear. Questionnaire survey research examined the relative importance of 18 potential critical success factors (CSF) for PPP/PFI construction projects in the UK. The results show that the three most important factors are: 'a strong and good private consortium', 'appropriate risk allocation' and 'available financial market'. Factor analysis revealed that appropriate factor groupings for the 18 CSFs are: effective procurement, project implementability, government guarantee, favourable economic conditions and available financial market. These findings should influence policy development towards PPPs and the manner in which partners go about the development of PFI projects. Journal: Construction Management and Economics Pages: 459-471 Issue: 5 Volume: 23 Year: 2005 Keywords: Critical success factors (CSF), factor analysis, procurement systems, PFI, PPP, project management, X-DOI: 10.1080/01446190500041537 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500041537 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:5:p:459-471 Template-Type: ReDIF-Article 1.0 Author-Name: Johan Nystrom Author-X-Name-First: Johan Author-X-Name-Last: Nystrom Title: The definition of partnering as a Wittgenstein family-resemblance concept Abstract: This article on partnering and family-resemblance makes two contributions to the debate about the definition of partnering in construction. The first is a distinction between general prerequisites, components and goals when discussing the concept. In order to understand what is specific about partnering the focus should be on the components, which are identified through a literature review. The second contribution is to apply Ludwig Wittgenstein's idea of family-resemblance to the partnering concept. His idea is that a complex concept can be understood as a network of overlapping similarities. From the literature review it is concluded that there are two necessary components in partnering - trust and mutual understanding - and that a number of different components can be added to form a specific variant of partnering. This provides a new method to define the vague and multifaceted concept of partnering in a flexible and structured way. Journal: Construction Management and Economics Pages: 473-481 Issue: 5 Volume: 23 Year: 2005 Keywords: Components, construction, definition, family-resemblance, general prerequisites, goals, partnering, Wittgenstein, X-DOI: 10.1080/01446190500040026 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500040026 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:5:p:473-481 Template-Type: ReDIF-Article 1.0 Author-Name: Robert Ellis Author-X-Name-First: Robert Author-X-Name-Last: Ellis Author-Name: Gerard Wood Author-X-Name-First: Gerard Author-X-Name-Last: Wood Author-Name: David Keel Author-X-Name-First: David Author-X-Name-Last: Keel Title: Value management practices of leading UK cost consultants Abstract: Value management (VM) is widely accepted as an important tool in the management of projects. Through a series of semi-structured interviews, this paper attempts to add to the qualitative exploration of VM, by investigating the attitudes and experiences of VM facilitators within major UK cost consultancies. Clients cut across all sectors, but relatively few subscribe to a formal VM process. Despite the acknowledged importance of early interventions, the focus for many VM studies tends to be at spaces and element levels, rather than at the earlier concept level. VM continues to be used as a cost-cutting exercise, particularly so on projects which are experiencing problems. Formal VM rarely extends beyond tender stage. Workshops remain the common format, but these are often compressed, due to commercial pressures, into a half-day. Techniques are adapted to suit the needs of the project, team and client rather than being rigidly applied according to the theoretical approaches outlined in the literature. The potential to integrate VM and risk management (RM) services is recognized by all, although such integration is yet to be fully developed and implemented. Journal: Construction Management and Economics Pages: 483-493 Issue: 5 Volume: 23 Year: 2005 Keywords: Quantity surveying practice, risk management, value management, X-DOI: 10.1080/01446190500040711 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500040711 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:5:p:483-493 Template-Type: ReDIF-Article 1.0 Author-Name: H. A. Bassioni Author-X-Name-First: H. A. Author-X-Name-Last: Bassioni Author-Name: A. D. F. Price Author-X-Name-First: A. D. F. Author-X-Name-Last: Price Author-Name: T. M. Hassan Author-X-Name-First: T. M. Author-X-Name-Last: Hassan Title: Building a conceptual framework for measuring business performance in construction: an empirical evaluation Abstract: The importance of business performance measurement across industries has elevated in the last decade in what has been described as a revolution. Meanwhile, the construction industry has been criticised for its underperformance and the Latham and Egan reports emphasized the need for performance improvement and measurement. Companies have had to face the dilemma of choosing among different performance measurement frameworks. Hence, a need has been identified for a comprehensive framework. The aim of this research is to fulfil this need by building a conceptual framework for measuring the business performance of construction organizations. The framework had been formulated in previous research upon the principles of the Balanced Scorecard and Business Excellence Models. The research attempts to empirically evaluate and revise the framework through a series of expert interviews and case studies. In addition, empirical feedback has been used to: express the revised framework in a more communicative form, illustrate how business performance can be measured; and highlight the differences between the proposed framework and contemporary performance frameworks. Journal: Construction Management and Economics Pages: 495-507 Issue: 5 Volume: 23 Year: 2005 Keywords: Balanced scorecard, construction, empirical evaluation, excellence model, performance measurement, X-DOI: 10.1080/0144619042000301401 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000301401 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:5:p:495-507 Template-Type: ReDIF-Article 1.0 Author-Name: Florence Yean Yng Ling Author-X-Name-First: Florence Yean Yng Author-X-Name-Last: Ling Author-Name: C. William Ibbs Author-X-Name-First: C. William Author-X-Name-Last: Ibbs Author-Name: Javier Cuervo Author-X-Name-First: Javier Author-X-Name-Last: Cuervo Title: Entry and business strategies used by international architectural, engineering and construction firms in China Abstract: International architectural, engineering and construction (AEC) firms need to decide on the appropriate market entry mode and business strategies when undertaking projects overseas. The objectives of this research are to investigate the effective market entry modes for penetrating China and the effective business strategies for managing projects in China. The research method is based on a structured questionnaire and data were collected via postal survey. Interviews have been conducted to complement the survey. The results show that establishing a wholly owned subsidiary in China is the most effective entry mode. Foreign AEC firms need to adopt a differentiation strategy by providing niche and superior service. They must also pay great attention to customer satisfaction to gain competitive advantage and clinch and manage projects. To succeed in China, foreign AEC firms need to set up a physical office there, to develop a good understanding of local by-laws, understand client requirements better and therefore provide them with a superior product or service. Journal: Construction Management and Economics Pages: 509-520 Issue: 5 Volume: 23 Year: 2005 Keywords: China, foreign firms, international construction, market entry mode, strategies, X-DOI: 10.1080/01446190500040141 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500040141 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:5:p:509-520 Template-Type: ReDIF-Article 1.0 Author-Name: R. J. Kirkham Author-X-Name-First: R. J. Author-X-Name-Last: Kirkham Author-Name: A. H. Boussabaine Author-X-Name-First: A. H. Author-X-Name-Last: Boussabaine Title: Forecasting the residual service life of NHS hospital buildings: a stochastic approach Abstract: Service life appraisal is an important facet of the management of the NHS estate portfolio. Existing approaches to remaining service life estimation use simple deterministic methods, which could yield inaccurate results. An alternative approach to forecasting the remaining life of hospital buildings, based upon a combination of weighted average techniques and a Markov property; the minimum of exponentials, is presented. The results from this model were compared with those obtained by means of existing techniques, and revealed an average percentage difference of 56.26%. This confirms the notion that stochastic approaches in combination with elemental weightings could yield greater accuracy. Whilst the results obtained can be used primarily to determine the overall residual service life of a hospital building, the model also allows the condition state transition probabilities to be calculated at a given time. On the macro level, this information can be used for optimization of maintenance strategies. Journal: Construction Management and Economics Pages: 521-529 Issue: 5 Volume: 23 Year: 2005 Keywords: Service life, forecasting, minimum of exponentials, hospital buildings, probability, Markov chain, stochastic forecasting, X-DOI: 10.1080/0144619042000326729 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000326729 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:5:p:521-529 Template-Type: ReDIF-Article 1.0 Author-Name: Tarek Zayed Author-X-Name-First: Tarek Author-X-Name-Last: Zayed Author-Name: Daniel Halpin Author-X-Name-First: Daniel Author-X-Name-Last: Halpin Title: Deterministic models for assessing productivity and cost of bored piles Abstract: The assessment process of productivity and cost of bored pile construction is dictated by unseen subsurface obstacles, lack of contractor experience and site planning. These problems complicate the estimator's role in evaluating pile equipment productivity and cost. Current research discusses the assessment of piling process productivity and cost using the deterministic technique. Data are collected through questionnaires, site interviews and telephone calls to experts in various construction companies. Many variables have been considered in the piling construction process, such as pile size, depth, pouring method, soil type and construction method. Five deterministic models have been designated to assess productivity, cycle time and cost. The developed models are validated whereas 79% of the outputs have been predicted with more than 75% accuracy. Consequently, three sets of charts have been developed to provide the decision-maker with a solid planning, scheduling and control tool for piling projects. If a pile has 60' depth with φ-18 (18'' diameter pile) in clay soil using a 5' auger height, the cycle time is estimated as 56 and 65.5 minutes; however, productivity is 6 and 5 holes/day for dry and wet methods, respectively. Journal: Construction Management and Economics Pages: 531-543 Issue: 5 Volume: 23 Year: 2005 Keywords: Bored pile, cost, cycle time, deterministic models, productivity, X-DOI: 10.1080/01446190500039911 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500039911 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:5:p:531-543 Template-Type: ReDIF-Article 1.0 Author-Name: Sang-Hoon Lee Author-X-Name-First: Sang-Hoon Author-X-Name-Last: Lee Author-Name: Stephen Thomas Author-X-Name-First: Stephen Author-X-Name-Last: Thomas Author-Name: Richard Tucker Author-X-Name-First: Richard Author-X-Name-Last: Tucker Title: The relative impacts of selected practices on project cost and schedule Abstract: Many studies reveal the positive impact of practices use on overall project performance, resulting in a consensus opinion in the industry that implementation of certain practices leads to improvement; yet there have been no definitive studies reporting in a quantitative manner, the relative impact of practices on different project objectives. This study develops models using multiple descriptive discriminant function analyses that divide project cost and schedule performance into four different performance groups. The study then examines the practices that discriminate among these four groups. Finally these results are summarized into a practice use index categorization for project cost and schedule performance. Critical practices indicating dominant impact on both cost and schedule performance are pre-project planning, project change management and design/information technology practice. Team building practice is a cost-beneficial practice and zero accident techniques practice is a schedule-beneficial practice, while constructability practice has a balanced bottom line impact on both cost and schedule. Journal: Construction Management and Economics Pages: 545-553 Issue: 5 Volume: 23 Year: 2005 Keywords: Cost, discriminant function analysis, practices, relative importance, schedule, X-DOI: 10.1080/01446190500040232 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500040232 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:5:p:545-553 Template-Type: ReDIF-Article 1.0 Author-Name: Frens Pries Author-X-Name-First: Frens Author-X-Name-Last: Pries Author-Name: Andre Doree Author-X-Name-First: Andre Author-X-Name-Last: Doree Title: A century of innovation in the Dutch construction industry Abstract: In recent years, the number of publications on innovation in the construction industry has increased. Many of these documents address qualitative issues, e.g. policies for innovation and present case studies. A more quantitative approach is taken in this paper, which is the continuation of a previous study. It focuses on main types and sources of innovation in the construction industry, and includes an analysis of 55 years of publications in two leading Dutch professional journals. The results show a recent increase in innovation, with two-thirds of innovations coming out of supplying industries. Construction companies contribute mainly in process innovations. Innovation in construction remains to be technology- rather than market-driven. Regulations have a surprising impact, as over one-third of all counted new innovations are related to new regulations. Journal: Construction Management and Economics Pages: 561-564 Issue: 6 Volume: 23 Year: 2005 Keywords: Construction industry, innovation, management, X-DOI: 10.1080/01446190500040349 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500040349 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:6:p:561-564 Template-Type: ReDIF-Article 1.0 Author-Name: Mohammed Fadhil Dulaimi Author-X-Name-First: Mohammed Fadhil Author-X-Name-Last: Dulaimi Author-Name: Madhav Prasad Nepal Author-X-Name-First: Madhav Prasad Author-X-Name-Last: Nepal Author-Name: Moonseo Park Author-X-Name-First: Moonseo Author-X-Name-Last: Park Title: A hierarchical structural model of assessing innovation and project performance Abstract: Research in construction innovation highlights construction industry as having many barriers and resistance to innovations and suggests that it needs champions. A hierarchical structural model is presented, to assess the impact of the role of the project manager (PM) on the levels of innovation and project performance. The model adopts the structural equation modelling technique and uses the survey data collected from PMs and project team members working for general contractors in Singapore. The model fits well to the observed data, accounting for 24%, 37% and 49% of the variance in championing behaviour, the level of innovation and project performance, respectively. The results of this study show the importance of the championing role of PMs in construction innovation. However, in order to increase their effectiveness, such a role should be complemented by their competency and professionalism, tactical use of influence tactics, and decision authority. Moreover, senior management should provide adequate resources and a sustained support to innovation and create a conducive environment or organizational culture that nurtures and facilitates the PM's role in the construction project as a champion of innovation. Journal: Construction Management and Economics Pages: 565-577 Issue: 6 Volume: 23 Year: 2005 Keywords: Champions, innovation, organizational climate, project manager, X-DOI: 10.1080/01446190500126684 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500126684 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:6:p:565-577 Template-Type: ReDIF-Article 1.0 Author-Name: Stuart Green Author-X-Name-First: Stuart Author-X-Name-Last: Green Author-Name: Scott Fernie Author-X-Name-First: Scott Author-X-Name-Last: Fernie Author-Name: Stephanie Weller Author-X-Name-First: Stephanie Author-X-Name-Last: Weller Title: Making sense of supply chain management: a comparative study of aerospace and construction Abstract: Current recipes for learning across business sectors too often fail to recognize the embedded and contextual nature of management practice. The existing literature gives little emphasis to the symbiotic relationship between supply chain management and the broader dynamics of context. The aerospace and construction sectors are selected for comparison on the basis that they are so different. The UK aerospace sector has undergone extensive consolidation as a result of the imperatives of global competitive pressures. In contrast, the construction industry has experienced decades of fragmentation and remains highly localized. An increasing proportion of output in the aerospace sector occurs within a small number of large, globally orientated firms. In contrast, construction output is dominated by a plethora of small firms with high levels of subcontracting and a widespread reliance on self-employment. These differences have fundamental implications for the way that supply chain management is understood and implemented in the two sectors. Semi-structured interviews with practitioners from both sectors support the contention that supply chain management is more established in aerospace than construction. The introduction of prime contracting and the increasing use of framework agreements within the construction sector potentially provide a much more supportive climate for supply chain management than has traditionally prevailed. However, progress depends upon an improved continuity of workload under such arrangements. Journal: Construction Management and Economics Pages: 579-593 Issue: 6 Volume: 23 Year: 2005 Keywords: Consolidation, context, industry structure, sense-making, supply chain management, X-DOI: 10.1080/01446190500126882 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500126882 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:6:p:579-593 Template-Type: ReDIF-Article 1.0 Author-Name: N. A. Ankrah Author-X-Name-First: N. A. Author-X-Name-Last: Ankrah Author-Name: D. A. Langford Author-X-Name-First: D. A. Author-X-Name-Last: Langford Title: Architects and contractors: a comparative study of organizational cultures Abstract: Conflicts between project participants have been identified in various construction industry reports as being one of the principal causes of poor performance on construction projects. These conflicts occur at the interface level in one respect because participants have different objectives and different organizational cultures which define their approach to work and relationship with the other project participants. This research was therefore undertaken to investigate and identify the organizational cultures of two significant players in the project coalition - architects and contractors - on the premise that by revealing specific cultural characteristics and orientations, establishing significant areas of difference and initiating discussion on some of the implications for conflicts and project performance, the context would have been set for assessing and understanding the behaviour of these project participants. A questionnaire survey based on some specific indices of organizational culture conducted on these two groups of participants revealed that in terms of specific traits, significant differences exist in task organization, sources of power and influence, control and coordination, formality, people issues and nature of tasks. The implications are that conflicts are likely to occur within the project coalition at the interface level where human interaction elements occur and this could detract from achieving project objectives. Awareness of these differences, however, improves the chances of achieving the right balance when constructing the team and this could lead to the development of synergy and good 'project chemistry' with positive consequences for overall project performance. Journal: Construction Management and Economics Pages: 595-607 Issue: 6 Volume: 23 Year: 2005 Keywords: Architects, construction industry, contractors, organizational culture, project coalition, X-DOI: 10.1080/01446190500126973 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500126973 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:6:p:595-607 Template-Type: ReDIF-Article 1.0 Author-Name: Julaikha Hossain Author-X-Name-First: Julaikha Author-X-Name-Last: Hossain Author-Name: Kyoko Kusakabe Author-X-Name-First: Kyoko Author-X-Name-Last: Kusakabe Title: Sex segregation in construction organizations in Bangladesh and Thailand Abstract: Why do more women in Bangladesh study civil engineering than in Thailand, but fewer Bangladeshi women take employment in construction companies? The primary data for answering this question were drawn from questionnaire surveys with 204 professional engineers, in-depth interviews with 80 professional women engineers, and informal discussions with employers/representatives in construction organizations in Bangladesh and Thailand. The findings underline the importance of organizational policy, practices and culture in creating a women-friendly workplace in both countries. The findings suggest that despite the reinforcement of societal gender expectations, organizations are able to create their own organizational culture and practices, which could help to utilize women's talent and improve their professional careers. Journal: Construction Management and Economics Pages: 609-619 Issue: 6 Volume: 23 Year: 2005 Keywords: Construction industry, organizational culture, sex segregation, women engineers, X-DOI: 10.1080/01446190500127062 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500127062 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:6:p:609-619 Template-Type: ReDIF-Article 1.0 Author-Name: Andreas Wibowo Author-X-Name-First: Andreas Author-X-Name-Last: Wibowo Title: Estimating general threshold traffic levels of typical build, operate, and transfer toll road projects in Indonesia Abstract: Applying the adjusted present value method enables the estimation of the general minimum traffic levels for the first year of operation required to make typical Indonesia's build, operate and transfer (BOT) toll road projects financially feasible. To determine the level, both average business risk as reflected by the opportunity cost of capital in the country's toll road industry, and project-specific risk as reflected by traffic risk in terms of ramp-up scale, ramp-up duration and catch-up extent are taken into consideration. Pessimistic and optimistic estimates reveal, respectively, that 18 000 vehicles per day (vhd) and 18 100 vhd are the minimum traffic levels under a low traffic risk scenario. This level increases particularly for optimistic estimate if traffic risk rises. To relax these high traffic requirements, the government should attempt to minimize traffic risk and average business risk or to provide financial supports. Sensitivity analysis results demonstrate that the threshold traffic levels are very sensitive to base tolls and construction cost. Journal: Construction Management and Economics Pages: 621-630 Issue: 6 Volume: 23 Year: 2005 Keywords: Adjusted present value, build-operate-transfer, Indonesia, toll road, X-DOI: 10.1080/01446190500040901 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500040901 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:6:p:621-630 Template-Type: ReDIF-Article 1.0 Author-Name: Toke Reichstein Author-X-Name-First: Toke Author-X-Name-Last: Reichstein Author-Name: Ammon Salter Author-X-Name-First: Ammon Author-X-Name-Last: Salter Author-Name: David Gann Author-X-Name-First: David Author-X-Name-Last: Gann Title: Last among equals: a comparison of innovation in construction, services and manufacturing in the UK Abstract: This paper contrasts the attitudes of firms towards innovation from the construction sector with those in services and manufacturing, using data from the UK innovation survey. We examine the liabilities that construction firms face in their innovative activities in comparison to other sectors, drawing from literature on the distinctiveness of construction as an economic activity. We find that the liabilities of immobility and unanticipated demand are among key distinguishing features that separate innovative behaviour in construction from other industries. The paper concludes with a discussion of the merits of cross-sectoral comparative research of this kind, together with issues for further research. Journal: Construction Management and Economics Pages: 631-644 Issue: 6 Volume: 23 Year: 2005 Keywords: Construction innovation, innovation, innovation strategy, manufacturing, services, X-DOI: 10.1080/01446190500126940 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500126940 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:6:p:631-644 Template-Type: ReDIF-Article 1.0 Author-Name: D. Darshi De Saram Author-X-Name-First: D. Darshi Author-X-Name-Last: De Saram Author-Name: S. L. Tang Author-X-Name-First: S. L. Author-X-Name-Last: Tang Title: Pain and suffering costs of persons in construction accidents: Hong Kong experience Abstract: Direct financial costs of accidents are the tip of the iceberg when compared to the indirect costs. Notwithstanding the difficulties involved, it is very important to estimate the indirect costs borne by society, and the non-material losses due to pain, suffering and loss of enjoyment of life undergone by the victim. This study investigates the pain and suffering costs (non-material losses) of the victims of construction accidents in Hong Kong based on relevant High Court personal injury case judgements in the years 1999-2003. The 54 non-fatal accident cases and 14 fatal accident cases analysed indicate that the average percentage of compensation awarded for non-material damages (pain, suffering and loss of enjoyment of life) to that for material damages (loss of earnings, medical and travelling expenses, etc.) during those years is about 30%. This result enables estimating the pain and suffering costs of the society for a particular year if the total material losses of all construction accidents in that year are known. Based on previous research in which the material losses in Hong Kong were evaluated for the years 1999, 2000 and 2001, the corresponding pain and suffering costs could be estimated as 219 million, 150 million and 107 million Hong Kong dollars, respectively (US$1.00 = HK$7.80). Journal: Construction Management and Economics Pages: 645-658 Issue: 6 Volume: 23 Year: 2005 Keywords: Accidents, construction, costs, damages, Hong Kong losses, pain, suffering, X-DOI: 10.1080/01446190500039739 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500039739 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:6:p:645-658 Template-Type: ReDIF-Article 1.0 Author-Name: K. C. Lam Author-X-Name-First: K. C. Author-X-Name-Last: Lam Author-Name: T. S. Hu Author-X-Name-First: T. S. Author-X-Name-Last: Hu Author-Name: S. T. Ng Author-X-Name-First: S. T. Author-X-Name-Last: Ng Title: Using the principal component analysis method as a tool in contractor pre-qualification Abstract: Contractor pre-qualification can be regarded as a complicated, two-group, non-linear classification problem. It involves a variety of subjective and uncertain information extracted from various parties such as contractors, pre-qualifiers and project teams. Non-linearity, uncertainty and subjectivity are the three predominant characteristics of the contractor pre-qualification process. This makes the process more of an art than a scientific evaluation. In addition to non-linearity, uncertainty and subjectivity, contractor pre-qualification is further complicated by the large number of contractor pre-qualification criteria (CPC) used in current practice and the multicollinearity existing between contractor attributes. An alternative empirical method using principal component analysis (PCA) is proposed for contractor pre-qualification in this study. The proposed method may alleviate the existing amount of multicollinearity and largely reduce the dimensionality of the pre-qualification data set. The applicability and potential of PCA for contractor pre-qualification has been examined by way of two data sets: (1) 73 pre-qualification cases (37 qualified and 36 disqualified) collected in England and (2) 85 (45 qualified and 40 disqualified) pre-qualification cases relating to 10 public sector projects in Hong Kong. The PCA-based results demonstrated that strong and positive inter-correlations existed between most of the qualifying variables, with the minimum correlation coefficient being 0.121 and the maximum being 0.899, and that qualified and disqualified contractors could be satisfactorily separated. Journal: Construction Management and Economics Pages: 673-684 Issue: 7 Volume: 23 Year: 2005 Keywords: Contractor pre-qualification, neural networks, principal component analysis, X-DOI: 10.1080/01446190500041263 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500041263 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:7:p:673-684 Template-Type: ReDIF-Article 1.0 Author-Name: Xiao-Hua Jin Author-X-Name-First: Xiao-Hua Author-X-Name-Last: Jin Author-Name: Florence Yean Yng Ling Author-X-Name-First: Florence Yean Yng Author-X-Name-Last: Ling Title: Constructing a framework for building relationships and trust in project organizations: two case studies of building projects in China Abstract: A framework is constructed that can be used to foster trust and build relationships in construction project organizations in China. The research method was based on in-depth study of two building projects in China and data were collected via face-to-face interviews. The results show that as the project progresses, the dominant relationship within each stage deepens. The deepening relationship gives rise to different types of inherent risks such as a partner's self-interest seeking behaviour and opportunistic actions. To counterbalance these risks, trust fostering tools must be employed such as careful selection and effective management of partners. The framework for fostering trust and building relationship developed in the study suggests that (1) relationship deepens from shallow dependence to deep interdependence as the project progresses; (2) different relationships bring about distinct inherent risks; and (3) different trust-fostering tools counterbalance specific inherent risks. This framework could aid in reducing adversarial relationships by suggesting ways to foster trustworthy relationships. Journal: Construction Management and Economics Pages: 685-696 Issue: 7 Volume: 23 Year: 2005 Keywords: China, project management, relationship, risk, trust, X-DOI: 10.1080/01446190500127039 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500127039 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:7:p:685-696 Template-Type: ReDIF-Article 1.0 Author-Name: Gul Polat Author-X-Name-First: Gul Author-X-Name-Last: Polat Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Title: The JIT materials management system in developing countries Abstract: The just-in-time (JIT) approach to materials management appears to be superior to a just-in-case (JIC) approach in terms of reducing cost and improving productivity under most circumstances encountered in industrialized countries. However, is it truly more advantageous than the more commonly used approaches in developing countries? Contractors in developing countries may be compelled to keep excessive inventory under some circumstances to help manage uncertainty in the supply chain and production process, high inflation rates, available discounts on prices of large amounts of materials, and price cuts in case of early purchasing. This study presents a comparison of the JIT and JIC materials management systems in terms of total cost of inventory by means of a simulation model that makes use of actual data obtained from an ongoing trade centre project in Istanbul, Turkey. The study suggests that had the JIT system been used in the project in Istanbul the total cost of inventory would have been 4.4% higher than the total cost of inventory in the JIC system currently used. Journal: Construction Management and Economics Pages: 697-712 Issue: 7 Volume: 23 Year: 2005 Keywords: Materials management systems, just-in-time, developing countries, simulation modelling, X-DOI: 10.1080/01446190500041388 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500041388 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:7:p:697-712 Template-Type: ReDIF-Article 1.0 Author-Name: Emrah Acar Author-X-Name-First: Emrah Author-X-Name-Last: Acar Author-Name: Ismail Kocak Author-X-Name-First: Ismail Author-X-Name-Last: Kocak Author-Name: Yildiz Sey Author-X-Name-First: Yildiz Author-X-Name-Last: Sey Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Title: Use of information and communication technologies by small and medium-sized enterprises (SMEs) in building construction Abstract: Scholars usually agree that small and medium-sized enterprises (SMEs) active in construction are not very innovative when compared with large-size construction enterprises. This is particularly evident in the case of adoption and diffusion of innovation associated with information and communication technologies (ICTs). Although ICTs are powerful instruments for the rapid and broader diffusion of technical knowledge, few SMEs are fully able to exploit their benefits. There is little evidence of how SMEs perceive ICTs and of the extent to which these technologies are actually used in the construction industry. There is a relationship between organizational size and the use of ICTs within the SMEs in the building construction sector in Turkey. A set of ICT variables comprising the perception, investment, usage and the software preferences of SMEs were analysed by making use of the data collected in a survey of a randomly selected sample of 227 building construction firms in Turkey. In contrast to the common approaches that consider SMEs as part of a homogeneous set of firms with similar characteristics, this study seeks the differences in ICT-related attitudes between SMEs of different sizes. Rather than using arbitrarily pre-defined intervals to classify firms by size, cluster analysis was used in this study. Although what emerges as a whole is the common under-utilization of ICTs by SMEs in building construction, 'organizational size' appears to explain some of the ICT-related attitude differences within these SMEs. Policy makers can consider using the findings of this study as inputs in their activities, as these findings represent a generic overview of the diffusion of new technologies and can assist in identifying future research directions. Journal: Construction Management and Economics Pages: 713-722 Issue: 7 Volume: 23 Year: 2005 Keywords: Information and communication technology, organizational size, small firms, Turkish building construction industry, X-DOI: 10.1080/01446190500127112 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500127112 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:7:p:713-722 Template-Type: ReDIF-Article 1.0 Author-Name: We Mild Spaulding Author-X-Name-First: We Mild Author-X-Name-Last: Spaulding Author-Name: Adrian Bridge Author-X-Name-First: Adrian Author-X-Name-Last: Bridge Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: The use of function analysis as the basis of value management in the Australian construction industry Abstract: Function analysis (FA) is considered to be at the core of value management (VM). However, research in the construction industry in the United States and Hong Kong indicates that this fundamental process is sometimes abbreviated or omitted from the VM process. In examining this situation in the Australian construction industry context, the research described in this paper aimed to gather a cross-sectional view of the role of FA in VM in the Australian construction industry by means of a postal questionnaire survey. The results confirm that FA is not always used in the VM process in Australia. Moreover, the functional hierarchy is preferred to the function analysis systems techniques (FAST) diagram when FA is implemented. It is also found that the greater the knowledge the participants have of FA, the more likely FA would be used in the VM process; while the greater the difficulty in implementing FA, the lesser is the commitment to use FA. In addition it is found that, in many ways, the use of FA and VM in general in Australia mirrors that of its operation (difficulty in applying FA, lack of expert facilitators, etc.) in other countries around the world. Exceptions to this include the length of time VM has been used in Australia and the duration of the VM workshops, both of which are shorter than in most countries. Journal: Construction Management and Economics Pages: 723-731 Issue: 7 Volume: 23 Year: 2005 Keywords: Australian construction industry, function analysis, functional hierarchy, value management, X-DOI: 10.1080/01446190500040679 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500040679 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:7:p:723-731 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Valerie Francis Author-X-Name-First: Valerie Author-X-Name-Last: Francis Title: Does work-family conflict mediate the relationship between job schedule demands and burnout in male construction professionals and managers? Abstract: It is unclear where work-family conflict should be theoretically positioned in the relationship between job stress and strain. Data collected from 231 male construction professionals, managers and administrators were analysed to determine whether work-family conflict mediates the relationship between job stressors and burnout. Two different aspects of work-schedule demands, i.e. job schedule irregularity and hours worked per week, were found to be related to the emotional exhaustion dimension of burnout. In all cases, the relationship between job schedule demands and emotional exhaustion was mediated by work-family conflict. The authors conclude that job schedule demands impact upon emotional exhaustion via work-family conflict. Further, work-family conflict is demonstrated to be a key mediating mechanism between schedule demands and emotional exhaustion for male employees. It is recommended that construction organizations examine ways to reduce work-family conflict as a means to reduce burnout and improve employees' wellbeing. Journal: Construction Management and Economics Pages: 733-745 Issue: 7 Volume: 23 Year: 2005 Keywords: Burnout, men, schedule inflexibility, work hours, work-family conflict, wellbeing, X-DOI: 10.1080/01446190500040836 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500040836 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:7:p:733-745 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Chan Author-X-Name-First: Paul Author-X-Name-Last: Chan Author-Name: Rachel Cooper Author-X-Name-First: Rachel Author-X-Name-Last: Cooper Author-Name: Patricia Tzortzopoulos Author-X-Name-First: Patricia Author-X-Name-Last: Tzortzopoulos Title: Organizational learning: conceptual challenges from a project perspective Abstract: Organizational learning has been widely acknowledged as holding the key for companies to survive and prosper and has, in recent years, gained currency in construction management research. Much research centred upon the study of organizational learning as a process, as well as the view and understanding of companies as learning organizations. However, non-construction management researchers have recently begun to recognize the incoherence of the concepts presented in the literature and identified a lack of a solid theoretical and empirical foundation. To further exacerbate the challenge of embracing organizational learning in construction, the industry is largely project-based, thus increasing the difficulties for organizational learning to occur. Past research into organizational learning has also mainly concentrated on an intra-organizational perspective and where construction is specifically concerned, on project partnering. However, we regard such a focus to be myopic as a means of exploring organizational learning at the construction project level. As such, a number of research challenges are recommended including the need to examine organizational learning beyond project partnering; an emphasis on the inter-organizational dynamics involved in both the process and outcomes of organizational learning and the investigation of construction projects as learning networks. Journal: Construction Management and Economics Pages: 747-756 Issue: 7 Volume: 23 Year: 2005 Keywords: Conceptual review, construction projects, learning organization, organizational learning, X-DOI: 10.1080/01446190500127021 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500127021 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:7:p:747-756 Template-Type: ReDIF-Article 1.0 Author-Name: Joe Tak-Yun Wong Author-X-Name-First: Joe Tak-Yun Author-X-Name-Last: Wong Author-Name: Eddie Hui Author-X-Name-First: Eddie Author-X-Name-Last: Hui Author-Name: William Seabrooke Author-X-Name-First: William Author-X-Name-Last: Seabrooke Author-Name: John Raftery Author-X-Name-First: John Author-X-Name-Last: Raftery Title: A study of the Hong Kong property market: housing price expectations Abstract: The size and direction of correlation between housing price movements and expectations differ between housing actors and change over time in Hong Kong. A cross-sectional market outlook survey was conducted in November 2000 to measure housing price expectations and their formation. The study challenges the traditional adaptive expectations theory and finds that the pessimistic mindset of market actors in a deflationary period was due to a lack of economic confidence - the root cause for weak expectations. It also suggests that there exist differential price expectations between different actors. Homebuyers and investors tend to be unrealistically overconfident in the long-term performance of the real estate market. Evidently, the determination of house sale prices is predominantly forward-looking, based more upon macroeconomic fundamentals than the past price trend. Journal: Construction Management and Economics Pages: 757-765 Issue: 7 Volume: 23 Year: 2005 Keywords: Expectation formation, Hong Kong, housing price expectations, X-DOI: 10.1080/01446190500127260 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500127260 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:7:p:757-765 Template-Type: ReDIF-Article 1.0 Author-Name: Danny Myers Author-X-Name-First: Danny Author-X-Name-Last: Myers Title: A review of construction companies' attitudes to sustainability Abstract: In the last decade several initiatives have been taken to encourage the construction industry to support the agenda of sustainable development. On the basis of public disclosures made by companies listed on the UK Stock Exchange this paper reviews current attitudes to sustainability and corporate social responsibility. The findings suggest that very few of the major companies positively embrace these ideas. It is subsequently argued that the fragmented and diverse nature of the industry further complicates the transition towards sustainable construction. The conclusion is that even though the construction industry has its own sustainability agenda, relatively few companies have changed their business paradigm. Journal: Construction Management and Economics Pages: 781-785 Issue: 8 Volume: 23 Year: 2005 Keywords: Corporate social responsibility, sustainable construction, public disclosures, UK government initiatives, X-DOI: 10.1080/01446190500184360 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500184360 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:8:p:781-785 Template-Type: ReDIF-Article 1.0 Author-Name: Graeme Larsen Author-X-Name-First: Graeme Author-X-Name-Last: Larsen Title: Horses for courses: relating innovation diffusion concepts to the stages of the diffusion process Abstract: The research uses a sociological perspective to build an improved, context specific understanding of innovation diffusion within the UK construction industry. It is argued there is an iterative interplay between actors and the social system they occupy that directly influences the diffusion process as well as the methodology adopted. The research builds upon previous findings that argued a level of best fit for the three innovation diffusion concepts of cohesion, structural equivalence and thresholds. That level of best fit is analysed here using empirical data from the UK construction industry. This analysis allows an understanding of how the relative importance of these concepts' actually varies within the stages of the innovation diffusion process. The conclusion that the level of relevance fluctuates in relation to the stages of the diffusion process is a new development in the field. Journal: Construction Management and Economics Pages: 787-792 Issue: 8 Volume: 23 Year: 2005 Keywords: Actor, cohesion, diffusion stages, innovation, structure, structural equivalence, thresholds, X-DOI: 10.1080/01446190500204770 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500204770 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:8:p:787-792 Template-Type: ReDIF-Article 1.0 Author-Name: Jan Brochner Author-X-Name-First: Jan Author-X-Name-Last: Brochner Author-Name: Per-erik Josephson Author-X-Name-First: Per-erik Author-X-Name-Last: Josephson Author-Name: Johan Alte Author-X-Name-First: Johan Author-X-Name-Last: Alte Title: Identifying management research priorities Abstract: An agenda for management research can be set by the academic community with more or less input from practising managers. The purpose of this note is to describe a model for collecting, structuring and analysing practitioner views of what should be the priorities for construction management research. A meeting with construction sector participants gave rise to proposals that were consolidated into 20 management themes. Next, a questionnaire sent to 260 individuals received 140 responses where these themes had been ranked and the strength of recent industry development for each theme assessed. Results show that high priority was assigned to leadership issues and identification of customer needs. The process should be possible to replicate abroad, although cultural differences are expected to influence priorities. Journal: Construction Management and Economics Pages: 793-796 Issue: 8 Volume: 23 Year: 2005 Keywords: Management research, construction management, research priorities, X-DOI: 10.1080/01446190500249569 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500249569 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:8:p:793-796 Template-Type: ReDIF-Article 1.0 Author-Name: Pierre Bonnal Author-X-Name-First: Pierre Author-X-Name-Last: Bonnal Author-Name: Didier Gourc Author-X-Name-First: Didier Author-X-Name-Last: Gourc Author-Name: Ari-pekka Hameri Author-X-Name-First: Ari-pekka Author-X-Name-Last: Hameri Author-Name: Germain Lacoste Author-X-Name-First: Germain Author-X-Name-Last: Lacoste Title: A linear-discrete scheduling model for the resource-constrained project scheduling problem Abstract: For some specific types of construction projects, the classical CPM or PDM scheduling techniques are not the most suitable. Few specific scheduling approaches have been developed to cope with construction projects that are made of either repetitive activities or activities with linear developments. But real-world construction projects do not consist only of such activities. They are generally made of a mixture of linear and/or repetitive activities and of more conventional activities. To allow this, the linear scheduling problem is reformulated, so classical schedule calculation approaches can be used. The implementation of some Allen's algebra features to avoid adverse discontinuities and to allow crew/work continuity, together with a resource-driven and space-constrained scheduling are among the key features of the proposed approach. It is also a spin-off of off-the-field practices used for scheduling real projects in the particle accelerator construction domain; an excerpt from such a construction project is provided for illustrating the methodology. Journal: Construction Management and Economics Pages: 797-814 Issue: 8 Volume: 23 Year: 2005 Keywords: Construction scheduling, linear scheduling, optimization, X-DOI: 10.1080/01446190500040869 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500040869 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:8:p:797-814 Template-Type: ReDIF-Article 1.0 Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Author-Name: Wu Min Author-X-Name-First: Wu Author-X-Name-Last: Min Title: Just-in-time management in the ready mixed concrete industries of Chongqing, China and Singapore Abstract: Implementing just-in-time (JIT) management in the ready mixed concrete (RMC) industry seems viable. It has been observed previously by others that the current practices for managing the concrete supply chain upstream in terms of raw materials acquisition or prerequisite work on site were not geared toward JIT production. However, it is unclear if this observation is also relevant for the procurement of raw materials in the RMC industry in Chongqing (in China) and Singapore. Hence, the purpose of this study is to investigate the implementation status of JIT in the RMC industry in Chongqing and Singapore. The field study conducted found that all the RMC suppliers surveyed were using the demand pull system to manage RMC production and delivery to sites. However, the study also found that the raw materials could be purchased either using the JIT purchasing method or the traditional economic order quantity (EOQ) purchasing method. Further studies to investigate the conditions where a RMC supplier can adopt the JIT purchasing method to procure its raw materials are recommended. Journal: Construction Management and Economics Pages: 815-829 Issue: 8 Volume: 23 Year: 2005 Keywords: Chongqing, JIT, production techniques, ready mixed concrete, Singapore, suppliers, X-DOI: 10.1080/01446190500040638 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500040638 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:8:p:815-829 Template-Type: ReDIF-Article 1.0 Author-Name: Max Bergstrom Author-X-Name-First: Max Author-X-Name-Last: Bergstrom Author-Name: Lars Stehn Author-X-Name-First: Lars Author-X-Name-Last: Stehn Title: Benefits and disadvantages of ERP in industrialised timber frame housing in Sweden Abstract: Industrialised timber frame housing is successful in the Swedish market for one-family housing. In the manufacturing industry, methods and software systems such as enterprise resource planning (ERP) are widespread, demonstrating significant benefits. A survey of the majority of industrialised timber frame housing companies in Sweden demonstrates low ERP use with a low degree of strategic importance, but with operational and managerial benefits. The ERP approach has potential for industrialised housing and its use is favoured by an increased maturity in IT. Journal: Construction Management and Economics Pages: 831-838 Issue: 8 Volume: 23 Year: 2005 Keywords: Enterprise resource planning, industrialised housing, small and medium-sized enterprises, X-DOI: 10.1080/01446190500184097 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500184097 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:8:p:831-838 Template-Type: ReDIF-Article 1.0 Author-Name: Tarek Zayed Author-X-Name-First: Tarek Author-X-Name-Last: Zayed Author-Name: Daniel Halpin Author-X-Name-First: Daniel Author-X-Name-Last: Halpin Author-Name: Ismail Basha Author-X-Name-First: Ismail Author-X-Name-Last: Basha Title: Productivity and delays assessment for concrete batch plant-truck mixer operations Abstract: Current research focuses on assessing productivity, cost, and delays for concrete batch plant (CBP) operations using Artificial Neural Network (ANN) methodology. Data were collected to assess cycle time, delays, cost of delays, cost of delivery, productivity, and price/m3 for the CBP. Two ANN models were designated to represent the CBP process considering many CBP variables. Input variables include delivery distance, concrete type, and truck mixer's load. Output variables include the assessment of cycle time, cost of delays, delivery cost, productivity, and price/m3. The ANN outputs have been validated to show the ANN's robustness in assessing the CBP output variables. The average validity percent for the ANN outputs is 96.25%. A Time-Quantity (TQ) chart is developed to assess the time required for both truck mixers and the CBP to produce a specified quantity of concrete. Charts have been developed to predict cycle time/truck, delays/truck, cost of delays/truck, cost of delivery/m3, and price/m3. Journal: Construction Management and Economics Pages: 839-850 Issue: 8 Volume: 23 Year: 2005 Keywords: Artificial Neural Network (ANN), productivity, cost analysis, cycle time, modeling, concrete batch plant (CBP), truck mixer, X-DOI: 10.1080/01446190500184451 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500184451 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:8:p:839-850 Template-Type: ReDIF-Article 1.0 Author-Name: Manish Gangwar Author-X-Name-First: Manish Author-X-Name-Last: Gangwar Author-Name: Paul Goodrum Author-X-Name-First: Paul Author-X-Name-Last: Goodrum Title: The effect of time on safety incentive programs in the US construction industry Abstract: Recently, safety incentive programs have been under scrutiny by the US Occupational Safety and Health Administration for their effectiveness to improve construction safety performance. Most of the previous research on construction safety incentives focused on anecdotal evidence examining the merits and demerits of safety incentives. Meanwhile, the long-term effect of safety incentive programs on construction safety remains uncertain. This research examined how key safety performance indicators changed over time in the presence of safety incentive programs in the US construction industry using primary survey data. The paper's key finding is that the effectiveness of safety incentive programs does diminish with time, as suspected by earlier experts and managers in the US construction industry. Journal: Construction Management and Economics Pages: 851-859 Issue: 8 Volume: 23 Year: 2005 Keywords: Construction, incentive, safety, personnel management, motivation, X-DOI: 10.1080/01446190500184527 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500184527 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:8:p:851-859 Template-Type: ReDIF-Article 1.0 Author-Name: Chris Ivory Author-X-Name-First: Chris Author-X-Name-Last: Ivory Title: The cult of customer responsiveness: is design innovation the price of a client-focused construction industry? Abstract: Much has been written about the positive contribution made by the customer to innovation in bespoke and low-volume products like those of construction. Far less attention has been given to the potentially corrosive effects the client might have on innovation. Drawing on three construction case studies, this paper argues that strong client leadership may have negative consequences for innovation, including the suppression of innovation and an overly narrow focus on particular types of innovation. Given that innovation has a key role in the future competitiveness of any industry, it is argued that the role of the client in construction innovation requires more careful examination than it has thus far been afforded. Journal: Construction Management and Economics Pages: 861-870 Issue: 8 Volume: 23 Year: 2005 Keywords: The client, innovation, competitiveness, X-DOI: 10.1080/01446190500204648 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500204648 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:8:p:861-870 Template-Type: ReDIF-Article 1.0 Author-Name: Anna Kadefors Author-X-Name-First: Anna Author-X-Name-Last: Kadefors Title: Fairness in interorganizational project relations: norms and strategies Abstract: There is a strong preference for fairness in human interaction, so that people who experience unfairness tend to react with anger, resentment and loss of motivation. Concerns to appear fair influence the behaviour of both individuals and firms. Perceptions of fairness are susceptible to framing and may be influenced by various norms for outcome distribution as well as by decision processes and interpersonal relations. This paper deals with causes and effects of fairness perceptions in construction project relations, mainly fixed price contracts procured by competitive tendering. In such projects, uncertainty results in continuous post contract award problem-solving and negotiations, and fairness concerns may have incremental but significant influence on the terms of exchange. Case studies of client-contractor interaction in two projects are used to discuss of how fairness norms relate to strategies and industry culture. It is concluded that that an intuitive cost-based norm of fair pricing shapes interaction in construction projects, but that consequences vary between projects. The norm may favour contractors, but is also related to poor risk management and client distrust. To improve performance, clients need to design procurement practices and communication so that perceptions of contractor losses are counteracted. Journal: Construction Management and Economics Pages: 871-878 Issue: 8 Volume: 23 Year: 2005 Keywords: Construction contracts, conflict, procurement, fairness, winner's curse, X-DOI: 10.1080/01446190500184238 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500184238 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:8:p:871-878 Template-Type: ReDIF-Article 1.0 Author-Name: Mei-Yung Leung Author-X-Name-First: Mei-Yung Author-X-Name-Last: Leung Author-Name: Paul Olomolaiye Author-X-Name-First: Paul Author-X-Name-Last: Olomolaiye Author-Name: Alice Chong Author-X-Name-First: Alice Author-X-Name-Last: Chong Author-Name: Chloe Lam Author-X-Name-First: Chloe Author-X-Name-Last: Lam Title: Impacts of stress on estimation performance in Hong Kong Abstract: Cost estimation not only requires precise technical and analytical input from estimators but also involves the use of subjective judgement. An investigation on the impact of stress on estimation performance was conducted involving 177 professional estimators in Hong Kong. Using correlation analysis, regression analysis and structural equation modelling, the relationships between stress and various aspects of estimation performance are examined and a causal structural model is developed. The results indicate that stress is a cause of negative estimation performance (resulting in weak interpersonal relationships, unfamiliarity with organization and ineffective process), while, simultaneously, it is beneficial to the professional estimation performance. Furthermore, there is an inverted U-shaped relationship between stress and the organizational relationship. Journal: Construction Management and Economics Pages: 891-903 Issue: 9 Volume: 23 Year: 2005 Keywords: Cost estimation, interpersonal, organization, performance, stress, task, X-DOI: 10.1080/0144619042000326701 File-URL: http://www.tandfonline.com/doi/abs/10.1080/0144619042000326701 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:9:p:891-903 Template-Type: ReDIF-Article 1.0 Author-Name: Xing Wu Author-X-Name-First: Xing Author-X-Name-Last: Wu Author-Name: Zhihui Zhang Author-X-Name-First: Zhihui Author-X-Name-Last: Zhang Title: Input-output analysis of the Chinese construction sector Abstract: The construction sector has played a key role in the Chinese economy, which has been experiencing a rapid growth for the past two decades. This development and growth are reviewed in a framework of input-output analysis. The national input-output table (IO table) was used to study the current input-output profile of the Chinese construction sector and the relationship between the construction sector and other sectors. The pull and push effect of the Chinese construction industry to the whole national economy has been estimated. It shows that the pull effect is much larger than the push effect. Furthermore, through the analysis of a series of four IO tables spanning over the last 10 years, it reveals that the pull and push effect of the Chinese construction industry are both getting larger and larger. This means the Chinese construction industry is becoming mature and is in great transition. Journal: Construction Management and Economics Pages: 905-912 Issue: 9 Volume: 23 Year: 2005 Keywords: Input-output analysis, construction sector, pull effect, push effect, X-DOI: 10.1080/01446190500183974 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500183974 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:9:p:905-912 Template-Type: ReDIF-Article 1.0 Author-Name: Chuan Chen Author-X-Name-First: Chuan Author-X-Name-Last: Chen Author-Name: John Messner Author-X-Name-First: John Author-X-Name-Last: Messner Title: An investigation of Chinese BOT projects in water supply: a comparative perspective Abstract: China has used the Build-Operate-Transfer (BOT) delivery method since the early 1980s. However, there has been a varying degree of success achieved through the use of this method aimed toward the increased development of economic infrastructure projects. The Chinese government continues to shift and revise their delivery approach on BOT projects to maintain public welfare and improve the potential for project success based on lessons learned from practice. Private sponsors accordingly design or adjust their strategies to survive and succeed in this turbulent market environment. Three representative BOT water projects in China were compared to provide both descriptive and predictive insights to both public and private parties involved in water BOT projects in China. Critical lessons were drawn from government initiatives in project institutional settings regarding government support, procurement method, tariff formulae, approval system, and dispute resolution process. Four generic strategies used by private sponsors were identified through these case studies including cost leadership, transaction size maximization, localization, and involvement of multilateral financial organization. Journal: Construction Management and Economics Pages: 913-925 Issue: 9 Volume: 23 Year: 2005 Keywords: Build-Operate-Transfer (BOT), water sector, China, governmental initiatives, strategy, X-DOI: 10.1080/01446190500184121 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500184121 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:9:p:913-925 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Pryke Author-X-Name-First: Stephen Author-X-Name-Last: Pryke Title: Towards a social network theory of project governance Abstract: The findings of a study are presented using social network analysis in an innovative application involving the analysis of construction project governance. The rationale supporting the application of social network analysis (SNA) within the construction project coalition context was published by this author in a previous paper in this journal. The rationale is summarised in order to explore a very specific framework for the examination of the governance of construction coalitions. The significance of the analytical approach proposed relates to the weakness in existing analytical methods, particularly in relation to changes in approach to procurement following the publication of the Latham and Egan reports. The research framework relates to the key functions of the coalitions to SNA. Within the framework of these key functions, network density and actor point centrality data are gathered using a form of linear responsibility analysis chart adapted to assemble network data in node list form for input in UCINET 6, SNA analysis and visualisation software. Analysis of the directional, non-trivial, valued and multivariate network data reveals that the study of comparative network density and project actor related point centrality is effective in providing an understanding of a number of characteristics of new procurement. Specifically, we can study and evaluate quantitatively, possibly for the first time: use and relevance of financial incentives in the governance of projects; emergent and redundant project actor roles; movement away from traditional independent financial management roles within projects adopting a supply chain management (SCM) approach; alternative candidates for the role of manager of the supply chain and their relative levels of engagement and effectiveness; the effects that the use of clusters and SCM have upon post-contract production activities; the effects that partnering arrangements and standardisation of design have upon transaction costs during the production phase; the effects on project governance of a reduced reliance on contract for project governance; and characteristics of the relatively new role of cluster leader. The results of the research are presented here principally in tabulated form and involve network density values for contractual, performance incentive and information exchange networks. Centrality values relate to the prominence of the key project actors within the three main types of network identified above. Journal: Construction Management and Economics Pages: 927-939 Issue: 9 Volume: 23 Year: 2005 Keywords: Governance, procurement, project management, social network analysis (SNA), intra-coalition networks, X-DOI: 10.1080/01446190500184196 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500184196 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:9:p:927-939 Template-Type: ReDIF-Article 1.0 Author-Name: R. Navon Author-X-Name-First: R. Author-X-Name-Last: Navon Author-Name: Y. Shpatnitsky Author-X-Name-First: Y. Author-X-Name-Last: Shpatnitsky Title: A model for automated monitoring of road construction Abstract: Monitoring and control of earthmoving operations is gaining an increasing interest. Manual monitoring and control of earthmoving operations have not yielded the expected results. Additionally, because manual monitoring is labor-intensive, construction managers have to choose between monitoring based on rough estimates, or spending a lot of time collecting and processing data. The latter choice distracts them from many other important duties. The purpose of the present model is to automatically collect and process monitoring data providing the construction manager with real-time control information. The model was developed for road construction. It uses GPS technology for automated data collection, logging the locations of all the earthmoving equipment while working on the project. Specially developed algorithms convert these locations to control information regarding productivity, duration (or progress) and actual consumption of materials. The model was implemented and tested for 3 weeks in a road construction project. The performance of four activities was measured by the model and compared to manual measurement of the same parameters. This comparison indicated that the model could reach a deviation of ±5%. Journal: Construction Management and Economics Pages: 941-951 Issue: 9 Volume: 23 Year: 2005 Keywords: Automated data collection, control, earthmoving, GPS, monitoring, road construction, X-DOI: 10.1080/01446190500183917 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500183917 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:9:p:941-951 Template-Type: ReDIF-Article 1.0 Author-Name: Kelu Guo Author-X-Name-First: Kelu Author-X-Name-Last: Guo Author-Name: Edward Minchin Author-X-Name-First: Edward Author-X-Name-Last: Minchin Author-Name: Ted Ferragut Author-X-Name-First: Ted Author-X-Name-Last: Ferragut Title: The shift to warranties and performance specifications: what of method specifications? Abstract: Assertions have been made recently by many in the public sector and the construction industry that a standard set of specifications based on measurable performance has been developed for the industry. The move from method, or prescriptive, specifications to performance specifications and warranties has produced innovative ideas and changes to the industry; however, it was not clear just how complete the change was or to what extent method specifications were still relied upon. In addition, it was not clear what contribution, if any, method specifications would make to the ideal set of standard specifications. A recently conducted study analyses the prevalence of method specifications versus performance specifications and warranties in highway and bridge construction. Innovative contracting and the trend within state highway agencies to move from method specifications to warranties and performance specifications are discussed, as are suggestions for integrating method specifications into performance and warranty specifications. Journal: Construction Management and Economics Pages: 953-963 Issue: 9 Volume: 23 Year: 2005 Keywords: Method specifications, prescriptive specifications, performance-related specifications, performance-based specifications, warranties, performance specifications, X-DOI: 10.1080/01446190500183842 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500183842 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:9:p:953-963 Template-Type: ReDIF-Article 1.0 Author-Name: David Delgado-Hernandez Author-X-Name-First: David Author-X-Name-Last: Delgado-Hernandez Author-Name: Elaine Aspinwall Author-X-Name-First: Elaine Author-X-Name-Last: Aspinwall Title: Improvement tools in the UK construction industry Abstract: The use of improvement tools in manufacturing industry has proven to be an important aspect of continuous improvement activities. To determine whether the same is true in the UK construction industry, a survey was conducted to assess the current level of use and perceived importance of such tools. In addition, the impact of the ISO 9001 quality system on the level of use and perceived importance of these tools was also investigated. Following a comprehensive literature review, more than thirty improvement tools were identified and categorized using affinity diagrams. Factor analysis was used to demonstrate that the proposed classification was valid. The results of the survey showed that, in terms of use, quality control, performance measures and technology tools are common practice in the industry. A similar set of tools/techniques was perceived as highly important except that technology and performance measures were interchanged. When comparing the mean use and mean perceived importance for each group of techniques, significant differences were found in tools that help to gather customer needs, those aimed at programming and those used for measuring performance. In terms of the ISO 9001 standard, it was found that certified companies make more use of and place higher levels of importance on most of the groups of tools studied than those not certified. The conclusions from the survey will help to develop a framework for suggesting which tools to use at each stage of a construction project. Journal: Construction Management and Economics Pages: 965-977 Issue: 9 Volume: 23 Year: 2005 Keywords: Improvement tools, total quality management (TQM), survey, construction projects, X-DOI: 10.1080/01446190500204705 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500204705 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:9:p:965-977 Template-Type: ReDIF-Article 1.0 Author-Name: James Wong Author-X-Name-First: James Author-X-Name-Last: Wong Author-Name: Albert Chan Author-X-Name-First: Albert Author-X-Name-Last: Chan Author-Name: Y. H. Chiang Author-X-Name-First: Y. H. Author-X-Name-Last: Chiang Title: Time series forecasts of the construction labour market in Hong Kong: the Box-Jenkins approach Abstract: Labour resources are invaluable assets in the construction industry. Nurturing a quality workforce and promoting stable employment for construction personnel have often been advocated as part and parcel of an industrial policy. Yet, the future labour market of the industry is always uncertain, and there is a need for estimating future labour market conditions as an aid to policy formulation and implementation. The Box-Jenkins approach has been applied to develop Autoregressive Integrated Moving Average (ARIMA) models to analyse and forecast five key indicators in the construction labour market of Hong Kong: employment level, productivity, unemployment rate, underemployment rate and real wage. This approach can be adopted in more complex and diverse labour markets subject to the properties of the utilized data series. Quarterly time-series statistics over the period 1983-2002 are used in this study. The predictive adequacy of the models derived is evaluated with out-of-sample forecasts in comparison with actual data, based on the mean absolute percentage error (MAPE) and the Theil's U statistics. The results indicate that except for construction employment, the proposed forecasting models have reasonably good predictive performance. Among the five case studies, the most accurate is the construction real wages model. In addition, we conclude that univariate projection is not an appropriate method for forecasting construction employment in Hong Kong. Multivariate structural forecasting analysis should be adopted in order to obtain more accurate estimates. The developed models can be used to provide benchmark estimates for further analysis of the construction labour market and the projections offer valuable information and early signals to training providers and employment policy makers. Journal: Construction Management and Economics Pages: 979-991 Issue: 9 Volume: 23 Year: 2005 Keywords: Box-Jenkins approach, time-series forecast, labour market, construction industry, Hong Kong, X-DOI: 10.1080/01446190500204911 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500204911 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:9:p:979-991 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: Barbara Bagilhole Author-X-Name-First: Barbara Author-X-Name-Last: Bagilhole Title: Guest Editorial Abstract: Journal: Construction Management and Economics Pages: 995-1000 Issue: 10 Volume: 23 Year: 2005 X-DOI: 10.1080/01446190500483036 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500483036 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:10:p:995-1000 Template-Type: ReDIF-Article 1.0 Author-Name: Geoff Briscoe Author-X-Name-First: Geoff Author-X-Name-Last: Briscoe Title: Women and minority groups in UK construction: recent trends Abstract: Trends in the employment share of women working in UK construction are compared to the proportions of women in the total national workforce. The distribution of women workers across occupations in construction is examined and factors limiting the participation of women are briefly addressed. The position of ethnic minority workers in construction is analysed using recent data. Broad statistics on the extent of disability in the workforce are presented. Recent data is produced on the regional distribution of women, ethnic minorities and disabled people in the industry workforce. Finally, attention is drawn to likely future changes in diversity in the workforce and influences are noted that may yet result in greater participation of minority groups in the construction labour market. Journal: Construction Management and Economics Pages: 1001-1005 Issue: 10 Volume: 23 Year: 2005 Keywords: Women in construction, ethnic minorities, disabled workers, current trends, regional differences, X-DOI: 10.1080/01446190500204739 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500204739 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:10:p:1001-1005 Template-Type: ReDIF-Article 1.0 Author-Name: A. S. Caplan Author-X-Name-First: A. S. Author-X-Name-Last: Caplan Author-Name: J. Gilham Author-X-Name-First: J. Author-X-Name-Last: Gilham Title: Included against the odds: failure and success among minority ethnic built-environment professionals in Britain Abstract: Despite domination of the built environment professions (BEPs) by white men, there exists within it a small core of minority ethnic (ME) professionals who are becoming well organized and articulate within their professions. Based on a foundation of research conducted for the Construction Industry Training Board (CITB) and more recent work for the Commission for Architecture and the Built Environment (CABE) by the Centre for Ethnic Minority Studies (CEMS, Royal Holloway, University of London), this paper describes and analyses the factors that have enabled this group to enter the industry and, in some cases, to prosper. Implicit in the analysis is a critique of those structural and cultural factors that have prevented others from following their career aims, and of the failure of the industry more generally to be inclusive and diversify its workforce. The discussion draws upon interviews with ME professionals, students, lecturers and employers working in Britain in construction, engineering, architecture, surveying, planning and urban and landscape design to exemplify the key areas of access, support, development and progression in the industry, and to present a clear and rounded picture of what it takes to succeed as a ME professional in the BEPs today. Journal: Construction Management and Economics Pages: 1007-1015 Issue: 10 Volume: 23 Year: 2005 Keywords: Construction, built environment, minority ethnic, management, diversity, X-DOI: 10.1080/01446190500310700 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500310700 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:10:p:1007-1015 Template-Type: ReDIF-Article 1.0 Author-Name: Andy Steele Author-X-Name-First: Andy Author-X-Name-Last: Steele Author-Name: Stephen Todd Author-X-Name-First: Stephen Author-X-Name-Last: Todd Title: The future of the black and minority ethnic (BME) construction sector in England Abstract: It is generally recognized that there is a lack of equality of opportunity for minority-led contractors and consultants (i.e. where at least 50 per cent of the workforce or ownership is from a minority group, such as women, disabled people or a black and minority ethnic community) to compete for work within the housing association sector. In response, the Housing Corporation, the government quango responsible for social housing in the UK, recently commissioned research to investigate the potential benefits of establishing a national database of such companies for the sector in England. The expectation was that such an initiative will help develop, support and promote black and minority ethnic (BME) companies and at the same time, redress the skills shortage in the construction industry. Recent funding cuts within the Housing Corporation now seriously undermine the future sustainability and development of this sector of the construction industry. This paper begins by providing an overview of the types of discrimination faced by BME contractors and consultants. This is set within the context of an unprecedented expansion in the construction sector but where restricted capacity among mainstream contractors due to skill and staff shortages is increasingly evident. The extent to which contractor registration databases have addressed these inequalities is then considered with particular reference to the largest of such contractor registration systems, Constructionline. Drawing on recent empirical work, the development requirements of such a database from the perspective of BME contractors and consultants is considered. The discussion also focuses on the future sustainability of BME small and medium enterprises. The commitment of social housing agencies to equality of opportunity will be crucial to the success of this sector. Journal: Construction Management and Economics Pages: 1017-1023 Issue: 10 Volume: 23 Year: 2005 Keywords: Equality, construction, housing, ethnic and minorities, X-DOI: 10.1080/01446190500372429 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500372429 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:10:p:1017-1023 Template-Type: ReDIF-Article 1.0 Author-Name: Justin Byrne Author-X-Name-First: Justin Author-X-Name-Last: Byrne Author-Name: Linda Clarke Author-X-Name-First: Linda Author-X-Name-Last: Clarke Author-Name: Marc Van Der Meer Author-X-Name-First: Marc Author-X-Name-Last: Van Der Meer Title: Gender and ethnic minority exclusion from skilled occupations in construction: a Western European comparison Abstract: Women and ethnic minorities remain seriously underrepresented in skilled construction occupations despite European Union policy to overcome labour market segregation and despite their increasing participation in the economy-wide labour market. The paper seeks to account for differences in female and ethnic minority/migrant participation in both the deregulated, craft-based construction industries of Italy and Spain and, to an extent, Britain and in the regulated industrial and training-based industries of Denmark and the Netherlands. The authors found that the only entry route for women is to obtain formal qualifications, with the Dutch and Danish education and training systems being especially pivotal to inclusion. Those from ethnic minorities and recent migrants, whilst proportionately overrepresented in Italy and Spain, face more vertical segregation in being largely confined to the bottom of the job ladder. Key obstacles confronted by both groups are the opportunity to undertake work-based training, output-based wage systems, informal methods of recruitment and lack of proactive implementation of equal opportunities policies. The conclusion drawn is that European and national authorities and social partners need to address equality of access and of employment conditions to ensure that regulation overcomes exclusion. Journal: Construction Management and Economics Pages: 1025-1034 Issue: 10 Volume: 23 Year: 2005 Keywords: Construction industry, gender segregation, ethnic minorities, Europe, labour markets, X-DOI: 10.1080/01446190500310759 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500310759 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:10:p:1025-1034 Template-Type: ReDIF-Article 1.0 Author-Name: Ann De Graft-Johnson Author-X-Name-First: Ann Author-X-Name-Last: De Graft-Johnson Author-Name: Sandra Manley Author-X-Name-First: Sandra Author-X-Name-Last: Manley Author-Name: Clara Greed Author-X-Name-First: Clara Author-X-Name-Last: Greed Title: Diversity or the lack of it in the architectural profession Abstract: Approximately 37 per cent of architectural students are women and the percentage is increasing. This increase is not reflected in the architectural profession; women represent only 13 per cent of the total and analysis reveals that women are leaving the profession after qualifying. The research reported here was undertaken in 2003 and investigated the reasons why women were leaving. Research methods included the appointment of an expert advisory group, an extensive literature review, a web-based questionnaire aimed at women architects and a series of interviews with women who had left architecture. No single reason emerged from the research to explain why women left but a multiplicity of factors, such as low pay, poor promotion prospects, discriminatory attitudes and sexist behaviour were found to influence departure. The problem has an international dimension as revealed through the web survey and from ongoing academic interest. There are serious implications for the future of the profession if, through its culture and practice, it loses skilled people after they have qualified. Finally a series of key strategic recommendations for the professional bodies as well as practitioners suggest ways of reducing this female brain drain. The aim is to increase diversity in the construction industry and improve the competitive edge of the architectural profession. Journal: Construction Management and Economics Pages: 1035-1043 Issue: 10 Volume: 23 Year: 2005 Keywords: Women in architecture, gender, discrimination, inclusion, equality, diversity, workplace practice and culture, equal opportunities, X-DOI: 10.1080/01446190500394233 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500394233 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:10:p:1035-1043 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Valerie Francis Author-X-Name-First: Valerie Author-X-Name-Last: Francis Title: The decline of the 'traditional' family: work-life benefits as a means of promoting a diverse workforce in the construction industry of Australia Abstract: The 'traditional' managerial career model was based upon a clear division of labour. Typically, women stayed at home to raise children and manage household work while men acted as primary breadwinners. In this arrangement, relocation, long and inflexible hours of work and frequent travel were not only possible but were a prerequisite for advancement. However, since the 1950s, dramatic changes to family structures and workforce composition have occurred. In the twenty-first century the majority of women, including those who may be considered in the child-bearing and early child-rearing age group, are in paid employment. There has also been an increase in the number of lone parents in the workforce. There is evidence of a corresponding change in employees' expectations, with both men and women placing greater value on both work and family involvement. Given these changes, it can no longer be assumed that employees are 'free' to devote all their energy to their work. Nor can it be assumed that there is a clear separation between employees' work and personal lives. The construction industry has a culture of long hours and weekend work, and construction employees struggle to achieve a balance between their work and personal lives. This paper suggests that, in order to attract and retain a talented workforce, construction organizations will increasingly have to cater for the diverse needs of employees with regard to work-life balance. Furthermore, it is likely that employees' needs will vary according to their gender, age and stage of family development. A 'one size fits all' approach to managing work-life balance is unlikely to suffice. This paper presents the results of an empirical investigation of project-based professional and managerial employees' preferences for work-life balance initiatives in Australian private and public sector construction organizations. Preferences were found to differ significantly by employee family structure and age. The small number of female respondents did not warrant statistical comparisons by gender. However, the profile of female respondents suggests that women with dependent children are seriously under-represented in project-based positions within the participating organizations. Finally, the implications for managing a diverse workforce are discussed. Journal: Construction Management and Economics Pages: 1045-1057 Issue: 10 Volume: 23 Year: 2005 Keywords: Work-life benefits, age, gender, family structure, diversity, X-DOI: 10.1080/01446190500394308 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500394308 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:10:p:1045-1057 Template-Type: ReDIF-Article 1.0 Author-Name: Clara Greed Author-X-Name-First: Clara Author-X-Name-Last: Greed Author-Name: Dory Reeves Author-X-Name-First: Dory Author-X-Name-Last: Reeves Title: Mainstreaming equality into strategic spatial policy making: are town planners losing sight of gender? Abstract: Spatial planning authorities have a pivotal role in shaping the built environment, through the production of development plans and the operation of the development control system. Previous research shows that the needs of women have not been given as much attention as those of men in the formulation of planning policy. Yet European Union directives and United Kingdom government guidance require local authorities to mainstream gender considerations into spatial policy-making. This paper draws on research undertaken for the Royal Town Planning Institute on the extent to which gender mainstreaming is taking place within planning authorities. A qualitative approach was adopted to identify those factors facilitating or restricting adoption. It was found that a generic, rather than gendered, approach to mainstreaming prevails. Gender is given a relatively low priority relative to other over-arching policy considerations, such as environmental sustainability or racial equality. A cameo study of the Greater London Authority demonstrates the difficulties encountered by even the most progressive planning departments. It is concluded that for gender considerations to be taken seriously by planners, legislative and procedural reforms are required, along with cultural change within the wider context of the construction industry. Journal: Construction Management and Economics Pages: 1059-1070 Issue: 10 Volume: 23 Year: 2005 Keywords: Spatial planning, gender, mainstreaming, diversity, equality, Greater London Authority, X-DOI: 10.1080/01446190500372353 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500372353 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:10:p:1059-1070 Template-Type: ReDIF-Article 1.0 Author-Name: Rita Newton Author-X-Name-First: Rita Author-X-Name-Last: Newton Author-Name: Marcus Ormerod Author-X-Name-First: Marcus Author-X-Name-Last: Ormerod Title: Do disabled people have a place in the UK construction industry? Abstract: In the UK, a significant number of disabled people are unemployed and previous research has suggested reasons for this include the inaccessibility of workplace environments that have either not been designed, or adapted, to accommodate the requirements of disabled people, and the nature of work being undertaken in that workplace environment. Since there has been no previous research within the context of the construction industry, the aim was to explore contractors' practices in the employment of disabled people and in the adaptation of workplace environments. A survey was undertaken of the top 100 UK contractors in the UK. Views of disabled people were also sought, and access audits of workplace environments were undertaken. The combined analysis shows that compared to UK industries in general, contractors are less likely to have appropriate policies and practices in place to support disabled job applicants through the recruitment process. However, contractors as employers are more likely to make 'reasonable adjustments' as required by the UK Disability Discrimination Act if the adjustment is relatively inexpensive, and if minimal adjustments are required in order to adapt workplaces such that they provide an inclusive approach to the employment of disabled people. Additionally, contractors work hard to ensure that if an employee becomes disabled they are appropriately supported in continued employment. Only a small number of construction organizations believed that 'disabled people do not have a place in the UK construction industry'. It can be concluded that while contractors are unlikely to recruit disabled people, they are more likely to continue to employ people once they become disabled, but there is very little monitoring and evaluation of this process by contractors and it is likely that contractors are not fulfilling their obligations under the Disability Discrimination Act as a result. Journal: Construction Management and Economics Pages: 1071-1081 Issue: 10 Volume: 23 Year: 2005 Keywords: Disability Discrimination Act, disabled employees, reasonable adjustments, social inclusion, workplace environments, X-DOI: 10.1080/01446190500372510 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500372510 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:23:y:2005:i:10:p:1071-1081 Template-Type: ReDIF-Article 1.0 Author-Name: Y. C. Huang Author-X-Name-First: Y. C. Author-X-Name-Last: Huang Title: Graphical-based multistage scheduling method for RC buildings Abstract: In Taiwan, contractors are becoming specialized in certain types of construction in an increasingly competitive environment and this specialization requires some scheduling models to provide better scheduling results for each type of construction. A new practical method, Graphical-Based Multistage Scheduling Method (GMSM), for scheduling RC building superstructures is presented herein. From the analysis of characteristics and construction custom of RC buildings, four constraints, (a) down-up construction, (b) building inspection, (c) reuse of beam forms, and (d) reuse of slab forms, can be established. The GMSM is developed utilizing a graphical-based method and the concept of resource reuse, and the general form of the GMSM to be facilely implemented in any worksheet software is derived as well. The results of this study provide some quantitative information as a useful guide for scheduling RC building superstructures. Journal: Construction Management and Economics Pages: 5-18 Issue: 1 Volume: 24 Year: 2006 Keywords: Multistage scheduling, repetitive project, RC building, GMSM, X-DOI: 10.1080/01446190500183743 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500183743 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:1:p:5-18 Template-Type: ReDIF-Article 1.0 Author-Name: Nashwan Dawood Author-X-Name-First: Nashwan Author-X-Name-Last: Dawood Author-Name: Eknarin Sriprasert Author-X-Name-First: Eknarin Author-X-Name-Last: Sriprasert Title: Construction scheduling using multi-constraint and genetic algorithms approach Abstract: Reliable construction schedules are important for effective co-ordination across the supply chain and various trades at the construction work face. Reliability of construction schedules can be enhanced and improved through satisfying all potential constraints prior to execution on site. Availability of resources, execution space, execution logic, physical dependency of construction products, client instructions and others can be regarded as potential constraints. Current scheduling tools and techniques are fragmented and designed to deal with a limited set of construction constraints. In this context, a methodology termed 'multi-constraint scheduling' is introduced in which four major groups of construction constraints including physical, contract, resource and information constraints are considered to demonstrate the approach. A genetic algorithm (GA) has been developed and used for a multi-constraint optimization problem. Given multiple constraints such as activity dependency, limited working area, and resource and information readiness, the GA alters tasks' priorities and construction methods so as to arrive at an optimum or near optimum set of project duration, cost, and smooth resource profiles. The multi-constraints approach has been practically developed as an embedded macro in MS Project. Several experiments were conducted using a simple project and it was concluded that GA can provide near optimum and constraint-free schedules within an acceptable searching time. This will be vital to improve the productivity and predictability of construction sites. Journal: Construction Management and Economics Pages: 19-30 Issue: 1 Volume: 24 Year: 2006 Keywords: Genetic algorithms, lean construction, multi-constraint scheduling, multi-objective optimization, project management, X-DOI: 10.1080/01446190500310486 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500310486 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:1:p:19-30 Template-Type: ReDIF-Article 1.0 Author-Name: Jasper Mbachu Author-X-Name-First: Jasper Author-X-Name-Last: Mbachu Author-Name: Raymond Nkado Author-X-Name-First: Raymond Author-X-Name-Last: Nkado Title: Conceptual framework for assessment of client needs and satisfaction in the building development process Abstract: A conceptual framework is developed for assessment of client needs, and the measurement and monitoring of client satisfaction levels in the building development process. Data were obtained from qualitative and quantitative surveys of a target population of clients of commercial buildings in South Africa. Satisfaction levels based on multi-attribute measures were compared with those based on single evaluative responses, using Wilcoxon's matched-pair test. Results showed no significant differences in pairwise comparisons. A strong positive correlation also existed between both equivalent measures of client satisfaction levels. These results validate the conceptual framework. Results of evaluation of client satisfaction levels showed that clients perceived average levels of satisfaction in the building development process. Areas for improvement in the services of contractors and consultants were identified through 'Criticality Index' analyses. Empirical models were developed for proactive measurements of client satisfaction levels at distinct stages of the development process. A dynamic approach to satisfaction measurement is recommended. This contrasts with post-purchase and static views adopted in the consumer services segment and enables consultants to monitor and improve satisfaction levels proactively, as the development process evolves. Journal: Construction Management and Economics Pages: 31-44 Issue: 1 Volume: 24 Year: 2006 Keywords: Building development, criticality index, needs assessment, performance measurement, satisfaction measurement, X-DOI: 10.1080/01446190500126866 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500126866 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:1:p:31-44 Template-Type: ReDIF-Article 1.0 Author-Name: Ajibade Ayodeji Aibinu Author-X-Name-First: Ajibade Ayodeji Author-X-Name-Last: Aibinu Title: The relationship between distribution of control, fairness and potential for dispute in the claims handling process Abstract: Parties' concern for fairness has been identified as one of the underlying causes of dissatisfaction and protracted dispute in the process for handling contractors' claims. Social psychology literature suggests that distribution of control over the various stages of any conflict resolution process is a factor that may influence concern for fairness. Despite the numerous studies in social psychology and management research, little or no attempt has been made to systematically investigate how distribution of control over the various stages of the process for handling a contractor's claims for delay and disruption could influence concern for fairness and potential for dispute. This should be a useful exercise in that it would suggest ways of reducing potential for disputes in construction project delivery. This study is an attempt to fill this research gap. Drawing on social psychology theory, this study proposes that, in order to enhance perceived fairness and thereby reduce potential for dispute, (1) the claims certifier needs to exercise a higher degree of process and content control over the early stages of process for handling claims than the control exercised by the employer and contractor; (2) the claims certifier must exercise total decision control so as to enhance the perceived impartiality and neutrality of the decision rendered on the claims. By examining two litigated cases, the study illustrates the relationship between distribution of control, perceived lack of fairness and dispute potential. By adopting the proposed principle for distributing control into the claims handling process and coupled with the use of an independent claims certifier, potential for dispute could be reduced on construction projects. Journal: Construction Management and Economics Pages: 45-54 Issue: 1 Volume: 24 Year: 2006 Keywords: Claims, delay and disruption claims, claims process, control, fairness, dispute, X-DOI: 10.1080/14697010500226954 File-URL: http://www.tandfonline.com/doi/abs/10.1080/14697010500226954 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:1:p:45-54 Template-Type: ReDIF-Article 1.0 Author-Name: Mei-Yung Leung Author-X-Name-First: Mei-Yung Author-X-Name-Last: Leung Author-Name: Anita Liu Author-X-Name-First: Anita Author-X-Name-Last: Liu Author-Name: Maggie Mei-ki Wong Author-X-Name-First: Maggie Mei-ki Author-X-Name-Last: Wong Title: Impact of stress-coping behaviour on estimation performance Abstract: The accuracy of an estimate may directly affect the success or failure of a project. Therefore, it is common for estimators in the construction industry to experience a great deal of stress. An appropriate coping behaviour can help estimators to adjust to stress, thereby optimizing their estimation performance. This study aims at identifying estimators' stress-coping behaviours and the impact of these behaviours on estimation performance. In order to understand the stress management of estimators in the industry, the paper investigates the impacts of stress-coping behaviours for two experienced estimator groups with different working experience in Hong Kong. Using correlation analysis and regression analysis, the relationships among stress, coping behaviours and estimation performance were examined. The results revealed that senior estimators normally apply problem-focused coping behaviours to alleviate the stress encountered in their jobs and to improve their estimation performance. A moderate level of stress supports project estimation for project estimators and the cooperative relationship between colleagues for senior estimators. It is suggested that time and stress management training be provided to senior estimators in order to relieve their stress effectively and ensure work efficiency, while a good team spirit should also be fostered in a company to encourage constructive relationships and thus improve estimation performance. Journal: Construction Management and Economics Pages: 55-67 Issue: 1 Volume: 24 Year: 2006 Keywords: Coping behaviours, construction estimators, estimation performance, stress, X-DOI: 10.1080/01446190500228381 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500228381 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:1:p:55-67 Template-Type: ReDIF-Article 1.0 Author-Name: Francis Adams Author-X-Name-First: Francis Author-X-Name-Last: Adams Title: Expert elicitation and Bayesian analysis of construction contract risks: an investigation Abstract: Formal risk analysis techniques applied in managing construction project risks tend to focus on risks that lend themselves to 'objective' methods of economic analysis. Although subjective probabilities and Bayesian methods are applied successfully in other industries to manage 'subjective' risks similar to those encountered in construction contracts, very little is reported on the application of such methods for analysing risks in construction contracts. An investigation has been carried out into using subjective expert opinions and Bayesian methods in construction contract risk analysis. The elicitation of expert opinions about the risk of encountering adverse ground conditions on construction sites is examined. Prior distributions of expert opinions about the risk form the critical component in the Bayesian analysis of risk. The conclusion of this is that although construction professionals have difficulty estimating intermediate and tail values of probability distributions, elicitation techniques can be used to develop prior distributions of contract risks which, coupled with sample information on the risks, would enable the Bayesian analysis of risks. Effective strategies for systematically analysing significant individual contract risks often covered under an 'arbitrary' project contingency sum can now be developed to enhance the risk management efforts of contractors and construction experts. Journal: Construction Management and Economics Pages: 81-96 Issue: 1 Volume: 24 Year: 2006 Keywords: Subjective probabilities, elicitation techniques, Bayesian analysis, risk analysis, Delphi techniques, X-DOI: 10.1080/01446190500310254 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500310254 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:1:p:81-96 Template-Type: ReDIF-Article 1.0 Author-Name: Nigel Dann Author-X-Name-First: Nigel Author-X-Name-Last: Dann Author-Name: Sarah Hills Author-X-Name-First: Sarah Author-X-Name-Last: Hills Author-Name: Derek Worthing Author-X-Name-First: Derek Author-X-Name-Last: Worthing Title: Assessing how organizations approach the maintenance management of listed buildings Abstract: Preventative maintenance has been identified as a key intervention in protecting built cultural heritage. How organizations approach the maintenance management of listed buildings in their care is explored using a framework which integrates best practice from the general maintenance management and conservation sectors. At present both heritage and non-heritage organizations are falling short of a best-practice approach. Although there is increasing awareness among heritage organizations about the importance of maintenance, these organizations lack a systematic and integrated approach to maintenance that centres on the idea of explicitly using the identification of cultural significance and vulnerability as the key reference point for management decisions and actions. While many of the non-heritage organizations had adopted aspects of a best-practice approach to general maintenance management, these had not been recontextualized for the needs of the listed stock. There is a need for a step change to ensure that the retention of cultural significance and minimal intervention set the context for maintenance management strategies and implementation. Journal: Construction Management and Economics Pages: 97-104 Issue: 1 Volume: 24 Year: 2006 Keywords: Maintenance management, listed buildings, X-DOI: 10.1080/01446190500249510 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500249510 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:1:p:97-104 Template-Type: ReDIF-Article 1.0 Author-Name: Odysseus Manoliadis Author-X-Name-First: Odysseus Author-X-Name-Last: Manoliadis Author-Name: Ioannis Tsolas Author-X-Name-First: Ioannis Author-X-Name-Last: Tsolas Author-Name: Alexandra Nakou Author-X-Name-First: Alexandra Author-X-Name-Last: Nakou Title: Sustainable construction and drivers of change in Greece: a Delphi study Abstract: During the last decade, sustainable development issues have been gradually adopted in Greece's construction industry, changing the traditional methods and technology. The aim of this investigation is to identify potential drivers of change, to position them properly in the wider context of sustainable construction and to outline the progress to be expected in the coming decade. The methodological framework used is a Delphi technique based on a questionnaire of 20 experts (consultant engineers, construction managers and contractors). The results show that the most important influences on sustainable construction in Greece are energy conservation measures, resource conservation strategies and waste reduction. In terms of the initiatives expected in the coming decade, energy conservation measures, waste reduction measures, as well as product innovation and certification are expected to rank high. In conclusion, the results are consistent with those of previous researchers showing significant trends towards land use, energy, and resource conservation. Journal: Construction Management and Economics Pages: 113-120 Issue: 2 Volume: 24 Year: 2006 Keywords: Change, sustainable construction, Delphi method, Greece, construction policy, X-DOI: 10.1080/01446190500204804 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500204804 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:2:p:113-120 Template-Type: ReDIF-Article 1.0 Author-Name: Nick Blismas Author-X-Name-First: Nick Author-X-Name-Last: Blismas Author-Name: Christine Pasquire Author-X-Name-First: Christine Author-X-Name-Last: Pasquire Author-Name: Alistair Gibb Author-X-Name-First: Alistair Author-X-Name-Last: Gibb Title: Benefit evaluation for off-site production in construction Abstract: Evaluating to what extent a component or building system should be produced off-site is inadequate within the industry. The potential benefits of off-site production (OSP) are commonly cited when justifying an OSP approach, yet holistic and methodical assessments of the applicability and overall benefit of these solutions, to a particular project, have been found to be deficient. Common methods of evaluation simply take material, labour and transportation costs into account when comparing various options, often disregarding other cost-related items such as site facilities, crane use and rectification of works. These cost factors are usually buried within the nebulous preliminaries figure, with little reference to the building approach taken. Further, softer issues such as health and safety, effects on management and process benefits are either implicit or disregarded within these comparison exercises. Yet it is demonstrated that these issues are some of the most significant benefits of OSP. A series of case studies demonstrated that evaluation focus is almost solely on direct material and labour costs of components, without explicit regard for the wider cost or soft issue implications of OSP on a project. The paper argues that until evaluation is more holistic and value-based rather than cost-based, OSP uptake in construction will be slow. Journal: Construction Management and Economics Pages: 121-130 Issue: 2 Volume: 24 Year: 2006 Keywords: Benefits, evaluation, off-site production, pre-assembly, value, X-DOI: 10.1080/01446190500184444 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500184444 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:2:p:121-130 Template-Type: ReDIF-Article 1.0 Author-Name: Igal Shohet Author-X-Name-First: Igal Author-X-Name-Last: Shohet Author-Name: Monica Paciuk Author-X-Name-First: Monica Author-X-Name-Last: Paciuk Title: Service life prediction of exterior cladding components under failure conditions Abstract: The reliability of service life prediction of building components strongly affects the effectiveness of maintenance policy setting. Despite continuous research and development efforts, existing methods still suffer lack of robustness. Typical failure mechanisms in exterior cladding systems, deterioration patterns, and service life limiting coefficients (modifying factors) are identified for a range of failure mechanisms. The method is based on monitoring the physical and visual performance of building components under similar service conditions, at different periods in the building service life. Three types of exterior cladding are studied: cementitious mortar, synthetic rendering, and ceramic mosaic. Failure mechanisms identified include: lack of design details (such as drip-edge and expansion joints), faulty design under marine environment, exposure to air pollution, and poor workmanship. Three typical deterioration patterns under failure conditions were determined statistically, namely, linear, exponential and logarithmic. The proposed method addresses two issues raised in ISO-15686 in order to improve the precision and reliability of service life forecasting: (a) modifying factors for quantifying the effect of failure mechanisms are estimated within 80% confidence limits and (b) the prediction models yield high degrees of fit to the data (coefficient of determination values ranging between R 2 = 0.88 and R 2 = 0.96 at a 0.0001 level of significance). Journal: Construction Management and Economics Pages: 131-148 Issue: 2 Volume: 24 Year: 2006 Keywords: Service life prediction, performance, premature deterioration, exterior cladding, durability, X-DOI: 10.1080/01446190500184535 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500184535 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:2:p:131-148 Template-Type: ReDIF-Article 1.0 Author-Name: Chris Leishman Author-X-Name-First: Chris Author-X-Name-Last: Leishman Author-Name: Fran Warren Author-X-Name-First: Fran Author-X-Name-Last: Warren Title: Private housing design customization through house type substitution Abstract: The private house building industry is increasingly under pressure to increase output and broaden the appeal of new-build housing to consumers. One possible method for meeting these objectives is through increased use of standardized components to facilitate house type customization. This research focuses on the role of planning and building regulations in permitting the house building industry to respond in this way. Using a database of standardized house types, the analysis examines variation within and between house builders' house type ranges. The analysis shows that the underlying variation between house types of a given size is relatively narrow but that volume builders maintain a comparatively large range of house types. Results from a simulation model demonstrate the positive impact of broadening house type choice on levels of consumer satisfaction. The main conclusion is that a form of house type customization could be achieved through the use of house type substitution. Journal: Construction Management and Economics Pages: 149-158 Issue: 2 Volume: 24 Year: 2006 Keywords: House building, standardized house types, customization, consumer choice, planning and building regulations, X-DOI: 10.1080/01446190500204754 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500204754 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:2:p:149-158 Template-Type: ReDIF-Article 1.0 Author-Name: Hong Zhang Author-X-Name-First: Hong Author-X-Name-Last: Zhang Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Title: Heuristic scheduling of resource-constrained, multiple-mode and repetitive projects Abstract: An alternative heuristic method for scheduling repetitive projects in which resources are limited and activities may be executed with multiple modes of resource demands associated with different durations is proposed. Unlike general heuristic methods that separately analyze each competing activity and schedule only one at a time, the proposed heuristic algorithm ranks possible combinations of activities every time and simultaneously schedules all activities in the selected combination leading to minimal project duration. All alternative combinations of activities in consideration of resource constraints, multiple modes and characteristics of the repetitive projects are determined through a permutation tree-based procedure. The heuristic method is implemented based on the corresponding framework. An example is presented to demonstrate the efficiency of the proposed heuristic method. The study is expected to provide an efficient heuristic methodology for solving the project scheduling problem. Journal: Construction Management and Economics Pages: 159-169 Issue: 2 Volume: 24 Year: 2006 Keywords: Scheduling, heuristic algorithm, repetitive projects, resource-constraints, multiple modes, a combination of activities, X-DOI: 10.1080/01446190500184311 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500184311 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:2:p:159-169 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Chang Author-X-Name-First: Andrew Author-X-Name-Last: Chang Author-Name: Chih-Chiang Tien Author-X-Name-First: Chih-Chiang Author-X-Name-Last: Tien Title: Quantifying uncertainty and equivocality in engineering projects Abstract: Engineering work is intangible and difficult to measure and manage. Engineering project tasks entail various degrees of uncertainty and equivocality (U&E). Quantifying U&E of project tasks helps understand and manage engineering work. This study developed an assessing questionnaire from five sources of U&E and tested it on a large subway design project. Questions were answered by nine discipline managers of 58 tasks and the quantified U&E scores reflect reality. It was found that uncertainty is higher than equivocality for most tasks. The U&E reduction test shows that task U&E decrease over one year and different reduction patterns exist. Task-possessed information contributes the largest decrease. This means information from planning, past projects or experiences is very important to performing new projects. The developed questionnaire can be a useful tool to help managers better understand and plan project tasks. Journal: Construction Management and Economics Pages: 171-184 Issue: 2 Volume: 24 Year: 2006 Keywords: Case study, information processing, organizational theory, project management, uncertainty, X-DOI: 10.1080/01446190500310353 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500310353 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:2:p:171-184 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Valerie Francis Author-X-Name-First: Valerie Author-X-Name-Last: Francis Title: Does a supportive work environment moderate the relationship between work-family conflict and burnout among construction professionals? Abstract: Research findings concerning the extent to which various forms of support in the workplace moderate the stressor-strain relationship are inconsistent. The effect of perceived organizational support (POS) and support from supervisors and co-workers in the relationship between work-family conflict (WFC) and burnout was examined in a sample of 202 construction professionals and managers. The results revealed that POS has a main effect on burnout and also moderates the relationship between WFC and burnout. The effect of social support did not differ according to its source. Effects for supervisory and co-worker support were similar. However, different effects were found for different types of support. Emotional support had a main effect on burnout but not a moderating effect in the WFC-burnout relationship. Practical support had a moderating effect, but not a main effect on burnout. The importance of supportive work environments to the success of interventions designed to alleviate or prevent employee burnout is discussed. Journal: Construction Management and Economics Pages: 185-196 Issue: 2 Volume: 24 Year: 2006 Keywords: Work-family conflict, burnout, social support, co-workers, supervisors, perceived organizational support, X-DOI: 10.1080/14697010500226913 File-URL: http://www.tandfonline.com/doi/abs/10.1080/14697010500226913 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:2:p:185-196 Template-Type: ReDIF-Article 1.0 Author-Name: M. Muya Author-X-Name-First: M. Author-X-Name-Last: Muya Author-Name: A. D. F. Price Author-X-Name-First: A. D. F. Author-X-Name-Last: Price Author-Name: F. T. Edum-Fotwe Author-X-Name-First: F. T. Author-X-Name-Last: Edum-Fotwe Title: Overview of funding for construction craft skills training in Sub-Saharan Africa: a case study of Zambia Abstract: The wealth of any nation is ultimately based on its human resource or social capital. Education and training are the primary vehicles of developing this resource. Funding of formal construction craft skills training at trade institutions in Sub-Saharan Africa (SSA) is examined, using Zambia as a country case study. The data in the research were collected via semi-structured questionnaire interviews directed at government financed trades training schools offering construction programmes in Zambia. Results of the research show that formal construction craft skills training in Zambia has not been adequately funded over the years resulting in: ill-qualified low numbers of poorly remunerated teaching staff; poorly maintained infrastructure and workshop facilities not well equipped for teaching purposes; and out-dated curricula of construction craft programmes. A wide range of measures is required to improve funding for construction craft skills training. These include: increased training regulation and co-ordination by government, development of efficient and effective funding mechanisms that involve employers of crafts-persons, and training provision frameworks that encourage increased involvement of private training providers. Journal: Construction Management and Economics Pages: 197-208 Issue: 2 Volume: 24 Year: 2006 Keywords: Construction craft skills, training, Sub-Saharan Africa, Zambia, X-DOI: 10.1080/01446190500310585 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500310585 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:2:p:197-208 Template-Type: ReDIF-Article 1.0 Author-Name: David Edwards Author-X-Name-First: David Author-X-Name-Last: Edwards Author-Name: Gary Holt Author-X-Name-First: Gary Author-X-Name-Last: Holt Title: Hand-arm vibration exposure from construction tools: results of a field study Abstract: By the nature of its activities, construction poses a significant risk from hand-arm vibration (HAV). The Control of Vibration at Work Regulations place a duty upon employers to limit HAV exposure, which can entail risk assessment of hand-held tools (by using vibration magnitude data). A field study recorded vibration measurements from a range of hand-held construction tools, so that the 'characteristics' of their vibration data could be explored. Substantial variance among vibration data are confirmed resulting from: method of vibration measurement; tool manufacturing tolerances; sharpness of tools' cutting edges; and differing operator techniques. Results of these measurements and analyses provide guidance for construction managers for performing HAV risk assessments. This includes preference for 'real' data over those from controlled conditions, and the need to recognize potential data variance when calculating operators' maximum exposure times. Journal: Construction Management and Economics Pages: 209-217 Issue: 2 Volume: 24 Year: 2006 Keywords: Hand-arm vibration, hand tools, vibration, health and safety, site operatives, X-DOI: 10.1080/01446190500310643 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500310643 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:2:p:209-217 Template-Type: ReDIF-Article 1.0 Author-Name: Farzad Khosrowshahi Author-X-Name-First: Farzad Author-X-Name-Last: Khosrowshahi Title: Professor Rodney Howes, 1943-2005 Abstract: Journal: Construction Management and Economics Pages: 227-228 Issue: 3 Volume: 24 Year: 2006 X-DOI: 10.1080/01446190500466601 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500466601 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:3:p:227-228 Template-Type: ReDIF-Article 1.0 Author-Name: Chen-Yu Chang Author-X-Name-First: Chen-Yu Author-X-Name-Last: Chang Title: The determinants of the vertical boundaries of the construction firm: comment Abstract: In recent years, the study of organizational issues has made a tremendous progress owing to the development of two powerful analytical theories - transaction cost economics (TCE) and the resource-based view (RBV). Both approaches have their strengths and limitations and thus researchers might think that synthesizing would be a way forward, Bridge and Tisdell (2004) being a case. In synthesizing TCE and RBV, several problems need to be overcome. First, there is a fundamental disparity in the basic assumption of rationality adopted by transaction cost economics (TCE) and. second, even after being operationalized for discovering the key determinants of the concept of competence, it still cannot escape the charge of tautology. Last, the inclusion of competence/resource and TCE-related variables may increase predictive power, but the potentially high correlation between asset specificity and rarity, as well as costliness to imitate, are likely to cause the multicollinearity problem that may reduce the reliability of estimators and hence disguise the true effect of each variable on construction contracting. Even if the critiques of tautology and multicollinearity can be technically overcome, ontological tension will remain. Journal: Construction Management and Economics Pages: 229-232 Issue: 3 Volume: 24 Year: 2006 Keywords: Subcontracting, transaction cost, competence-based approach, X-DOI: 10.1080/01446190500516579 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500516579 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:3:p:229-232 Template-Type: ReDIF-Article 1.0 Author-Name: Adrian Bridge Author-X-Name-First: Adrian Author-X-Name-Last: Bridge Author-Name: Clem Tisdell Author-X-Name-First: Clem Author-X-Name-Last: Tisdell Title: The determinants of the vertical boundaries of the construction firm: response Abstract: Chang seems to suggest that developing closer relations between Transaction Cost Economics (TCE) and the Resource-Based View (RBV) is not yet needed. However, we are unmoved in our belief that this development is compelling and remain committed to our approach to pluralism. We disagree with Chang's critiques of our approach. We clarify that a synthesis of TCE and RBV along the lines of theoretical monism is not attempted. On this basis, two of the three questions raised, labelled 'ontological dissonance' and 'variable multicollinearity', are not applicable. With regard to the other question that relates to refutability, Barney has shown that the variables are refutable and Barney also makes reference to empirical work pertaining to RBV. We agree with Chang that TCE is weak on differential production and believe that an acceptance of the coexistence of TCE and RBV is likely to make both theories more successful on the issue of vertical integration. In the end, pluralism appeals as much to us as it does to the chief proponents of TCE and RBV, as a means of making progress in the near term. Journal: Construction Management and Economics Pages: 233-236 Issue: 3 Volume: 24 Year: 2006 Keywords: Construction firm, vertical boundaries, transaction costs, capability, competence, X-DOI: 10.1080/01446190600604895 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600604895 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:3:p:233-236 Template-Type: ReDIF-Article 1.0 Author-Name: A. D. F. Price Author-X-Name-First: A. D. F. Author-X-Name-Last: Price Author-Name: K. Chahal Author-X-Name-First: K. Author-X-Name-Last: Chahal Title: A strategic framework for change management Abstract: Many organizations have undergone substantial change over recent years and the importance of organizational culture to organizational analysis and change management has been increasingly recognized. However, the implementation of change is a complex process that is not always successful due to a variety of reasons. Failure in most change processes can be traced back to poor communications and underestimation of the amount of retraining required. The main aim of this research is to identify the key steps that could improve the management of change. Literature relating to organizational culture, the need for change, types of change and resistance to change was used to develop a theoretical basis for the research. Organizational change management case studies and exploratory interviews were used to document experiences of organizational change and develop a strategic framework for change management. Validation was through acceptance and adoption of the developed process within a construction-based organization. The research has demonstrated how well-planned change helps to ensure that change is successfully implemented. Critical to successful change is not only the development of more efficient and effective processes but alignment of organizational culture to support these new processes. Journal: Construction Management and Economics Pages: 237-251 Issue: 3 Volume: 24 Year: 2006 Keywords: Change, culture, strategy, framework, organization, X-DOI: 10.1080/01446190500227011 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500227011 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:3:p:237-251 Template-Type: ReDIF-Article 1.0 Author-Name: D. R. Ogunsemi Author-X-Name-First: D. R. Author-X-Name-Last: Ogunsemi Author-Name: G. O. Jagboro Author-X-Name-First: G. O. Author-X-Name-Last: Jagboro Title: Time-cost model for building projects in Nigeria Abstract: The concept of project duration is important in assessing the success or viability of a construction project. A time-cost relationship for construction projects in Nigeria has been developed based on Bromilow's time-cost model. Cost data on 87 completed building projects executed within the period 1991-2000 were obtained. The data were subjected to regression analyses using double log and later the piecewise model with breakpoint. For the Nigerian situation, the Bromilow's time-cost model was found to be T = 63C0.262 with poor predictive abilities (R = 0.453, R2 = 0.205). An improved model using piecewise model with good predictive abilities (R = 0.875, R2 = 0.765) was found to be T = 118.563-0.401C (C ≤ 408) or 603.427 + 0.610C (C>408). The model is shown to be useful in predicting construction project durations. Journal: Construction Management and Economics Pages: 253-258 Issue: 3 Volume: 24 Year: 2006 Keywords: Project management, cost, time, cost modelling, Nigeria, X-DOI: 10.1080/01446190500521041 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500521041 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:3:p:253-258 Template-Type: ReDIF-Article 1.0 Author-Name: Wen-Der Yu Author-X-Name-First: Wen-Der Author-X-Name-Last: Yu Title: PIREM: a new model for conceptual cost estimation Abstract: A new conceptual construction cost estimating method, namely, Principal Item Ratios Estimating Method (PIREM), is presented. The proposed PIREM integrates several existing conceptual estimating methods (including parametric estimating, ratios estimating, and cost significant model) with advanced nonlinear mapping techniques, and adopts a scheme that separates unit prices with the quantities of a cost item. It allows estimators to estimate based on the prevailing unit prices in the marketplace, thus the fluctuation of prices can be reflected on a real-time basis. Two comprehensive case studies were conducted for verification of PIREM. The demonstration case studies show that PIREM is able to provide accurate and the most updated estimates when advanced mapping technologies are incorporated. Journal: Construction Management and Economics Pages: 259-270 Issue: 3 Volume: 24 Year: 2006 Keywords: Conceptual cost estimation, parametric estimation, project planning, nonlinear mapping, X-DOI: 10.1080/01446190500183735 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500183735 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:3:p:259-270 Template-Type: ReDIF-Article 1.0 Author-Name: T. A. El-Diraby Author-X-Name-First: T. A. Author-X-Name-Last: El-Diraby Author-Name: S. M. Gill Author-X-Name-First: S. M. Author-X-Name-Last: Gill Title: A taxonomy for construction terms in privatized-infrastructure finance: supporting semantic exchange of project risk information Abstract: There is an increasing need for effective flow of information between the various participants in privatized infrastructure projects particularly between construction companies and financial institutions. A taxonomy is developed for relevant concepts in the domain of privatized-infrastructure finance. The taxonomy is an attempt to create information interoperability between the construction and financial industries. The taxonomy models the concepts of a privatized-infrastructure finance into six main domains: processes, products, projects, actors, resources and technical topics (technical details and basic concepts). The taxonomy was designed to be consistent with Open Financial Exchange (OFX). It was developed through the analysis of 10 case studies and involvement in project development and interaction with industry experts. The taxonomy was validated through interviews with domain experts, and through the analysis of two independent case studies. A prototypical semantic web-based portal for communicating project risks was developed to in order to illustrate the use of the taxonomy. Project partners are able to post and view risk items and their status in this portal, observe who is handling them, be aware of what decisions have been made to manage them and what lessons learned are available to address these risks. Journal: Construction Management and Economics Pages: 271-285 Issue: 3 Volume: 24 Year: 2006 Keywords: Privatized infrastructure, project finance, semantic web, X-DOI: 10.1080/01446190500434971 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500434971 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:3:p:271-285 Template-Type: ReDIF-Article 1.0 Author-Name: Vivian Tam Author-X-Name-First: Vivian Author-X-Name-Last: Tam Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Author-Name: L. Y. Shen Author-X-Name-First: L. Y. Author-X-Name-Last: Shen Author-Name: S. X. Zeng Author-X-Name-First: S. X. Author-X-Name-Last: Zeng Author-Name: C. M. Ho Author-X-Name-First: C. M. Author-X-Name-Last: Ho Title: Environmental performance assessment: perceptions of project managers on the relationship between operational and environmental performance indicators Abstract: There is a growing concern about environmental impacts resulting from construction activities. To help minimize the environmental impacts from construction, Environmental Management Systems (EMSs) have been advocated and in some cases, implemented. Within the construction industry, Environmental Performance Assessment (EPA) forms one of the most important tools in monitoring and evaluating environmental performance. However, the relations between Environmental Operational Indicators (EOIs) (inputs) used in EPA and Environmental Performance Indicators (EPIs) (outputs) have not been tested and correlated, casting doubt on the reliability of these inputs. This paper attempts to develop a series of input (EOI) and output (EPI) indicators for EPA and measure their relations based on the perceptions of project managers. The results show that EOIs defined correlate strongly with EPIs. Therefore, EPA can help to identify areas for continuous improvement, and also provide an early indication of the environmental performance for an organization. Journal: Construction Management and Economics Pages: 287-299 Issue: 3 Volume: 24 Year: 2006 Keywords: Environmental management system, environmental performance assessment, operational levels, Hong Kong, X-DOI: 10.1080/01446190500372197 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500372197 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:3:p:287-299 Template-Type: ReDIF-Article 1.0 Author-Name: Roine Leiringer Author-X-Name-First: Roine Author-X-Name-Last: Leiringer Title: Technological innovation in PPPs: incentives, opportunities and actions Abstract: From a construction perspective, Public-Private Partnership projects (PPPs) are often credited as providing real incentives for the actors involved as well as a business environment that is conducive to innovation and improved practices. The validity of four common rhetorical arguments used to promote the PPP procurement route is explored: collaborative working, design freedom, long-term commitment and risk transfer. Particular interest is given to the extent to which espoused intentions correlate with experienced realities in allowing actors involved in the design and construction phases to be presented with, and able to exploit, opportunities for technological innovation. It is argued that there is reason to be cautious in fully accepting the purported benefits of the PPP framework and that the arguments often presented need to be revised. Alternative interpretations are provided. Journal: Construction Management and Economics Pages: 301-308 Issue: 3 Volume: 24 Year: 2006 Keywords: Public-private partnership, technological innovation, risk transfer, collaborative working, design freedom, long term commitment, X-DOI: 10.1080/01446190500435028 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500435028 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:3:p:301-308 Template-Type: ReDIF-Article 1.0 Author-Name: Florence Phua Author-X-Name-First: Florence Author-X-Name-Last: Phua Title: Predicting construction firm performance: an empirical assessment of the differential impact between industry- and firm-specific factors Abstract: It is obvious that the performance of firms hinges upon the dynamics of both industry- and firm-specific factors. A less obvious, and perhaps a more important, line of inquiry is that to the extent that they have a bearing on firm performance, how much do these two groups of factors respectively predict firm performance? To date, performance differences among construction firms that stem from industry- and firm-specific differential effect has remained largely unexplored. Using a dataset comprising 526 firms across various construction-related sectors, the sector-by-sector firm performance variation that is attributable to the heterogeneity of both industry- and firm-specific characteristics was empirically examined. That statistically significant results of different effect sizes are found indicates that although these factors are often assumed to be intertwined it is possible to study their respective impact on firm performance. Future studies could usefully replicate and extend this study to construction firms in other countries to further investigate what drives firm performance under different national, industry and firm contexts. Journal: Construction Management and Economics Pages: 309-320 Issue: 3 Volume: 24 Year: 2006 Keywords: Firm performance, performance heterogeneity, industry-specific factors, firm-specific factors, institutional environment, resource-based view, X-DOI: 10.1080/01446190500435127 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500435127 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:3:p:309-320 Template-Type: ReDIF-Article 1.0 Author-Name: Vachara Peansupap Author-X-Name-First: Vachara Author-X-Name-Last: Peansupap Author-Name: Derek Walker Author-X-Name-First: Derek Author-X-Name-Last: Walker Title: Innovation diffusion at the implementation stage of a construction project: a case study of information communication technology Abstract: Interest in construction industry (CI) innovation, particularly in information communication technology (ICT), has been steadily growing with the advent and widespread use of the Internet. However, despite its potential for delivering competitive advantage, many companies have failed to effectively realize promised benefits from ICT due to misunderstanding the relationship between factors and processes influencing ICT implementation. Results from recent in-depth qualitative ICT implementation research on three construction contractors provides useful insights and practical experience of lessons learned that can be more broadly disseminated. These research results provide an ICT innovation diffusion organizational level framework with insights about how it may be applied to improve ICT adoption at different implementation stages for the CI. They suggest that strategic ICT implementation planning needs to consider issues of critical management support, technical support, supportive workplace environment and ICT users' individual-characteristics so that the framework processes offered can be effectively applied. Journal: Construction Management and Economics Pages: 321-332 Issue: 3 Volume: 24 Year: 2006 Keywords: Innovation diffusion, IT implementation, technology management, X-DOI: 10.1080/01446190500435317 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500435317 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:3:p:321-332 Template-Type: ReDIF-Article 1.0 Author-Name: Rodney Stewart Author-X-Name-First: Rodney Author-X-Name-Last: Stewart Author-Name: Clinton Spencer Author-X-Name-First: Clinton Author-X-Name-Last: Spencer Title: Six-sigma as a strategy for process improvement on construction projects: a case study Abstract: Significant expenditures of time, money and resources, both human and material, are wasted each year as a result of inefficient or non-existent quality management procedures. In an attempt to improve their market competitiveness, by limiting the extent of non-value-adding activities, some organizations are beginning to monitor the performance of internal and external engineering and construction processes. To achieve these bold aims, these organizations are looking to other industries such as manufacturing to examine the effectiveness of measuring and monitoring tools such as six-sigma. Only in recent years has the six-sigma method been utilized by some of the major players in the construction sector. To familiarize both researchers and practitioners on how to implement the six-sigma method and its potential benefits, the paper describes the outcomes of a six-sigma process improvement project (PIP) conducted for the construction of concrete longitudinal beams on the St Pancras raised railway station in London, UK. The outcome of the six-sigma PIP was the improved productivity of beam construction, enhanced interaction between project teams and reduced project delays. Moreover, interviews with key project participants were conducted to determine the success factors, barriers, suitability and advantages of the six-sigma approach compared with other TQM techniqes. In summary, the six-sigma approach provided the PIP team with a structured process improvement strategy to reduce waste and other non-value adding activities from the construction process. Journal: Construction Management and Economics Pages: 339-348 Issue: 4 Volume: 24 Year: 2006 Keywords: Six-sigma, process improvement, total quality management, X-DOI: 10.1080/01446190500521082 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500521082 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:4:p:339-348 Template-Type: ReDIF-Article 1.0 Author-Name: C. M. Tang Author-X-Name-First: C. M. Author-X-Name-Last: Tang Author-Name: C. W. Y. Wong Author-X-Name-First: C. W. Y. Author-X-Name-Last: Wong Author-Name: A. Y. T. Leung Author-X-Name-First: A. Y. T. Author-X-Name-Last: Leung Author-Name: K. C. Lam Author-X-Name-First: K. C. Author-X-Name-Last: Lam Title: Selection of funding schemes by a borrowing decision model: a Hong Kong case study Abstract: In financial decision-making, a number of mathematical models have been developed for financial management in construction. However, optimizing both qualitative and quantitative factors and the semi-structured nature of construction finance optimization problems are key challenges in solving construction finance decisions. The selection of funding schemes by a modified construction loan acquisition model is solved by an adaptive genetic algorithm (AGA) approach. The basic objectives of the model are to optimize the loan and to minimize the interest payments for all projects. Multiple projects being undertaken by a medium-size construction firm in Hong Kong were used as a real case study to demonstrate the application of the model to the borrowing decision problems. A compromise monthly borrowing schedule was finally achieved. The results indicate that Small and Medium Enterprise (SME) Loan Guarantee Scheme (SGS) was first identified as the source of external financing. Selection of sources of funding can then be made to avoid the possibility of financial problems in the firm by classifying qualitative factors into external, interactive and internal types and taking additional qualitative factors including sovereignty, credit ability and networking into consideration. Thus a more accurate, objective and reliable borrowing decision can be provided for the decision-maker to analyse the financial options. Journal: Construction Management and Economics Pages: 349-365 Issue: 4 Volume: 24 Year: 2006 Keywords: Construction firm, genetic algorithm, loan and finance, optimization, X-DOI: 10.1080/01446190500434906 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500434906 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:4:p:349-365 Template-Type: ReDIF-Article 1.0 Author-Name: Cassidy Johnson Author-X-Name-First: Cassidy Author-X-Name-Last: Johnson Author-Name: Gonzalo Lizarralde Author-X-Name-First: Gonzalo Author-X-Name-Last: Lizarralde Author-Name: Colin Davidson Author-X-Name-First: Colin Author-X-Name-Last: Davidson Title: A systems view of temporary housing projects in post-disaster reconstruction Abstract: Natural cataclysms (earthquakes, hurricanes and so forth) become natural disasters when they coincide with vulnerabilities; unfortunately, informal settlements in developing countries are only too often highly vulnerable - a reality amply and unhappily confirmed by available statistics. In this context, reconstruction projects are sandwiched between the short-term necessity to act promptly and the long-term requirements of sustainable community development - a situation that is currently reflected in alternative and conflicting paradigms at the policy level. Adopting a case-study approach, we explore the use of temporary housing within two post-disaster environments, where the impact of different organizational designs leads to fundamentally different solutions to the short-term housing problem. Our research adopts a dynamic systems approach, associating strategic organizational team design with the development of tactical technical proposals. Two case studies from Turkey and Colombia show that a coherent approach to the sequential stages of providing immediate shelter, temporary housing and permanent reconstruction is not always obtained. The research results emphasize that the performance of reconstruction projects is directly linked to the design and management of the project team. Journal: Construction Management and Economics Pages: 367-378 Issue: 4 Volume: 24 Year: 2006 Keywords: Natural disasters, organizational design, post-disaster reconstruction, systems approach, temporary housing, X-DOI: 10.1080/01446190600567977 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600567977 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:4:p:367-378 Template-Type: ReDIF-Article 1.0 Author-Name: Yu-Lin Huang Author-X-Name-First: Yu-Lin Author-X-Name-Last: Huang Author-Name: Shih-Pei Chou Author-X-Name-First: Shih-Pei Author-X-Name-Last: Chou Title: Valuation of the minimum revenue guarantee and the option to abandon in BOT infrastructure projects Abstract: The real option approach is used to value the minimum revenue guarantee (MRG) and the option to abandon in Build-Operate-Transfer infrastructure projects. The option to abandon is formulated under an investment option held by the concessionaire at contract signing and to expire before construction commencement. MRG is formulated as a series of European style put options in a single option pricing model. When combined with the option to abandon in the pre-construction phase, MRG is reconstructed as a series of European style call options to develop a compound option pricing formula. The Taiwan High-Speed Rail Project is chosen as a numerical case to apply the formulas. The results show both MRG and the option to abandon can create values. When MRG and the option to abandon are combined, they will counteract each other and their values will thus be reduced. Increasing the MRG level will decrease the value of the option to abandon, and, at a certain MRG level, the option to abandon will be rendered worthless. Journal: Construction Management and Economics Pages: 379-389 Issue: 4 Volume: 24 Year: 2006 Keywords: BOT, infrastructure, real option, option to abandon, minimum revenue guarantee, X-DOI: 10.1080/01446190500434997 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500434997 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:4:p:379-389 Template-Type: ReDIF-Article 1.0 Author-Name: Franco Cheung Author-X-Name-First: Franco Author-X-Name-Last: Cheung Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: A modified storey enclosure model Abstract: James' Storey Enclosure Method (JSEM), developed in 1954, is considered by many to be the most sophisticated single-rate method ever devised for early-design-stage tender price forecasts. However, the method is seldom used in practice partly because it has been superseded by multi-rate methods (such as the elemental method) and partly due to the arbitrary nature of the weightings prescribed for its use. The approach has been further developed and empirical values of the weightings are derived by multivariate regression analysis. A set of 50 completed Hong Kong private housing projects is used to demonstrate the use of the technique. This involves, firstly, the modification of the variables used in the original JSEM to incorporate the special characteristics of Hong Kong multi-storey residential buildings. This results in what is termed here as a Modified James' Storey Enclosure Model (MJSEM). Next, the optimal number of variables for inclusion in the model is identified by means of a dual stepwise cross validation regression procedure - resulting in a Regressed Modified Model for James' Storey Enclosure Method (RMJSEM). In addition, using an amended version of MJSEM, the dual stepwise cross validation regression is used to produce a Regressed Modified Model for Amended Storey Enclosure Method (RMASEM). The forecasting accuracy of RMJSEM and RMASEM is then compared with that of MJSEM together with the floor area and cube method to provide an indication of the improvement achieved. It is shown that the RMASEM provides significantly more consistent forecasts than the MJSEM and floor area models, leading to the conclusion that RMASEM may be the best model. Journal: Construction Management and Economics Pages: 391-405 Issue: 4 Volume: 24 Year: 2006 Keywords: Forecasts, cost model, regression, cross validation, X-DOI: 10.1080/01446190500435093 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500435093 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:4:p:391-405 Template-Type: ReDIF-Article 1.0 Author-Name: A. V. Thomas Author-X-Name-First: A. V. Author-X-Name-Last: Thomas Author-Name: Satyanarayana Kalidindi Author-X-Name-First: Satyanarayana Author-X-Name-Last: Kalidindi Author-Name: L. S. Ganesh Author-X-Name-First: L. S. Author-X-Name-Last: Ganesh Title: Modelling and assessment of critical risks in BOT road projects Abstract: Over the years, many private sector participation (PSP) models have been evolved for infrastructure procurement and the Build-Operate-Transfer (BOT) model is one of the most common approaches used for the same. Private infrastructure projects under BOT arrangement have a complex risk profile and to a considerable extent, the success of any BOT project is influenced by the degree to which various project risks are managed. The major steps involved in risk management of a project are risk identification, risk assessment and the processes of prioritization and response to the risks. The conventional risk assessment approaches may not be effective in privatized infrastructure projects because of the fact that, they have very long project lifecycle with many country and sector specific risk factors. The assessment of complex risks is often a difficult task when past data on similar risks are not available. In this research, a risk probability and impact assessment framework based on fuzzy-fault tree and the Delphi method is proposed. The framework includes extensive scenario modelling of critical risks in projects and systematic processing of professional judgement (subjective knowledge) of experts and is developed and demonstrated in the context of critical risks in Indian BOT road projects. Detailed scenario modelling of most critical risks such as traffic revenue risk, delay in land acquisition, demand risk and delay in financial closure are also presented. The proposed risk assessment framework is generic and can be applied with appropriate modifications to suit any complex developmental project where past data is inadequate for risk assessment. Journal: Construction Management and Economics Pages: 407-424 Issue: 4 Volume: 24 Year: 2006 Keywords: BOT projects, risk modelling, risk assessment, fuzzy sets, possibility distribution, X-DOI: 10.1080/01446190500435275 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500435275 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:4:p:407-424 Template-Type: ReDIF-Article 1.0 Author-Name: Joe Wong Author-X-Name-First: Joe Author-X-Name-Last: Wong Author-Name: Eddie Hui Author-X-Name-First: Eddie Author-X-Name-Last: Hui Title: Construction project risks: further considerations for constructors' pricing in Hong Kong Abstract: Construction project risks affect contractors' tender price. A host of factors influencing tender prices were identified and the importance of these factors evaluated by making use of the data collected in a postal questionnaire survey conducted to the 'Buildings' contractors in Hong Kong. Out of 60 factors identified, the availability of required cash, uncertainty in costs estimates, urgent need for work, past experience in similar projects and contract size are considered most important. The need for work and the amount of experience are similar to those factors affecting bidding decisions of top UK contractors. The findings suggest that in the upward adjustment of tender prices, the large-size contractors are more concerned with the uncertainty in costs estimates while the medium- and small-size contractors care more about no past experience. In the downward adjustment of prices, the large size of the contract is the main factor affecting the pricing of the large- and medium-size contractors while the urgent need for work is the main drive for the small-size ones. There are significant differences between the contractors' perceptions of the importance of the risk factors. This is consistent with differing attitudes towards bid mark-up decisions of the large- and medium-size contractors in Singapore. Journal: Construction Management and Economics Pages: 425-438 Issue: 4 Volume: 24 Year: 2006 Keywords: Construction project risks, importance indices, bidding, mark-up, Hong Kong, X-DOI: 10.1080/01446190600601602 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600601602 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:4:p:425-438 Template-Type: ReDIF-Article 1.0 Author-Name: Rick Best Author-X-Name-First: Rick Author-X-Name-Last: Best Author-Name: Craig Langston Author-X-Name-First: Craig Author-X-Name-Last: Langston Title: Evaluation of construction contractor performance: a critical analysis of some recent research Abstract: International comparisons of construction industry performance are notoriously difficult. A recent comparative study, extensive in scope and using an innovative approach, is reviewed and questions raised regarding various aspects of the methodology adopted, the validity of the conclusions drawn and manner in which outcomes were reported. Particular areas of concern include the unequivocal statement of conclusions that are based on a small sample, and the use of data from that sample that are, in fact, no more than estimates of project performance. Attention is drawn to the limitations of the research reported and the reliability of the methods used, and the data gathered is examined. Journal: Construction Management and Economics Pages: 439-445 Issue: 4 Volume: 24 Year: 2006 Keywords: International construction, industry comparisons, purchasing power parity, construction research, X-DOI: 10.1080/01446190500435457 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500435457 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:4:p:439-445 Template-Type: ReDIF-Article 1.0 Author-Name: Raymond Levitt Author-X-Name-First: Raymond Author-X-Name-Last: Levitt Title: Boyd C. Paulson, Jr died on 1 December 2005, in Menlo Park, California Abstract: Journal: Construction Management and Economics Pages: 453-455 Issue: 5 Volume: 24 Year: 2006 X-DOI: 10.1080/01446190600602931 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600602931 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:5:p:453-455 Template-Type: ReDIF-Article 1.0 Author-Name: Valerie Caven Author-X-Name-First: Valerie Author-X-Name-Last: Caven Title: Career building: women and non-standard employment in architecture Abstract: Non-standard working arrangements are traditionally associated with insecure employment and thus said to act as a constraint on women architects' careers. The working patterns of 37 women architects have been examined using a career life history approach and findings indicate that to follow non-standard working patterns in professional employment need not necessarily serve to constrain and may even enhance women's career development. Many of the women architects following non-standard forms of employment find that it has been beneficial to their career. The recurring theme from these interviews was the need to be able to follow a career but on certain terms. The time commitment required prior to qualification provides a strong motivation to continue working throughout their working lives. Journal: Construction Management and Economics Pages: 457-464 Issue: 5 Volume: 24 Year: 2006 Keywords: Women, architecture, career, X-DOI: 10.1080/01446190600601354 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600601354 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:5:p:457-464 Template-Type: ReDIF-Article 1.0 Author-Name: Ramesh Ramsaran Author-X-Name-First: Ramesh Author-X-Name-Last: Ramsaran Author-Name: Roger Hosein Author-X-Name-First: Roger Author-X-Name-Last: Hosein Title: Growth, employment and the construction industry in Trinidad and Tobago Abstract: Trinidad and Tobago is a small open oil- and gas-based economy that has experienced the effects of boom and bust and the associated fluctuations in income and employment. This paper focuses on the behaviour of the construction sector and its relationship to income and employment over the last three decades in this small oil-rich economy. In the boom period the construction sector grew twice as fast as the rest of the economy. Similarly, during the recession the construction sector contracted faster than any other sector, providing proof that the multiplier operates in both directions. The correlation coefficient between construction labour productivity and per capita GDP for the period 1973-2002 was 0.70. As pertains to employment in construction per thousand population and per capita GDP, the correlation coefficient was 0.94. Journal: Construction Management and Economics Pages: 465-474 Issue: 5 Volume: 24 Year: 2006 Keywords: Construction, employment, correlation, X-DOI: 10.1080/01446190500521157 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500521157 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:5:p:465-474 Template-Type: ReDIF-Article 1.0 Author-Name: C. Y. Yiu Author-X-Name-First: C. Y. Author-X-Name-Last: Yiu Author-Name: C. S. Tam Author-X-Name-First: C. S. Author-X-Name-Last: Tam Title: Rational under-pricing in bidding strategy: a real options model Abstract: Under-pricing in construction tenders is a common phenomenon and is commonly explained by the need of cash flows and penetration strategy. However, these explanations involve profit cutting and therefore are not plausible in explaining a long-term persistent phenomenon of under-pricing. A real options model is proposed and using the binomial lattice method a real-life construction project tender was analysed to examine how management flexibility and uncertainty provide real options value. When uncertainties of cost items in a tender exist and choices are available to defer and switch modes of construction, then a valuable option is available to the bidders. It amounts to about 4% of the lump sum tendered in our case. The under-priced portion is the options value which the bidder is willing to pay for the flexibility and the uncertainty. These findings enable contractors to be more competitive and to estimate construction costs more accurately in devising their bid strategies. Journal: Construction Management and Economics Pages: 475-484 Issue: 5 Volume: 24 Year: 2006 Keywords: Real options, pricing, bidding strategy, tendering, X-DOI: 10.1080/01446190600601560 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600601560 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:5:p:475-484 Template-Type: ReDIF-Article 1.0 Author-Name: Serdar Kale Author-X-Name-First: Serdar Author-X-Name-Last: Kale Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Title: Diffusion of ISO 9000 certification in the precast concrete industry Abstract: ISO 9000 is one of the most important administrative innovations of the last two decades. The Turkish precast concrete industry is an interesting example of the diffusion of this important administrative innovation. Innovation diffusion theory proposes that the diffusion of an innovation is driven by internal (i.e. behaviours of copying others) and external (i.e. complying with client requirements, changes in government regulations, demand conditions, and consulting firms' suggestions) influence factors. The propositions of innovation diffusion theory are empirically tested by using three mathematical models: the internal influence model, the external influence model and the mixed influence model. The mixed influence model has the highest explanatory power and the diffusion of ISO 9000 certification in the precast concrete industry is primarily driven by internal rather than external influence factors. Journal: Construction Management and Economics Pages: 485-495 Issue: 5 Volume: 24 Year: 2006 Keywords: Innovation diffusion, quality control, quality assurance, ISO 9000 series, precast concrete industry, X-DOI: 10.1080/01446190600601594 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600601594 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:5:p:485-495 Template-Type: ReDIF-Article 1.0 Author-Name: Anita Liu Author-X-Name-First: Anita Author-X-Name-Last: Liu Author-Name: Zhaoyang Fang Author-X-Name-First: Zhaoyang Author-X-Name-Last: Fang Title: A power-based leadership approach to project management Abstract: The concept of leadership relates to power structuring whereby the project leader may lead and motivate through power disposition. Power, in its diverse guises, combines interpersonal and structural elements and can be enhanced through political manoeuvring. Power may also be distributed unevenly between individuals in the project team. In this article a power-based model of project leadership is developed, underpinned by a behaviour-performance-outcome approach and an appropriate methodology is developed for testing the construction enterprises in China using structural equations modelling. The fitness indices show that the resulting model which postulates that the motivational function of good leadership operates through managing power gaps by means of power-sharing and power-amassing is acceptable. The effects (both predominant magnitudes and statistical significance) from the project managers' referent power to power-sharing and power-amassing show that the project manager's inherent personal traits and credentials are critical to his/her power exercising so as to motivate members to secure management effectiveness. Journal: Construction Management and Economics Pages: 497-507 Issue: 5 Volume: 24 Year: 2006 Keywords: Managerial behaviours, motivation, power, project leadership, X-DOI: 10.1080/01446190600567944 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600567944 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:5:p:497-507 Template-Type: ReDIF-Article 1.0 Author-Name: Dansong Wang Author-X-Name-First: Dansong Author-X-Name-Last: Wang Author-Name: Ahmad Hadavi Author-X-Name-First: Ahmad Author-X-Name-Last: Hadavi Author-Name: Raymond Krizek Author-X-Name-First: Raymond Author-X-Name-Last: Krizek Title: Chinese construction firms in reform Abstract: Since the economic reforms that began 20 years ago, and especially with the enterprise reforms in recent years, ownership of Chinese construction firms has evolved from traditional state and collective ownership towards a mixed economy characterised by diversified ownership forms. Based on a questionnaire survey and personal interviews with individuals from firms representing four types of ownership, it has been determined that the majority of Chinese construction firms have already embraced commercial objectives and behaviour patterns similar to those of typical firms in developed market economies. Nevertheless, despite the important progress that the reforms have made, this study indicated that various construction firms during this transition are suffering serious difficulties caused by the former planned system and underdeveloped market mechanisms. Unfair practices were found to be quite serious in the construction market. Major problems stem from clients' abnormal behaviour in forcing the price down, asking contractors to finance a project wholly or partially during its construction, and delays in payment; these actions have caused severe financial difficulties to Chinese firms and seriously disrupted the normal order of market stability. Journal: Construction Management and Economics Pages: 509-519 Issue: 5 Volume: 24 Year: 2006 Keywords: China, Chinese construction firms, reform, firm objective, firm behaviour, ownership form, X-DOI: 10.1080/01446190600704810 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600704810 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:5:p:509-519 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Author-Name: Per-Erik Josephson Author-X-Name-First: Per-Erik Author-X-Name-Last: Josephson Title: Revisiting site manager work: stuck in the middle? Abstract: The literature on middle managers tends to portray their role in rather negative terms. Middle managers are here stuck in between superiors and subordinates, with few opportunities for determining their work situation. In the construction industry, site managers play a role similar to that of the middle managers of large companies, located in between the firm's strategic decisions and day-to-day production work on construction sites. The aim of this study is to examine how site managers experience their work situation. Drawing on an interview study encompassing 13 site managers and seven foremen and top managers in 13 construction projects, the research suggests that site managers are generally pleased with their work situation even though they are critical of the demands made of them to handle a variety of heterogeneous activities. However, a work situation fraught with unanticipated challenges and ambiguities easily leads to excessive workloads and long working hours. It is concluded that the literature on middle managers presents too negative an image of middle management and thus needs to revise the assumptions regarding the nature of middle managerial work. In addition, the study also underlines the needs of construction firms to regard their middle managers as a central function and resource. Journal: Construction Management and Economics Pages: 521-528 Issue: 5 Volume: 24 Year: 2006 Keywords: Site managers, construction projects, middle managers, X-DOI: 10.1080/01446190600658743 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600658743 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:5:p:521-528 Template-Type: ReDIF-Article 1.0 Author-Name: G. Zhang Author-X-Name-First: G. Author-X-Name-Last: Zhang Author-Name: J. Yang Author-X-Name-First: J. Author-X-Name-Last: Yang Title: Factors influencing the implementation of the raised floor system in Australian office buildings Abstract: Raised floor systems (RFS) were initially developed for computer room applications. As an alternative for general office space fitout, they have not been widely accepted, particularly in Australia. Despite the potential exhibited, such as improved ventilation and air quality when used with underfloor sub-systems, and the flexibility for office space reconfiguration, RFS implementation had encountered problems, ranging from the excessive costs perceived by owners and developers, to the lack of technical expertise among builders and contractors on the installation of RFS and specialized components. In the research work reported in this article, these problems were identified together with the highlighting of 44 Significant Influence Factors (SIFs). This was achieved through RFS product study, questionnaire survey, interviews and site observations. These SIFs and problems were then amplified in the research by industry focus groups and life cycle cost comparison between RFS and ceiling based fitout methods. The resulting 36 Project Level Critical Factors (PLCFs) pertaining to fitout design, construction, operation and maintenance were then considered in a constructability study, which established an integrated constructability framework for RFS fitout implementation, the most appropriate contracting strategy, and a process-based model for RFS product selection under local conditions. A set of guidelines that recommend main activities and subsidiary tasks through five stages of RFS project implementation was also presented. These findings will contribute to improved awareness, adoption rate and implementation efficiency of RFS fitout in the Australian office building industry. Journal: Construction Management and Economics Pages: 529-543 Issue: 5 Volume: 24 Year: 2006 Keywords: Australia, constructability, fitout, office building, raised floor system, X-DOI: 10.1080/01446190600568025 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600568025 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:5:p:529-543 Template-Type: ReDIF-Article 1.0 Author-Name: Charles Cheah Author-X-Name-First: Charles Author-X-Name-Last: Cheah Author-Name: Jicai Liu Author-X-Name-First: Jicai Author-X-Name-Last: Liu Title: Valuing governmental support in infrastructure projects as real options using Monte Carlo simulation Abstract: In Build-Operate-Transfer (BOT) infrastructure projects, host governments often provide subsidies, guarantees or alternative forms of support as incentives to attract private sector participation. A guaranteed level of minimum revenue, for example, can be specially designed to alleviate the concern of demand risk. Although researchers have generally acknowledged the significance of subsidies and guarantees leading toward successful negotiation, there is a lack of attempt to evaluate these concessions quantitatively. Without a deeper understanding of the value of these concessions, risk and reward may not be equitably matched in the proposed terms and arrangements. In this paper, relevant elements of a contractual package are treated as a form of real options. A proposition is put forward to incorporate the value of such options into the negotiation framework. By relying on simplifying assumptions on risk preferences, these options can be evaluated using Monte Carlo simulation of a discounted cash flow (DCF) model. The methodology is applied to the case of the Malaysia-Singapore Second Crossing, which shows that the value of a guarantee can indeed be significant relative to the basic net present value. The case study also highlights other aspects of flexibility in the design and execution of a project. Journal: Construction Management and Economics Pages: 545-554 Issue: 5 Volume: 24 Year: 2006 Keywords: Build-operate-transfer, concessions, infrastructure projects, negotiation, real option, X-DOI: 10.1080/01446190500435572 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500435572 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:5:p:545-554 Template-Type: ReDIF-Article 1.0 Author-Name: Andreas Hartmann Author-X-Name-First: Andreas Author-X-Name-Last: Hartmann Title: The context of innovation management in construction firms Abstract: Conscious management of innovation in construction firms is becoming more and more a necessity. However, the possibilities and ways to successfully put an innovative idea into practice depend on a range of contingencies. A framework of innovation management was devised to structure the context variables of construction innovation. Furthermore, an analytical approach was developed to enable researchers as well as construction managers to detect those variables which should be considered for managing construction innovation. The application of the approach to the case of a Swiss contractor revealed dependency on client and location, procurement form, innovation acceptance of the client and regulation degree as significant variables of the external environment. Service offer, knowledge strength, cooperative behaviour, financial strength and time needs were identified as critical variables of the internal environment. The implications are that the management of construction firms should advocate innovative ideas explicitly, make conscious strategic decisions about the direction of the firm's innovation activity and provide methodical and hierarchical support during the innovation process. Establishing internal innovation brokers and using portfolio-based project checkpoints are supportive measures in this regard. Journal: Construction Management and Economics Pages: 567-578 Issue: 6 Volume: 24 Year: 2006 Keywords: Innovation management, context variables, construction firm, X-DOI: 10.1080/01446190600790629 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600790629 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:6:p:567-578 Template-Type: ReDIF-Article 1.0 Author-Name: Yu Song Author-X-Name-First: Yu Author-X-Name-Last: Song Author-Name: Chunlu Liu Author-X-Name-First: Chunlu Author-X-Name-Last: Liu Author-Name: Craig Langston Author-X-Name-First: Craig Author-X-Name-Last: Langston Title: Linkage measures of the construction sector using the hypothetical extraction method Abstract: The hypothetical extraction method (HEM) is used to extract a sector hypothetically from an economic system and examine the influence of this extraction on other sectors in the economy. Linkage measures based on the HEM become increasingly prominent. However, little construction linkage research applies the HEM. Using the recently published Organisation for Economic Co-operation and Development input-output database at constant prices, this research applies the HEM to the construction sector in order to explore the role of this sector in national economies and the quantitative interdependence between the construction sector and the remaining sectors. The output differences before and after the hypothetical extraction reflect the linkages of the construction sector. Empirical results show a declining trend of the total, backward and forward linkages, which confirms the decreasing role of the construction sector with economic maturity over the examined period from a new angle. Analytical results reveal that the unique nature of the construction sector and multifold external factors are the main reasons for the linkage difference between countries. Moreover, hypothesis-testing results consider statistically that the extraction structures employed in this research are appropriate to analyse the linkages of the construction sector. Journal: Construction Management and Economics Pages: 579-589 Issue: 6 Volume: 24 Year: 2006 Keywords: Input-output analysis, hypothetical extraction method, construction sector, linkage, X-DOI: 10.1080/01446190500435358 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500435358 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:6:p:579-589 Template-Type: ReDIF-Article 1.0 Author-Name: Khalied Hyari Author-X-Name-First: Khalied Author-X-Name-Last: Hyari Author-Name: Khaled El-Rayes Author-X-Name-First: Khaled Author-X-Name-Last: El-Rayes Title: Field experiments to evaluate lighting performance in nighttime highway construction Abstract: The utilisation of nighttime highway construction has increased in recent years in order to minimise daytime construction-related service disruptions and traffic congestion. In this type of nighttime construction, lighting arrangements need to be properly designed and implemented in order to enhance safety and productivity on site, and ensure full compliance with the required lighting specifications. A number of field experiments were conducted to evaluate the performance of various lighting arrangements in three typical highway construction zones, namely: activity area, transition and termination areas and flagger stations. In each of these zones, a number of practical lighting arrangements were found to be capable of satisfying all the lighting design criteria required by various Departments of Transportation. The experimental results also confirm that the set-up of lighting equipment on site has a significant impact on lighting performance, and therefore lighting arrangements should be carefully designed and executed on nighttime highway construction projects. Journal: Construction Management and Economics Pages: 591-601 Issue: 6 Volume: 24 Year: 2006 Keywords: Highway construction, workspace, nighttime construction, computer models, light, X-DOI: 10.1080/01446190600601669 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600601669 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:6:p:591-601 Template-Type: ReDIF-Article 1.0 Author-Name: R. Soetanto Author-X-Name-First: R. Author-X-Name-Last: Soetanto Author-Name: A. R. J. Dainty Author-X-Name-First: A. R. J. Author-X-Name-Last: Dainty Author-Name: J. Glass Author-X-Name-First: J. Author-X-Name-Last: Glass Author-Name: A. D. F. Price Author-X-Name-First: A. D. F. Author-X-Name-Last: Price Title: Towards an explicit design decision process: the case of the structural frame Abstract: Decisions made during the briefing and conceptual design stages of a building project are critical to its success. One of the earliest major decisions which can have a significant effect on downstream events and results is the selection of the structural frame. Given its importance to the efficacy of the finished building, the structural frame selection process should arguably be objective and transparent, the final decision being based on the frame's ability to perform against a range of criteria appropriate to the scheme in question. However, the heuristics underpinning such decisions tend not to be explicit and thus, are difficult for inexperienced clients to understand. This article reports on research which examined the criteria used by clients, structural engineers, architects and main contractors when selecting structural frames. These were established via a postal questionnaire survey of a stratified sample of design professionals, contractors and client organizations. The analysis reveals marked differences in the perceived importance of the criteria identified amongst the respondents, which may result in conflicts between design and construction advisers and their clients should they be made explicit in the design process. Nevertheless, it is important that such differences are revealed within the decision-making process if more appropriate design decisions are to be made in the future. Journal: Construction Management and Economics Pages: 603-614 Issue: 6 Volume: 24 Year: 2006 Keywords: Conflict, criteria, design, project team, structural frame, X-DOI: 10.1080/01446190600568173 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600568173 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:6:p:603-614 Template-Type: ReDIF-Article 1.0 Author-Name: Florence Phua Author-X-Name-First: Florence Author-X-Name-Last: Phua Title: When is construction partnering likely to happen? An empirical examination of the role of institutional norms Abstract: Despite the vast interest and enthusiasm on the benefits of construction partnering, no apparent trend exists to show that it has become the dominant choice of procurement method across construction industries internationally. Rather, the implementation of construction partnering has been patchy, with varying degrees of success and, in many instances, its adoption is more an exception than the norm. This study argues and sets out to test the proposition that despite the huge advocacy for the use of partnering, its slow uptake and, more importantly, the inconsistent results it yields are due to the lack of systematic investigation into the institutional determinants of partnering. Based on data collected from 526 firms covering various industry disciplines, results show that firms' use of partnering is selective and that this selectiveness is significantly determined by the industry's level of institutional norms and not by the conventional notion that partnering increases a firm's profitability or efficiency. Findings further indicate that firms that perceive there are strong industry norms for partnering are twice as likely to use partnering as firms that do not have such perception. By empirically examining the institutional conditions under which partnering is more likely to occur, this study sheds some light on why the implementation of partnering remains at a conservative rate and suggests avenues for future research. Journal: Construction Management and Economics Pages: 615-624 Issue: 6 Volume: 24 Year: 2006 Keywords: Construction partnering, institutional norms, procurement methods, X-DOI: 10.1080/01446190500521256 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500521256 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:6:p:615-624 Template-Type: ReDIF-Article 1.0 Author-Name: Kevin Duncan Author-X-Name-First: Kevin Author-X-Name-Last: Duncan Author-Name: Peter Philips Author-X-Name-First: Peter Author-X-Name-Last: Philips Author-Name: Mark Prus Author-X-Name-First: Mark Author-X-Name-Last: Prus Title: Prevailing wage legislation and public school construction efficiency: a stochastic frontier approach Abstract: Stochastic frontier regression is used to examine the effect of introducing prevailing wage legislation on public school construction efficiency in British Columbia. Prior to the legislation, public school projects were from 16% to 19% smaller, in terms of square feet, than comparable private structures. However, likelihood ratio tests consistently indicate that the coefficients measuring the effect of the policy on the size differential between covered and uncovered projects are not statistically different from zero. These results suggest that construction wage requirements did not alter input utilisation in a way that significantly affected construction output. Average inefficiency for school construction in British Columbia over the period of the study is 12.1%. Journal: Construction Management and Economics Pages: 625-634 Issue: 6 Volume: 24 Year: 2006 Keywords: Prevailing wage laws, regression analysis, X-DOI: 10.1080/01446190600601719 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600601719 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:6:p:625-634 Template-Type: ReDIF-Article 1.0 Author-Name: R. Navon Author-X-Name-First: R. Author-X-Name-Last: Navon Author-Name: O. Berkovich Author-X-Name-First: O. Author-X-Name-Last: Berkovich Title: An automated model for materials management and control Abstract: Current, manual, materials management and control procedures are unsatisfactory: they are labour intensive, inaccurate and error prone. The result is waste and surplus of materials, delays, decrease in productivity and lack of up-to-date, real-time information regarding the status of purchase orders (PO), the levels of inventory, the actual vs. planned usage of materials, and others. The purpose of the present work was to develop an automated model, which alleviates some of these problems. Prior to developing the model, a field survey was conducted to learn, at first hand, what the typical problems with materials management and control are. The model initiates materials purchasing, follows up the status of PO, records materials data as they arrive to the site and their movement around the site, makes recommendations, generates reports and issues warnings. The model was implemented, tested and evaluated in an ongoing building construction project. The onsite experiments confirmed that automated materials management and control are feasible, resulting in real benefits, such as time savings, and availability of up-to-date and accurate information regarding stocks of materials on site. Journal: Construction Management and Economics Pages: 635-646 Issue: 6 Volume: 24 Year: 2006 Keywords: Automation, data collection, feedback control, control methods, materials management, monitoring, X-DOI: 10.1080/01446190500435671 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500435671 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:6:p:635-646 Template-Type: ReDIF-Article 1.0 Author-Name: Chen-Yu Chang Author-X-Name-First: Chen-Yu Author-X-Name-Last: Chang Author-Name: Hui-Yu Chou Author-X-Name-First: Hui-Yu Author-X-Name-Last: Chou Author-Name: Ming-Teh Wang Author-X-Name-First: Ming-Teh Author-X-Name-Last: Wang Title: Characterizing the corporate governance of UK listed construction companies Abstract: In response to the emergence of scandals involving many high-profile companies during the 1990s, corporate governance is considered as an area requiring immediate reform. The government of the United Kingdom has conducted a series of reviews on corporate governance and incorporated the recommendations of these reports into regulatory codes. Compliance with these codes can be considered to indicate the implementation of best corporate practice. A question of interest is how UK construction companies perform in corporate governance. The answer can be revealed by comparing construction companies with the top 50 companies listed in the UK, based on the provisions of corporate governance codes. Construction companies are found to (1) disclose less corporate governance information; (2) display lower levels of structural board independence in terms of separate roles of chairman and chief executive officer (CEO) and percentage of independent directors; (3) rely less on external consultant advice in assisting the decision making of three board committees. Research thus should be conducted on whether these disparities cause adverse effects on construction company performance. Journal: Construction Management and Economics Pages: 647-656 Issue: 6 Volume: 24 Year: 2006 Keywords: Corporate governance, best practice, performance, construction companies, X-DOI: 10.1080/01446190500529424 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500529424 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:6:p:647-656 Template-Type: ReDIF-Article 1.0 Author-Name: Gerard De Valence Author-X-Name-First: Gerard Author-X-Name-Last: De Valence Title: Guest Editorial Abstract: Journal: Construction Management and Economics Pages: 661-668 Issue: 7 Volume: 24 Year: 2006 X-DOI: 10.1080/01446190600906779 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600906779 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:7:p:661-668 Template-Type: ReDIF-Article 1.0 Author-Name: Patricia Hillebrandt Author-X-Name-First: Patricia Author-X-Name-Last: Hillebrandt Title: Letter to the Editor Abstract: Journal: Construction Management and Economics Pages: 669-670 Issue: 7 Volume: 24 Year: 2006 X-DOI: 10.1080/01446190500249429 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500249429 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:7:p:669-670 Template-Type: ReDIF-Article 1.0 Author-Name: Erik Dietzenbacher Author-X-Name-First: Erik Author-X-Name-Last: Dietzenbacher Author-Name: Alex Hoen Author-X-Name-First: Alex Author-X-Name-Last: Hoen Title: Coefficient stability and predictability in input-output models: a comparative analysis for the Netherlands Abstract: Following the work of Bon, this article compares the stability of two types of input-output models. These are, the Leontief (or demand-driven) model and the Ghosh (or supply-driven) model. The empirical results are based on a times series of annual input-output tables for the Netherlands, covering the period 1948-84. Three types of analysis are carried out. The first to evaluate the stability of the models' underlying coefficients over time. The second to investigate the forecasting behaviour when there is perfect foresight with respect to the models' exogenous variables. The third to examine the predictability of the models, absent of perfect foresight. Journal: Construction Management and Economics Pages: 671-680 Issue: 7 Volume: 24 Year: 2006 Keywords: Stability, forecasting behaviour, input-output models, X-DOI: 10.1080/01446190600567985 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600567985 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:7:p:671-680 Template-Type: ReDIF-Article 1.0 Author-Name: Philip Mccann Author-X-Name-First: Philip Author-X-Name-Last: Mccann Title: On the supply-side determinants of regional growth Abstract: The major developments in thought regarding regional economic growth and development are traced over the last two decades. The supply-side micro-foundations of regional growth have come under scrutiny in a manner which has previously not been evident. In particular, an examination of the elements of industrial clustering, regional industrial structure, and place characteristics which may promote innovation, have become a central focus of modern regional growth analysis. The micro-foundations of these arguments are analysed, and the links between innovation and clustering explored within a transactions-costs framework. This allows us to point to areas in which our understanding has grown over recent years, and to identify further areas of analysis which are required. Journal: Construction Management and Economics Pages: 681-693 Issue: 7 Volume: 24 Year: 2006 Keywords: Economic theory, urban development, urban planning, markets, transaction cost economics, X-DOI: 10.1080/01446190500514756 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500514756 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:7:p:681-693 Template-Type: ReDIF-Article 1.0 Author-Name: David Shipworth Author-X-Name-First: David Author-X-Name-Last: Shipworth Title: Qualitative modelling of sustainable energy scenarios: an extension of the Bon qualitative input-output model Abstract: Climate change is one of the major challenges facing economic systems at the start of the 21st century. Reducing greenhouse gas emissions will require both restructuring the energy supply system (production) and addressing the efficiency and sufficiency of the social uses of energy (consumption). The energy production system is a complicated supply network of interlinked sectors with 'knock-on' effects throughout the economy. End use energy consumption is governed by complex sets of interdependent cultural, social, psychological and economic variables driven by shifts in consumer preference and technological development trajectories. To date, few models have been developed for exploring alternative joint energy production-consumption systems. The aim of this work is to propose one such model. This is achieved in a methodologically coherent manner through integration of qualitative input-output models of production, with Bayesian belief network models of consumption, at point of final demand. The resulting integrated framework can be applied either (relatively) quickly and qualitatively to explore alternative energy scenarios, or as a fully developed quantitative model to derive or assess specific energy policy options. The qualitative applications are explored here. Journal: Construction Management and Economics Pages: 695-703 Issue: 7 Volume: 24 Year: 2006 Keywords: Energy policy, input-output analysis, Bayesian belief networks, carbon management, sustainable consumption and production, X-DOI: 10.1080/01446190600658917 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600658917 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:7:p:695-703 Template-Type: ReDIF-Article 1.0 Author-Name: Nicola Costantino Author-X-Name-First: Nicola Author-X-Name-Last: Costantino Title: The contribution of Ranko Bon to the debate on sustainable construction Abstract: Ranko Bon is best-known for his studies of building economics. Less known is his contribution to the debate on sustainable construction, which shows unique features, particularly if compared to those of most recent related studies. By building upon on the initial systems approach to the problem of 'the limits to growth' and its macro- and micro-economic implications, Bon proposes a unique methodological contribution to such a problem. This paper outlines the historical debate about sustainability, its relation with construction and finally Bon's personal contribution in this regard. Journal: Construction Management and Economics Pages: 705-709 Issue: 7 Volume: 24 Year: 2006 Keywords: Economic measures, sustainable building, sustainable construction, X-DOI: 10.1080/01446190500127203 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500127203 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:7:p:705-709 Template-Type: ReDIF-Article 1.0 Author-Name: Roberto Pietroforte Author-X-Name-First: Roberto Author-X-Name-Last: Pietroforte Author-Name: Tullio Gregori Author-X-Name-First: Tullio Author-X-Name-Last: Gregori Title: Does volume follow share? The case of the Danish construction industry Abstract: In 1992, Ranko Bon argued that in highly developed countries the relatively declining economic importance of the construction industry is followed by the absolute decline of its output. The shrinking volume has implications with production capacity that, at a certain point of economic maturity, tends to be added at a slower rate than in the past. By using statistical data of the Danish construction industry, this study attempts to verify Bon's proposition. The absolute decline of housing investments partially supports such a proposition. What is more, since the peak of the mid-1970s, the addition rate to the capacity of the Danish economy has slowed down. Journal: Construction Management and Economics Pages: 711-715 Issue: 7 Volume: 24 Year: 2006 Keywords: Construction industry, Denmark, construction investments, construction output, X-DOI: 10.1080/01446190500204606 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500204606 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:7:p:711-715 Template-Type: ReDIF-Article 1.0 Author-Name: Les Ruddock Author-X-Name-First: Les Author-X-Name-Last: Ruddock Author-Name: Jorge Lopes Author-X-Name-First: Jorge Author-X-Name-Last: Lopes Title: The construction sector and economic development: the 'Bon curve' Abstract: The complexities of the relationship between a country's level of construction activity and its stage of economic development are considerable. Studies over the last three decades, based on macroeconomic analysis, have attempted to model the relationship but have usually been hampered by problems of data quality and availability. Nevertheless, paradigms have emerged (usually based on Keynesian philosophy), which are concerned with the dynamics of construction activity as an agent in the promotion of economic growth in economies at different stages of development. One such is the 'Bon curve'. An examination of the data issues of attempting to assess the validity of the proposition is made and then the role of the construction sector in highly developed economies is considered. Journal: Construction Management and Economics Pages: 717-723 Issue: 7 Volume: 24 Year: 2006 Keywords: 'Bon curve', construction activity, economic development, X-DOI: 10.1080/01446190500435218 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500435218 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:7:p:717-723 Template-Type: ReDIF-Article 1.0 Author-Name: Irem Dikmen Author-X-Name-First: Irem Author-X-Name-Last: Dikmen Author-Name: M. Talat Birgonul Author-X-Name-First: M. Talat Author-X-Name-Last: Birgonul Title: A review of international construction research: Ranko Bon's contribution Abstract: Literature on international construction is rich in adopting conceptual frameworks to investigate levels of international competitiveness and making inter-country comparisons about sources of national competitive advantage. However, there are limited studies that result from collaborative work between different country researchers about development of custom frameworks to investigate complexities of international construction business, experience-based generic libraries applicable to international construction projects and forecasting models. Ranko Bon's contribution to the international construction literature is invaluable as he has dealt with broad trends and dominant patterns of change in the global construction market by referring to judgments of experts from all over the world and helped dissemination of this practical information which may be used by policy makers and construction professionals seeking jobs in the global market. Journal: Construction Management and Economics Pages: 725-733 Issue: 7 Volume: 24 Year: 2006 Keywords: International construction, international construction research, global construction market, X-DOI: 10.1080/01446190600601909 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600601909 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:7:p:725-733 Template-Type: ReDIF-Article 1.0 Author-Name: David Hawk Author-X-Name-First: David Author-X-Name-Last: Hawk Title: Conditions of Success: a platform for international construction development Abstract: 'Conditions of Success' (COS) was organised to study the internationalisation of the construction industry in 1989. At that time few companies, and even fewer researchers, were interested in international construction endeavours. The purpose of the study was to collect information on activities of the 1980s in order to project who might be successful and under what conditions would they be successful in the next century. Extensive interviews were conducted with 60 participating firms from seven countries. While this group has now been reduced to about 20 via mergers and acquisitions they have demonstrated the value of several of the recommendations from the study. Critical to the study was an Executive Symposium held in Stockholm in 1991 where executives presented their view of the future and how best to prepare for it. Professor Ranko Bon, of Reading University, played a pivotal role in this special Symposium, as chair of the diverse interests and adviser to organising the results. Ten major recommendations are outlined in the paper. A critical distinction emerged from the study, which has grown in theoretical importance since 1991. It is between the North American, primarily Harvard-centric, strategic model for internationalisation and the relationship-building approach of Asia (initially Japanese and now Chinese). The Asian approach is closer to that of Europe and gaining in effectiveness and prominence over that of North America. Journal: Construction Management and Economics Pages: 735-742 Issue: 7 Volume: 24 Year: 2006 Keywords: Internationalisation, conditions, success, interdependence, value creation, construction activities, relationship building, X-DOI: 10.1080/01446190600658966 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600658966 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:7:p:735-742 Template-Type: ReDIF-Article 1.0 Author-Name: Sivaguru Ganesan Author-X-Name-First: Sivaguru Author-X-Name-Last: Ganesan Author-Name: John Kelsey Author-X-Name-First: John Author-X-Name-Last: Kelsey Title: Technology transfer: international collaboration in Sri Lanka Abstract: The real tests for technology transfer are whether such transfers have contributed significantly to the vibrant development of the recipient industry. Technology transfer (TT) process that is knowledge driven demands a recipient industry with adequate capacity for absorbing new knowledge. International joint ventures and subcontracts employed in building material and construction can be serious vehicles of TT provided they contribute to providing higher quality inputs into the wider industry. These issues are examined through a survey of construction subcontracts during the period 1985-2002. The respondents indicated that moderately favourable conditions for TT existed in the completed projects. Nonetheless, the paper argues that negligible real productivity changes in construction in Sri Lanka in the recent decade point to stagnation in growth in local absorptive capacity. China in contrast has placed a balanced emphasis on upgrading building materials and equipment, design and construction, and built up an impressive absorptive capacity, with modernisation of the entire industry in prospect. The paper suggests advance planning for TT in foreign funded projects to ensure greater participation of local firms, together with a balanced focus on efficient and timely execution of projects, the profitability of participants, and realisation of TT goals. Journal: Construction Management and Economics Pages: 743-753 Issue: 7 Volume: 24 Year: 2006 Keywords: Construction, technology transfer, absorptive capacity, modernisation, X-DOI: 10.1080/01446190600704703 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600704703 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:7:p:743-753 Template-Type: ReDIF-Article 1.0 Author-Name: Philip Steadman Author-X-Name-First: Philip Author-X-Name-Last: Steadman Title: Allometry and built form: revisiting Ranko Bon's work with the Harvard Philomorphs Abstract: Ranko Bon's Master's thesis at Harvard was devoted to the phenomenon of allometry in the forms of buildings. The concept of allometry comes from biology, and refers to changes in the forms of organisms as they alter in size. For example the ratio of volume to surface exposed to the air (including the lungs) is of great functional importance to animals, and tends to remain constant as they get larger. Bon studied allometry in residential buildings, and showed that both the ratio of surface to volume and the ratio of circulation length to floor area were preserved over a wide range of building sizes. Bon's work is revisited from a theoretical point of view, using a new method for representing large numbers of theoretical but realistic built forms, all derived from a single 'archetypal building'. By choosing default dimensions typical of dwellings, Bon's original results can be reproduced. By varying these dimensions of plan depth, numbers of storeys and widths of courts or light-wells, it is possible to show what precise kinds of allometric relationships are likely to be found in other types of day-lit buildings besides dwellings. Journal: Construction Management and Economics Pages: 755-765 Issue: 7 Volume: 24 Year: 2006 Keywords: Allometry, built form, archetypal building, surface area, volume, circulation length, floor area, X-DOI: 10.1080/01446190600601966 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600601966 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:7:p:755-765 Template-Type: ReDIF-Article 1.0 Author-Name: Gerard De Valence Author-X-Name-First: Gerard Author-X-Name-Last: De Valence Title: Building as an economic process: the Austrian approach revisited Abstract: Bon's book Building as an Economic Process: An Introduction to Building Economics was an important step in the development of the economic theory of the built environment. The book's aim was to establish theoretical foundations for building economics, using the perspective of Austrian economics. The objective of this review is to assess the significance and impact of the book, and how successful Bon was in achieving his stated purpose. Each of the major topics in the book is discussed, with the Austrian approach as used by Bon on capital theory, the building process, and business and building cycles assessed. Bon proposed a significant research programme based on these ideas. The impact of the ideas is discussed before progress on the research programme is reviewed. The conclusion attempts to bring out the significance of the book's contribution. Journal: Construction Management and Economics Pages: 767-771 Issue: 7 Volume: 24 Year: 2006 Keywords: Building economics, Austrian economics, building process, capital theory, Ranko Bon, X-DOI: 10.1080/01446190600601859 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600601859 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:7:p:767-771 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Goran Runeson Author-X-Name-First: Goran Author-X-Name-Last: Runeson Author-Name: Xinling Chang Author-X-Name-First: Xinling Author-X-Name-Last: Chang Title: Construction price formation: full-cost pricing or neoclassical microeconomic theory? Abstract: Neo-classical microeconomic theory has been suggested to offer (1) an appropriate analytical tool for construction price determination while, at the same time, (2) full-cost pricing is most commonly accepted pricing policy of construction firms. Paradoxically, however, both are mutually exclusive theories. Only one, if any, can be correct. This paper examines both (1) and (2) by analysis of the evidence available in literature and concludes in favour of (1). It is only in disequilibrium, however, that the differences in behaviour can be clearly observed. In equilibrium, the difference between the two theories from a practical point of view is not very substantial. In addition, the endemic nature of uncertainty in the industry in general makes the task of estimating costs and prices difficult in practice. Therefore, although neoclassical microeconomic theory provides a useful means of analysis, it offers little for the practice of pricing, which is much more closely related to the marketing discipline than economics. Journal: Construction Management and Economics Pages: 773-783 Issue: 7 Volume: 24 Year: 2006 Keywords: Construction, contracts, pricing, theory, policy, costs, prices, neo-classical microeconomics, marketing, X-DOI: 10.1080/01446190500434849 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500434849 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:7:p:773-783 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Goran Runeson Author-X-Name-First: Goran Author-X-Name-Last: Runeson Title: Bidding models: testing the stationarity assumption Abstract: With notably few exceptions, bidding models contain probability distributions with parameters that are assumed to be fixed, or stationary, over time. Some methods of testing the tenability of this assumption are examined and applied to eight datasets. Of particular interest is the statistical significance of two types of periodicity: (1) that bidders gradually reduce their bids prior to winning a contract; and (2) that bidders have periods in which they are more competitive and periods in which they are less competitive. To test (1), McCaffer and Pettitt's (1976) cusum method is used and shown to have a limited interpretation in this context. McCaffer's 'deficit' statistic is then used in conjunction with a one-way analysis of variance (ANOVA) and shows (1) to be untenable for the samples involved. To test (2), the deficit statistic is again used with an ANOVA to examine all possible sub-series of bids. Journal: Construction Management and Economics Pages: 791-803 Issue: 8 Volume: 24 Year: 2006 Keywords: Bidding, behaviour, parameters, cusum method, deficit statistic, X-DOI: 10.1080/01446190600680432 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600680432 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:8:p:791-803 Template-Type: ReDIF-Article 1.0 Author-Name: Timothy Michael Lewis Author-X-Name-First: Timothy Michael Author-X-Name-Last: Lewis Author-Name: Roger Hosein Author-X-Name-First: Roger Author-X-Name-Last: Hosein Title: An estimation of the size of the hidden labour force in construction in Trinidad and Tobago Abstract: In every country there is a hidden economy operating alongside the formal economy. The published national statistics record only the formal economy. These statistics indicate that the construction industry is an important source of both wealth creation and employment despite the fact that they fail to take account of three important aspects of the sector. These are that the broadly defined construction sector is much larger than the construction industry, what is known as the 'informal' sector, and the work done by direct labour organisations. In the absence of actual measures of the size of these aspects, an indirect technique has been used to provide an estimate of their scale. These estimates are used to obtain an overview of their possible impact on the actual role of the sector in terms of output and employment in the economy. The preliminary estimates suggest the overall contribution of construction to the economy of Trinidad and Tobago represents some three times the official Figure. Journal: Construction Management and Economics Pages: 805-815 Issue: 8 Volume: 24 Year: 2006 Keywords: Formal, informal, direct labour, employment, construction sector, X-DOI: 10.1080/01446190600658594 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600658594 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:8:p:805-815 Template-Type: ReDIF-Article 1.0 Author-Name: S. B. Zhang Author-X-Name-First: S. B. Author-X-Name-Last: Zhang Author-Name: Anita Liu Author-X-Name-First: Anita Author-X-Name-Last: Liu Title: Organisational culture profiles of construction enterprises in China Abstract: The vast economic growth in China in the past decade has brought forth opportunities for the development of its construction industry. However, the construction industry in China has been criticised for poor performance and low effectiveness in terms of quality and profitability in the face of challenges and uncertainties resulting from the fast changing economic environment. Given that organisational culture plays a significant role in work performance and effectiveness, the apparently low effectiveness of the construction industry may be related to the culture of the contractors' organisations. The culture-effectiveness (C-E) relationship has received increased attention in organisational research and the aim of the study is to develop a culture-effectiveness model of the contractors' motivated behaviour towards performance. Results of cluster analysis of the culture profiles of Chinese construction enterprises show that hierarchy and clan cultures are dominant and that culture profiles of Chinese contractors may vary in different geographical regions. Journal: Construction Management and Economics Pages: 817-828 Issue: 8 Volume: 24 Year: 2006 Keywords: Behaviours, motivation, organisational culture, performance effectiveness, schemas, X-DOI: 10.1080/01446190600704604 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600704604 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:8:p:817-828 Template-Type: ReDIF-Article 1.0 Author-Name: Susan Bogus Author-X-Name-First: Susan Author-X-Name-Last: Bogus Author-Name: Keith Molenaar Author-X-Name-First: Keith Author-X-Name-Last: Molenaar Author-Name: James Diekmann Author-X-Name-First: James Author-X-Name-Last: Diekmann Title: Strategies for overlapping dependent design activities Abstract: Overlapping activities that are traditionally performed in a sequential manner can significantly reduce project delivery times. Overlapping, however, should be approached in a systematic manner to reduce the costs and risks. Information gathered from sector-based case studies and from the manufacturing domain suggest a formalised framework for identifying overlapping opportunities and strategies can be successfully implemented for infrastructure projects. This framework considers activity characteristics, such as evolution of upstream information and sensitivity of downstream activities to changes in upstream information, to identify appropriate overlapping strategies. Overlapping strategies, such as early freezing of design criteria, overdesign, and early release of preliminary information, are selected based on activity characteristics. These strategies operate either by speeding up the evolution of upstream information or by reducing the sensitivity of downstream activities. By aligning overlapping strategies with activity characteristics, project managers can make better decisions on when and how much to overlap sequential activities to reduce overall project delivery time. Journal: Construction Management and Economics Pages: 829-837 Issue: 8 Volume: 24 Year: 2006 Keywords: Concurrent engineering, project management, decision making, X-DOI: 10.1080/01446190600658529 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600658529 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:8:p:829-837 Template-Type: ReDIF-Article 1.0 Author-Name: K. R. Grosskopf Author-X-Name-First: K. R. Author-X-Name-Last: Grosskopf Author-Name: Charles Kibert Author-X-Name-First: Charles Author-X-Name-Last: Kibert Title: Economic incentive framework for sustainable energy use in US residential construction Abstract: Searching for new ways to be competitive in an increasingly deregulated market, energy suppliers worldwide have turned to energy conservation measures (ECMs) to avoid costly generation expansion, to build relationships with consumers and to comply with new international emissions standards. To maximise the cost effectiveness of an energy conservation programme, a framework is presented to assess consumer 'willingness-to-pay' for ECMs and avoided supply costs. The goal of this framework is to provide a methodology to optimise supplier incentives that will maximise consumer adoption and minimise energy production costs. A survey of 400 US homebuyers found that nearly 90% would invest in ECMs. Yet for every two years required to 'payback' the initial investment, consumer willingness-to-pay declines 25%. A case study of a medium-size US utility found that most ECMs contribute more to profitable base load reduction than to costly peak load reduction, meaning utility loss in revenue often exceeds avoided supply costs. However, the average housing unit conserving 7,718kWh/yr could save US$216.10 per year, in addition to electricity costs, if the cost of avoided emissions abatement were credited back to the consumer. Based on these savings, expected ECM adoption could eliminate 1.65×108 kWh of energy use and 107,197 tons of CO2 emissions for every 20,000 single family homes. Journal: Construction Management and Economics Pages: 839-846 Issue: 8 Volume: 24 Year: 2006 Keywords: Energy conservation, incentives, residential, USA, X-DOI: 10.1080/01446190600601818 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600601818 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:8:p:839-846 Template-Type: ReDIF-Article 1.0 Author-Name: Mahdi Mattar Author-X-Name-First: Mahdi Author-X-Name-Last: Mattar Author-Name: Charles Cheah Author-X-Name-First: Charles Author-X-Name-Last: Cheah Title: Valuing large engineering projects under uncertainty: private risk effects and real options Abstract: In all large engineering projects, valuation constitutes an important step during the initial stage as each stakeholder assesses the prospect of his or her investment. The complexity of valuation increases dramatically in the face of uncertainty especially when the risks are dynamic and stochastic in nature. The usual classification in finance theory divides risks into either market or unique. In this research, a new notion of private risk is introduced. A private risk may either be correlated with the market or be unique, but in addition it represents a substantial portion of an investor's wealth and is not tradable due to agency costs or other strategic reasons. The principles of pricing would differ according to the treatment of these different types of risks. Methods that are currently in vogue for pricing private risks are first evaluated, followed by a study of the effect of private risks in real option problems. Through a classic oil and gas exploration and development example, it is demonstrated that the methods chosen for pricing private risks can lead to decisively different real option values, exercise strategies and development policies. Effectively, the difference in real option values can be interpreted as a form of private risk premium. Journal: Construction Management and Economics Pages: 847-860 Issue: 8 Volume: 24 Year: 2006 Keywords: Decision analysis, private risk, real option, risk, valuation, X-DOI: 10.1080/01446190600658818 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600658818 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:8:p:847-860 Template-Type: ReDIF-Article 1.0 Author-Name: Y. P. Poh Author-X-Name-First: Y. P. Author-X-Name-Last: Poh Author-Name: J. H. M. Tah Author-X-Name-First: J. H. M. Author-X-Name-Last: Tah Title: Integrated duration-cost influence network for modelling risk impacts on construction tasks Abstract: Quantitative risk analysis is usually ignored in construction risk management, although numerous techniques are available. One of the shortcomings of conventional quantitative risk analysis techniques is that they can only analyse either duration or cost risks. In view of this, an integrated duration-cost influence network that systematically represents the interdependencies among the duration and cost parameters of a construction task has been developed, and mathematical equations have been formulated to represent the dependencies. The generic structure of the influence network can be used for explicitly modelling risk impacts affecting any construction task, and the nature of risks can be investigated in the risk modelling process. In addition, risk impacts modelled can potentially be propagated through the influence network for quantifying the risk-adjusted task duration and cost simultaneously. Thus, the influence network provides the basis for performing integrated duration-cost risk modelling and simulation in future research. Journal: Construction Management and Economics Pages: 861-868 Issue: 8 Volume: 24 Year: 2006 Keywords: Quantitative risk analysis, integrated duration-cost influence network, risk factors, risk modelling, risk propagation, X-DOI: 10.1080/01446190600658891 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600658891 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:8:p:861-868 Template-Type: ReDIF-Article 1.0 Author-Name: Rafael Sacks Author-X-Name-First: Rafael Author-X-Name-Last: Sacks Author-Name: Michael Harel Author-X-Name-First: Michael Author-X-Name-Last: Harel Title: An economic game theory model of subcontractor resource allocation behaviour Abstract: Periodic review and adjustment of resource allocations to construction projects is critical for subcontractors to maintain profitability under traditional unit price or lump sum contracts. Project managers strive to control subcontractors in an effort to meet budgets and schedules; subcontractors often work on multiple projects simultaneously and strive independently to allocate resources to those projects where they perceive that they will bring maximum utility. An economic game theory model is proposed as a foundation for understanding the behaviour of subcontractors in allocating resources to projects. The model describes the influence of the degree of reliability of the planned schedule on subcontractors' and project managers' behaviours under traditional unit price contracting. Unreliable plans undermine efforts to promote cooperative behaviour. Journal: Construction Management and Economics Pages: 869-881 Issue: 8 Volume: 24 Year: 2006 Keywords: Decision making, game theory, lean construction, partnering, resource allocation, subcontracting, X-DOI: 10.1080/01446190600631856 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600631856 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:8:p:869-881 Template-Type: ReDIF-Article 1.0 Author-Name: Ani Birgit Raiden Author-X-Name-First: Ani Birgit Author-X-Name-Last: Raiden Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: Richard Neale Author-X-Name-First: Richard Author-X-Name-Last: Neale Title: Balancing employee needs, project requirements and organisational priorities in team deployment Abstract: The 'people and performance' model asserts that performance is a sum of employee ability, motivation and opportunity (AMO). Despite extensive evidence of this people-performance link within manufacturing and many service sectors, studies within the construction industry are limited. Thus, a recent research project set out to explore the team deployment strategies of a large construction company with the view of establishing how a balance could be achieved between organisational strategic priorities, operational project requirements and individual employee needs and preferences. The findings suggested that project priorities often took precedence over the delivery of the strategic intentions of the organisation in meeting employees' individual needs. This approach is not sustainable in the long term because of the negative implications that such a policy had in relation to employee stress and staff turnover. It is suggested that a resourcing structure that takes into account the multiple facets of AMO may provide a more effective approach for balancing organisational strategic priorities, operational project requirements and individual employee needs and preferences more appropriately in the future. Journal: Construction Management and Economics Pages: 883-895 Issue: 8 Volume: 24 Year: 2006 Keywords: Human resource management, organisational culture, teams, motivation, case study, X-DOI: 10.1080/01446190600647191 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600647191 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:8:p:883-895 Template-Type: ReDIF-Article 1.0 Author-Name: I-Tung Yang Author-X-Name-First: I-Tung Author-X-Name-Last: Yang Title: Using Gaussian copula to simulate repetitive projects Abstract: An important requirement for simulating repetitive projects is to treat correlations inherent in the repetition of same crews working at various locations. To attain the requirement, this study develops a new Monte Carlo simulation model implementing a Gaussian copula in conjunction with the inverse-transform method to generate correlated duration samples in repetitive projects that have pre-specified marginal distributions and pairwise rank correlations. The proposed model is equipped with an automatic approximation procedure to adjust an infeasible correlation matrix, if necessary. The proposed model is statistically verified through a real-life residential apartment project. The simulation results are compared to two conventional analyses (PERT and simulation without correlation) to show the aggregated impact of correlations. The proposed model contributes to the state-of-the-art in handling non-linear dependencies among activity durations that may have non-normal distributions. Moreover, it is flexible in the ways of correlation assessments (qualitative or quantitative), the magnitudes of correlations (weak to strong), and the types of marginal distributions (symmetrical or skewed). Journal: Construction Management and Economics Pages: 901-909 Issue: 9 Volume: 24 Year: 2006 Keywords: Copula, simulation, stochastic estimation, risk management, repetitive project, X-DOI: 10.1080/01446190600658784 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600658784 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:9:p:901-909 Template-Type: ReDIF-Article 1.0 Author-Name: Karen Manley Author-X-Name-First: Karen Author-X-Name-Last: Manley Author-Name: Steve Mcfallan Author-X-Name-First: Steve Author-X-Name-Last: Mcfallan Title: Exploring the drivers of firm-level innovation in the construction industry Abstract: A survey of 335 businesses in the Australian road industry has been carried out to ascertain those factors that make firms innovate. 'Innovative' is measured by adoption rates of advanced technologies and practices, and the range of innovation drivers reviewed encompasses business strategy and environment. The findings indicate that business strategies are more important than business conditions, and that the following three strategies are significant in differentiating between firms with high and low adoption rates: (1) hiring new graduates; (2) introducing new technologies; and (3) enhancing technical capabilities. The findings also highlight the importance of undertaking R&D and encouraging employee ideas for improvement. The public policy implications are that the quality of university graduates should be protected and advanced, as should technical skills within public sector client agencies. Journal: Construction Management and Economics Pages: 911-920 Issue: 9 Volume: 24 Year: 2006 Keywords: Innovation, technology adoption, business practices, business conditions, X-DOI: 10.1080/01446190600799034 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600799034 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:9:p:911-920 Template-Type: ReDIF-Article 1.0 Author-Name: Ina Drejer Author-X-Name-First: Ina Author-X-Name-Last: Drejer Author-Name: Anker Lund Vinding Author-X-Name-First: Anker Lund Author-X-Name-Last: Vinding Title: Organisation, 'anchoring' of knowledge, and innovative activity in construction Abstract: The construction industry is characterised by the widespread use of project organisation. It has been suggested that the relatively low level of innovative activity in the industry can be explained by the temporary nature of firm boundary-crossing projects. Survey data from the Danish construction industry is used to investigate the importance of learning and 'anchoring' of project-specific knowledge at the firm level for participation in innovative activities. The data cover both the overall Danish construction industry and a specific region, North Jutland, which has a relatively high specialisation of construction workers. Latent class and regression analyses reveal that firms that make extensive use of partnering, together with internal product and process evaluation and knowledge diffusion (labelled 'knowledge-anchoring mechanisms'), are more likely to participate in innovative activities than firms which make less use of these mechanisms. This indicates that construction firms are able to compensate for the problems that temporary interorganisational projects may cause in relation to continuous learning at the firm level. Journal: Construction Management and Economics Pages: 921-931 Issue: 9 Volume: 24 Year: 2006 Keywords: Project organisation, partnering, innovative activity, X-DOI: 10.1080/01446190600799166 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600799166 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:9:p:921-931 Template-Type: ReDIF-Article 1.0 Author-Name: Christian Stoy Author-X-Name-First: Christian Author-X-Name-Last: Stoy Author-Name: Wolfdietrich Kalusche Author-X-Name-First: Wolfdietrich Author-X-Name-Last: Kalusche Title: The determination of occupancy costs during early project phases Abstract: In addition to the earnings, costs determine the commercial success of real estate investments. The discussion in the German-speaking region focuses on occupancy costs and their planning. When planning, the occupancy costs must be determined early, continually monitored, and controlled if necessary. A process for determining occupancy costs, the construction element process, is presented and tested using an actual property. The test results deviate by only approximately 8% from the occupancy costs actually incurred. The process demonstrates its suitability for the early determination of occupancy costs using only a few pieces of data on the property. However, it does require occupancy cost indicators. Also, the significant drivers of these indictors must be known in order to select the appropriate indicator. For this reason, future work on occupancy costs must not only collect additional data, but the data must also be analysed with regard to the cost drivers. Journal: Construction Management and Economics Pages: 933-944 Issue: 9 Volume: 24 Year: 2006 Keywords: Occupancy costs, cost planning, construction element process, building planning, Germany, X-DOI: 10.1080/01446190600799307 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600799307 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:9:p:933-944 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Whitla Author-X-Name-First: Paul Author-X-Name-Last: Whitla Author-Name: Peter Walters Author-X-Name-First: Peter Author-X-Name-Last: Walters Author-Name: Howard Davies Author-X-Name-First: Howard Author-X-Name-Last: Davies Title: The use of global strategies by British construction firms Abstract: A two-stage qualitative case study, and Yip's conceptual framework, are used to examine the extent to which British construction firms have adopted 'global' strategies. In the first stage industry experts provided evidence on the forces driving global strategy. In the second stage executives from eight internationally active firms described how they have responded to those forces. Results indicate that the forces driving globalisation, at least for traditional contracting activities, are not strong. Evidence shows that most firms operating internationally organise 'multi-locally' and make little use of globally integrated strategies. However, firms that have moved into 'higher value-added' construction activities have a greater propensity to integrate some aspects of their strategy on a global basis. Journal: Construction Management and Economics Pages: 945-954 Issue: 9 Volume: 24 Year: 2006 Keywords: Globalisation, strategy, international competition, multinational companies, transnationals, X-DOI: 10.1080/01446190600799679 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600799679 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:9:p:945-954 Template-Type: ReDIF-Article 1.0 Author-Name: Hyung Jin Kim Author-X-Name-First: Hyung Jin Author-X-Name-Last: Kim Author-Name: Kenneth Reinschmidt Author-X-Name-First: Kenneth Author-X-Name-Last: Reinschmidt Title: A dynamic competition model for construction contractors Abstract: In construction, the issue of competition has been studied focusing on competitive bidding. The objective of most competitive bidding models is to find the optimum mark-up to maximise the expected profit from a single firm's perspective. However, a firm's success depends on its long-term interactions with the market and its competitors. To better understand competition in the market, there is a need to analyse competition from a dynamic market perspective. Building on previous models and relevant competition studies, a dynamic simulation model has been developed to provide an analytical framework for understanding dynamic competition. In this model, similar firms are equally exposed to demand uncertainties. Each applies its own policy, responding to market changes and to competitors' actions to optimise its market position. The firms' responses and their dynamic feedback are simulated and analysed. The results show how difficult it is for any firm to acquire a long-term competitive advantage by means of bidding/marketing strategies—just as it is in the real world of price-competitive contracting. Some considerations are presented for a single firm to develop a competitive strategy. Journal: Construction Management and Economics Pages: 955-965 Issue: 9 Volume: 24 Year: 2006 Keywords: Competitive bidding, dynamic competition, interaction and feedback, market changes and timing, competitive factors, X-DOI: 10.1080/01446190600799729 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600799729 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:9:p:955-965 Template-Type: ReDIF-Article 1.0 Author-Name: Sung Kin Pun Author-X-Name-First: Sung Kin Author-X-Name-Last: Pun Author-Name: Chunlu Liu Author-X-Name-First: Chunlu Author-X-Name-Last: Liu Author-Name: Craig Langston Author-X-Name-First: Craig Author-X-Name-Last: Langston Title: Case study of demolition costs of residential buildings Abstract: Building demolition is one of the most common activities in the construction industry. Several demolition techniques are commonly used, including mechanical demolition, deconstruction and hybrid demolition. Although deconstruction has been advocated for its environmentally friendly approaches, the cost comparison of a demolition project under different techniques is rarely researched. In this paper, the cost of a demolition project is broken down to input and output costs, which are further broken down to more countable sections. Through an empirical study in Victoria, Australia, project costs of mechanical demolition, hybrid demolition and deconstruction are investigated. It is found that deconstruction has the greatest profitability among the three techniques. Hybrid demolition, which is the actual technique adopted by the contractor, has a slightly lower profit, and mechanical demolition is the most expensive. Although deconstruction has the best overall economical performance, the small extra gain comes with increased complexity and risk that deters demolition contractors from its attempt. It is found in the paper that an optimized demolition project strategy exists between hybrid demolition and deconstruction with the greatest profitability among various building demolition techniques. Journal: Construction Management and Economics Pages: 967-976 Issue: 9 Volume: 24 Year: 2006 Keywords: Australia, recycling, project appraisal, demolition, cost modelling, X-DOI: 10.1080/01446190500512024 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500512024 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:9:p:967-976 Template-Type: ReDIF-Article 1.0 Author-Name: Kumar Neeraj Jha Author-X-Name-First: Kumar Neeraj Author-X-Name-Last: Jha Author-Name: Chandrashekhar Iyer Author-X-Name-First: Chandrashekhar Author-X-Name-Last: Iyer Title: What attributes should a project coordinator possess? Abstract: Construction projects are increasingly multidisciplinary and the role of a project coordinator has become critical for success. A clear differentiation is drawn between the roles of a project manager and a project coordinator, and the attributes required in a successful project coordinator are defined. A total of 24 such attributes were identified through a survey of available literature and personal interviews with top construction professionals based in India. A ranking has also been assigned to these attributes on the basis of a questionnaire survey. Statistical analyses of responses indicated a distinct difference between the attributes possessed by the project coordinators in projects that were considered successful, and those that were considered failures. Project coordinators of successful projects were found to excel in certain important attributes such as relationship with client, consultant and contractor; timeliness; technical knowledge of the subject; belief in team playing spirit; and coordination for achieving quality compared to their counterparts in projects which were regarded as failures. Interestingly, the required attributes remained the same for project coordinators whether they worked for the contracting agency or the owner's organisation. Factor analysis was used to group the 24 attributes into three major skills categories: team building skills; contract implementation skills; and project organisation skills. These findings will be useful to practitioners during the recruitment of project coordinators. Journal: Construction Management and Economics Pages: 977-988 Issue: 9 Volume: 24 Year: 2006 Keywords: Project coordinator, project manager, coordination, questionnaire, X-DOI: 10.1080/01446190600781826 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600781826 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:9:p:977-988 Template-Type: ReDIF-Article 1.0 Author-Name: Fanie Buys Author-X-Name-First: Fanie Author-X-Name-Last: Buys Author-Name: Raymond Nkado Author-X-Name-First: Raymond Author-X-Name-Last: Nkado Title: A survey of maintenance management systems in South African tertiary educational institutions Abstract: The implementation of an effective maintenance management system is vital if the maintenance of assets of any organisation or institution is to be managed effectively. A survey was undertaken among tertiary educational institutions in South Africa to identify a list of best practice criteria and to prioritise these in order of importance. The study evaluated the performance of the existing maintenance management systems used by tertiary educational institutions to determine whether there is a need to improve current maintenance management systems. Results showed that existing performance is far below best practice standards and that the use of computerised maintenance management systems is very limited. This led to the development of a model to assist maintenance managers at tertiary educational institutions to evaluate and improve their existing approaches to maintenance management. Journal: Construction Management and Economics Pages: 997-1005 Issue: 10 Volume: 24 Year: 2006 Keywords: Maintenance management, modelling, South Africa, universities, X-DOI: 10.1080/01446190600851009 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600851009 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:10:p:997-1005 Template-Type: ReDIF-Article 1.0 Author-Name: Stuart Carmichael Author-X-Name-First: Stuart Author-X-Name-Last: Carmichael Author-Name: Maria Murray Author-X-Name-First: Maria Author-X-Name-Last: Murray Title: Record keeping for contemporaneous delay analysis: a model for effective event management Abstract: Increasingly sophisticated computer software is being utilized to support detailed critical path method (CPM) analysis for resolving delay and disruption claims. The accurate determination of entitlement is however still dependent on the quality of programme and progress information provided by all parties. A comparative analysis of record-keeping methods in the UK and the US reveals that there is less rigour to this practice in the UK, where parties are not required by the contract to provide such records. In most forms of US government construction contract the contractor is required to produce a schedule using CPM software and to regularly update this to reflect project progress and changes. Recent recommended best practice in the UK also stipulates that the contractor should keep reliable and accurate progress and programme records to assist contemporaneous assessment of the cause and effect of project changes. While not contractually imperative, a clear method of managing information is important in UK construction and engineering projects to facilitate more effective and accurate assessments of delay and disruption. The US experience and good practice approaches in the UK demonstrate the importance of implementing and establishing an 'event management strategy and archive' at the outset of projects. Journal: Construction Management and Economics Pages: 1007-1018 Issue: 10 Volume: 24 Year: 2006 Keywords: Delay analysis, records, change event, event archive, programme, claims, X-DOI: 10.1080/01446190500521207 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500521207 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:10:p:1007-1018 Template-Type: ReDIF-Article 1.0 Author-Name: Wai-Ki Fu Author-X-Name-First: Wai-Ki Author-X-Name-Last: Fu Author-Name: Hing-Po Lo Author-X-Name-First: Hing-Po Author-X-Name-Last: Lo Author-Name: Derek Drew Author-X-Name-First: Derek Author-X-Name-Last: Drew Title: Collective learning, collective knowledge and learning networks in construction Abstract: The interrelationships between collective learning, collective knowledge and learning networks are complex and difficult, especially in a construction context. A questionnaire survey was carried out in Hong Kong to test the hypothesis that practitioners who need a wider domain of knowledge for work learn more actively through their learning networks. This empirical work revealed a positive association between the demand for learning from others at work and the size of construction practitioners' learning networks. The analysis also revealed two opposing aspects of practitioners' learning behaviour influenced by the nature of their work. First, civil engineers tend to manage larger learning networks, given that they very often need to seek advice from other practitioners to deal with issues beyond their specialities at work and coordinate outputs of other practitioners as the project leader. Second, draughtsmen and clerks of works (or inspectors of works), whose work mainly involves complying with a finite scope of predetermined instructions and rules, appear not very active in network learning. These findings will be useful in developing learning policy for enhancing the competitiveness of the construction industry. Journal: Construction Management and Economics Pages: 1019-1028 Issue: 10 Volume: 24 Year: 2006 Keywords: Construction, knowledge, learning, rule, network, X-DOI: 10.1080/01446190500228258 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500228258 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:10:p:1019-1028 Template-Type: ReDIF-Article 1.0 Author-Name: Seung Ok Author-X-Name-First: Seung Author-X-Name-Last: Ok Author-Name: Sunil Sinha Author-X-Name-First: Sunil Author-X-Name-Last: Sinha Title: Construction equipment productivity estimation using artificial neural network model Abstract: Estimating equipment production rates is both an art and a science. An accurate prediction of the productivity of earthmoving equipment is critical for accurate construction planning and project control. Owing to the unique work requirements and changeable environment of each construction project, the influences of job and management factors on operation productivity are often very complex. Hence, construction productivity estimation, even for an operation with well-known equipment and work methods, can be challenging. This study develops and compares two methods for estimating construction productivity of dozer operations (the transformed regression analysis, and a non-linear analysis using neural network model). It is the hypothesis of this study that the proposed neural networks model may improve productivity estimation models because of the neural network's inherent ability to capture non-linearity and the complexity of the changeable environment of each construction project. The comparison of results suggests that the non-linear artificial neural network (ANN) has the potential to improve the equipment productivity estimation model. Journal: Construction Management and Economics Pages: 1029-1044 Issue: 10 Volume: 24 Year: 2006 Keywords: Construction equipment, artificial neural network, productivity estimation, X-DOI: 10.1080/01446190600851033 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600851033 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:10:p:1029-1044 Template-Type: ReDIF-Article 1.0 Author-Name: Patricia Carrillo Author-X-Name-First: Patricia Author-X-Name-Last: Carrillo Author-Name: Herbert Robinson Author-X-Name-First: Herbert Author-X-Name-Last: Robinson Author-Name: Chimay Anumba Author-X-Name-First: Chimay Author-X-Name-Last: Anumba Author-Name: Nasreddine Bouchlaghem Author-X-Name-First: Nasreddine Author-X-Name-Last: Bouchlaghem Title: A Knowledge Transfer Framework: the PFI context Abstract: The UK's Private Finance Initiative market is predicted to rise to over £8 billion a year and there are indications of growing opportunities. PFI creates a long-term income stream and provides valuable opportunities for portfolio diversification. PFI has evolved at a fast pace and the momentum is set to continue. However, there are major challenges facing construction organisations. These include the lack of PFI experts, longer negotiation periods and tight time schedules to deliver large-scale schemes, high levels of investment and risks involved and limited knowledge transfer between PFI projects. Concerns over the level of knowledge sharing have prompted the development and evaluation of a Knowledge Transfer Framework that encourages construction organisations to transfer PFI knowledge between projects. It achieves this by building on a questionnaire survey of PFI clients and construction companies, case studies of companies involved in PFI, and research workshops to validate the framework developed. Journal: Construction Management and Economics Pages: 1045-1056 Issue: 10 Volume: 24 Year: 2006 Keywords: Knowledge transfer, Private Finance Initiative, framework, X-DOI: 10.1080/01446190600799224 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600799224 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:10:p:1045-1056 Template-Type: ReDIF-Article 1.0 Author-Name: Bradley Eeing Author-X-Name-First: Bradley Author-X-Name-Last: Eeing Author-Name: Jamie Brown Kruse Author-X-Name-First: Jamie Brown Author-X-Name-Last: Kruse Title: Valuing self-protection: income and certification effects for safe rooms Abstract: Survey data from Tulsa, Oklahoma residents are used to examine individual valuations of safe rooms. The study utilises two measures of individual valuations, the maximum willingness to pay (WTP) and willingness to accept (WTA) for safe rooms. The primary research questions are concerned with whether the willingness to pay measure exhibits income effects and whether certification standards make the safe room investment more desirable. The main findings can be summarised as follows. The mean willingness to pay for a safe room was $2,500. The value of certification by a national organisation increased willingness to pay for the safe room by $600 on average. There is no direct income effect in that respondents' stated willingness to pay does not bear a statistically significant relationship to reported income. There is evidence of a secondary income effect in that willingness to pay elicited from attendees of a suburban parade of homes was $731 higher than attendees of an urban parade of homes. A mortgage payment-based WTA measure yields mean valuations of the safe room more than three times higher than the lump sum WTP valuation. Journal: Construction Management and Economics Pages: 1057-1068 Issue: 10 Volume: 24 Year: 2006 Keywords: Safe room, willingness to pay, willingness to accept, valuation, certification, X-DOI: 10.1080/01446190600851090 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600851090 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:10:p:1057-1068 Template-Type: ReDIF-Article 1.0 Author-Name: Rong-Yau Huang Author-X-Name-First: Rong-Yau Author-X-Name-Last: Huang Title: A performance-based bridge LCCA model using visual inspection inventory data Abstract: Since most bridge life cycle cost analysis (LCCA) depends heavily on the analyst's experience to determine the times and costs of remedial actions over a bridge's lifetime, the results are often subject to question because of their subjectivity. While some work has been done over the years to develop reliable deterioration models for determining such times and costs, the proposed models often require sophisticated inspection data, which is costly to obtain, and/or complex mathematical calculations. A simple linear deterioration model based on visual inspection inventory data concerning bridge components is introduced and integrated into the LCC analysis. The proposed model provides an alternative approach to bridge LCC analysis that can improve the objectivity of analysis and does not require input of sophisticated inspection, and thus facilitates application of bridge life cycle cost analysis. The LCCA method developed in this study is applied to a case study of alternative PCI (Pre-stressed Concrete I-girder) and a PCB (Pre-stressed Concrete Box-girder) bridges for the purpose of model validation. Journal: Construction Management and Economics Pages: 1069-1081 Issue: 10 Volume: 24 Year: 2006 Keywords: Bridge management systems, life cycle cost analysis, deterioration model, X-DOI: 10.1080/01446190600568124 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600568124 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:10:p:1069-1081 Template-Type: ReDIF-Article 1.0 Author-Name: Christian Stoy Author-X-Name-First: Christian Author-X-Name-Last: Stoy Author-Name: Susanne Kytzia Author-X-Name-First: Susanne Author-X-Name-Last: Kytzia Title: Benchmarking electricity consumption Abstract: The building stock is one of the largest energy consumers and simultaneously represents a relevant cost driver for most companies. Thus, buildings should be optimally planned, constructed and used from both an environmental and from an economic perspective. Benchmarking electricity consumption in the usage phase is a tool for achieving this objective. This requires a uniform collection of key usage indicators on the one hand, and on the other hand it is necessary to be cognisant of the factors that drive these key indicators and how they do so. This alone makes it possible to satisfy the benchmarking principle of comparing like or similar objects. Uniformly collected key indicators for electricity consumption (kWh/m2 usable floor area and year) are presented on the basis of 109 Swiss office buildings. This is broken down into further groupings on the basis of the relevant drivers. The analysis of the drivers relies on regression analysis. This demonstrates above all the great relevance of technical installation (e.g. the share of mechanically vented and ventilated as well as air-conditioned areas), given that the coverage area of such systems has a significant effect on the electricity consumption of office buildings. Accordingly, special attention should be paid to the planning, construction and use of technical installations, in order to be able to provide optimally energy-efficient buildings. Journal: Construction Management and Economics Pages: 1083-1089 Issue: 10 Volume: 24 Year: 2006 Keywords: Benchmarking, energy, electricity consumption, office, X-DOI: 10.1080/01446190600799414 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600799414 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:10:p:1083-1089 Template-Type: ReDIF-Article 1.0 Author-Name: Chris Fortune Author-X-Name-First: Chris Author-X-Name-Last: Fortune Title: Process standardisation and the impact of professional judgement on the formulation of building project budget price advice Abstract: The generation of a reliable early stage building project price forecast for its capital cost is an important aspect of any project's initial appraisal. Such professional advice is central to clients' decision-making processes. Work on early stage building project budget price forecasting is reviewed and a change in the direction of future research is called for in this topic area. This aim has been achieved by identifying seminal work on the general topic, addressing its shortcomings, and then focusing on research conducted to explore the formulation processes of quality building project budget price advice. It is posited that poor quality building project price forecasts affect clients seeking to make value for money business decisions. Empirical evidence from previous research indicates that previous calls for paradigm changes in practice towards the adoption of newer more stochastic models or tools such as expert systems, probabilistic and regression models have now been generally rejected. As a result it is asserted that practice can be considered to be in crisis and is looking to establish a new way forward. It is concluded that a research agenda needs to be established that has process standardisation and practitioner judgement as well as the existing information engineering-based approach at its core. Such an additional strand to future research in the topic area will help to ensure that the newly emerging wave of project budget formulation tools, such as neural nets, neuro-fuzzy nets, sustainability and whole life cost models are taken up and used more effectively in practice. Journal: Construction Management and Economics Pages: 1091-1098 Issue: 10 Volume: 24 Year: 2006 Keywords: Project budget estimating, process, quality, judgement, X-DOI: 10.1080/01446190600851116 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600851116 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:10:p:1091-1098 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Title: Letter to the Editor Abstract: Journal: Construction Management and Economics Pages: 1107-1109 Issue: 11 Volume: 24 Year: 2006 X-DOI: 10.1080/01446190601001620 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601001620 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:11:p:1107-1109 Template-Type: ReDIF-Article 1.0 Author-Name: Paolo Tombesi Author-X-Name-First: Paolo Author-X-Name-Last: Tombesi Title: Letter to the Editor Abstract: Journal: Construction Management and Economics Pages: 1111-1111 Issue: 11 Volume: 24 Year: 2006 X-DOI: 10.1080/01446190601004012 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601004012 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:11:p:1111-1111 Template-Type: ReDIF-Article 1.0 Author-Name: Vivian Tam Author-X-Name-First: Vivian Author-X-Name-Last: Tam Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Author-Name: Kenneth Yiu Author-X-Name-First: Kenneth Author-X-Name-Last: Yiu Author-Name: S. O. Cheung Author-X-Name-First: S. O. Author-X-Name-Last: Cheung Title: Critical factors for environmental performance assessment (EPA) in the Hong Kong construction industry Abstract: With the rise in the public concern on environmental protection, more construction firms start to apply environmental management for their construction activities. As a result, environmental management systems (EMS) have been implemented in construction. However, to improve the construction environment in Hong Kong, environmental performance assessment (EPA) has been designed for reviewing, monitoring, checking and evaluating environmental performance. A list of evaluation factors for EPA are identified and grouped into seven major factors: management and training; air and noise; auditing; waste and water; cost saving on resources; energy; and regulation. The results from a survey highlight that the most important evaluation factor is management and training and the least significant result is regulation. A voluntary approach has been promoted instead of the traditional mandatory system. Furthermore, three case studies are used to test the reliability with seven groups of evaluation factors in measuring the environmental performance for construction. The results from the case study analysis proved the effectiveness of the developed environmental performance assessment. Therefore, the developed environmental performance assessment can benefit the construction industry and help to achieve continuous improvement on environmental performance. Journal: Construction Management and Economics Pages: 1113-1123 Issue: 11 Volume: 24 Year: 2006 Keywords: Environmental performance assessment, factor analysis, Hong Kong, X-DOI: 10.1080/01446190600799620 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600799620 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:11:p:1113-1123 Template-Type: ReDIF-Article 1.0 Author-Name: I Putu Artama Wiguna Author-X-Name-First: I Putu Artama Author-X-Name-Last: Wiguna Author-Name: Stephen Scott Author-X-Name-First: Stephen Author-X-Name-Last: Scott Title: Relating risk to project performance in Indonesian building contracts Abstract: A construction project is unique, specific and dynamic, and therefore projects have different levels and combinations of risks, different responses are taken to minimise those risks and different consequences affect project performance. The primary aim of this study was to analyse the impacts of perceived project risk on project performance. A path model was developed and path analysis was used to determine the relationships between risk and performance. The main survey was predominantly based on a series of interviews with project managers. A total of 22 building projects under construction were surveyed; however, only 13 projects used an 'S' curve to monitor their project performance. The study focused on these 13 projects and found that perceived project risk had a direct negative effect on monthly progress achievement, while monthly progress had a direct positive impact on schedule performance. Although project risk had no direct effect on schedule performance, this was influenced indirectly with monthly progress as the mediator between them. These findings indicate that the higher the project risk in a project, the greater the negative impact on monthly progress, and consequently the worse the schedule performance will be. Journal: Construction Management and Economics Pages: 1125-1135 Issue: 11 Volume: 24 Year: 2006 Keywords: Building project, path analysis, project delay, project performance, risk management, X-DOI: 10.1080/01446190600799760 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600799760 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:11:p:1125-1135 Template-Type: ReDIF-Article 1.0 Author-Name: Xiaohong Li Author-X-Name-First: Xiaohong Author-X-Name-Last: Li Author-Name: John Ogier Author-X-Name-First: John Author-X-Name-Last: Ogier Author-Name: John Cullen Author-X-Name-First: John Author-X-Name-Last: Cullen Title: An economic modelling approach for public sector construction workload planning Abstract: The effectiveness of public sector construction workload planning can be enhanced through employing an economic modelling approach to predict the impact of different workloads on tender price changes. The main problem associated with existing methods used for predicting tender price index (TPI) for construction projects is a lack of robustness when the market becomes unstable. This is due to limited consideration of market conditions in these methods. An economic modelling approach has been developed and applied for public sector construction workload planning in the States of Guernsey where forward planning was required. The developed model overcomes the problem of existing methods—lack of robustness—by correlating TPI of construction projects to demand over capacity ratio of the industry, which represents the industry's economic condition. The model generates the price changes under different planning options associated with different workloads over a five-year planning period. The information is valuable to the public sector in estimating actually required investment. This ensures the feasibility of the plan and the possibility of contribution to the stability of the construction market. The model development and application process developed in this research can be used to assist a planning process for an industry where a demand, capacity and price relationship is applied. Journal: Construction Management and Economics Pages: 1137-1147 Issue: 11 Volume: 24 Year: 2006 Keywords: Modelling, construction workload planning, tender price index, demand, capacity, X-DOI: 10.1080/01446190600798960 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600798960 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:11:p:1137-1147 Template-Type: ReDIF-Article 1.0 Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Author-Name: Jiang Hongbin Author-X-Name-First: Jiang Author-X-Name-Last: Hongbin Title: Analysing ownership, locational and internalization advantages of Chinese construction MNCs using rough sets analysis Abstract: The rough sets analysis focusing on the ownership, locational and internalization (OLI) advantages of Chinese construction multinational corporations (MNCs) in the international market under Dunning's Eclectic Paradigm was adopted to overcome the sample size constraint in MNC research that seeks to examine the causality patterns of the factors identified. The rough sets methodology provides a solution that conventional statistical methods do not offer to ascertain how these factors are determined and their influence in the OLI analysis of the performance of Chinese construction MNCs. The rough sets approach to handling imperfect data with uncertainty and vagueness was adopted to describe dependencies between attributes, evaluate the significance of attributes and deal with inconsistencies. Based on a questionnaire survey of 31 Chinese construction MNCs, findings from the rough sets analysis suggest, among other things, that: (1) a firm is likely to perform well in terms of its ownership advantages when it has a significant advantage on its reputation and its accessibility to resources when compared with local contractors; (2) a firm may be expected to achieve better results in terms of its locational advantages if the large number of competitors from China in the host countries becomes its most important consideration; and (3) a firm that conscientiously avoids or reduces information search and business negotiation costs would tend to perform well in terms of its internalization advantages. Journal: Construction Management and Economics Pages: 1149-1165 Issue: 11 Volume: 24 Year: 2006 Keywords: Rough sets, eclectic paradigm, international construction, Chinese multinational corporations, X-DOI: 10.1080/01446190500435739 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500435739 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:11:p:1149-1165 Template-Type: ReDIF-Article 1.0 Author-Name: Arshi Shakeel Faridi Author-X-Name-First: Arshi Shakeel Author-X-Name-Last: Faridi Author-Name: Sameh Monir El-Sayegh Author-X-Name-First: Sameh Monir Author-X-Name-Last: El-Sayegh Title: Significant factors causing delay in the UAE construction industry Abstract: Construction delay is considered one of the most recurring problems in the construction industry. Delays have an adverse impact on project success in terms of time, cost, quality and safety. The effects of construction delays are not confined to the construction industry only, but influence the overall economy of a country like UAE, where construction plays a major role in its development and contributes 14% to the GDP. Thus, it is essential to define the most significant causes of delay in order to avoid or minimise their impact on construction projects. A detailed questionnaire was developed and used to get input from professionals associated with the UAE construction industry. The perspective of contractors and consultants has been analysed to rank the causes of delays based on their Relative Importance Index. Contractors and consultants were in agreement on the most significant causes of delays. The research revealed that 50% of the construction projects in UAE encounter delays and are not completed on time. The top 10 most significant causes of construction delays have been identified by this research. Approval of drawings, inadequate early planning and slowness of the owners' decision-making process are the top causes of delay in the UAE construction industry. Journal: Construction Management and Economics Pages: 1167-1176 Issue: 11 Volume: 24 Year: 2006 Keywords: Delay, project management, project controls, time, UAE, X-DOI: 10.1080/01446190600827033 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600827033 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:11:p:1167-1176 Template-Type: ReDIF-Article 1.0 Author-Name: David Shiers Author-X-Name-First: David Author-X-Name-Last: Shiers Author-Name: Daniel Rapson Author-X-Name-First: Daniel Author-X-Name-Last: Rapson Author-Name: Claire Roberts Author-X-Name-First: Claire Author-X-Name-Last: Roberts Author-Name: Miles Keeping Author-X-Name-First: Miles Author-X-Name-Last: Keeping Title: Sustainable construction: the development and evaluation of an environmental profiling system for construction products Abstract: There has been a rapid increase in the number of low environmental impact or 'green' buildings constructed in recent years, due to factors such as the UK government's Sustainable Development Strategy, new environmental legislation and perceived operational and business advantages. Consequently, the demand for up-to-date information, guidance and design 'tools' to help property professionals procure greener buildings also continues to grow. The development of a new edition of one such tool: The Green Guide to Specification, was based on research designed to evaluate user needs and current design and specification practices and expectations. Many property professionals do not use environmental tools on all projects because of time considerations and the disruption caused by having to take an 'extra step' in the design and specification process. Specifiers would only use such tools either when instructed to do so by clients or because of the specifier's own organisational green agenda. For environmental tools to be more widely used, information should also be embedded within commonly used specification programmes such as the National Building Specification (NBS) as well as in stand-alone versions. Journal: Construction Management and Economics Pages: 1177-1184 Issue: 11 Volume: 24 Year: 2006 Keywords: Sustainability, green buildings, design process, specification, materials, X-DOI: 10.1080/01446190600892987 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600892987 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:11:p:1177-1184 Template-Type: ReDIF-Article 1.0 Author-Name: Gul Polat Author-X-Name-First: Gul Author-X-Name-Last: Polat Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Author-Name: Glenn Ballard Author-X-Name-First: Glenn Author-X-Name-Last: Ballard Author-Name: Ugur Mungen Author-X-Name-First: Ugur Author-X-Name-Last: Mungen Title: Economics of on-site vs. off-site fabrication of rebar Abstract: Many contractors prefer on-site fabrication of rebar while others find that off-site fabrication is more advantageous. The economics of on-site and off-site fabrication of rebar need to be compared on the basis of several factors that include the project environment, wages, labour considerations, the initial investment for equipment, waste of rebar, the cost of inventory, cycle time, and supply chain management. This study presents an economic comparison of the on-site and off-site fabrication practices of rebar by means of a simulation model that makes use of the factors mentioned earlier. The model is populated with actual data obtained from a trade centre project in Istanbul, Turkey. The article indicates that the off-site fabrication practice would have been more costly than the on-site practice in the project in Istanbul, a finding that was to be expected in circumstances that prevail in most developing countries. Journal: Construction Management and Economics Pages: 1185-1198 Issue: 11 Volume: 24 Year: 2006 Keywords: Lean construction, cut and bent rebar, on-site fabrication, off-site fabrication, simulation model, X-DOI: 10.1080/01446190500529432 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190500529432 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:11:p:1185-1198 Template-Type: ReDIF-Article 1.0 Author-Name: Chi Mint Tam Author-X-Name-First: Chi Mint Author-X-Name-Last: Tam Author-Name: Thomas Tong Author-X-Name-First: Thomas Author-X-Name-Last: Tong Author-Name: K. K. Chan Author-X-Name-First: K. K. Author-X-Name-Last: Chan Title: Rough set theory for distilling construction safety measures Abstract: There are numerous construction safety measures adopted by the local construction industry in Hong Kong. The purpose of this study is to distil the more significant measures from all these practices. To achieve this, the rough set theory, a data mining technique by applying the rule induction method, is proposed to distil the rules that determine the safety performance of construction firms. Rough sets represent a different mathematical approach to vagueness and uncertainty. It is based on the assumption that lowering the degree of precision in the data makes the data pattern more visible. Under such an assumption, the rough set theory can provide the ability of classifying vague and uncertain data. A practical example is used to illustrate its application to distil these safety measures and highlight those which are most effective and important in combating site accidents. There are three decision rules identified; the best one is companies with a comprehensive safety orientation programme and good safety award campaigns for senior management staff which give the lowest accident rate and the best safety performance. Safety management rules can be successfully reduced, facilitating contractors to direct their limited recourses effectively. Journal: Construction Management and Economics Pages: 1199-1206 Issue: 11 Volume: 24 Year: 2006 Keywords: Rough set theory, site operations, health and safety, X-DOI: 10.1080/01446190600879091 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600879091 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:11:p:1199-1206 Template-Type: ReDIF-Article 1.0 Author-Name: Yu Song Author-X-Name-First: Yu Author-X-Name-Last: Song Author-Name: Chunlu Liu Author-X-Name-First: Chunlu Author-X-Name-Last: Liu Author-Name: Craig Langston Author-X-Name-First: Craig Author-X-Name-Last: Langston Title: Extending construction linkage measures by the consideration of the impact of capital Abstract: Construction linkage is a well-established research field. However, a significant limitation in previous linkage research is that the flow of capital goods is not addressed. Using the OECD input-output tables, this research first generates a new input-output model considering capital as an intermediate factor. Using the new model, the construction linkages are recalculated and investigated in order to evaluate further the role of construction in national economies. The findings verify that traditional construction linkages were extremely underestimated in previous research. Furthermore, the effect of capital on construction shows a declining trend over the examined period. After considering the effect of capital, most values and rankings of backward and forward linkages show a decreasing trend, which confirms the declining role of the construction sector with economic maturity. Journal: Construction Management and Economics Pages: 1207-1216 Issue: 11 Volume: 24 Year: 2006 Keywords: Construction sector, input-output analysis, capital, linkages, X-DOI: 10.1080/01446190600599152 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600599152 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:11:p:1207-1216 Template-Type: ReDIF-Article 1.0 Author-Name: Ronie Navon Author-X-Name-First: Ronie Author-X-Name-Last: Navon Author-Name: Issam Haskaya Author-X-Name-First: Issam Author-X-Name-Last: Haskaya Title: Is detailed progress monitoring possible without designated manual data collection? Abstract: The daily site report (DSR)—a common tool, which contains a lot of valuable data— is normally used for litigation purposes, i.e. claims and dispute resolution. All these valuable data are rarely used for the management and control of the ongoing project. The purpose of the current research is to develop a tool that uses data taken from a computerized DSR to generate monitoring and control information. We have developed a progress monitoring model, which uses data from a computerized DSR to generate information regarding the actual progress and then transfer it to the scheduling software. The model was developed and implemented in a concept proving prototype using Excel and MS Project. The operation and the usefulness of the prototype are demonstrated with a case study, synthetic, project. The results indicate that the DSR is a useful data collection tool for progress monitoring. The cost of the information generated from these data is low because no additional manual operations are required in order to collect the data. Journal: Construction Management and Economics Pages: 1225-1229 Issue: 12 Volume: 24 Year: 2006 Keywords: Daily site report, data collection, progress control, project control, site records, X-DOI: 10.1080/01446190600999097 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600999097 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:12:p:1225-1229 Template-Type: ReDIF-Article 1.0 Author-Name: Wei Tong Chen Author-X-Name-First: Wei Tong Author-X-Name-Last: Chen Author-Name: Ying-Hua Huang Author-X-Name-First: Ying-Hua Author-X-Name-Last: Huang Title: Approximately predicting the cost and duration of school reconstruction projects in Taiwan Abstract: Regression and neural network models have been developed to predict the cost and duration of projects for the reconstruction of schools which must be quickly rebuilt. Data for the school reconstruction projects in central Taiwan, which received the most serious damage from the Chi-Chi Earthquake, were collected and analysed. The analytical results demonstrate that the floor area provides a good basis for estimating the cost and duration of school reconstruction projects, and suggest that the neural network model with back-propagation learning technique is a feasible approach that yields better prediction results than the regression model for school reconstruction projects. Journal: Construction Management and Economics Pages: 1231-1239 Issue: 12 Volume: 24 Year: 2006 Keywords: Cost and duration, reconstruction project, regression analysis, neural networks, X-DOI: 10.1080/01446190600953805 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600953805 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:12:p:1231-1239 Template-Type: ReDIF-Article 1.0 Author-Name: Nang-Fei Pan Author-X-Name-First: Nang-Fei Author-X-Name-Last: Pan Title: Evaluation of building performance using fuzzy FTA Abstract: Estimating exact probabilities of occurrence of fault events for use in the conventional fault tree analysis (FTA) is difficult when failure data are insufficient or fault events are imprecise such as human error. A hybrid approach employing fuzzy sets and possibility theory is proposed to overcome this problem. In this approach, failure possibilities of vague events are characterised by fuzzy sets to translate expert subjective judgements while fuzzy fault rates are derived from fuzzy possibility scores based on a transformed Onisawa's possibility function. An example of beam failure illustrates the use of the approach and demonstrates the capability of the model that can assist safety engineers to effectively assess fault possibilities and better evaluate building performance. Journal: Construction Management and Economics Pages: 1241-1252 Issue: 12 Volume: 24 Year: 2006 Keywords: Building performance, failure possibility, risk assessment, FTA, fuzzy sets, X-DOI: 10.1080/01446190600851066 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600851066 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:12:p:1241-1252 Template-Type: ReDIF-Article 1.0 Author-Name: Onur Tokdemir Author-X-Name-First: Onur Author-X-Name-Last: Tokdemir Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Author-Name: Cenk Balcik Author-X-Name-First: Cenk Author-X-Name-Last: Balcik Title: ALISS: Advanced Linear Scheduling System Abstract: The line of balance (LOB) method is not widely used in the construction industry even though it has distinct advantages in repetitive construction projects. Attempts were made in the past to develop LOB systems but no system has met with universal acceptance because of a multitude of problems. As a response, a tool named ALISS was developed that solves most of the problems associated with LOB applications. ALISS is an acronym for Advanced Linear Scheduling System and makes use of a model that utilises the tools of information technology to the fullest extent. This is accomplished by creating a system that has a standalone and a web-based version. ALISS is programmed using Visual Basic and Visual Basic Script languages. It utilises MS Access and SQL server as a data repository. The resulting Advanced Linear Scheduling System not only accommodates all LOB requirements but also provides the latest technological developments as an embedded tool. Journal: Construction Management and Economics Pages: 1253-1267 Issue: 12 Volume: 24 Year: 2006 Keywords: Linear scheduling, repetitive construction, line of balance, X-DOI: 10.1080/01446190600953706 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600953706 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:12:p:1253-1267 Template-Type: ReDIF-Article 1.0 Author-Name: Shu-Ling Lu Author-X-Name-First: Shu-Ling Author-X-Name-Last: Lu Author-Name: Martin Sexton Author-X-Name-First: Martin Author-X-Name-Last: Sexton Title: Innovation in small construction knowledge-intensive professional service firms: a case study of an architectural practice Abstract: Small construction knowledge-intensive professional service firms (SCKIPSFs) are becoming increasingly important agents of innovation within the construction industry. The nature and process of innovation in SCKIPSFs, however, is generally considered through the constraining prism of research results generated from significantly different contexts, such as from manufacturing sectors or non-project based firms. A theory of innovation for SCKIPSFs is developed from a longitudinal 22-month case study of a small architectural practice. Two forms of knowledge-based innovation were discerned from the empirical work: exploitative innovation and explorative innovation. 'Explorative innovation' was found to be located in immediate 'new' project domains, and entailed search, variation, experimentation, activity to solve project-specific problems; while 'exploitative innovation' concentrated on developing generic organisational infrastructure to 'refine' and 'improve the efficiency' of the firm operations to nurture capability for future activity. The key challenge for SCKIPSFs is to develop and manage an appropriate balance between explorative and exploitative innovation over time in order to generate sustainable competitive advantage. Journal: Construction Management and Economics Pages: 1269-1282 Issue: 12 Volume: 24 Year: 2006 Keywords: Knowledge-intensive, professional service firms, innovation, small enterprises, X-DOI: 10.1080/01446190600879109 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600879109 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:12:p:1269-1282 Template-Type: ReDIF-Article 1.0 Author-Name: Evelyn Ai-Lin Teo Author-X-Name-First: Evelyn Ai-Lin Author-X-Name-Last: Teo Author-Name: N. Harikrishna Author-X-Name-First: N. Author-X-Name-Last: Harikrishna Title: A quantitative model for efficient maintenance of plastered and painted facades Abstract: Building owners are faced with increasing maintenance costs incurred to rectify defects on different building elements and systems. With a significant proportion of maintenance costs spent on upkeep of building facades, there is a need for cost-effective approaches for facade maintenance. A quantitative model is developed for effective evaluation, optimization and management of costs of maintenance of plastered and painted facades. Visual surveys were used to collect information about defects on the external plaster and paint finish for public housing apartment blocks in Singapore. The data were used to develop 'defect index models' for each type of defect to predict its onset and propagation. The output from these models was incorporated into a life cycle cost model that can be used to predict and optimise the timing and magnitude of maintenance/repair costs incurred on plastered and painted facades during their intended lifetime. Journal: Construction Management and Economics Pages: 1283-1293 Issue: 12 Volume: 24 Year: 2006 Keywords: External finish, facade, life cycle cost, maintenance, service life, X-DOI: 10.1080/01446190600987704 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600987704 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:12:p:1283-1293 Template-Type: ReDIF-Article 1.0 Author-Name: Karen Manley Author-X-Name-First: Karen Author-X-Name-Last: Manley Title: The innovation competence of repeat public sector clients in the Australian construction industry Abstract: The role of client leadership in improving construction industry performance by increasing the rate and quality of innovation activity has been receiving increasing attention globally over the past decade. There has however been less attention given to the capability of clients to effectively perform this role. The literature suggests that the internal innovation competency of clients impacts on their potential to encourage innovation throughout the industry. Based on data collected via a large-scale survey of the Australian construction industry, the innovation competence of repeat public sector clients is examined using descriptive statistics. The results show that the clients have a relatively high level of innovation competence, compared to contractors, consultants and suppliers. The role of innovation competence is important. If public sector client agencies wish to protect and promote the role they play in encouraging industry innovation, they need to nurture their internal innovation competence. Journal: Construction Management and Economics Pages: 1295-1304 Issue: 12 Volume: 24 Year: 2006 Keywords: Innovation competence, innovation indicators, client leadership, X-DOI: 10.1080/01446190600934953 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600934953 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:12:p:1295-1304 Template-Type: ReDIF-Article 1.0 Author-Name: Eric Johansen Author-X-Name-First: Eric Author-X-Name-Last: Johansen Author-Name: Brian Wilson Author-X-Name-First: Brian Author-X-Name-Last: Wilson Title: Investigating first planning in construction Abstract: There is a divergence of research opinion as to the efficacy of detailed front end construction planning (first planning) and its use for strategic or tactical purposes. What really happens in planning construction projects is considered by focusing on comparing the responses of key stakeholders in the construction planning process. Contrasting perspectives of office- and site-based staff upon the accuracy of project timescales are identified together with their dissimilar methods of programme development and preferred first planning detail level. Consistently divergent views are expressed by office-based preconstruction planners and site-based construction project managers, including a reluctance to engage others during first planning held by the former and a limited belief in completion of the project to another's timescale (without their personal input) expressed by the latter. Significant role-based discrepancies in their approach to first planning are revealed and the potential for further research into cultural and behavioural motivators is highlighted. Journal: Construction Management and Economics Pages: 1305-1314 Issue: 12 Volume: 24 Year: 2006 Keywords: First planning, project planning, construction planning, X-DOI: 10.1080/01446190600863160 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600863160 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:24:y:2006:i:12:p:1305-1314 Template-Type: ReDIF-Article 1.0 Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Title: Construction in Developing Countries Abstract: Journal: Construction Management and Economics Pages: 1-6 Issue: 1 Volume: 25 Year: 2007 X-DOI: 10.1080/01446190601114134 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601114134 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:1:p:1-6 Template-Type: ReDIF-Article 1.0 Author-Name: Timothy Michael Lewis Author-X-Name-First: Timothy Michael Author-X-Name-Last: Lewis Title: Impact of globalization on the construction sector in developing countries Abstract: The international movement towards open markets promoted by the World Trade Organisation (WTO) has as its premise that trade liberalisation will benefit all concerned. Each country should be able to exploit its position of comparative advantage once a free and fair trade regime has been implemented. Although most commentators agree that in theory free trade should be beneficial, its implementation has been anything but beneficial for the developing countries. The construction sector falls under the provisions of the services negotiations of the WTO, and stands to experience the effects of trade liberalisation. Whether construction firms from the developing countries stand to gain or lose from this exposure to open competition is discussed in the light of the inequity with which the developing countries have been treated in the globalization of markets to date. Journal: Construction Management and Economics Pages: 7-23 Issue: 1 Volume: 25 Year: 2007 Keywords: Free trade, inequality, construction, globalization, WTO, X-DOI: 10.1080/01446190600601248 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600601248 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:1:p:7-23 Template-Type: ReDIF-Article 1.0 Author-Name: Charles Cheah Author-X-Name-First: Charles Author-X-Name-Last: Cheah Author-Name: Jian Kang Author-X-Name-First: Jian Author-X-Name-Last: Kang Author-Name: David Chew Author-X-Name-First: David Author-X-Name-Last: Chew Title: Strategic analysis of large local construction firms in China Abstract: The many transitory changes in China have raised the intensity level of competition among construction firms. Despite having a high growth economy, some construction firms continue to suffer from low profitability. Meanwhile, practical cases and empirical findings related to Chinese construction firms remain lacking. This research develops a conceptual model for improving the competitiveness of large construction firms in China. The model integrates two main streams of strategic management theories—the industrial organisation theories, and the resource-based and competence-based views. Critical variables that form the model are initially identified from an environmental analysis and the case studies of 12 large Chinese construction companies. The relationships between competitive strategies, important resources and competencies, and competitive advantage are then verified using survey results. The statistical findings suggest that two strategies—differentiation and market/product diversification, and three important resources and competencies—technological innovative capabilities, financial capabilities and guanxi (relationship), directly affect firm performance as measured by revenue and profit growth. Journal: Construction Management and Economics Pages: 25-38 Issue: 1 Volume: 25 Year: 2007 Keywords: China, competence, competitiveness, construction companies, strategic analysis, X-DOI: 10.1080/01446190600693450 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600693450 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:1:p:25-38 Template-Type: ReDIF-Article 1.0 Author-Name: Jasper Mbachu Author-X-Name-First: Jasper Author-X-Name-Last: Mbachu Author-Name: Raymond Nkado Author-X-Name-First: Raymond Author-X-Name-Last: Nkado Title: Factors constraining successful building project implementation in South Africa Abstract: The prevalence of client dissatisfaction in the South African building industry is a consequence of non-achievement of set project objectives due to identifiable constraints. The paper presents the results of investigations into the nature, magnitudes and frequencies of occurrence of these constraints. The descriptive survey method was used with qualitative data gathering through semi-structured interviews, and quantitative data gathering using structured questionnaires. Multi-attribute methods and rank correlation tests were used in the data analyses. A set of consultants' and contractors' acts of omission or commission is shown as the most influential and most frequently occurring factor constraining successful project delivery in the South African building industry. The controllable factors account for 67% of the perceived discrepancies between expected and actual outcomes of project development. An Influence-Frequency matrix was developed and applied as a conceptual framework for establishing the risk levels of the identified project constraints. The application of this framework is recommended as an effective approach to risk analysis and risk response development in project management. Journal: Construction Management and Economics Pages: 39-54 Issue: 1 Volume: 25 Year: 2007 Keywords: Development constraints, Influence-Frequency matrix, project management, project success criteria, risk management, X-DOI: 10.1080/01446190600601297 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600601297 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:1:p:39-54 Template-Type: ReDIF-Article 1.0 Author-Name: Pantaleo Mutajwaa Daniel Rwelamila Author-X-Name-First: Pantaleo Mutajwaa Daniel Author-X-Name-Last: Rwelamila Title: Project management competence in public sector infrastructure organisations Abstract: Public sector organisations responsible for infrastructure development in most non-industrialised countries, which include infrastructure departments/ministries, parastatal organisations and other statutory organisations qualify as project-oriented organisations (POO). There are strong indications to suggest that these organisations' project management (PM) competencies leave a lot to be desired. At face value they purport to be fully fledged project-oriented organisations and performing as competent PM organisations, while in reality they are predominantly dependent on accidental project managers. This paper reports on a study that was carried out in one of the large infrastructure departments in South Africa. The focus is on one of the premiere programmes managed by the department. The management of the programme is scrutinised in order to establish the department/ministry's PM competence. An evaluation of the performance of the programme was carried out in relation to the ministry's mandate in order to assess its PM competence. It is found that the programme in its current form could be described as a 'white elephant' and a programme that does not have an appropriate organisation structure, nor appropriate and sufficient staff to carry out its objectives. The programme's management system is found to be very poor and at the lowest level of maturity (level 1 out of 5). Recommendations are made that the programme in its current form cannot fulfil its mandate successfully without a fundamental overhaul, addressing its organisational structure, personnel qualifications and programme management system. Journal: Construction Management and Economics Pages: 55-66 Issue: 1 Volume: 25 Year: 2007 Keywords: Project management competence, public sector, culture, infrastructure organisations, South Africa, non-industrialised countries, X-DOI: 10.1080/01446190601099210 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601099210 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:1:p:55-66 Template-Type: ReDIF-Article 1.0 Author-Name: Chrisna Du Plessis Author-X-Name-First: Chrisna Du Author-X-Name-Last: Plessis Title: A strategic framework for sustainable construction in developing countries Abstract: There is no doubt that large-scale development in the built environment and its physical infrastructure is needed in the so-called 'developing countries'. However, these problems need to be addressed in a way that is socially and ecologically responsible. There is great urgency to make sustainable interventions now, while these built environments are being created, rather than try and change things after the fact. However, there are a number of challenges to the introduction of sustainable construction technologies and practices, and certain enablers need to be developed to help these countries adopt a more sustainable path. The Agenda 21 for Sustainable Construction in Developing Countries suggested a strategy for addressing some of these challenges by developing a Research and Development Agenda, based on a matrix of immediate, medium-term and long-term technological, institutional and value enablers. This Agenda is supported by a Stakeholder Plan for Action. The challenge now is to find the means to implement these suggestions at a local level by developing regional and national action plans. Journal: Construction Management and Economics Pages: 67-76 Issue: 1 Volume: 25 Year: 2007 Keywords: Sustainable, construction, development, developing countries, strategy, X-DOI: 10.1080/01446190600601313 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600601313 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:1:p:67-76 Template-Type: ReDIF-Article 1.0 Author-Name: Vedat Yorucu Author-X-Name-First: Vedat Author-X-Name-Last: Yorucu Author-Name: Rusen Keles Author-X-Name-First: Rusen Author-X-Name-Last: Keles Title: The construction boom and environmental protection in Northern Cyprus as a consequence of the Annan Plan Abstract: The Annan peace plan has led to a major construction boom in the Turkish Republic of Northern Cyprus (TRNC), in large part driven by speculative demand for real estate. A macroeconomic framework has been used to analyse the principal causes and impacts of the construction sector on the TRNC economy, particularly in terms of income and employment. Given that the TRNC possesses a unique and rare ecosystem in the Eastern Mediterranean, special attention is given to environmental impacts of the current construction boom, highlighting environmental costs and deficiencies in land zoning regulations. Environmental pollution as a result of rapid construction and unplanned urbanisation are also discussed and there is urgent need for rigorous environmental legislation, especially at local government level. Journal: Construction Management and Economics Pages: 77-86 Issue: 1 Volume: 25 Year: 2007 Keywords: Annan Plan, construction boom, economy, environmental ethics, X-DOI: 10.1080/01446190600902356 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600902356 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:1:p:77-86 Template-Type: ReDIF-Article 1.0 Author-Name: Jill Wells Author-X-Name-First: Jill Author-X-Name-Last: Wells Title: Informality in the construction sector in developing countries Abstract: Studies dating from the mid 1990s describe a rapid expansion of 'informal' construction activity in many parts of the developing world. This has been accompanied by increasing diversity in the interpretation of the concept, leading to considerable confusion. Through a wide review of the literature an attempt is made to bring some clarity to the debate. It is argued that the essence of informality is the absence of regulation. As construction activity is subject to a wide variety of regulations, different interpretations of informality in the construction industry are inevitable. Four aspects of regulation are highlighted: regulation of enterprises, of the terms and conditions of employment, of the process of construction and of the product. This suggests four areas of informality: the informal sector of enterprises, informal labour, the informal construction system and informal building/settlements. The four areas are frequently interrelated. But there are no hard and fast dividing lines between formal and informal, rather a gradation. Journal: Construction Management and Economics Pages: 87-93 Issue: 1 Volume: 25 Year: 2007 Keywords: Informal sector, regulation, construction, developing countries, Africa, X-DOI: 10.1080/01446190600601339 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600601339 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:1:p:87-93 Template-Type: ReDIF-Article 1.0 Author-Name: Johnny Wong Author-X-Name-First: Johnny Author-X-Name-Last: Wong Author-Name: Philco Wong Author-X-Name-First: Philco Author-X-Name-Last: Wong Author-Name: Li Heng Author-X-Name-First: Li Author-X-Name-Last: Heng Title: An investigation of leadership styles and relationship cultures of Chinese and expatriate managers in multinational construction companies in Hong Kong Abstract: Cross-cultural leadership research has predicted that the Chinese are perceived as people-oriented and prefer a high-context power relationship, whereas Westerners are perceived as task-oriented and prefer a low-context power relationship. However, such general predictions are less accurate when intercultural interactions exist in multicultural workplaces. For this reason leadership perceptions and power relationships of both Chinese and Western expatriate project managers are explored in multinational construction firms in Hong Kong. Questionnaire data from 45 project managers and 61 subordinates suggested that the local (Hong Kong) Chinese and Western expatriate managers do not differ significantly in terms of leadership perceptions and power relationships. Both manager groups equally considered the importance of task performance and interpersonal relationships. Two possibilities are proposed which lead to similar leadership and power relationship styles of managers from different cultural orientations: the 'intercultural adjustment' of expatriates, and the adaptation of Western styles of leadership by the Hong Kong Chinese project managers. Journal: Construction Management and Economics Pages: 95-106 Issue: 1 Volume: 25 Year: 2007 Keywords: China, project manager, leadership, culture, international business, X-DOI: 10.1080/01446190600632573 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600632573 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:1:p:95-106 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Gruneberg Author-X-Name-First: Stephen Author-X-Name-Last: Gruneberg Title: Performance-Based Contracting: an alternative approach to transacting in construction Abstract: Journal: Construction Management and Economics Pages: 111-112 Issue: 2 Volume: 25 Year: 2007 X-DOI: 10.1080/01446190601043119 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601043119 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:2:p:111-112 Template-Type: ReDIF-Article 1.0 Author-Name: Mei-Yung Leung Author-X-Name-First: Mei-Yung Author-X-Name-Last: Leung Author-Name: Hubert Chan Author-X-Name-First: Hubert Author-X-Name-Last: Chan Title: Antecedents of commitment in construction management Abstract: It is difficult to request that all professionals implementing a construction project have intrinsic responsibility for the whole project from planning to construction and maintenance due to the dynamic environment and the intracompany transitions. In an attempt to understand the phenomenon of commitment in the construction industry, this study seeks to identify the factors that bring about goal commitment among construction professionals. A questionnaire survey was conducted in Hong Kong. Analytical techniques including factor analysis, correlation coefficient and regression analysis, and structural equation modelling were applied to investigate the relationships among the factors and three forms of commitment. The results indicate that goal assignment and acceptance, specific goal achievement and membership maintenance in an organization are the major antecedents of (affective and normative) commitment for construction professionals. Journal: Construction Management and Economics Pages: 113-127 Issue: 2 Volume: 25 Year: 2007 Keywords: Behaviour, commitment, construction industry, professionals, X-DOI: 10.1080/01446190601061939 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601061939 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:2:p:113-127 Template-Type: ReDIF-Article 1.0 Author-Name: Ching-Hwang Wang Author-X-Name-First: Ching-Hwang Author-X-Name-Last: Wang Author-Name: Chia-Chang Tsai Author-X-Name-First: Chia-Chang Author-X-Name-Last: Tsai Author-Name: Yi-Yen Cheng Author-X-Name-First: Yi-Yen Author-X-Name-Last: Cheng Title: Knowledge-based diagnosis model for PCM executing problems in public construction Abstract: A knowledge-based diagnosis model for PCM executing problems in Taiwan public construction is proposed by using a new fuzzy-neural approach. The diagnosis model confirms the causalities of the critical executing problems. By inputting the fuzziness of semantic description of the problems in the design phase this model can deduce the corresponding influence of the problems in the construction phase. The gravity of the problem is measured by the specific lagging percentage of estimated pricing progress. Finally, the data is integrated into a database management system to facilitate application, so as to make this diagnosis model an efficient instrument for public construction management. Journal: Construction Management and Economics Pages: 129-142 Issue: 2 Volume: 25 Year: 2007 Keywords: Professional construction management, knowledge-base, fuzzy-neural approach, X-DOI: 10.1080/01446190600799091 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600799091 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:2:p:129-142 Template-Type: ReDIF-Article 1.0 Author-Name: Milan Radosavljevic Author-X-Name-First: Milan Author-X-Name-Last: Radosavljevic Author-Name: Malcolm Horner Author-X-Name-First: Malcolm Author-X-Name-Last: Horner Title: Process planning methodology: dynamic short-term planning for off-site construction in Slovenia Abstract: Planning is a vital element of project management but it is still not recognized as a process variable. Its objective should be to outperform the initially defined processes, and foresee and overcome possible undesirable events. Detailed task-level master planning is unrealistic since one cannot accurately predict all the requirements and obstacles before work has even started. The process planning methodology (PPM) has thus been developed in order to overcome common problems of the overwhelming project complexity. The essential elements of the PPM are the process planning group (PPG), including a control team that dynamically links the production/site and management, and the planning algorithm embodied within two continuous-improvement loops. The methodology was tested on a factory project in Slovenia and in four successive projects of a similar nature. In addition to a number of improvement ideas and enhanced communication, the applied PPM resulted in 32% higher total productivity, 6% total savings and created a synergistic project environment. Journal: Construction Management and Economics Pages: 143-156 Issue: 2 Volume: 25 Year: 2007 Keywords: Productivity, planning, project management, project control, X-DOI: 10.1080/01446190601026494 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601026494 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:2:p:143-156 Template-Type: ReDIF-Article 1.0 Author-Name: Goh Bee Hua Author-X-Name-First: Goh Bee Author-X-Name-Last: Hua Title: Applying the strategic alignment model to business and ICT strategies of Singapore's small and medium-sized architecture, engineering and construction enterprises Abstract: The concept of strategic alignment advocates that decisions on business strategy, information and communication technology (ICT) strategy, business infrastructure and ICT infrastructure need to be coordinated in order to better realize the benefits from ICT investments. In Singapore, there is a 10-year plan presented by the government to transform the sector of small and medium-sized enterprises (SMEs), and ICT is identified as an area for SMEs to acquire new capabilities. In this context, the strategic alignment framework is used to evaluate Singapore's small and medium-sized architecture, engineering and construction enterprises on their current practices in the ICT domain. An industry-wide postal survey, adopting the IT Barometer questionnaire and applying stratified sampling, obtained 84 responses out of a total of 754 companies contacted. Of the 84, 67 responses were further stratified by size and annual turnover, according to the SMEs definition, to allow a closer examination of each strata or class. Both qualitative and quantitative methods of analysis are used, and the main findings of the research are: (1) targeted schemes need to be set up to address the specific needs and concerns of the micro and small enterprises as distinct from those of the medium-sized enterprises pertaining to building ICT capability; (2) the two common alignment perspectives adopted by the larger 'designer' and 'builder' SMEs are 'strategy execution' and 'competitive potential'; and (3) the medium-sized 'designer' and 'builder' enterprises are shown to favour technology leadership and customer satisfaction, respectively, as their niche performance criteria for the strategic use of ICTs. Journal: Construction Management and Economics Pages: 157-169 Issue: 2 Volume: 25 Year: 2007 Keywords: Business strategy, information and communication technology strategy, strategic alignment, small and medium-sized enterprises, Singapore construction industry, X-DOI: 10.1080/01446190600827041 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600827041 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:2:p:157-169 Template-Type: ReDIF-Article 1.0 Author-Name: Perry John Forsythe Author-X-Name-First: Perry John Author-X-Name-Last: Forsythe Title: A conceptual framework for studying customer satisfaction in residential construction Abstract: A conceptual framework for studying customer satisfaction in Australian residential construction is developed using marketing theory merged with construction concepts. The framework aims to act as a stepping stone for determining how empirical data from real residential construction situations and real customers, fits marketing theory. To this end, customer satisfaction is modelled as a gap between two constructs: pre-purchase expectations and purchase perceptions. A parallel marketing concept known as the purchase decision process is used to model identifiable inputs to the two constructs, thus creating the ability to model different customer profiles. The purchase decision process is adapted to suit residential construction and can be described as: housing needs recognition, search for tenders, evaluation of competing contractors, signing of contracts, progressive construction outcomes and practical completion outcomes. The first four contribute to pre-purchase expectations and the remainder to perceptions of what is actually provided. Service quality, product quality and price are modelled as features that manifest consistently during the purchase decision process and therefore in pre-purchase expectations and purchase perceptions, as well. Future research aims to develop a grounded model of customer satisfaction in residential construction. Journal: Construction Management and Economics Pages: 171-182 Issue: 2 Volume: 25 Year: 2007 Keywords: Customer satisfaction, residential construction, house building, X-DOI: 10.1080/01446190600771439 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600771439 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:2:p:171-182 Template-Type: ReDIF-Article 1.0 Author-Name: Wei Pan Author-X-Name-First: Wei Author-X-Name-Last: Pan Author-Name: Alistair Gibb Author-X-Name-First: Alistair Author-X-Name-Last: Gibb Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Title: Perspectives of UK housebuilders on the use of offsite modern methods of construction Abstract: Despite an increasing demand for housing and wider concerns over the need to improve performance, the industry seems to be reluctant to adopt offsite technologies. Many studies have attempted to scrutinize the barriers and seek ways forward, but the perspectives of housebuilders remain unclear. UK housebuilders' views on the use of offsite modern methods of construction (offsite MMC) have been investigated. This investigation was carried out through a combination of personal interviews and a questionnaire survey of the top 100 housebuilders by unit completion. Results suggest that the traditional drivers of time, cost, quality and productivity are still driving the industry in deciding whether to use offsite technologies. Nearly two-thirds of the firms believed that there needs to be an increase in the take-up of such technologies. However, current barriers relate to a perceived higher capital cost, complex interfacing, long lead-in time and delayed planning process. Strategies recommended are centred on changing peoples' perceptions, improving procurement, providing better cost data, tackling planning and regulations, encouraging political levers and providing practical guidance. The suggestions present a model for encouraging the take-up of offsite MMC in the future. Journal: Construction Management and Economics Pages: 183-194 Issue: 2 Volume: 25 Year: 2007 Keywords: Construction methods, housebuilding, offsite production, strategy, X-DOI: 10.1080/01446190600827058 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600827058 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:2:p:183-194 Template-Type: ReDIF-Article 1.0 Author-Name: Johan Graafland Author-X-Name-First: Johan Author-X-Name-Last: Graafland Author-Name: Andre Nijhof Author-X-Name-First: Andre Author-X-Name-Last: Nijhof Title: Transparency, market operation and trust in the Dutch construction industry: an exploratory study Abstract: After the discovery of illegal price agreements in the Dutch construction industry, the government and major players in the sector have initiated a transition process towards more professional commercial relations. In the transition process transparency plays an important part, as it is a precondition for better market operation in the construction sector. However, there are significant disadvantages to a pursuit of transparency, such as higher costs and the risk of information overload. It is therefore necessary to find a good balance between more transparency and other ways to restore trust between key players in the construction sector. Especially complex products with a high degree of risk can best be dealt with through implicit contracts, in which trust is based on a mixture of the reputation mechanism, contracts that create a congruity of interests and the integrity of the contract partners. Journal: Construction Management and Economics Pages: 195-205 Issue: 2 Volume: 25 Year: 2007 Keywords: Transparency, market operation, trust, integrity, implicit contracts, X-DOI: 10.1080/01446190600830631 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600830631 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:2:p:195-205 Template-Type: ReDIF-Article 1.0 Author-Name: Bambang Trigunarsyah Author-X-Name-First: Bambang Author-X-Name-Last: Trigunarsyah Title: Project designers' role in improving constructability of Indonesian construction projects Abstract: The concept of constructability in the US evolved from studies into how improvement can be achieved to increase cost efficiency and quality in the construction industry. It is an approach that links the design and construction processes. Studies in the US, UK and Australia have demonstrated that improved constructability has led to significant savings in both cost and time required for completing construction projects. Improving projects' constructability is the responsibility of all project stakeholders. As design activities dominate the early project phases, design consultants play an important role in improving project constructability. Information has been collected on construction project designers in Indonesia in regard to constructability practice and its impact on the project performance. A questionnaire survey was carried out to collect the data, which were then analysed using descriptive and inferential statistics. The results show that project designers in Indonesia have some understanding of the importance of constructability. However, they were concerned more about preparing the design than interfacing with construction personnel. Journal: Construction Management and Economics Pages: 207-215 Issue: 2 Volume: 25 Year: 2007 Keywords: Constructability, project designers, project performance, Indonesia, X-DOI: 10.1080/01446190600830649 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600830649 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:2:p:207-215 Template-Type: ReDIF-Article 1.0 Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Title: The temporal nature of forces acting on innovative IT in major construction projects Abstract: Strategic IT implementation decisions for major construction projects in Hong Kong are subject to various forces or factors identified in previous research—such as external forces, technological factors and organizational factors. The aim of this research was to examine the relationship (if any) between these families of forces and evaluate their impact, individually and collectively. A complex combination of several families of forces/factors that affect decision making was found to be 'temporal' with respect to project teams on major projects in Hong Kong. The research was underpinned by a broad questionnaire survey to establish 'current practice' before in-depth analysis of the forces by means of a case study followed by interviews with industry leaders to confirm the results. It was found that respondents (n = 33) ordered cost, security and confidentiality as the most influential factors affecting IT implementation. A difference was found in the perceptions of 'hired-in' project-based staff in joint ventures and 'permanent staff' of single companies, the former evaluating IT performance more highly but evaluating the strategic use of, and user satisfaction with, IT significantly lower. The major constraint on IT implementation was found to be lack of budget, not cost per se. It is concluded that the temporal factors that apply to implementing innovative IT technology in project teams are relevant to different team members at different stages in the project life cycle and these factors are conditioned by a set of business conditions applying to project-specific coalition organizations that are different from those that apply to single-entity organizations. Journal: Construction Management and Economics Pages: 227-238 Issue: 3 Volume: 25 Year: 2007 Keywords: Innovative IT, adoption factors, electronic communications, temporal nature of projects, X-DOI: 10.1080/01446190600953698 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600953698 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:3:p:227-238 Template-Type: ReDIF-Article 1.0 Author-Name: Joseph Gaiva Kappia Author-X-Name-First: Joseph Gaiva Author-X-Name-Last: Kappia Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: Andrew Price Author-X-Name-First: Andrew Author-X-Name-Last: Price Title: Prioritising career development in relation to recruitment and retention: a trade and craft perspective Abstract: Individuals attach a certain priority to key extrinsic and intrinsic work-related factors, namely: career development, financial incentives, work conditions, job content, job security and social relations. These factors have variously been described as influencing career choice and also determining what causes individuals to remain or leave careers. In particular, the ongoing skills crisis faced by the UK construction sector has raised the profile of career development as a factor to recruiting and retaining an appropriately skilled workforce. The priorities attached to career development and other work-related factors were explored via a questionnaire survey of over 550 craft trainees. Their relative priorities were validated through a set of focused discussions in which informants disclosed the reasons underlying their preference, and their wider perceptions of the industry. Results reveal that, contrary to anecdotal suggestions, craft workers are not purely motivated by monetary reward. Trainees aspired to develop their career beyond the confines of their specific craft specialization. However, further results suggest that available career development opportunities do not provide suitable transitional routes towards managerial and professional positions. This raises questions as to whether the industry will be able to attract and retain workers in the future without improving career pathways. Journal: Construction Management and Economics Pages: 239-253 Issue: 3 Volume: 25 Year: 2007 Keywords: Human resource management, occupation, craft, workforce, careers, X-DOI: 10.1080/01446190600863145 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600863145 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:3:p:239-253 Template-Type: ReDIF-Article 1.0 Author-Name: Ingrid Meintjes Author-X-Name-First: Ingrid Author-X-Name-Last: Meintjes Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Author-Name: David Root Author-X-Name-First: David Author-X-Name-Last: Root Title: HIV/AIDS in the South African construction industry: understanding the HIV/AIDS discourse for a sector-specific response Abstract: HIV/AIDS is a pandemic with serious implications for South Africa in general, and the South African construction industry in particular. It is the single largest cause of death in South Africa. Against a backdrop of an acute shortage of housing and infrastructure provision, the prevalence of HIV/AIDS among construction workers is impacting negatively on the delivery capacity of the industry. The construction sector is uniquely vulnerable to the pandemic but there is limited industry-specific research available. Industry-specific interventions are limited to 'awareness' initiatives at project level. Political ambivalence is a major stumbling block. The institutional audit methodology is used to examine the impact of HIV/AIDS on the construction industry as a whole. This examination is conducted within the prevailing political context within which the industry operates. The construction sector urgently needs to develop mechanisms to manage the impact of the HIV/AIDS pandemic so that anticipated industry growth is not compromised by the economic, systemic and social impacts of the disease. In South Africa, the CIDB should provide more effective leadership; legislation is required to compel the universal adoption of HIV/AIDS programmes; and a change is needed in the mindset of key role players in the construction industry. Journal: Construction Management and Economics Pages: 255-266 Issue: 3 Volume: 25 Year: 2007 Keywords: HIV/AIDS, health care, site operatives, construction sector, South Africa, X-DOI: 10.1080/01446190601071813 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601071813 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:3:p:255-266 Template-Type: ReDIF-Article 1.0 Author-Name: Florence Yean Yng Ling Author-X-Name-First: Florence Yean Yng Author-X-Name-Last: Ling Author-Name: Denise Hui Ying Kwok Author-X-Name-First: Denise Hui Ying Author-X-Name-Last: Kwok Title: Enablers for Singapore contractors to internationalize construction services Abstract: With international trade liberalization, construction firms are expected to export their services to ensure continued growth. Some firms have been successful in the international arena, while many are still struggling to gain a foothold outside their domestic markets. The characteristics of construction firms that enable them to secure contracts outside their home countries are investigated. The characteristics of exporters and non-exporters are compared. Detailed characteristics of 60 exporters and 60 non-exporters were obtained from the database of registered contractors in Singapore. Significant variables that correlate with the number and value of international projects were identified. In order to win more overseas projects, firms should be well established, have stronger financial capability and have continued operations in the home market. When exporting, firms should be willing to play the role of both main and subcontractors, have the capability to handle different types of projects and venture into several geographical locations. Several differences between exporters and non-exporters based in Singapore are identified. Exporting firms are more likely to be public listed firms, and larger firms with higher paid up capital. Non-exporters are more likely to be principal contractors who are handling a wide variety of projects. Firms that want to export their services would need to develop their financial strength, and offer niche products or services. Journal: Construction Management and Economics Pages: 267-275 Issue: 3 Volume: 25 Year: 2007 Keywords: International construction, export, construction services, construction firms, X-DOI: 10.1080/01446190600781834 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600781834 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:3:p:267-275 Template-Type: ReDIF-Article 1.0 Author-Name: Stefan Olander Author-X-Name-First: Stefan Author-X-Name-Last: Olander Title: Stakeholder impact analysis in construction project management Abstract: Construction projects attract interest from various stakeholders who express needs and expectations about the project. These are often in conflict with each other and it is unlikely that all of them can be fulfilled. The stakeholder management process involves evaluating the needs and expectations of stakeholders in relation to the main objectives of the project. An important basis for this evaluation is stakeholder analysis. The approach is based upon established theory, knowledge of stakeholder management and empirical data. The analysis consists of a stakeholder impact index to determine the nature and impact of stakeholder influence, the probability of stakeholders exercising their influence and each stakeholder's position in relation to the project—are they proponents or opponents? The analysis of the stakeholder impact index can help project managers to formalize a stakeholder management process. Journal: Construction Management and Economics Pages: 277-287 Issue: 3 Volume: 25 Year: 2007 Keywords: Project management, project stakeholders, project strategies, X-DOI: 10.1080/01446190600879125 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600879125 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:3:p:277-287 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Fox Author-X-Name-First: Stephen Author-X-Name-Last: Fox Author-Name: Jiri Hietanen Author-X-Name-First: Jiri Author-X-Name-Last: Hietanen Title: Interorganizational use of building information models: potential for automational, informational and transformational effects Abstract: Numerous potential barriers to the interorganizational use of building information models (BIMs) have been reported. These potential barriers are technological and organizational. Further, potential barriers are specific to building information models and general to the diffusion of innovation. In spite of potential barriers, there is interorganizational use of BIMs in Finland. The research was carried out in Finland, and investigated organizations' existing and planned interorganizational use of BIMs. The research revealed the potential for interorganizational use of BIMs to enable three types of effects. These are automational effects, informational effects and transformational effects. The generalizability of findings is restricted by at least three factors. First, the research involved only 20 organizations. Second, the research was carried out in one country. Third, the research participants had previously developed skills which can contribute to the interorganizational use of BIMs. Notwithstanding these limitations, consideration of findings suggests that there are few, if any, fundamental barriers to the achievement of automational, informational and/or transformational effects. Journal: Construction Management and Economics Pages: 289-296 Issue: 3 Volume: 25 Year: 2007 Keywords: Information technology, interfirm collaboration, building information model, X-DOI: 10.1080/01446190600892995 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600892995 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:3:p:289-296 Template-Type: ReDIF-Article 1.0 Author-Name: Xiao-Hua Jin Author-X-Name-First: Xiao-Hua Author-X-Name-Last: Jin Author-Name: Hemanta Doloi Author-X-Name-First: Hemanta Author-X-Name-Last: Doloi Author-Name: Shi-Yun Gao Author-X-Name-First: Shi-Yun Author-X-Name-Last: Gao Title: Relationship-based determinants of building project performance in China Abstract: The aim of this paper is to investigate the relationship-based factors that affect performance of general building projects in China. Eight performance metrics that may be used to measure the success level of construction projects are defined and categorized into two groups namely 'hard' and 'soft' performance. Eight indicators of risks inherent in relationships and seven indicators of tools expected to facilitate relationship building that may affect project success are identified. Data of different projects were collected in China via a self-administered postal survey. By using structural equation modelling techniques, a structural model is developed to help explain the relationship among different variables. It has been found that relational risk has negative influence on project performance. It is recommended that firms in the Chinese construction industry manage the relationship-based factors that are significant in the model so as to achieve project success. Journal: Construction Management and Economics Pages: 297-304 Issue: 3 Volume: 25 Year: 2007 Keywords: Relationship, risk, project performance, structural equation modelling, China, X-DOI: 10.1080/01446190600863178 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600863178 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:3:p:297-304 Template-Type: ReDIF-Article 1.0 Author-Name: Filippo Giammaria Pratico Author-X-Name-First: Filippo Giammaria Author-X-Name-Last: Pratico Title: Quality and timeliness in highway construction contracts: a new acceptance model based on both mechanical and surface performance of flexible pavements Abstract: Timely completion and high performance are becoming key factors in modern road projects, so research is needed to have reliable contracts and acceptance criteria. The goal of this paper is confined to the formalization and validation of a unique model for the determination of pay adjustment on the basis of both quality (mechanical and surface performance of road pavements) and timeliness. Three main topics are addressed. The first is the estimation of pay adjustment (PA, negative or positive) when both structural and non-structural deficiencies/surplus in characteristics are detected (e.g. low drainability in porous asphalt concretes). The second is the estimation of PA based on the quality of all the layers of the pavement. The third is the estimation of PA for early or late completion of the work. The formalized model is applied to an experimental case history. Analyses and validation demonstrate that the proposed model can efficiently solve typical problems in contract administration, in which decisions based upon objective criteria are needed. Journal: Construction Management and Economics Pages: 305-313 Issue: 3 Volume: 25 Year: 2007 Keywords: Quality assurance, cost, roads, contract administration, life cycle, X-DOI: 10.1080/01446190601042426 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601042426 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:3:p:305-313 Template-Type: ReDIF-Article 1.0 Author-Name: O. A. K'Akumu Author-X-Name-First: O. A. Author-X-Name-Last: K'Akumu Title: Construction statistics review for Kenya Abstract: Construction is a strategic industry in developing economies like Kenya. In order for construction to ably perform this role, there is a need to provide information on its various economic aspects including raw materials, products, processes, finance and labour. Construction statistics of Kenya have been evaluated in order to ascertain their adequacy in terms of scope, portrait, reliability and responsiveness in their coverage of the construction industry. Official statistics published in the annual Statistical Abstract were reviewed according to these adequacy criteria. The findings are that: the scope of construction statistics is narrowly defined making the statistical portrait of the sector incomplete; the statistics are also unreliable in terms of quality and unresponsive to economical challenges of inflation, structural adjustment policies and the decline of the public sector's role in the construction industry. A participatory statistical governance framework is recommended in order to improve the scope of statistics and alleviate the attendant problems, such as the incomplete portrait, that come with the narrow scope. Journal: Construction Management and Economics Pages: 315-326 Issue: 3 Volume: 25 Year: 2007 Keywords: Construction industry, national statistics, Kenya, X-DOI: 10.1080/01446190601139883 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601139883 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:3:p:315-326 Template-Type: ReDIF-Article 1.0 Author-Name: Ranko Bon Author-X-Name-First: Ranko Author-X-Name-Last: Bon Title: In response to the festschrift: a letter to Construction Management and Economics Abstract: Journal: Construction Management and Economics Pages: 341-343 Issue: 4 Volume: 25 Year: 2007 X-DOI: 10.1080/01446190701313776 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701313776 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:4:p:341-343 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Clare Lingard Author-X-Name-First: Helen Clare Author-X-Name-Last: Lingard Author-Name: Brenda Yip Author-X-Name-First: Brenda Author-X-Name-Last: Yip Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Author-Name: Thomas Kvan Author-X-Name-First: Thomas Author-X-Name-Last: Kvan Title: The experience of burnout among future construction professionals: a cross-national study Abstract: A survey of undergraduate students in Australia and Hong Kong revealed that a specially adapted version of the Maslach Burnout Inventory (the MBI-SS) possesses good internal consistency reliability among construction students. A three-component model of student burnout, comprising emotional exhaustion, cynicism and personal efficacy was supported in both the Australian and Hong Kong samples. Burnout levels among construction students were similar to those reported in previous non-construction student samples. Both Australian and Hong Kong construction students reported higher personal efficacy than non-construction students. Australian students expressed considerably higher cynicism in relation to their university education than the Hong Kong students. The three dimensions of burnout were differentially correlated with work, study and socio-economic variables. In Australia, student burnout was associated with a perceived tension between paid work and study. In Hong Kong, the demands of study and concern with the economy were significant correlates of student burnout. Journal: Construction Management and Economics Pages: 345-357 Issue: 4 Volume: 25 Year: 2007 Keywords: Burnout, work-study conflict, stress, higher education, culture, X-DOI: 10.1080/01446190600599145 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600599145 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:4:p:345-357 Template-Type: ReDIF-Article 1.0 Author-Name: Ka-Chi Lam Author-X-Name-First: Ka-Chi Author-X-Name-Last: Lam Author-Name: Xin Ning Author-X-Name-First: Xin Author-X-Name-Last: Ning Author-Name: Thomas Ng Author-X-Name-First: Thomas Author-X-Name-Last: Ng Title: The application of the ant colony optimization algorithm to the construction site layout planning problem Abstract: A good site layout is vital to ensure the safety of the working environment, and for effective and efficient operations. Moreover, it minimizes travel distance, decreases materials handling, and avoids the obstruction of materials and plant movement. Based on studies in the manufacturing industry, the cost of materials handling could be reduced by 20-60% if an appropriate facility layout is adopted. In designing a site layout, a planner will first position the key facilities that influence the method and sequence of construction, and then assign the remaining facilities in the available space that is left over. This process is similar to the positioning of facilities in the ant colony optimization (ACO) algorithm. The general principle of the ACO algorithm is to assign facilities to a location one by one, and the occupied locations are deleted from the location scope in the next assignment. In the study, ACO algorithm is employed to resolve the construction site layout planning problem in a hypothetical medium-sized construction project. By applying fuzzy reasoning and the entropy technique, the study calculates the closeness relationship between facilities, in which the optimal site layout is affected by the mutual interaction of facilities. Journal: Construction Management and Economics Pages: 359-374 Issue: 4 Volume: 25 Year: 2007 Keywords: ACO algorithm, site layout, heuristic, closeness relationship, X-DOI: 10.1080/01446190600972870 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600972870 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:4:p:359-374 Template-Type: ReDIF-Article 1.0 Author-Name: Paul W. Chan Author-X-Name-First: Paul W. Author-X-Name-Last: Chan Author-Name: Andrew R. J. Dainty Author-X-Name-First: Andrew R. J. Author-X-Name-Last: Dainty Title: Resolving the UK construction skills crisis: a critical perspective on the research and policy agenda Abstract: The ongoing skills crisis in the UK construction industry has constrained the productive capacity of the industry. Past research and skills policies have largely failed to develop an understanding of the realities of the skills crisis at the grassroots level. Solutions offered by researchers and policy makers have previously had little demonstrable impact in addressing skills concerns. Much of these policies seems disconnected from the realities experienced by employers and by those working in the industry. A critical perspective on resolving the skills crisis is offered. A set of mutually reinforcing research and policy initiatives are proposed, including the need for researchers and policy makers to move away from the conventionally national approach in addressing the skills problem and to engage in genuine, joined-up thinking that meets the needs of local regions. Furthermore, employers and employees are called to be reflective practitioners in their participation of the skills development agenda. Adopting these recommendations could overcome many shortcomings in research and policy that have hitherto done little to combat the construction skills crisis. Journal: Construction Management and Economics Pages: 375-386 Issue: 4 Volume: 25 Year: 2007 Keywords: Skills shortages, critical perspective, bottom-up approach, labour market, research, X-DOI: 10.1080/01446190600863152 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600863152 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:4:p:375-386 Template-Type: ReDIF-Article 1.0 Author-Name: Bee-Lan Oo Author-X-Name-First: Bee-Lan Author-X-Name-Last: Oo Author-Name: Derek S. Drew Author-X-Name-First: Derek S. Author-X-Name-Last: Drew Author-Name: H. P. Lo Author-X-Name-First: H. P. Author-X-Name-Last: Lo Title: Applying a random coefficients logistic model to contractors' decision to bid Abstract: Contractors' decision to bid is dependent on many individual characteristics, including some that are unobservable by their competitors. There is natural heterogeneity across contractors in terms of their (i) intrinsic bid/no-bid preferences; and (ii) responses to decision to bid factors. This heterogeneity can be accounted for by applying a random coefficients approach to multiple bid/no-bid responses through logistic modelling. The bid/no-bid data were collected from managers of large and medium-sized contractors in Hong Kong via a designed bidding experiment. Two random coefficients logistic models are developed. Model 1 considers only two groups of decision to bid factors, namely market environment factors (i.e. number of bidders, market conditions) and project-specific factors (i.e. type and size of project). Model 2 extends Model 1 by adding two subject factors (i.e. years of experience, firm size) to study the effect of these individual factors on decision to bid. The results show that there is significant unobserved heterogeneity across contractors and that ignoring its effect results in a downward bias in the parameter estimates of the decision to bid factors. In using this approach contractors can better account for unobserved characteristics of their competitors when formulating their competitive strategies in deciding to bid. Journal: Construction Management and Economics Pages: 387-398 Issue: 4 Volume: 25 Year: 2007 Keywords: Decision making, bidding, logistic modelling, X-DOI: 10.1080/01446190600922552 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600922552 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:4:p:387-398 Template-Type: ReDIF-Article 1.0 Author-Name: Kate Carter Author-X-Name-First: Kate Author-X-Name-Last: Carter Author-Name: Chris Fortune Author-X-Name-First: Chris Author-X-Name-Last: Fortune Title: Sustainable development policy perceptions and practice in the UK social housing sector Abstract: Massive investment has been allocated by the UK government to improve the quality of its programme of rented social housing over the next five years. Central to the achievement of this aim will be the incorporation of sustainability features within the building projects associated with this development programme. A sustainable development policy that addresses environment, economy and society in equal measure is a new funding requirement for social housing projects. There is a gap between policy and practice in two areas: (i) the possession or otherwise of a sustainable development (SD) policy; and (ii) the relative importance given to differing features of sustainability. The perceptions and practice of built environment professionals involved in the procurement of sustainable housing schemes has been gauged regarding SD policy. Quantitative data were collected from a randomized sample of 338 developing registered social landlords (RSLs). The results show that only a minority of respondent organizations have developed a sustainable development policy and that environmental, economical and societal aspects of sustainability are not given equal weighting. This does not reflect governmental policy and suggests that sustainability is not being fully addressed in the procurement of social housing projects. Further work is needed to evaluate the links between sustainability and procurement approaches, and to model the benefits of delivering sustainable housing projects for RSLs in the UK. Journal: Construction Management and Economics Pages: 399-408 Issue: 4 Volume: 25 Year: 2007 Keywords: Sustainability, housing development, policy, housing associations, X-DOI: 10.1080/01446190600922578 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600922578 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:4:p:399-408 Template-Type: ReDIF-Article 1.0 Author-Name: Kumar Neeraj Jha Author-X-Name-First: Kumar Neeraj Author-X-Name-Last: Jha Author-Name: Sudhir Misra Author-X-Name-First: Sudhir Author-X-Name-Last: Misra Title: Ranking and classification of construction coordination activities in Indian projects Abstract: The efforts of contractors, consultants and owners need to be appropriately coordinated in large civil engineering projects, whose success can be defined in terms of compliance to schedule, economy in cost, adherence to quality, and non-occurrence of disputes. Based on the hypothesis that coordination activities affect the different dimensions of project success differently, and that different stakeholders prioritize the activities differently, a questionnaire survey covering senior Indian construction professionals was carried out. For this a list of 59 coordination activities influencing successful completion of a construction project was drawn up. These coordination activities were ranked for the four success dimensions using statistical tools on the responses received. 'Regular monitoring of critical path activities'; 'monitoring the budget on all activities and taking corrective action'; 'application of sound technical practices'; 'implementation of all contractual commitments' are the most important coordination activities corresponding to schedule, cost, quality and no-dispute performance criteria, respectively. Results show that project coordination issues can be addressed by attending to essentially the four broad groups of coordination activities—resource handling, planning, team building and contract implementation. Findings presented in the paper could interest construction professionals and help them identify and concentrate on important coordination activities. Journal: Construction Management and Economics Pages: 409-421 Issue: 4 Volume: 25 Year: 2007 Keywords: Coordination, project performance, project management, questionnaire, X-DOI: 10.1080/01446190601083271 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601083271 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:4:p:409-421 Template-Type: ReDIF-Article 1.0 Author-Name: Jake Olsen Author-X-Name-First: Jake Author-X-Name-Last: Olsen Author-Name: Zu-Hsu Lee Author-X-Name-First: Zu-Hsu Author-X-Name-Last: Lee Author-Name: Wenshen Pong Author-X-Name-First: Wenshen Author-X-Name-Last: Pong Title: Optimal selection of concrete anchors for connection cost reduction Abstract: A proprietary product such as a post-installed concrete anchor has a unique place in the engineering community that includes product design, manufacturing, testing, evaluation and design for expected service conditions. An economic model in a non-linear integer programming form is proposed for selection of concrete anchors in order to minimize connection cost. It is shown that the model can be easily incorporated with available computer software packages and generalized when different parameters and constraints are imposed to handle a variety of material selections. The information from recent testing conducted by CEL Consulting for a major engineering, procurement and construction (EPC) contractor is used to provide computational results. The method introduced here adds practical value to these types of industrial problems because it considers points of view from both structural engineers and project managers. Journal: Construction Management and Economics Pages: 423-434 Issue: 4 Volume: 25 Year: 2007 Keywords: Structural design, optimization, cost, computer-aided design, civil engineering, anchorages, X-DOI: 10.1080/01446190601156119 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601156119 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:4:p:423-434 Template-Type: ReDIF-Article 1.0 Author-Name: John Kelly Author-X-Name-First: John Author-X-Name-Last: Kelly Title: Making client values explicit in value management workshops Abstract: Value management is a project-focused process that makes explicit and appraises the functional benefits of a product, process or service consistent with a value system determined by the client. The value system of the client necessarily requires a method for value setting using harder performance variables than the commonly described facets of time, cost and quality. Current value theory is critically appraised in the context of current value management practice. The research proposition is that the constituent parts of time, cost and quality can be made overt enabling a client to express satisfaction in terms of a finite number of variables enabling the explicit statement of client value within a value management workshop. An action research study into the discovery of the component parts of the client's value system at the early stages of construction projects concludes that the variables are the nine non-correlated, high order, discretionary performance variables of capital expenditure, operational expenditure, time, esteem, environment, exchange, politics/community, flexibility and comfort. Journal: Construction Management and Economics Pages: 435-442 Issue: 4 Volume: 25 Year: 2007 Keywords: Value management, client, function analysis, quality, value, X-DOI: 10.1080/01446190601071839 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601071839 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:4:p:435-442 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Franco K. T. Cheung Author-X-Name-First: Franco K. T. Author-X-Name-Last: Cheung Title: Explorations in specifying construction price forecast loss functions Abstract: Typical measures of goodness of construction price forecasts are the mean and standard deviation, coefficient of variation and root mean square of the deviations between forecasted and actual values. This can only be valid, however, if the pain, or loss, incurred as a result of such deviations is directly proportional to the square of their value. Two approaches are used to test this. The first of these analyses 10 sets of data collected from around the world, while the second explores the use of a postal questionnaire survey to elicit construction industry client disutilities. The results of the first analysis mitigate against any general view that projects tend to be overestimated but do clearly suggest asymmetric under/overestimates for the measures used. The second analysis results in an approximated loss function although in ordinal terms only. This also suggests that the functional form varies between building types, with Commercial and Residential being the most asymmetric and Schools and Industrial being less asymmetric. The work to date indicates that, for construction price forecasting, the loss functions involved are asymmetric, with the degree of asymmetry increasing according to the level of commercial financial viability at stake. Journal: Construction Management and Economics Pages: 449-465 Issue: 5 Volume: 25 Year: 2007 Keywords: Loss functions, construction, price, forecasts, forecasting, specification, estimate errors, X-DOI: 10.1080/01446190600794571 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600794571 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:5:p:449-465 Template-Type: ReDIF-Article 1.0 Author-Name: Kristian Widen Author-X-Name-First: Kristian Author-X-Name-Last: Widen Author-Name: Bengt Hansson Author-X-Name-First: Bengt Author-X-Name-Last: Hansson Title: Diffusion characteristics of private sector financed innovation in Sweden Abstract: Although construction is considered to be slow in adopting new technology and new processes, innovation, research and development are performed routinely. Nonetheless, knowledge about what affects the diffusion of research results—in the context of innovations—is incomplete, limiting the effectiveness of procedures designed to evaluate project proposals. The aim is to examine the factors that can influence the diffusion of results, in this case from externally funded construction innovation projects. A Fisher's exact test is performed on six concepts derived from general innovation theory which are tested on 20 development projects. The test is used to establish the significance of the six concepts and their applicability to construction-related innovation. The results reveal support for all six concepts, although only four of them attract a high level of significance. External lateral and vertical communication and external integration during the development phase are shown to increase the chances of successful diffusion and should therefore be assessed in project proposals. Journal: Construction Management and Economics Pages: 467-475 Issue: 5 Volume: 25 Year: 2007 Keywords: Innovation theory, construction innovation, development, diffusion, adoption, X-DOI: 10.1080/01446190601089104 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601089104 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:5:p:467-475 Template-Type: ReDIF-Article 1.0 Author-Name: Chris Harty Author-X-Name-First: Chris Author-X-Name-Last: Harty Author-Name: Chris Ian Goodier Author-X-Name-First: Chris Ian Author-X-Name-Last: Goodier Author-Name: Robby Soetanto Author-X-Name-First: Robby Author-X-Name-Last: Soetanto Author-Name: Simon Austin Author-X-Name-First: Simon Author-X-Name-Last: Austin Author-Name: Andrew R. J. Dainty Author-X-Name-First: Andrew R. J. Author-X-Name-Last: Dainty Author-Name: Andrew D. F. Price Author-X-Name-First: Andrew D. F. Author-X-Name-Last: Price Title: The futures of construction: a critical review of construction future studies Abstract: Anticipating the future is increasingly being seen as a useful way to align, direct and improve current organizational strategy. Several such 'future studies' have been produced which envision various construction industry scenarios which result from technological and socio-economic trends and influences. Thirteen construction-related future studies are critically reviewed. Most studies fail to address the complexities and uncertainties of both the present and the future, and fail to explore the connections between global, local, construction-specific and more widespread factors. The methodological approaches used in these studies do not generate any significantly different advice or recommendations for the industry than those emerging from the much larger canon of non-future oriented construction research. As such, these reports are less about the future than the present. If future studies are to make a worthwhile contribution to construction, it is critical that they develop our appreciation of the practical ability of stakeholders to influence some aspects of the future and not others, and an awareness of the competing agendas and the relative benefits and disadvantages of specific futures within the construction sector. Only then can future studies provide insights and help in preparing for the opportunities and threats the future may bring. Journal: Construction Management and Economics Pages: 477-493 Issue: 5 Volume: 25 Year: 2007 Keywords: Future studies, scenarios, construction, X-DOI: 10.1080/01446190600879117 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600879117 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:5:p:477-493 Template-Type: ReDIF-Article 1.0 Author-Name: Iain Cameron Author-X-Name-First: Iain Author-X-Name-Last: Cameron Author-Name: Roy Duff Author-X-Name-First: Roy Author-X-Name-Last: Duff Title: A critical review of safety initiatives using goal setting and feedback Abstract: A review and synthesis of behavioural safety literature identified three behaviour change perspectives: cognitive (goal setting); behaviourist (behaviour modification); and eclectic (social learning). Bandura's social learning theory usefully integrates the divergent philosophies of Locke's goal setting and Luthan's behaviour modification. Social learning theory assumes that behaviour is controlled by internal processes and environmental stimuli, and so human action can be explained by the combined effect of goals and feedback. The effectiveness of behavioural safety has been demonstrated consistently, but, despite some success, token reward programmes are controversial because they are close to 'paying for safety'. Researchers have overwhelmingly favoured initiatives based on goals and performance feedback without material reward. Goals and feedback produced good results in the varying cultures of North American, European and Middle-East manufacturing environments, including mines, chemical plants, laboratories, paper mills and shipyards. Goals and feedback, aimed principally at operatives, have been used to improve safety in Finnish, British and Hong Kong construction industries. It is also clear that their effectiveness is strongly related to management commitment; and that they must be supported by a developed safety infrastructure. This suggests that goals should also embrace management safety behaviours, in order to improve management commitment. Journal: Construction Management and Economics Pages: 495-508 Issue: 5 Volume: 25 Year: 2007 Keywords: Safety, organizational psychology, organizational behaviour, X-DOI: 10.1080/01446190701275173 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701275173 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:5:p:495-508 Template-Type: ReDIF-Article 1.0 Author-Name: Najat Abdallah Krima Author-X-Name-First: Najat Abdallah Author-X-Name-Last: Krima Author-Name: Gerard Wood Author-X-Name-First: Gerard Author-X-Name-Last: Wood Author-Name: Ghassan F. Aouad Author-X-Name-First: Ghassan F. Author-X-Name-Last: Aouad Author-Name: Zedan Hatush Author-X-Name-First: Zedan Author-X-Name-Last: Hatush Title: Assessing the performance of Libyan supervising engineers Abstract: In the Libyan construction industry, the supervising engineer plays an important role in checking time schedules and protecting the client from delays and associated claims but there is no existing means of determining their proficiency in performing this task. A list of factors identifying a broad range of characteristics and skills necessary for the effective supervision of construction projects is compiled. A field survey comprising semi-structured interviews and questionnaires with 32 client and contractor project managers experienced in the Libyan construction sector is undertaken. The responses are used to develop a method of assessing the effectiveness of supervising engineers in dealing with construction project delays through a set of weighted criteria which are scored according to currently perceived levels of performance. The results indicate that Libyan supervising engineers are currently deficient in a number of areas, particularly communication skills (33%); obtained scientific, technical and legal knowledge (34%); knowledge in dealing with claims (36%); previous experience (37%); knowledge and use of modern techniques (37%). These factors are therefore a key focus for the professional development needs of supervising engineers and the method of assessment should assist clients in the process of selection and appointment. Journal: Construction Management and Economics Pages: 509-518 Issue: 5 Volume: 25 Year: 2007 Keywords: Supervision, delay, performance evaluation, project control, Libya, X-DOI: 10.1080/01446190701247883 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701247883 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:5:p:509-518 Template-Type: ReDIF-Article 1.0 Author-Name: James Robert Mason Author-X-Name-First: James Robert Author-X-Name-Last: Mason Title: The views and experiences of specialist contractors on partnering in the UK Abstract: The views and experiences of specialist contractors on partnering have to date received insufficient attention in the UK where the focus has been centred on the client-main contractor relationship. An investigation into the position of specialists brings a new perspective on the national and international debate about how further steps towards partnering the supply chain can be achieved and whether they are desirable. Some of the findings are positive such as the high level of understanding of partnering concepts among specialists. There are examples of successful collaborations and evidence of informal partnering being continued downstream of the specialist contractors, often irrespective of whether upstream partnering is occurring or not. Practical issues about involvement and some cynicism about the aims of partnering are also detectable. The discussion recommends that greater emphasis should be placed on the role of the client and the competitive advantage available to all through the proper use of partnering. Despite positive developments little has changed in the 10 years since partnering was introduced to improve the lot of the specialist contractor in terms of the levels of disputes and the incidence of long-term collaboration. Journal: Construction Management and Economics Pages: 519-527 Issue: 5 Volume: 25 Year: 2007 Keywords: Collaboration, partnering, procurement, specialist contractors, subcontractors, X-DOI: 10.1080/01446190701326828 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701326828 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:5:p:519-527 Template-Type: ReDIF-Article 1.0 Author-Name: Ahmed M. Abdel Aziz Author-X-Name-First: Ahmed M. Abdel Author-X-Name-Last: Aziz Title: A survey of the payment mechanisms for transportation DBFO projects in British Columbia Abstract: In traditional project delivery systems, payment mechanisms provide compensation for the work performed using construction capital payments. In the alternative public-private partnership (PPP) systems, payment mechanisms follow the selected PPP system. For example, the build-operate-transfer system provides compensation based on project demand using real-tolls usage payments; the design-build-finance-operate (DBFO) system provides shadow-tolls usage payments; and the performance-based DBFO system provides compensation based on contractor's performance using service availability payments. Designing the payment structure is an important task where several factors have to be considered. This paper analyses the implementation of payment mechanisms in a number of DBFO transportation projects in BC, Canada, in terms of payment structure, payment types and characteristics, determination and funding. The analysis provides insights for the design of payment mechanisms. The analysis shows that more payment types are being used and that the mechanisms are designed to achieve specific government objectives. The analysis refers to a new 'hybrid' payment mechanism with elements derived from the traditional and the PPP systems. The hybrid system may have potential to minimize the overall project cost; however, agencies have to be flexible in the delivery concepts as combinations of payments for inputs, usage and services might have to be used. Journal: Construction Management and Economics Pages: 529-543 Issue: 5 Volume: 25 Year: 2007 Keywords: Contracting, infrastructure, payment mechanism, project delivery, DBFO, X-DOI: 10.1080/01446190601161465 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601161465 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:5:p:529-543 Template-Type: ReDIF-Article 1.0 Author-Name: Hsiuyu Tsai Author-X-Name-First: Hsiuyu Author-X-Name-Last: Tsai Author-Name: Lungchang Wang Author-X-Name-First: Lungchang Author-X-Name-Last: Wang Author-Name: Leekuo Lin Author-X-Name-First: Leekuo Author-X-Name-Last: Lin Title: A study on improving the ranking procedure for determining the most advantageous tender Abstract: According to the rules of the current Government Procurement Law in Taiwan, the most advantageous tender is often determined based on the sum of ranks among all tenders. This method is criticized, however, for its violating the basic propositions of the measurement theory, being easily biased by a few members in the evaluation Committee, and lack of distinct bases to discriminate the evaluation differences among the Committee members. The improved procedure suggested in this study, which is based on fuzzy relations and adopts eigenvector method, conforms to the judgment principles as well as the measurement theory. With analysis of a procurement case, the results demonstrate that the improved procedure is able to use quantitative methods to identify the evaluation differences among individual Committee members. Therefore, this improved procedure may enhance the quality in determining the most advantageous tender. Journal: Construction Management and Economics Pages: 545-554 Issue: 5 Volume: 25 Year: 2007 Keywords: Procurement, tendering, committee, ranking method, group decision, X-DOI: 10.1080/01446190601139925 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601139925 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:5:p:545-554 Template-Type: ReDIF-Article 1.0 Author-Name: Kamardeen Imriyas Author-X-Name-First: Kamardeen Author-X-Name-Last: Imriyas Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Author-Name: Evelyn Ai-Lin Teo Author-X-Name-First: Evelyn Ai-Lin Author-X-Name-Last: Teo Title: A framework for computing workers' compensation insurance premiums in construction Abstract: Singapore's general insurers have been recording detrimental loss ratios in workers' compensation insurance business for construction projects. This is due to the ineffectiveness in the risk assessment for premium-rating and the failure of contractors to provide adequate safety measures with an increased reliance on the workers' compensation insurance. Based on the findings of an extensive literature review and an interview questionnaire survey in the general insurance industry of Singapore, a new premium-rating framework is proposed. The proposed new premium-rating framework facilitates structured assessments of risks in construction projects and market conditions to derive optimal premiums. It also establishes an effective risk control strategy via a well-structured incentive system for contractors and clients. The implementation of the framework in the general insurance industry can facilitate accident control in the construction industry and thereby minimize insurers' financial risks. Journal: Construction Management and Economics Pages: 563-584 Issue: 6 Volume: 25 Year: 2007 Keywords: Insurance, operatives, injury, safety, X-DOI: 10.1080/01446190601110116 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601110116 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:6:p:563-584 Template-Type: ReDIF-Article 1.0 Author-Name: Chris Goodier Author-X-Name-First: Chris Author-X-Name-Last: Goodier Author-Name: Alistair Gibb Author-X-Name-First: Alistair Author-X-Name-Last: Gibb Title: Future opportunities for offsite in the UK Abstract: Practitioners' views and opinions on the benefits and drawbacks of offsite technologies in the UK construction industry can vary widely, often depending upon their role or position. This research provides an indication of the opinions of the different sectors within the industry, including clients, designers, contractors and offsite suppliers, together with some predictions for the future growth of the offsite sector in the UK. A questionnaire survey of UK construction was conducted in order to target the three main construction industry sectors—suppliers/manufacturers, contractors and designers/clients. More than 80 questionnaires were completed and returned. The vast majority of practitioners within the industry are aware of the possibilities and potential of offsite, and most also understand the advantages and disadvantages of its use. The value of the UK offsite market was valued at £2.2bn in 2004 and the demand for offsite is clearly increasing, but it is not always clear in a project who is the main driver for its use. For the offsite market to develop further however, two main problems need to be addressed; the lack of transparent information for the decision makers in the construction process, particularly that relating to comparative costs, and the lack of available multi-skilled labour to work in the offsite factories. Journal: Construction Management and Economics Pages: 585-595 Issue: 6 Volume: 25 Year: 2007 Keywords: Future studies, offsite production, prefabrication, standardization, X-DOI: 10.1080/01446190601071821 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601071821 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:6:p:585-595 Template-Type: ReDIF-Article 1.0 Author-Name: David Joaquin Delgado-Hernandez Author-X-Name-First: David Joaquin Author-X-Name-Last: Delgado-Hernandez Author-Name: Katherine Elizabeth Bampton Author-X-Name-First: Katherine Elizabeth Author-X-Name-Last: Bampton Author-Name: Elaine Aspinwall Author-X-Name-First: Elaine Author-X-Name-Last: Aspinwall Title: Quality function deployment in construction Abstract: Quality function deployment (QFD) is a system for translating customer requirements (government regulations, operating conditions and buyer expectations) into suitable technical characteristics and ensuring that important ones are prioritized in the design. The method has been successfully applied in the manufacturing sector; however, its benefits have not yet been fully realized in construction. The House of Quality (HoQ), the most common 'tool' in QFD, has been used to identify and analyse customer requirements for a new children's nursery. A focus group was formed to gather these and a comparison made between an existing nursery and two competitors to ensure that the new build was designed to be at least as good as its competition. The results showed that QFD could be applied in construction projects as a tool for considering the most important customer requirements from the outset, with favourable indicators of project success (on-time delivery and customer satisfaction). In addition, the case study company considered it to be an innovative approach and has used the results in its designs. Journal: Construction Management and Economics Pages: 597-609 Issue: 6 Volume: 25 Year: 2007 Keywords: Case study, quality function deployment, total quality management, X-DOI: 10.1080/01446190601139917 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601139917 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:6:p:597-609 Template-Type: ReDIF-Article 1.0 Author-Name: Caroline T. W. Chan Author-X-Name-First: Caroline T. W. Author-X-Name-Last: Chan Title: Fuzzy procurement selection model for construction projects Abstract: Recent developments in procurement selection systems are reviewed and this reveals contradiction and conflict with previous work. A mathematical rank model called fuzzy procurement selection model (FPSM) is proposed to adapt to local circumstances. FPSM can be modified according to local conditions or requirements and the modification methods are well documented in previous work. The proposed model overcomes the continual arguments on establishing a set of universal criteria on procurement selection systems and provides a useful tool to cope with different project/client's requirements. Journal: Construction Management and Economics Pages: 611-618 Issue: 6 Volume: 25 Year: 2007 Keywords: Procurement, selection criteria, fuzzy logic, X-DOI: 10.1080/01446190701209933 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701209933 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:6:p:611-618 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Hedley Smyth Author-X-Name-First: Hedley Author-X-Name-Last: Smyth Title: Pricing construction work: a marketing viewpoint Abstract: Recent work on pricing has shown that neoclassical microeconomic theory (NCMT) is preferred to tendering theory and that implied by absorption, or full-cost, pricing of construction work because of its explicit treatment of market conditions, competitor behaviour and firm capacity levels. Applying NCMT in practice, however, requires the consideration of pricing from a marketing perspective. This paper examines the challenges involved in terms of the two prevalent marketing paradigms—marketing mix and relationship marketing—to pricing construction work generally, and the traditional contracting (TC), design and construction (D&C) and speculative building (SB) procurement systems in particular. In general, the marketing mix (MM) approach, having the closest fit with NCMT, is most aligned to current practice. However, conceptual and practical limitations are identified. Relationship marketing (RM) is theoretically more applicable, yet has been largely overlooked in practice due to the transaction costs and investment involved. Nevertheless, some RM tools are increasingly being adopted in response to demand criteria and clients' needs for continuous improvement, offering a challenge to NCMT-related pricing. In terms of specific procurement arrangements, SB would seem most suited to the MM approach over the long term as it is closest to consumer good markets. D&C on the other hand is considered to be the most price sensitive to demand factors, with SB the least because of its ability to control resources, specifically land and financial packages, while TC is most suited to developing RM practices. Journal: Construction Management and Economics Pages: 619-630 Issue: 6 Volume: 25 Year: 2007 Keywords: Marketing, marketing mix, pricing policies, relationship marketing, X-DOI: 10.1080/01446190701280710 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701280710 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:6:p:619-630 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Author-Name: Akintola Akintoye Author-X-Name-First: Akintola Author-X-Name-Last: Akintoye Author-Name: Robert Pearl Author-X-Name-First: Robert Author-X-Name-Last: Pearl Author-Name: Peter J. Edwards Author-X-Name-First: Peter J. Author-X-Name-Last: Edwards Title: Ethical behaviour in the South African construction industry Abstract: An opinion survey of South African architects, quantity surveyors, engineers and contractors regarding ethical behaviour within the construction industry reveals that South African contractors seem to possess a reputation for unethical conduct. The range of problems encountered includes collusion, bribery, negligence, fraud, dishonesty and unfair practices. While bribery in the form of payments and gifts is prevalent, fraud does not appear to be as serious a problem. Most construction professionals believe that the industry suffers from unfair tendering practices, as well as over-claiming and/or withholding payment for service delivery. Negligence arises mainly from poor documentation and poor workmanship. Incidents of collusive tendering encompass cover pricing and bid cutting by contractors, while the primary form of fraudulent behaviour is deceit and misinformation. The Organisation for Economic Co-operation and Development's bribery codes conditions could be used to counter unethical behaviour in the construction industry. Journal: Construction Management and Economics Pages: 631-648 Issue: 6 Volume: 25 Year: 2007 Keywords: Corruption, codes of conduct, professional ethics, business ethics, South Africa, X-DOI: 10.1080/01446190701225707 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701225707 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:6:p:631-648 Template-Type: ReDIF-Article 1.0 Author-Name: Stuart D. Green Author-X-Name-First: Stuart D. Author-X-Name-Last: Green Author-Name: Anita M. M. Liu Author-X-Name-First: Anita M. M. Author-X-Name-Last: Liu Title: Theory and practice in value management: a reply to Ellis et al. (2005) Abstract: The constructivist model of 'soft' value management (VM) is contrasted with the VM discourse appropriated by cost consultants who operate from within UK quantity surveying (QS) practices. The enactment of VM by cost consultants is shaped by the institutional context within which they operate and is not necessarily representative of VM practice per se. Opportunities to perform VM during the formative stages of design are further constrained by the positivistic rhetoric that such practitioners use to conceptualize and promote their services. The complex interplay between VM theory and practice is highlighted and analysed from a non-deterministic perspective. Codified models of 'best practice' are seen to be socially constructed and legitimized through human interaction in the context of interorganizational networks. Published methodologies are seen to inform practice in only a loose and indirect manner, with extensive scope for localized improvization. New insights into the relationship between VM theory and practice are derived from the dramaturgical metaphor. The social reality of VM is seen to be constituted through scripts and performances, both of which are continuously contested across organizational arenas. It is concluded that VM defies universal definition and is conceptualized and enacted differently across different localized contexts. Journal: Construction Management and Economics Pages: 649-659 Issue: 6 Volume: 25 Year: 2007 Keywords: Diffusion, best practice, value management, methodological decay, dramaturgical metaphor, X-DOI: 10.1080/01446190601161473 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601161473 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:6:p:649-659 Template-Type: ReDIF-Article 1.0 Author-Name: Fredrik Malmberg Author-X-Name-First: Fredrik Author-X-Name-Last: Malmberg Title: Introduction of a new form of quote evaluation: a case study in southern Sweden Abstract: The effects of changing from traditional tendering methods to an alternative form of quote evaluation were tested in a case study within the southern Swedish construction market. The project studied replacing the outer surface of the roof of a multiple-dwelling building 2000m2 in area. Procurement was carried out in two steps. The first step consisted of traditional tendering methods in which quotations were obtained by asking different contractors to bid. In the second step, formal tender documents were sent by mail to the same contractors. These documents included an alternative form of quote evaluation requiring that references to be provided for similar work, as well as for issues of environmental control, working environment, quality control and the material's life cycle. This second step was found to create additional value for the client and to improve competition. It was also observed that although there was a communication threshold to overcome, this segment of the construction market appeared ready to accept alternative methods for evaluating quotes. It was regarded as important to make the criteria readily understandable and measurable and strive towards a standardized template form of quote evaluation to reflect the goals of both the project and the clients. Journal: Construction Management and Economics Pages: 661-669 Issue: 6 Volume: 25 Year: 2007 Keywords: Procurement, quote evaluation, case study, southern Sweden, renovation, X-DOI: 10.1080/01446190701288051 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701288051 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:6:p:661-669 Template-Type: ReDIF-Article 1.0 Author-Name: Edwin H. W. Chan Author-X-Name-First: Edwin H. W. Author-X-Name-Last: Chan Author-Name: John Uff Cbe Qc Author-X-Name-First: John Uff Cbe Author-X-Name-Last: Qc Title: Guest Editorial Abstract: Journal: Construction Management and Economics Pages: 673-675 Issue: 7 Volume: 25 Year: 2007 X-DOI: 10.1080/01446190701563354 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701563354 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:673-675 Template-Type: ReDIF-Article 1.0 Author-Name: Graham Ive Author-X-Name-First: Graham Author-X-Name-Last: Ive Author-Name: Chen-Yu Chang Author-X-Name-First: Chen-Yu Author-X-Name-Last: Chang Title: The principle of inconsistent trinity in the selection of procurement systems Abstract: This paper examines the economic characteristics of construction procurement systems partially in terms of transaction cost economics and partly those of project management. It proposes the theoretical principle of an inconsistent trinity, according to which, in selecting a procurement system, the client will inevitably face a trade-off between the procurement system best able to deliver: (1) fastest completion of the project (and therefore higher discounted present value of revenue from the project); (2) least vulnerability when making changes (lower transaction hold-up costs arising from temporal or process specificity); as well as (3) least vulnerability to non-performance (lower transaction measurement costs from greater visibility to third parties for ordering of disputes). The model provides a potentially testable contribution to a transaction cost theory of construction procurement. It also has two implications: (1) the three main family types of procurement systems are held to be intrinsically different in economic terms, so selection of procurement system does matter; (2) no system can enjoy absolute advantage over others, so the proposed strategy of procurement system selection is to align the characteristics of procurement systems with attributes of projects. Journal: Construction Management and Economics Pages: 677-690 Issue: 7 Volume: 25 Year: 2007 Keywords: Transaction costs, hold-up, measurement costs, opportunism, temporal specificity, procurement system, X-DOI: 10.1080/01446190601164089 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601164089 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:677-690 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Gruneberg Author-X-Name-First: Stephen Author-X-Name-Last: Gruneberg Author-Name: Will Hughes Author-X-Name-First: Will Author-X-Name-Last: Hughes Author-Name: Debbie Ancell Author-X-Name-First: Debbie Author-X-Name-Last: Ancell Title: Risk under performance-based contracting in the UK construction sector Abstract: As a method of procuring the services of the built environment, performance-based contracting (PBC) seeks to link the building supplier to longer term commitments than has traditionally been the case in the construction sector. By rewarding the building producer according to the way that building or structure delivers the users' requirements, rather than according to a list of assembled parts, a number of additional risks are taken by contractors, including fitness for purpose, costs and briefing. The extent to which contractors recognize these risks and their methods of dealing with them vary considerably and are influenced by their attitudes towards risk. As the risks associated with PBC are seen as large, uninsurable, and vulnerable to changing client requirements, the majority of respondents would reject the use of PBC as a method of contracting. Nevertheless, PBC may be used under particular conditions, where rewards are deemed sufficient to compensate for the additional risk to the contractor of undertaking work on the basis of a stream of payments paid over the life of a structure depending on the satisfactory performance of the building or as part of a private finance initiative. Journal: Construction Management and Economics Pages: 691-699 Issue: 7 Volume: 25 Year: 2007 Keywords: Performance-based contracting, risk management, private finance initiative, X-DOI: 10.1080/01446190601164097 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601164097 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:691-699 Template-Type: ReDIF-Article 1.0 Author-Name: Steve Donohoe Author-X-Name-First: Steve Author-X-Name-Last: Donohoe Author-Name: Lynn Brooks Author-X-Name-First: Lynn Author-X-Name-Last: Brooks Title: Reflections on construction management procurement following Great Eastern Hotel Company v. John Laing Abstract: Construction management as a procurement method has been used increasingly in the UK construction industry, particularly for complex, multidisciplinary project work. Great Eastern Hotel v. John Laing (2005) (the 'GEH' case) is the first case to be decided by the courts in England in respect of works completed under a construction management agreement (CMA) and, as such, sets a precedent for the industry. As a precedent, this judgment has implications for construction management as a form of procurement and for construction management as a profession. The implications arising from the decision in this case pose problems for the future construction industry, which are considered here. The consequences arising from this decision for the profession of construction management and the expected levels of competency of individual construction managers are considered. This judgment defines a legal benchmark for construction management which hitherto did not exist. Construction management as a form of procurement has been viewed as placing the highest proportion of risk with the client in the event of problems. The construction management company, having no direct contractual link with any of the subcontractors, was seen as carrying a relatively low level of risk. Following the decision in GEH, the statement that a construction management company carries a low level of risk has to be revised. In addition, it is submitted that the GEH judgment will act as a driver for change in the perception of construction management and its future as a method of procurement. Questions are also posed regarding the level of competence of the construction manager post GEH. Journal: Construction Management and Economics Pages: 701-708 Issue: 7 Volume: 25 Year: 2007 Keywords: Construction management, procurement, liability, negligence, X-DOI: 10.1080/01446190601139909 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601139909 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:701-708 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Buckingham Author-X-Name-First: Paul Author-X-Name-Last: Buckingham Title: International process plant contracts for use on other performance-based projects Abstract: Selecting a contract that is appropriate for the construction work being carried out is a crucial part of the construction management process. Process plants are performance based, and the industry has developed its own conditions of contract to deal with the particular features and demands of its projects. This paper looks at the basic differences between process plants and traditional building projects, and discusses how these differences influence the conditions of contract. In addition to its suite of English law contracts, the IChemE has recently launched an international lump sum contract that retains the same basic contracting philosophy but is suitable for use on international projects. This paper analyses some of the key changes introduced into this international contract, and suggests that it is suitable for use on a wide range of performance-based projects. Journal: Construction Management and Economics Pages: 709-713 Issue: 7 Volume: 25 Year: 2007 Keywords: Process, contracts, international, performance, X-DOI: 10.1080/01446190701499591 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701499591 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:709-713 Template-Type: ReDIF-Article 1.0 Author-Name: Daniel Alain Dagenais Author-X-Name-First: Daniel Alain Author-X-Name-Last: Dagenais Title: Introduction to good faith in construction contracts Abstract: Advocating good faith as a key element of construction contracts under a 'new contract morality', as it has been developed mainly in Canada, this paper presents the advantages of an open exchange of information, of an adequate way of treating the unavoidable contingencies and of a global approach of collaboration between all participants on a construction project. Journal: Construction Management and Economics Pages: 715-721 Issue: 7 Volume: 25 Year: 2007 Keywords: Construction law, contract strategy, collaboration, dispute resolution, good faith, information, morality, X-DOI: 10.1080/01446190701393000 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701393000 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:715-721 Template-Type: ReDIF-Article 1.0 Author-Name: Said Boukendour Author-X-Name-First: Said Author-X-Name-Last: Boukendour Title: Preventing post-contractual opportunism by an option to switch from one contract to another Abstract: This article proposes a pre-emptive mechanism that prevents a self-interested contractor from taking benefits resulting from any post-contractual opportunism. The mechanism is based on an option to switch from one contract to another. The client and the contractor must simultaneously enter into two (or more) contracts with an option given to the client to decide which one will apply once the work has been completed. The client's advantage lies in the power of preventing the contractor's opportunistic behaviour. The contractor's advantage lies in the possibility to demonstrate good faith. Journal: Construction Management and Economics Pages: 723-727 Issue: 7 Volume: 25 Year: 2007 Keywords: Contract incompleteness, opportunism, residual rights, transaction costs, construction contracts, switching option, X-DOI: 10.1080/01446190701392994 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701392994 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:723-727 Template-Type: ReDIF-Article 1.0 Author-Name: Raufdeen Rameezdeen Author-X-Name-First: Raufdeen Author-X-Name-Last: Rameezdeen Author-Name: Chamil Rajapakse Author-X-Name-First: Chamil Author-X-Name-Last: Rajapakse Title: Contract interpretation: the impact of readability Abstract: The standard form of contract plays a significant role in a construction project as it communicates the procedures to be adopted in executing the project including the determination of the rights and obligations of contracting parties. Hence, an acceptable degree of commonality in interpretation of this document by different contracting parties is a prerequisite for the smooth functioning of a construction project. The aim of this research is to ascertain whether there is a relationship between readability of contract clauses and their interpretation. Readability is concerned with the complexity of words and sentences of text and it is commonly assessed by readability formulas. The survey undertaken for this research measured the ability of construction contract clauses having different readability values to convey a common understanding to all categories of respondents in terms of the degree to which risk was apportioned between the client and the contractor. The study reveals that there is a relationship between readability and contract interpretation. When the readability of the contract document is high, there found to be a high degree of commonality in interpretation of the document by different readers. Journal: Construction Management and Economics Pages: 729-737 Issue: 7 Volume: 25 Year: 2007 Keywords: Standard form of contract, contract clauses, readability, risk, interpretation, X-DOI: 10.1080/01446190601099228 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601099228 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:729-737 Template-Type: ReDIF-Article 1.0 Author-Name: John Wilson Twyford Author-X-Name-First: John Wilson Author-X-Name-Last: Twyford Title: Additional payments under construction contracts Abstract: Parties to a construction contract who wish to increase the sum payable under the contract face legal problems. Such transactions are manifest in a promise by the principal or head contractor to pay more. According to traditional contract theory, a promise is not enforceable unless supported by consideration, that is, the party making the promise receives something tangible in return. The courts have attempted to define circumstances where promises that do not strictly comply with this requirement would be enforceable. The issue arose in the English Court of Appeal decision of Williams v. Roffey Bros & Nicholls; the solution, there proposed, depended on the application of subjective tests that are unworkable in the construction industry. Equally, the High Court of Australia in Walton Stores v. Maher proposed a solution that leaves the parties in doubt as to their position. The law as it presently stands is reviewed and the recommendation made that the original contract be replaced by one confirming the new price. Otherwise the consideration requirement needs to be satisfied by a new promise in exchange for the promised additional payment. Journal: Construction Management and Economics Pages: 739-745 Issue: 7 Volume: 25 Year: 2007 Keywords: Contracts, variations, consideration, estoppel, economic duress, X-DOI: 10.1080/01446190701429804 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701429804 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:739-745 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Ward Author-X-Name-First: Peter Author-X-Name-Last: Ward Author-Name: William Sher Author-X-Name-First: William Author-X-Name-Last: Sher Author-Name: Rod Gameson Author-X-Name-First: Rod Author-X-Name-Last: Gameson Author-Name: Guillermo Aranda-Mena Author-X-Name-First: Guillermo Author-X-Name-Last: Aranda-Mena Title: Innovative protocols and technologies as a means of complying with the Building and Construction Industry Security of Payments Act 1999 (NSW) Australia Abstract: The Building and Construction Industry Security of Payments Act 1999—updated 27 November 2003, New South Wales, Australia provides a statutory framework which governs compulsory progress payments for those who undertake works or provide goods or services as part of a construction contract. Respondents to the process are being disadvantaged as a result of complying with the Act. Claimants are purported to be taking months to prepare detailed and comprehensive payment claims, prior to serving them on the respondents, who, under the Act, have limited time to compile a detailed payment schedule in response. This research investigates the use of two recent innovations that could assist in the administration of the process. The first is the Society of Construction Law's Delay and Disruption Protocol's model clauses, and the second is the use of web-based technology as a project administrative tool. A literature search was carried out, together with semi-structured qualitative interviews, to determine opinions of their use and effectiveness. Results indicate a recognition and appreciation of the likely benefits of transparency, efficiency and improved cost effectiveness of the project administrative processes, possibly resulting in potential savings and improved cost recovery opportunities, with the potential to reduce and/or avoid disputes. Journal: Construction Management and Economics Pages: 747-763 Issue: 7 Volume: 25 Year: 2007 Keywords: Payment, contract administration, documentation, claims, X-DOI: 10.1080/01446190601042434 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601042434 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:747-763 Template-Type: ReDIF-Article 1.0 Author-Name: Thomas Uher Author-X-Name-First: Thomas Author-X-Name-Last: Uher Author-Name: Michael Brand Author-X-Name-First: Michael Author-X-Name-Last: Brand Title: A comparative analysis of the operation of 'compulsory rapid adjudication' in New South Wales and New Zealand Abstract: The purpose of this research was to make a comparative analysis of the operation of the Building and Construction Industry Security of Payment Act 1999 (NSW) (the NSW Act) and the Construction Contracts Act 2002 (NZ) (the NZ Act). Data were extracted from the NSW and NZ Acts, the NSW Department of Commerce and from the published books, reports and articles. Under the NSW Act, which is only concerned with payment claim disputes, adjudicators' jurisdiction is narrow and timelines for the submission of documents and for making an adjudication determination are short. Consequently, payment claim disputes are resolved rapidly and economically. The NZ Act on the other hand addresses all kinds of disputes. The jurisdiction of adjudicators is broad and the period for making an adjudication determination is about twice as long as in NSW. One of the strengths of the NSW Act is the ability to enter judgment for an adjudicated amount by simply filing an adjudication certificate in a court. One of the strengths of the NZ Act is in allowing the claimant to join the owner of a construction site in an adjudication; the adjudicator has a power to determine that the owner, who is an associate of the respondent, is jointly and severally liable with the respondent for the debt, and can approve of a charging order over the construction site owned by the owner. Journal: Construction Management and Economics Pages: 765-775 Issue: 7 Volume: 25 Year: 2007 Keywords: Australia, construction claims, New Zealand, statutory adjudication, X-DOI: 10.1080/01446190601047748 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601047748 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:765-775 Template-Type: ReDIF-Article 1.0 Author-Name: Robert Gaitskell Author-X-Name-First: Robert Author-X-Name-Last: Gaitskell Title: International statutory adjudication: its development and impact Abstract: This paper sets out an overview of the development of statutory adjudication, noting its origin in the UK and comparing adjudication in different jurisdictions, including Australia, New Zealand, Singapore, Hong Kong and South Africa. Through appraisal of the statistics of case workload referred to different dispute resolution methods, this paper considers the impact this procedure has had upon other dispute resolution processes. From the UK experience, the adoption of a statutory adjudication scheme by any jurisdiction is likely to result in significant reductions in most other forms of dispute resolution. Journal: Construction Management and Economics Pages: 777-784 Issue: 7 Volume: 25 Year: 2007 Keywords: Adjudication, dispute resolution, arbitration, construction, X-DOI: 10.1080/01446190701499609 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701499609 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:777-784 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Nissen Qc Author-X-Name-First: Alexander Nissen Author-X-Name-Last: Qc Title: Expert evidence: problems and safeguards Abstract: This paper examines the role of expert evidence and expert witnesses in the resolution of construction disputes. The history of experts in court is traced through the cases, including guidelines as to the proper conduct of experts. The status and potential liability of an expert is then considered, particularly in the context of the recent Court of Appeal in Meadow v. General Medical Council [2007] 1 All ER 1. The role of an expert as advocate is considered and conclusions drawn as to the key problems which arise. Journal: Construction Management and Economics Pages: 785-790 Issue: 7 Volume: 25 Year: 2007 Keywords: Expert evidence, construction dispute, witness, negligence, X-DOI: 10.1080/01446190701499583 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701499583 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:785-790 Template-Type: ReDIF-Article 1.0 Author-Name: Issaka Ndekugri Author-X-Name-First: Issaka Author-X-Name-Last: Ndekugri Author-Name: Nigel Smith Author-X-Name-First: Nigel Author-X-Name-Last: Smith Author-Name: Will Hughes Author-X-Name-First: Will Author-X-Name-Last: Hughes Title: The engineer under FIDIC's conditions of contract for construction Abstract: FIDIC has over the years produced standard forms of contracts for the international procurement of projects. A source of continuing criticism of its Red Book concerns the duality in the traditional role of the engineer as the employer's agent and as an independent third party holding the balance fairly between the employer and the contractor. In response to this and other criticisms FIDIC produced a replacement for it in 1999. The role of the engineer under the new Red Book is critically examined in the light of relevant case law, expert commentaries and feedback from two multidisciplinary workshops with international participation. The examination identified three major changes: (1) a duty to act impartially has been replaced by a duty to make fair determination of certain matters; (2) it is open to parties to allow greater control of the engineer by the employer by stating in the appropriate part of the contract powers the engineer must not exercise without the employer's approval; (3) there is provision for a Dispute Adjudication Board (DAB) to which disputes may be referred. Although the duality has not been eliminated completely, the contract is structured flexibly enough to support those who wish to contract on the basis of the engineer acting solely as the agent of the employer. Journal: Construction Management and Economics Pages: 791-799 Issue: 7 Volume: 25 Year: 2007 Keywords: Contract, Dispute Adjudication Board, engineer, FIDIC, X-DOI: 10.1080/01446190701411216 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701411216 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:791-799 Template-Type: ReDIF-Article 1.0 Author-Name: Jiayuan Wang Author-X-Name-First: Jiayuan Author-X-Name-Last: Wang Author-Name: Jian Liu Author-X-Name-First: Jian Author-X-Name-Last: Liu Author-Name: Liyuan Huang Author-X-Name-First: Liyuan Author-X-Name-Last: Huang Title: Study on the professional liability insurance system of the supervision engineer in China Abstract: Although the supervision system has been adopted in the construction industry for more than 10 years in China, a professional liability insurance system for the supervision engineer has yet to be established. The implementation of a professional liability insurance for the supervision engineer in China is suggested. The range of issues cover the professional liabilities and typical professional faults of the supervision engineer, the scope of the insurance liability, exclusions, insurance types and the assured. The three premium-rating methods are presented. A five-thrust implementation strategy for professional liability insurance for the supervision engineer is offered in order to overcome the main obstacles. The data applied for the analysis in the study were collected from a comprehensive questionnaire survey to the Shenzhen-based supervision firms. Selected interviews were conducted to supplement the survey data. This study provides a valuable reference for further research in examining project supervision practices in other construction industries. Journal: Construction Management and Economics Pages: 801-810 Issue: 7 Volume: 25 Year: 2007 Keywords: Insurance, liability, professional, supervision engineer, X-DOI: 10.1080/01446190601139891 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601139891 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:801-810 Template-Type: ReDIF-Article 1.0 Author-Name: Ronald William Craig Author-X-Name-First: Ronald William Author-X-Name-Last: Craig Author-Name: Wilson C. Barnes Author-X-Name-First: Wilson C. Author-X-Name-Last: Barnes Title: Professional employees' exposure to risk of negligence claims from the client Abstract: Construction professionals owe duties of care and skill to clients in both contract and tort. Usually the principal or the corporate employer takes responsibility for employees' negligence under the principle of vicarious liability. But analysis of court judgments from England, New Zealand, Hong Kong and Florida (USA) reveals circumstances in which professional employees might attract personal liability to the firm's client, despite an apparent lack of contractual or tortious relationship with that client. Professional employees of unincorporated businesses might be more exposed to this risk than employees of incorporated businesses. Factors causing professional employees to be uninsured include lack of contractual privity between client and employee and absence of compelling rules or statutes. Professional employees seem unaware of these risks. Increased awareness of these risks could encourage employees to take out insurance but clients will resist paying twice to insure the negligence of both principal and employee. Journal: Construction Management and Economics Pages: 811-819 Issue: 7 Volume: 25 Year: 2007 Keywords: Construction law, contract law, negligence, liability, professional, X-DOI: 10.1080/01446190600987712 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190600987712 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:811-819 Template-Type: ReDIF-Article 1.0 Author-Name: David Shiers Author-X-Name-First: David Author-X-Name-Last: Shiers Author-Name: Anthony Lavers Author-X-Name-First: Anthony Author-X-Name-Last: Lavers Author-Name: Miles Keeping Author-X-Name-First: Miles Author-X-Name-Last: Keeping Title: Indicators of the impact of environmental factors on UK construction law: developments in the new millennium Abstract: In examining the impact of environmental issues on construction law, recent construction-related legislation and litigation can be seen as indicators of the growing importance of specific property-related environmental issues. Through reference to relevant literature and law reports, several recent legal developments can be identified relating to energy production and consumption, water inundation, the physical qualities of buildings, excluded materials, noise and disability discrimination and, finally, waste disposal and contamination. Recent law relating to energy consumption in buildings is evidence of the ever-widening set of legal obligations regarding energy efficiency. Similarly, recent litigation relating to nuclear waste and wind farms may be more typical of future energy cases than those relating to traditional fossil fuel production processes. Noise represents another form of environmental pollution and has been seen in a number of cases. The impact of the built environment on people with disabilities is now recognized in Part M of the Building Regulations which places additional disabled access requirements on all building owners, landlords, employers and service providers. Property professionals, local authorities and statutory authorities need, more than ever before, to be aware of their current legal obligations while remaining constrained by resource and financial management regulation. Journal: Construction Management and Economics Pages: 821-829 Issue: 7 Volume: 25 Year: 2007 Keywords: Construction law, liability, environment, X-DOI: 10.1080/01446190601145278 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601145278 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:7:p:821-829 Template-Type: ReDIF-Article 1.0 Author-Name: Li-Chung Chao Author-X-Name-First: Li-Chung Author-X-Name-Last: Chao Author-Name: Chang-Nan Liou Author-X-Name-First: Chang-Nan Author-X-Name-Last: Liou Title: Risk-minimizing approach to bid-cutting limit determination Abstract: Intense price competition is quite common in the construction industry. In many markets, contractors have to cut their bids to compete, giving priority to winning enough contracts to sustain normal operation, and it is common to see a winning bid close to the expected project cost. While cutting bids not only gives up profits but also undoubtedly increases the risk of making a loss, the behaviour of contractors in intense competition is difficult to explain by existing academic bidding models. An approach to determining the lower limit of the bid for a project is proposed based on minimization of the overall loss risk defined by a probabilistic model. The approach can be used to prevent arbitrary over-cuts in final bid decision where price competition is intense. Factors influencing the suggested bid-cutting limit for a project are analysed. An illustrative example using real case data is provided. Journal: Construction Management and Economics Pages: 835-843 Issue: 8 Volume: 25 Year: 2007 Keywords: Bidding, estimating, probability, Monte Carlo simulation, risk analysis, X-DOI: 10.1080/01446190701393018 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701393018 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:8:p:835-843 Template-Type: ReDIF-Article 1.0 Author-Name: Chen-Yu Chang Author-X-Name-First: Chen-Yu Author-X-Name-Last: Chang Author-Name: Graham Ive Author-X-Name-First: Graham Author-X-Name-Last: Ive Title: Reversal of bargaining power in construction projects: meaning, existence and implications Abstract: Reversal of bargaining power arising from asset specificity is important for the understanding of hold-up problems. Various types of asset specificity have been identified in different transaction contexts, but a previously unidentified or unnamed type is developed here: process specificity. Numerous widely used financial and contractual preventive measures in construction practice can be justified as responses to this problem of process specificity. These include bonds and retentions. However, these measures have limitations. Specifically, the client-led change orders cannot be completely averted and when they occur, the pricing of additional work largely relies on negotiation, implying that bargaining power determines the result. Consequently, the hold-up problem remains a managerial issue. To mitigate this problem, clients should choose a procurement system by aligning project attributes with the procurement system characteristics. Journal: Construction Management and Economics Pages: 845-855 Issue: 8 Volume: 25 Year: 2007 Keywords: Bargaining power, transaction cost, opportunism, asset specificity, procurement, X-DOI: 10.1080/01446190601164113 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601164113 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:8:p:845-855 Template-Type: ReDIF-Article 1.0 Author-Name: Ingeborg Knauseder Author-X-Name-First: Ingeborg Author-X-Name-Last: Knauseder Author-Name: Per-Erik Josephson Author-X-Name-First: Per-Erik Author-X-Name-Last: Josephson Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Title: Learning approaches for housing, service and infrastructure project organizations Abstract: Capturing and sharing experiences that may be applicable in several projects is generally recognized as a way of enhancing the performance of construction projects. Several studies have reported difficulties in applying learning approaches that could be applicable for a wide range of projects. The learning behaviour in three types of construction project: housing, service and infrastructure, is examined by the means of a questionnaire study including 51 construction projects and more than 800 responses from clients, designers, contractors' managers, contractors' workers and subcontractors. The effects of leadership, openness and influence are considered. Based on a factor analysis, three approaches to learning were identified: organizing for learning, experimenting and networking. While housing project organizations do not demonstrate any specific preferences, service project organizations show a focus on networking and infrastructure project organizations show the highest interest in experimenting. On the basis of these results it can be concluded that learning approaches are dependent on the type of project. Thus adopting different learning approaches for different types of construction project seems to be a more relevant strategy than implementing a 'one size fits all' learning approach for all construction project organizations. Journal: Construction Management and Economics Pages: 857-867 Issue: 8 Volume: 25 Year: 2007 Keywords: Organizational learning, questionnaire, leadership, X-DOI: 10.1080/01446190601164121 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190601164121 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:8:p:857-867 Template-Type: ReDIF-Article 1.0 Author-Name: Iain Cameron Author-X-Name-First: Iain Author-X-Name-Last: Cameron Author-Name: Roy Duff Author-X-Name-First: Roy Author-X-Name-Last: Duff Title: Use of performance measurement and goal setting to improve construction managers' focus on health and safety Abstract: Previous attempts to use goal setting and feedback to improve safety behaviour on construction sites have focused on operatives, but recognized management commitment as essential for success. This research addressed two problems: validly and reliably measuring the safety performance of construction managers; and motivating managers to improve their safety performance. A measure of management safety performance was developed, covering seven items: induction training; toolbox talk training; safety committees; subcontractor safety; maintenance of safety records; safety manager actions and safety consideration (interaction, communication and worker engagement). This was used on a case study site to improve motivation of the management team. During an intervention, using monthly feedback and goal-setting techniques, their performance improved from 49% to 82% of maximum expected performance. The results demonstrate that a valid and reliable measure of management safety performance is practicable and support the proposition that goal setting can improve management safety performance in the construction industry. Journal: Construction Management and Economics Pages: 869-881 Issue: 8 Volume: 25 Year: 2007 Keywords: Behavioural safety, feedback, goal setting, organizational behaviour, organizational psychology, safety, X-DOI: 10.1080/01446190701268848 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701268848 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:8:p:869-881 Template-Type: ReDIF-Article 1.0 Author-Name: David Hudak Author-X-Name-First: David Author-X-Name-Last: Hudak Author-Name: Mark Maxwell Author-X-Name-First: Mark Author-X-Name-Last: Maxwell Title: A macro approach to estimating correlated random variables in engineering production projects Abstract: An important consideration in cost risk analysis is the amount of correlation between different cost elements. If correlation is ignored, both the probability and magnitude of costs overruns could be significantly underestimated. The two major difficulties in implementing correlation addressed are estimating correlation coefficients and providing an accurate theoretical risk analysis approach to account for these correlations. Since detailed correlation data are often difficult or impossible to obtain, an intuitive approach is proposed, which estimates correlations for cost estimates relative to several underlying macro factors. The correlation matrix obtained by this method is positive semi-definite and a case study based upon three macro factors is given. The cost risk distributions are computed and compared using the beta fit model and two other more complicated models. This study shows negligible differences in cost risk dollars when computed by the various models. This method of using macro factors to estimate correlation coefficients can account for significant additional cost risk dollars while not requiring external correlation data. Journal: Construction Management and Economics Pages: 883-892 Issue: 8 Volume: 25 Year: 2007 Keywords: Cost analysis, risk analysis, correlation, simulation, project management, X-DOI: 10.1080/01446190701411224 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701411224 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:8:p:883-892 Template-Type: ReDIF-Article 1.0 Author-Name: Per Erik Eriksson Author-X-Name-First: Per Erik Author-X-Name-Last: Eriksson Author-Name: Ossi Pesamaa Author-X-Name-First: Ossi Author-X-Name-Last: Pesamaa Title: Modelling procurement effects on cooperation Abstract: Cooperative arrangements, such as partnering, have received increased interest in recent years. Several studies show however that cooperative relationships are not easily achieved in construction. Implementation of cooperative relationships requires changes in several elements of the traditional procurement procedures. The purpose of this paper is therefore to propose and test a sequential model regarding clients' cooperative procurement procedures. We especially ask: what elements in clients' procurement procedures facilitate the establishment of cooperation and trust in their relationships with contractors? The model was tested through structural equation modelling. The empirical data required for the test were collected through a survey responded to by 87 Swedish professional construction clients. The empirical results show that cooperative procurement procedures are triggered by clients' wish to involve contractors early in specification, which has a simultaneous effect on procedures regarding bid invitation and compensation. Furthermore, these simultaneous effects breed a certain kind of partner selection based on task-related attributes, which also has a direct positive effect on trust and above all on cooperation in client-contractor relationships. Besides these implications from the model, the improvement of measurements for future modelling is discussed. Journal: Construction Management and Economics Pages: 893-901 Issue: 8 Volume: 25 Year: 2007 Keywords: Cooperation, partnering, procurement, SEM, X-DOI: 10.1080/01446190701468844 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701468844 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:8:p:893-901 Template-Type: ReDIF-Article 1.0 Author-Name: Alan Griffith Author-X-Name-First: Alan Author-X-Name-Last: Griffith Title: Key considerations for delivering best value in the small building works portfolio of large client organizations Abstract: Many large organizations own and occupy extensive, complex and varied property estates, which are essential to their business. Continued reliance on these resources often requires considerable annual expenditure on maintenance, alterations, refurbishment and small-scale new building works. Such activities form the category small building works, a sub-sector of the UK construction industry which currently approximates to £11 billion, or 20% of annual total output. The delivery of best value in the management of small building works, in the context of an organization with a large property portfolio, is important to the business. Studies into small building works conducted over the past 15 years have been synthesized and augmented to highlight the key considerations for ensuring best value in small building works. The delivery of best value requires a comprehensive understanding of the proposed works themselves and then the potential impact of those works upon the property portfolio, and all within the context of the organization's business activities. Clients need to establish first, an effective procurement approach and second, an effective operational approach. Journal: Construction Management and Economics Pages: 903-909 Issue: 8 Volume: 25 Year: 2007 Keywords: Procurement, property estates, operations, small building works, workload management, X-DOI: 10.1080/01446190701385212 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701385212 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:8:p:903-909 Template-Type: ReDIF-Article 1.0 Author-Name: S. Thomas Ng Author-X-Name-First: S. Thomas Author-X-Name-Last: Ng Author-Name: Yoki Wong Author-X-Name-First: Yoki Author-X-Name-Last: Wong Title: Payment and audit mechanisms for non private-funded PPP-based infrastructure maintenance projects Abstract: The introduction of a non private-funded public-private partnerships (PPP) approach to the maintenance and operation of infrastructure facilities necessitates an equitable performance standard, a sensible penalty mechanism and a credible auditing system. Yet, with limited research on this type of scheme, it is not clear whether the payment and audit mechanisms can adequately gauge the performance of private partners and truly reflect the quality of service provided in their payment. The question is whether the reliability of the payment reduction and auditing mechanisms pertinent to the non-private funded PPP infrastructure maintenance can be systematically verified. With reference to a case study in Hong Kong, field data have been collected and tested according to the sensitivity analysis and level of confidence. The results indicate that the level of payment reduction due to poor performance is fair and the audit frequency is adequate to reflect the overall performance of the service provider. The approaches adopted in this research should provide an objective basis for public and private partners to formulate a mutually acceptable and effective mechanism for non private-funded PPP infrastructure maintenance contracts. Journal: Construction Management and Economics Pages: 915-923 Issue: 9 Volume: 25 Year: 2007 Keywords: Public-private partnerships, infrastructure facilities, maintenance, performance-based payment, auditing, X-DOI: 10.1080/01446190701544396 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701544396 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:9:p:915-923 Template-Type: ReDIF-Article 1.0 Author-Name: Dussadee Satirasetthavee Author-X-Name-First: Dussadee Author-X-Name-Last: Satirasetthavee Author-Name: Pannapa Herabat Author-X-Name-First: Pannapa Author-X-Name-Last: Herabat Title: Integration of the component of financial statement in highway maintenance planning Abstract: Highway agencies attempt to apply efficient accounting systems to help improve the transparency of their budget allocation and their overall performance. The accrual accounting system has been adopted to substitute the cash accounting system by many central governments around the world. The system reports transactions of economic value changes rather than when cash movements are made. The asset value and its depreciation determined by the accrual accounting system illustrate the total amount of economic value owned by an agency and the consumption of the future economic benefits for an asset. The age-based depreciation approach, which is a traditional approach, is applied to determine the depreciation of an asset based on the defined useful life and the straight-line depreciation method. The advantage of this approach is its simplicity and its ability to support the long-term asset management system. The condition-based depreciation is recommended as an alternative approach since the actual condition of an asset can reflect its depreciation. The depreciation of an asset based on the condition-based approach is suitable for single-year maintenance planning since the executives cannot estimate the required budget for replacing or preserving of an asset in the long-term period. This research focuses on developing the new depreciation approach by integrating the age-based and the condition-based depreciation approaches in order to strategically plan long-term highway maintenance and to enable the actual condition of an asset to be reflected. Journal: Construction Management and Economics Pages: 925-936 Issue: 9 Volume: 25 Year: 2007 Keywords: Asset management, accountability, maintenance, highway, X-DOI: 10.1080/01446190701280702 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701280702 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:9:p:925-936 Template-Type: ReDIF-Article 1.0 Author-Name: Zhikun Ding Author-X-Name-First: Zhikun Author-X-Name-Last: Ding Author-Name: Fungfai Ng Author-X-Name-First: Fungfai Author-X-Name-Last: Ng Author-Name: Qiying Cai Author-X-Name-First: Qiying Author-X-Name-Last: Cai Title: Personal constructs affecting interpersonal trust and willingness to share knowledge between architects in project design teams Abstract: Architectural design is a knowledge-intensive activity. However, architects are not always willing to share their knowledge with their team members. Based on a literature review and in-depth interviews, this research identifies and validates factors as well as the underlying personal constructs that influence architects' interpersonal trust and willingness to share their knowledge in project design teams in China. The results of triangulation data analysis show that there are four factors affecting both interpersonal trust and willingness to share knowledge, i.e. 'team member's attitude towards work', 'team member's ability with regard to work', 'team member's personality' and 'team member's social interaction'. Contrary to previous findings, interpersonal trust is not identified as an individual factor influencing willingness to share knowledge. The personal constructs underlying each factor e.g. 'hard working-lazy when working', etc. are summarized and can be employed as measurement scales in designing future quantitative research, i.e. the explanatory study. Moreover, the identified personal constructs provide directions for the management in architectural design institutes to encourage knowledge sharing behaviour among architects. Journal: Construction Management and Economics Pages: 937-950 Issue: 9 Volume: 25 Year: 2007 Keywords: Knowledge management, interpersonal trust, personal construct theory, knowledge sharing, full grid technique, X-DOI: 10.1080/01446190701468828 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701468828 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:9:p:937-950 Template-Type: ReDIF-Article 1.0 Author-Name: Kwabena Asomanin Anaman Author-X-Name-First: Kwabena Asomanin Author-X-Name-Last: Anaman Author-Name: Charity Osei-Amponsah Author-X-Name-First: Charity Author-X-Name-Last: Osei-Amponsah Title: Analysis of the causality links between the growth of the construction industry and the growth of the macro-economy in Ghana Abstract: A vibrant construction industry in a developing country, that mobilizes human and local material resources in the development and maintenance of buildings, housing and physical infrastructure, is an important means to promote increased local employment and accelerate economic growth. Ghana, a country of about 22 million people, currently has one of the fastest growing economies in West Africa. The Government of Ghana (GOG) has recently set a target of annual economic growth rate of 8% and above, up from annual growth rates of 5-6% in the past five years (2001-05). It intends to use the agricultural sector as the major vehicle for achieving such high growth rates in order for the country to reach the status of a middle income country by 2015. Surprisingly, the construction industry was left out from the list of major growth drivers of the economy. We contend that with the construction industry currently making up the third largest sector of the economy, special attention should be given to this industry as one of the main drivers of economic growth in Ghana. Therefore we conducted a study to analyse the causality links between the growth in the construction industry and the growth in the macro-economy of Ghana, measured by the gross domestic product (GDP), to ascertain whether the construction industry can be used to lead the entire economy on a growth path. The analysis was based on a simple Granger causality test using time series data from 1968 to 2004. We showed that growth in the construction industry Granger-caused growth in GDP, with a three-year lag. The construction industry needs to be considered as one of the major drivers of economic growth in Ghana. Journal: Construction Management and Economics Pages: 951-961 Issue: 9 Volume: 25 Year: 2007 Keywords: Construction industry, gross domestic product, economic growth, Ghana, Granger causality test, West Africa, X-DOI: 10.1080/01446190701411208 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701411208 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:9:p:951-961 Template-Type: ReDIF-Article 1.0 Author-Name: Jay Na Lim Author-X-Name-First: Jay Na Author-X-Name-Last: Lim Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Title: Classification of innovation for strategic decision making in construction businesses Abstract: Innovations in construction may be classified in several different ways. To encourage construction firms in Singapore to innovate, a practical approach is provided for the classification of innovations, in order to guide construction firms in their development of innovation strategies. A qualitative systems model, portraying the innovation behaviour of contractors, is developed and validated through Pearson correlation analysis and interviews. From interviews with 21 construction practitioners, the profit maximization goals of construction firms are shown to be a major driving force of innovation. Construction innovation should be classified in accordance with the types of benefits and returns that emerge from them, which makes the investment of money and effort in innovation worthwhile. Three classes of innovations were identified: innovations that consumers are willing to pay for; innovations that reduce contractors' construction costs; and innovations that encompass intangible benefits, thus providing contractors with competitive advantage. Journal: Construction Management and Economics Pages: 963-978 Issue: 9 Volume: 25 Year: 2007 Keywords: Willingness to pay, profit maximization, innovation, systems thinking, X-DOI: 10.1080/01446190701393026 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701393026 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:9:p:963-978 Template-Type: ReDIF-Article 1.0 Author-Name: John Alfred Rooke Author-X-Name-First: John Alfred Author-X-Name-Last: Rooke Author-Name: Mike Kagioglou Author-X-Name-First: Mike Author-X-Name-Last: Kagioglou Title: Criteria for evaluating research: the unique adequacy requirement of methods Abstract: The Unique Adequacy requirement of methods (UA) is proposed as a means of evaluating research in construction management. UA addresses the problems stemming from the significance of conscious action in constituting human organization. These may be summarized as: first, that objectivity is a problematic concept in such studies; second, that the determination of meaning is their primary goal; and third, that formal procedures, whether as methods of research or explanation, have significant limitations. The UA requirement has two forms: the weak form demands that the researcher is competent in the research setting; the strong form, that research reports use only concepts originating within the research setting. The consequences of applying these criteria are explored with reference to recent research reports in construction management, including: a questionnaire survey of cultural difference; an exercise in grounded theorizing; a case study of the implementation of a quality management initiative. It is concluded that the UA requirement is a viable tool for evaluating and guiding research. Emphasis is placed on the importance of maintaining a principled distinction between empirical research and theory building. Journal: Construction Management and Economics Pages: 979-987 Issue: 9 Volume: 25 Year: 2007 Keywords: Research methods, methodology, culture, grounded theory, total quality management, X-DOI: 10.1080/01446190701268855 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701268855 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:9:p:979-987 Template-Type: ReDIF-Article 1.0 Author-Name: Roger Flanagan Author-X-Name-First: Roger Author-X-Name-Last: Flanagan Author-Name: Weisheng Lu Author-X-Name-First: Weisheng Author-X-Name-Last: Lu Author-Name: Liyin Shen Author-X-Name-First: Liyin Author-X-Name-Last: Shen Author-Name: Carol Jewell Author-X-Name-First: Carol Author-X-Name-Last: Jewell Title: Competitiveness in construction: a critical review of research Abstract: Since its popularization in the 1980s, competitiveness has received close attention from practitioners and researchers across a wide range of industries. In the construction sector, many works on competitiveness have also been published. So far, however, there seems to be no comprehensive review to summarize and critique existing research on competitiveness in construction. This research, therefore, reviews the extant literature from four aspects: concept of competitiveness, competitiveness research at the construction industry level, competitiveness research at the firm level, and competitiveness research at the project level. The review presents the state-of-the-art development of competitiveness research in construction, identifies the research gaps, and proposes new directions for further studies. Further research is recommended to validate previous studies in construction practices, identify the mechanisms that encourage mutual enhancement of competitiveness at different levels, and how to achieve its sustainability by embracing new management and/or economics techniques. Journal: Construction Management and Economics Pages: 989-1000 Issue: 9 Volume: 25 Year: 2007 Keywords: Competitiveness, competitive advantage, critical review, construction sector, X-DOI: 10.1080/01446190701258039 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701258039 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:9:p:989-1000 Template-Type: ReDIF-Article 1.0 Author-Name: Abdul-Rashid Abdul-Aziz Author-X-Name-First: Abdul-Rashid Author-X-Name-Last: Abdul-Aziz Author-Name: Mastura Jaafar Author-X-Name-First: Mastura Author-X-Name-Last: Jaafar Author-Name: Abdul Aziz Hussin Author-X-Name-First: Abdul Aziz Author-X-Name-Last: Hussin Title: Are government-linked construction companies in Malaysia still valid? The indigenous contractors' perspective Abstract: Despite privatization, many government-linked companies (GLCs) still continue to operate in Malaysia. Many have objectives that include the redressing of ethnic economic imbalance. Government-linked construction companies (GLCCs) were created within these larger public groups. A study was conducted to explore whether the GLCCs are still valid in Malaysia's present construction industry scenario, and if not, what actions should be taken in respect of them. Four aspects (i.e. social obligation, competitiveness, efficiency and income generation) were looked into. To answer the research questions, the viewpoints of 'A' Class bumiputera contractors were solicited which were then investigated on four GLCCs, three belonging to state economic development corporations (SEDCs) and one to a land development agency (LDA). The exploratory study found that three case study GLCCs have limited public value. This paper concludes by recommending changes that should be made to them. There is much that policy makers in developing countries with GLCCs can learn from the Malaysian experience. At the very least, it underscores the need to assess their raison d'etre periodically. This study also hopes to encourage other scholars to look into a much under-researched area—that of a particular set of actors commonly created to promote local construction industry development. Journal: Construction Management and Economics Pages: 1009-1019 Issue: 10 Volume: 25 Year: 2007 Keywords: Government-linked construction companies, Malaysia, X-DOI: 10.1080/01446190701598640 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701598640 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:10:p:1009-1019 Template-Type: ReDIF-Article 1.0 Author-Name: Lim Jay Na Author-X-Name-First: Lim Jay Author-X-Name-Last: Na Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Author-Name: Florence Yean Yng Ling Author-X-Name-First: Florence Yean Yng Author-X-Name-Last: Ling Author-Name: Goh Bee Hua Author-X-Name-First: Goh Bee Author-X-Name-Last: Hua Title: Role of national institutions in promoting innovation by contractors in Singapore Abstract: The complexity of the relationships among the government, national institutions and enterprises often hinders efforts to understand the effectiveness of national institutions in encouraging contractors to innovate. The role of national institutions in stimulating innovation is investigated, with a focus on construction firms in Singapore. A qualitative systems model portraying the role of national institutions in the construction industry is developed and validated through statistical analysis and interviews. Technological advance from national institutions that cultivates a competitive environment is able to stimulate a direct increase in construction innovation, and develop industry clusters that enhance the contractors' research capabilities. The primary policy recommendation is that a national body that unifies various institutions and parties within the construction sector should be established to spearhead an integrated and focused research agenda for the construction industry. Journal: Construction Management and Economics Pages: 1021-1039 Issue: 10 Volume: 25 Year: 2007 Keywords: Systems thinking, innovation, national institutions, policy, X-DOI: 10.1080/01446190701209925 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701209925 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:10:p:1021-1039 Template-Type: ReDIF-Article 1.0 Author-Name: Li-Ren Yang Author-X-Name-First: Li-Ren Author-X-Name-Last: Yang Title: Exploring the links between technology usage and project outcomes Abstract: Ninety-eight capital facility projects from across Taiwan have been assessed on the issue of technology usage at the work function level and overall project cost and schedule success. The links between technology utilization and project success are explored in detail. Identification of project performance-leveraging work functions is employed as a way to gain greater understanding of the connection between technology usage and project performance. In addition, work function characteristics (WFCs) are investigated as an additional basis for gaining deeper insights into how technology usage may impact on project success. The analyses suggest that degrees of technology used in executing the project performance-leveraging work functions may have a significant impact on project cost or schedule performance. The results also indicate that information and data-intensive and management-related WFCs can positively influence project cost and schedule success. Journal: Construction Management and Economics Pages: 1041-1051 Issue: 10 Volume: 25 Year: 2007 Keywords: Cost, project, scheduling, technological change, technology management, X-DOI: 10.1080/01446190701598657 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701598657 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:10:p:1041-1051 Template-Type: ReDIF-Article 1.0 Author-Name: Yamuna Kaluarachchi Author-X-Name-First: Yamuna Author-X-Name-Last: Kaluarachchi Author-Name: Keith Jones Author-X-Name-First: Keith Author-X-Name-Last: Jones Title: Monitoring of a strategic partnering process: the Amphion experience Abstract: Amphion Consortium was formed with the membership of a number of registered social landlords as an initiative in implementing the Egan agenda which championed long-term successful partnering as a mechanism for achieving radical change in the construction industry. This was an opportunity to monitor and record the performance of 12 housing development projects and the roles played by a complex team network in contributing to an innovative partnering agreement. Relevant KPIs, benchmarks, a data collection and site monitoring system were developed. A range of workshops, questionnaire surveys, detailed interviews with key project personnel, examination of site meeting notes and feedback reviews were undertaken as research tools to gather data. An attempt was made to identify the softer, qualitative issues that are difficult to grapple with normal numerical data collection methods. A number of takeover bids within a short space of time had a substantial effect on the consortium as well as the research project. Mutual trust, effective communication, a changed mindset from all parties, the quality of the services and commitment of all stakeholders seem to be the key factors that contribute to a successful strategic partnering process. Journal: Construction Management and Economics Pages: 1053-1061 Issue: 10 Volume: 25 Year: 2007 Keywords: Strategic partnering, social housing, key performance indicators, Amphion, procurement, X-DOI: 10.1080/01446190701504226 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701504226 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:10:p:1053-1061 Template-Type: ReDIF-Article 1.0 Author-Name: Mei-Yung Leung Author-X-Name-First: Mei-Yung Author-X-Name-Last: Leung Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Yee Shan Chan Author-X-Name-First: Yee Shan Author-X-Name-Last: Chan Title: Subjective and objective stress in construction cost estimation Abstract: Cost estimators play an important role in an organization, as they produce most predictions of probable final construction cost. Since both under- and overestimates can be costly, attention should be paid to the estimating tasks. People involved are therefore likely to experience a considerable amount of mental and emotional stress as a result of inaccurate estimation. The types of stress can be divided into objective stress (OS), subjective stress (SS) and emotional exhaustion (EE). The research described in this paper examined the relationships between OS, SS, EE and stressors based on a survey of construction cost estimation personnel. T-tests, factor analyses, correlation analyses and regression analyses were applied to identify differences between the professional estimators and other personnel, and the types of stress endured. The results indicate that the stress levels of both the professional estimators and other personnel are similar, with OS being significantly higher than SS, which is in turn significantly higher than EE. For professional estimators, increased levels of OS were found to be mainly associated with lack of autonomy and unfair reward and treatment. Increased SS and EE, on the other hand, appeared to be a function of relationship conflict, work underload, lack of feedback, lack of autonomy and unfair reward and treatment. Journal: Construction Management and Economics Pages: 1063-1075 Issue: 10 Volume: 25 Year: 2007 Keywords: Cost estimator, emotional exhaustion, objective stress, subjective stress, stress, stressors, X-DOI: 10.1080/01446190701573296 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701573296 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:10:p:1063-1075 Template-Type: ReDIF-Article 1.0 Author-Name: John Alfred Rooke Author-X-Name-First: John Alfred Author-X-Name-Last: Rooke Author-Name: Lauri Koskela Author-X-Name-First: Lauri Author-X-Name-Last: Koskela Author-Name: David Seymour Author-X-Name-First: David Author-X-Name-Last: Seymour Title: Producing things or production flows? Ontological assumptions in the thinking of managers and professionals in construction Abstract: New approaches to production management can be conceptualized as treating production as flow rather than transformation. These alternatives can in turn be regarded as reflecting opposing ontological positions, holding respectively that reality is constituted of temporal process, or atemporal substance. The new production philosophy thus arguably represents a process ontology radically different from the atemporal metaphysics underlying conventional methods and theories. Moreover, research in physics education has identified the disjunction between ontological categories of 'substance' and 'process' as a particularly acute barrier to understanding process phenomena. Studies are presented which demonstrate the possibility of specifying and classifying mental models, with regard to two important management solutions in construction. Thus, procedures typically adopted in quantity surveying and the implementation of structural engineering design are examined. Methods of measurement used in quantity surveying are designed to account primarily for physical, rather than temporal properties. In design, the emphasis is on representing properties of finished structures, rather than the construction processes. The process is then managed by treating the design and its execution as separate products. It is argued here that alternative, more effective management solutions are derived from a process ontology. Journal: Construction Management and Economics Pages: 1077-1085 Issue: 10 Volume: 25 Year: 2007 Keywords: Decision making, indexicality, learning, lean construction, management theory, metaphysics, ontological categories, X-DOI: 10.1080/01446190701598665 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701598665 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:10:p:1077-1085 Template-Type: ReDIF-Article 1.0 Author-Name: Sarel Lavy Author-X-Name-First: Sarel Author-X-Name-Last: Lavy Author-Name: Igal Shohet Author-X-Name-First: Igal Author-X-Name-Last: Shohet Title: On the effect of service life conditions on the maintenance costs of healthcare facilities Abstract: Global competitiveness and increasing performance requirements have placed facilities management (FM) under constraints of limited resources, particularly in non-core aspects of facilities, such as maintenance and operations. The hypothesis applied in this research is that the actual service life of buildings, their occupancy and their ambient environmental conditions affect the required maintenance resources of these facilities. The objective was to develop a facility coefficient aiming to adjust the allocation of maintenance resources to prevailing service conditions in healthcare facilities. The research uses deterioration patterns and predicted service lives of building components and systems under moderate, standard and intensive occupancy and under two categories of environment: marine and inland. In total, five configurations combining occupancy and environmental conditions were investigated through simulations and compared to a reference configuration defined as standard occupancy and inland environment along with a building designed service life of 75 years. The findings of the simulations show that maintenance resources in healthcare facilities vary between -9% and +18% of the standard configuration. The simulation results can be used for reliable allocation of resources for maintenance of healthcare facilities. Findings can be adapted for residential, office, public and educational facilities. Journal: Construction Management and Economics Pages: 1087-1098 Issue: 10 Volume: 25 Year: 2007 Keywords: Facilities management, healthcare, maintenance, occupancy, service conditions, X-DOI: 10.1080/01446190701393034 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701393034 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:10:p:1087-1098 Template-Type: ReDIF-Article 1.0 Author-Name: Gerard Wood Author-X-Name-First: Gerard Author-X-Name-Last: Wood Author-Name: David Keel Author-X-Name-First: David Author-X-Name-Last: Keel Title: Letter to the editor Abstract: Journal: Construction Management and Economics Pages: 1103-1105 Issue: 11 Volume: 25 Year: 2007 X-DOI: 10.1080/01446190701670340 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701670340 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:11:p:1103-1105 Template-Type: ReDIF-Article 1.0 Author-Name: Zhikun Ding Author-X-Name-First: Zhikun Author-X-Name-Last: Ding Author-Name: Fungfai Ng Author-X-Name-First: Fungfai Author-X-Name-Last: Ng Title: Reliability and validity of the Chinese version of McAllister's trust scale Abstract: While most trust scales have their original versions in English, few attempts have been made to study the reliability and validity of their translated versions. Among the trust scales available in the literature, McAllister's cognition- and affect-based trust scale is a self-rating scale, developed to test the trust relationship between managers and professionals. It is translated into Chinese with translation/back-translation technique and used in a survey among architects in Mainland China to measure interpersonal trust in a design team. Reliability analysis shows that Cronbach alphas for cognition-based and affect-based trust are found to be high (0.803 and 0.841 respectively). First-order and second-order confirmatory factor analysis with Amos 6.0 are conducted to test the validity of the two-dimensional structure. Structural equation modelling method is used to test the nomological validity of the translated trust scale with respect to architects' willingness to share knowledge in a design team. Findings suggest that the two-dimensional structure of the McAllister's trust scale can be applied to Chinese architects. Moreover, the cognition- and affect-based trust scale could be used in a more general context. The positive relationship between the two-dimensional trust and architects' willingness to share knowledge is also confirmed, which substantiates the nomological validity of the translated trust scale. Journal: Construction Management and Economics Pages: 1107-1117 Issue: 11 Volume: 25 Year: 2007 Keywords: Trust, scale, translation, confirmatory factor analysis, architect, X-DOI: 10.1080/01446190701670357 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701670357 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:11:p:1107-1117 Template-Type: ReDIF-Article 1.0 Author-Name: Kevin Simmons Author-X-Name-First: Kevin Author-X-Name-Last: Simmons Author-Name: Daniel Sutter Author-X-Name-First: Daniel Author-X-Name-Last: Sutter Title: Tornado shelters and the housing market Abstract: Mitigation against natural hazards often involves long-lived, immobile investments. Home owners must be able to capture the present value of future benefits to equate the private and societal return on mitigation. The capitalization of mitigation into home prices thus is crucial for home owners to have a proper incentive for mitigation. We investigate the existence of a premium for tornado shelters using home sales in Oklahoma City, where the deadly tornado outbreak of 3 May 1999 and the Oklahoma Saferoom Initiative increased public awareness of tornado shelters. We find that a shelter increases the sale price of a home by 3.5% to 4% or approximately $4200 given the mean price of homes sold in 2005. The magnitude of the premium is plausible given that shelters retail for $2500-$3000 installed. Journal: Construction Management and Economics Pages: 1119-1126 Issue: 11 Volume: 25 Year: 2007 Keywords: Natural disasters, prices, tornado shelters, mitigation, multiple regression, X-DOI: 10.1080/01446190701618299 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701618299 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:11:p:1119-1126 Template-Type: ReDIF-Article 1.0 Author-Name: Chi Ming Tam Author-X-Name-First: Chi Ming Author-X-Name-Last: Tam Author-Name: Thomas Tong Author-X-Name-First: Thomas Author-X-Name-Last: Tong Author-Name: Bill Wong Author-X-Name-First: Bill Author-X-Name-Last: Wong Title: An integrated system for earthmoving planning Abstract: In earthmoving operations, there are a number of activities that need to be considered; for example, path identification, plant selection, assessing the compatibility of the paths and the plants so selected, cost and productivity comparison of alternatives, safety and environmental considerations, etc. The traditional approach to this problem by heuristic rules generated from the experience of planners cannot guarantee an optimal solution. Hence, a scientific method is proposed to automate the earthmoving planning by integrating: (1) a path-finding algorithm; (2) a plant selection system; (3) application of extenics theory to address the compatibility; and (4) the use of genetic algorithms to optimize the alternatives in terms of costs, productivity, safety and environmental considerations. The integrated system is illustrated step by step using a genuine construction project as an example. The result demonstrates the effectiveness of the system in automating the earthmoving planning exercise. Journal: Construction Management and Economics Pages: 1127-1137 Issue: 11 Volume: 25 Year: 2007 Keywords: Automation, earthworks, extenics theory, integrated system, genetic algorithms, X-DOI: 10.1080/01446190701468836 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701468836 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:11:p:1127-1137 Template-Type: ReDIF-Article 1.0 Author-Name: Jiukun Dai Author-X-Name-First: Jiukun Author-X-Name-Last: Dai Author-Name: Paul Goodrum Author-X-Name-First: Paul Author-X-Name-Last: Goodrum Author-Name: William Maloney Author-X-Name-First: William Author-X-Name-Last: Maloney Title: Analysis of craft workers' and foremen's perceptions of the factors affecting construction labour productivity Abstract: Extensive studies have been conducted to examine the factors affecting construction productivity, but efforts have rarely been made to obtain craft workers' input. A survey was administered to 1996 craft workers throughout the US to quantify the workforce's perspective of construction labour productivity. Specifically, the survey measured the impact of 83 productivity factors, which had been identified through 18 focus group sessions with craft workers and their immediate supervisors on jobsites located throughout the US. Craft workers provide detailed insight into the factors affecting their daily productivity, and most of the adversarial factors affecting construction labour productivity can be addressed by jobsite management teams. The major findings indicated that craft workers and foremen share a general perception of the factors impacting on construction productivity; however, differences do exist. Specifically, foremen reported factors related to project management and engineering drawings having a more severe impact on their productivity compared to craft workers, and craft workers reported factors related to construction materials as having a more severe impact. Journal: Construction Management and Economics Pages: 1139-1152 Issue: 11 Volume: 25 Year: 2007 Keywords: Labour productivity, workforce, site management, USA, X-DOI: 10.1080/01446190701598681 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701598681 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:11:p:1139-1152 Template-Type: ReDIF-Article 1.0 Author-Name: Patricia Tzortzopoulos Author-X-Name-First: Patricia Author-X-Name-Last: Tzortzopoulos Author-Name: Martin Sexton Author-X-Name-First: Martin Author-X-Name-Last: Sexton Title: An investigation on the implementation of product development process models in construction companies Abstract: Process models have been developed by academia and industry to enhance design and construction activities. However, effective and widespread adoption and use of such models in practice has been limited. This research investigated the dynamics of product development process (PDP) models implementation in construction companies. Four case studies were undertaken, and key findings emphasize the need to consider the design and implementation of PDP models in an integrated fashion within the organizational context in which it takes place; and the need for a shift in the role of PDP models from a rational 'planning and control' perspective to a softer 'learning' approach. Journal: Construction Management and Economics Pages: 1153-1164 Issue: 11 Volume: 25 Year: 2007 Keywords: Product development process, process modelling, implementation, construction companies, X-DOI: 10.1080/01446190701468851 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701468851 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:11:p:1153-1164 Template-Type: ReDIF-Article 1.0 Author-Name: Ilknur Akiner Author-X-Name-First: Ilknur Author-X-Name-Last: Akiner Author-Name: Wilco Tijhuis Author-X-Name-First: Wilco Author-X-Name-Last: Tijhuis Title: Work goal orientation of construction professionals in Turkey: comparison of architects and civil engineers Abstract: The construction industry is a significant part of the global economy, affected by and affecting all dynamics of global competition. However, there seems to have been a limited amount of research conducted on differences between countries through the construction industry's culture. Such comparisons are crucial to identify the cultural factors that are likely to influence the competitive advantage of the Turkish construction industry at both domestic and international levels. Cultural similarities and differences in work goal orientation are compared between selected groups of professionals in the Turkish construction industry. We aim to provide information on the work goals of both civil engineers and architects involved with the construction sector in terms of occupation, gender and age, respectively. Hofstede's VSM question form was used to establish cultural profiles of the participants. The cultural dimensions of architects and civil engineers provide a sample picture of Turkish construction industry. Journal: Construction Management and Economics Pages: 1165-1175 Issue: 11 Volume: 25 Year: 2007 Keywords: Culture, occupational culture, Turkey, work goals, professionals, X-DOI: 10.1080/01446190701670365 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701670365 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:11:p:1165-1175 Template-Type: ReDIF-Article 1.0 Author-Name: Kamardeen Imriyas Author-X-Name-First: Kamardeen Author-X-Name-Last: Imriyas Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Author-Name: Evelyn Ai-Lin Teo Author-X-Name-First: Evelyn Ai-Lin Author-X-Name-Last: Teo Title: A fuzzy knowledge-based system for premium rating of workers' compensation insurance for building projects Abstract: Occupational injuries and fatalities are rampant in construction. The significance of the workers' compensation insurance (WCI) is immeasurable in safeguarding the interests of construction workers and contractors. From the insurers' perspective, the commitment under this insurance is extremely broad; there are no exclusions and a maximum limit on their liability. Thus, insurers must accomplish rigorous risk and market assessments to decide optimal premiums for construction projects. The conventional experience rating approach of premium rating has been proven ineffective for construction applications. Based on the findings of a literature review and an interview questionnaire survey, a new WCI premium rating model was developed for building projects. A hybrid of interviews and past workers' compensation claims data analysis was adopted to develop the conceptual model of a fuzzy knowledge-based system (KBS) to automate the proposed model. It was then prototyped, and verified with Turing tests. The proposed model and its fuzzy KBS advocate real time structured assessments of project hazards, safety, market condition and insurers' internal factors for premium rating. They also establish an effective risk control strategy via a well-structured incentive system for contractors and clients. Their implementation in the general insurance industry can facilitate accident control in the construction industry, thereby minimizing insurers' financial risks. Journal: Construction Management and Economics Pages: 1177-1195 Issue: 11 Volume: 25 Year: 2007 Keywords: Occupational health and safety, insurance, fuzzy logic, knowledge-based system, X-DOI: 10.1080/01446190701398462 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701398462 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:11:p:1177-1195 Template-Type: ReDIF-Article 1.0 Author-Name: Christopher Gorse Author-X-Name-First: Christopher Author-X-Name-Last: Gorse Author-Name: Stephen Emmitt Author-X-Name-First: Stephen Author-X-Name-Last: Emmitt Title: Communication behaviour during management and design team meetings: a comparison of group interaction Abstract: Although a few studies have investigated the communication behaviour of construction professionals this research represents the first attempt to model the construction team's interaction in live project meetings. Using the established Bales interaction process analysis (IPA) method, both task and relational interaction were recorded and a model of group communication was produced. A total of 36 meetings were observed from 10 construction projects and the data aggregated to provide a single profile of the groups' interaction. The construction meetings' interaction is compared to previous research undertaken in other contexts. Differences were found between the interaction patterns of work, social and academic groups. Typical of the interaction previously observed in work groups, the participants in construction meetings use high levels of task-based interaction and low levels of socio-emotional interaction. The adversarial environment often associated with construction was not found, indeed the level of negative emotion and critical discussion was so low that it could be suggested that problems may pass unchallenged. Journal: Construction Management and Economics Pages: 1197-1213 Issue: 11 Volume: 25 Year: 2007 Keywords: Communication, group dynamics, design, management, teams, X-DOI: 10.1080/01446190701567413 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701567413 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:11:p:1197-1213 Template-Type: ReDIF-Article 1.0 Author-Name: John Yeung Author-X-Name-First: John Author-X-Name-Last: Yeung Author-Name: Albert Chan Author-X-Name-First: Albert Author-X-Name-Last: Chan Author-Name: Daniel Chan Author-X-Name-First: Daniel Author-X-Name-Last: Chan Author-Name: Leong Kwan Li Author-X-Name-First: Leong Kwan Author-X-Name-Last: Li Title: Development of a partnering performance index (PPI) for construction projects in Hong Kong: a Delphi study Abstract: Over the past decade, research studies on benefits, critical success factors, difficulties, process, conceptual and theoretical models of construction partnering have been ubiquitous in the construction management discipline. In fact, there is adequate evidence that an increasing number of client organizations are adopting a partnering approach to undertake their building and construction projects both locally and worldwide during the last decade. With the perceived benefits that partnering brings about, research into Key Performance Indicators (KPIs) to evaluate the success of partnering projects in construction becomes vital as it can help set a benchmark for measuring the performance level of partnering projects. However, although there are some related studies and papers on this research area, few, if any, comprehensive and systematic studies focus on developing a comprehensive, objective, reliable and practical performance evaluation model for partnering projects. A model has been developed using the Delphi survey technique to objectively measure the performance of partnering projects in Hong Kong based on a consolidated KPIs' conceptual framework previously developed for partnering projects. Four rounds of Delphi questionnaire survey were conducted with 31 construction experts in Hong Kong. The results reveal that the top seven weighted KPIs to evaluate the success of partnering projects in Hong Kong were: (1) time performance; (2) cost performance; (3) top management commitment; (4) trust and respect; (5) quality performance; (6) effective communications; and (7) innovation and improvement. A statistically significant consensus on the top seven weighted KPIs was also obtained. Finally, a composite Partnering Performance Index (PPI) for partnering projects in Hong Kong was derived to provide an all-round assessment of partnering performance. Different partnering projects can now be assessed on the same basis for benchmarking purposes. Construction senior executives and project managers can thus use the Index to measure, evaluate and improve the performance of their partnering projects to strive for construction excellence. Although the PPI was developed locally in Hong Kong, the research method could be replicated in other parts of the world to produce similar indices for international comparison. Such an extension would aid the understanding of managing partnering projects across different geographic locations. Journal: Construction Management and Economics Pages: 1219-1237 Issue: 12 Volume: 25 Year: 2007 Keywords: Key Performance Indicators (KPIs), Partnering Performance Index (PPI), Delphi method, Delphi study, Hong Kong, X-DOI: 10.1080/01446190701598673 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701598673 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:12:p:1219-1237 Template-Type: ReDIF-Article 1.0 Author-Name: Jack Goulding Author-X-Name-First: Jack Author-X-Name-Last: Goulding Author-Name: Martin Sexton Author-X-Name-First: Martin Author-X-Name-Last: Sexton Author-Name: Xiaonan Zhang Author-X-Name-First: Xiaonan Author-X-Name-Last: Zhang Author-Name: Mike Kagioglou Author-X-Name-First: Mike Author-X-Name-Last: Kagioglou Author-Name: Ghassan Aouad Author-X-Name-First: Ghassan Author-X-Name-Last: Aouad Author-Name: Peter Barrett Author-X-Name-First: Peter Author-X-Name-Last: Barrett Title: Technology adoption: breaking down barriers using a virtual reality design support tool for hybrid concrete Abstract: The use of hybrid concrete technologies as a viable solution to traditional frame design has been inhibited by a general lack of information. The uptake of this technology has therefore been slow and parochial, as designers have tended to stay loyal to 'traditional', tried and tested technologies—their 'comfort zone'. This research identifies the barriers associated with technology adoption at industry, organization and individual levels; and uses hybrid concrete as the core context for discussion. The role of an enabling design support tool (HyCon) is presented, which can allow designers to overcome these inhibitors by providing an immersive, interactive and information-rich environment through which design solutions can be explored. This collaborative research project describes a 'proof of concept' design support tool to promote the use of hybrid concrete in structural frames. It encompasses knowledge creation, application and sharing functionality, to envision support and use of this new technology—thereby promoting organizational learning. Research findings note that, while design tools have a valuable role to play, it is also important to appreciate that the uptake of any new technology is a social phenomenon, and that subsequent adoption/uptake requires careful embedding and augmentation into company organizational systems in order to leverage advantage. Journal: Construction Management and Economics Pages: 1239-1250 Issue: 12 Volume: 25 Year: 2007 Keywords: Design method, virtual prototyping, organizational learning, decision making, simulation, X-DOI: 10.1080/01446190701504234 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701504234 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:12:p:1239-1250 Template-Type: ReDIF-Article 1.0 Author-Name: Colin Gray Author-X-Name-First: Colin Author-X-Name-Last: Gray Author-Name: Richard John Davies Author-X-Name-First: Richard John Author-X-Name-Last: Davies Title: Perspectives on experiences of innovation: the development of an assessment methodology appropriate to construction project organizations Abstract: The UK construction industry is in the process of trying to adopt a new culture based on the large-scale take up of innovative practices. Through the Demonstration Project process many organizations are implementing changed practices and learning from the experiences of others. This is probably the largest experiment in innovation in any industry in recent times. The long-term success will be measured by the effectiveness of embedding the new practices in the organization. As yet there is no recognized approach to measuring the receptivity of the organization to the innovation process as an indication of the likelihood of long-term development. The development of an appropriate approach is described here. Existing approaches to the measurement of the take up of innovation were reviewed and where appropriate used as the base for the development of a questionnaire. The questionnaire could be applicable to multi-organizational construction project situations such that the output could determine an individual organization's innovative practices via an innovation scorecard, a project team's approach or it could be used to survey a wide cross-section of the industry. Journal: Construction Management and Economics Pages: 1251-1268 Issue: 12 Volume: 25 Year: 2007 Keywords: Innovation, measurement, methodology, X-DOI: 10.1080/01446190701573692 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701573692 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:12:p:1251-1268 Template-Type: ReDIF-Article 1.0 Author-Name: Nannan Wang Author-X-Name-First: Nannan Author-X-Name-Last: Wang Author-Name: Malcolm Horner Author-X-Name-First: Malcolm Author-X-Name-Last: Horner Title: CSI model for estimating road maintenance projects Abstract: Major road maintenance projects need an accurate cost estimate at the early stage of design. At present, simple and quick models are lacking. Two easy-to-use cost models for major asphalt road maintenance projects are developed. The double mean model and the trend line model are based on the cost-significance method. The historical data used are bills of quantities (BoQs) of major road maintenance projects including reconstruction, overlay and resurfacing. The cost-significant items in the models are consistent for this type of project. Further BoQs are used to test the accuracy of the cost-significance models. The two cost-significance models simplify the data collection and cost modelling process. The double mean model is suitable for quick estimates at scheme design stage, while the trend line model has a much better accuracy and is still simpler than traditional methods, and is therefore appropriate to use for the detailed design stage. Because there are fewer items whose costs require estimating, it is likely that the cost of each item can be estimated more accurately. Journal: Construction Management and Economics Pages: 1269-1281 Issue: 12 Volume: 25 Year: 2007 Keywords: Cost significance, cost modelling, estimating, major road maintenance project, X-DOI: 10.1080/01446190701670373 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701670373 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:12:p:1269-1281 Template-Type: ReDIF-Article 1.0 Author-Name: Rosanna Isadora Duncan Author-X-Name-First: Rosanna Isadora Author-X-Name-Last: Duncan Author-Name: Julianne Mortimer Author-X-Name-First: Julianne Author-X-Name-Last: Mortimer Title: Race equality and procurement: an investigation into the impact of race equality policy on the procurement of Black and Minority Ethnic (BME) contractors and consultants in the Welsh social housing sector Abstract: In 2002, the Welsh Assembly Government published its Black and Minority Ethnic (BME) Housing Action Plan for Wales. This required social landlords in Wales to develop policies, practices and procedures which took into account the needs of BME people. This plan also stated that they should promote race equality within the procurement process by increasing their use of BME contractors and consultants and by ensuring that the contractors and consultants they engaged were operating within a race equality framework. The aim of this research was to investigate the factors affecting race equality and procurement in the social housing sector in Wales. This involved collecting data from social landlords, main contractors and consultants and BME contractors and consultants. This research discusses the data collected from 39 social landlords in Wales (12 of the 22 local authorities and 27 of the 30 major housing associations). Data were collected relating to their procurement practices and procedures. The research found that few social landlords in Wales were actively addressing the issue of race equality within the procurement process and that much is needed to be done by social landlords in Wales to ensure race equality throughout the procurement process. Journal: Construction Management and Economics Pages: 1283-1293 Issue: 12 Volume: 25 Year: 2007 Keywords: BME, construction industry, equality, procurement and social housing, X-DOI: 10.1080/01446190701474198 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701474198 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:12:p:1283-1293 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Author-Name: Per-Erik Josephson Author-X-Name-First: Per-Erik Author-X-Name-Last: Josephson Title: Coaching the site manager: effects on learning and managerial practice Abstract: Coaching has emerged as a potentially powerful leadership development approach, capable of effectively blending theoretical knowledge and practical skills in onsite training. To date, little research on the use of coaching in the construction industry has been published and the coaching literature is primarily written by coaches with vested interests. In addition, there are a limited number of critical and empirical evaluations of the approach. A year-long action research coaching project in the Swedish construction industry shows that site managers participating in the coaching programme developed skills for reflecting on their work life situation, improved their communication, and became better equipped for seeing a broader range of perspectives in their work. In addition, the coaching programme opened up new discussions in the construction projects, which benefited further communication. The overall reception of the coaching programme was enthusiastic. While coaching does not come without costs and efforts, it may serve as a leadership development approach capable of helping site managers develop their leadership skills, cope with work-family conflicts, and improve their communication. Journal: Construction Management and Economics Pages: 1295-1304 Issue: 12 Volume: 25 Year: 2007 Keywords: Coaching, leadership development, site managers, X-DOI: 10.1080/01446190701466111 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701466111 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:12:p:1295-1304 Template-Type: ReDIF-Article 1.0 Author-Name: Katherine Sang Author-X-Name-First: Katherine Author-X-Name-Last: Sang Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: Stephen Ison Author-X-Name-First: Stephen Author-X-Name-Last: Ison Title: Gender: a risk factor for occupational stress in the architectural profession? Abstract: There is significant evidence that those working in construction are at risk of poor health and well-being due to long working hours, job insecurity, poor work-life balance, low professional worth and temporary teams. There is also a disparate body of evidence which highlights the discrimination experienced by women working in the construction industry. There is, however, a paucity of research exploring gender differences in occupational health and well-being within construction. The current research utilizes standardized measures of occupational health and well-being to identify any gender-determined differences among a sample of architects. A self-completion questionnaire was used to assess job satisfaction, physical health problems, work-life conflict and turnover intentions. Female respondents reported significantly lower overall job satisfaction and significantly higher levels of insomnia and constipation, work-life conflict and turnover intentions. Although further work is needed to understand the causal relationships between variables and the nature of the female architects' dissatisfactions and concerns, the suggestion that women working in the architectural profession are at risk of poorer occupational health and well-being than their male colleagues will be of concern to a profession seeking to embrace diversity. Journal: Construction Management and Economics Pages: 1305-1317 Issue: 12 Volume: 25 Year: 2007 Keywords: Architects, occupational health and well-being, women, gender differences, X-DOI: 10.1080/01446190701546177 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701546177 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:25:y:2007:i:12:p:1305-1317 Template-Type: ReDIF-Article 1.0 Author-Name: Joao Neves Author-X-Name-First: Joao Author-X-Name-Last: Neves Author-Name: Antonio Bugalho Author-X-Name-First: Antonio Author-X-Name-Last: Bugalho Title: Coordination and control in emerging international construction firms Abstract: Decisions pertaining to the coordination and control of subsidiaries made by emerging international construction firms are crucial for the success of their internationalization process. The case study approach, based on four emerging international construction firms with headquarters in Portugal, is used to analyse the coordination and control processes adopted by these construction firms at an early internationalization stage. The proposition of the study was that these types of firms learn more from their experiences than from the existing theory in the literature. The results show a clear pattern of replication of home norms and practices, suggesting that at an early stage they neglect the theory of international business, the host countries' specificities and the consequent adaptation needs. The case studies show that all the headquarters initiated the control of their international activities through home-based bureaucratic systems, but have realized that they need more cultural and social control, as recommended by Bartlett and Ghoshal (1989, 1992). Journal: Construction Management and Economics Pages: 3-13 Issue: 1 Volume: 26 Year: 2008 Keywords: Multinational firms, international business, management control, X-DOI: 10.1080/01446190701793670 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701793670 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:1:p:3-13 Template-Type: ReDIF-Article 1.0 Author-Name: Hamzah Abdul-Rahman Author-X-Name-First: Hamzah Author-X-Name-Last: Abdul-Rahman Author-Name: Imran Ariff Yahya Author-X-Name-First: Imran Ariff Author-X-Name-Last: Yahya Author-Name: Mohammed Ali Berawi Author-X-Name-First: Mohammed Ali Author-X-Name-Last: Berawi Author-Name: Low Wai Wah Author-X-Name-First: Low Wai Author-X-Name-Last: Wah Title: Conceptual delay mitigation model using a project learning approach in practice Abstract: There is universal agreement that construction delay is a common phenomenon in the construction industry worldwide. Poor or lack of project knowledge management continues to plague the construction industry, especially in relation to project delays. Knowledge management is used to reduce the impact of construction projects delay using a project learning approach. Three different phases of data collection were used for the development of a delay mitigation model, namely preliminary survey, case studies and interviews survey. The project learning approach contributes towards positive impacts on project schedule performance. Also, good leadership and integrated commitment of all project parties are the principal impetus to improve the delay phenomenon in the construction industry. The conceptual model incorporates knowledge on knowledge management, project learning, lessons learned feedback and supervisory control principles. The results indicate that the application of project learning is a way to align the project schedule performance to client and market needs while maintaining the contractor's core competency. Journal: Construction Management and Economics Pages: 15-27 Issue: 1 Volume: 26 Year: 2008 Keywords: Delay, knowledge management, project learning, X-DOI: 10.1080/01446190701744350 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701744350 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:1:p:15-27 Template-Type: ReDIF-Article 1.0 Author-Name: Lawrence Wai Chung Lai Author-X-Name-First: Lawrence Wai Chung Author-X-Name-Last: Lai Author-Name: Felicity Wai Ngar Ng Author-X-Name-First: Felicity Wai Author-X-Name-Last: Ngar Ng Author-Name: Ping Yung Author-X-Name-First: Ping Author-X-Name-Last: Yung Title: The Coase Theorem and a Coasian construction economics and management research agenda Abstract: This paper seeks to construct an empirical research agenda based on transaction cost reasoning informed by the Coase Theorem. It explains why the Coase Theorem has not been well received in the area of construction economics and management, as revealed by the relevant bibliometrics; develops a transaction cost-based research agenda for this arena based on the corollaries of the invariant version and optimality version of the Coase Theorem; and maps the current research endeavours that fall into that agenda. It has been explained that the Coase Theorem was based on Coase's 1960 article, 'The problem of social cost', and is not only compatible with, but also more general than, Coase's theory of the firm offered in his 1937 paper, 'The nature of the firm'. Hence, the 'two Coases' characterization, which suggests a dichotomy pro-organization/regulation stance versus a pro-free market stance, is fallacious. Journal: Construction Management and Economics Pages: 29-46 Issue: 1 Volume: 26 Year: 2007 Keywords: Coase Theorem, transaction cost, property rights, bibliometrics, construction economics and management, X-DOI: 10.1080/01446190701450438 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701450438 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2007:i:1:p:29-46 Template-Type: ReDIF-Article 1.0 Author-Name: Ren-Jye Dzeng Author-X-Name-First: Ren-Jye Author-X-Name-Last: Dzeng Author-Name: Shyh-Shiuh Wang Author-X-Name-First: Shyh-Shiuh Author-X-Name-Last: Wang Title: An analysis of infrastructure development based on national competitiveness perspectives Abstract: Development of the infrastructure is one of the key factors in determining the competitiveness of a nation. Most world competitiveness reports include infrastructure development as a primary set of indicators in assessing the competitiveness of nations. We ranked the indicators based on their performances in terms of not only standard deviations but also leading and falling-behind groups classified by the cluster analysis. The discriminant competitiveness graphic-based representation of the indicator performance allowed policy makers to formulate infrastructure strategies. Simulated experiments based on the competitiveness data of Canada, Taiwan and Thailand also demonstrated that such ranking resulted in a better selection of weak indicators for improvement. Journal: Construction Management and Economics Pages: 47-61 Issue: 1 Volume: 26 Year: 2007 Keywords: National competitiveness, infrastructure, discriminant competitiveness graphics, clustering analysis, X-DOI: 10.1080/01446190701670381 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701670381 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2007:i:1:p:47-61 Template-Type: ReDIF-Article 1.0 Author-Name: Stuart Green Author-X-Name-First: Stuart Author-X-Name-Last: Green Author-Name: Graeme Larsen Author-X-Name-First: Graeme Author-X-Name-Last: Larsen Author-Name: Chung-Chin Kao Author-X-Name-First: Chung-Chin Author-X-Name-Last: Kao Title: Competitive strategy revisited: contested concepts and dynamic capabilities Abstract: Strategy is a contested concept. The generic literature is characterized by a diverse range of competing theories and alternative perspectives. Traditional models of the competitive strategy of construction firms have tended to focus on exogenous factors. In contrast, the resource-based view of strategic management emphasizes the importance of endogenous factors. The more recently espoused concept of dynamic capabilities extends consideration beyond static resources to focus on the ability of firms to reconfigure their operating routines to enable responses to changing environments. The relevance of the dynamics capabilities framework to the construction sector is investigated through an exploratory case study of a regional contractor. The focus on how firms continuously adapt to changing environments provides new insights into competitive strategy in the construction sector. Strong support is found for the importance of path dependency in shaping strategic choice. The case study further suggests that strategy is a collective endeavour enacted by a loosely defined group of individual actors. Dynamic capabilities are characterized by an empirical elusiveness and as such are best construed as situated practices embedded within a social and physical context. Journal: Construction Management and Economics Pages: 63-78 Issue: 1 Volume: 26 Year: 2008 Keywords: Strategic management, contracting, industry change, case study, dynamic capabilities, X-DOI: 10.1080/01446190701656174 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701656174 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:1:p:63-78 Template-Type: ReDIF-Article 1.0 Author-Name: Ozay Mehmet Author-X-Name-First: Ozay Author-X-Name-Last: Mehmet Author-Name: Vedat Yorucu Author-X-Name-First: Vedat Author-X-Name-Last: Yorucu Title: Explosive construction in a micro-state: environmental limit and the Bon curve: evidence from North Cyprus Abstract: The dynamo role of the construction sector in North Cyprus is documented on the basis of an empirical estimation of backward and forward linkages during the period 1998 to 2005. This was a period when the North Cyprus economy experienced an economic boom in the aftermath of the UN Peace Plan known as the Annan Plan for settling the Cyprus problem. The latest input-output table for the North Cyprus economy is 1998 and we had to derive backward and forward linkages for 2005 from a detailed breakdown of inter-industry transactions per unit of construction output using the most significant purchases and deliveries, normalizing these transactions for comparability between 2005 and 1998. The results reflect radically different pattern of inter-industry transactions in 2005 compared to 1998. This work also has general interest in highlighting the possibility of a modified Bon curve for micro-states, such as North Cyprus, in which environmental constraints may be encountered earlier implying an inverted V-shaped Bon curve in place of an inverted U-shape. Journal: Construction Management and Economics Pages: 79-88 Issue: 1 Volume: 26 Year: 2007 Keywords: Developing countries, backward linkages, Bon-curve, environmental impacts, X-DOI: 10.1080/01446190701708272 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701708272 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2007:i:1:p:79-88 Template-Type: ReDIF-Article 1.0 Author-Name: Sonja Petrovic-Lazarevic Author-X-Name-First: Sonja Author-X-Name-Last: Petrovic-Lazarevic Title: The development of corporate social responsibility in the Australian construction industry Abstract: In the Australian construction industry, large companies develop corporate social responsibility (CSR) in order to maintain an image of being a good corporate citizen. CSR relevant to the construction industry is defined including the following activities: moral obligation to be a good citizen; sustainability; reputation; relationship with employees and unions; relationship with suppliers and community representatives; and commitment to reporting on CSR. CSR is then examined through 85 interviews conducted with members of boards of directors, suppliers, employees, customers and community representatives of 17 large corporations. In order to be recognized as a socially responsible business, the corporations should: apply a corporate governance structure that takes into consideration working environment concerns; improve their sustainability, occupational health and safety measures, relationships with suppliers and commitment to local community protection and engagement. Journal: Construction Management and Economics Pages: 93-101 Issue: 2 Volume: 26 Year: 2008 Keywords: Corporate social responsibility, construction industry, corporate governance, X-DOI: 10.1080/01446190701819079 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701819079 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:2:p:93-101 Template-Type: ReDIF-Article 1.0 Author-Name: Gonzalo Lizarralde Author-X-Name-First: Gonzalo Author-X-Name-Last: Lizarralde Author-Name: David Root Author-X-Name-First: David Author-X-Name-Last: Root Title: The informal construction sector and the inefficiency of low cost housing markets Abstract: Urban low cost housing markets in developing countries are often inefficient and subsidized programmes can add further market distortions. In the case of South Africa, one of the important causes of the inefficiency of the housing market (and one that is often ignored) is the fact that housing policies and construction practices systematically exclude the informal construction sector: the very sector that has been the only source of delivery of affordable housing for the bottom poor. After the end of the apartheid era and the transition to democracy in 1994, an ambitious programme of subsidized housing was implemented in the country. Since then, more than 1.6 million housing units have been built but the housing policies have not created a functional residential market for low income South Africans. In spite of the good intentions of the stakeholders in the marketplace, some projects developed by NGOs do not help to overcome these shortcomings and frequently accentuate some of the inefficiencies of the market. Four case studies of housing projects in Cape Town show the common constraints derived from institutional structures and prevailing attitudes among the NGOs and other stakeholders that prevent the informal sector from being involved. Giving greater participation to the informal sector in subsidized housing projects might prove difficult as it requires modification of structural policies and reformulation of the principles and values of urban intervention. However, these changes are required to reduce the housing deficit in South Africa. Journal: Construction Management and Economics Pages: 103-113 Issue: 2 Volume: 26 Year: 2008 Keywords: Housing development, residential, informal housing, markets, South Africa, X-DOI: 10.1080/01446190701808965 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701808965 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:2:p:103-113 Template-Type: ReDIF-Article 1.0 Author-Name: Yong-Huang Lin Author-X-Name-First: Yong-Huang Author-X-Name-Last: Lin Author-Name: Pin-Chan Lee Author-X-Name-First: Pin-Chan Author-X-Name-Last: Lee Author-Name: Ta-Peng Chang Author-X-Name-First: Ta-Peng Author-X-Name-Last: Chang Title: Integrating grey number and Minkowski distance function into grey relational analysis technique to improve the decision quality under uncertain information Abstract: Giving precise evaluation numbers becomes much more problematic in decision-making problems owing to the growing uncertainty inherently embedded in the increasing complexity of engineering systems. To alleviate this problem, both grey number and Minkowski distance function are integrated into the grey relational analysis technique to establish an effective multi-attribute decision-making model. In the proposed model, the uncertain information is transformed through the operations of grey numbers and then evaluated by the approachability of the ideal preference alternative, from which the suitability of each alternative is measured by the grey number Minkowski distance function to decide the appropriate selection. Two illustrative examples, the selection of construction alternatives and the evaluation of subcontractors, are adopted to demonstrate the feasibility and practicability of the proposed model. Results are confirmed by the experts afterwards and show that the proposed model is efficient, robust and well appropriate for real-world applications. Journal: Construction Management and Economics Pages: 115-123 Issue: 2 Volume: 26 Year: 2008 Keywords: Grey number, grey relational analysis technique, multi-attribute decision making, uncertain information, X-DOI: 10.1080/01446190701821802 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701821802 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:2:p:115-123 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Natalie Galea Author-X-Name-First: Natalie Author-X-Name-Last: Galea Title: Genderlect and conflict in the Australian construction industry Abstract: The Australian construction industry is male dominated and highly confrontational. Critical decision and concept mapping methods are employed to explore the connection between these two characteristics by contrasting the cognitive bases of judgement and communication used by male and female workers in hypothetical conflict settings. Results indicate that the Australian construction industry's genderlect is male-centric and that this perpetuates the relatively high incidence of conflict. Women and men also behave differently in conflicts and in jobs that require them to engage in conflict and confrontation. Consequently, levels of conflict in the Australian construction industry could be reduced by increased female participation and feminizing communicative and behavioural responses to conflict. Journal: Construction Management and Economics Pages: 125-135 Issue: 2 Volume: 26 Year: 2008 Keywords: Gender, conflict, dispute, communication, X-DOI: 10.1080/01446190701798810 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701798810 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:2:p:125-135 Template-Type: ReDIF-Article 1.0 Author-Name: Fredrik Waara Author-X-Name-First: Fredrik Author-X-Name-Last: Waara Title: Mitigating contractual hazards in public procurement: a study of Swedish local authorities Abstract: Private sector buyers often award construction contracts through negotiation rather than through open competitive tendering. Negotiating with a reputable contractor is a way to mitigate contractual hazards. For many public sector buyers, however, open competitive tendering is required by law. The practices of procurement officers in local authorities are examined in regard to the selection of construction contractors, focusing particularly on their use of scoring-based competitive tendering and ex ante information exchange between procurement officers and the firms competing for contracts. Semi-structured interviews were carried out with 15 procurement officers in 10 local authorities in Sweden. Using the contractor's staffing of the project organization as a contract award criterion allows procurement officers to select reputable contractors. Arranging face-to-face meetings with contractors before the final award decision allows procurement officers to resolve at least some technical problems in complex construction projects. When negotiations are prohibited by law, these practices can be seen as combined responses to hazards of construction contracting. Journal: Construction Management and Economics Pages: 137-145 Issue: 2 Volume: 26 Year: 2008 Keywords: Contracting, procurement law, public sector, Sweden, X-DOI: 10.1080/01446190701793696 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701793696 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:2:p:137-145 Template-Type: ReDIF-Article 1.0 Author-Name: Yu Lay Langston Author-X-Name-First: Yu Lay Author-X-Name-Last: Langston Author-Name: Craig Ashley Langston Author-X-Name-First: Craig Ashley Author-X-Name-Last: Langston Title: Reliability of building embodied energy modelling: an analysis of 30 Melbourne case studies Abstract: Building design decisions are commonly based on issues pertaining to construction cost, and consideration of energy performance is made only within the context of the initial project budget. Even where energy is elevated to more importance, operating energy is seen as the focus and embodied energy is nearly always ignored. For the first time, a large sample of buildings has been assembled and analysed in a single study to improve the understanding of the relationship between energy and cost performance over their full life cycle. Thirty recently completed buildings in Melbourne, Australia have been studied to explore the accuracy of initial embodied energy prediction based on capital cost at various levels of model detail. The embodied energy of projects, elemental groups, elements and selected items of work are correlated against capital cost and the strength of the relationship is computed. The relationship between initial embodied energy and capital cost generally declines as the predictive model assumes more detail, although elemental modelling may provide the best solution on balance. Journal: Construction Management and Economics Pages: 147-160 Issue: 2 Volume: 26 Year: 2008 Keywords: Accuracy, capital cost, embodied energy, capital cost, modelling, X-DOI: 10.1080/01446190701716564 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701716564 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:2:p:147-160 Template-Type: ReDIF-Article 1.0 Author-Name: Yat-Hung Chiang Author-X-Name-First: Yat-Hung Author-X-Name-Last: Chiang Author-Name: Bo-Sin Tang Author-X-Name-First: Bo-Sin Author-X-Name-Last: Tang Author-Name: Francis Wong Author-X-Name-First: Francis Author-X-Name-Last: Wong Title: Volume building as competitive strategy Abstract: The competitive strategy and advantage of building contractors is examined. In Hong Kong, just a few contractors have dominated the market of public housing construction, where prefabrication is mandatory. Does prefabrication technology lead to business success? Based on quantitative analysis of a questionnaire survey and its validation with interviews, we find that prefabrication by itself is not regarded as a sustainable source of competitive advantage. Instead, market share is the most statistically significant factor related to business growth. The experience curve theory suggests that, upon acquiring a critical volume of business, contractors have the opportunity to exploit economies of scale, bargaining power and learning to reduce costs to get more business. Through this iterative process, some contractors would manage to innovate their building process to make their supply chain management more efficient and effective than others', thus attaining competitive advantage in cost leadership and getting more business in return to sustain their volume building strategy. The findings suggest that, to succeed in a mature industry such as building construction, it takes clever harnessing of the construction process rather than simply the mastery of prefabrication technology itself. Journal: Construction Management and Economics Pages: 161-176 Issue: 2 Volume: 26 Year: 2008 Keywords: Competitive advantage, strategy, prefabrication, Hong Kong, X-DOI: 10.1080/01446190701749151 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701749151 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:2:p:161-176 Template-Type: ReDIF-Article 1.0 Author-Name: Bon-Gang Hwang Author-X-Name-First: Bon-Gang Author-X-Name-Last: Hwang Author-Name: Stephen Thomas Author-X-Name-First: Stephen Author-X-Name-Last: Thomas Author-Name: Deborah Degezelle Author-X-Name-First: Deborah Author-X-Name-Last: Degezelle Author-Name: Carlos Caldas Author-X-Name-First: Carlos Author-X-Name-Last: Caldas Title: Development of a benchmarking framework for pharmaceutical capital projects Abstract: Benchmarking is a proven technique for improving project performance and, as such, is a critical component of any mature project delivery system. Competitive benchmarking requires industry-specific metrics in absolute terms since processes vary by industry, and any metrics used within a single industry must be attuned to its particular processes. A framework is developed for evaluating pharmaceutical capital facility projects using metrics specific to the characteristics of these unique projects. Establishment of the framework made possible the development of a set of industry-specific metrics and a flexible data collection and reporting system for measuring project performance. Preliminary findings from an initial sample of 40 pharmaceutical projects confirm that meaningful industry-specific metrics can be produced for pharmaceutical capital facilities benchmarking. Developing such a framework enables the industry to measure project performance more accurately, get meaningful project performance comparisons, and ultimately establish credible norms for project performance. Journal: Construction Management and Economics Pages: 177-195 Issue: 2 Volume: 26 Year: 2008 Keywords: Benchmarking, pharmaceutical project, project management, project performance, X-DOI: 10.1080/01446190701802398 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701802398 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:2:p:177-195 Template-Type: ReDIF-Article 1.0 Author-Name: Chin-Hsiang Chang Author-X-Name-First: Chin-Hsiang Author-X-Name-Last: Chang Author-Name: Yu-Cheng Lin Author-X-Name-First: Yu-Cheng Author-X-Name-Last: Lin Author-Name: H. Ping Tserng Author-X-Name-First: H. Ping Author-X-Name-Last: Tserng Title: Distilling and managing engineers' experience in construction projects using a pattern approach Abstract: Construction management requires engineers to acquire effectively and efficiently management experience. Most experience management (EM) in the construction industry focuses on explicit experience (such as writing reports and documents). Furthermore, tacit experience is usually more difficult to acquire than explicit experience. This study proposes an After the Issue Review (AIR) approach to acquire experience from engineers involved in construction projects, and effectively enhance experience sharing through a web-based platform. Moreover, an AIR Construction Pattern (AIRCP) scheme is proposed and utilized to codify and edit the acquired experience. The web-based experience management system presents a user-friendly interface of an experience-sharing platform, through which engineers learn valuable tacit experience derived from previous projects. Finally, a case study involving tunnel construction for expressway projects in Taiwan is utilized to validate the proposed approach and demonstrate the effectiveness of experience acquisition and management in construction. Journal: Construction Management and Economics Pages: 209-223 Issue: 3 Volume: 26 Year: 2008 Keywords: Construction management, experience management, construction project, pattern, X-DOI: 10.1080/01446190701819061 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701819061 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:3:p:209-223 Template-Type: ReDIF-Article 1.0 Author-Name: Zhen Yu Zhao Author-X-Name-First: Zhen Yu Author-X-Name-Last: Zhao Author-Name: Li Yin Shen Author-X-Name-First: Li Yin Author-X-Name-Last: Shen Title: Are Chinese contractors competitive in international markets? Abstract: Chinese contractors have become more active in recent years in the international arena. This development is largely due to the encouragement and support by the Chinese government, coupled with the pressure of intensive competition within the domestic market. The increasing presence of Chinese international contractors (CICs) has attracted the attention of competitors from other countries. The CICs' strengths, weaknesses, opportunities and threats in the international construction market are identified through analysing their business performance. Data used for the analysis are from multiple sources including literature reviews, policy reports, published statistics data and interviews with 25 construction professionals who work in CICs. It is suggested that CICs have made significant progress in building up their competitiveness in recent years and become competitors to other overseas contractors in international construction markets. The results provide valuable references for undertaking comparative research on organizational competitiveness among the contractors who come from different countries in international construction markets. Journal: Construction Management and Economics Pages: 225-236 Issue: 3 Volume: 26 Year: 2008 Keywords: China, construction industry, contractor, international business, competitiveness, X-DOI: 10.1080/01446190801905380 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801905380 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:3:p:225-236 Template-Type: ReDIF-Article 1.0 Author-Name: Koh Tas Yong Author-X-Name-First: Koh Tas Author-X-Name-Last: Yong Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Title: Organizational culture and TQM implementation in construction firms in Singapore Abstract: The adoption and implementation of total quality management (TQM) are related to a company's culture. The relationship between cultural orientation and the implementation of TQM practices among certified Singapore contractors is investigated from an organizational culture perspective. The competing values framework was used to assess organizational culture and eight TQM elements were identified to gauge the implementation of TQM practices among contractors. A survey questionnaire was administered. Four organizational culture types have been identified from the survey findings. These are strong comprehensive, clan-driven, hierarchy-driven and weak comprehensive culture. Firms with strong comprehensive culture implement highly the TQM elements of top management leadership, people, process, customer and supplier management. Firms with clan-driven culture implement highly the element of process management while firms with hierarchy-driven and weak comprehensive culture implement lowly to moderately all elements. A culture-based TQM implementation strategy is proposed. Journal: Construction Management and Economics Pages: 237-248 Issue: 3 Volume: 26 Year: 2008 Keywords: Competing values framework, contractor, organizational culture, total quality management, X-DOI: 10.1080/01446190701874397 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701874397 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:3:p:237-248 Template-Type: ReDIF-Article 1.0 Author-Name: S. Thomas Ng Author-X-Name-First: S. Thomas Author-X-Name-Last: Ng Author-Name: Ziwei Tang Author-X-Name-First: Ziwei Author-X-Name-Last: Tang Title: Delineating the predominant criteria for subcontractor appraisal and their latent relationships Abstract: An industry report in Hong Kong calls for an agreed framework for appraising subcontractor performance. A set of performance appraisal criteria is developed that is agreeable to all key stakeholders in subcontracting. By examining the criteria being applied around the world and reviewing the available literature, a set of 31 subcontractor performance appraisal criteria was compiled. A questionnaire survey was conducted in Hong Kong to reveal the perception of relevant stakeholders on the most critical criteria for subcontractor appraisal. The independent samples t-test confirmed that the main contractor and subcontractor groups had a significant agreement on the importance levels of most subcontractor performance appraisal criteria. Through factor analysis, the 15 most important subcontractor performance appraisal criteria and their underlying relationships are identified. The results indicate that the three overarching factors for subcontractor performance appraisal are 'team interaction', 'accomplishment of project goals' and 'track record'. The identified appraisal criteria lay a solid foundation for the development of a centralized subcontractor performance appraisal system to facilitate performance reporting, data sharing and benchmarking. Journal: Construction Management and Economics Pages: 249-259 Issue: 3 Volume: 26 Year: 2008 Keywords: Subcontractor, performance appraisal, decision criteria, factor analysis, X-DOI: 10.1080/01446190701874405 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701874405 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:3:p:249-259 Template-Type: ReDIF-Article 1.0 Author-Name: Mohamed Matar Author-X-Name-First: Mohamed Author-X-Name-Last: Matar Author-Name: Maged Georgy Author-X-Name-First: Maged Author-X-Name-Last: Georgy Author-Name: Moheeb Elsaid Ibrahim Author-X-Name-First: Moheeb Elsaid Author-X-Name-Last: Ibrahim Title: Sustainable construction management: introduction of the operational context space (OCS) Abstract: Sustainable construction is an emerging field of science that aims at incorporating the general sustainable development concepts into conventional construction practices. While the foundation of knowledge in this field is continuously expanding, sustainable construction is not yet standard industry practice. One major technical barrier that hinders enacting sustainable construction is the absence of an application framework that integrates both sustainability and construction practices at an operational level. This shortcoming is being addressed through a three-dimensional operational context space (OCS) that achieves the sought integration aspect. The three dimensions of OCS are: (1) project life cycle phases; (2) project executing entities; and (3) sustainability performance parameters. Such OCS facilitates the association of responsibility, by assigning each sustainability requirement to a specific project entity (or entities) during specific project phase(s), and further provides a numerical assessment for construction projects using sustainability as a criterion. Steps of constructing the OCS and how it could be employed in the evaluation and benchmarking of a project's environmental performance are examined, along with sample illustrations in the area of construction waste management. Journal: Construction Management and Economics Pages: 261-275 Issue: 3 Volume: 26 Year: 2008 Keywords: Sustainability, sustainable construction, environmental impact, integration, benchmarking, X-DOI: 10.1080/01446190701842972 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701842972 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:3:p:261-275 Template-Type: ReDIF-Article 1.0 Author-Name: John Yeung Author-X-Name-First: John Author-X-Name-Last: Yeung Author-Name: Albert Chan Author-X-Name-First: Albert Author-X-Name-Last: Chan Author-Name: Daniel Chan Author-X-Name-First: Daniel Author-X-Name-Last: Chan Title: Establishing quantitative indicators for measuring the partnering performance of construction projects in Hong Kong Abstract: Research into Key Performance Indicators (KPIs) for partnering projects in construction becomes vital because an increasing trend of client organizations has been observed to introduce a partnering approach to their building and construction works internationally during the last decade. A Partnering Performance Index (PPI) has been developed for construction projects in Hong Kong. The PPI can assist in developing a benchmark for measuring the performance of their partnering projects. However, it is worth noting that assessors may have their own semantic interpretations on each KPI. The aim of this paper is to establish suitable quantitative indicators (QIs) and reasonable quantitative ranges (QRs) for each KPI in order to avoid any possible discrepancies in interpreting the meaning of each KPI and provide objective evaluation results based on quantitative evidence. By conducting five structured face-to-face interviews and two rounds of a Delphi questionnaire survey in Hong Kong, a set of QIs were developed to measure the seven most important KPIs, including: (1) time performance; (2) cost performance; (3) top management commitment performance; (4) quality performance; (5) trust and respect performance; (6) effective communications performance; and (7) innovation and improvement performance. The identified QIs and QRs could assess and compare different partnering projects on a common basis objectively, thus helping to set a benchmark for measuring the performance level of partnering projects in Hong Kong. Construction senior executives and project managers can thus apply the QIs and QRs to measure, evaluate and improve the existing performance of their partnering projects in order to strive for construction excellence. Journal: Construction Management and Economics Pages: 277-301 Issue: 3 Volume: 26 Year: 2008 Keywords: Key Performance Indicators, partnering, quantitative indicators, Delphi method, Hong Kong, X-DOI: 10.1080/01446190701793688 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701793688 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:3:p:277-301 Template-Type: ReDIF-Article 1.0 Author-Name: Chuan Chen Author-X-Name-First: Chuan Author-X-Name-Last: Chen Title: Entry mode selection for international construction markets: the influence of host country related factors Abstract: The increasing necessity to establish a permanent presence in overseas markets challenges the tradition of tide-like market entry mode of international contractors and confronts them with an important dichotomous selection between permanent entry mode and mobile entry mode. By borrowing theories and previous findings from the general international business area, the hypotheses regarding the influences of specific host country related factors upon the selection between the two generic entry modes, including cultural difference, trade link, host market potential, investment risk, institutional entry barrier and competition intensity are developed. Measures are proposed for these factors as well as some control variables and the dependent variable (entry mode). Data were collected from multiple sources for these variables. A binary logistic regression analysis was performed to test the hypotheses and develop a statistical model for entry mode selection. The model is statistically significant and not all the hypotheses are supported, confirming the uniqueness of the population of international contractors in market entry mode selection. Journal: Construction Management and Economics Pages: 303-314 Issue: 3 Volume: 26 Year: 2008 Keywords: International business, marketing strategy, international construction, market entry strategy, market entry model, X-DOI: 10.1080/01446190701882382 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701882382 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:3:p:303-314 Template-Type: ReDIF-Article 1.0 Author-Name: David James Bryde Author-X-Name-First: David James Author-X-Name-Last: Bryde Title: Is construction different? A comparison of perceptions of project management performance and practices by business sector and project type Abstract: Although poor project management (PM) performance on construction projects and limitations in PM practices continue to be reported, there has been little research specifically focused on comparing perceptions of PM performance and practices of the construction business sector with other sectors and of construction projects with other types of project. This gap is addressed by a survey of 238 UK organizations, incorporating a sub-sample from the construction business sector. A questionnaire was used to obtain data relating to perceived levels of PM performance and of levels of maturity in certain PM practices. Those involved in projects in the construction business sector perceived their PM performance to be higher than did those involved in projects from other business sectors. However, there was no difference in perceptions of PM performance on specific construction projects among participants drawn from all business sectors, i.e. owner/clients from other business sectors. In terms of practices the construction business sector reported higher levels of maturity in the management of programmes and organizational support for PM than other sectors. However, in the areas of sponsorship and benefit management the construction sector practices were no more evolved than those in other business sectors. Journal: Construction Management and Economics Pages: 315-327 Issue: 3 Volume: 26 Year: 2008 Keywords: Performance evaluation, project management, project performance, X-DOI: 10.1080/01446190701874413 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701874413 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:3:p:315-327 Template-Type: ReDIF-Article 1.0 Author-Name: Kumar Neeraj Jha Author-X-Name-First: Kumar Neeraj Author-X-Name-Last: Jha Author-Name: M. N. Devaya Author-X-Name-First: M. N. Author-X-Name-Last: Devaya Title: Modelling the risks faced by Indian construction companies assessing international projects Abstract: There are just two Indian construction companies in the ENR 'Top 225 Global Contractors 2006' list and Indian construction companies have only a 0.05% market share of the $3-4 trillion global construction business. International construction experience in India is limited, but enormous scope for growth exists. This research presents the international construction risk factors from the Indian construction professionals' viewpoint, in a comprehensive format to enable practitioners to prioritize the efforts to manage the risk factors. Fourteen important risk factors have been identified through literature survey and interaction with industry experts. Interpretive structural modelling (ISM) has been used to present a hierarchical model showing the interrelationships between the risk factors. MICMAC analysis has been used to quantify and classify the risk factors based on their influence and dependence on other risk factors and to highlight counter-intuitive risk factors. We find that poor project management is a key risk factor forming the hub of the system, while political instability has maximum influence. The findings may be useful to the practitioners in the construction industry and may also interest academicians, since the method used here can be applied in other areas of construction management as well. Journal: Construction Management and Economics Pages: 337-348 Issue: 4 Volume: 26 Year: 2008 Keywords: India, risk analysis, international project, interpretive structural modelling, globalization, X-DOI: 10.1080/01446190801953281 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801953281 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:4:p:337-348 Template-Type: ReDIF-Article 1.0 Author-Name: Franco Cheung Author-X-Name-First: Franco Author-X-Name-Last: Cheung Author-Name: Margie Wong Author-X-Name-First: Margie Author-X-Name-Last: Wong Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: A study of clients' and estimators' tolerance towards estimating errors Abstract: Previous research on building pre-tender cost estimating stresses the importance of giving accurate estimates and minimizing estimating errors. Cost models, especially those mathematical models using mean square error or the like for model training and validation, often treat positive errors (overestimates) and negative errors (underestimates) of equal magnitude the same with an implicit assumption that the regret or disutility of positive errors (overestimates) is equal to that of negative errors (underestimates). A survey was conducted in Hong Kong to study estimating practice and in particular, the attitude of clients and estimators towards estimating errors. This involved the use of regression analysis to model the relative disutility of underestimates (in terms of overestimates) for four different building types. Both clients and estimators are found to be risk averse—tolerating overestimates more than underestimates—and, arguably, clients are satisfied with overestimates. However, they have contrasting views on the desired characteristics of estimates with clients considering the ability to identify cost sensitive elements to be more important than accuracy. In this regard, the formalization of value analysis as part of the cost advice function under typical cost consulting agreements should be the best form of improvement. Journal: Construction Management and Economics Pages: 349-362 Issue: 4 Volume: 26 Year: 2008 Keywords: Expert judgement, cost planning, client, accuracy, survey, X-DOI: 10.1080/01446190701802380 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701802380 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:4:p:349-362 Template-Type: ReDIF-Article 1.0 Author-Name: Nader Naderpajouh Author-X-Name-First: Nader Author-X-Name-Last: Naderpajouh Author-Name: Abbas Afshar Author-X-Name-First: Abbas Author-X-Name-Last: Afshar Title: A case-based reasoning approach to application of value engineering methodology in the construction industry Abstract: A key point in value engineering (VE) methodology is to acquire and apply knowledge of the assorted fields. An appropriate definition of VE expert knowledge flow could, therefore, yield more productive VE workshops. A conceptual expert case-based reasoning (CBR) framework is introduced in this paper to form a coherent basis for the provision of practically suitable VE expert models. The proposed framework outlines knowledge entities and their relations in the VE workshop. The model benefits from a fuzzy approach to handle uncertainties in the evaluation phase of the methodology. In addition, a computer program is devised, based on the proposed framework, using Borland Delphi 7.0. It comprises an interface representing several phases of the VE job plan. The model is employed in a tunnelling project to demonstrate feasibility of the model in a practical workshop. Owing to its expert nature, the developed model contributes to efficiency of the methodology through providing VE teams with canalized expert knowledge of diverse domains. The propounded model may avail researchers in promoting expert models for pre-construction and specifically VE studies in major construction projects. Journal: Construction Management and Economics Pages: 363-372 Issue: 4 Volume: 26 Year: 2008 Keywords: Value engineering, expert system, case-based reasoning, decision support system, fuzzy sets, X-DOI: 10.1080/01446190801905398 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801905398 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:4:p:363-372 Template-Type: ReDIF-Article 1.0 Author-Name: Truong-Van Luu Author-X-Name-First: Truong-Van Author-X-Name-Last: Luu Author-Name: Soo-Yong Kim Author-X-Name-First: Soo-Yong Author-X-Name-Last: Kim Author-Name: Huu-Loi Cao Author-X-Name-First: Huu-Loi Author-X-Name-Last: Cao Author-Name: Young-Min Park Author-X-Name-First: Young-Min Author-X-Name-Last: Park Title: Performance measurement of construction firms in developing countries Abstract: Many large contractors in Vietnam are lacking an effective method to measure their performance and identify weaknesses and threats. The integration of the balanced scorecard (BSC) and strengths-weaknesses-opportunities-threats (SWOT) matrix is described to evaluate the strategic performance of large contractors in Vietnam. The AnGiang Construction Company (ACC) was used as an example to validate the approach. The BSC-oriented SWOT matrix is developed to formulate the short- and long-term strategies of ACC. The benchmarking approach was adapted to evaluate the ACC's performance and expose its competitors' best practices for improvement. The results indicated that only the financial perspective is at a poor level on the performance scale whereas the customer, learning and growth, and internal process perspectives are at a moderate level on the performance scale. The effective evaluation matrix uncovered 11 effective solutions that could be grouped under four categories: (1) innovating organizational structure; (2) effectively managing processes at construction sites; (3) stepping up cost control; and (4) improving equipment management. The findings may benefit not only Vietnamese construction firms but also firms in other developing countries to identify their strategies, quantify the strategic performance, and improve their competitive advantages. Journal: Construction Management and Economics Pages: 373-386 Issue: 4 Volume: 26 Year: 2008 Keywords: Balanced scorecard (BSC), construction companies, SWOT analysis, performance measurement, Vietnam, X-DOI: 10.1080/01446190801918706 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801918706 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:4:p:373-386 Template-Type: ReDIF-Article 1.0 Author-Name: Yi Zou Author-X-Name-First: Yi Author-X-Name-Last: Zou Author-Name: Sang-Hoon Lee Author-X-Name-First: Sang-Hoon Author-X-Name-Last: Lee Title: The impacts of change management practices on project change cost performance Abstract: Change cost is one of the most sensitive aspects of construction project management, but it is also one of the most difficult to control. It has been widely recognized that construction projects that adopt change management practices generally incur lower change costs in comparison with project budgets. The relationship between change management practices and cost performance is investigated. Construction project data for this research are derived from the Construction Industry Institute Benchmarking and Metrics database. Multiple one-way ANOVA and linear regression are performed to investigate the effectiveness of individual change management practices elements and overall change management practices implementation in controlling project change cost, respectively. The data analysis results show that individual change management practices elements have different levels of leverage in helping to control project change cost and that using change management practices is truly helpful in lowering the proportion of change cost in project actual cost. Journal: Construction Management and Economics Pages: 387-393 Issue: 4 Volume: 26 Year: 2008 Keywords: Project management, change management, performance improvement, X-DOI: 10.1080/01446190801918714 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801918714 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:4:p:387-393 Template-Type: ReDIF-Article 1.0 Author-Name: Shamas-Ur-Rehman Toor Author-X-Name-First: Shamas-Ur-Rehman Author-X-Name-Last: Toor Author-Name: Stephen Ogunlana Author-X-Name-First: Stephen Author-X-Name-Last: Ogunlana Title: Problems causing delays in major construction projects in Thailand Abstract: Delays are frequent and recurring in construction projects in developing countries. Although the principal reasons for construction delays are comparable across developing countries, several factors pertaining to local industry, socio-economic and cultural issues and project characteristics also contribute to construction delays. Questionnaire surveys and interviews were conducted on a major construction project in Thailand to explore the most significant problems causing construction delays. Factors related to designers, contractors and consultants were rated among the top problems. Issues such as lack of resources, poor contractor management, shortage of labour, design delays, planning and scheduling deficiencies, changed orders and contractors' financial difficulties were also highlighted during the interviews. Notably, problems such as 'multicultural and multilingual environment causing ineffective communication', 'large number of participants of project' and 'involvement of several foreign designers and contractors' were rated among the bottom 10 problems in the 75-item problem inventory. These findings can be helpful for project managers to mitigate the construction delays in Thailand. In order to effectively overcome the construction delays in developing countries, suggestions are made for fundamental and large-scale reforms in procurement systems, value chain management and stakeholders' management. Journal: Construction Management and Economics Pages: 395-408 Issue: 4 Volume: 26 Year: 2008 Keywords: Delays, major projects, developing country, Thailand, X-DOI: 10.1080/01446190801905406 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801905406 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:4:p:395-408 Template-Type: ReDIF-Article 1.0 Author-Name: Thanet Aksorn Author-X-Name-First: Thanet Author-X-Name-Last: Aksorn Author-Name: Bonaventura Hadikusumo Author-X-Name-First: Bonaventura Author-X-Name-Last: Hadikusumo Title: Measuring effectiveness of safety programmes in the Thai construction industry Abstract: Some safety programmes are more effective than others in improving safety performance at the project level. The effectiveness of safety programmes was evaluated by studying 70 construction projects in the Thai construction sector, examining the relationship between their actual status and associated site safety performance. The actual status was assessed by using an evaluation tool developed in compliance with Thai safety legislation and validated by safety experts. Safety performance was assessed by using reactive and proactive measures. Particularly, the accident rate was used as a reactive indicator, while the unsafe act index and the unsafe condition index were used as proactive indicators. The results demonstrated that safety performance was influenced by the nature of implemented safety programmes. First, safety programmes which positively affect accident rates include accident investigations, jobsite inspections, control of subcontractors and safety incentives. Secondly, five programmes, namely jobsite inspections, accident investigations, job hazard analysis, safety committees and safety record keeping, were found to have the most contributions to fewer unsafe acts. And thirdly, accident investigations, jobsite inspections, job hazard analysis, safety inductions and safety auditing were the most effective programmes in reducing unsafe conditions. Journal: Construction Management and Economics Pages: 409-421 Issue: 4 Volume: 26 Year: 2008 Keywords: Accident, safety, health and safety, performance improvement, Thailand, X-DOI: 10.1080/01446190801918722 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801918722 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:4:p:409-421 Template-Type: ReDIF-Article 1.0 Author-Name: John-Paris Pantouvakis Author-X-Name-First: John-Paris Author-X-Name-Last: Pantouvakis Author-Name: Odysseus George Manoliadis Author-X-Name-First: Odysseus George Author-X-Name-Last: Manoliadis Title: A compromise programming model for site selection of borrow pits Abstract: Road fill construction requires soil for filling low areas; this soil is obtained from temporary mineral workings known as 'borrow pits' (BP). Between a number of possible BPs, the appropriate site should be selected based upon conflicting econo-technical and environmental criteria aiming at achieving optimal BP performance while minimizing the adverse impacts to human and natural resources. For solving this problem a model for BP selection has been developed by this research using compromise programming (CP). The model incorporates a hierarchical structure integrating criteria and sub-criteria whose relative importance is set by the decision makers. Possible alternative BP sites are subsequently assessed on all these sub-criteria. Based upon this analysis, the model determines the distance of each of the possible alternatives from the utopia (ideal) point; the option with the minimum distance is considered the best compromise. The relevant concepts are exemplified through the presentation of a case study concerning the BP site selection for an Egnatia Motorway section in northwest Greece. The main conclusion that can be drawn from this work is that the CP approach is appropriate and valid for BP selection and, furthermore, it may also be used for other multiple objective construction-related site selection problems. Journal: Construction Management and Economics Pages: 433-446 Issue: 5 Volume: 26 Year: 2008 Keywords: Multiple objectives, decision making, compromise programming, borrow pits, X-DOI: 10.1080/01446190801953299 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801953299 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:5:p:433-446 Template-Type: ReDIF-Article 1.0 Author-Name: Ka-Chi Lam Author-X-Name-First: Ka-Chi Author-X-Name-Last: Lam Author-Name: Mike Chun-Kit Lam Author-X-Name-First: Mike Chun-Kit Author-X-Name-Last: Lam Author-Name: Dan Wang Author-X-Name-First: Dan Author-X-Name-Last: Wang Title: MBNQA-oriented self-assessment quality management system for contractors: fuzzy AHP approach Abstract: Many construction clients are not satisfied with the quality performance achieved on their projects though many contractors are ISO9000:1994 certified. Total quality management (TQM) has been a widely applied quality management system for obtaining the benefits of better quality and higher customer satisfaction through the spirit of continuous improvement, which is also adopted by ISO9001:2000 version. It is believed that TQM can help to raise quality and productivity in the construction industry. Self-assessment systems provide an opportunity to design in quality on an organization-wide basis, in which the self-assessment process allows the organization to identify its strengths and weaknesses for continuous improvement actions. A MBNQA-oriented self-assessment quality management system (SQMS), which is based on the seven criteria of Malcolm Baldrige National Quality Award (MBNQA), for construction contractors to benchmark, is proposed. A questionnaire survey of Hong Kong construction quality management experts, in which a fuzzy analytical hierarchy process (AHP) was employed to calculate the weights of the seven criteria, was carried out. Remarkable differences for the allocation of weights in the seven criteria particularly in the input criteria (leadership, strategic planning and customer and market focus) and the 'results' criterion compared with the original weights of MBNQA were observed. Journal: Construction Management and Economics Pages: 447-461 Issue: 5 Volume: 26 Year: 2008 Keywords: TQM, self-assessment, contractor, quality management system, fuzzy AHP, X-DOI: 10.1080/01446190801965350 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801965350 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:5:p:447-461 Template-Type: ReDIF-Article 1.0 Author-Name: Kunhui Ye Author-X-Name-First: Kunhui Author-X-Name-Last: Ye Author-Name: Weiyan Jiang Author-X-Name-First: Weiyan Author-X-Name-Last: Jiang Author-Name: Liyin Shen Author-X-Name-First: Liyin Author-X-Name-Last: Shen Title: Project competition intensity (PCI) in the construction market: a case study in China Abstract: In economic terminology, 'competition intensity' can be used to mirror to a certain degree the status of industrial competition in a specific market, while in the construction market, it particularly involves the part of project competition intensity (PCI). Based on a road project in China, two forms of PCI, overt and covert, are identified in this study. To lower project construction cost thus enabling better project tendering performance, clients can facilitate higher levels of overt PCI by tailoring their tendering procedures, whereas, through covert PCI project competitors can adopt anti-competitive behaviours to attain the expected works. The difference between overt PCI and covert PCI indicates various practitioners' perspectives and impact on the levels of competition intensity in construction. The findings suggest a way to promote PCI studies in the future, and offer new insights into other parts of competition intensity in construction. Journal: Construction Management and Economics Pages: 463-470 Issue: 5 Volume: 26 Year: 2008 Keywords: Competition, project complexity index, attributes, case study, road, China, X-DOI: 10.1080/01446190802036136 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802036136 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:5:p:463-470 Template-Type: ReDIF-Article 1.0 Author-Name: Jasper Mbachu Author-X-Name-First: Jasper Author-X-Name-Last: Mbachu Title: Conceptual framework for the assessment of subcontractors' eligibility and performance in the construction industry Abstract: Subcontractors handle a major portion—about 85%—of all construction projects in the building industry. The ability of the main contractor and consultants to deliver the project within time, quality and cost targets depends largely on the performance of the subcontractors. Selection of subcontractors on the basis of overall ability to perform is therefore crucial to successful project delivery. The key criteria for assessing subcontractors' eligibility for tender invitation and award, and subsequent performance at the construction stage, were investigated. Using the descriptive survey method, 243 contractors and 307 subcontractors registered with the Gauteng Master Builders Association of South Africa were surveyed. The multi-attribute technique was used to analyse the data. Results showed that quality record is the most influential criterion for selecting high performing subcontractors at the pre-qualification stage, and for assessing their performance at the construction stage. Tender price exerts the most significant influence in the subcontract award. A framework was developed for use by main contractors and consultants in the assessment of the suitability and performance of subcontractors. Application of the framework to a case study demonstrated its merit as a tool for ensuring that only high performing subcontractors are selected for subcontract jobs. Journal: Construction Management and Economics Pages: 471-484 Issue: 5 Volume: 26 Year: 2008 Keywords: Performance evaluation, pre-qualification, selection, subcontracting, tendering, X-DOI: 10.1080/01446190801918730 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801918730 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:5:p:471-484 Template-Type: ReDIF-Article 1.0 Author-Name: Goh Bee Hua Author-X-Name-First: Goh Bee Author-X-Name-Last: Hua Title: The state of applications of quantitative analysis techniques to construction economics and management (1983 to 2006) Abstract: With increasing complexity of construction industry problems, researchers are experimenting with computationally rigorous techniques with the aim of seeking innovative solutions. In order to trace the applications of quantitative analysis techniques to research in the two fields of construction economics and construction management for both conventional and AI techniques, the methodology involves compiling all the relevant papers from the top two ranking construction management journals, namely, Construction Management and Economics and ASCE's Journal of Construction Engineering and Management. The period is from 1983 to 2006. The compiled papers are classified by field, area (or topic), technique applied and year of publication to enable time series and cross-sectional analyses of the data. Mainly, the results are depicted as trends when the patterns of distribution of the papers are plotted over time. The three findings are: (1) for construction economics, the overall increasing trend is higher for papers that have applied conventional techniques; (2) for construction management, there is a clear positive trend for papers that have applied AI techniques which starts from 1995; and (3) the areas (or topics) of construction management that have increasingly higher growth in the application of AI techniques are optimization of site operations and optimization of project time, cost and resources allocation. Two broad recommendations are made that relate to advancing the fields of construction economics and construction management with the view that researchers must better enable themselves to build tools that incorporate intelligence as innovative solutions for increasingly complex problems. Journal: Construction Management and Economics Pages: 485-497 Issue: 5 Volume: 26 Year: 2008 Keywords: Artificial intelligence, statistical method, quantitative analysis technique, bibliometrics, construction economics, construction management, X-DOI: 10.1080/01446190801998716 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801998716 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:5:p:485-497 Template-Type: ReDIF-Article 1.0 Author-Name: Raufdeen Rameezdeen Author-X-Name-First: Raufdeen Author-X-Name-Last: Rameezdeen Author-Name: Thanuja Ramachandra Author-X-Name-First: Thanuja Author-X-Name-Last: Ramachandra Title: Construction linkages in a developing economy: the case of Sri Lanka Abstract: The importance of the construction industry stems from its strong linkages with other sectors of the economy. Despite the extensive research on input-output analysis and sectoral linkages of construction, a gap is found in the literature dealing with developing economies. The objective is to study the construction linkages in a developing economy using input-output tables compiled since the 1970s in Sri Lanka. Results show that the share of construction in gross national product and national income is lower in Sri Lanka than in developed countries. In Sri Lanka, the share of manufacturing in GNP declined while the share of services has increased with economic development. The backward linkage indicator ranges between 0.364 and 0.457 during the period of 1970-2000 while output multiplier ranges between 1.496 and 1.641 indicating the 'pull effect'. The 'push effect' is found to be very insignificant. An aggregated sectoral analysis reveals high dependence of construction on manufacturing followed by services. The trend analysis shows an increasing dependence of construction on the services sector. The direct and total inputs from manufacturing and services have increased over time. Journal: Construction Management and Economics Pages: 499-506 Issue: 5 Volume: 26 Year: 2008 Keywords: Input-output analysis, construction sector, backward linkages, forward linkages, Sri Lanka, X-DOI: 10.1080/01446190802017706 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802017706 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:5:p:499-506 Template-Type: ReDIF-Article 1.0 Author-Name: Ahmed M. Abdel Aziz Author-X-Name-First: Ahmed M. Abdel Author-X-Name-Last: Aziz Title: Minimum performance bounds for evaluating contractors performance during construction of highway pavement projects Abstract: For project control during construction, evaluating the performance of contractors is usually established through progress measurement that compares the actual performance to the planned performance. Corrective actions and/or performance penalties are then established as relative measures that judge the actual performance based on current project plans without considering the performance of other similar projects or the lowest performance that projects could reach while still being successful. To establish a generalized benchmark measure and a non-project-specific project control tool, the concept of minimum performance bounds is explained in relation to their development for highway pavement projects. The bounds were developed using constrained-parameters polynomial regression and cluster analysis for a sample of 497 highway pavement projects in Washington State. Minimum bounds for small, medium and large projects were fairly distinguishable signifying the project size effect on the location and shape of performance bounds. Bounds were also developed for projects classified by asphalt quantities, contract values, project duration and project length, being the common criteria used by highway agencies. Owners would use the minimum performance bounds as control tools when requesting corrective actions, establishing incentives, imposing performance penalties, initiating a default clause for substandard performance, and/or in pre-qualifying contractors for new projects. Journal: Construction Management and Economics Pages: 507-529 Issue: 5 Volume: 26 Year: 2008 Keywords: Performance evaluation, regression analysis, highways, cash flow forecasting, X-DOI: 10.1080/01446190801918748 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801918748 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:5:p:507-529 Template-Type: ReDIF-Article 1.0 Author-Name: Johan Nystrom Author-X-Name-First: Johan Author-X-Name-Last: Nystrom Title: A quasi-experimental evaluation of partnering Abstract: Construction managerial literature often argues that there are gains to be made by using partnering. Voices have however been raised to approach partnering in a more neutral perspective and with well-founded methods of evaluation. This study can be seen as an outcome of the criticisms against earlier empirical evaluations by setting out to provide more tangible data and an improved method for evaluating partnering. A quasi-experimental method has been adopted in order to control for other affecting variables and find the unique effect of partnering. This approach strives to match partnering projects with identical non-partnering projects on every relevant variable except partnering. Six hundred and twenty three site meeting minutes from 20 publicly procured projects have been analysed to extract differences between partnering and non-partnering projects concerning cost and quality. Time delays, the amount of disputes, financial outcome and contract flexibility have been used as indicators. The paper has made a first attempt in trying to push the frontier for partnering evaluations forward by providing a new type of data (site meeting minutes) and applying a well-reputed evaluation method (quasi-experiment). The main result is that no systematic or general trends can be seen in the material. This result casts a shadow over the optimistic results from earlier evaluations and suggests that the main contribution of partnering might lie in its intangible effects. Journal: Construction Management and Economics Pages: 531-541 Issue: 5 Volume: 26 Year: 2008 Keywords: Partnering, evaluation, research methods, X-DOI: 10.1080/01446190802036144 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802036144 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:5:p:531-541 Template-Type: ReDIF-Article 1.0 Author-Name: Brian Atkin Author-X-Name-First: Brian Author-X-Name-Last: Atkin Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Editorial: stakeholder management in construction Abstract: Journal: Construction Management and Economics Pages: 549-552 Issue: 6 Volume: 26 Year: 2008 X-DOI: 10.1080/01446190802142405 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802142405 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:6:p:549-552 Template-Type: ReDIF-Article 1.0 Author-Name: Stefan Olander Author-X-Name-First: Stefan Author-X-Name-Last: Olander Author-Name: Anne Landin Author-X-Name-First: Anne Author-X-Name-Last: Landin Title: A comparative study of factors affecting the external stakeholder management process Abstract: There is a natural tendency for stakeholder groups to try to influence the implementation of construction projects in line with their individual concerns and needs. This presents a challenge for construction project managers in analysing and managing these various concerns and needs in a stakeholder management process falling within the limits of the project. The aim of the research presented here was to show the factors affecting the stakeholder management process positively or negatively from the perspective of project implementation. A comparative study of two railway projects in Sweden was undertaken to analyse these factors. The study showed that the outcome of the stakeholder management process depended mainly upon how well the project managers presented the benefits and negative consequences brought on by the construction project. Techniques and tools exist for this purpose, but must be appropriate, and these are discussed in the context of the two projects. The challenge for project managers is to implement the project in such a way that the effects of negative impacts are minimized and, if possible, the benefits for all stakeholders are maximized. Project managers must communicate and interact with stakeholders so that the perceived benefits and negative impacts are realistically defined. Journal: Construction Management and Economics Pages: 553-561 Issue: 6 Volume: 26 Year: 2008 Keywords: Customer relations, stakeholder, railways, Sweden, X-DOI: 10.1080/01446190701821810 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701821810 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:6:p:553-561 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Ward Author-X-Name-First: Stephen Author-X-Name-Last: Ward Author-Name: Chris Chapman Author-X-Name-First: Chris Author-X-Name-Last: Chapman Title: Stakeholders and uncertainty management in projects Abstract: Stakeholders are a major source of uncertainty in projects. This uncertainty encompasses who relevant stakeholders are, how they could influence a project, and what their motives are in so far as their actions affect project activity. A generic project uncertainty management process framework is employed to provide a structure for a review of approaches to analysing stakeholders and related uncertainty management issues. This framework, the SHAMPU (Shape, Harness, and Manage Project Uncertainty) process, consists of nine phases: project definition, focusing the uncertainty management process, identifying sources of uncertainty, structuring issues, clarifying ownership, estimating variability, evaluating implications of uncertainty, harnessing plans, and managing implementation. A variety of approaches to stakeholder analysis are considered in relation to these phases. In particular, characterizing projects on a 'hard-soft' spectrum suggests generic strategies for managing stakeholder expectations and fostering trust between stakeholders. An important conclusion is that a systematic approach to stakeholder management is facilitated by the use of project uncertainty management processes that distinguish different stages of the project life cycle. Journal: Construction Management and Economics Pages: 563-577 Issue: 6 Volume: 26 Year: 2008 Keywords: Project management, risk management, stakeholder, uncertainty, X-DOI: 10.1080/01446190801998708 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801998708 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:6:p:563-577 Template-Type: ReDIF-Article 1.0 Author-Name: Campbell Fraser Author-X-Name-First: Campbell Author-X-Name-Last: Fraser Author-Name: Chunxue Zhu Author-X-Name-First: Chunxue Author-X-Name-Last: Zhu Title: Stakeholder perception of construction site managers' effectiveness Abstract: Contemporary management thinking pays a great deal of attention to 'stakeholder theory', positing that sustainable success rests, to a great extent, with the systematic consideration of the needs and goals of all key stakeholders. This paper examines managerial effectiveness under the light of stakeholder theory. Using multivariate analysis, it investigates perceptions of importance of the dimensions of effectiveness held by a sample of 61 managers and 268 key project stakeholders in all major cities in Australia through a performance measurement tool comprising 52 performance elements. The findings of the research show that perceptions vary significantly across professional groups as well as high and low performing managers. The application the method presented in this paper can provide a framework for improvement of both managerial performance and stakeholder relationships. Journal: Construction Management and Economics Pages: 579-590 Issue: 6 Volume: 26 Year: 2008 Keywords: Stakeholder management, managerial effectiveness, performance measurement, X-DOI: 10.1080/01446190802036151 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802036151 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:6:p:579-590 Template-Type: ReDIF-Article 1.0 Author-Name: Ezekiel Chinyio Author-X-Name-First: Ezekiel Author-X-Name-Last: Chinyio Author-Name: Akintola Akintoye Author-X-Name-First: Akintola Author-X-Name-Last: Akintoye Title: Practical approaches for engaging stakeholders: findings from the UK Abstract: Principles for managing stakeholders are discussed in the context of UK construction practice. The number of stakeholders in a modern construction project can be large, presenting numerous interfaces that have to be managed. Meanwhile, each organization has its own characteristic disposition. Therefore, the interactions between diverse organizations in a project pose a high potential for conflicting stakes. Against this background, stakeholder management assumes high priority. Qualitative research was used to investigate the practice of stakeholder management with 12 UK companies in the construction sector. Interviews were held with these companies and content analysis was used to identify themes that demonstrate effective stakeholder management practice. Construct validity and a workshop underpinned the verification of underlying and frontline approaches for managing stakeholders. The underlying approaches include maintaining existing relationships, providing top-level support and being proactive while the frontline approaches include the use of negotiations, trade-offs, incentives and concessions. Journal: Construction Management and Economics Pages: 591-599 Issue: 6 Volume: 26 Year: 2008 Keywords: Communication, conflict, corporate governance, relationship, negotiation, X-DOI: 10.1080/01446190802078310 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802078310 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:6:p:591-599 Template-Type: ReDIF-Article 1.0 Author-Name: Vivek Narain Mathur Author-X-Name-First: Vivek Narain Author-X-Name-Last: Mathur Author-Name: Andrew Price Author-X-Name-First: Andrew Author-X-Name-Last: Price Author-Name: Simon Austin Author-X-Name-First: Simon Author-X-Name-Last: Austin Title: Conceptualizing stakeholder engagement in the context of sustainability and its assessment Abstract: Stakeholder engagement in construction projects can be conceptualized in different ways. It can be seen from a strategic management perspective aimed at capturing knowledge, increasing ownership of the project by users, reducing conflict, encouraging innovation and facilitating spin-off partnerships. From an ethical perspective, meaningful stakeholder engagement can be seen to enhance inclusive decision making, promote equity, enhance local decision making and build social capital. The benefits from both of these perspectives are vital for sustainability; however, stakeholder engagement can also be seen from the perspective of an opportunity for social learning—a social process where diverse stakeholders share a common forum, learn about each other's values, reflect upon their own values and create a shared vision and shared objectives. Dialogue is also useful in increasing awareness, changing attitudes and affecting behaviours. Existing practices view stakeholder engagement: mostly from a management perspective; sometimes from an ethical perspective; less often as a combination of the two; and rarely have any element of the social learning perspective. There is a need for an approach that combines all the three perspectives if sustainability is to be pursued. A dialogue-oriented approach to integrated sustainability assessment could provide an ideal means to do so. Journal: Construction Management and Economics Pages: 601-609 Issue: 6 Volume: 26 Year: 2008 Keywords: Stakeholder, sustainability, strategic management, ethics, social learning, dialogue, sustainability assessment, X-DOI: 10.1080/01446190802061233 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802061233 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:6:p:601-609 Template-Type: ReDIF-Article 1.0 Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Author-Name: Yan Ki Fiona Cheung Author-X-Name-First: Yan Ki Fiona Author-X-Name-Last: Cheung Title: Stakeholder management through empowerment: modelling project success Abstract: Stakeholder management is part of the project management process and this ongoing research builds on previous studies in the field of relationship management in Hong Kong and Australia and presents a testable stakeholder management process model in which the concepts of empowerment, organizational culture, trust and commitment are used as a basis for exploring the process. This may appear somewhat paradoxical to the reader as project managers, traditionally, have been seen to attempt to mollify stakeholders while focusing their attention on the details of project management rather than to empower stakeholders to have a significant input to the project—empowerment being seen to encourage 'interference' from non-specialists into the managers' domain. This change in attitude to stakeholders marks a culture change in the real estate and construction industry, brought about by an increased emphasis on relationship management. The research reported in this paper looks at the issues of stakeholder management via a research model that has identified project contextual factors which, through perceptual processes, influence empowerment and so the outcomes of the project. Hence, the problem addressed is how and why relationship management and stakeholder management are different in two unique cultures and what elements can be considered common and what elements are different. Journal: Construction Management and Economics Pages: 611-623 Issue: 6 Volume: 26 Year: 2008 Keywords: Australia, empowerment, Hong Kong, relationship management, stakeholder management model, X-DOI: 10.1080/01446190802071182 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802071182 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:6:p:611-623 Template-Type: ReDIF-Article 1.0 Author-Name: Krisen Moodley Author-X-Name-First: Krisen Author-X-Name-Last: Moodley Author-Name: Nigel Smith Author-X-Name-First: Nigel Author-X-Name-Last: Smith Author-Name: Christopher Nigel Preece Author-X-Name-First: Christopher Nigel Author-X-Name-Last: Preece Title: Stakeholder matrix for ethical relationships in the construction industry Abstract: The construction industry in general has a poor ethical reputation, being widely regarded by the public as a sector with corrupt practices, health and safety failures, and causing damage to the environment. A modern 21st century industry needs to consider how it orientates itself to the dilemma of conflicting stakeholder and ethical demands. The implications for stakeholders of the all pervasive drive for globalization in the construction industry is reviewed, leading to a consideration of the ethical relationship interfaces that construction organizations have with their stakeholders from the viewpoint of ethics, social contracts and corporate responsibility. Building upon earlier work a prototype stakeholder ethical responsibility matrix (SERM) is proposed as a management tool. Stakeholder management using an ethical perspective can meet the needs of both agency and stakeholder requirements. The increasingly complex global construction industry presents many challenges as key business decisions in construction are in reality moral decisions also. A completed version of the SERM offers a way forward for managing the ethical dimension of construction industry decision making. Journal: Construction Management and Economics Pages: 625-632 Issue: 6 Volume: 26 Year: 2008 Keywords: Stakeholders, ethics, social contracts, responsibility matrix, X-DOI: 10.1080/01446190801965368 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801965368 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:6:p:625-632 Template-Type: ReDIF-Article 1.0 Author-Name: Hedley Smyth Author-X-Name-First: Hedley Author-X-Name-Last: Smyth Title: The credibility gap in stakeholder management: ethics and evidence of relationship management Abstract: The predominant utilitarian conceptualization of stakeholder management within construction is reviewed. Utilitarianism will be contrasted with an ethics of nurture and care perspective. A credibility gap is identified in the utilitarian approach whereby individual parties in positions of power are unable to maximize net well-being. The relationship management concept will be outlined and located within the ethics of care, showing how aggregated behaviours can be linked to this approach. Behaviours that management can facilitate will be outlined and links made with the ethics of care concerning stakeholder management. The analysis will conceptually establish how the credibility gap in stakeholder management can be bridged. Research into relationships within PPP/PFI projects will be explored. The relationships between the SPV and the public sector will provide a particular focus. Recommendations for practice and future research will draw the analysis to a conclusion. Journal: Construction Management and Economics Pages: 633-643 Issue: 6 Volume: 26 Year: 2008 Keywords: Ethics, relationship management, stakeholder management, utility, X-DOI: 10.1080/01446190801905414 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801905414 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:6:p:633-643 Template-Type: ReDIF-Article 1.0 Author-Name: Derek Walker Author-X-Name-First: Derek Author-X-Name-Last: Walker Author-Name: Lynda Margaret Bourne Author-X-Name-First: Lynda Margaret Author-X-Name-Last: Bourne Author-Name: Arthur Shelley Author-X-Name-First: Arthur Author-X-Name-Last: Shelley Title: Influence, stakeholder mapping and visualization Abstract: Stakeholder identification, management and engagement are recognized as key project management skills; however, this is a 'soft' skill that requires both intuition and a strong capacity for analysis. There are few tools and methodologies to which people undertaking stakeholder management activities can turn. Highly complex problem solving activities, such as stakeholder management, can benefit from high level conceptual approaches that allow those involved to see clearly or to visualize the situation being examined. Metaphors, particularly highly visual representations of complex situations, can be very helpful in triggering simplification of complex situations to a level where understanding of the situation can yield fruitful results in moving forward to developing plans and actions. Visualization tools for stakeholder management can be of great value. Describing stakeholder visualization tools that can be used to develop a stakeholder engagement strategy can therefore raise awareness of these tools. The development and use of two such tools are described. While they are both independently useful they could be effectively combined. This prospect could reduce the chances of project failure and enhance success through having clearer pictures of stakeholder influence patterns. Journal: Construction Management and Economics Pages: 645-658 Issue: 6 Volume: 26 Year: 2008 Keywords: Stakeholder management, organization behaviour, organizational politics, X-DOI: 10.1080/01446190701882390 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190701882390 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:6:p:645-658 Template-Type: ReDIF-Article 1.0 Author-Name: Chris Chapman Author-X-Name-First: Chris Author-X-Name-Last: Chapman Author-Name: Stephen Ward Author-X-Name-First: Stephen Author-X-Name-Last: Ward Title: Developing and implementing a balanced incentive and risk sharing contract Abstract: An important aspect of stakeholder management in construction projects is the contractual approach to managing risk and uncertainty. Clients need to choose an appropriate form of contract from available common options, like fixed price, design and build (D&B), and design, build, finance and operate (DBFO). Facilitating appropriate choices is usefully addressed within a balanced incentive and risk sharing (BIARS) contract framework, 'balance' implying incentives that align client and contractor objectives. What this means in operational terms, within the context of a best practice approach to project risk and uncertainty management, is explored and clarified. The work is based on a mix of conventionally funded academic research and consultancy-based research. It was stimulated by the need to explain these ideas to a client using target contracts with unbalanced risk sharing, a common practice. Best practice requires a balanced approach, and the difference is significant. Best practice also involves a number of other relevant features. The key conclusion is that full integration of contract choice decisions and other aspects of a best practice approach to risk and uncertainty management is practical and advantageous, and a reasonable next step in the evolution of best practice. Journal: Construction Management and Economics Pages: 659-669 Issue: 6 Volume: 26 Year: 2008 Keywords: Contract conditions, risk management, X-DOI: 10.1080/01446190802014760 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802014760 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:6:p:659-669 Template-Type: ReDIF-Article 1.0 Author-Name: Ehsan Eshtehardian Author-X-Name-First: Ehsan Author-X-Name-Last: Eshtehardian Author-Name: Abbas Afshar Author-X-Name-First: Abbas Author-X-Name-Last: Afshar Author-Name: Reza Abbasnia Author-X-Name-First: Reza Author-X-Name-Last: Abbasnia Title: Time-cost optimization: using GA and fuzzy sets theory for uncertainties in cost Abstract: Uncertainties should be considered in any time-cost trade-off problems when minimizing project cost and duration, which leads to the so-called stochastic time-cost trade-off problem. A new approach to investigate stochastic time-cost trade-off problems employing fuzzy logic theory is presented. The proposed approach fully embeds the fuzzy structure of the uncertainties in total direct cost into the model. An appropriate GA is used to develop a solution to the multi-objective fuzzy time cost model. The accepted risk level of the project manager is defined through α cut approach for which a separate Pareto front with set of non-dominated solutions has been developed. To compare the alternative set of options for any assumed project duration, associated fuzzy costs for different values of α cut are ranked employing two appropriate approaches for fuzzy costs comparison. The proposed models are applied to solve two benchmark test problems. It is shown that the models facilitate the decision-making process by selecting specified risk levels and employing the associated Pareto front. Journal: Construction Management and Economics Pages: 679-691 Issue: 7 Volume: 26 Year: 2008 Keywords: Time-cost, optimization, uncertainties, fuzzy sets, Pareto front, X-DOI: 10.1080/01446190802036128 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802036128 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:7:p:679-691 Template-Type: ReDIF-Article 1.0 Author-Name: Marco Yu Author-X-Name-First: Marco Author-X-Name-Last: Yu Author-Name: Graham Ive Author-X-Name-First: Graham Author-X-Name-Last: Ive Title: The compilation methods of building price indices in Britain: a critical review Abstract: The major message that I will be trying to convey is that we often misinterpret the available data because of inadequate attention to how they are produced … (Griliches, 1994, p. 2) The importance of accurate measurement and pertinent modelling of the general level of construction prices cannot be overemphasized. Uses range from macroeconomic statistics such as real value of investment to micro-level budgeting like construction project price forecasts. Numerous research studies posit that the measured productivity growth rates of the construction sector are distorted and that an inaccurate general construction price index is a main villain of the piece. The academic research published in this arena has primarily focused on models to forecast or predict changes in the general construction price level, whereas this research scrutinizes the compilation methods of the general construction price index in Britain and finds that the indices measure the price movement of more traditional building trades but almost completely ignore the mechanical and electrical services. The existing indices also do not gauge the tender price movements of new building work that is not procured through the conventional lump sum BQs route, such as many projects in private housing and PFI markets. These make out a case for allowing resources to the project of developing alternative methodologies: (1) a revised version of the present method; and (2) hedonic price index. Journal: Construction Management and Economics Pages: 693-705 Issue: 7 Volume: 26 Year: 2008 Keywords: Tender price index, construction output deflator, index compilation methodology, construction statistics, X-DOI: 10.1080/01446190802043918 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802043918 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:7:p:693-705 Template-Type: ReDIF-Article 1.0 Author-Name: Xiao-Hua Jin Author-X-Name-First: Xiao-Hua Author-X-Name-Last: Jin Author-Name: Hemanta Doloi Author-X-Name-First: Hemanta Author-X-Name-Last: Doloi Title: Interpreting risk allocation mechanism in public-private partnership projects: an empirical study in a transaction cost economics perspective Abstract: Risk allocation in public-private partnership (PPP) projects is currently claimed as capability driven. While lacking theoretical support, the claim is often 'violated' by current industrial practice. There is thus a need for formal mechanisms to interpret why a particular risk is retained by government in one project while transferred to private partners in another. From the viewpoint of transaction cost economics (TCE), integrated with the resource-based view (RBV) of organizational capabilities, this paper proposed a theoretical framework for understanding risk allocation practice in PPP projects. The theories underlying the major constructs and their links were articulated. Data gathered from an industry-wide survey were used to test the framework. The results of multiple linear regression (MLR) generally support the proposed framework. It has been found that partners' risk management routine, mechanism, commitment, cooperation history, and uncertainties associated with project risk management could serve to determine the risk allocation strategies adopted in a PPP project. This theoretical framework thus provides both government and private agencies with a logical and complete understanding of the process of selecting the allocation strategy for a particular risk in PPP projects. Moreover, it could be utilized to steer the risk allocation strategy by controlling certain critical determinants identified in the study. Study limitations and future research directions have also been set out. Journal: Construction Management and Economics Pages: 707-721 Issue: 7 Volume: 26 Year: 2008 Keywords: Risk management, risk allocation, organizational capability, commitment, uncertainty, transaction cost economics, PPP, X-DOI: 10.1080/01446190801998682 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801998682 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:7:p:707-721 Template-Type: ReDIF-Article 1.0 Author-Name: Ping Yung Author-X-Name-First: Ping Author-X-Name-Last: Yung Author-Name: Lawrence Wai Chung Lai Author-X-Name-First: Lawrence Wai Chung Author-X-Name-Last: Lai Title: Supervising for quality: an empirical examination of institutional arrangements in China's construction industry Abstract: Most of the literature on the rapid changes in institutional arrangements in China's construction industry have either limited themselves to a description of these changes or relied on opinion surveys to draw conclusions. Few researchers have conducted serious empirical examinations, especially regarding the ownership of developers or contractors. To fill this gap, we empirically examined the effectiveness of compulsory construction supervision arrangements on the quality of construction projects in mainland China, explained the seemingly inexplicable phenomenon that projects undertaken by state-owned enterprises (SOEs) are of better quality than those undertaken by non-SOEs, explored the law of tort in relation to construction supervision firms, tested the published official data from 1991 to 2001 on construction 'good quality rates' with regression against per capita values and powers of machinery as well as the capital-output ratios of both SOEs and non-SOEs, identified the determining factors affecting construction quality, and demonstrated the limitations of using the principal-agent theory in analysing the construction industry. The results supported the corollary of the Coase Theorem that resource allocation in terms of output quality will be affected by changes in the institutional arrangements. Journal: Construction Management and Economics Pages: 723-737 Issue: 7 Volume: 26 Year: 2008 Keywords: Construction supervision, construction quality, state-owned enterprise, Coase Theorem, principal-agent theory, X-DOI: 10.1080/01446190801998690 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801998690 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:7:p:723-737 Template-Type: ReDIF-Article 1.0 Author-Name: Jan Brochner Author-X-Name-First: Jan Author-X-Name-Last: Brochner Author-Name: Bo-Christer Bjork Author-X-Name-First: Bo-Christer Author-X-Name-Last: Bjork Title: Where to submit? Journal choice by construction management authors Abstract: Publishers of academic journals can be seen as service providers to authors, in addition to the traditional role of providers of research results to readers. The purpose of this study was to analyse how author choices of journal in construction management are affected by quality and service perceptions. Seven journals were identified and for each 2006 article, one author e-mail address was extracted. A web-based questionnaire was sent to 397 authors and 35% responded. It was found that there were three journals regularly followed by at least half the respondents. Most of the other four journals have scopes broader than construction management and receive lower scores for characteristics such as impact on researchers. No open access journals were included, and authors in the field of construction management rarely post openly accessible copies of their manuscripts or publications on the web. Author ranking of journals for their next submission is found to be related to general criteria such as academic status, circulation figures and ISI indexation. Journal: Construction Management and Economics Pages: 739-749 Issue: 7 Volume: 26 Year: 2008 Keywords: Construction management, research policy, scientific journals, X-DOI: 10.1080/01446190802017698 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802017698 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:7:p:739-749 Template-Type: ReDIF-Article 1.0 Author-Name: Athena Roumboutsos Author-X-Name-First: Athena Author-X-Name-Last: Roumboutsos Author-Name: Konstantinos Anagnostopoulos Author-X-Name-First: Konstantinos Author-X-Name-Last: Anagnostopoulos Title: Public-private partnership projects in Greece: risk ranking and preferred risk allocation Abstract: Project participants, through experience, have an initial perception and predisposition towards risk and the types of risks they are willing and able to undertake. This is equally true for parties interested in public-private partnership (PPP) projects. These initial positions have been registered for the major Greek PPP market stakeholders potentially involved in a PPP arrangement through a survey covering all candidate construction companies, interested financing institutes and a number of public sector entities to be involved in PPPs. Findings revealed that stakeholders were, for the majority of risks identified, in agreement as to preferred risk allocation. Risk allocation preferences for construction companies were compared with similar findings for the UK, a mature PPP market, indicating a possible learning/maturing process based on the particular country background. Conclusions add to other surveys carried out on the subject and should enable public sector clients to establish a more efficient framework for risk allocation, thus reducing negotiations prior to contract award and minimizing the risk of poor risk distribution. Journal: Construction Management and Economics Pages: 751-763 Issue: 7 Volume: 26 Year: 2008 Keywords: Public-private partnerships, risk allocation, stakeholders, X-DOI: 10.1080/01446190802140086 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802140086 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:7:p:751-763 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Author-Name: Keith Cattell Author-X-Name-First: Keith Author-X-Name-Last: Cattell Author-Name: Greg Distiller Author-X-Name-First: Greg Author-X-Name-Last: Distiller Author-Name: Peter Edwards Author-X-Name-First: Peter Author-X-Name-Last: Edwards Title: Job satisfaction of South African quantity surveyors: an empirical study Abstract: A web-based national questionnaire survey of the opinions of registered South African quantity surveyors was undertaken to establish their levels of job satisfaction. Issues explored included demographic factors; factors influencing job satisfaction; choice of career; gender and race in the workplace; and harassment and discrimination at work. Generally, it can be said that South African quantity surveyors like their jobs. Respondents tended to be poorly informed about career prospects when embarking on their careers and, although salary was a main driver in respect of career choice, many quantity surveyors 'drifted' into the career. However, most respondents claimed that they would choose the same career again. Important factors influencing job satisfaction for quantity surveyors were found to include: personal satisfaction in doing the work; a low degree of supervision; participating in decision-making; undertaking challenging and creative work; and receiving recognition for achievements. Not all motivators were present in the respondents' workplaces, particularly participation in decision making and receiving regular feedback on performance. Women quantity surveyors perceive the profession to be male dominated, especially with regard to attitudes towards maternity leave and flexible working hours. The findings provide a valuable basis for indicating how quantity surveying firms can create an environment more conducive to enhancing job satisfaction of professional staff. Journal: Construction Management and Economics Pages: 765-780 Issue: 7 Volume: 26 Year: 2008 Keywords: Job satisfaction, quantity surveyors, South Africa, X-DOI: 10.1080/01446190801998724 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190801998724 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:7:p:765-780 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: First and second price independent values sealed bid procurement auctions: some scalar equilibrium results Abstract: A great body of knowledge exists on the theory of auctions and competitive bidding that is of potential relevance to construction contract tendering. Most of this, however, contains assumptions—such as perfect information—that are unlikely to be tenable in practice. The aim, therefore, is to examine the effects of relaxing some of the more restrictive of these assumptions to align more closely with the construction tendering situation. In particular, the effects of additive and multiplicative (scalar) mark-ups in equilibrium are examined for first and second price auctions in situations where bidders have different, uncertain, costs. This is illustrated first by Monte Carlo simulation—by which bids are generated randomly from a normal distribution for six bidders and mark-ups applied systematically for each bidder in turn until equilibrium is reached. An extensive numerical analysis is then applied to obtain equilibrium results for both mark-up values and expected profit from the simple symmetric case through to more complex asymmetric cases for the uniform and normal distributions. In general, it is found that first price auction bidders with relatively high cv levels and a larger number of bidders involved bid higher in equilibrium but can expect little profit unless the number of bidders involved is small. Where there are asymmetries, stronger bidders (i.e. those with lower costs and less variability) bid much higher and achieve much higher profits in equilibrium. From the seller's point of view, it is cheaper, in equilibrium, to have a homogeneous group of low variability bidders. The work contributes to the body of knowledge on the economic theory of auctions by closing some of the gap between theory and practice. Journal: Construction Management and Economics Pages: 787-803 Issue: 8 Volume: 26 Year: 2008 Keywords: Auction theory, tendering, bidding, equilibrium, mark-up, X-DOI: 10.1080/01446190802175678 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802175678 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:8:p:787-803 Template-Type: ReDIF-Article 1.0 Author-Name: Jieh-Haur Chen Author-X-Name-First: Jieh-Haur Author-X-Name-Last: Chen Author-Name: Li-Ren Yang Author-X-Name-First: Li-Ren Author-X-Name-Last: Yang Author-Name: W. H. Chen Author-X-Name-First: W. H. Author-X-Name-Last: Chen Author-Name: C. K. Chang Author-X-Name-First: C. K. Author-X-Name-Last: Chang Title: Case-based allocation of onsite supervisory manpower for construction projects Abstract: In the highly competitive worldwide construction industry, a slight inaccuracy of estimation can easily cause the loss of a project. Erroneous experience-based cost estimates or allocations of onsite supervisory manpower often offset the profit gained from the project and may even jeopardize the management processes. To counter these types of problems, we develop a model using mathematical analysis and case-based reasoning to automate the allocation of onsite supervisory manpower and its costs. The method is founded upon laborious data collection processes and analysis by matching statistical assumptions, and is applicable to construction projects for residential buildings, industrial office buildings, commercial buildings and industrial construction. In the modelling the costs and allocation of onsite supervisory manpower are quantified for both owners and contractors before initiating or bidding on the projects. The findings confirm that the degree of variation of the model predictions has an accuracy rate at 88.47%. Single-site construction projects with the following characteristics: a non-crashing schedule, a floor area of less than 35 000 m2, a height of less than 50m, can be accurately predicted and the assignment of supervisory manpower feasibly automated. Journal: Construction Management and Economics Pages: 805-814 Issue: 8 Volume: 26 Year: 2008 Keywords: Allocation, human resource management, onsite, overheads, supervisory manpower costs, X-DOI: 10.1080/01446190802014778 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802014778 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:8:p:805-814 Template-Type: ReDIF-Article 1.0 Author-Name: James Wong Author-X-Name-First: James Author-X-Name-Last: Wong Author-Name: Y. H. Chiang Author-X-Name-First: Y. H. Author-X-Name-Last: Chiang Author-Name: Thomas Ng Author-X-Name-First: Thomas Author-X-Name-Last: Ng Title: Construction and economic development: the case of Hong Kong Abstract: The role of construction in economic development is an important issue facing the construction research community, government and international development agencies. Based on empirical analyses, the complexities of the relationship between construction activity and stage of economic development in Hong Kong were examined. With time series data, Granger causality test results show that the construction output particularly the infrastructure sector drives the economic growth of Hong Kong, and not vice versa. Findings further indicate that the role of the local construction industry changes as the economy matures from newly industrializing country (NIC) to advanced industrialized country (AIC) status, as revealed by the diminishing rate of capacity addition by construction as well as the growing maintenance and repair sector. This complies with Bon's inverted U-shaped relationship between construction activity and gross domestic product (GDP). However, the proposition of 'volume follows share' is not supported since the indigenous construction investments still sustain for the service-oriented economy which inevitably needs commercial development and logistics infrastructure to provide the services. The results may be significant for policy makers in NICs, in the long run, to formulate corporate and industrial policies to chart out a viable and sustainable course to revive the vigour of the industry. Journal: Construction Management and Economics Pages: 815-826 Issue: 8 Volume: 26 Year: 2008 Keywords: Bon curve, construction industry, investments, economic development, Hong Kong, X-DOI: 10.1080/01446190802189927 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802189927 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:8:p:815-826 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Author-Name: Rob Dorrington Author-X-Name-First: Rob Author-X-Name-Last: Dorrington Author-Name: Greg Distiller Author-X-Name-First: Greg Author-X-Name-Last: Distiller Author-Name: Harry Lake Author-X-Name-First: Harry Author-X-Name-Last: Lake Author-Name: Sarika Besesar Author-X-Name-First: Sarika Author-X-Name-Last: Besesar Title: HIV/AIDS in the South African construction industry: an empirical study Abstract: South Africa has one of the highest HIV/AIDS prevalence rates, with 11% of South Africans currently estimated to be HIV positive. The construction industry has one of the highest prevalence rates of any economic sector. To indicate the nature and extent of HIV/AIDS in the SA construction industry and to establish the degree of association between certain risk factors and the prevalence of HIV/AIDS, the results of HIV tests on 10 243 construction employees drawn from 55 companies nationwide are reported. In addition to the HIV test, a test for tuberculosis (TB) was conducted but proved inconclusive. Permanently employed, semi-skilled operators and drivers, as well as skilled employees, have the highest prevalence rate of HIV/AIDS; even greater than casual labourers. The group displaying the next highest prevalence is temporarily employed general labourers. With regard to age, middle-aged employees were shown to be the most at risk. Geographically, KwaZulu-Natal exhibits the highest HIV prevalence rate, with the Western Cape the lowest. It is recommended that a compulsory, industry-wide initiative be adopted, funded via levies, involving education, testing and treatment programmes supported via formal certification as part of the completion of work certification process. Journal: Construction Management and Economics Pages: 827-839 Issue: 8 Volume: 26 Year: 2008 Keywords: HIV/AIDS, construction industry, construction worker, South Africa, X-DOI: 10.1080/01446190802061225 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802061225 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:8:p:827-839 Template-Type: ReDIF-Article 1.0 Author-Name: Hemanta Doloi Author-X-Name-First: Hemanta Author-X-Name-Last: Doloi Title: Application of AHP in improving construction productivity from a management perspective Abstract: Poor productivity of construction workers is one of the major causes of cost overruns and schedule slippages in construction projects. Anecdotal evidence suggests that workers' attitudes towards higher productivity may not be limited to purely financial rewards, but inherently linked to many other latent factors. Some building construction projects in Melbourne are compared to each other to ascertain the factors that influence productivity. The factors and their relative importance impacting on workers' productivity are investigated by using a structured questionnaire survey approach. The survey was formulated with 72 questions covering three broad categories, namely (1) project planning; (2) incentives/disincentives; and (3) job satisfaction. Perceived best practices that impact on improvement of productivity on site were identified from 19 targeted experts. Analytical hierarchy process shows that the biggest influences on productivity are planning and programming. The outcome of this study should assist management decisions in determining the effect on productivity and suggest possible improvements to establish the appropriate management procedures for most productive use of labour resources in construction projects. Journal: Construction Management and Economics Pages: 841-854 Issue: 8 Volume: 26 Year: 2008 Keywords: Analytical hierarchy process, productivity, site management, X-DOI: 10.1080/01446190802244789 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802244789 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:8:p:841-854 Template-Type: ReDIF-Article 1.0 Author-Name: Cindy Menches Author-X-Name-First: Cindy Author-X-Name-Last: Menches Author-Name: Awad Hanna Author-X-Name-First: Awad Author-X-Name-Last: Hanna Author-Name: Erik Nordheim Author-X-Name-First: Erik Author-X-Name-Last: Nordheim Author-Name: Jeffrey Russell Author-X-Name-First: Jeffrey Author-X-Name-Last: Russell Title: Impact of pre-construction planning and project characteristics on performance in the US electrical construction industry Abstract: The mild recession experienced in the early part of this decade forced many US electrical contractors to reduce their profit margins as a way to win jobs and survive economically. However, to make up for lower profit margins, contractors turned to 'better planning' as a method for improving their efficiency and increasing their profitability. In general, contractors believe that better planning contributes to better project performance, but the evidence has been mostly anecdotal. A study was conducted recently that transformed anecdotal evidence about the impact of pre-construction planning on performance into quantitative evidence. The research resulted in the development of a model pre-construction planning process that was based on outstanding projects that were well planned and performed well. The study quantified the relationship between pre-construction planning activities, project characteristics and performance, and a separate validation study found that those projects that performed a comprehensive planning process similar to the model planning process were more likely to achieve their estimated work hours, profit, budget and completion goals. Journal: Construction Management and Economics Pages: 855-869 Issue: 8 Volume: 26 Year: 2008 Keywords: Assessments, construction planning, efficiency, electrical measurement, performance measurement, X-DOI: 10.1080/01446190802213511 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802213511 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:8:p:855-869 Template-Type: ReDIF-Article 1.0 Author-Name: Brenda Yip Author-X-Name-First: Brenda Author-X-Name-Last: Yip Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Author-Name: Oi Ling Siu Author-X-Name-First: Oi Ling Author-X-Name-Last: Siu Title: Coping strategies as moderators in the relationship between role overload and burnout Abstract: The moderating effect coping strategies have on the relationship between role overload and burnout was investigated in a sample of 222 professional engineers in the construction industry. A four-factor model of coping strategies, based on the Ways of Coping Questionnaire (WCQ) revised scale, was identified to consist of rational problem solving, resigned distancing, seeking support/ventilation and passive wishful thinking. The results revealed that only rational problem solving significantly moderated the relationship between role overload and all three dimensions of burnout, i.e. emotional exhaustion, cynicism and reduced professional efficacy; whereas the moderating effect of resigned distancing and seeking support/ventilation was significant only on emotional exhaustion and cynicism respectively. Passive wishful thinking failed to demonstrate a significant moderating effect on any of the burnout dimensions at all. The importance and methods of incorporating effective coping strategies as a successful intervention for managing burnout at individual, organizational and institutional levels are discussed. Journal: Construction Management and Economics Pages: 871-882 Issue: 8 Volume: 26 Year: 2008 Keywords: Burnout, coping, moderating effect, role overload, X-DOI: 10.1080/01446190802213529 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802213529 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:8:p:871-882 Template-Type: ReDIF-Article 1.0 Author-Name: Saleh Abu Dabous Author-X-Name-First: Saleh Abu Author-X-Name-Last: Dabous Author-Name: Sabah Alkass Author-X-Name-First: Sabah Author-X-Name-Last: Alkass Title: Decision support method for multi-criteria selection of bridge rehabilitation strategy Abstract: Bridge management is the decision-making process for selecting and prioritizing the actions necessary to maintain a bridge within acceptable limits of safety and serviceability. The current decision-making approach for bridge management is based on optimizing the life cycle cost of the structure. This is a single criterion decision-making process which does not include the indirect impact of the maintenance, repair and replacement actions. Sound bridge management decisions should be made through balanced consideration of multiple and conflicting criteria. This requirement motivated the development of a multi-criteria decision support method for bridge deck management. The method is based on a modified analytic hierarchy process (AHP) to evaluate and rank alternative bridge rehabilitation strategies. The modified AHP provides an effective analytical tool to deal with complex decision making and has the following features: (1) multi-criteria decision-making process; (2) accounts for the uncertainty associated with the pairwise comparison values; and (3) provides a sensitive evaluation of consistency in judgements. The proposed decision support method is a rational decision-making technique for bridge management. The method practicality and validity is demonstrated using a real case study from the industry. Journal: Construction Management and Economics Pages: 883-893 Issue: 8 Volume: 26 Year: 2008 Keywords: AHP, bridge, decision, rehabilitation, X-DOI: 10.1080/01446190802071190 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802071190 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:8:p:883-893 Template-Type: ReDIF-Article 1.0 Author-Name: Iain Cameron Author-X-Name-First: Iain Author-X-Name-Last: Cameron Author-Name: Billy Hare Author-X-Name-First: Billy Author-X-Name-Last: Hare Title: Planning tools for integrating health and safety in construction Abstract: Approaches to planning for health and safety in the UK construction industry have been criticised for being bureaucratic and irrelevant, especially if done by individuals in isolation. This paper reports on the findings of a research project, commissioned by the UK Health and Safety Executive, which investigated the integration of health and safety with construction project planning. A combination of group and individual interviews were undertaken, with qualitative methods of analysis, to develop integrated management tools for all members of the project team. Eight integrated tools were developed: a responsibility chart; an option evaluation chart; health and safety hazard workshops; safety information on drawings; red-amber-green lists; health and safety milestones on programmes; and a design change control process. These were found to aid project planning while simultaneously integrating health and safety issues. However, recommendations are given on how their application can be improved. Journal: Construction Management and Economics Pages: 899-909 Issue: 9 Volume: 26 Year: 2008 Keywords: Health, management, qualitative, planning, safety, X-DOI: 10.1080/01446190802175660 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802175660 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:9:p:899-909 Template-Type: ReDIF-Article 1.0 Author-Name: Samuel Laryea Author-X-Name-First: Samuel Author-X-Name-Last: Laryea Author-Name: Will Hughes Author-X-Name-First: Will Author-X-Name-Last: Hughes Title: How contractors price risk in bids: theory and practice Abstract: Formal and analytical models that contractors can use to assess and price project risk at the tender stage have proliferated in recent years. However, they are rarely used in practice. Introducing more models would, therefore, not necessarily help. A better understanding is needed of how contractors arrive at a bid price in practice, and how, and in what circumstances, risk apportionment actually influences pricing levels. More than 60 proposed risk models for contractors that are published in journals were examined and classified. Then exploratory interviews with five UK contractors and documentary analyses on how contractors price work generally and risk specifically were carried out to help in comparing the propositions from the literature to what contractors actually do. No comprehensive literature on the real bidding processes used in practice was found, and there is no evidence that pricing is systematic. Hence, systematic risk and pricing models for contractors may have no justifiable basis. Contractors process their bids through certain tendering gateways. They acknowledge the risk that they should price. However, the final settlement depends on a set of complex, micro-economic factors. Hence, risk accountability may be smaller than its true cost to the contractor. Risk apportionment occurs at three stages of the whole bid-pricing process. However, analytical approaches tend not to incorporate this, although they could. Journal: Construction Management and Economics Pages: 911-924 Issue: 9 Volume: 26 Year: 2008 Keywords: Contractor, interview and documents, pricing, risk apportionment, tendering, X-DOI: 10.1080/01446190802317718 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802317718 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:9:p:911-924 Template-Type: ReDIF-Article 1.0 Author-Name: Nicola Chiara Author-X-Name-First: Nicola Author-X-Name-Last: Chiara Author-Name: Michael Garvin Author-X-Name-First: Michael Author-X-Name-Last: Garvin Title: Variance models for project financial risk analysis with applications to greenfield BOT highway projects Abstract: Assessment of BOT project financial risk is generally performed by combining Monte Carlo simulation with discounted cash flow analysis. The outcomes of this risk assessment depend, to a significant extent, upon the total project uncertainty, which aggregates aleatory and epistemic uncertainties of key risk variables. Unlike aleatory uncertainty, modelling epistemic uncertainty is a rather difficult endeavour. In fact, BOT epistemic uncertainty may vary according to the significant information disclosed during the concession period. Two properties generally characterize the stochastic behaviour of the uncertainty of BOT epistemic variables: (1) the learning property and (2) the increasing uncertainty property. A new family of Markovian processes, the Martingale variance model and the general variance model, are proposed as an alternative modelling tool for BOT risk variables. Unlike current stochastic models, the proposed models can be adapted to incorporate a risk analyst's view of properties (1) and (2). A case study, a hypothetical BOT transportation project, illustrates that failing to properly model a project's epistemic uncertainty may lead to a biased estimate of the project's financial risk. The variance models may support, guide and extend the thinking process of risk analysts who face the challenging task of representing subjective assessments of key risk factors. Journal: Construction Management and Economics Pages: 925-939 Issue: 9 Volume: 26 Year: 2008 Keywords: Build-operate-transfer, Monte Carlo simulation, risk analysis, stochastic models, X-DOI: 10.1080/01446190802259027 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802259027 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:9:p:925-939 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Title: The role of social capital in knowledge sharing: the case of a specialist rock construction company Abstract: In the discourse on knowledge management, the concept of social capital plays a key role as the mediator of individual know-how or 'human capital' (i.e. individual cognitive or embodied skills and know-how) and structural 'organizational capital', i.e. knowledge embedded in the routines and standard operating procedures of an organization. A study of a Swedish specialist rock construction company, ConCo, demonstrates how the social network acquired by individual site managers is mobilized when unanticipated events occur in day-to-day working life. Rather than using a written or mediated system of knowledge sharing (i.e. Intranets or databases), the site managers relied primarily on verbal communication with their peers. Whenever they encounter a problem, site managers talk to their colleagues or call experts outside the firm in order to get credible and useful advice on how to handle precarious situations. One of the implications of the study is that conceiving of knowledge not as an individual property but as a social accomplishment may enable more detailed understanding of how intellectual resources are used in the construction industry. Journal: Construction Management and Economics Pages: 941-951 Issue: 9 Volume: 26 Year: 2008 Keywords: Social capital, learning-by-doing, knowledge management, X-DOI: 10.1080/01446190802259035 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802259035 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:9:p:941-951 Template-Type: ReDIF-Article 1.0 Author-Name: Lara Jaillon Author-X-Name-First: Lara Author-X-Name-Last: Jaillon Author-Name: C. S. Poon Author-X-Name-First: C. S. Author-X-Name-Last: Poon Title: Sustainable construction aspects of using prefabrication in dense urban environment: a Hong Kong case study Abstract: The construction industry in Hong Kong heavily relies on conventional cast in-situ construction involving extensive use of timber formworks and wet trades. In 2001, the Construction Industry Review Committee (CIRC) report described the construction activities in Hong Kong as 'labour intensive, dangerous and polluting', in which 'built products are rarely defect-free'. Globally, however, the recent trend is prefabrication, which is being increasingly used in the building industry, alleviating some of the environmental burdens associated with conventional construction. The sustainable construction aspects of adopting prefabrication in high-rise buildings are examined, and the economic, environmental and social aspects of using prefabrication are assessed. A questionnaire survey was administered to experienced professionals and case studies of seven recent residential and non-residential buildings in Hong Kong were conducted. The findings revealed that environmental, economic and social benefits of using prefabrication were significant when compared to conventional construction methods. This implies that a wider use of prefabrication techniques could contribute to sustainable construction in a dense urban environment like Hong Kong. Journal: Construction Management and Economics Pages: 953-966 Issue: 9 Volume: 26 Year: 2008 Keywords: High-rise buildings, Hong Kong, precast concrete, prefabrication, sustainable construction, X-DOI: 10.1080/01446190802259043 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802259043 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:9:p:953-966 Template-Type: ReDIF-Article 1.0 Author-Name: Yu-Lin Huang Author-X-Name-First: Yu-Lin Author-X-Name-Last: Huang Title: The pricing of conditional performance guarantees with risky collateral Abstract: Conditional performance guarantees with risky collaterals are specific bonding instruments that are not credit extensions or require only a service fee. Instead, they resemble a credit default swap (CDS) that is essentially an insurance contract and can thus be priced accordingly. A CDS-based model is proposed here for pricing these instruments. The model incorporates both contractor default probability and the recovery risk of collateral. It also allows for explicit specification of bonding parameters such as the promised amount of payment in the event of default. For model implementation, a quasi-KMV-Merton approach is proposed for the estimation of contractor default probability. The historical market prices and basic accounting data of publicly traded construction firms in the Taiwan Economic Journal Database (TEJD) are used to test the model. The model demonstrates effective statistical power to distinguish categorized samples of the firms. It shows that the current industrial practice of asking a standard service rate of 1% tends to charge too little for financially distressed firms and too much for normal ones. Journal: Construction Management and Economics Pages: 967-978 Issue: 9 Volume: 26 Year: 2008 Keywords: Guarantees, contractor default probability, collateral, credit default swap, pricing, models, X-DOI: 10.1080/01446190802290469 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802290469 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:9:p:967-978 Template-Type: ReDIF-Article 1.0 Author-Name: Ivan Damnjanovic Author-X-Name-First: Ivan Author-X-Name-Last: Damnjanovic Author-Name: Jennifer Duthie Author-X-Name-First: Jennifer Author-X-Name-Last: Duthie Author-Name: S. Travis Waller Author-X-Name-First: S. Travis Author-X-Name-Last: Waller Title: Valuation of strategic network flexibility in development of toll road projects Abstract: A reliable, cost-effective and safe transportation system is essential to economic growth. To keep pace with demands for network capacity, revenue-generating projects are increasingly being used to complement the current procurement practices and lessen the pressure on public finances. In such transportation networks where there exists a mix of free access links and links with user fees, network interconnectivity is an important component of project valuation. A bilevel stochastic recourse model for valuating network flexibility is formulated. A key component of the model is consideration of network-based managerial flexibility in context of the upper level project valuation objective and the lower level network user equilibrium solution under demand uncertainty. The results from a test network, for which a closed form solution is possible, indicate that the value of network flexibility directly depends on initial network conditions, variance in future travel demand and toll pricing decisions. Journal: Construction Management and Economics Pages: 979-990 Issue: 9 Volume: 26 Year: 2008 Keywords: Infrastructure planning, real options, network analysis, tolls, X-DOI: 10.1080/01446190802272707 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802272707 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:9:p:979-990 Template-Type: ReDIF-Article 1.0 Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Author-Name: Hongling Guo Author-X-Name-First: Hongling Author-X-Name-Last: Guo Author-Name: Miroslaw Skibniewski Author-X-Name-First: Miroslaw Author-X-Name-Last: Skibniewski Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Using the IKEA model and virtual prototyping technology to improve construction process management Abstract: Learning from manufacturing industries is a useful approach to improving the productivity of the construction industry and to solve problems arising from construction processes. Through the use of virtual prototyping (VP) technology, the lean production process engaged in the IKEA business model (IKEA model) is studied and implemented in a real-life construction project. Specifically, based on the analysis of the IKEA model, the IKEA model can be applied to optimize construction processes and simplify management activities. A case study is analysed to demonstrate the improvement of construction process management through using the VP-IKEA approach. Journal: Construction Management and Economics Pages: 991-1000 Issue: 9 Volume: 26 Year: 2008 Keywords: IKEA model, site operations, virtual prototyping, X-DOI: 10.1080/01446190802290477 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802290477 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:9:p:991-1000 Template-Type: ReDIF-Article 1.0 Author-Name: Xiaoxing Zhang Author-X-Name-First: Xiaoxing Author-X-Name-Last: Zhang Author-Name: Simon Austin Author-X-Name-First: Simon Author-X-Name-Last: Austin Author-Name: Jacqueline Glass Author-X-Name-First: Jacqueline Author-X-Name-Last: Glass Author-Name: Grant Mills Author-X-Name-First: Grant Author-X-Name-Last: Mills Title: Toward collective organizational values: a case study in UK construction Abstract: Values have held a prominent place in business ethics and organizational theories in recent years. Some organizations now aim to integrate values into their business practices, which requires a thorough understanding of the organizational values. However, while many believe organizational values should reflect the collective values of the staff, the majority of values statements are generated by senior management with little examination of employees' personal values. The difficulties surrounding the development of an organization's values are exacerbated by the dearth of literature offering practical guidance. The case study presented has been conducted in a UK construction company using Schwartz's theoretical framework of human values as a starting point and framing device. Employees' values profiles were collected and analysed through an organizational-wide values survey. Follow-up workshops and post-workshop activities facilitated the sharing of common values and helped staff representatives develop their own organizational values statements, independent of the senior management, before a final stage of negotiation with them. The findings support the argument that the shaping of collective organizational values should be based on a clear understanding and communication of employees' personal values, and Schwartz's circumplex model of values and associated survey instrument are helpful framing devices to initiate and structure such a debate. Compared to the usual management-imposed approach, this bottom-up process could make organizational values explicit in a more understandable and useful way, and improve values congruence between individuals and host organizations. Journal: Construction Management and Economics Pages: 1009-1028 Issue: 10 Volume: 26 Year: 2008 Keywords: Case study, management, organizational values, personal values, values statements, X-DOI: 10.1080/01446190802422146 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802422146 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:10:p:1009-1028 Template-Type: ReDIF-Article 1.0 Author-Name: Chris Harty Author-X-Name-First: Chris Author-X-Name-Last: Harty Title: Implementing innovation in construction: contexts, relative boundedness and actor-network theory Abstract: Theoretical understanding of the implementation and use of innovations within construction contexts is discussed and developed. It is argued that both the rhetoric of the 'improvement agenda' within construction and theories of innovation fail to account for the complex contexts and disparate perspectives which characterize construction work. To address this, the concept of relative boundedness is offered. Relatively unbounded innovation is characterized by a lack of a coherent central driving force or mediator with the ability to reconcile potential conflicts and overcome resistance to implementation. This is a situation not exclusive to, but certainly indicative of, much construction project work. Drawing on empirical material from the implementation of new design and coordination technologies on a large construction project, the concept is developed, concentrating on the negotiations and translations implementation mobilized. An actor-network theory (ANT) approach is adopted, which emphasizes the roles that both human actors and non-human agents play in the performance and outcomes of these interactions. Three aspects of how relative boundedness is constituted and affected are described; through the robustness of existing practices and expectations, through the delegation of interests on to technological artefacts and through the mobilization of actors and artefacts to constrain and limit the scope of negotiations over new technology implementation. Journal: Construction Management and Economics Pages: 1029-1041 Issue: 10 Volume: 26 Year: 2008 Keywords: Innovation, implementation, information technology, context, relative boundedness, actor-network theory, X-DOI: 10.1080/01446190802298413 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802298413 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:10:p:1029-1041 Template-Type: ReDIF-Article 1.0 Author-Name: Linda Clarke Author-X-Name-First: Linda Author-X-Name-Last: Clarke Author-Name: Maria Gribling Author-X-Name-First: Maria Author-X-Name-Last: Gribling Title: Obstacles to diversity in construction: the example of Heathrow Terminal 5 Abstract: Why does the construction industry remain a predominantly white, male, able-bodied enclave, despite all the efforts made to make it inclusive? What are the real obstacles to women, those from ethnic minority groups, in particular black and Asian, and those with disabilities entering and remaining in different construction occupations? The recruitment, employment and working conditions on a major and prestigious project in London, Heathrow Terminal 5, where concerted attempts were made to include the local diverse labour force and to improve representation of different minority groups, are examined. Given the high level of building activity, client encouragements and serious skill shortages, the fact that the demand for construction labour was not met by the ready supply of local labour and trainees suggests that the obstacles to inclusion are not related to demand or evident supply factors. Inappropriate provision of training, as well as employment and working conditions, shape the exclusivity of the construction industry. The conclusion drawn is that adherence to traditional practices—old-style apprenticeships, craft-based skill structures, an itinerant workforce, and intensive deployment of labour—are the real basis of the construction industry's lack of diversity. The study is part of a project for the Greater London Authority (GLA) on diversity performance in the London construction industry, conducted jointly with the Working Lives Institute of London Metropolitan University (GLA, 2007). It is based on semi-structured interviews with key stakeholders, including representatives of the client BAA, contractors, trainers from a Further Education College, ConstructionSkills, union organizers, convenors and officers, and workers. The aim is to provide an industry perspective of the issues related to diversity in construction. Journal: Construction Management and Economics Pages: 1055-1065 Issue: 10 Volume: 26 Year: 2008 Keywords: Construction sites, disability, discrimination, equal opportunities, employee relations, X-DOI: 10.1080/01446190802326776 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802326776 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:10:p:1055-1065 Template-Type: ReDIF-Article 1.0 Author-Name: Wei Pan Author-X-Name-First: Wei Author-X-Name-Last: Pan Author-Name: Alistair Gibb Author-X-Name-First: Alistair Author-X-Name-Last: Gibb Author-Name: Andrew Sellars Author-X-Name-First: Andrew Author-X-Name-Last: Sellars Title: Maintenance cost implications of utilizing bathroom modules manufactured offsite Abstract: Though the benefits from using offsite technologies have been rehearsed, their uptake within the UK construction industry is slow. A critical barrier is the lack of cost data of using such technology. Another is the unsubstantiated perception that maintenance of offsite solutions is difficult and expensive. But, yet again, there appear to be no data publicly available on this topic. This knowledge gap is addressed by presenting the cost data of maintaining offsite and insitu bathrooms for student accommodation. The records of 732 maintenance jobs were investigated. These jobs span three years for 398 bathrooms, including precast concrete modules, glass reinforced polyester (GRP) modules and insitu bathrooms. The results suggest that GRP modules required the lowest maintenance costs, while insitu bathrooms were significantly more expensive to maintain. For offsite modules, drainage, toilets, vents and sink were identified as the main problematic areas for maintenance. The maintenance of insitu bathrooms was more complex and involved a wider range of problematic areas. The design imposed significant effects on the long-term cost of offsite bathrooms. Aspirations of clients need to be fully understood and integrated into design. The findings should facilitate the design decision making of using offsite bathrooms for residential buildings. Journal: Construction Management and Economics Pages: 1067-1077 Issue: 10 Volume: 26 Year: 2008 Keywords: Bathroom modules, maintenance costs, offsite, student accommodation, X-DOI: 10.1080/01446190802422161 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802422161 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:10:p:1067-1077 Template-Type: ReDIF-Article 1.0 Author-Name: Carlos Caldas Author-X-Name-First: Carlos Author-X-Name-Last: Caldas Author-Name: Chien-Cheng Chou Author-X-Name-First: Chien-Cheng Author-X-Name-Last: Chou Author-Name: Jim O'connor Author-X-Name-First: Jim Author-X-Name-Last: O'connor Title: Negotiation-based decision support model for utility relocations in transportation infrastructure projects Abstract: Highway projects in metropolitan areas often require that adjacent utilities be relocated to accommodate new or expanded highway facilities. Traditionally, utility owners have been responsible for their own relocations prior to highway construction. However, utility relocation delay was reported as one of the root causes of overall project delays in highway construction. In the USA, one strategic approach sporadically taken over the past 15 years by some state departments of transportation (DOTs) has been to combine utility relocation work with the highway contractor's scope of work. While the combined strategy offers many benefits, it does have its own set of challenges and disadvantages. Many of these difficulties involve disagreements between DOTs and utility owners over the appropriateness of the combined strategy for particular types of relocations. Hence, a negotiation-based decision support model (DSM) for determining whether to use the combined strategy was developed to provide guidance to both DOTs and utility decision makers during the planning and design phases of highways. A literature review and interviews with experts from both DOTs and the utility industry were conducted to identify significant factors as well as their impact levels on the decision. A DSM aiming at synthesizing the factors and orchestrating the negotiation process for the decision was proposed and verified. As suggested by the model evaluators, the proposed DSM can improve the quality of this complex decision-making process, especially for less experienced project managers or designers. Journal: Construction Management and Economics Pages: 1079-1090 Issue: 10 Volume: 26 Year: 2008 Keywords: Decision support systems, utilities, highway transportation, X-DOI: 10.1080/01446190802331388 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802331388 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:10:p:1079-1090 Template-Type: ReDIF-Article 1.0 Author-Name: Matilda Hook Author-X-Name-First: Matilda Author-X-Name-Last: Hook Author-Name: Lars Stehn Author-X-Name-First: Lars Author-X-Name-Last: Stehn Title: Applicability of lean principles and practices in industrialized housing production Abstract: The applicability of lean principles and practices to industrialized housing in Sweden are examined, taking the production culture into consideration. The factory production of industrialized housing shows apparent similarities to manufacturing, but areas related to fully integrated lean production practices, such as error proofing and standardized work floor and equipment maintenance, are scarce. Hence, applicability of lean principles and practices to industrialized housing production is clearly influenced by a production culture that has similarities to a traditional construction culture. Setting up industrialized housing production thus requires careful implementation of lean principles if workers from traditional building are moved into factories, and managers still adhere to the prevailing site-based production mentality. However, the influence of the traditional construction project culture is not solely a constraint; flexible teams that take their own responsibility are also important in a lean culture. Hence, retaining parts of the existing construction mentality, context and way of working is also central when discussing lean applicability in industrialized housing. Journal: Construction Management and Economics Pages: 1091-1100 Issue: 10 Volume: 26 Year: 2008 Keywords: Lean production, lean construction, industrialized housing, culture, X-DOI: 10.1080/01446190802422179 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802422179 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:10:p:1091-1100 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Clare Lingard Author-X-Name-First: Helen Clare Author-X-Name-Last: Lingard Author-Name: Keith Townsend Author-X-Name-First: Keith Author-X-Name-Last: Townsend Author-Name: Lisa Bradley Author-X-Name-First: Lisa Author-X-Name-Last: Bradley Author-Name: Kerry Brown Author-X-Name-First: Kerry Author-X-Name-Last: Brown Title: Alternative work schedule interventions in the Australian construction industry: a comparative case study analysis Abstract: Project-based construction workers in the Australian construction industry work long and irregular hours and experience higher levels of work-to-family conflict and burnout than office-based workers, giving rise to an interest in alternative work schedules as a means of supporting work-life balance. Alternative work schedules were implemented in four case study construction projects in Australia. Interventions differed between projects, with two implementing a compressed work week, and the others introducing reduced hours schedules (one of which was optional). Data were collected from each case study project, using various combinations of focus groups, surveys, interviews and daily diary collection methods. The results were mixed. The compressed work week appears to have been favourably received where it was introduced. However, waged workers still expressed concerns about the impact on their weekly 'take-home' pay. Attempts to reduce work hours by changing from a six- to a five-day schedule (without extending the length of the working day between Monday and Friday) were less favourably received. Waged workers, in particular, did not favour reduced hours schedules. The results confirm the existence of two distinct labour markets operating in the Australian construction industry and markedly different responses to alternative work schedules, based upon whether workers are waged or salaried. The results clearly show that attempts to improve work-life balance must take the structural characteristics of the industry's labour markets into consideration in the design of interventions. The impact of alternative work schedules is likely to be moderated by institutional working time regimes within the construction industry. Journal: Construction Management and Economics Pages: 1101-1112 Issue: 10 Volume: 26 Year: 2008 Keywords: Work hours, alternative work schedules, work-life balance, labour market characteristics, X-DOI: 10.1080/01446190802389402 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802389402 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:10:p:1101-1112 Template-Type: ReDIF-Article 1.0 Author-Name: Roine Leiringer Author-X-Name-First: Roine Author-X-Name-Last: Leiringer Author-Name: Paula Cardellino Author-X-Name-First: Paula Author-X-Name-Last: Cardellino Title: Tales of the expected: investigating the rhetorical strategies of innovation champions Abstract: Innovation continues to be high on the agenda in construction. It is widely considered to be an essential prerequisite of improved performance both for the sector at large and for individual firms. Success stories dominate the parts of the academic literature that rely heavily on the recollections of key individuals. A complementary interpretation focuses on the way innovation champions in hindsight interpret, justify and legitimize the diffusion of innovations. Emphasis is put on the temporal dimension of interpretation and how this links to rhetorical strategies and impression management tactics. Rhetorical theories are drawn upon to analyse the accounts given by innovation champions in seven facilities management organizations. In particular, the three persuasive appeals in classic rhetoric are used to highlight the rhetorical justifications mobilized in the descriptions of what took place. The findings demonstrate the usefulness of rhetorical theories in complementing studies of innovation. Journal: Construction Management and Economics Pages: 1043-1054 Issue: 10 Volume: 26 Year: 2008 Keywords: Innovation, innovation champion, rhetorical strategies, impression management, legitimacy, X-DOI: 10.1080/01446190802389394 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802389394 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:10:p:1043-1054 Template-Type: ReDIF-Article 1.0 Author-Name: Mohamed Marzouk Author-X-Name-First: Mohamed Author-X-Name-Last: Marzouk Author-Name: Magdy Madany Author-X-Name-First: Magdy Author-X-Name-Last: Madany Author-Name: Azza Abou-Zied Author-X-Name-First: Azza Author-X-Name-Last: Abou-Zied Author-Name: Moheeb El-said Author-X-Name-First: Moheeb Author-X-Name-Last: El-said Title: Handling construction pollutions using multi-objective optimization Abstract: Quantitative assessment of emissions associated with construction projects should be carried out during the planning phase of the projects. This is important to detect and highlight any excesses of residuals during the construction phase. A newly developed framework is proposed to handle construction pollution using multi-objective optimization. The approach, utilized by the proposed framework, is based on calculating the generated pollution for each activity involved in the project, as a result of dust, harmful gases and noise. The results of the quantitative assessment are integrated in a utility function that expresses the amount of total pollution. Then, evolutionary genetic algorithms (GAs) are used to carry multi-objective optimization, considering three objective functions (project duration, project cost and total pollution). The proposed application considers the dynamic nature of construction activities including different types of relationships and the change of activities' criticality. An actual case study is worked out to demonstrate the practical use of the proposed framework and to investigate the sensitivity of its parameters. Journal: Construction Management and Economics Pages: 1113-1125 Issue: 10 Volume: 26 Year: 2008 Keywords: Built environment, genetic algorithms, optimization, X-DOI: 10.1080/01446190802400779 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802400779 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:10:p:1113-1125 Template-Type: ReDIF-Article 1.0 Author-Name: Ani Birgit Raiden Author-X-Name-First: Ani Birgit Author-X-Name-Last: Raiden Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: Richard Neale Author-X-Name-First: Richard Author-X-Name-Last: Neale Title: Understanding employee resourcing in construction organizations Abstract: In recent years the literature on employee resourcing has consistently advocated the importance of adopting a holistic, strategic approach to employee deployment decision making rather than adopting a reactive needs-based approach. This is particularly problematic in construction where the multi-project environment leads to constantly changing resource requirements and to changing demands over a project's life cycle. This can lead to inappropriate decisions, which fail to meet the longer-term needs of both construction organizations and their employees. A structured and comprehensive understanding of the current project team deployment practices within large construction organizations was developed. Project deployment practices were examined within seven case study contracting firms. The emergent themes that shaped the decision-making processes were grouped into five broad clusters comprising human resource planning, performance/career management, team deployment, employee involvement and training and development. The research confirms that a reactive and ad hoc approach to the function prevails within the firms investigated. This suggests a weak relationship between the deployment process and human resource planning, team deployment, performance management, employee involvement and training and development activities. It is suggested that strategic HR-business partnering could engender more transparent and productive relationships in this crucial area. Journal: Construction Management and Economics Pages: 1133-1143 Issue: 11 Volume: 26 Year: 2008 Keywords: Employee involvement, human resource management, recruitment, project team, strategic management, X-DOI: 10.1080/01446190802422153 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802422153 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:11:p:1133-1143 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Raisbeck Author-X-Name-First: Peter Author-X-Name-Last: Raisbeck Title: Perceptions of architectural design and project risk: understanding the architects' role in a PPP project Abstract: Southern Cross Station is one of the largest public-private partnership (PPP) projects undertaken in Australia. In this project the architects played a significant role in developing an iconic design which has received international professional design awards and much media attention. In the media the architects' design was perceived as having impacted negatively on capital costs. Given these contradictory perceptions, the aim of this study was to better understand perceptions of the architects' role in relation to project risks arising out of their design. A survey of key project executives working in the PPP consortium responsible for delivering the project was undertaken. The survey was structured by a framework combining the PPP life cycle, project risks and the idea that architectural design can be viewed as a research and development activity rather than simply as a problem-solving activity. The survey responses point to the fact that the architects mitigated technical and operating risks and their activities had little bearing on the project's substantial write-downs. This counters media perceptions of the project that the design activities of the architects created more risks than they mitigated. Journal: Construction Management and Economics Pages: 1145-1157 Issue: 11 Volume: 26 Year: 2008 Keywords: Architecture, risk management, design, public-private partnerships, X-DOI: 10.1080/01446190802512342 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802512342 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:11:p:1145-1157 Template-Type: ReDIF-Article 1.0 Author-Name: Nongiba Kheni Author-X-Name-First: Nongiba Author-X-Name-Last: Kheni Author-Name: Andy Dainty Author-X-Name-First: Andy Author-X-Name-Last: Dainty Author-Name: Alistair Gibb Author-X-Name-First: Alistair Author-X-Name-Last: Gibb Title: Health and safety management in developing countries: a study of construction SMEs in Ghana Abstract: The construction industry plays a significant role in the economy of developing countries. The sector is, however, also one of the most hazardous with frequent accidents and health-related problems. The health and safety practices of construction small and medium-sized enterprises (SMEs) in Ghana are examined with a view to improving the health and safety performance of the sector. A survey questionnaire was administered to owner/managers of SMEs, with a response rate of 32% of the sampling frame. Few of the SMEs adopted proactive health and safety practices. However, health and safety practices identified as being particularly associated with firm characteristics were: accident investigation procedures; accident reporting procedures; use of health and safety posters; documentation of method statements; and health and safety inductions. The diversity of health and safety practices associated with different size categories of SMEs and constraints to improving health and safety are highlighted. A positive change is needed in the attitudes of owner/managers which takes into account size-related constraints in order to improve the health and safety performance of Ghanaian SMEs. Journal: Construction Management and Economics Pages: 1159-1169 Issue: 11 Volume: 26 Year: 2008 Keywords: Developing countries, health and safety, SMEs, survey, X-DOI: 10.1080/01446190802459916 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802459916 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:11:p:1159-1169 Template-Type: ReDIF-Article 1.0 Author-Name: Luiz Eduardo Brandao Author-X-Name-First: Luiz Eduardo Author-X-Name-Last: Brandao Author-Name: Eduardo Saraiva Author-X-Name-First: Eduardo Author-X-Name-Last: Saraiva Title: The option value of government guarantees in infrastructure projects Abstract: The participation of private capital in public infrastructure investment projects has been sought by many governments who perceive this as a way to overcome budgetary constraints and foster economic growth. For some types of projects, this investment may require government participation in the form of project guarantees in order to reduce the risk to the private investor, and as a consequence, the government assumes a contingent liability which may have significant future budgetary impacts. We present a minimum traffic guarantee (MTG) real options model that differs from most of the literature in the field by using market data to determine stochastic project parameters. This model can be used to assess the value of these guarantees, allows the government to analyse the cost-benefit of each level of support, and proposes an alternative to limit the exposure of the government while still maintaining the benefits to the private investor. We apply this model to the projected 1000 mile long BR-163 toll road that will link the Brazilian Midwest to the Amazon River. We conclude that the use of public-private partnerships (PPP) with guarantees and caps on total government outlays can be modelled effectively using option pricing methods and can be a solution to attract private investment to high risk public infrastructure projects. Journal: Construction Management and Economics Pages: 1171-1180 Issue: 11 Volume: 26 Year: 2008 Keywords: Real options, infrastructure projects, toll roads, government guarantees, concessions, X-DOI: 10.1080/01446190802428051 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802428051 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:11:p:1171-1180 Template-Type: ReDIF-Article 1.0 Author-Name: Hemanta Doloi Author-X-Name-First: Hemanta Author-X-Name-Last: Doloi Title: Analysing the novated design and construct contract from the client's, design team's and contractor's perspectives Abstract: The novated design and construct (ND&C) contract is one of the increasingly preferred options among developers of large commercial and residential projects across Australia. As a consequence of novation, the design team's obligation to the client gets transferred to the contractor who becomes responsible for carrying out the detailed design work at a later stage of project life cycle. Subsequently, there are some inherent factors that can depict the effectiveness of how all parties in the process interact leading to a successful delivery of project through ND&C contracts. A common set of 31 influencing attributes have been identified through a systematic research approach and their relative significance and impacts have been determined based on a structured questionnaire survey in selected construction projects. By performing the factor analysis, a total of eight factors significant to ND&C contracts were extracted, namely (1) impact of initial design; (2) client's involvements in post novation design; (3) selection of design team; (4) contractor's obligation; (5) morale in post novation; (6) experience of design team; (7) relationship between contractor and design team; and (8) expertise of DT in ND&C projects. With a clear understanding of the roles of clients, design team and the contractors, these findings could potentially contribute to develop a company's procedures or enhance existing knowledge in relation to the ND&C procurement approach. Journal: Construction Management and Economics Pages: 1181-1196 Issue: 11 Volume: 26 Year: 2008 Keywords: Design novation, procurement practice, factor analysis, X-DOI: 10.1080/01446190802512359 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802512359 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:11:p:1181-1196 Template-Type: ReDIF-Article 1.0 Author-Name: Farnad Nasirzadeh Author-X-Name-First: Farnad Author-X-Name-Last: Nasirzadeh Author-Name: Abbas Afshar Author-X-Name-First: Abbas Author-X-Name-Last: Afshar Author-Name: Mostafa Khanzadi Author-X-Name-First: Mostafa Author-X-Name-Last: Khanzadi Author-Name: Susan Howick Author-X-Name-First: Susan Author-X-Name-Last: Howick Title: Integrating system dynamics and fuzzy logic modelling for construction risk management Abstract: The complex structure of construction project risks arises from their internal and external interactions with their dynamic nature throughout the life cycle of the project. A system dynamics (SD) approach to construction project risk management is presented, including risk analysis and response process. Owing to the imprecise and uncertain nature of risks, fuzzy logic is integrated into system dynamics modelling structure. Risk magnitudes are defined by a fuzzy logic based risk magnitude prediction system. Zadeh's extension principle and interval arithmetic is employed in the SD simulation model to present the system outcomes considering uncertainties in the magnitude of risks resulting from the risk magnitude prediction system. The performance of the proposed method is assessed by employing the method in the risk management plan of a sample project. The impact of a sample risk is quantified and efficiency of different alternative response scenarios is assessed. The proposed approach supports different stages of the risk management process considering both the systemic and uncertain nature of risks. Journal: Construction Management and Economics Pages: 1197-1212 Issue: 11 Volume: 26 Year: 2008 Keywords: Fuzzy logic, risk management, system dynamics, X-DOI: 10.1080/01446190802459924 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802459924 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:11:p:1197-1212 Template-Type: ReDIF-Article 1.0 Author-Name: Zhikun Ding Author-X-Name-First: Zhikun Author-X-Name-Last: Ding Author-Name: Fungfai Ng Author-X-Name-First: Fungfai Author-X-Name-Last: Ng Title: A new way of developing semantic differential scales with personal construct theory Abstract: Measurement is a fundamental issue in management research. However, traditional scale development methods have the drawback of mixing researchers' bias with the scale design. Based on Ding et al.'s (2007) exploratory work, a new way to develop semantic differential measurement scales is proposed and tested with a survey in the context of the construction industry. The purpose is to provide researchers and practitioners with a new method to develop semantic differential scales for measurement while the bias from their own perspective can be reduced. The reliability and validity of semantic differential scales according to the new method are tested with SPSS and Amos 6.0. The results show that the generated semantic differential scales with this method have high reliability and validity. The new way to develop semantic differential scales offers researchers and practitioners one more choice of scale development. The general application of this new method to other contexts is yet to be tested. Journal: Construction Management and Economics Pages: 1213-1226 Issue: 11 Volume: 26 Year: 2008 Keywords: Personal construct theory, full grid technique, semantic differential scale, exploratory factor analysis, confirmatory factor analysis, X-DOI: 10.1080/01446190802527522 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802527522 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:11:p:1213-1226 Template-Type: ReDIF-Article 1.0 Author-Name: Oyeshola Femi Kofoworola Author-X-Name-First: Oyeshola Femi Author-X-Name-Last: Kofoworola Author-Name: Shabbir Gheewala Author-X-Name-First: Shabbir Author-X-Name-Last: Gheewala Title: An input-output analysis of Thailand's construction sector Abstract: Three input-output (IO) tables compiled between 1995 and 2000 were used to examine the significance of the construction sector and its relationships with other sectors of the Thai economy. The pull and push effect of the Thai construction sector to the national economy indicated that the former is much larger than the latter. Additionally, the relatively high output multipliers and backward linkage indicators showed that the construction sector had the potential to trigger off production in many economic sectors linked to it. An aggregated sectoral analysis revealed the high dependence of construction on manufacturing followed by services. The findings also suggest that the trends of the profile of inputs and outputs are correlated to the economic conditions in Thailand at the time the IO tables were compiled. Finally, the results of employment analysis showed that although the share of construction sector in direct employment generation may not be very large, its economic importance lies in its direct and indirect contribution to employment through strong backward linkage effects. Consequently, when its backward linkages and output multiplier are considered together with the employment opportunities latent within it, then the construction sector could be a major contributor to the economic growth of Thailand. Journal: Construction Management and Economics Pages: 1227-1240 Issue: 11 Volume: 26 Year: 2008 Keywords: Input-output analysis, multipliers, linkages, construction sector, Thailand, X-DOI: 10.1080/01446190802425560 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802425560 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:11:p:1227-1240 Template-Type: ReDIF-Article 1.0 Author-Name: Doug Forbes Author-X-Name-First: Doug Author-X-Name-Last: Forbes Author-Name: Simon Smith Author-X-Name-First: Simon Author-X-Name-Last: Smith Author-Name: Malcolm Horner Author-X-Name-First: Malcolm Author-X-Name-Last: Horner Title: Tools for selecting appropriate risk management techniques in the built environment Abstract: The built environment is full of uncertainty which leads to risk. The literature shows that there is a wide range of techniques available to deal with risk; however numerous studies have shown that only a relatively small number are used in practice. One reason for this small number is a lack of knowledge of the circumstances in which they can be used. With the aim of overcoming this lack of knowledge two decision support tools are developed, which assist in selecting appropriate cases. The first tool is a two-dimensional matrix which provides a graphical output but has several limitations; the second is a case-based reasoning (CBR) model. These tools have been built from literature examples of the application of risk techniques. A framework has been developed to assess the examples. It uses a PESTLE (Political, Economic, Social, Technical, Legal and Environmental) analysis to assess the problem characteristics. The associated data used in the problem were defined as fuzzy, incomplete or random. The results of the CBR validation demonstrated a tool that predicts the correct technique in excess of 80% of cases, and allows the matrix to be revised and refined. Journal: Construction Management and Economics Pages: 1241-1250 Issue: 11 Volume: 26 Year: 2008 Keywords: Risk management, risk techniques, decision support system, case-based reasoning, X-DOI: 10.1080/01446190802468487 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802468487 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:11:p:1241-1250 Template-Type: ReDIF-Article 1.0 Author-Name: Ajibade Ayodeji Aibinu Author-X-Name-First: Ajibade Ayodeji Author-X-Name-Last: Aibinu Author-Name: Thomas Pasco Author-X-Name-First: Thomas Author-X-Name-Last: Pasco Title: The accuracy of pre-tender building cost estimates in Australia Abstract: A pre-tender building cost estimate is an important piece of information when making decisions at the project planning and design stage. The important project characteristics influencing the accuracy of pre-tender building cost estimates are examined and practical improvement for increasing the accuracy of estimates are considered. A quantitative approach is used to address the research problem. Analysis of data from 56 projects and from a postal questionnaire survey of 102 quantity surveying firms suggests that the accuracy of pre-tender building cost estimates varies according to project size and principal structural material. When eight identified project characteristics are controlled in a multiple regression analysis, the accuracy of estimates is influenced by project size. The estimates of smaller projects are more biased than the estimates of larger projects. It was discovered that pre-tender building costs are more often overestimated than are underestimated. Overestimated forecasts are incorrect by a larger amount than underestimated forecasts. Data analysis also revealed that the accuracy of pre-tender building cost estimates has not improved over time. The majority of the respondents are somewhat dissatisfied with the accuracy of estimates in the industry. Probability estimation and simulation of past estimates, reducing quantity surveying and cost engineering skill turnover, incorporating market sentiments into estimates, early involvement of the quantity surveyor at the brief stage, and proper documentation of experience gained in the estimation of projects should help firms increase the accuracy of estimates for new projects. Journal: Construction Management and Economics Pages: 1257-1269 Issue: 12 Volume: 26 Year: 2008 Keywords: Australia, estimating accuracy, pre-tender estimates, quantity surveying, tendering, X-DOI: 10.1080/01446190802527514 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802527514 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:12:p:1257-1269 Template-Type: ReDIF-Article 1.0 Author-Name: Anita Liu Author-X-Name-First: Anita Author-X-Name-Last: Liu Author-Name: Richard Fellows Author-X-Name-First: Richard Author-X-Name-Last: Fellows Title: Behaviour of quantity surveyors as organizational citizens Abstract: Understanding the individual's collectivistic orientations toward group goals and task activities is critical for developing cooperative and productive teams. The complex environment of modern construction, where the emphasis shifts from individually oriented to team-based work, has led to many challenges. There are important issues of cooperative behaviours in a world of cultural pluralism in which interpersonal cooperation is juxtaposed with organizational citizenship behaviour. Behaviours of construction project participants are important manifestations of culture that are dependent upon norms, values and beliefs. Certain organizational cultures support individualistic behaviours while others emphasize the benefits to the collective whole. Collectivistic orientation is examined as the cultural dimension of individualism-collectivism (IC) and found to be related to organizational citizenship behaviour (OCB) where the correlations of IC and most OCB variables are significant for quantity surveyors in Hong Kong. Generally, the (more) individualistic persons are less likely to exhibit organizational citizenship behaviours. Journal: Construction Management and Economics Pages: 1271-1282 Issue: 12 Volume: 26 Year: 2008 Keywords: Culture, individualism-collectivism, organizational citizenship behaviour, X-DOI: 10.1080/01446190802527530 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802527530 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:12:p:1271-1282 Template-Type: ReDIF-Article 1.0 Author-Name: David William Cattell Author-X-Name-First: David William Author-X-Name-Last: Cattell Author-Name: Paul Anthony Bowen Author-X-Name-First: Paul Anthony Author-X-Name-Last: Bowen Author-Name: Ammar Kaka Author-X-Name-First: Ammar Author-X-Name-Last: Kaka Title: A simplified unbalanced bidding model Abstract: Much research effort to date has focused on the development and use of bidding models in optimizing contractors' bid prices in competitive tendering environments. Unbalanced bidding models, in particular, have the objective of maximizing a project's prospective profits by using techniques of applying differentiated mark-ups to all of a project's items of work. It is shown here that these unbalanced bidding models have been unnecessarily complicated by incorporating consideration of a project's item costs. Bidding models can be significantly simplified by having the objective of maximizing a project's top-line revenue rather than maximizing bottom-line profit. A new model, incorporating all three standard effects of item price loading: namely, front-end loading, individual-rate loading, and back-end loading, is proposed that gives effect to determining the optimum pricing for a project's component items. Journal: Construction Management and Economics Pages: 1283-1290 Issue: 12 Volume: 26 Year: 2008 Keywords: Bidding, competitive advantage, cost modelling, revenue, mark-up, X-DOI: 10.1080/01446190802570506 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802570506 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:12:p:1283-1290 Template-Type: ReDIF-Article 1.0 Author-Name: Symeon Christodoulou Author-X-Name-First: Symeon Author-X-Name-Last: Christodoulou Title: A bid-unbalancing method for lowering a contractor's financial risk Abstract: A method is presented for unbalancing bids and optimizing the allocation of overall project profits to individual activities by considering the financial parameters of a project (bid mark-up and projected cash flow), in conjunction with lowering the exposure to possible financial disorder in the project. The method utilizes the general concept of entropy and a variant of it (hereby termed 'monetary entropy', H M) as measures of a project's perceived level of disorder, in order to distribute the total bid mark-up to the project activities. The entropy-based bid-unbalancing method seeks to minimize a possible financial disorder (the monetary entropy) resulting from limited monetary resources available to the project and from badly developed project cash flows. The intended primary users of the method are contractors during the initial bidding stage of a project. Journal: Construction Management and Economics Pages: 1291-1302 Issue: 12 Volume: 26 Year: 2008 Keywords: Bid-unbalancing, project profitability, cash flow optimization, entropy, X-DOI: 10.1080/01446190802596238 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802596238 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:12:p:1291-1302 Template-Type: ReDIF-Article 1.0 Author-Name: Sepani Senaratne Author-X-Name-First: Sepani Author-X-Name-Last: Senaratne Author-Name: Martin Sexton Author-X-Name-First: Martin Author-X-Name-Last: Sexton Title: Managing construction project change: a knowledge management perspective Abstract: In the information age, organization theories have addressed problem-solving as an information-processing activity. However, in this era, with the realization of knowledge-based views of the organization, shared problem-solving is increasingly recognized as a knowledge creation trigger. During shared problem-solving, stakeholders bring different types of knowledge into the problem situation and it is captured, created and shared by the team members. In construction projects, shared problem-solving often takes place through pragmatic problem-solving on site, in particular, through managing project changes. However, this significant role of knowledge in managing project change is not well appreciated in the extant literature. Accordingly, to explore how knowledge is created during project changes in construction a case study approach was adopted using two change events in two collaborative settings within the UK construction industry. The case study findings revealed that different forms of knowledge are created during the project change process within construction projects. However, this knowledge remains largely tacit and does not disseminate to the wider organization due to imbalanced codification and personalization strategies existing in such settings. A knowledge management perspective is introduced to manage project change so that construction project teams can successfully resolve and learn from change events. Journal: Construction Management and Economics Pages: 1303-1311 Issue: 12 Volume: 26 Year: 2008 Keywords: Shared problem-solving, managing project change, construction projects, knowledge management, X-DOI: 10.1080/01446190802621044 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802621044 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:12:p:1303-1311 Template-Type: ReDIF-Article 1.0 Author-Name: R. Edward Minchin Author-X-Name-First: R. Edward Author-X-Name-Last: Minchin Author-Name: Michael Hammons Author-X-Name-First: Michael Author-X-Name-Last: Hammons Author-Name: Junyong Ahn Author-X-Name-First: Junyong Author-X-Name-Last: Ahn Title: A construction quality index for highway construction Abstract: Changes in policy regarding the use of contractor-conducted testing in quality assurance decisions have hit state highway agencies (SHAs) during a time of continuing reduction in agency personnel. These changes have increased the need for quality-driven contractors. This, coupled with more agencies adopting specifications tied to performance, places more requirements on contractors to emphasize quality management in their operations. There is a need for rational, comprehensive methods to evaluate a contractor's end product from a quality perspective; thus, there is a need for new techniques and approaches for examining and rating the quality of performance. Researchers and practitioners alike should benefit from this description of the construction quality index (CQI) developed through a grant from the Florida Department of Transportation. The CQI is a rating of the quality of materials and workmanship on highway projects that, unlike current quality rating models used by SHAs, is completely objective. Under limited validation testing, the model proved able to assign quality index values consistent with the owner's level of satisfaction with the overall project. Journal: Construction Management and Economics Pages: 1313-1324 Issue: 12 Volume: 26 Year: 2008 Keywords: Highways, pavement, analytical hierarchy process, quality, X-DOI: 10.1080/01446190802621036 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802621036 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:26:y:2008:i:12:p:1313-1324 Template-Type: ReDIF-Article 1.0 Author-Name: Adel Al-Kharashi Author-X-Name-First: Adel Author-X-Name-Last: Al-Kharashi Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Causes of delays in Saudi Arabian public sector construction projects Abstract: Many public construction projects have been undertaken throughout the Kingdom of Saudi Arabia as part of the government's national development plans in the past three decades, with significant public expenditure involved. One of the critical problems concerning these projects is the frequent and lengthy delays that occur. In order to improve the situation, it is first necessary to identify the major causes involved. Several studies have already been reported which do this but all use different sets of variables. Also, none has attempted to identify the extent to which improvements are possible in practice. A new survey is reported that uses all the variables from the previous work and measures for both current degree of effect on delays and the extent to which each can be practically improved. These are contained in seven groupings: client, contractor, consultant, materials, labour, contract and relationship-related causes. The survey covers a sample of 86 clients, contractors and consultants working in the Saudi construction industry. The analysis reveals some considerable heterogeneity between the cause groupings and respondent groupings in terms of means and correlations, apparently partly due to lack of knowledge of respondents and a tendency for the consultants to blame the contractors for the delays and vice versa. The main results, therefore, are disaggregated to reflect the views of each respondent group concerning each group of causes. In general however, it is found that the most influencing current cause of delay is the lack of qualified and experienced personnel—attributed to the considerable amount of large, innovative, construction projects and associated current undersupply of manpower in the industry. Journal: Construction Management and Economics Pages: 3-23 Issue: 1 Volume: 27 Year: 2009 Keywords: Delays, public sector, Saudi Arabia, survey, X-DOI: 10.1080/01446190802541457 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802541457 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:1:p:3-23 Template-Type: ReDIF-Article 1.0 Author-Name: Liaquat Hossain Author-X-Name-First: Liaquat Author-X-Name-Last: Hossain Title: Communications and coordination in construction projects Abstract: Coordination can be seen as a process of managing resources in an organized manner so that a higher degree of operational efficiency can be achieved for a given project. Social network matrices are constructed using different centrality measures. These measurements are used to explore the association between network centrality and coordination for a construction project. Network centrality affects the ability of an individual to coordinate the actions of others. The following questions guide this study: What is the effect of network centrality on coordination? How is the actor's ability to coordinate projects related to his or her structural position in the communications network? Multi-layered test designs were developed to explore this relationship in a project-based coordination of Dabhol Power Company Construction company and Azurix Corporation. There are three major findings from this analysis. First, centrally positioned actors show more coordinative activity. Second, the betweenness index of centrality is the most potent predicate for coordination. Last, the influence of an actor is associated with coordination more than the actor's prominence. Journal: Construction Management and Economics Pages: 25-39 Issue: 1 Volume: 27 Year: 2009 Keywords: Communications, coordination, network centrality, social network analysis, X-DOI: 10.1080/01446190802558923 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802558923 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:1:p:25-39 Template-Type: ReDIF-Article 1.0 Author-Name: Patrick Lam Author-X-Name-First: Patrick Author-X-Name-Last: Lam Author-Name: Franky Wong Author-X-Name-First: Franky Author-X-Name-Last: Wong Title: Improving building project performance: how buildability benchmarking can help Abstract: Although the buildability of building designs has not been commonly taken as an important parameter in design quality assessment, previous studies have linked buildability to time, cost, quality and safety performance in many ways. Based on this observation, the question arises of how buildability can be benchmarked and which aspects of project performance can be improved. After identifying available benchmarking tools, the relative correlations are investigated between different buildability attributes and construction performance in terms of time, cost, quality and safety. Based on a questionnaire survey, it was found that construction time performance has strong positive correlations with buildability in the design of external wall elements, simplicity of assembly and installation considerations, while other design attributes affect cost, quality and safety performance to varying degrees. With this understanding, it is postulated that best practice can be promoted among design teams for enhancing buildability, which would in turn raise project performance. Three experienced practitioners have been interviewed for verifying the practicality of buildability benchmarking. As an incentive to improve buildability, benchmarking would help construction stakeholders reap their desired benefits by focusing on the related design attributes in the pre-construction stage, particularly for functionally oriented buildings. Journal: Construction Management and Economics Pages: 41-52 Issue: 1 Volume: 27 Year: 2009 Keywords: Buildability, project performance, benchmarking, best practice, X-DOI: 10.1080/01446190802570498 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802570498 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:1:p:41-52 Template-Type: ReDIF-Article 1.0 Author-Name: Abdulrahman Salem Bageis Author-X-Name-First: Abdulrahman Salem Author-X-Name-Last: Bageis Author-Name: Chris Fortune Author-X-Name-First: Chris Author-X-Name-Last: Fortune Title: Factors affecting the bid/no bid decision in the Saudi Arabian construction contractors Abstract: The bid/no bid decision requires an understanding of a company's assessment in relation to factors affecting the decision. Different companies might have different assessment values. The aim is to investigate how bid/no bid decisions are influenced by different characteristics of contractors. Various factors are identified and then analysed in order to investigate their influence and relative significance. A questionnaire survey was used to identify and rank the factors affecting the bidding decision and then analyse them in terms of differences between the returned responses with respect to the differing respondent characteristics. The findings have established the ranking order of the factors affecting the bid/no bid decision and identified their weights of importance. In addition, the influence of these characteristics upon the different weights of importance given by the survey respondents is found to be statistically significant. The most influential characteristics that affected their assessment of the weight of importance are contractor size, classification status of the contractor and the main client type. Different contractors' characteristics should be reflected in the way that the bid/no bid decisions are modelled. Also, the data collected should be categorized with regards to contractors' characteristics before starting the data analysis and modelling processes. Journal: Construction Management and Economics Pages: 53-71 Issue: 1 Volume: 27 Year: 2009 Keywords: Bid/no bid decision, decision making, project selection, X-DOI: 10.1080/01446190802596220 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802596220 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:1:p:53-71 Template-Type: ReDIF-Article 1.0 Author-Name: Sungmin Yun Author-X-Name-First: Sungmin Author-X-Name-Last: Yun Author-Name: Carlos Caldas Author-X-Name-First: Carlos Author-X-Name-Last: Caldas Title: Analysing decision variables that influence preliminary feasibility studies using data mining techniques Abstract: The development of infrastructure contributes to the social and economic improvement of a country, and generally requires huge and immediate investments. To decide on appropriate infrastructure projects, many countries use preliminary feasibility studies (PFS). However, a preliminary feasibility study takes a relatively long time to complete. During this time, decision-making parameters such as the estimated project cost as well as the project environment may change. To identify the decision parameters that affect the feasibility analysis, data mining techniques are applied to analyse the Go/No Go decision-making process in infrastructure projects. The data mining analysis uses PFS data obtained from large-scale infrastructure projects in Korea. Classification models found 57 hidden rules in the PFS. Prediction models were also developed for Go/No Go decision making using an artificial neural network (ANN) and logistic regression analysis. In order to validate the results, the study evaluated the accuracies and errors of both the classification and the prediction model. Journal: Construction Management and Economics Pages: 73-87 Issue: 1 Volume: 27 Year: 2009 Keywords: Data mining, feasibility, infrastructure, forecasting, X-DOI: 10.1080/01446190802596246 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802596246 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:1:p:73-87 Template-Type: ReDIF-Article 1.0 Author-Name: Divine Kwaku Ahadzie Author-X-Name-First: Divine Kwaku Author-X-Name-Last: Ahadzie Author-Name: David Proverbs Author-X-Name-First: David Author-X-Name-Last: Proverbs Author-Name: Paul Olomolaiye Author-X-Name-First: Paul Author-X-Name-Last: Olomolaiye Author-Name: N. Ankrah Author-X-Name-First: N. Author-X-Name-Last: Ankrah Title: Towards developing competency-based measures for project managers in mass house building projects in developing countries Abstract: Within the human resource management (HRM) genre, the identification and development of appropriate competency-based measures is widely seen as the only viable means for validating and engendering managerial best practices. A competency-based conceptual model is proposed towards the development of a taxonomy of project managers' (PMs') performance measures in mass house building projects (MHBPs). The model reflects elements of both performance behaviours and outcomes in predicting the performance of PMs at the construction phase of the project life cycle. Data were elicited from members of the Ghana Real Estate Developers Association (GREDA), whose speciality is the construction of residential buildings, to test the validity of this conceptual model. The findings, which confirm the validity of the model, demonstrate the suitability and potential usefulness of this model for developing a competency-based agenda towards the professional development of PMs involved in the implementation of MHBPs in developing countries, like Ghana. The model could, therefore, form the basis for curriculum development, recruitment and selection, team deployment and job matching, career development and succession planning to facilitate the achievement of managerial best practices in MHBPs. Journal: Construction Management and Economics Pages: 89-102 Issue: 1 Volume: 27 Year: 2009 Keywords: Competency-based measures, developing countries, Ghana, project managers, mass house building projects, X-DOI: 10.1080/01446190802621028 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802621028 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:1:p:89-102 Template-Type: ReDIF-Article 1.0 Author-Name: Yehiel Rosenfeld Author-X-Name-First: Yehiel Author-X-Name-Last: Rosenfeld Title: Cost of quality versus cost of non-quality in construction: the crucial balance Abstract: The research is a pioneering attempt to determine the optimal level of investment in quality by construction companies. The methodology is based on quantifying the four types of quality-related costs in residential construction, and relates them to each other by expressing them all as percentages of the relevant total construction revenues (revenues to the company due to construction, excluding land, etc.). The findings reaffirm, on the one hand, that investing in quality is a worthy strategy and that, in the situations examined, the ratio of the direct benefits to the investment (in terms of savings on internal and external failures) is at least 2:1. On the other hand, the findings also show that an excess of quality costs (prevention and appraisal) is wasteful. Above a certain level of investment, the extra benefits are marginal, and thus do not offset the extra costs. Statistically fitted graphs, based on actual quantitative data, support this hypothesis, and provide approximate boundaries of effective versus ineffective investments in quality. In this study, the optimal range lies between 2% and 4% of the company's revenue. Investing less than 2% in prevention and appraisal will definitely entail higher failure costs, whereas an investment of over 4% most probably will not pay itself back. Journal: Construction Management and Economics Pages: 107-117 Issue: 2 Volume: 27 Year: 2009 Keywords: Quality, cost of quality, quality assurance, X-DOI: 10.1080/01446190802651744 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802651744 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:2:p:107-117 Template-Type: ReDIF-Article 1.0 Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Author-Name: Shamas-Ur-Rehman Toor Author-X-Name-First: Shamas-Ur-Rehman Author-X-Name-Last: Toor Title: Research on cross-cultural leadership and management in construction: a review and directions for future research Abstract: A great volume of cross-cultural research has been undertaken during the past two decades. Although the interaction among participants and organizations from different cultures is one of the most complex issues evident on large construction projects, there is not much cross-cultural research in the context of the construction industry. An overview of cross-cultural research in the social sciences and management studies is presented and some of the recent conceptual and methodological advances are highlighted. Studies on cross-cultural research in construction are then summarized. A number of conceptual and methodological issues are highlighted that deserve more attention in future research in construction. Among these is the need for a more interdisciplinary and interactionist perspective to unearth the complexity of cross-cultural issues. Research in construction should move beyond the conventional models to try more challenging approaches. This calls for the development of comprehensive research frameworks which can derive benefits from the methodologies being applied, and advances being made in cross-cultural research. Journal: Construction Management and Economics Pages: 119-133 Issue: 2 Volume: 27 Year: 2009 Keywords: Cross-cultural research, construction industry, leadership, management, future research, X-DOI: 10.1080/01446190802616937 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802616937 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:2:p:119-133 Template-Type: ReDIF-Article 1.0 Author-Name: Henk-Jan van Mossel Author-X-Name-First: Henk-Jan Author-X-Name-Last: van Mossel Author-Name: Ad Straub Author-X-Name-First: Ad Author-X-Name-Last: Straub Title: The need for customizing maintenance services in social housing Abstract: Market segmentation theory is based on the notion that although customers are unique they may be grouped into relatively homogeneous categories which respond in a certain manner to the supplier's marketing efforts. Despite the lack of commercial necessity for the Dutch social rented sector in meeting the demands of tenants, public objectives do compel housing associations to be efficient and effective in maintenance spending. Through customization of maintenance service delivery, the match between users' expectations and the results of maintenance may be improved. Given the limited body of knowledge with respect to preferences of target groups in maintenance of dwellings a post hoc approach is used for this purpose. A large-scale survey was conducted among tenants of large housing associations in the Netherlands. By means of respectively principal component and cluster analyses, customer segments were given shape. Profiling of these segments was achieved through ANOVA and chi-square analyses. There seem to be grounds for housing associations to differentiate, to a limited degree, in their maintenance (purchasing) policy. This, however, always depends on the applicable strategic objectives of the housing association in question. Journal: Construction Management and Economics Pages: 135-151 Issue: 2 Volume: 27 Year: 2009 Keywords: Maintenance, service quality, cluster analysis, housing associations, X-DOI: 10.1080/01446190802695766 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802695766 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:2:p:135-151 Template-Type: ReDIF-Article 1.0 Author-Name: Abukar Warsame Author-X-Name-First: Abukar Author-X-Name-Last: Warsame Title: Organizational modes in the residential building sector in Sweden Abstract: Traditional organizational studies emphasize department groupings and the management style of different organizations that are often based on common tasks, products, geography and processes. They also mainly emphasize the connection between construction supply chain and procurement methods but have not analysed of how external factors shape the organization structure and consequently the supply chain. Three things are analysed: the impact of competitive pressure, required competence and degree of flexibility on various modes of construction organization used for producing multi-family residential housing in Sweden from a transaction cost theory perspective. Organization structures depend on the level of project engagement, competence demanded by the preferred organization mode as well as the economic environment, and the level of construction activities. Journal: Construction Management and Economics Pages: 153-163 Issue: 2 Volume: 27 Year: 2009 Keywords: Organization structure, flexibility, risk allocation, competition, competence, X-DOI: 10.1080/01446190802699503 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802699503 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:2:p:153-163 Template-Type: ReDIF-Article 1.0 Author-Name: S. Thomas Ng Author-X-Name-First: S. Thomas Author-X-Name-Last: Ng Author-Name: Ryan Fan Author-X-Name-First: Ryan Author-X-Name-Last: Fan Author-Name: James Wong Author-X-Name-First: James Author-X-Name-Last: Wong Author-Name: Albert Chan Author-X-Name-First: Albert Author-X-Name-Last: Chan Author-Name: Y. H. Chiang Author-X-Name-First: Y. H. Author-X-Name-Last: Chiang Author-Name: Patrick Lam Author-X-Name-First: Patrick Author-X-Name-Last: Lam Author-Name: Mohan Kumaraswamy Author-X-Name-First: Mohan Author-X-Name-Last: Kumaraswamy Title: Coping with structural change in construction: experiences gained from advanced economies Abstract: As an economy approaches maturity, the relative importance of the construction sector would gradually decline. Without effective policies and strategies, the construction industry will suffer irreversably and this may trigger a knock-on effect to the overall economy. The experiences of selected advanced economies are examined, including Australia, Japan, Singapore, South Korea and the UK in coping with structural changes in construction. Strategies employed by the government and the construction industry of these advanced economies to reinvent the construction industry were captured through an extensive literature review and a series of interviews with indigenous industry practitioners. In order to revitalize the construction industry, governments would accelerate publicly funded projects; provide financial support to ease the burden of industry stakeholders; and stimulate the market demand. In contrast, the industry would explore various market alternatives while companies would sharpen their competitive advantage locally and internationally through merger and acquisition. The identified strategies are corresponded to a construction industry development framework, which could therefore serve as a valuable reference for policy makers and practitioners to rejuvenate construction demand when a country approaches an urban service economy. Journal: Construction Management and Economics Pages: 165-180 Issue: 2 Volume: 27 Year: 2009 Keywords: Construction industry, advanced economies, recession, recovery, strategy, X-DOI: 10.1080/01446190802699040 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802699040 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:2:p:165-180 Template-Type: ReDIF-Article 1.0 Author-Name: Herbert Robinson Author-X-Name-First: Herbert Author-X-Name-Last: Robinson Author-Name: Jon Scott Author-X-Name-First: Jon Author-X-Name-Last: Scott Title: Service delivery and performance monitoring in PFI/PPP projects Abstract: Value for money in a PFI project depends crucially on performance monitoring to provide incentives for improvement and to ensure that service delivery is in accordance with the output specification. However, the effectiveness of performance monitoring and output specification cannot be fully assessed until PFI projects become operational. There is a need to examine the role of the performance monitoring mechanism in ensuring that 'value for money' is achieved throughout the delivery of services. Based on semi-structured interviews with key stakeholders from the public and private sectors, the case studies suggest that there are low levels of performance deductions in PFI projects during the operational phase. However, the complexity of performance measurement, inadequate resources for performance monitoring and the difficulties in the interpretation of the output specification raise questions as to whether the low level of deductions truly reflect the actual level of services delivered. There is also evidence of the public sector forgoing entitled deductions in the 'spirit of partnership' and in exchange for minor contract variations in the output specification. Both the public and private sectors are undergoing a learning process which should lead to improvements in future PFI contracts. Journal: Construction Management and Economics Pages: 181-197 Issue: 2 Volume: 27 Year: 2009 Keywords: Service delivery, performance monitoring, output specification, PFI/PPP projects, X-DOI: 10.1080/01446190802614163 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802614163 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:2:p:181-197 Template-Type: ReDIF-Article 1.0 Author-Name: Ashraf Elazouni Author-X-Name-First: Ashraf Author-X-Name-Last: Elazouni Title: Heuristic method for multi-project finance-based scheduling Abstract: A heuristic method is proposed for scheduling multiple projects subject to cash constraints. The heuristic determines cash availability during a given period, identifies all possible activities' schedules, determines the cash requirements for each schedule, ranks schedules based on the contribution to minimizing the increase in the project duration, schedules all activities of the selected schedule and determines the impact of the scheduled activities on the project cash flow. The effectiveness of the heuristic method was validated by comparing the results with the optimum results obtained by using the integer programming (IP) technique for 15 networks comprising up to 60 activities. The comparison indicated that the solutions obtained using the proposed heuristic are very comparable to the optimum solutions. An example of two concurrent projects was presented to demonstrate the proposed heuristic method. The proposed heuristic offers the ultimate flexibility to enter cash outflows and inflows at the actual occurrence time, the ability to rationalize the scheduling process, the flexibility to either devise or update schedules, and the ability to schedule practical-size multiple projects. Finally, this heuristic can be easily coded in software to help managers schedule projects under finance-constrained conditions. Journal: Construction Management and Economics Pages: 199-211 Issue: 2 Volume: 27 Year: 2009 Keywords: Cash flow management, construction finance, financial management, heuristic, scheduling, X-DOI: 10.1080/01446190802673110 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802673110 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:2:p:199-211 Template-Type: ReDIF-Article 1.0 Author-Name: Eddie Chi-Man Hui Author-X-Name-First: Eddie Chi-Man Author-X-Name-Last: Hui Author-Name: Hankel Hon-Kwok Fung Author-X-Name-First: Hankel Hon-Kwok Author-X-Name-Last: Fung Title: Real estate development as real options Abstract: One of the recent advances in property valuation is to view a property or the right to develop it as a call option. Shilling et al. (1985) were among the first to apply option pricing theory in this way. For real estate development, although not explicitly said so in his paper, Titman (1985) was the first to treat vacant lots of land as options to wait to develop. A frequently cited paper by Quigg (1993) presents the first empirical effort to support the real option pricing point of view. The valuation framework of Quigg (1993) is in one sense a specialization and in another sense a generalization of the framework of Williams (1991). Unfortunately, the works of both Williams and Quigg are technically flawed, but surprisingly their errors have gone unnoticed for over 15 years and are still propagating in the literature (e.g. in Yamaguchi et al., 2000 and Patel and Paxson, 2001). In the following, we will first address the flaws of Quigg (1993). Then we will examine the problems in Williams' (1991) work. Finally, we will discuss some implications of the Williams-Quigg valuation framework. Journal: Construction Management and Economics Pages: 221-227 Issue: 3 Volume: 27 Year: 2009 Keywords: Real estate, real options, X-DOI: 10.1080/01446190902759017 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902759017 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:3:p:221-227 Template-Type: ReDIF-Article 1.0 Author-Name: Symeon Christodoulou Author-X-Name-First: Symeon Author-X-Name-Last: Christodoulou Author-Name: Georgios Ellinas Author-X-Name-First: Georgios Author-X-Name-Last: Ellinas Author-Name: Pooyan Aslani Author-X-Name-First: Pooyan Author-X-Name-Last: Aslani Title: Disorder considerations in resource-constrained scheduling Abstract: A method is presented for allocating resources to construction activities and for scheduling construction projects under resource constraints by considering the effects that such resource limitations may have on the tendency of the activities (and the project in general) to fall into disarray and behind schedule. Resource-constrained scheduling problems (RCSP) are very common in real-life construction projects and because of their nature their numerical solution is computationally intensive. The method utilizes a measure of each activity's perceived level of disorder stemming from resource limitations. The proposed technique aims to optimize the number of resources assigned to the activities and to schedule the project so as to minimize the overall project's tendency to fall into disorder. The entropy-like metric used in the scheduling optimization is related to the ratio of required over-assigned resource units per activity, and its utilization allows a planner to take into consideration project disorder when planning a project. A case study and its mathematical framework help demonstrate the 'duration vs. disorder' trade-off analysis that planners should perform when considering possible activity resource assignments and the feasibility of these assignments in terms of induced disorder. The entropy optimization method proves to be a powerful project-planning metric. Journal: Construction Management and Economics Pages: 229-240 Issue: 3 Volume: 27 Year: 2009 Keywords: Resource allocation, resource-constrained scheduling, project planning, entropy, X-DOI: 10.1080/01446190802635416 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802635416 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:3:p:229-240 Template-Type: ReDIF-Article 1.0 Author-Name: Thaveeporn Pulket Author-X-Name-First: Thaveeporn Author-X-Name-Last: Pulket Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Title: Construction litigation prediction system using ant colony optimization Abstract: The frequency of construction litigation has increased over the years, making litigation a costly and time-consuming activity. It is in the interests of all parties to a construction contract to avoid litigation. A tool (Ant Miner) is proposed to predict the outcome of construction litigation, hence encouraging the parties to settle out of court. Ant Miner, a rule-based classification system extracts classification rules by using ant colony optimization. It is used on 151 Illinois circuit court cases filed in the period 1987-2005. The prediction model is composed of data consolidation, attribute selection, classification and assessment. The results provide evidence that Ant Miner performs better than models used in earlier studies and that the rule sets discovered by this tool are highly interpretable, but that this tool suffers a great deal from noisy data. If the parties involved in a dispute have access to the proposed system that predicts the decision of the courts with higher accuracy and reliability than before, then they are expected to avoid litigation and settle out of court in order to save considerable time, money and aggravation. Journal: Construction Management and Economics Pages: 241-251 Issue: 3 Volume: 27 Year: 2009 Keywords: Ant colony algorithm, artificial intelligence, case-based reasoning, decision trees, litigation, neural networks, X-DOI: 10.1080/01446190802714781 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802714781 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:3:p:241-251 Template-Type: ReDIF-Article 1.0 Author-Name: Jingfeng Yuan Author-X-Name-First: Jingfeng Author-X-Name-Last: Yuan Author-Name: Alex Yajun Zeng Author-X-Name-First: Alex Yajun Author-X-Name-Last: Zeng Author-Name: Miroslaw Skibniewski Author-X-Name-First: Miroslaw Author-X-Name-Last: Skibniewski Author-Name: Qiming Li Author-X-Name-First: Qiming Author-X-Name-Last: Li Title: Selection of performance objectives and key performance indicators in public-private partnership projects to achieve value for money Abstract: Public-private partnerships (PPPs) have been applied widely in the global construction market. During the life cycle of PPP projects, their performance could be affected by a number of factors and their interactions, which might cause the inefficiency and ineffectiveness of the projects. Previous researches on PPPs mainly concentrated on the procurement, success measurement and risk management of PPPs, but paid little attention to the process factors that can strongly influence the performance of PPPs. In order to improve process and performance management in PPPs, the performance objectives and key performance indicators (KPIs) are identified to improve the partnership outcomes. Based on the goal-setting theory, 15 performance objectives are selected. The relative significance and difference of performance objectives for different stakeholders are presented based on a structured questionnaire survey. The survey results show that all identified objectives are important. In spite of stakeholders' common opinions on the objectives of quality, costs, time and the services provided by PPPs, there are evident differences in the objectives of budget constraints of the public sector, risks, revenue and guarantees. According to the survey results, a conceptual KPIs framework is established. Furthermore, the KPIs are identified to assess PPP projects' performance. The performance objectives and the KPIs, which can be used to identify the strengths and weaknesses of PPP projects, are useful tools for effective project performance management in PPPs. Journal: Construction Management and Economics Pages: 253-270 Issue: 3 Volume: 27 Year: 2009 Keywords: Public-private partnership (PPP), key performance indicators (KPIs), performance management, value for money, X-DOI: 10.1080/01446190902748705 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902748705 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:3:p:253-270 Template-Type: ReDIF-Article 1.0 Author-Name: Roine Leiringer Author-X-Name-First: Roine Author-X-Name-Last: Leiringer Author-Name: Stuart Green Author-X-Name-First: Stuart Author-X-Name-Last: Green Author-Name: Jawwad Raja Author-X-Name-First: Jawwad Author-X-Name-Last: Raja Title: Living up to the value agenda: the empirical realities of through-life value creation in construction Abstract: Current research agendas are increasingly encouraging the construction industry to operate on the basis of 'added value'. Such debates echo the established concept of 'high value manufacturing' and associated trends towards servitization. Within construction, the so-called 'value agenda' draws heavily from the notion of integrated solutions. This is held to be especially appropriate in the context of PFI projects. Also relevant is the concept of service-led projects whereby the project rationale is driven by the client's objectives for delivering an enhanced service to its own customers. Such ideas are contextualized by a consideration of broader trends of privatization and outsourcing within and across the construction industry's client base. The current emphasis on integrated solutions reflects long-term trends within privatized client organizations towards the outsourcing of asset management capabilities. However, such trends are by no means uniform or consistent. An in-depth case study of three operating divisions within a major construction company illustrates that firms are unlikely to reorientate their business in response to the 'value agenda'. In the case of PFI, the tendency has been to establish specialist units for the purposes of winning work. Meanwhile, institutionally embedded operating routines within the rest of the business remain broadly unaffected. Journal: Construction Management and Economics Pages: 271-285 Issue: 3 Volume: 27 Year: 2009 Keywords: Servitization, integrated solutions, PFI, value, outsourcing, X-DOI: 10.1080/01446190802699032 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190802699032 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:3:p:271-285 Template-Type: ReDIF-Article 1.0 Author-Name: Yunyan Andrea Jia Author-X-Name-First: Yunyan Andrea Author-X-Name-Last: Jia Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Author-Name: Thomas Kvan Author-X-Name-First: Thomas Author-X-Name-Last: Kvan Author-Name: Helen Clare Lingard Author-X-Name-First: Helen Clare Author-X-Name-Last: Lingard Author-Name: Brenda Yip Author-X-Name-First: Brenda Author-X-Name-Last: Yip Title: Burnout among Hong Kong Chinese architecture students: the paradoxical effect of Confucian conformity values Abstract: Burnout is a multidimensional indicator of people's psychological relationship with their job, the opposite end of which is engagement. Culture's impact on students' burnout is investigated by examining the burnout level of Hong Kong Chinese architecture students and its correlation with Confucian conformity values, the dominant societal cultural values in Confucian-Heritage-Cultures (CHC)1 society. Two hundred and ninety-four students enrolled in Bachelor and Master programmes in architecture from two Hong Kong universities participated in the study. The Chinese version of Maslach Burnout Inventory-Student Survey and a seven-item conformity scale taken from the Schwartz Value Survey were employed to measure burnout and conformity values. Conformity values were found to be positively correlated with the EX dimension of burnout, negatively correlated with the CY (doubt significance) and the IE dimension of burnout, and not correlated with the CY (lose interest) dimension of burnout. The paradoxical effect of conformity values suggests that burnout is more than an individual phenomenon. Rather, it is a systematic problem rooted in the inconsistencies between the social culture in which the individual students are immersed and the learning culture of the architectural schools to which students are trying to adapt. Without an understanding of the contextual inconsistency, the burnout dilemma seems to be certain. The organizers of the architecture curriculum are urged to take students' social cultural context into account and address cultural diversity in their programmes. Journal: Construction Management and Economics Pages: 287-298 Issue: 3 Volume: 27 Year: 2009 Keywords: Architecture student, burnout, conformity values, Confucian-Heritage-Cultures, X-DOI: 10.1080/01446190902736296 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902736296 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:3:p:287-298 Template-Type: ReDIF-Article 1.0 Author-Name: Shamas-Ur-Rehman Toor Author-X-Name-First: Shamas-Ur-Rehman Author-X-Name-Last: Toor Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Title: Authenticity and its influence on psychological well-being and contingent self-esteem of leaders in Singapore construction sector Abstract: 'Authentic leadership' has emerged as an important subject in the management science literature. Although several scholars have presented their viewpoints about authenticity and authentic leadership, there is scarcity of empirical evidence on what leaders can really gain from being authentic. The results of the questionnaire-based survey with 32 leaders suggest that authenticity is significantly correlated with psychological well-being and negatively correlated with contingent self-esteem. Regression analysis also shows that authenticity successfully predicts psychological well-being. These findings indicate that authenticity results in healthy psychological functioning of leaders and hence several positive work-related outcomes. Journal: Construction Management and Economics Pages: 299-313 Issue: 3 Volume: 27 Year: 2009 Keywords: Authenticity, authentic leadership, psychological well-being, contingent self-esteem, Singapore, X-DOI: 10.1080/01446190902729721 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902729721 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:3:p:299-313 Template-Type: ReDIF-Article 1.0 Author-Name: S. Ping Ho Author-X-Name-First: S. Author-X-Name-Last: Ping Ho Author-Name: Yi-Hsin Lin Author-X-Name-First: Yi-Hsin Author-X-Name-Last: Lin Author-Name: Hsueh-Liang Wu Author-X-Name-First: Hsueh-Liang Author-X-Name-Last: Wu Author-Name: Wenyi Chu Author-X-Name-First: Wenyi Author-X-Name-Last: Chu Title: Empirical test of a model for organizational governance structure choices in construction joint ventures Abstract: In the construction industry, joint ventures (JVs) have become one of the major organizational forms utilized in large-scale and international projects. Because of the complexity of JVs, the management of JVs is much more difficult than that of usual projects. Among various management challenges, the choice of organizational governance structure has a profound impact on JV success. A model for governance structure choices in construction JVs (CJVs) is tested. The governance structure model focuses on four major factors, namely, corporate cultural difference, trust, needs for procurement autonomy and motivation for learning, and is expressed in terms of four propositions, which are tested. We conclude from the econometric analysis results that the four model variables together explain about 53% of the variation of governance structure choices. Most important, all the four model propositions are strongly supported by the econometric analysis results and the sign of each coefficient is consistent with that in each proposition. Overall, the governance structure model is well supported by statistical testing, which complements previous case-study-based evidence. Journal: Construction Management and Economics Pages: 315-324 Issue: 3 Volume: 27 Year: 2009 Keywords: Joint venture, organizational design, strategic management, governance structure, econometric analysis, X-DOI: 10.1080/01446190902725588 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902725588 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:3:p:315-324 Template-Type: ReDIF-Article 1.0 Author-Name: Jicai Liu Author-X-Name-First: Jicai Author-X-Name-Last: Liu Author-Name: Charles Cheah Author-X-Name-First: Charles Author-X-Name-Last: Cheah Title: Real option application in PPP/PFI project negotiation Abstract: Over the past two decades, many developing countries have grown to become more familiar with the notions and the use of public-private partnership/private financing initiative (PPP/PFI) schemes in building large-scale infrastructure assets. However, owing to higher levels of complexity and longer contractual durations, PPP/PFI projects are often embedded with higher risks. On the one hand, any private sector concessionaire would strive to secure some forms of subsidies or guarantees from the host government to alleviate its risk concerns. On the other hand, the host government would also attempt to counterbalance the grant of these incentives by introducing additional 'repayment' obligations, such as placement of a cap on the tariff or toll rates. Modelled as real options, support and repayment features found in the case of a wastewater treatment plant in Southern China are evaluated using a combination of Monte Carlo simulation and spreadsheet-based cash flow models. The objective is to illustrate how a negotiation band incorporating these option values can be constructed, which would enlarge the feasible bargaining range for both parties. The risk implications of two disparate bidding scenarios found in the case will also be discussed. Journal: Construction Management and Economics Pages: 331-342 Issue: 4 Volume: 27 Year: 2009 Keywords: Concession, negotiation, real option, public-private partnerships, private finance initiative, X-DOI: 10.1080/01446190902807071 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902807071 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:4:p:331-342 Template-Type: ReDIF-Article 1.0 Author-Name: Konelio Tone Author-X-Name-First: Konelio Author-X-Name-Last: Tone Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Johnny Kwok Wai Wong Author-X-Name-First: Johnny Kwok Wai Author-X-Name-Last: Wong Title: An investigation of the impact of cross-cultural communication on the management of construction projects in Samoa Abstract: Communication problems have emerged as one of the most significant contemporary challenges facing construction project managers in an increasingly international construction market. However, little research has investigated the impact of cross-cultural communication (CCC) on management systems in this context. The key problems of CCC and their impact for construction project management systems in Samoa are investigated via a questionnaire survey of 41 project managers to solicit their views and experiences concerning the impact of human and cultural influences on project management and CCC evaluation processes in Samoa. Also provided are the results of a series of interviews with 32 practitioners and key stakeholders concerning the key barriers to effective communication, and suggested strategies and proactive measures for improving the CCC in Samoa. The findings highlight the need for cultural sensitivity when designing an inter-organizational communication strategy for the management of international projects. An organization also needs to have a global perspective if it is involved in the international construction market, and be willing to modify communication strategies that are appropriate within the context of host cultures. A strong link is established between changes in perspectives as a result of experiences and the impact of CCC on project management systems. Journal: Construction Management and Economics Pages: 343-361 Issue: 4 Volume: 27 Year: 2009 Keywords: Communication, culture, international project, project management, Samoa, X-DOI: 10.1080/01446190902748713 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902748713 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:4:p:343-361 Template-Type: ReDIF-Article 1.0 Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Author-Name: Weisheng Lu Author-X-Name-First: Weisheng Author-X-Name-Last: Lu Author-Name: Ting Huang Author-X-Name-First: Ting Author-X-Name-Last: Huang Title: Rethinking project management and exploring virtual design and construction as a potential solution Abstract: The construction sector is facing widespread criticism of its low efficiency and poor performance. This has led to a rethink of contemporary project management (PM). However, current critical perspectives have failed to diagnose the practical problems existing in PM, and as a consequence, no promising solutions have been proposed. In this research, a combination of critical literature review, field works, case studies, open debates and interviews revealed five fundamentally problematic aspects of contemporary PM: (1) using artificial tools and methods; (2) cannot try before build; (3) discontinuity in construction processes; (4) ineffective information and knowledge management; and (5) creeping managerialism. These problems were then scrutinized by referring them to Virtual Design and Construction (VDC) as a potential solution. Strengths of VDC are explored, and hurdles that prevent it from gaining momentum are also evaluated. It is found that the problems of contemporary PM can largely be alleviated by the use of VDC although its many hurdles are yet to be overcome. This research provides new insights into how construction companies can adopt VDC technology to improve the problematic PM practices. Journal: Construction Management and Economics Pages: 363-371 Issue: 4 Volume: 27 Year: 2009 Keywords: Project management, virtual design and construction, X-DOI: 10.1080/01446190902838217 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902838217 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:4:p:363-371 Template-Type: ReDIF-Article 1.0 Author-Name: Odysseus George Manoliadis Author-X-Name-First: Odysseus George Author-X-Name-Last: Manoliadis Author-Name: John-Paris Pantouvakis Author-X-Name-First: John-Paris Author-X-Name-Last: Pantouvakis Author-Name: Symeon Christodoulou Author-X-Name-First: Symeon Author-X-Name-Last: Christodoulou Title: Improving qualifications-based selection by use of the fuzzy Delphi method Abstract: Among prevailing contract-awarding paradigms, the qualifications-based selection (QBS) method offers awarding agencies a substantial level of flexibility and multifactored decision-making capability over traditional cost-based paradigms (such as competitive bidding). QBS is a process used by owners to select proposers to whom they can award a project contract, based on the proposers' professional qualifications in relation to the specific project parameters. Further to being very suitable for the selection of professional engineering design services, QBS can also be applied for the selection of contractors involved in specialized construction or design-build projects. In such cases, the procurement method and the selection criteria used are critical decisions involving several key project team members and decision factors, the formulation of which requires complex evaluation methodologies. Within this context, a process is proposed by which the traditional QBS method can be improved via the utilization of a fuzzy Delphi method (FDM), a cross-mutation of the traditional Delphi method (DM) and fuzzy logic (FL). The method utilizes 'expert' appraisals to identify both the factors and their weights in the overall evaluation process through a 'fuzzy attractiveness ratio' (FAR) which is used for evaluating the bidders' suitability to task. Journal: Construction Management and Economics Pages: 373-384 Issue: 4 Volume: 27 Year: 2009 Keywords: Decision making, Delphi method, design-build, fuzzy logic, qualifications-based selection, X-DOI: 10.1080/01446190902758993 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902758993 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:4:p:373-384 Template-Type: ReDIF-Article 1.0 Author-Name: Sameh Monir El-Sayegh Author-X-Name-First: Sameh Monir Author-X-Name-Last: El-Sayegh Title: Multi-criteria decision support model for selecting the appropriate construction management at risk firm Abstract: Selecting the appropriate firm is of paramount importance especially when using a unique delivery method such as construction management at risk. In addition to general contracting services, the construction management at risk firm provides construction management services throughout the design and construction phases. A new decision support model is proposed to assist owners in the selection decision. Key selection factors were identified through a literature review. They are divided into four categories: firm characteristics; technical and commercial bid; construction management services; and general contracting services. Each consists of five selection factors. The selection criteria were determined using the analytical hierarchy process (AHP) based on a questionnaire that was sent to construction professionals. The proposed model consists of five functions: strategic alignment; selection criteria; initial screening; firms' evaluations; and sensitivity analysis. The heart of the model is the use of the AHP to develop the decision criteria and compare candidate firms. A case study is also presented to demonstrate the application of the model. Journal: Construction Management and Economics Pages: 385-398 Issue: 4 Volume: 27 Year: 2009 Keywords: Bidding, contracting, construction management at risk, decision support models, selection factors, X-DOI: 10.1080/01446190902759009 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902759009 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:4:p:385-398 Template-Type: ReDIF-Article 1.0 Author-Name: Hedley Smyth Author-X-Name-First: Hedley Author-X-Name-Last: Smyth Author-Name: Tim Fitch Author-X-Name-First: Tim Author-X-Name-Last: Fitch Title: Application of relationship marketing and management: a large contractor case study Abstract: Marketing-led enterprise change management initiated by a major UK contractor is explored in this paper as a contrast to procurement-led changes to projects driven by clients. Procurement-led initiatives try to induce changes to behaviour through market governance. Relationship marketing and management proactively change organizational behaviour, the enterprise taking responsibility for its own destiny. Investment and resource allocation, and organizational behaviour have posed constraints, particularly concerning service continuity in construction. Overcoming these constraints offers opportunities for delivering service improvements and adding value for clients and yielding further increases in repeat business and increasing profitability. Relationship marketing is the conceptual starting point, application developing into relationship management in line with theory. The main relationship marketing tenets are outlined. In the case explored key account management (KAM) principles are adopted as the conceptual point of departure for introducing relationship marketing processes. Adoption resulted in some minor restructuring and provided the basis for a series of process changes. Application is producing early results in terms of increased client satisfaction, consequential repeat business, inducing greater cross-functional communication and collaboration within the firm resulting in cross-selling opportunities between market segments. Some repeat business is producing higher margins in response to meeting demands of the clients. Journal: Construction Management and Economics Pages: 399-410 Issue: 4 Volume: 27 Year: 2009 Keywords: Change management, organizational behaviour, relationship management, relationship marketing, X-DOI: 10.1080/01446190902777365 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902777365 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:4:p:399-410 Template-Type: ReDIF-Article 1.0 Author-Name: Catherine Comet Author-X-Name-First: Catherine Author-X-Name-Last: Comet Title: Social capital and profits of small firms in the French construction industry Abstract: The profitability of small businesses in the French construction industry depends partly on their social capital. However, social capital yields advantages as well as constraints. How and under what conditions do social networks improve a company's profit margins? From a socio-technical perspective and strategic analysis, we defend the idea that return on social capital is conditioned by the nature of the tasks performed and by the interdependencies among firms. Comparing about 160 businesses from four various crafts, we show that loose networks profit relatively specialized businesses working independently on construction sites, while cohesive networks benefit those businesses that are most affected by socio-technical uncertainties. Journal: Construction Management and Economics Pages: 411-418 Issue: 4 Volume: 27 Year: 2009 Keywords: Profits, network analysis, SMEs, strategic analysis, socio-technical systems, X-DOI: 10.1080/01446190902822989 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902822989 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:4:p:411-418 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Clare Lingard Author-X-Name-First: Helen Clare Author-X-Name-Last: Lingard Author-Name: Tracy Cooke Author-X-Name-First: Tracy Author-X-Name-Last: Cooke Author-Name: Nick Blismas Author-X-Name-First: Nick Author-X-Name-Last: Blismas Title: Group-level safety climate in the Australian construction industry: within-group homogeneity and between-group differences in road construction and maintenance Abstract: In modern organizations it is overly simplistic to assume that a uniform, organization-wide climate for safety develops. Workgroup-level safety climates are more likely to arise in decentralized organizations and their influence on occupational health and safety (OHS) behaviour is likely to be stronger when work is non-routine, as in construction. The existence of workgroup-level safety climates was examined in the Australian construction industry. A group-level safety climate survey was conducted in a road maintenance and construction organization. The clear factorial structure produced in a larger sample of Australian defence logistics workers was not replicated and factors splintered, possibly due to the subject-to-item ratio in the construction study. However, the internal reliability consistency of the factors produced in the earlier pilot study was found to be acceptable for the construction industry data. Two requisite conditions for the existence of group-level safety climates, i.e. (1) within-group homogeneity; and (2) between-group variation, were satisfied within the road construction and maintenance organization. The results indicate that distinct workgroup safety climates exist in construction, providing a theoretical explanation for why some workgroups perform better in OHS than others, despite having similar risk exposure. Journal: Construction Management and Economics Pages: 419-432 Issue: 4 Volume: 27 Year: 2009 Keywords: Co-workers, group dynamics, road maintenance, safety climate, supervisory leadership, X-DOI: 10.1080/01446190902822971 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902822971 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:4:p:419-432 Template-Type: ReDIF-Article 1.0 Author-Name: Paula Gerber Author-X-Name-First: Paula Author-X-Name-Last: Gerber Title: Defective Construction Work Abstract: Journal: Construction Management and Economics Pages: 433-433 Issue: 4 Volume: 27 Year: 2009 X-DOI: 10.1080/01446190902822153 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902822153 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:4:p:433-433 Template-Type: ReDIF-Article 1.0 Author-Name: Ping Yung Author-X-Name-First: Ping Author-X-Name-Last: Yung Title: Institutional arrangements and construction safety in China: an empirical examination Abstract: Previous studies merely attempted to identify factors affecting safety performance from the micro perspective of project management, while they never questioned why those factors, such as lack of the top-management support and training, existed. A macro perspective, informed by the corollary of the Coase Theorem, was adopted here to show that suitable institutional arrangements are essential for better safety performance in a construction industry. Province-level construction safety records in China from 1994 to 2000 were used to test the effects of institutional arrangements on construction safety in China. Major factors affecting construction safety were found to be the implementation of construction safety laws, the rate of subcontracting, while neither the extent of using temporary workers, nor the availability of resources, nor the level of per capita GDP have any effects. Journal: Construction Management and Economics Pages: 439-450 Issue: 5 Volume: 27 Year: 2009 Keywords: Safety, Coase Theorem, institutional arrangements, farmer worker, subcontracting, X-DOI: 10.1080/01446190902855633 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902855633 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:5:p:439-450 Template-Type: ReDIF-Article 1.0 Author-Name: Pernilla Gluch Author-X-Name-First: Pernilla Author-X-Name-Last: Gluch Author-Name: Mathias Gustafsson Author-X-Name-First: Mathias Author-X-Name-Last: Gustafsson Author-Name: Liane Thuvander Author-X-Name-First: Liane Author-X-Name-Last: Thuvander Title: An absorptive capacity model for green innovation and performance in the construction industry Abstract: Applying the model of absorptive capacity (ACAP), antecedents, predictors and moderators for green innovation and performance in the construction industry are investigated. The aim is to identify mechanisms that influence green innovation and environmental performance in a construction company. Data come from a questionnaire survey assessing environmental attitudes, management and performance within the Swedish construction industry. For data analysis, linear regression analysis was used. From testing the ACAP theory and model, it was concluded that it has a promising potential in explaining mechanisms behind green innovation and performance. The application of ACAP has resulted in a revised ACAP model, green ACAP. Findings indicate that organizations can affect their capacity to absorb green innovations and improve their business performance by focusing on three predictors of green business advantage: acquisition, assimilation and transformation. As such, the green ACAP can serve as a framework for focused efforts within the construction industry. Journal: Construction Management and Economics Pages: 451-464 Issue: 5 Volume: 27 Year: 2009 Keywords: Innovation, sustainable development, absorptive capacity, construction industry, survey, regression analysis, X-DOI: 10.1080/01446190902896645 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902896645 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:5:p:451-464 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Fox Author-X-Name-First: Stephen Author-X-Name-Last: Fox Title: Applying critical realism to information and communication technologies: a case study Abstract: Critical realism is a philosophy of science which has been developed as an alternative to positivism and interpretivism. It has been argued that critical realism should be applied to research concerned with information and communication technologies (ICTs). In particular, it has been argued that critical realism can increase understanding of causal mechanisms and contexts that are needed in order to achieve outcomes from actions. However, there is a lack of examples of how critical realism might be applied in practice. The aim of the research was to investigate the potential for practical application of critical realism to research concerned with ICTs. Four interrelated examples are presented from practical application of critical realism during ICT research. These are examples of causal mechanism, technological context, social context and business context. Findings suggest that practical application of critical realism to ICT research in AECO may be possible without any particular training or extensive prior knowledge. Journal: Construction Management and Economics Pages: 465-472 Issue: 5 Volume: 27 Year: 2009 Keywords: Technology management, information and communication technology, X-DOI: 10.1080/01446190902842292 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902842292 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:5:p:465-472 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Morgan Tuuli Author-X-Name-First: Martin Morgan Author-X-Name-Last: Tuuli Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Title: Empowerment in project teams: a multilevel examination of the job performance implications Abstract: An integrative multilevel model of empowerment and job performance behaviours is advanced, building on social cognitive theory (SCT). Empowerment climate is hypothesized as influencing individual and team performance behaviours directly and partially through individual and team (psychological) empowerment. Using survey responses from 380 individuals, nested in 115 project management teams, we tested the direct, indirect and cross-level relationships delineated in the multilevel model, using a combination of OLS regression models and hierarchical linear modelling (HLM). Empowerment climate positively related not only directly to both task and contextual performance behaviours but partially through both individual and team empowerment. At the team level, empowerment climate also positively related directly to taskwork and teamwork behaviours and partially through team empowerment. The results suggest that empowerment climate and psychological empowerment play complementary roles in engendering individual and team performance behaviours and are therefore not mutually exclusive. The findings are also evident of convergence in management practices across cultures as well as different work contexts and further provide concrete targets of manipulation by organizations and leaders desirous of empowering individuals and teams in the project context. Journal: Construction Management and Economics Pages: 473-498 Issue: 5 Volume: 27 Year: 2009 Keywords: Empowerment climate, hierarchical linear modelling (HLM), job performance behaviours, psychological empowerment, social cognitive theory (SCT), X-DOI: 10.1080/01446190902729713 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902729713 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:5:p:473-498 Template-Type: ReDIF-Article 1.0 Author-Name: Llewellyn Tang Author-X-Name-First: Llewellyn Author-X-Name-Last: Tang Author-Name: Andrew Leung Author-X-Name-First: Andrew Author-X-Name-Last: Leung Title: An entropy-based financial decision support system (e-FDSS) for project analysis in construction SMEs Abstract: Uncertainty contributes a major part in the accuracy of a decision-making process while its inconsistency is always difficult to be solved by existing decision-making tools. Entropy has been proved to be useful to evaluate the inconsistency of uncertainty among different respondents. The study demonstrates an entropy-based financial decision support system called e-FDSS. This integrated system provides decision support to evaluate attributes (funding options and multiple risks) available in projects. Fuzzy logic theory is included in the system to deal with the qualitative aspect of these options and risks. An adaptive genetic algorithm (AGA) is also employed to solve the decision algorithm in the system in order to provide optimal and consistent rates to these attributes. Seven simplified and parallel projects from a Hong Kong construction small and medium enterprise (SME) were assessed to evaluate the system. The result shows that the system calculates risk adjusted discount rates (RADR) of projects in an objective way. These rates discount project cash flow impartially. Inconsistency of uncertainty is also successfully evaluated by the use of the entropy method. Finally, the system identifies the favourable funding options that are managed by a scheme called SME Loan Guarantee Scheme (SGS). Based on these results, resource allocation could then be optimized and the best time to start a new project could also be identified throughout the overall project life cycle. Journal: Construction Management and Economics Pages: 499-513 Issue: 5 Volume: 27 Year: 2009 Keywords: Decision support system, entropy, fuzzy logic, genetic algorithm, project management, X-DOI: 10.1080/01446190902883049 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902883049 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:5:p:499-513 Template-Type: ReDIF-Article 1.0 Author-Name: Jan Brochner Author-X-Name-First: Jan Author-X-Name-Last: Brochner Title: Construction metaphors in Aristotle: knowledge, purpose, process Abstract: Writers on construction management have begun showing an interest in Aristotle's views on ethics, leadership, metaphysics and change, although overlooking that he frequently resorted to construction metaphors. This investigation shows that 16 of his writings contain about 140 construction metaphors and about 370 occurrences of construction terms. Metaphysics, Nicomachean Ethics and Physics provide more than half of these metaphors. For Aristotle, the process of house building is both knowledge driven and purpose driven: the building is to be a shelter against the elements, and the builder has to consider this ultimate goal for every step of production when choosing tools and materials. Builders learn the art of building by building; when they enjoy their work, they will go on improving. Building users can judge whether a building is good or bad, not builders. That Aristotle's metaphysics are object oriented and that practical wisdom is prominent in his ethics appear as irrelevant to construction, which was the typical example of managed production in his time. Journal: Construction Management and Economics Pages: 515-523 Issue: 5 Volume: 27 Year: 2009 Keywords: Construction management, construction process, learning, ethics, ancient construction, X-DOI: 10.1080/01446190902915643 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902915643 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:5:p:515-523 Template-Type: ReDIF-Article 1.0 Author-Name: Djoen San Santoso Author-X-Name-First: Djoen San Author-X-Name-Last: Santoso Title: The construction site as a multicultural workplace: a perspective of minority migrant workers in Brunei Abstract: Construction projects have become progressively multicultural, especially for countries with limited labour force where there is need to depend on migrant workers. This multicultural environment can easily create problems related to unfair treatment or discrimination. Focus group discussions were conducted with migrant workers from Indonesia and Thailand to examine factors directly and indirectly related to construction activities that need to be considered in a diverse nationality construction site, with a focus on the minority group. The study suggested that communication, wage segmentation, task assignment and trust, scapegoatism, and belief and religion are the important aspects needing to be carefully taken into account to have a constructive working and living environment in a multicultural project. Management should not overlook the above factors to avoid disenfranchizing minority workers. Journal: Construction Management and Economics Pages: 529-537 Issue: 6 Volume: 27 Year: 2009 Keywords: Discrimination, motivation, labour relations, culture, minorities, X-DOI: 10.1080/01446190902960482 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902960482 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:6:p:529-537 Template-Type: ReDIF-Article 1.0 Author-Name: Ellen Lau Author-X-Name-First: Ellen Author-X-Name-Last: Lau Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Title: Interpersonal trust and inter-firm trust in construction projects Abstract: Working relationships are important in effecting project performance and cooperation is believed to be a behavioural consequence of trust. Trust, being a quality of relationships, involves people interacting at interpersonal and inter-firm levels. This is investigated through 10 partnering and non-partnering projects, using a validated trust scale. A case study approach is used to collect qualitative data through a quantitative approach to help understand the concept of trust. Data were collected from clients, contractors, consultants and subcontractors. Clients and contractors have a tendency to trust individuals whereas contractors and subcontractors have a tendency to trust firms. Inter-firm trust is better understood than interpersonal trust; but both are associated with keeping commitments and demonstrating cooperation, even though interpersonal trust is considered more important. Partnering does not necessarily exhibit more trust than non-partnering projects whereas clients and contractors have different emphasis on interpersonal and inter-firm trust. Therefore, to promote trusting relationships in multi-parties is to fulfil not only the technological and economical goals, but also the moral and social goals as expressed in people relationships such that a socially safe working place can be created. For this reason, middle managers need to know about trust because they face more relationship problems than others. Journal: Construction Management and Economics Pages: 539-554 Issue: 6 Volume: 27 Year: 2009 Keywords: Interpersonal trust, inter-firm trust, relationship, partnering, project, X-DOI: 10.1080/01446190903003886 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903003886 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:6:p:539-554 Template-Type: ReDIF-Article 1.0 Author-Name: Linda Clarke Author-X-Name-First: Linda Author-X-Name-Last: Clarke Author-Name: Marc van der Meer Author-X-Name-First: Marc Author-X-Name-Last: van der Meer Author-Name: Cecilie Bingham Author-X-Name-First: Cecilie Author-X-Name-Last: Bingham Author-Name: Elisabeth Michielsens Author-X-Name-First: Elisabeth Author-X-Name-Last: Michielsens Author-Name: Sue Miller Author-X-Name-First: Sue Author-X-Name-Last: Miller Title: Enabling and disabling: disability in the British and Dutch construction sectors Abstract: Though the British and Dutch approaches to disability in the construction sector exhibit common features, Britain tends towards a capabilities model compared with the Netherlands which is closer to a social model. The construction sector is considerably more regulated in the Netherlands but is in both countries highly disabling and exclusive. Sector-specific disabling and enabling factors and policy measures were investigated in the two countries with a view to identifying which policies might facilitate labour market participation. The investigation was based on interviews using similar questionnaires with key stakeholders, firms and disabled employees and a focus group. Policy in each country addresses the nature of exclusion in different ways. The conclusion drawn is that a sector-specific approach is needed if disability policy in Britain is to be more in tune with the social model—as apparent from the comparison with the Netherlands. Journal: Construction Management and Economics Pages: 555-566 Issue: 6 Volume: 27 Year: 2009 Keywords: Disability, health and safety, UK, Netherlands, discrimination, policy, X-DOI: 10.1080/01446190902977445 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902977445 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:6:p:555-566 Template-Type: ReDIF-Article 1.0 Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Author-Name: Vera Li Author-X-Name-First: Vera Author-X-Name-Last: Li Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Johnny Kwok Wai Wong Author-X-Name-First: Johnny Kwok Wai Author-X-Name-Last: Wong Author-Name: Eddie Cheng Author-X-Name-First: Eddie Author-X-Name-Last: Cheng Title: Competitiveness factors: a study of the real estate market in China Abstract: The execution of 'macro-adjustment' policies by the central government to cool down the overheated real estate market in the past few years has created an unfavourable operating environment for real estate developers in Mainland China. Developers need to rethink their business model and create a new form of competitive advantage in order to survive. Despite this, research into the factors that influence the competitiveness of the real estate market in China has been limited. Therefore, a survey of 58 real estate practitioners, experts and academics in China was conducted to probe opinion on the factors that influence competitiveness in real estate firms in China. Survey results suggest that the developer's financial competency, market coverage and management competencies are vital to its competitiveness. Findings also highlight the importance of industry recognition/award, share in different types of property sales/development projects, profit after tax, growth rate of their securities price, and diversification of R&D in reflecting the competitiveness of real estate developers in China. The findings provide an insight into the factors that influence competitiveness in China's real estate market and also assist practitioners to formulate competitiveness improvement strategies. Journal: Construction Management and Economics Pages: 567-579 Issue: 6 Volume: 27 Year: 2009 Keywords: Competitiveness, real estate market, developer, China, X-DOI: 10.1080/01446190903005865 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903005865 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:6:p:567-579 Template-Type: ReDIF-Article 1.0 Author-Name: Yu-Lin Huang Author-X-Name-First: Yu-Lin Author-X-Name-Last: Huang Title: Prediction of contractor default probability using structural models of credit risk: an empirical investigation Abstract: Structural models of credit risk can apply for quantitatively predicting contractor defaults and pricing performance guarantees. However, the application involves crucial empirical issues. Some of the empirical issues are investigated using market and accounting data of public construction firms in Taiwan. Statistical analyses are conducted using the Wilcoxon rank sum test, Shumway's discrete-time hazard model, and the receiver operating characteristic curve. Structural models are viable, and market value tends to dominate other measures of economic or financial distress in terms of prediction accuracy. However, when calibrated to minimize Type I and Type II errors, the default boundary of market value produces substantial residual errors. In addition, the calibrated boundary is at 151% of face debt, much higher than those suggested by previous empirical studies. This seems to reflect the idiosyncratic short-term debt structures of Taiwanese construction firms. Leland and Toft's model is recommended for further investigations, because their theory explains the higher than expected calibrated boundary. Journal: Construction Management and Economics Pages: 581-596 Issue: 6 Volume: 27 Year: 2009 Keywords: Contractor default, probability, prediction, structural model, regression analysis, ROC curve, X-DOI: 10.1080/01446190902960474 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902960474 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:6:p:581-596 Template-Type: ReDIF-Article 1.0 Author-Name: Arjan Walraven Author-X-Name-First: Arjan Author-X-Name-Last: Walraven Author-Name: Bauke de Vries Author-X-Name-First: Bauke Author-X-Name-Last: de Vries Title: From demand driven contractor selection towards value driven contractor selection Abstract: The procurement of a construction contractor should consider more aspects than only cost or price. Taking value and price into account to select the 'best value for money' bid results in adopting a structured multi-criteria approach. An alternative contractor selection method is presented, which identifies the contractor with the best potential to deliver the highest value for money. An investigation of the client needs and product performances for contractor selection has been conducted for a building type, and the relative weight of each product performance is analysed through a questionnaire. The relative weights of the product performances are identified by allocating a fictional budget to the client needs and translating these values into the relative weight of the product performances by using the quality function deployment method. In the contractor selection method, the relative importance of the product performances are combined with the scores of the bids, resulting in the best bid and contractor in a specific building project. Journal: Construction Management and Economics Pages: 597-604 Issue: 6 Volume: 27 Year: 2009 Keywords: Procurement, contractor selection, multi-criteria selection, tendering, quality function deployment, value, X-DOI: 10.1080/01446190902933356 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902933356 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:6:p:597-604 Template-Type: ReDIF-Article 1.0 Author-Name: Richard Fellows Author-X-Name-First: Richard Author-X-Name-Last: Fellows Title: Advanced Research Methods in the Built Environment Abstract: Journal: Construction Management and Economics Pages: 605-609 Issue: 6 Volume: 27 Year: 2009 X-DOI: 10.1080/01446190902896637 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902896637 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:6:p:605-609 Template-Type: ReDIF-Article 1.0 Author-Name: Roine Leiringer Author-X-Name-First: Roine Author-X-Name-Last: Leiringer Title: Policy, Management and Finance for Public-Private Partnerships Abstract: Journal: Construction Management and Economics Pages: 609-610 Issue: 6 Volume: 27 Year: 2009 X-DOI: 10.1080/01446190902912301 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902912301 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:6:p:609-610 Template-Type: ReDIF-Article 1.0 Author-Name: Michael Garvin Author-X-Name-First: Michael Author-X-Name-Last: Garvin Title: Procurement Systems: A Cross-Industry Project Management Perspective Abstract: Journal: Construction Management and Economics Pages: 610-611 Issue: 6 Volume: 27 Year: 2009 X-DOI: 10.1080/01446190902954139 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902954139 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:6:p:610-611 Template-Type: ReDIF-Article 1.0 Author-Name: Ifte Choudhury Author-X-Name-First: Ifte Author-X-Name-Last: Choudhury Title: The effect of political unrest on construction time for food grain warehouses in Bangladesh Abstract: A range of poorly understood factors affect actual construction time in the context of food sector projects in Bangladesh. One factor of particular interest is political unrest. The data for this study were obtained from a leading design and construction management company in Bangladesh. The sample size consisted of data for 104 food grain warehouse projects scattered all over the country. The effect of political unrest on construction time was analysed in conjunction with other known variables for actual construction time, such as increase in project cost and delay in procurement of construction materials. The effect of local political unrest on construction time was statistically significant even in the presence of project cost and procurement of materials variables. Political unrest could be included in prediction models used for finding out actual construction time of food grain warehouse projects in Bangladesh. Based on these findings, a prediction model for construction time for such projects is developed. Journal: Construction Management and Economics Pages: 619-624 Issue: 7 Volume: 27 Year: 2009 Keywords: Bangladesh, cost, developing country, political unrest, X-DOI: 10.1080/01446190903009099 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903009099 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:7:p:619-624 Template-Type: ReDIF-Article 1.0 Author-Name: Ophir Rozenfeld Author-X-Name-First: Ophir Author-X-Name-Last: Rozenfeld Author-Name: Rafael Sacks Author-X-Name-First: Rafael Author-X-Name-Last: Sacks Author-Name: Yehiel Rosenfeld Author-X-Name-First: Yehiel Author-X-Name-Last: Rosenfeld Title: 'CHASTE': construction hazard assessment with spatial and temporal exposure Abstract: CHASTE—'Construction Hazard Assessment with Spatial and Temporal Exposure'—is a conceptual model that enables forecasting of safety risks in construction projects for different trades, at appropriate levels of detail and reliability for different planning windows and managerial purposes, in a highly automated fashion. Unlike earlier models, CHASTE explicitly accounts for the fact that construction workers are frequently endangered by activities performed by teams other than their own. The risks to which workers are exposed change through time, as the activities performed and the physical environment of construction sites change. CHASTE uses a knowledge base of construction activities and probabilities of loss-of-control events, coupled with a project's construction plan and a digital building model, to forecast risk levels for work teams. It has been implemented in prototype software and tested on two projects. Journal: Construction Management and Economics Pages: 625-638 Issue: 7 Volume: 27 Year: 2009 Keywords: Construction safety, safety management, lean construction, risk analysis, X-DOI: 10.1080/01446190903002771 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903002771 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:7:p:625-638 Template-Type: ReDIF-Article 1.0 Author-Name: Noël Houthoofd Author-X-Name-First: Noël Author-X-Name-Last: Houthoofd Title: Business definition and performance implications: the case of the Belgian construction sector Abstract: Business definition (either explicitly or implicitly defined) matters in the construction sector in Belgium. A business is a three-dimensional 'strategic space' within an industry, defined by the buyer types targeted, product types sold and geographical reach. The research setting is one of family owned small non-diversified firms in the construction industry. The sample consists of 61 firms. Data on these firms were gathered for the year 2006. Firms with a similar business definition within the construction sector were clustered. Three clusters could be delineated: residential, non-residential and a civil engineering business. Performance differs between the three businesses. Performance was measured with perceptions on sales, sales growth, gross sales margin and return on invested capital. Perceived performance correlated with financial performance. Competitive forces differ according to the business. Firms in the civil engineering sector working for government agencies performed best. Journal: Construction Management and Economics Pages: 639-652 Issue: 7 Volume: 27 Year: 2009 Keywords: Business definition, business domain choice, construction sector, performance differences, X-DOI: 10.1080/01446190903029543 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903029543 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:7:p:639-652 Template-Type: ReDIF-Article 1.0 Author-Name: Yu-Lin Huang Author-X-Name-First: Yu-Lin Author-X-Name-Last: Huang Author-Name: Chai-Chi Pi Author-X-Name-First: Chai-Chi Author-X-Name-Last: Pi Title: Valuation of multi-stage BOT projects involving dedicated asset investments: a sequential compound option approach Abstract: The valuation of multi-stage build-operate-transfer projects is not a trivial task. It needs to deal with uncertain project values in future expansions and the possibility of expansions or abandonment in the presence of project risks. The valuation problem becomes more difficult when multi-stage projects require upfront and intermediate dedicated asset investments for future expansions. Dedicated asset investments may or may not create project values, depending on whether future expansions could be justified and realized. A sequential compound option model is proposed to tackle these important valuation issues. Journal: Construction Management and Economics Pages: 653-666 Issue: 7 Volume: 27 Year: 2009 Keywords: Valuation, build-operate-transfer, X-DOI: 10.1080/01446190903002789 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903002789 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:7:p:653-666 Template-Type: ReDIF-Article 1.0 Author-Name: Helena Johnsson Author-X-Name-First: Helena Author-X-Name-Last: Johnsson Author-Name: John Henrik Meiling Author-X-Name-First: John Henrik Author-X-Name-Last: Meiling Title: Defects in offsite construction: timber module prefabrication Abstract: The construction industry is based on craftsmanship. Quality control and assurance procedures applied in manufacturing cannot usually be readily applied in construction, where there are higher degrees of uniqueness in each project. One category of companies, industrialized housebuilders, is attempting to bridge some of the gaps between construction and manufacturing. These companies prefabricate building modules for later assembly at the building site. Since they are wholly responsible for large parts of the building process, these companies have greater opportunities to control and improve quality in a more consistent way than ordinary construction companies. Thus, it could be hypothesized that the frequency and severity of defects should be lower in industrialized housing than in ordinary construction. The aim of the study presented here is to examine this hypothesis by measuring and characterizing defects in industrialized housing. The design and manufacturing processes at two Swedish timber module prefabrication firms has been analysed through interviews, site visits and document reviews. Quality audits from three phases of the building process were compiled, analysed and categorized to provide statistical measures of defects in industrialized housing. The results show that the case study companies are better in terms of product quality than conventional housing. Journal: Construction Management and Economics Pages: 667-681 Issue: 7 Volume: 27 Year: 2009 Keywords: Building defects, offsite production, quality management, industrialized housing, modular construction, X-DOI: 10.1080/01446190903002797 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903002797 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:7:p:667-681 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Sexton Author-X-Name-First: Martin Author-X-Name-Last: Sexton Author-Name: Shu-Ling Lu Author-X-Name-First: Shu-Ling Author-X-Name-Last: Lu Title: The challenges of creating actionable knowledge: an action research perspective Abstract: Academia has a critical role in developing new knowledge which construction industry practitioners need to envision, undertake and sustain successful innovation. The new knowledge produced by academia, however, often does not satisfy the needs of practitioners. This unsatisfactory state of affairs is frequently taken to be the consequence of the cultural, motivational and operational differences between the two communities. Actionable knowledge is presented as a useful concept which can fuse the expectations, contributions and outputs of academia and practitioners. Within this context, action research is argued to be an appropriate methodology to develop successful actionable knowledge. Results from an action research project are given which provide researchers and practitioners greater understanding of the key factors that shape the degree to which action research produces actionable knowledge: change focus, collaboration capabilities and systematic process. The criteria intrinsic to Mode 2 research (Gibbons et al., 1994) are demonstrated to have utility in evidencing actionable knowledge. The implication for policy is that there is a need to develop and use appropriate actionable knowledge frameworks and measures to design funding calls, and to evaluate research proposals and outputs. Journal: Construction Management and Economics Pages: 683-694 Issue: 7 Volume: 27 Year: 2009 Keywords: Actionable knowledge, action research, Mode 2 knowledge production, X-DOI: 10.1080/01446190903037702 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903037702 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:7:p:683-694 Template-Type: ReDIF-Article 1.0 Author-Name: Lena Elisabeth Bygballe Author-X-Name-First: Lena Elisabeth Author-X-Name-Last: Bygballe Author-Name: Marianne Jahre Author-X-Name-First: Marianne Author-X-Name-Last: Jahre Title: Balancing value creating logics in construction Abstract: Construction companies apply different logics to create value. Some companies are organized according to one primary logic, while others are based on multiple logics. Different value creating logics have different cost and value drivers according to the type of activities involved and the interdependencies between them. Where multiple logics coexist, the different cost and value drivers may generate tensions. The purpose of the paper is to study how construction companies maintain a balance between multiple logics and how they handle tensions between them through a case study from the Norwegian construction industry. Both project management and supply chain management perspectives have been used to explain construction practice. By applying a 'value configuration analysis', it is clear how value creation is achieved in construction practice by balancing the needs of both the project and the supply chain. Both intra- and inter-organizational interactions are vital in creating value across different logics. The contribution of the study lies in applying this framework to the construction area by adding knowledge about the underlying principles of different logics, including the tensions between them. Furthermore, the case study illustrates how these may be handled in order to create value in construction. Journal: Construction Management and Economics Pages: 695-704 Issue: 7 Volume: 27 Year: 2009 Keywords: Norway, value creating logics, interdependence, case study, interaction, X-DOI: 10.1080/01446190903096609 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903096609 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:7:p:695-704 Template-Type: ReDIF-Article 1.0 Author-Name: Joseph Tah Author-X-Name-First: Joseph Author-X-Name-Last: Tah Title: Implementing IT in Construction Abstract: Journal: Construction Management and Economics Pages: 705-706 Issue: 7 Volume: 27 Year: 2009 X-DOI: 10.1080/01446190902933349 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902933349 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:7:p:705-706 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Sexton Author-X-Name-First: Martin Author-X-Name-Last: Sexton Title: Book reviews Abstract: Journal: Construction Management and Economics Pages: 707-707 Issue: 7 Volume: 27 Year: 2009 X-DOI: 10.1080/01446190902992923 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902992923 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:7:p:707-707 Template-Type: ReDIF-Article 1.0 Author-Name: Hans Voordijk Author-X-Name-First: Hans Author-X-Name-Last: Voordijk Title: Construction management and economics: the epistemology of a multidisciplinary design science Abstract: Research in the field of construction management and economics (CME) can be characterized as a multidisciplinary design science. Results from the sciences and humanities are necessary inputs for this field of research that deals with design, production and operation of the built environment. The output of CME research as multidisciplinary design science consists of three types of solution concepts: empirical generalizations based on statistical data analysis (technological laws), concepts that specify what to do, if a certain result is to be attained under given circumstances (functional rules), and insights in the interrelationship between design, production and operation of the built environment and social practice (socio-technological understanding). Scientific justification of these solution concepts is obtained through testing them in the specific context of the built environment. Journal: Construction Management and Economics Pages: 713-720 Issue: 8 Volume: 27 Year: 2009 Keywords: Epistemology, knowledge production, design science, X-DOI: 10.1080/01446190903117777 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903117777 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:8:p:713-720 Template-Type: ReDIF-Article 1.0 Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Author-Name: Ranon Chotibhongs Author-X-Name-First: Ranon Author-X-Name-Last: Chotibhongs Title: Detection and prevention of unbalanced bids Abstract: Unbalanced bidding is a serious problem for the construction owner because it may increase the cost of construction The most common way to mathematically unbalance a bid is frontloading where a bidder overstates the unit price of line items scheduled to be performed early in the project and understates the unit price of line items performed later. A bidder can also overstate the unit price of a line item whose quantity was somehow underrated by the engineer. If the owner proves that a mathematically unbalanced bid costs more to perform, the bid is said to be materially unbalanced, in which case the owner can reject the bid. A model is presented that formalizes and automates the process of detecting mathematically and materially unbalanced bids by comparing line item prices with the engineer's estimates and the average prices offered by the bidders. This model allows owners to detect and reject unbalanced bids, and deters bidders from unbalancing their bid. Journal: Construction Management and Economics Pages: 721-732 Issue: 8 Volume: 27 Year: 2009 Keywords: Bids, mathematical models, financial management, construction costs, optimization, X-DOI: 10.1080/01446190903117785 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903117785 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:8:p:721-732 Template-Type: ReDIF-Article 1.0 Author-Name: Wen-der Yu Author-X-Name-First: Wen-der Author-X-Name-Last: Yu Author-Name: Pei-lun Chang Author-X-Name-First: Pei-lun Author-X-Name-Last: Chang Author-Name: Shuen-Ho Yao Author-X-Name-First: Shuen-Ho Author-X-Name-Last: Yao Author-Name: Shen-Jung Liu Author-X-Name-First: Shen-Jung Author-X-Name-Last: Liu Title: KVAM: model for measuring knowledge management performance of engineering community of practice Abstract: The research presents the development of the knowledge value-adding model (KVAM) for quantitative performance measurement of the community of practice (CoP) of the knowledge management system (KMS) in an A/E consulting firm. The proposed KVAM combines several existing KM theories including knowledge creation spiral, knowledge chain model, and knowledge value added theory to form a process-level model for measuring the performance of a generic community of practice (CoP). Case study results show that the proposed KVAM provides KM managers with a useful tool not only to monitor the performance of a CoP and its members but also to plan an effective strategy for performance improvement. Unlike the traditional organizational-level approaches, the proposed KVAM was concluded to better reflect the actual values solely generated by the KMS rather than other management factors. Journal: Construction Management and Economics Pages: 733-747 Issue: 8 Volume: 27 Year: 2009 Keywords: Knowledge management, community of practice, performance evaluation, engineering consulting, value-adding models, X-DOI: 10.1080/01446190903074978 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903074978 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:8:p:733-747 Template-Type: ReDIF-Article 1.0 Author-Name: Khalied Hesham Hyari Author-X-Name-First: Khalied Hesham Author-X-Name-Last: Hyari Author-Name: Khaled El-Rayes Author-X-Name-First: Khaled Author-X-Name-Last: El-Rayes Author-Name: Mohammad El-Mashaleh Author-X-Name-First: Mohammad Author-X-Name-Last: El-Mashaleh Title: Automated trade-off between time and cost in planning repetitive construction projects Abstract: An automated model is developed to support the optimization of the planning and scheduling of repetitive construction projects. The model provides the capability of optimizing two important objectives commonly sought in scheduling repetitive construction projects: minimizing project duration; and minimizing project cost. The model performs this multi-objective optimization using a genetic algorithm approach. The output of the model is a set of optimal solutions that represent the trade-off between time and cost in planning repetitive construction projects. Furthermore, the model can be utilized to find a single scheduling solution that provides the minimum overall project cost by simply adding project indirect cost to the obtained project direct cost for each of the obtained scheduling solutions on the Pareto optimal curve. Other important time-related costs are also considered in the model including: early completion incentives, late completion penalties and lane rental costs. Providing the planners of repetitive construction projects with an automated set of optimal time-cost trade-off solutions should contribute to cost-effective and speedy delivery of this type of construction project. An application example is analysed to illustrate the use of the model and demonstrate its capabilities in generating optimal trade-off solutions between minimizing the project time and cost for repetitive construction projects. Journal: Construction Management and Economics Pages: 749-761 Issue: 8 Volume: 27 Year: 2009 Keywords: Repetitive construction, scheduling, genetic algorithms, optimization, resource utilization, X-DOI: 10.1080/01446190903117793 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903117793 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:8:p:749-761 Template-Type: ReDIF-Article 1.0 Author-Name: Ben Dozie Ilozor Author-X-Name-First: Ben Dozie Author-X-Name-Last: Ilozor Title: Differential management of waste by construction sectors: a case study in Michigan, USA Abstract: Waste is a great problem in the world of construction. If dealt with appropriately, there can be many benefits, including lower overall cost, faster production, a higher quality and more sustainable buildings. There are many solutions available for minimizing waste during construction. However, a great amount of waste still exists, whether in residential, commercial, industrial, infrastructural or other constructions. The purpose of this investigation is to ascertain key sources of waste, and whether generation varies with the type and size of the constructors. A sample of 30 general contractors was studied, and several null hypotheses on waste generation and minimization differences among sectors were tested using the Kruskal-Wallis H-test. Although subtle shifts were observed in the aspects of waste behaviour that seemed predicated on construction sectors and capital base, to some extent the proposition that the construction type and size can influence waste generation and minimization was validated. Based on this study, some solutions are provided as viable avenues to managing and minimizing construction waste across sectors. Journal: Construction Management and Economics Pages: 763-770 Issue: 8 Volume: 27 Year: 2009 Keywords: Construction sectors, waste management, differences, X-DOI: 10.1080/01446190903117769 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903117769 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:8:p:763-770 Template-Type: ReDIF-Article 1.0 Author-Name: Kunhee Choi Author-X-Name-First: Kunhee Author-X-Name-Last: Choi Author-Name: Eul-Bum Lee Author-X-Name-First: Eul-Bum Author-X-Name-Last: Lee Author-Name: C. William Ibbs Author-X-Name-First: C. William Author-X-Name-Last: Ibbs Author-Name: Yong-Woo Kim Author-X-Name-First: Yong-Woo Author-X-Name-Last: Kim Title: Multifaceted public outreach and cost-benefit analysis for its effectiveness validation Abstract: A heavily trafficked 4.5km highway stretch on Interstate 15 east of Los Angeles was rebuilt using two extended closures, each spanning nine days with 24/7 operations. Before and during the closures, a multifaceted, extensive, dynamic public outreach programme was implemented to gain public support for the project and to minimize inconvenience to the public. That outreach programme is described, its overall effectiveness in terms of total net benefit and traffic inconvenience during lane closures is assessed, and changes in public perception of the accelerated construction strategy resulting from the outreach programme is examined. Pre- and post-construction surveys performed using the project website mirrored the findings of the traffic measurement study, indicating that the outreach programme effectively reduced traffic demand. The results of two web-based surveys with a combined total of approximately 400 respondents indicated a dramatic change in public perception of the accelerated construction strategy. The survey results showed that strong initial objection to the accelerated project eventually became supportive of future, accelerated projects. The cost-benefit analysis showed that the additional cost of the outreach programme was outweighed by the savings achieved from reduced road user delay costs. Journal: Construction Management and Economics Pages: 771-782 Issue: 8 Volume: 27 Year: 2009 Keywords: Infrastructure management, project strategies, web-based system, cost-benefit analysis, public outreach, X-DOI: 10.1080/01446190903096591 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903096591 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:8:p:771-782 Template-Type: ReDIF-Article 1.0 Author-Name: Amy Nicole Javernick-Will Author-X-Name-First: Amy Nicole Author-X-Name-Last: Javernick-Will Title: Organizational learning during internationalization: acquiring local institutional knowledge Abstract: Organizational learning plays an important role for firms entering new international markets. Acquiring knowledge of a foreign market helps firms to decrease uncertainties, misunderstandings and risks, allowing them to plan and achieve project expectations more accurately. Little is known, however, about how real estate developers, contractors and engineering firms initially collect important local knowledge for their international projects. This study uses qualitative research methods to explore the sources firms use to acquire different types of local knowledge. The results indicate that organizational learning is a complex process, and although similarities exist, different types of firms use different sources to collect needed knowledge. The research contributes to theory by responding to requests for additional research on how firms actually acquire and develop institutional knowledge. In addition, by understanding the sources used to acquire different types of institutional knowledge, company managers can determine the best sources to employ to acquire knowledge that is important for their specific business. Journal: Construction Management and Economics Pages: 783-797 Issue: 8 Volume: 27 Year: 2009 Keywords: Organizational learning, international projects, institutional theory, internationalization, knowledge management, X-DOI: 10.1080/01446190903117801 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903117801 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:8:p:783-797 Template-Type: ReDIF-Article 1.0 Author-Name: Abigail Powell Author-X-Name-First: Abigail Author-X-Name-Last: Powell Author-Name: Tarek Hassan Author-X-Name-First: Tarek Author-X-Name-Last: Hassan Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: Chris Carter Author-X-Name-First: Chris Author-X-Name-Last: Carter Title: Note: Exploring gender differences in construction research: a European perspective Abstract: Research suggests that women in academia face problematic career paths as a result of masculine cultures and horizontal segregation. At the same time, research in the construction sector has documented the barriers women face in entering and remaining in construction careers. Construction academia is investigating in this exploratory study to determine whether gender disparities found in academic research generally are valid in this field. As there is a lack of data on women in academia, particularly by sub-disciplines, scientific publication is used to explore gender differences and similarities. Publication is a significant area where gender disparities have been found in other fields and an area that can have substantial consequences for career progression in academia. The data are from a wider European study exploring women's participation in construction research and are based on secondary analysis of statistics from the ISI Web of Knowledge. Gender differences in publication are found to exist, suggesting that women are under-represented in construction research at a similar rate to women in engineering and technology academia. However, there are important differences between the different areas of construction research, which indicate that women may not face the same barriers and difficulties in all areas of construction academia. It also highlights the need for further research to investigate horizontal segregation and the gendered nature of publication, citation and collaboration in construction research. Journal: Construction Management and Economics Pages: 803-807 Issue: 9 Volume: 27 Year: 2009 Keywords: Europe, gender, publication, research, women, X-DOI: 10.1080/01446190903179736 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903179736 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:9:p:803-807 Template-Type: ReDIF-Article 1.0 Author-Name: Ignacio Castro Author-X-Name-First: Ignacio Author-X-Name-Last: Castro Author-Name: Jose Luis Galan Author-X-Name-First: Jose Luis Author-X-Name-Last: Galan Author-Name: Cristobal Casanueva Author-X-Name-First: Cristobal Author-X-Name-Last: Casanueva Title: Antecedents of construction project coalitions: a study of the Spanish construction industry Abstract: Research into the formation of alliances, relevant in the field of strategic management and especially, in the construction industry, is often explained in terms of interdependency and complementarities (exogenous factors). In contrast, the influence of a firm's social relations networks (endogenous factors) has hardly been studied at all. Thus, a model is needed that includes both exogenous and endogenous factors as antecedents to the formation of strategic alliances in the construction industry. Cooperation in the construction sector is especially frequent, above all in public works programmes, as their scale requires coalitions of different-sized firms. Accordingly, to explore how both exogenous and endogenous factors influence the formation of alliances, a social network analytical method—Multiple Regression Quadratic Assignment Procedure (MRQAP)—was applied to cooperative project coalitions in the Spanish public works construction sector from 2001-2007. Empirical findings confirm that construction companies form coalitions, principally on the basis of past alliances. Membership of business associations and groups is also a key factor, though the influence of geographic proximity is the most debatable result. In the construction industry, the formation of alliances is conditioned, among other factors, by previous social and economic relations that can generate the necessary information and trust for the selection of whichever partner is considered the most suitable for the development of the joint project. Journal: Construction Management and Economics Pages: 809-822 Issue: 9 Volume: 27 Year: 2009 Keywords: Social ties, alliances, inter-organizational relations, cooperation, X-DOI: 10.1080/01446190903117751 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903117751 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:9:p:809-822 Template-Type: ReDIF-Article 1.0 Author-Name: Boeing Singh Laishram Author-X-Name-First: Boeing Singh Author-X-Name-Last: Laishram Author-Name: Satyanaranaya Kalidindi Author-X-Name-First: Satyanaranaya Author-X-Name-Last: Kalidindi Title: Desirability rating analysis for debt financing of public-private partnership road projects Abstract: Public-private partnership (PPP) road projects are highly leveraged capital-intensive projects. Lenders, which provide the major portion of financing in the form of debt instruments, undertake loan approval processes to examine the various aspects of the projects that could influence the debt servicing capability while making credit decisions. In view of this, project sponsors could also assess beforehand how desirable is the project from the debt financing perspective in order to facilitate timely arrangement of debt financing and avoid funding problems. The Desirability Rating Analytical Tool (DRAT) has been developed in order to enable the project sponsor to assess how desirable the project is from a debt financing perspective. DRAT uses the aggregation operator Choquet fuzzy integral to aggregate the information relating to the various aspects of PPP road projects that lenders take into account while making credit decisions. The application of DRAT is illustrated with an example of a PPP road project from a National Highways Development Programme undertaken by the National Highway Authority of India, Government of India. DRAT expressed the result of the information aggregation in the form of a desirability rating profile indicating the degrees of membership to different levels of desirability. The desirability rating profiles of the project provide valuable information for decision making and can help in formulating strategies on improving the performance of the project where it is not performing satisfactorily. Journal: Construction Management and Economics Pages: 823-837 Issue: 9 Volume: 27 Year: 2009 Keywords: Decision making, public-private partnerships, fuzzy set, risk management, project finance, X-DOI: 10.1080/01446190903222387 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903222387 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:9:p:823-837 Template-Type: ReDIF-Article 1.0 Author-Name: Mohammed Mubashir Ali Author-X-Name-First: Mohammed Mubashir Author-X-Name-Last: Ali Author-Name: Ashraf Elazouni Author-X-Name-First: Ashraf Author-X-Name-Last: Elazouni Title: Finance-based CPM/LOB scheduling of projects with repetitive non-serial activities Abstract: Projects of repetitive non-serial activities constitute a major category of construction projects which can be scheduled more conveniently using the line of balance (LOB) technique. Generally, scheduling activities such that the expenditures are always in balance with the available cash is a must to devise financially feasible schedules. The objective is to integrate a CPM/LOB model for a project of repetitive non-serial activities with a cash flow model and utilize the integrated model to devise financially feasible schedules. The genetic algorithms (GAs) technique is employed to maximize the profit at the end of the project under the constraints of available cash. The optimization of the integrated models was demonstrated using an example project of 15 activities carried out at five units. The CPM/LOB model was validated against the results of a dynamic programming model in the literature and further by conducting a sensitivity analysis of the results of the integrated model. Finally, the model offers an effective financial planning tool for projects of repetitive non-serial activities. Journal: Construction Management and Economics Pages: 839-856 Issue: 9 Volume: 27 Year: 2009 Keywords: Scheduling, repetitive construction, genetic algorithms, cash flow management, line of balance, X-DOI: 10.1080/01446190903191764 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903191764 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:9:p:839-856 Template-Type: ReDIF-Article 1.0 Author-Name: Liu Shu-Shun Author-X-Name-First: Liu Author-X-Name-Last: Shu-Shun Author-Name: Kuo-Chuan Shih Author-X-Name-First: Kuo-Chuan Author-X-Name-Last: Shih Title: A framework of critical resource chain for project schedule analysis Abstract: Analysing a schedule is beneficial to help stakeholders understand the scheduled project. Project schedules, which create time plans based on the critical path method (CPM) or on resource-constrained project scheduling problem (RCPSP) optimization, are targets herein. The Theory of Constraints (TOC) treats a schedule as a system. Schedule elements are suspected constraints and a goal depends on the schedule creation policy. Resource information is further surveyed herein to identify true constraints. A framework is proposed to integrate identified constraints on a schedule, and the critical resource chain concept is introduced. Three scenarios illustrate the proposed framework under different scheduling considerations. Results explain schedule constraints, and several schedule analysis issues are discussed. Journal: Construction Management and Economics Pages: 857-869 Issue: 9 Volume: 27 Year: 2009 Keywords: Critical path method, resource-constrained project scheduling problem optimization, Theory of Constraints, resource importance, X-DOI: 10.1080/01446190903171196 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903171196 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:9:p:857-869 Template-Type: ReDIF-Article 1.0 Author-Name: Les Ruddock Author-X-Name-First: Les Author-X-Name-Last: Ruddock Author-Name: Steven Ruddock Author-X-Name-First: Steven Author-X-Name-Last: Ruddock Title: Reassessing productivity in the construction sector to reflect hidden innovation and the knowledge economy Abstract: With the development of a knowledge economy, it is reasonable to assume that the level of innovation should be particularly high and that it should have a major effect on investment and productivity across all sectors, including the construction industry. For a valid assessment of the economic performance of the construction sector in terms of its productivity, it is important that the economic benefits for the sector from technological change are properly recognized but the impact of such benefits may be 'hidden' due to measurement issues, as innovative activity and investment in intangible assets have both gone unrecognized in official statistics. Much of the innovation in the construction sector is hidden from conventional measures and, for the UK economy, there is evidence that investment in intangibles may be even greater than tangible investment, if a definition of intangible assets incorporating spending on a broad range of knowledge-based assets including organizational capital, human capital, etc. is taken. While accurate data are difficult to determine, an appraisal of the potential for utilizing existing data sources and for improved measurement is presented. Journal: Construction Management and Economics Pages: 871-879 Issue: 9 Volume: 27 Year: 2009 Keywords: Economic performance, innovation, intangible investment, knowledge economy, productivity, X-DOI: 10.1080/01446190903131166 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903131166 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:9:p:871-879 Template-Type: ReDIF-Article 1.0 Author-Name: Ivan Damnjanovic Author-X-Name-First: Ivan Author-X-Name-Last: Damnjanovic Author-Name: Xue Zhou Author-X-Name-First: Xue Author-X-Name-Last: Zhou Title: Impact of crude oil market behaviour on unit bid prices: the evidence from the highway construction sector Abstract: It is well known that the cost of highway construction is affected by the cost of crude oil. While this relationship is highly visible for construction items such as asphalt cement (a by-product in the process of refining oil), the effects of the crude oil prices on the cost of other construction items, such as concrete cement or construction operations are less direct, but equally important. For unit-based contracts without price adjustment clauses, this relationship is of a particular significance. In fact, an increase in price of fuel could result in substantial losses, as contractors are not protected. Hence, to hedge against this risk, contractors are likely to incorporate a premium in bid prices to manage project risks. The objective of this paper is to investigate the evidence of this behaviour. New evidence shows that the expected change in oil prices (the difference between future and spot price) and the implied volatility in the oil market affect the price of bid items for contracts without price adjustment clauses. Such results allow for more effective implementation of risk management on project- and programme-level basis. Journal: Construction Management and Economics Pages: 881-890 Issue: 9 Volume: 27 Year: 2009 Keywords: Unit bid cost, crude oil price, implied volatility, Extreme Bounds Analysis, X-DOI: 10.1080/01446190903171204 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903171204 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:9:p:881-890 Template-Type: ReDIF-Article 1.0 Author-Name: Udayangani Kulatunga Author-X-Name-First: Udayangani Author-X-Name-Last: Kulatunga Author-Name: Dilanthi Amaratunga Author-X-Name-First: Dilanthi Author-X-Name-Last: Amaratunga Author-Name: Richard Haigh Author-X-Name-First: Richard Author-X-Name-Last: Haigh Title: Critical success factors of construction research and development Abstract: Research and development (R&D) activities are important to the construction industry to successfully address the challenges placed upon it and to be competitive. Identifying the factors that influence the success of construction R&D activities is important as such identification would help the research team to concentrate on the most significant and influential factors and the proper management of them to enhance the performance of construction R&D activities. The critical success factors (CSFs) of construction research and development during its different phases namely initiation, conceptualization, development and launch and at the project management stage were evaluated. A questionnaire survey and a series of semi-structured interviews were used to collect the data from academic members and industrial partners who have been involved in construction R&D activities. It revealed that from the initiation to the launch of the R&D project, emphasis was placed on the stakeholders' satisfaction. In contrast, less attention was given to satisfying the researchers' requirements during the R&D project. The principal investigator's role in leading the project and providing sufficient commitment; effective monitoring and controlling of activities, having a proper dissemination plan and effective dissemination of work were also elaborated. Journal: Construction Management and Economics Pages: 891-900 Issue: 9 Volume: 27 Year: 2009 Keywords: Critical success factors, research and development, stakeholder satisfaction, X-DOI: 10.1080/01446190903186152 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903186152 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:9:p:891-900 Template-Type: ReDIF-Article 1.0 Author-Name: John Schaufelberger Author-X-Name-First: John Author-X-Name-Last: Schaufelberger Title: Life Cycle Project Management: A Systems Approach to Managing Complex Projects Abstract: Journal: Construction Management and Economics Pages: 901-901 Issue: 9 Volume: 27 Year: 2009 X-DOI: 10.1080/01446190903171188 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903171188 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:9:p:901-901 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Chan Author-X-Name-First: Paul Author-X-Name-Last: Chan Author-Name: Christine Raisanen Author-X-Name-First: Christine Author-X-Name-Last: Raisanen Title: Editorial: informality and emergence in construction Abstract: Journal: Construction Management and Economics Pages: 907-912 Issue: 10 Volume: 27 Year: 2009 X-DOI: 10.1080/01446190903361912 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903361912 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:10:p:907-912 Template-Type: ReDIF-Article 1.0 Author-Name: John Alfred Rooke Author-X-Name-First: John Alfred Author-X-Name-Last: Rooke Author-Name: Lauri Koskela Author-X-Name-First: Lauri Author-X-Name-Last: Koskela Author-Name: Mike Kagioglou Author-X-Name-First: Mike Author-X-Name-Last: Kagioglou Title: Informality in organization and research: a review and a proposal Abstract: The growing interest in informal and emergent features of organizations has accompanied changes in both the dominant forms of organization and prevailing academic views about how best to think about and research them. It is argued here that currently espoused dichotomous characterizations of both organizations and research approaches are over-simplified and misleading. A review of types of organization research is conducted and it is suggested that the relationship between theory and data collection provides a more detailed and illuminating taxonomy than a distinction between qualitative and quantitative research. Two major distinctions are proposed: (1) between theory driven and phenomenon driven research; (2) between descriptive and prescriptive theory. It is suggested that organization theory is properly prescriptive in nature. The place of informality in organization and management studies is explicated, drawing on insights from Wittgenstein and ethnomethodology (EM). A distinction is drawn between (1) the degree of formality in particular organizational settings; and (2) the necessarily informal foundations of formal organizational schemes and methods. Finally, the organization of research itself is addressed. A prescriptive theory (TFV) is suggested as a means of organizing and explaining the research process. This suggestion serves as both (1) a proposal for research management; and (2) an illustration of the relationship between theory and organization. Journal: Construction Management and Economics Pages: 913-922 Issue: 10 Volume: 27 Year: 2009 Keywords: Research methods, research policy, organization theory, organizational analysis, production process, X-DOI: 10.1080/01446190903273950 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903273950 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:10:p:913-922 Template-Type: ReDIF-Article 1.0 Author-Name: Mike Bresnen Author-X-Name-First: Mike Author-X-Name-Last: Bresnen Title: Living the dream? Understanding partnering as emergent practice Abstract: The 'practice turn' in organizational studies has recently emerged as an important set of perspectives which has implications for understanding processes of knowing and learning within and between organizations. Consisting of a range of different approaches, it emphasizes the situated nature of knowing and learning in practice and offers an alternative to understanding human action that transcends the dualism of structure and agency effects on action. The ontological and epistemological underpinnings of a practice-based approach are explored before attention is directed towards assessing the implications for understanding the knowledge, learning and change in project-based organizations associated with the emergence of partnering. Journal: Construction Management and Economics Pages: 923-933 Issue: 10 Volume: 27 Year: 2009 Keywords: Partnering, practice-based perspective, organizational learning, X-DOI: 10.1080/01446190902974145 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190902974145 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:10:p:923-933 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Barrett Author-X-Name-First: Peter Author-X-Name-Last: Barrett Author-Name: Monty Sutrisna Author-X-Name-First: Monty Author-X-Name-Last: Sutrisna Title: Methodological strategies to gain insights into informality and emergence in construction project case studies Abstract: In investigating complex situations, such as construction projects, the case study approach has been considered reliable to capture rich information for the purpose of the investigation by allowing the investigators to retain the holistic and meaningful characteristics of real-life events. Subsequent to data capture, data analysis will take place according to the intended research methodology. However, there is a potential for certain information to be hidden within the data and diluted during this data analysis phase. In order to minimize this and to reveal informal aspects and freshly emerging themes from the case study data, it is proposed that there is great value in analysing case studies on various levels, through different phases using multiple methods. Examples of the outcomes of applying multiple analyses involving different approaches, such as grounded theory methodology, rich picture diagrams and cognitive mapping, to the same set of data from multiple case studies are presented and discussed. This application of multiple analyses to case study research of construction projects provides valuable insights by revealing informal aspects and stimulating the emergence of a fresh understanding of the processes and interactions among different stakeholders. From the findings, the limits of the formal management systems were revealed. Further, the limits of tacit understanding around an evolving shared vision for a project were found to be substantial dimensions in understanding construction projects in a more holistic way. Journal: Construction Management and Economics Pages: 935-948 Issue: 10 Volume: 27 Year: 2009 Keywords: Case study, cognitive mapping, construction projects, emergence, grounded theory methodology, informality, rich picture diagrams, X-DOI: 10.1080/01446190903273943 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903273943 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:10:p:935-948 Template-Type: ReDIF-Article 1.0 Author-Name: Charlotte Baarts Author-X-Name-First: Charlotte Author-X-Name-Last: Baarts Title: Collective individualism: the informal and emergent dynamics of practising safety in a high-risk work environment Abstract: Safety knowledge appears to be 'a doing'. In construction work safety is practised in the complex interrelationship between the individual, pair and gang. Thus the aim is to explore the nature and scope of individualist and collectivist preferences pertaining to the practice of safety at a construction site. An ethnographic fieldwork, in which the researcher worked as an apprentice, will provide detailed and experience-near insights into the complexity of these processes. Findings show that individualist and collectivist preferences influence the amount of risk the individual worker will assume and expose workmates to. Aspects such as self-regulation, self-confidence and independence are acceptable values only to the extent that they do not pose a threat to the solidarity of the community or safety of other workers. The informal practice of safety is a tight-rope act that involves balancing the form and scope of these preferences. Journal: Construction Management and Economics Pages: 949-957 Issue: 10 Volume: 27 Year: 2009 Keywords: Collectivism, ethnography, individualism, safety, teamwork, X-DOI: 10.1080/01446190903147501 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903147501 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:10:p:949-957 Template-Type: ReDIF-Article 1.0 Author-Name: Pernilla Gluch Author-X-Name-First: Pernilla Author-X-Name-Last: Gluch Title: Unfolding roles and identities of professionals in construction projects: exploring the informality of practices Abstract: Using a practice lens perspective, the environmental professional's role is examined in relation to social practices in construction projects. Drawing on several case studies of environmental management, the findings show that contradictory practices prevent environmental professionals from fulfilling their expected role and function. Different world-views and communication cultures as well as a perception of environmental management as bureaucratic nit-picking, create tensions between environmental work and project practice. Dealing with these tensions, environmental professionals develop alternative identities to adapt to the different situations that they find themselves in, i.e. formal roles in accordance with their job description and informal roles to suit different project practices. However, this strategy seems to result in further fragmentation between existing practices, creating barriers between professions. The study reveals four aspects that affect the professional's role: relational and positional power, professional identity, visibility, and the facilitation of meaning-making processes in the project context. The research approach taken has created an opportunity to closely follow the development of an emerging profession in construction, opening a window that allows connecting a local and situational context to a wider societal discourse of environmentalism. Journal: Construction Management and Economics Pages: 959-968 Issue: 10 Volume: 27 Year: 2009 Keywords: Social practice, professionals, environmental management, roles, practice-based research, X-DOI: 10.1080/01446190903179728 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903179728 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:10:p:959-968 Template-Type: ReDIF-Article 1.0 Author-Name: Susse Georg Author-X-Name-First: Susse Author-X-Name-Last: Georg Author-Name: Kjell Tryggestad Author-X-Name-First: Kjell Author-X-Name-Last: Tryggestad Title: On the emergence of roles in construction: the qualculative role of project management Abstract: Within construction, roles are generally thought of in terms of a division of labour, tasks and responsibilities, established through contractual and/or cultural relations. Moreover, roles are also presumed to be relatively stable. Drawing upon actor network theory, roles are re-conceptualized and it is argued that roles are emergent and that they depend upon the tools and devices with which the project managers are equipped. A case study of the construction of a skyscraper, the 'Turning Torso', in Malmo, Sweden highlights the hybrid role of project management. In some instances project management may act as a mediator having qualitative effects on the project while in other instances project management may only be an intermediary, merely speeding up the process by conveying the concerns of others. The concept of qualculative project management is introduced to account for this emerging hybrid role. The analysis shows the ways in which the budget and other devices participates in enacting a qualculative role for project management, while simultaneously being involved in negotiating boundaries between professional roles in construction as well as the qualitative and quantitative properties of the building. Journal: Construction Management and Economics Pages: 969-981 Issue: 10 Volume: 27 Year: 2009 Keywords: Roles, emergence, construction process, project management, budgeting, X-DOI: 10.1080/01446190903181096 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903181096 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:10:p:969-981 Template-Type: ReDIF-Article 1.0 Author-Name: Christopher Gorse Author-X-Name-First: Christopher Author-X-Name-Last: Gorse Author-Name: Stephen Emmitt Author-X-Name-First: Stephen Author-X-Name-Last: Emmitt Title: Informal interaction in construction progress meetings Abstract: The small amount of published research into construction project meetings demonstrates some of the principal difficulties of investigating such sensitive business environments. Using the Bales Interaction Process Analysis (IPA) research method, data on group interaction were collected. A project outcome, namely whether the project was within contract budget, was used as a basis of enquiry between interaction patterns. Analysis was concerned with the socio-emotional (relationship building) and the task-based components of communication and the positive and negative socio-emotional interaction characteristics. Socio-emotional interaction was found to be significantly greater in the projects completed within budget. Socio-emotional interaction is used to express feelings in relation to tasks and it serves as the flux that creates and sustains the group's social framework, which is crucial in a project environment. The data provide an indication of the importance of informal communication in the maintenance of relationships within project meetings. Journal: Construction Management and Economics Pages: 983-993 Issue: 10 Volume: 27 Year: 2009 Keywords: Interpersonal communication, interaction, meetings, project success, X-DOI: 10.1080/01446190903179710 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903179710 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:10:p:983-993 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Title: Tacit knowledge in rock construction work: a study and a critique of the use of the term Abstract: Tacit knowledge is one of the perennial issues of discussion in both the knowledge management and construction management literature. Being by definition that which cannot be properly explained in existing operative vocabularies, tacit knowledge is a residual category in prescribed analytical frameworks in the knowledge management literature. However, knowledge that is not easily explained verbally or in written form plays a decisive role in the construction industry. For instance, in the case of rock construction work, the most skilled construction workers are capable of carrying out certain procedures without fully mastering accompanying operative vocabularies, thereby demonstrating the capacity to use what has been called aesthetic knowledge, a specific form of tacit knowledge recognizing the limits of verbal and written communication. Aesthetic knowledge is an emergent competence residing in everyday practices and is therefore capable of transcending operative vocabularies. In practical terms, both managers and practitioners should pay attention to the importance of tacit knowledge and aesthetic knowledge and construction companies should seek to provide arenas where tacit and aesthetic knowledge should be shared effectively. Journal: Construction Management and Economics Pages: 995-1003 Issue: 10 Volume: 27 Year: 2009 Keywords: Tacit knowledge, rock construction work, aesthetic knowledge, X-DOI: 10.1080/01446190903236379 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903236379 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:10:p:995-1003 Template-Type: ReDIF-Article 1.0 Author-Name: Chung-Chin Kao Author-X-Name-First: Chung-Chin Author-X-Name-Last: Kao Author-Name: Stuart Green Author-X-Name-First: Stuart Author-X-Name-Last: Green Author-Name: Graeme Larsen Author-X-Name-First: Graeme Author-X-Name-Last: Larsen Title: Emergent discourses of construction competitiveness: localized learning and embeddedness Abstract: Research is described that sought to understand how senior managers within regional contracting firms conceptualize and enact competitiveness. Existing formal discourses of construction competitiveness include the discourse of 'best practice' and the various theories of competitiveness as routinely mobilized within the academic literature. Such discourses consistently underplay the influence of contextual factors in shaping how competitiveness is enacted. An alternative discourse of competitiveness is outlined based on the concepts of localized learning and embeddedness. Two case studies of regional construction firms provide new insights into the emergent discourses of construction competitiveness. The empirical findings resonate strongly with the concepts of localized learning and embeddedness. The case studies illustrate the importance of de-centralized structures which enable multiple business units to become embedded within localized markets. A significant degree of autonomy is essential to facilitate localized entrepreneurial behaviour. In essence, sustained competitiveness was found to depend upon the extent to which de-centralized business units enact ongoing processes of localized learning. Once local business units have become embedded within localized markets the essential challenge is how to encourage continued entrepreneurial behaviour while maintaining a degree of centralized control and coordination. Of key importance is the recognition that the capabilities that make companies competitive transcend organizational boundaries such that they become situated within complex networks of relational ties. Journal: Construction Management and Economics Pages: 1005-1017 Issue: 10 Volume: 27 Year: 2009 Keywords: Competitiveness, contractor, case study, discourse, embeddedness, localized learning, X-DOI: 10.1080/01446190903273935 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903273935 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:10:p:1005-1017 Template-Type: ReDIF-Article 1.0 Author-Name: Shu-Shun Liu Author-X-Name-First: Shu-Shun Author-X-Name-Last: Liu Author-Name: Chang-Jung Wang Author-X-Name-First: Chang-Jung Author-X-Name-Last: Wang Title: Two-stage profit optimization model for linear scheduling problems considering cash flow Abstract: Linear projects with repetitive activity in units are considered for investigation, and a two-stage profit optimization model for linear scheduling problems using constraint programming (CP) is proposed. To maintain work continuity for repetitive activities, interruption time and crew availability are addressed, and the optimization process is presented as follows: (1) optimizing the primary objective (project profit); (2) minimizing total interruption time, given the optimized value of the primary objective. Repetitive activities incur batches of budget expenditure according to activity implementation time. Cash flow and financial elements are therefore integrated into the optimization model. Owing to flexible CP techniques, contractors' requirements, such as credit limit and payment conditions, can be integrated simply into the model formulation for practical use. Lastly, a bridge example is adopted, with various constraints such as duration limitation, for scenario analysis. Consequently, the two-stage optimization process optimizes project profit, and also maximizes work continuity for linear scheduling problems. Journal: Construction Management and Economics Pages: 1023-1037 Issue: 11 Volume: 27 Year: 2009 Keywords: Two-stage profit optimization, linear scheduling problems, cash flow, constraint programming, X-DOI: 10.1080/01446190903233111 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903233111 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:11:p:1023-1037 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Anthony Bowen Author-X-Name-First: Paul Anthony Author-X-Name-Last: Bowen Author-Name: Peter Edwards Author-X-Name-First: Peter Author-X-Name-Last: Edwards Author-Name: Keith Cattell Author-X-Name-First: Keith Author-X-Name-Last: Cattell Title: Value management practice in South Africa: the built environment professions compared Abstract: Using an online survey, value management practice by construction professionals in South Africa is investigated. Opinions were sought from architects, engineers, quantity surveyors, and project and construction managers. An objective is to test the UK-based assertion of Kelly et al. (2004) that VM is an established service with commonly understood tools, techniques and styles. While awareness of VM is reasonably prevalent among the professions, it is far less so among architects. Actual practice of VM is considerably less extensive, with the architects reporting the lowest level of usage. Much higher levels of awareness and practice could have been expected. Knowledge of VM techniques appears dated, and membership of VM associations is rare. Usage of VM is invariably founded on a cost-minimization driver. Little attempt is made to benchmark VM activities against international standards nor is a standard methodology employed. Value management is not generally used to facilitate the client briefing process. The findings are important given the increasing globalization of construction services, especially the growth of international ties between built environment professionals. It is recommended that the professional associations that promote the activities of the professions in SA should organize suitable refresher skills and training opportunities in VM. Journal: Construction Management and Economics Pages: 1039-1057 Issue: 11 Volume: 27 Year: 2009 Keywords: Value management, built environment professionals, quantity surveyors, engineers, project and construction managers, architects, professional practice, South Africa, X-DOI: 10.1080/01446190903280435 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903280435 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:11:p:1039-1057 Template-Type: ReDIF-Article 1.0 Author-Name: David James Bryde Author-X-Name-First: David James Author-X-Name-Last: Bryde Author-Name: Jurgen Marc Volm Author-X-Name-First: Jurgen Marc Author-X-Name-Last: Volm Title: Perceptions of owners in German construction projects: congruence with project risk theory Abstract: The construction industry is a major user of formal project risk management practices, yet risk is often dealt with inadequately, which is a contributory factor to poor performance. Conceptual developments propose a holistic view of risk incorporating threats and opportunities and the management of uncertainty. To optimize a risk management process there needs to be a reflection of this holistic view in management practice. A key project participant is the owner and understanding the perceptions of project risk of construction owners is an important step in assessing the degree to which practices reflect theory. Semi-structured interviews were conducted with 10 practitioners in German construction owner organizations to explore their perceptions of project risk. The results showed no common definition of project risk and a general belief that risk equated to threat. Some owners did manage opportunities and saw a link between threats and opportunities, yet this practice seemed more the result of experience than an awareness that it was an integral part of a theoretical risk management framework. Most owners perceived risk to encompass uncertainty and the sources of uncertainty perceived as most important were those linked to a longer timescale, such as the ability to let out buildings. Journal: Construction Management and Economics Pages: 1059-1071 Issue: 11 Volume: 27 Year: 2009 Keywords: Project management, risk management, owner, interview, Germany, risk perceptions, X-DOI: 10.1080/01446190903222403 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903222403 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:11:p:1059-1071 Template-Type: ReDIF-Article 1.0 Author-Name: Chung-Li Tseng Author-X-Name-First: Chung-Li Author-X-Name-Last: Tseng Author-Name: Tong Zhao Author-X-Name-First: Tong Author-X-Name-Last: Zhao Author-Name: Chung Fu Author-X-Name-First: Chung Author-X-Name-Last: Fu Title: Contingency estimation using a real options approach Abstract: In construction projects, contingency is the budget which is made available to cope with uncertainties that would incur schedule and cost overruns. Contingency estimation requires considering project cost, schedule and technology variability. The effect of dynamic project management of the decision maker should also be taken into account. Accordingly a real options approach for estimating contingency from the owner's point of view is presented. This approach not only explicitly recognizes the uncertainty in the life cycle of a construction project, but also incorporates a dynamic project management mechanism into contingency estimation. The contingency is valued by minimizing the expected project cost via a multi-stage stochastic model that accounts for the variability of project cost and schedule and the exercise of dynamic project crashing. The numerical results indicate that the value of the decision maker's dynamic project management makes up an important portion of the contingency. Journal: Construction Management and Economics Pages: 1073-1087 Issue: 11 Volume: 27 Year: 2009 Keywords: Contingency, estimating, project management, real options, stochastic modelling, X-DOI: 10.1080/01446190903222411 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903222411 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:11:p:1073-1087 Template-Type: ReDIF-Article 1.0 Author-Name: Roberto Pietroforte Author-X-Name-First: Roberto Author-X-Name-Last: Pietroforte Author-Name: Tullio Gregori Author-X-Name-First: Tullio Author-X-Name-Last: Gregori Author-Name: Marco Falagario Author-X-Name-First: Marco Author-X-Name-Last: Falagario Title: The changing input structure of the US construction industry: a longitudinal analysis Abstract: Eleven input-output tables are used for analysing the technological changes of the US construction industry from 1947 to 2002. Over the years, the industry has been characterized by a significant input shift that reflects the evolution of the USA towards services and away from a manufacturing-based economy. This evolution is also reflected in the 1997 adoption of a new classification system of the US industries by the Bureau of Economic Analysis (BEA). Changes are also found in analysing the direct requirements of two key sectors of the industry, residential and highway construction, during the 1967-1997 period. New materials and labour-saving machinery have been some of the major drivers in the changing input structure of the two considered sectors. The study demonstrates the importance of using very long series of data and input-output tables with more than 400 industries for the further understanding of the secular changes of the construction industry and its constituent sectors. Journal: Construction Management and Economics Pages: 1089-1098 Issue: 11 Volume: 27 Year: 2009 Keywords: US construction, input-output analysis, direct inputs, residential construction, highway construction, X-DOI: 10.1080/01446190903280443 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903280443 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:11:p:1089-1098 Template-Type: ReDIF-Article 1.0 Author-Name: Hemanta Doloi Author-X-Name-First: Hemanta Author-X-Name-Last: Doloi Title: Relational partnerships: the importance of communication, trust and confidence and joint risk management in achieving project success Abstract: The advantages of relational partnerships as an alternative project delivery mechanism to the traditional methods have yet to be realized by the wider construction industry. In relational partnerships, all parties work together as a cohesive team to achieve an agreed outcome. However, an accurate estimation of the underlying factors associated with the relationships of these parties and assessment of their impacts on partnering success are difficult to achieve. By identifying three major factors, communication, trust and confidence and joint risk management, this research unfolded the relational links between these factors and analysed the impacts in the context of the relational partnering success. Based on a questionnaire survey and the structural equation modelling technique, results identified communication as the single most influencing factor impacting on relational partnering success. While trust and confidence were found to be mutually inclusive for effective communication, it was found to have direct influence on developing capability for joint risk management within the partnering organizations. This finding diverges from the widely accepted view across the Australian construction industry that partnering is built on trust and confidence only and any risks associated in projects are best dealt with by means of joint responsibility without any problems. Journal: Construction Management and Economics Pages: 1099-1109 Issue: 11 Volume: 27 Year: 2009 Keywords: Relational partnerships, structural modelling equation, project success, procurement methods, X-DOI: 10.1080/01446190903286564 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903286564 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:11:p:1099-1109 Template-Type: ReDIF-Article 1.0 Author-Name: Susan McGrath-Champ Author-X-Name-First: Susan Author-X-Name-Last: McGrath-Champ Author-Name: Stuart Rosewarne Author-X-Name-First: Stuart Author-X-Name-Last: Rosewarne Title: Organizational change in Australian building and construction: rethinking a unilinear 'leaning' discourse Abstract: Over the past few decades there has been extensive reorganization of the construction industry in many developed countries including removal of head contractor companies from direct operational construction, elongation of the subcontracting chain, rising self-employment, casualization of work and reduced investment in training. These trends are the subject of a prescriptive, industry literature directed at industry 'improvement' and an important British-based critique of the underlying drivers of 'leanness' and organizational 're-engineering'. Drawing primarily upon interviews with organizations across the breadth of the industry, this paper provides evidence concerning such key changes in the Australian context, revealing both 'leaning'/'re-engineering' tendencies but also counter-tendencies necessitated by the goal of sustaining enduring enterprise and a viable labour force. A more reflexive approach by major companies to competitive pressures and risk shifting is revealed. Further, this evidence provides grounds for challenging the re-engineering/lean construction critique which is discerned as succumbing to the unitarist and unilinear discourse which it seeks to challenge. Journal: Construction Management and Economics Pages: 1111-1128 Issue: 11 Volume: 27 Year: 2009 Keywords: Business process re-engineering, lean production, Australia, X-DOI: 10.1080/01446190903236361 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903236361 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:11:p:1111-1128 Template-Type: ReDIF-Article 1.0 Author-Name: Nhat Hong Nguyen Author-X-Name-First: Nhat Hong Author-X-Name-Last: Nguyen Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Johnny Kwok Wai Wong Author-X-Name-First: Johnny Kwok Wai Author-X-Name-Last: Wong Title: Stakeholder impact analysis of infrastructure project management in developing countries: a study of perception of project managers in state-owned engineering firms in Vietnam Abstract: Construction projects can involve a diverse range of stakeholders and the success of the project depends very much on fulfilling their needs and expectations. It is important, therefore, to identify and recognize project stakeholders and develop a rigorous stakeholder management process. However, limited research has investigated the impact of stakeholders on construction projects in developing countries. A stakeholder impact analysis (SIA), based on an approach developed by Olander (2007), was adopted to investigate the stakeholders' impact on state-owned civil engineering projects in Vietnam. This involved the analysis of a questionnaire survey of 57 project managers to determine the relative importance of different stakeholders. The results show the client to have the highest level of impact on the projects, followed by project managers and the senior management of state-owned engineering firms. The SIA also provides suggestions to project managers in developing and evaluating the stakeholder management process. Journal: Construction Management and Economics Pages: 1129-1140 Issue: 11 Volume: 27 Year: 2009 Keywords: Project management, project success, project stakeholders, infrastructure projects, Vietnam, X-DOI: 10.1080/01446190903280468 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903280468 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:11:p:1129-1140 Template-Type: ReDIF-Article 1.0 Author-Name: Bo Xia Author-X-Name-First: Bo Author-X-Name-Last: Xia Author-Name: Albert Chan Author-X-Name-First: Albert Author-X-Name-Last: Chan Author-Name: John Yeung Author-X-Name-First: John Author-X-Name-Last: Yeung Title: Identification of key competences of design-builders in the construction market of the People's Republic of China (PRC) Abstract: Design-builders play a vital role in the success of DB projects. In the construction market of the People's Republic of China, most of the design-builders, however, lack adequate competences to conduct the DB projects successfully. The objective of this study is, therefore, to identify the key competences that design-builders should possess to not only ensure the success of DB projects but also acquire the competitive advantages in the DB market. Five semi-structured face-to-face interviews and two rounds of Delphi questionnaire survey were conducted to identify the key competences of design-builders. Rankings have been assigned to these key competences on the basis of their relative importance. Six ranked key competences of design-builders have been identified, namely: (1) experience with similar DB projects; (2) capability of corporate management; (3) combination of building techniques and design expertise; (4) financial capability for DB projects; (5) enterprise qualification and scale; and (6) credit records and reputation in the industry. The design-builders can make use of the research findings as guidelines to improve their DB competence. These research findings will also be useful to clients during the selection of design-builders. Journal: Construction Management and Economics Pages: 1141-1152 Issue: 11 Volume: 27 Year: 2009 Keywords: Design and build, procurement, competitive advantages, competence, Delphi method, China, X-DOI: 10.1080/01446190903280476 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903280476 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:11:p:1141-1152 Template-Type: ReDIF-Article 1.0 Author-Name: Jiayuan Wang Author-X-Name-First: Jiayuan Author-X-Name-Last: Wang Author-Name: Jian Liu Author-X-Name-First: Jian Author-X-Name-Last: Liu Author-Name: Zegao Liao Author-X-Name-First: Zegao Author-X-Name-Last: Liao Author-Name: Pei Tang Author-X-Name-First: Pei Author-X-Name-Last: Tang Title: Identification of key liability risks of supervision engineers in China Abstract: Until the present, the supervision engineer's liability risks in China have mostly been analysed by means of a qualitative approach by which it is difficult to identify the key liability risks of the Chinese supervision profession. Two questionnaire surveys were conducted to find out the supervision liability risks. The causes of those risks were analysed by reference to Chinese laws, regulations and questionnaire survey results. The score of the relative importance was creatively used to quantify the liability risks. Eleven key liability risks with higher scores of relative importance were identified. The risks have important influences on project quality, safety production and supervision profession development. The research results provide valuable information not only to government departments, professional associations, Chinese supervision engineers and supervision firms, but also to the foreign companies that offer services in China. The quantitative research method can be employed for other questionnaire surveys such as construction project quality and safety accidents. Journal: Construction Management and Economics Pages: 1157-1173 Issue: 12 Volume: 27 Year: 2009 Keywords: Liability risks, risk management, supervision, supervision engineer, X-DOI: 10.1080/01446190903222395 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903222395 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:12:p:1157-1173 Template-Type: ReDIF-Article 1.0 Author-Name: Eddie Chi-man Hui Author-X-Name-First: Eddie Chi-man Author-X-Name-Last: Hui Author-Name: Ivan Ng Author-X-Name-First: Ivan Author-X-Name-Last: Ng Title: Price discovery of property markets in Shenzhen and Hong Kong Abstract: Hong Kong and Shenzhen, while being interrelated in many aspects, have encountered different types of demand shocks throughout the past decade. This is likely due to disparities in market conditions and degrees of government regulations. In the light of such differences in property price trends, this research first investigates the relationships between housing prices and market fundamentals for both cities; and then it explores whether a housing price bubble existed for them in 2006. The results indicate that housing prices seem to have interacted abnormally with market fundamentals in recent years, especially for Shenzhen. In addition, while Shenzhen's housing prices are mainly explained by previous housing prices and personal income, most economic indicators explain Hong Kong's housing prices well. With regard to price bubbles, a puny bubble which amounts to as much as 4.5% of the housing price was formed in Shenzhen in 2006. In the meantime, the housing price bubble for Hong Kong had been diminished. Though currently not at dangerous levels, housing price bubbles should be taken with caution especially in today's China, characterized by overinvestment and rapid policy changes. Journal: Construction Management and Economics Pages: 1175-1196 Issue: 12 Volume: 27 Year: 2009 Keywords: Price, Granger causality, generalized impulse response, property market, variance decomposition, X-DOI: 10.1080/01446190903365640 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903365640 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:12:p:1175-1196 Template-Type: ReDIF-Article 1.0 Author-Name: Kunhui Ye Author-X-Name-First: Kunhui Author-X-Name-Last: Ye Author-Name: Weisheng Lu Author-X-Name-First: Weisheng Author-X-Name-Last: Lu Author-Name: Weiyan Jiang Author-X-Name-First: Weiyan Author-X-Name-Last: Jiang Title: Concentration in the international construction market Abstract: With the involvement of an increasing number of contractors in the international construction market, venturing overseas has been fraught with fierce competition and considerable uncertainties. This underscores the importance of examining the extent to which the intensity of competition (IoC) for international construction business is moderate. Concentration is a conventional IoC measure. By synthesizing four major concentration methods including concentration ratio, entropy, Gini coefficient and the Herfindahl index, a new model for measuring moderate IoC is thus proposed. Using the 28 years ENR-based data of the top 225 international contractors (TIC 225) in the proposed model, the IoC for international construction business is found to be moderate, if the magnitude of the market shares occupied by the top four international contractors is 0.2735. The finding revises a popular view that international construction competition has been intensifying only since 2002. It is implied that the proposed model favours a better understanding of competition characteristics in the international construction market and provides new insights into the theories about concentration. Journal: Construction Management and Economics Pages: 1197-1207 Issue: 12 Volume: 27 Year: 2009 Keywords: International construction market, business concentration, intensity of competition, moderate competition, X-DOI: 10.1080/01446190903222429 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903222429 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:12:p:1197-1207 Template-Type: ReDIF-Article 1.0 Author-Name: Hasan Haroglu Author-X-Name-First: Hasan Author-X-Name-Last: Haroglu Author-Name: Jacqueline Glass Author-X-Name-First: Jacqueline Author-X-Name-Last: Glass Author-Name: Tony Thorpe Author-X-Name-First: Tony Author-X-Name-Last: Thorpe Title: A study of professional perspectives on structural frame selection Abstract: The choice of an appropriate structural frame can contribute to effective short- and long-term performance, and enhance client satisfaction but limited research indicates that the issues taken into account during structural frame selection are not very well understood. With this in mind, a major research programme, including interviews and an industry survey, examined the attitudes of project managers, cost consultants and construction clients in analysing the issues they typically consider when choosing the structural frame for a building, and to provide insights about how such decisions are made in practice. Ten key issues were identified as being the most important affecting structural frame selection, but the extent to which different parties considered these and at what stage was found to vary. Also, the variations, between what these parties themselves think of the issues and what others perceive their attitudes to be, were examined. In particular, the results showed that what clients perceive differs considerably from how clients' views are perceived by others. For instance, according to cost consultants and project managers, their clients' preference to regularly select a 'preferred' frame type or material is a far more widespread tendency than clients themselves actually acknowledged. Journal: Construction Management and Economics Pages: 1209-1217 Issue: 12 Volume: 27 Year: 2009 Keywords: Decision making, structural frame, X-DOI: 10.1080/01446190903233129 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903233129 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:12:p:1209-1217 Template-Type: ReDIF-Article 1.0 Author-Name: Samuel Laryea Author-X-Name-First: Samuel Author-X-Name-Last: Laryea Title: Subcontract and supply enquiries in the tender process of contractors Abstract: In the tender process, contractors often rely on subcontract and supply enquiries to calculate their bid prices. However, this integral part of the bidding process is not empirically articulated in the literature. Over 30 published materials on the tendering process of contractors that talk about enquiries were reviewed and found to be based mainly on experiential knowledge rather than systematic evidence. The empirical research here helps to describe the process of enquiries precisely, improve it in practice, and have some basis to support it in theory. Using a live participant observation case study approach, the whole tender process was shadowed in the offices of two of the top 20 UK civil engineering construction firms. This helped to investigate 15 research questions on how contractors enquire and obtain prices from subcontractors and suppliers. Forty-three subcontract enquiries and 18 supply enquiries were made across two different projects with average value of £7m. An average of 15 subcontract packages and seven supply packages was involved. Thus, two or three subcontractors or suppliers were invited to bid in each package. All enquiries were formulated by the estimator, with occasional involvement of three other personnel. Most subcontract prices were received in an average of 14 working days; and supply prices took five days. The findings show 10 main activities involved in processing enquiries and their durations, as well as wasteful practices associated with enquiries. Contractors should limit their enquiry invitations to a maximum of three per package, and optimize the waiting time for quotations in order to improve cost efficiency. Journal: Construction Management and Economics Pages: 1219-1230 Issue: 12 Volume: 27 Year: 2009 Keywords: Case study, enquiries, subcontractors, suppliers, UK, X-DOI: 10.1080/01446190903394533 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903394533 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:12:p:1219-1230 Template-Type: ReDIF-Article 1.0 Author-Name: Toong Khuan Chan Author-X-Name-First: Toong Khuan Author-X-Name-Last: Chan Title: Measuring performance of the Malaysian construction industry Abstract: A systematic measurement framework for the Malaysian construction industry is essential to enable the industry to monitor its progress towards achieving the goals set out in the Construction Industry Master Plan 2006-15. The objectives were to develop a comprehensive set of performance measures for the construction industry, to compute these measures for the 2006 base year and to benchmark the available data. The Balanced Scorecard approach was used to examine the links between the critical success factors and strategic thrusts defined in the master plan to ensure that these provide a balanced view of the industry's competitive standing. The resulting strategy map revealed that the eight critical success factors and seven strategic thrusts of the master plan generally cover all four Balanced Scorecard perspectives with a strong emphasis on learning and growth. Thirty-four performance measures were adapted from other initiatives, modified to suit local practices, or were created specifically to measure the outcomes of the strategic thrusts. Performance measures were computed for the 2006 base year. A comparative analysis of the available data was conducted to determine tentative targets for these measures. Journal: Construction Management and Economics Pages: 1231-1244 Issue: 12 Volume: 27 Year: 2009 Keywords: Benchmarking, performance evaluation, Malaysia, X-DOI: 10.1080/01446190903233137 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903233137 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:12:p:1231-1244 Template-Type: ReDIF-Article 1.0 Author-Name: Hemanta Doloi Author-X-Name-First: Hemanta Author-X-Name-Last: Doloi Title: Analysis of pre-qualification criteria in contractor selection and their impacts on project success Abstract: While construction industry practices are reasonably well developed, construction projects still witness widespread failures of many contractors due to varied reasons such as financial problems, poor management, over-commitment and or conflicts and disputes associated with construction activities. Pre-qualification of contractors is a common practice across projects, yet the investigation on the ability of the selected contractors in successful delivery of projects is not widespread. In an attempt to understand these pre-emptive qualification criteria and their links in contractors' performance in projects, a total of 43 influencing technical attributes were identified through a systematic research approach. The relative significance and impacts of the attributes have been determined based on a structured questionnaire survey in selected construction projects. By performing the factor analysis, a total of seven factors significant to contractors' performance were extracted, namely (1) soundness of business and workforce; (2) planning and control; (3) quality management; (4) past performance; (5) risk management; (6) organizational capability; and (7) commitment and dedication. Multiple linear regression models reveal that technical expertise, past success, time in business, work methods and working capital significantly impact on contractors' performance across time, cost and quality success. With a clear understanding of a contractor's performance, these findings could potentially contribute to development of a company's procedures or enhance existing knowledge in relation to the pre-qualification practices in contractor selection in projects. Journal: Construction Management and Economics Pages: 1245-1263 Issue: 12 Volume: 27 Year: 2009 Keywords: Pre-qualification, contractor selection, project performance, factor analysis, regression modelling, X-DOI: 10.1080/01446190903394541 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903394541 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:12:p:1245-1263 Template-Type: ReDIF-Article 1.0 Author-Name: Patrick Zou Author-X-Name-First: Patrick Author-X-Name-Last: Zou Title: Construction Supply Chain Management Handbook Abstract: Journal: Construction Management and Economics Pages: 1265-1266 Issue: 12 Volume: 27 Year: 2009 X-DOI: 10.1080/01446190903222361 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903222361 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:12:p:1265-1266 Template-Type: ReDIF-Article 1.0 Author-Name: Said Boukendour Author-X-Name-First: Said Author-X-Name-Last: Boukendour Title: Construction Delays: Extensions of Time and Prolongation Claims Abstract: Journal: Construction Management and Economics Pages: 1266-1267 Issue: 12 Volume: 27 Year: 2009 X-DOI: 10.1080/01446190903222379 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903222379 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:12:p:1266-1267 Template-Type: ReDIF-Article 1.0 Author-Name: Danny Myers Author-X-Name-First: Danny Author-X-Name-Last: Myers Title: Economics for the Modern Built Environment Abstract: Journal: Construction Management and Economics Pages: 1267-1269 Issue: 12 Volume: 27 Year: 2009 X-DOI: 10.1080/01446190903233103 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903233103 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:12:p:1267-1269 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Chinowsky Author-X-Name-First: Paul Author-X-Name-Last: Chinowsky Title: Construction Planning, Programming and Control Abstract: Journal: Construction Management and Economics Pages: 1269-1270 Issue: 12 Volume: 27 Year: 2009 X-DOI: 10.1080/01446190903365624 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903365624 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:27:y:2009:i:12:p:1269-1270 Template-Type: ReDIF-Article 1.0 Author-Name: Lai Kit Chow Author-X-Name-First: Lai Kit Author-X-Name-Last: Chow Author-Name: S. Thomas Ng Author-X-Name-First: S. Thomas Author-X-Name-Last: Ng Title: Delineating the performance standards of engineering consultants at design stage Abstract: Many clients nowadays scrutinize consultants' performance carefully before determining which company should be awarded a consultancy assignment. Despite that, evaluating the performance of an engineering consultant is seldom conducted in a systematic manner, as every assessor has his/her own value judgment to distinguish what is a 'good' or 'bad' performance. In order to reduce the divergence between different assessors when the evaluation is carried out, it would be desirable to define the standards of each indicator used for describing the performance of an engineering consultant in an objective manner. In this research, a survey is conducted to unveil the standards for various performance levels which correspond to a list of indicators used for gauging engineering consultants' performance at the design stage. A modified horizontal approach is employed to analyse the data, and the results indicate that engineering consultants should fulfil greater than 90% in most of the aspects relevant to the design stage to qualify for an 'excellent' performance rating. By referring to the expected performance standards, clients can identify which quantitative indicators at the design stage should deserve much greater attention so as to minimize the chance of commissioning an incapable engineering consultant. Journal: Construction Management and Economics Pages: 3-11 Issue: 1 Volume: 28 Year: 2010 Keywords: Consultant performance, performance evaluation, fuzzy membership functions, X-DOI: 10.1080/01446190903450053 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903450053 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:1:p:3-11 Template-Type: ReDIF-Article 1.0 Author-Name: Mattias Jacobsson Author-X-Name-First: Mattias Author-X-Name-Last: Jacobsson Author-Name: Henrik Linderoth Author-X-Name-First: Henrik Author-X-Name-Last: Linderoth Title: The influence of contextual elements, actors' frames of reference, and technology on the adoption and use of ICT in construction projects: a Swedish case study Abstract: In contemporary research on construction-related ICT (information communication technologies), little distinction is made between the use of ICT in permanent line organizations and its use in temporary organizations (for example, in building and construction projects). This paper makes that distinction. The aim is to understand how the interplay among contextual elements, actors' frames of reference, and the ICT itself, influences the adoption and use of ICT in a building and construction project. This will be done through a description and analysis of a case study of ICT use in a major Swedish construction company. It is concluded that the well-defined duration of the temporary organization (the construction project) stands in sharp contrast to the generally indefinite duration of ICT-mediated change processes. However, by analysing the ICT application to be implemented, it can be revealed whether it can be 'ready packed' for, or delimited to, certain processes in order to achieve immediate benefits. When implementing more encompassing ICT applications, the challenge for the company is to find alternative ways of implementation in the project-based organization and of creating alternative spaces for innovation and renewal where new ICT can be tested and experimented with. Journal: Construction Management and Economics Pages: 13-23 Issue: 1 Volume: 28 Year: 2010 Keywords: Organizational change, temporary organizations, project-based organizations, X-DOI: 10.1080/01446190903406154 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903406154 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:1:p:13-23 Template-Type: ReDIF-Article 1.0 Author-Name: Matthew Hallowell Author-X-Name-First: Matthew Author-X-Name-Last: Hallowell Title: Cost-effectiveness of construction safety programme elements Abstract: Every year the construction industry accounts for a disproportionate injury rate when compared to the all-industry average. In recent years, incident rates have declined as a result of improvements in safety management. While there is a great deal of knowledge regarding the safety management strategies of highly effective construction firms, little is known about the cost-effectiveness of these strategies. Interviews with 26 representatives of construction firms headquartered in the US were undertaken to quantify the cost of implementing common safety programme elements by: (1) quantifying cost for each element per US$1 million of project scope; and (2) determining the distribution of safety funding to each element. Using these cost data and effectiveness ratings from previous research, the cost-effectiveness of 13 safety programme elements was quantified. The results indicate that the most cost-effective safety programme elements are subcontractor selection and management and upper management support and commitment. Alternatively, the least cost-effective elements are the employment of a full-time safety manager and record-keeping. The information presented in this paper may be used by practitioners to direct resource investments, strategically select a subset of safety programme elements when resources are limited, and to justify additional resource investment in accident prevention. Journal: Construction Management and Economics Pages: 25-34 Issue: 1 Volume: 28 Year: 2010 Keywords: Safety, risk management, X-DOI: 10.1080/01446190903460706 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903460706 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:1:p:25-34 Template-Type: ReDIF-Article 1.0 Author-Name: Jati Utomo Dwi Hatmoko Author-X-Name-First: Jati Utomo Dwi Author-X-Name-Last: Hatmoko Author-Name: Stephen Scott Author-X-Name-First: Stephen Author-X-Name-Last: Scott Title: Simulating the impact of supply chain management practice on the performance of medium-sized building projects Abstract: Construction supply chains encompass the flows of materials, labour, information, plant, equipment and temporary works that originate from a variety of different parties. The impact of various supply chain management practices on project performance has been measured, through a combination of a survey and the development of simulation models. Preliminary investigations were carried out by visiting two medium-sized building projects regularly over a period of six months to gain an understanding of the ways in which delays on supply chains impact on project performance. This was followed by the main survey which was designed to collect data required for developing the simulation models. These models were developed using Pertmaster Risk Expert™ software and incorporated supply chain delays applied to a CPM network of a typical medium-sized building project of 300 days' duration. The results of the simulation showed that the project's median delay was 67 days (22% of the project duration). The use of subcontractors in the project reduced this delay by approximately 45%. It was also learned that delays in material flow caused the biggest impact on the project, followed by labour flow, information flow and 'plant, equipment and temporary work' flow. These findings are an important measure of how much supply chain delays impact on project performance. Journal: Construction Management and Economics Pages: 35-49 Issue: 1 Volume: 28 Year: 2010 Keywords: Supply chain management, supply chain delays, project performance, simulation, risk, X-DOI: 10.1080/01446190903365632 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903365632 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:1:p:35-49 Template-Type: ReDIF-Article 1.0 Author-Name: Abdul-Rashid Abdul-Aziz Author-X-Name-First: Abdul-Rashid Author-X-Name-Last: Abdul-Aziz Author-Name: Sing Sing Wong Author-X-Name-First: Sing Sing Author-X-Name-Last: Wong Title: Exploring the internationalization of Malaysian contractors: the international entrepreneurship dimension Abstract: The internationalization of construction companies is a subject of enduring interest among construction management scholars. The internationalization pattern of Malaysian contractors was explored, this time mainly using the international entrepreneurship body of literature as the theoretical basis. In doing so, the focus of the internationalization process was on the entrepreneurs or top management. Data were collected with a postal questionnaire survey and follow-up semi-structured interviews. The findings underscore the importance of the entrepreneurs' decision in the surveyed firms' internationalization trajectory. Top management's perception of how their companies might benefit from internationalization was the highest ranked foreign market entry consideration. Top managements' initial and subsequent motivation also fashioned their companies' degree of internationalization and tactics for securing contracts. The characteristics of the entrepreneurs which drove their companies to internationalize were also captured. The international entrepreneurship domain continues to expand into previously uncharted areas. As such there is potential to uncover even more interesting findings from future research endeavours on international contractors using the international entrepreneurship approach. Journal: Construction Management and Economics Pages: 51-61 Issue: 1 Volume: 28 Year: 2010 Keywords: Contracting, internationalization, entrepreneurship, Malaysia, X-DOI: 10.1080/01446190903460680 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903460680 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:1:p:51-61 Template-Type: ReDIF-Article 1.0 Author-Name: Donald Jensen Author-X-Name-First: Donald Author-X-Name-Last: Jensen Title: A longitudinal study of a Type I differing conditions claim: investigating the contractor's failure to meet the reasonable prudent standard Abstract: The United States government's differing conditions clause poses extensive legal and financial risk. This contract clause addresses Type I and Type II unforeseen conditions. A Type I condition occurs when a latent physical condition materially differs from that condition indicated in the bidding documents. A Type II condition exists when an unknown physical condition has an unusual nature different from that condition generally encountered and naturally inhering in the contract work. The occurrence of either provides a contractor with the contractual right to file a claim for equitable contract adjustment. A contractor desiring to prevail, regarding a Type I claim, must properly comply with the Weeks Dredging proof elements. Chi-square statistical results, for 143 Type I differing conditions claims, provide empirical evidence that 79% of the contractors receive a disfavourable court award when challenging the United States government. Forty-four per cent of the reported cases cite the Weeks Dredging proof element, contractor did not act as a reasonably prudent contractor, as a basis for denying a contractor's claim for equitable adjustment. This standard measures whether a reasonable contractor did or did not review and properly document all bidding documents. Journal: Construction Management and Economics Pages: 63-74 Issue: 1 Volume: 28 Year: 2010 Keywords: Bidding, contract claims, government contracts, site conditions, Type I claim, X-DOI: 10.1080/01446190903406162 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903406162 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:1:p:63-74 Template-Type: ReDIF-Article 1.0 Author-Name: Hong Zhang Author-X-Name-First: Hong Author-X-Name-Last: Zhang Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Title: Multi-objective particle swarm optimization for construction time-cost tradeoff problems Abstract: Reduction in construction project duration is generally linked to additional cost due to more expensive resources required. Hence tradeoff between time and cost is crucial to the efficiency of a construction project. The time-cost tradeoff (TCT) issue has been studied through various multi-objective optimization methodologies to determine an optimal set of activity methods with the objectives of minimizing project duration and total cost. A multi-objective particle swarm optimization that adopts a combined scheme for determining the global best of each particle is presented for solving the TCT problem. The candidate TCT solutions in terms of a set of construction methods for activities are represented through the multidimensional particles. The framework of the combined scheme-based multi-objective particle swarm optimization (CSMOPSO) is developed. Computational analyses are conducted to investigate the performance of the CSMOPSO, including comparison with other methods. This study is expected to provide an alternative solving methodology for the TCT problem and help contractors or engineers plan construction methods with optimal time-cost tradeoff. Journal: Construction Management and Economics Pages: 75-88 Issue: 1 Volume: 28 Year: 2010 Keywords: Time-cost tradeoff, multi-objective optimization, particle swarm optimization (PSO), construction methods, X-DOI: 10.1080/01446190903406170 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903406170 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:1:p:75-88 Template-Type: ReDIF-Article 1.0 Author-Name: Li Liu Author-X-Name-First: Li Author-X-Name-Last: Liu Author-Name: Zigrid Napier Author-X-Name-First: Zigrid Author-X-Name-Last: Napier Title: The accuracy of risk-based cost estimation for water infrastructure projects: preliminary evidence from Australian projects Abstract: Infrastructure projects are still being plagued by cost overruns, delays and revenue shortfalls despite decades of practice and research. Risk-based estimating (RBE) is growing in popularity and has the potential to overcome the two main cost overrun factors—optimistic bias and strategic misrepresentation. Yet, little is known about the accuracy of RBE and its performance drivers. A comparison of water projects using RBE with a sample of construction projects using the conventional estimating approach shows that the projects estimated using RBE have better estimation accuracy than those estimated using more conventional approaches. In addition, the projects using RBE appear more likely to be under-budget while the ones using the conventional approach appear more likely to be over-budget. Further, through interviews and observations of the RBE process, three main performance drivers for the RBE method were identified to include outside view/collective experience, attention focusing and probabilistic, bottom-up modelling. Journal: Construction Management and Economics Pages: 89-100 Issue: 1 Volume: 28 Year: 2010 Keywords: Cost estimating, forecasting, accuracy, risk-based estimating, fixed contingency approach, X-DOI: 10.1080/01446190903431525 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903431525 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:1:p:89-100 Template-Type: ReDIF-Article 1.0 Author-Name: Henry Russell Author-X-Name-First: Henry Author-X-Name-Last: Russell Title: Materials and Skills for Historic Building Conservation Abstract: Journal: Construction Management and Economics Pages: 101-102 Issue: 1 Volume: 28 Year: 2010 X-DOI: 10.1080/01446190903460649 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903460649 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:1:p:101-102 Template-Type: ReDIF-Article 1.0 Author-Name: Wai Kiong Chong Author-X-Name-First: Wai Kiong Author-X-Name-Last: Chong Title: The Green Guide to Specification, 4th edn Abstract: Journal: Construction Management and Economics Pages: 102-103 Issue: 1 Volume: 28 Year: 2010 X-DOI: 10.1080/01446190903460656 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903460656 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:1:p:102-103 Template-Type: ReDIF-Article 1.0 Author-Name: Sandra Manley Author-X-Name-First: Sandra Author-X-Name-Last: Manley Title: Managing Diversity and Equality in Construction Abstract: Journal: Construction Management and Economics Pages: 103-105 Issue: 1 Volume: 28 Year: 2010 X-DOI: 10.1080/01446190903460664 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903460664 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:1:p:103-105 Template-Type: ReDIF-Article 1.0 Author-Name: Kunhui Ye Author-X-Name-First: Kunhui Author-X-Name-Last: Ye Author-Name: Liyin Shen Author-X-Name-First: Liyin Author-X-Name-Last: Shen Author-Name: Yongtao Tan Author-X-Name-First: Yongtao Author-X-Name-Last: Tan Title: Response strategies to the competition in the Chinese construction market Abstract: The Chinese construction market is composed of 31 local markets which differ from each other in various aspects such as competition intensity. Contractors moving from one market to another need to consider the competition strategies and make due response to new competition situation in order to survive. Nevertheless, the research into response strategies to competition situations has been limited. Effective response strategies can assist contractors to respond to different competition environments. Based on the data collected from major cities in China, five typical competition situations are identified and six strategies are found effective to guide contractors' response to various competition situations. For instance, a closer cooperation between main contractors helps contractors respond effectively where safety accidents occur frequently in the market. The research findings present new perspectives of developing competitive strategies in the Chinese construction market and provide recommendations for adopting a conduct-performance approach for examining response strategies in other construction markets. Journal: Construction Management and Economics Pages: 115-124 Issue: 2 Volume: 28 Year: 2010 Keywords: Competition, response strategies, market performance indicators, coefficient analysis, China, X-DOI: 10.1080/01446190903473774 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903473774 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:2:p:115-124 Template-Type: ReDIF-Article 1.0 Author-Name: Shu-Ling Lu Author-X-Name-First: Shu-Ling Author-X-Name-Last: Lu Author-Name: Martin Sexton Author-X-Name-First: Martin Author-X-Name-Last: Sexton Title: Career journeys and turning points of senior female managers in small construction firms Abstract: There is under-representation of senior female managers within small construction firms in the United Kingdom. The position is denying the sector a valuable pool of labour to address acute knowledge and skill shortages. Grounded theory on the career progression of senior female managers in these firms is developed from biographical interviews. First, a turning point model which distinguishes the interplay between human agency and work/home structure is given. Second, four career development phases are identified. The career journeys are characterized by ad hoc decisions and opportunities which were not influenced by external policies aimed at improving the representation of women in construction. Third, the 'hidden', but potentially significant, contribution of women-owned small construction firms is noted. The key challenge for policy and practice is to balance these external approaches with recognition of the 'inside out' reality of the 'lived experiences' of female managers. To progress this agenda there is a need for: appropriate longitudinal statistical data to quantify the scale of senior female managers and owners of small construction firms over time; and, social construction and gendered organizational analysis research to develop a general discourse on gender difference with these firms. Journal: Construction Management and Economics Pages: 125-139 Issue: 2 Volume: 28 Year: 2010 Keywords: Career development, senior female managers, small construction firms, women company owners, X-DOI: 10.1080/01446190903280450 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903280450 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:2:p:125-139 Template-Type: ReDIF-Article 1.0 Author-Name: Alexis Anne McGuffin Author-X-Name-First: Alexis Anne Author-X-Name-Last: McGuffin Author-Name: Esther Obonyo Author-X-Name-First: Esther Author-X-Name-Last: Obonyo Title: Enhancing performance: a case study of the effects of employee coaching in construction practice Abstract: The contemporary practice of coaching in the business world entails engaging accredited professionals to enhance the performance of employees. A key problem impeding the widespread adoption of coaching is the lack of empirical research supporting the effectiveness of implemented programmes and the returns on investment. The benefits of coaching are assessed from the perspective of employees. Data were collected through a case study of an employee coaching programme within a large, multinational construction company. The programme had significantly enhanced the employees' personal and professional growth and development. It had also increased their motivation levels and loyalty to the company. Journal: Construction Management and Economics Pages: 141-149 Issue: 2 Volume: 28 Year: 2010 Keywords: Employee coaching, enhancing performance, motivation, case study, human factors, X-DOI: 10.1080/01446190903460672 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903460672 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:2:p:141-149 Template-Type: ReDIF-Article 1.0 Author-Name: Abdulsalam Al-Sudairi Author-X-Name-First: Abdulsalam Author-X-Name-Last: Al-Sudairi Author-Name: Mohammed Al-Motairi Author-X-Name-First: Mohammed Author-X-Name-Last: Al-Motairi Title: Multi objective land use allocation model using priority-based goal programming technique Abstract: A multi-objective goal programming model was used to optimize land use allocation for housing projects in the Kingdom of Saudi Arabia. The main goal of this model is twofold. It is hoped, on the one hand, that it would reduce the effort and time in planning for such projects, as well as guarantee the element of accuracy on the other. The model utilized the planning standards and requirements set by the Ministry of Municipalities and Rural Affaires (MOMRA) in allocating land uses of various housing projects. Based on the results of the study, certain planning constraints were proved to be more sensitive than others as planners need to take into account essential factors such as population density and provision of private and semi-public facilities. In addition, linear goal programming models accompanied by prioritization usually fit the nature of land use allocation problems in housing projects. The result shows that a high level of optimization has been achieved. Journal: Construction Management and Economics Pages: 151-161 Issue: 2 Volume: 28 Year: 2010 Keywords: MOMRA, goal programming, land use, allocation, X-DOI: 10.1080/01446190903460698 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903460698 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:2:p:151-161 Template-Type: ReDIF-Article 1.0 Author-Name: Konstantinos Anagnostopoulos Author-X-Name-First: Konstantinos Author-X-Name-Last: Anagnostopoulos Author-Name: Georgios Koulinas Author-X-Name-First: Georgios Author-X-Name-Last: Koulinas Title: A simulated annealing hyperheuristic for construction resource levelling Abstract: Resource levelling techniques aim to minimize the fluctuation from one time period to another in resource usage. Except for small-sized problems, though, computational optimization procedures are inefficient when solving construction resource levelling problems. Consequently, heuristic and metaheuristic approaches are used to get an acceptable, but not necessarily optimal, solution. A simulated annealing hyperheuristic to generate better-levelled resource profiles is proposed. Unlike traditional heuristic algorithms, a hyperheuristic operates in the 'low level' heuristics domain rather than in the solutions domain. A low level heuristic, on the other hand, works in the current solution neighbourhood. The algorithm has been programmed within a commercial project management software system to improve its performance. The low level heuristics operate on the priority levels that the software uses for resource levelling. An illustrative example and the computational analysis demonstrate the potential of the procedure in solving complex scheduling problems. Journal: Construction Management and Economics Pages: 163-175 Issue: 2 Volume: 28 Year: 2010 Keywords: Hyperheuristic, metaheuristics, priorities, resource levelling, simulated annealing, X-DOI: 10.1080/01446190903369907 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903369907 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:2:p:163-175 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Florence Phua Author-X-Name-First: Florence Author-X-Name-Last: Phua Author-Name: Kevin Dunn Author-X-Name-First: Kevin Author-X-Name-Last: Dunn Author-Name: Umut Ozguc Author-X-Name-First: Umut Author-X-Name-Last: Ozguc Title: Operatives' experiences of cultural diversity on Australian construction sites Abstract: Construction sites are among Australia's most culturally diverse workplaces. A survey of 1155 construction operatives on Australian construction sites investigated, for the first time, the extent of this diversity and how it is experienced by workers. Results show that while cultural diversity presents organizational challenges by segregating the workforce, operatives' cultural groups also perform positive functions such as maintaining positive bonds among group members and providing group support and safe havens. While there broadly appears to be equality of opportunity for all cultural groups, there is significant evidence of differential treatment for some groups, particularly in relation to accessing higher paying jobs, offensive graffiti and racist joke telling. Language barriers are one of the major challenges affecting work and social relations between different cultural groups and there is evidence that this has a detrimental impact upon safety. Journal: Construction Management and Economics Pages: 177-188 Issue: 2 Volume: 28 Year: 2010 Keywords: Diversity, culture, immigrants, safety, racism, discrimination, X-DOI: 10.1080/01446190903450087 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903450087 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:2:p:177-188 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Morgan Tuuli Author-X-Name-First: Martin Morgan Author-X-Name-Last: Tuuli Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Author-Name: Tas Yong Koh Author-X-Name-First: Tas Yong Author-X-Name-Last: Koh Title: Dynamics of control in construction project teams Abstract: Control is pervasive in construction project environments. The management of projects through various planning and control tools has therefore been described essentially as rebureaucratization which increases control over individuals, teams and organizations through ideologies of efficiency and performativity. Yet certain characteristics of the project setting make it an ideal climate for the empowerment of individuals and teams. The manifestations of control in five construction project management teams involved in two ongoing construction projects in Hong Kong are examined. The interpretive and exploratory focus of the study favoured the use of a qualitative research design and the case study approach in particular. Control is viewed as all devices and systems employed to ensure that acts, behaviours, outcomes and decisions of individuals, teams and organizations are consistent with meeting organizational or project goals, objectives and strategies. The findings indicate that a portfolio of control modes is implemented in project teams comprising both formal (i.e. behaviour- and outcome-based) and informal (i.e. clan- and self-based) control mechanisms which are not necessarily incompatible. While formal control remains the primary control mode, a portfolio of control appears necessary to augment the inadequacies of formal control due to the evolving nature of the project environment. Journal: Construction Management and Economics Pages: 189-202 Issue: 2 Volume: 28 Year: 2010 Keywords: Empowerment, formal control, Hong Kong, informal control, portfolio of control, X-DOI: 10.1080/01446190903365657 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903365657 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:2:p:189-202 Template-Type: ReDIF-Article 1.0 Author-Name: Onder Okmen Author-X-Name-First: Onder Author-X-Name-Last: Okmen Author-Name: Ahmet Oztas Author-X-Name-First: Ahmet Author-X-Name-Last: Oztas Title: Construction cost analysis under uncertainty with correlated cost risk analysis model Abstract: Cost estimation is an important task in construction projects. Since various risk-factors affect the construction costs, the actual costs generally deviate from the estimated costs in a favourable or an adverse direction. Therefore, not only estimation of the costs but also an analysis of the uncertainty of the estimated costs is required. This requirement gains more importance in projects constrained by money as the main driver. The traditional cost estimation, i.e. predicting the construction costs and simply calculating the total, is deterministic and insufficient. This approach neglects the uncertainty and the correlation effects. A new simulation-based model—the correlated cost risk analysis model (CCRAM)—is proposed to analyse the construction costs under uncertainty when the costs and risk-factors are correlated. CCRAM captures the correlation between the costs and risk-factors indirectly and qualitatively. The efficiency and effectiveness of the model is evaluated through an application of CCRAM and Monte Carlo simulation (MCS) based method using the same hypothetical data. The findings show that CCRAM operates well and produces more consistent results compatible with the theoretical expectancies. Journal: Construction Management and Economics Pages: 203-212 Issue: 2 Volume: 28 Year: 2010 Keywords: Cost modelling, uncertainty, risk management, risk analysis, correlation, simulation, X-DOI: 10.1080/01446190903468923 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903468923 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:2:p:203-212 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Title: Construction Safety Management Abstract: Journal: Construction Management and Economics Pages: 213-214 Issue: 2 Volume: 28 Year: 2010 X-DOI: 10.1080/01446190903468915 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903468915 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:2:p:213-214 Template-Type: ReDIF-Article 1.0 Author-Name: Joe Wong Author-X-Name-First: Joe Author-X-Name-Last: Wong Author-Name: Eddie Hui Author-X-Name-First: Eddie Author-X-Name-Last: Hui Title: Construction project risks: further considerations for constructors' pricing in Hong Kong Abstract: Journal: Construction Management and Economics Pages: 215-215 Issue: 3 Volume: 28 Year: 2010 X-DOI: 10.1080/01446191003698161 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003698161 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:3:p:215-215 Template-Type: ReDIF-Article 1.0 Author-Name: Giuseppe Pellegrini-Masini Author-X-Name-First: Giuseppe Author-X-Name-Last: Pellegrini-Masini Author-Name: Graeme Bowles Author-X-Name-First: Graeme Author-X-Name-Last: Bowles Author-Name: Andrew Peacock Author-X-Name-First: Andrew Author-X-Name-Last: Peacock Author-Name: Marcus Ahadzi Author-X-Name-First: Marcus Author-X-Name-Last: Ahadzi Author-Name: Phillip Banfill Author-X-Name-First: Phillip Author-X-Name-Last: Banfill Title: Whole life costing of domestic energy demand reduction technologies: householder perspectives Abstract: A recent, major UK research project investigated technical and social aspects of reducing the CO2 emissions of UK domestic housing by 50% by the year 2030. As 80% of the UK housing stock that will be present in 2030 has already been built, this study aimed to research the whole life costs of three sets of energy demand reduction technologies for existing housing, over a 25-year period, suitable to deliver significant CO2 emissions reduction up to 50%. Demand side technological interventions in the form of fabric upgrades and ventilation systems are identified. Whole life cycle analysis of interventions carried out on two housing variants prominent in the domestic stock under different energy price scenarios is carried out using discounted cash flow and compared with the do-nothing option. The results show that, despite reducing annual energy bills, there is no clear financial case even over a 25-year horizon for householders to invest in the proposed interventions that contribute to CO2 emission reduction targets. When discussed with respect to household income and consumption preferences, the results reveal the need for new policy approaches to overcome the financial and non-financial hurdles for a mass uptake of energy efficient technologies. Journal: Construction Management and Economics Pages: 217-229 Issue: 3 Volume: 28 Year: 2010 Keywords: Energy consumption, energy efficiency, whole life costing, housing, X-DOI: 10.1080/01446190903480027 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903480027 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:3:p:217-229 Template-Type: ReDIF-Article 1.0 Author-Name: Carol Jewell Author-X-Name-First: Carol Author-X-Name-Last: Jewell Author-Name: Roger Flanagan Author-X-Name-First: Roger Author-X-Name-Last: Flanagan Author-Name: Caner Anac Author-X-Name-First: Caner Author-X-Name-Last: Anac Title: Understanding UK construction professional services exports: definitions and characteristics Abstract: Services are very important to the UK balance of trade; a surplus has been recorded for trade in services every year since 1966. Construction professional services exports (CPS), which cover architecture, engineering and surveying (AES), have also increased, contributing over £3bn to the UK trade balance in 2007. The changing environment of construction professional services exports complicates the validity of the characteristics and definitions of services as described in the research literature and official export statistics. Through semi-structured interviews undertaken with large consulting engineers and a roundtable discussion with industry and government representatives, the research found that the impact of globalization and the changes in the construction business environment, such as increasing foreign ownership and changing forms of procurement, are not fully reflected in the official statistics. There have also been rapid changes in technology, procurement and methods of delivery which have impacted on exporting AES firms and a more appropriate set of characteristics is needed to better reflect the project-specific and knowledge-intensive nature of AES firms. Journal: Construction Management and Economics Pages: 231-239 Issue: 3 Volume: 28 Year: 2010 Keywords: Exports, services, construction, globalization, knowledge-based economy, X-DOI: 10.1080/01446191003587729 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003587729 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:3:p:231-239 Template-Type: ReDIF-Article 1.0 Author-Name: Ryan Fan Author-X-Name-First: Ryan Author-X-Name-Last: Fan Author-Name: S. Thomas Ng Author-X-Name-First: S. Thomas Author-X-Name-Last: Ng Author-Name: James Wong Author-X-Name-First: James Author-X-Name-Last: Wong Title: Reliability of the Box-Jenkins model for forecasting construction demand covering times of economic austerity Abstract: As a driving engine for growth, the construction industry plays an important role in a country's economic development process. Despite that, the industry is vulnerable to cyclical oscillation and at times more fundamental changes in work volume when the regional or global economy is hit by unforeseen events. In order to formulate appropriate policies and directions to help ease the impact of a fluctuating volume of construction work, a model that can reliably predict the work of various construction sectors after any economic turbulence would be extremely useful. In this study, the Box-Jenkins approach is used for model development due to its simplicity and sound theoretical background. The results illustrate that the Box-Jenkins models can reliably predict the medium-term total construction demand and residential demand covering a turbulent period of ups and downs in construction demand. A multiple regression model is also developed to compare against the modelling reliability of the Box-Jenkins model. Journal: Construction Management and Economics Pages: 241-254 Issue: 3 Volume: 28 Year: 2010 Keywords: Construction demand, forecasting, Box-Jenkins technique, economic environment, X-DOI: 10.1080/01446190903369899 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903369899 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:3:p:241-254 Template-Type: ReDIF-Article 1.0 Author-Name: Hedley Smyth Author-X-Name-First: Hedley Author-X-Name-Last: Smyth Title: Construction industry performance improvement programmes: the UK case of demonstration projects in the 'Continuous Improvement' programme Abstract: There has been a range of initiatives across many countries over the last 10 to 15 years to introduce reform to the construction process in order to improve performance. The so-called UK 'Continuous Improvement' programme is evaluated as a case study through an analysis of demonstration projects. These projects symbolically represent best practice for others to follow directly in the UK and through influence indirectly in other countries. This raises methodological challenges, yet the scant empirical attention given to this field justifies such attention. The main conclusion is that there have been improvements, yet these seem not to have been continuous. Contractors are distant from direct value creation, increasingly relying upon others in the supply chain. Improvement measures have not penetrated most supply chains. This suggests that contractors need to develop learning and competency capacity; especially stakeholder management and/or clients need to identify new solution providers. There has been little direct evidence of this and the current environment is placing emphasis upon price rather than value. Capacity and capabilities for continuous improvement appear largely transient and insufficiently embedded to persist where present. Journal: Construction Management and Economics Pages: 255-270 Issue: 3 Volume: 28 Year: 2010 Keywords: Performance improvement, demonstration projects, investment, knowledge transfer management, X-DOI: 10.1080/01446190903505948 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903505948 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:3:p:255-270 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Mark Jones Author-X-Name-First: Stephen Mark Author-X-Name-Last: Jones Author-Name: Andrew Ross Author-X-Name-First: Andrew Author-X-Name-Last: Ross Author-Name: Begum Sertyesilisik Author-X-Name-First: Begum Author-X-Name-Last: Sertyesilisik Title: Testing the unfolding model of voluntary turnover on construction professionals Abstract: Employee turnover affects performance and competitiveness of companies. Traditional voluntary employee turnover models attempting to predict voluntary turnover are based on job satisfaction. A recent model that breaks away from this tradition is the unfolding model of voluntary employee turnover (UMVT) which takes account of additional factors such as labour market forces, economy and habit. UMVT has been tested in various industries. However, in the construction sector UMVT is tested for the first time in this study. A convenience sample of 320 construction professionals was taken from the Global Construction Consultants, Davis Langdon. The sample provided useable online survey data from 104 respondents who had voluntarily left their previous employers in the last four years. The results reveal that UMVT's ability to interpret voluntary employee turnover among construction professionals was weak. In contrast to previous studies of UMVT, a significant number of respondents (80.8%) followed paths other than the original five theorized paths. As a result, a new extended version of the UMVT is proposed that includes two new paths that have been theorized, which add to the understanding of voluntary employee turnover and may, in the long term, help support human resource management in construction professional practices to predict and manage voluntary employee turnover. Journal: Construction Management and Economics Pages: 271-285 Issue: 3 Volume: 28 Year: 2010 Keywords: Human resource management, workforce, professional, professional service firms, employee relations, X-DOI: 10.1080/01446191003587737 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003587737 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:3:p:271-285 Template-Type: ReDIF-Article 1.0 Author-Name: Li-Chung Chao Author-X-Name-First: Li-Chung Author-X-Name-Last: Chao Title: Estimating project overheads rate in bidding: DSS approach using neural networks Abstract: Project overheads estimation by applying a selected rate as a percentage of direct cost is used widely in bidding in construction, but the rate is prone to inaccuracy if it is selected subjectively. An improved approach is developed, a decision support system (DSS) based on a construction firm's cost data and using a neural network model for mapping of overheads rates from project attributes. The estimating ability of the proposed DSS is continually updated by retraining the neural networks with accumulated cost data in an expanding project database. An illustrative example is provided, in which the creation and updating of a prototype neural network model were simulated using cost data for projects spanning six years. The model explains the effects of duration and direct cost on overheads rates that the regression method fails to account for. The results also give empirical evidence that the DSS is capable of improving accuracy through annual model updating and may be used as a means for implementing organizational learning. The methods for assessing the loss risk for a bid incorporating an estimate from the DSS are provided. Journal: Construction Management and Economics Pages: 287-299 Issue: 3 Volume: 28 Year: 2010 Keywords: Estimating, overheads, neural networks, statistical analysis, decision support systems, X-DOI: 10.1080/01446190903473782 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903473782 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:3:p:287-299 Template-Type: ReDIF-Article 1.0 Author-Name: Ulrika Badenfelt Author-X-Name-First: Ulrika Author-X-Name-Last: Badenfelt Title: I trust you, I trust you not: a longitudinal study of control mechanisms in incentive contracts Abstract: The relationship between trust and control in client-contractor interactions is explored, focusing on the control mechanisms used in a construction project. A longitudinal case study of a large laboratory construction project found that the client used a variety of control mechanisms to ensure that the contractor behaved trustworthily. Empirical data were gathered through interviews and non-participant observation. The results indicate that the use of control mechanisms is part of a complex and dynamic socially constructed process that requires ongoing discussion and evaluation, and to which informal control mechanisms are central. Business relationships built solely on trust are seemingly rare; even in trust-based collaborative settings, such as partnering arrangements; the contracting parties must pay attention to trust-nurturing actions. Journal: Construction Management and Economics Pages: 301-310 Issue: 3 Volume: 28 Year: 2010 Keywords: Longitudinal study, trust, control mechanisms, partnering arrangements, target cost contracts, X-DOI: 10.1080/01446191003587745 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003587745 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:3:p:301-310 Template-Type: ReDIF-Article 1.0 Author-Name: Patrick Erik Bradley Author-X-Name-First: Patrick Erik Author-X-Name-Last: Bradley Title: An ultrametric interpretation of building related event data Abstract: The long-term behaviour of the built environment is relevant to practising architects and engineers as well as to investors and policy makers. In contrast to this, the size, structure and dynamics of that important capital of society are not well established. As a first step towards assessing the dynamics of new constructions, refurbishments, demolitions and other building related event variables in urban building stocks in Southwest Germany, a first random sample of event data is examined using the more efficient ultrametric hierarchical classification in order to compare their dynamics. To this end, different ways of binary encodings of the multivariate data are carried out, and their ultrametric classification results compared. It turns out that municipalities of comparable sizes show similar behaviour in contrast to those of differing sizes, which corresponds to previous findings. Consequently, ultrametric methods can be applied to the study of building stock dynamics by revealing inherent hierarchical structure in data. Journal: Construction Management and Economics Pages: 311-326 Issue: 3 Volume: 28 Year: 2010 Keywords: Building stock dynamics, hierarchical classification, ultrametric methods, X-DOI: 10.1080/01446190903473790 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903473790 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:3:p:311-326 Template-Type: ReDIF-Article 1.0 Author-Name: David William Cattell Author-X-Name-First: David William Author-X-Name-Last: Cattell Author-Name: Paul Anthony Bowen Author-X-Name-First: Paul Anthony Author-X-Name-Last: Bowen Author-Name: Ammar Kaka Author-X-Name-First: Ammar Author-X-Name-Last: Kaka Title: The risks of unbalanced bidding Abstract: Unbalanced bidding models have largely ignored the risk aspect of item pricing. Many researchers have acknowledged that there are considerable risks associated with unbalancing a bid but little has been done to describe these risks, let alone model them. A new framework is proposed by which all of these risks can be assessed. It identifies that these risks comprise the risk of rejection, the risk of reaction, and the risk of being wrong. It is further proposed that the value-at-risk ('VaR') method of measuring risk is a convenient way by which to combine all of these risks into one composite assessment. This quantified assessment serves to describe the extent of risk generated by each level of each item's price. Previous related research has proposed an unbalanced bidding model that has likewise provided a measurement of the expected reward generated by each level of each item's price. By doing a summation of these, keeping in mind that the prices applied to all of a project's component items must add up to the overall bid price, the contractor is able to assess both the risks as well as the rewards of all possible item price combinations. Journal: Construction Management and Economics Pages: 333-344 Issue: 4 Volume: 28 Year: 2010 Keywords: Bidding, cost modelling, risk analysis, risk management, mark-up, X-DOI: 10.1080/01446191003663264 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003663264 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:4:p:333-344 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Raisbeck Author-X-Name-First: Peter Author-X-Name-Last: Raisbeck Author-Name: Colin Duffield Author-X-Name-First: Colin Author-X-Name-Last: Duffield Author-Name: Ming Xu Author-X-Name-First: Ming Author-X-Name-Last: Xu Title: Comparative performance of PPPs and traditional procurement in Australia Abstract: Empirical research comparing projects procured as public-private partnerships (PPPs) with other methods of procurement is important because Australian governments plan to spend $320 billion on infrastructure over the next decade and PPPs are perceived to be an appropriate form of delivery. Estimating cost and risks in Australian capital projects is often characterized by optimism bias—the tendency to be overly optimistic about planned actions—and is too often based on insufficient historical data on which to make decisions. Given this broad context it is important to begin to understand in detail how PPPs have performed against other forms of procurement. To achieve this, a detailed study has been undertaken to compare the project time and cost outcomes observed in the Australian PPP market with those projects delivered by governments via traditional procurement methods. Two sets or pools of projects were compared based on a detailed analysis of publicly available data for a sample of 21 PPP projects and 33 traditional projects. This selection was based on a consideration of previous studies, time and cost metrics, project size and the relative complexity of different project types. In comparing the two sets PPPs demonstrated superior cost efficiency over traditional procurement, which ranged from 30.8% when measured from project inception, to 11.4% when measured from contractual commitment to the final outcome. Between the signing of the final contract and project completion, PPPs were found to be completed 3.4% ahead of time on average, while traditional projects were completed 23.5% behind time. The overall conclusion is that PPPs provide superior performance in both the cost and time dimensions, and that the PPP advantage increases (in absolute terms) with the size and complexity of projects. Journal: Construction Management and Economics Pages: 345-359 Issue: 4 Volume: 28 Year: 2010 Keywords: PPPs, PFI, time and cost performance, procurement, infrastructure, X-DOI: 10.1080/01446190903582731 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903582731 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:4:p:345-359 Template-Type: ReDIF-Article 1.0 Author-Name: Qingbin Cui Author-X-Name-First: Qingbin Author-X-Name-Last: Cui Author-Name: Makarand Hastak Author-X-Name-First: Makarand Author-X-Name-Last: Hastak Author-Name: Daniel Halpin Author-X-Name-First: Daniel Author-X-Name-Last: Halpin Title: Systems analysis of project cash flow management strategies Abstract: Cash flow management is one of the most important determinants of the success of construction project management. Overdraft, retainage, financing, payment and billing policies constitute the most significant financial issues that contractors must plan, control and manage for the successful completion of construction jobs. Particularly, in an attempt to reduce project costs, contractors must balance cost savings of material discounts due to early payments and extra interest expenses because of additional overdraft. Through identifying feedback loops in project cash flows, a system dynamics model is developed for project cash flow management. The model is flexible to incorporate typical front-end and back-end loading cash flow management strategies and provides an interactive predication of project cash flows. A warehouse project is discussed to demonstrate how various cash flow strategies improve overdraft financing requirements and profitability. Especially, the analysis shows an 11% reduction on overdraft requirements while using an overbilling strategy, and 30% reduction if the trade credit strategy is implemented. Journal: Construction Management and Economics Pages: 361-376 Issue: 4 Volume: 28 Year: 2010 Keywords: Project cash flow, overdraft, cash flow management strategies, system dynamics, scenario analysis, X-DOI: 10.1080/01446191003702484 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003702484 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:4:p:361-376 Template-Type: ReDIF-Article 1.0 Author-Name: Ivan Lai Author-X-Name-First: Ivan Author-X-Name-Last: Lai Author-Name: Frankie Lam Author-X-Name-First: Frankie Author-X-Name-Last: Lam Title: Perception of various performance criteria by stakeholders in the construction sector in Hong Kong Abstract: All construction projects in Hong Kong have in common a cast of key contract participants, consisting of clients, consultants (designers) and contractors. The aim of this research is to examine, from different points of view, these practitioners in regard to the importance of perceived performance criteria and their respective performance outcomes in a construction project. A research model is structured based on nine performance criteria and their respective performances. The data were collected from 324 practitioners who have participated in construction projects in Hong Kong. One-way analysis of variance (ANOVA) and repeated measures ANOVA are used to analyse the data. The relative importance of nine performance criteria and their performances are measured. Timely completion of the project is the most important performance criterion, followed by profit, environmental protection and quality. There are differences in the importance of the performance criteria with respect to performance. The differences in the perceptions of performance that are identified are: (i) among different practitioners in a construction project; (ii) due to different project types; and (iii) between different functional roles in the partnering organizations. In order to further understand the importance of the performance criteria with respect to performance, the status quo of project partnering and congeniality problems in the construction industry is reviewed. It is intended to stimulate interest in the further exploration of solutions to improve the overall performance of the construction industry in Hong Kong. Journal: Construction Management and Economics Pages: 377-391 Issue: 4 Volume: 28 Year: 2010 Keywords: Performance improvement, performance evaluation, partnering, supplier relationship, performance criteria, X-DOI: 10.1080/01446190903521515 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903521515 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:4:p:377-391 Template-Type: ReDIF-Article 1.0 Author-Name: Mohammed Fadhil Dulaimi Author-X-Name-First: Mohammed Fadhil Author-X-Name-Last: Dulaimi Author-Name: Mohamed Alhashemi Author-X-Name-First: Mohamed Author-X-Name-Last: Alhashemi Author-Name: Florence Yean Yng Ling Author-X-Name-First: Florence Yean Yng Author-X-Name-Last: Ling Author-Name: Mohan Kumaraswamy Author-X-Name-First: Mohan Author-X-Name-Last: Kumaraswamy Title: The execution of public-private partnership projects in the UAE Abstract: There are few public-private partnership (PPP) projects in the UAE, but the number is increasing. Recently government and public bodies have intensified their interest in PPPs to encourage more involvement of the private sector in the country's development. The aim of the research is to evaluate the UAE experience in using PPP projects focusing on the critical success and failure factors for PPPs in the UAE. Three case studies were examined to identify the critical success factors and the failure factors. The results have shown that political support is the most important success factor followed by having a strong private consortium. The most important factor that causes PPP projects to fail in this context is when the consortium lacks the appropriate knowledge and skills. Hence, private consortia need to ensure that they assemble the relevant skills and knowledge of how to set up and manage a PPP as well as the crucial knowledge pertaining to the local business environment and political drivers. Journal: Construction Management and Economics Pages: 393-402 Issue: 4 Volume: 28 Year: 2010 Keywords: Public-private partnerships, critical success factors, failure factors, United Arab Emirate, X-DOI: 10.1080/01446191003702492 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003702492 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:4:p:393-402 Template-Type: ReDIF-Article 1.0 Author-Name: Matthew Hallowell Author-X-Name-First: Matthew Author-X-Name-Last: Hallowell Title: Safety risk perception in construction companies in the Pacific Northwest of the USA Abstract: Unsafe worker actions contribute greatly to the frequency and severity of construction injuries. Recently, contractors have expressed concern with the high rate of injuries that occur when workers violate company safety policies. To enhance knowledge associated with this topic the following four objectives were targeted: (1) quantifying the current level of safety risk as perceived by construction workers; (2) quantifying the risk tolerance of workers and managers; (3) comparing the risk perceptions and tolerance of workers with managers; and (4) identifying factors that may affect one's risk tolerance. Fifty-one risk perceptions were gathered through interviews with managers and workers of nine different construction firms in the Pacific Northwest region of the United States. The results indicate that the level of current perceived risk is approximately five times higher than the tolerable risk value, workers are most dissatisfied with the frequency of high severity injuries, and there is a statistically significant difference in the risk tolerance between workers and managers. The findings presented can be used by project managers to increase awareness of risk tolerances, current areas where workers feel improvement is most needed, and for goal setting. Journal: Construction Management and Economics Pages: 403-413 Issue: 4 Volume: 28 Year: 2010 Keywords: Safety, risk, X-DOI: 10.1080/01446191003587752 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003587752 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:4:p:403-413 Template-Type: ReDIF-Article 1.0 Author-Name: Joseph Hung Kit Lai Author-X-Name-First: Joseph Hung Kit Author-X-Name-Last: Lai Title: Operation and maintenance budgeting for commercial buildings in Hong Kong Abstract: The significance of whole-life costs for building operation and maintenance (O&M) is well known. The causes of ill-budgeted O&M resources, however, are often uncertain. An in-depth exploration of the problems with budgeting O&M works for commercial buildings in Hong Kong was carried out, based on interviews with building owners, management companies and O&M contractors. The practice of historical-based budgeting predominates among a variety of budgeting bases, and budgets are largely constrained by preceding budgets and predetermined budget ceilings. Budgetary costs are significant, which can be economized through bundling small contracts into larger procurement packages. The importance of satisfying O&M needs is usually recognized but the motivations of practitioners toward preparation of proper budgets are inadequate. Corresponding to the range of problems identified, a framework of improvement measures is outlined, which requires further development to help achieve proper budgeting for sustainable operation and maintenance of buildings. Journal: Construction Management and Economics Pages: 415-427 Issue: 4 Volume: 28 Year: 2010 Keywords: Budgeting, facilities management, maintenance, cost, X-DOI: 10.1080/01446190903365665 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903365665 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:4:p:415-427 Template-Type: ReDIF-Article 1.0 Author-Name: Nicole Ross Author-X-Name-First: Nicole Author-X-Name-Last: Ross Author-Name: Paul Anthony Bowen Author-X-Name-First: Paul Anthony Author-X-Name-Last: Bowen Author-Name: David Lincoln Author-X-Name-First: David Author-X-Name-Last: Lincoln Title: Sustainable housing for low-income communities: lessons for South Africa in local and other developing world cases Abstract: South Africa's housing backlog continues to grow amid delivery focused more on quantum than on a consideration of the principles of sustainable construction. South Africa needs to move away from its existing poor environmental and housing conditions in the informal and low-income settlements and address its housing backlog by considering all the principles of sustainable construction. Using a case study approach, nine sustainable housing projects across the developing world and South Africa are assessed to draw best practice lessons for the construction of sustainable housing for low-income communities in South Africa. An evaluation framework comprising 49 indicators drawn from the literature is used to assess each case's application of seven principles of sustainable construction. Many sustainable practices have successfully been implemented in the projects reviewed, including energy- and water-efficient systems, the reuse of old buildings, the use of non-toxic products, the preservation of natural vegetation, and the provision of settlements that are dense and well located. Barriers to the implementation of sustainable practices were identified as low levels of user support; initial high costs of certain sustainable measures; and political factors. The 'minimization of materials' was the most widely adopted sustainability criterion, whilst the 'reuse of materials' was the least. User support and acceptability, together with adequate funding, are crucial to the success of sustainable settlements. The results provide lessons for South Africa to address the needs of the poor using a comprehensive sustainability approach. Journal: Construction Management and Economics Pages: 433-449 Issue: 5 Volume: 28 Year: 2010 Keywords: Low-income settlements, sustainable construction, sustainable development, developing world, South Africa, X-DOI: 10.1080/01446190903450079 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903450079 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:5:p:433-449 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Morgan Tuuli Author-X-Name-First: Martin Morgan Author-X-Name-Last: Tuuli Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Author-Name: Tas Yong Koh Author-X-Name-First: Tas Yong Author-X-Name-Last: Koh Title: Control modes and mechanisms in construction project teams: drivers and consequences Abstract: Control is purposive or goal directed, hence, there are underlying drivers and consequences of the exercise of control modes and mechanisms. In response to recent empirical findings that cast doubts on the empowerment-control incompatibility thesis, the broader question of whether control is predominantly 'controlling' or rather supportive in work environments is addressed. Drivers and consequences of control modes and mechanisms in five project teams involved in two ongoing construction projects in Hong Kong are explored. As an interpretive and exploratory study, a qualitative research design and the case study approach in particular was appropriate. Framework, category formation and cross-case analysis techniques were employed to analyse data collected through documentary analysis, passive observations and semi-structured face-to-face interviews. The exercise of control is driven by a range of factors emanating from the individual-, team-, organization- and project-level. Control modes and mechanisms also have performance-related consequences for individuals, teams and organizations and are predominantly attributable to self-based control mechanisms. Preliminary evidence of the important link between self-control/empowerment and performance is therefore provided which is instructive for the performance improvement agenda in the construction industry. Journal: Construction Management and Economics Pages: 451-465 Issue: 5 Volume: 28 Year: 2010 Keywords: Empowerment, drivers of control, Hong Kong, consequences of control, portfolio of control, X-DOI: 10.1080/01446191003702500 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003702500 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:5:p:451-465 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Clare Lingard Author-X-Name-First: Helen Clare Author-X-Name-Last: Lingard Author-Name: Valerie Francis Author-X-Name-First: Valerie Author-X-Name-Last: Francis Author-Name: Michelle Turner Author-X-Name-First: Michelle Author-X-Name-Last: Turner Title: Work-family enrichment in the Australian construction industry: implications for job design Abstract: A survey of waged and salaried, project-based construction workers was conducted. The survey measured work-family enrichment, a type of positive interaction between work and family life. A six-item work-family enrichment scale confirmed the bi-directional nature of work-family enrichment. Job-related correlates of work-to-family enrichment were identified. Flexibility, perceptions of control, time adequacy and supervisor support were all positively correlated with work-to-family enrichment. Regression analyses were performed to examine the extent to which the relationship between these job-related resources and work-to-family enrichment were mediated by perceptions of work schedule fit. Work schedule fit fully mediated the relationship between flexibility and control and work-to-family enrichment. The relationship between supervisor support and time adequacy were only partially mediated by work schedule fit, though a significant mediation effect was still observed. The research suggests that jobs may be designed to facilitate work-family enrichment in the construction industry, in particular through the provision of supervisor support, flexibility, time adequacy and control. Journal: Construction Management and Economics Pages: 467-480 Issue: 5 Volume: 28 Year: 2010 Keywords: Work-family enrichment, supervisor support, flexibility, job design, resources, X-DOI: 10.1080/01446190903511268 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903511268 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:5:p:467-480 Template-Type: ReDIF-Article 1.0 Author-Name: Kate Ness Author-X-Name-First: Kate Author-X-Name-Last: Ness Title: The discourse of 'Respect for People' in UK construction Abstract: Critical discourse analysis (CDA) is mobilized to investigate some of the assumptions that lie behind the text of the Respect for People reports (2000, 2004), part of the 'Egan agenda' in the UK. The concept of respect is examined, contrasting the humanist view of people as ends in themselves with the instrumentalist view in which human beings are treated as means to an end. Conceptualizing people as an asset encourages this instrumental view. Similarly, the 'business case' argument for respecting people means that improvements to working conditions are judged purely in accordance with their contribution to efficiency and profitability rather than in terms of moral imperatives (not killing people) or fairness (not discriminating against them). Investigation of the structural, institutional and discursive context of the text reveals it to be a response to conditions at a particular historical moment: labour shortages; the desire to avoid or pre-empt regulation; changes in the wider prevailing discourse; and the need to give the impression that 'something is being done'. In conclusion it is suggested that, while the Respect for People discourse may be seen as a way of containing and defusing potential critique, it could also be drawn on by those seeking to improve working conditions. Journal: Construction Management and Economics Pages: 481-493 Issue: 5 Volume: 28 Year: 2010 Keywords: Discourse, human resource management, Respect for People, working conditions, labour relations, X-DOI: 10.1080/01446191003674501 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003674501 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:5:p:481-493 Template-Type: ReDIF-Article 1.0 Author-Name: Madelyn Marrero Author-X-Name-First: Madelyn Author-X-Name-Last: Marrero Author-Name: Antonio Ramirez-De-Arellano Author-X-Name-First: Antonio Author-X-Name-Last: Ramirez-De-Arellano Title: The building cost system in Andalusia: application to construction and demolition waste management Abstract: During the last 25 years, a building cost system (BCS) has been developed in Andalusia, Spain. The first step was to generate the Andalusia construction information classification system (ACICS). Not only is ACICS valid as an estimation of cost, but it also provides a common method to manage information during the design and construction of buildings. Another important innovation is that this BCS defines the cost structure which distinguishes between direct and indirect cost and thereby allows a clear definition of all costs for each project type. Its most extended usage is for estimating cost in building projects and it is mandatory in public developments in Andalusia. This is the first time that this system is presented internationally and compared to others. Furthermore, the latest additions to ACICS are explained, and these take into account the waste management of reused and recycled materials in the budget estimate through a new division in the classification: Waste Management. Finally, a new way to address the cost related to construction and demolition waste management is explained which increases precision and generates an estimate independent from the general budget. Journal: Construction Management and Economics Pages: 495-507 Issue: 5 Volume: 28 Year: 2010 Keywords: Cost control, cost estimation, waste, construction information classification system, X-DOI: 10.1080/01446191003735500 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003735500 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:5:p:495-507 Template-Type: ReDIF-Article 1.0 Author-Name: Yakubu Adisa Olawale Author-X-Name-First: Yakubu Adisa Author-X-Name-Last: Olawale Author-Name: Ming Sun Author-X-Name-First: Ming Author-X-Name-Last: Sun Title: Cost and time control of construction projects: inhibiting factors and mitigating measures in practice Abstract: Despite the availability of various control techniques and project control software many construction projects still do not achieve their cost and time objectives. Research in this area so far has mainly been devoted to identifying causes of cost and time overruns. There is limited research geared towards studying factors inhibiting the ability of practitioners to effectively control their projects. To fill this gap, a survey was conducted on 250 construction project organizations in the UK, which was followed by face-to-face interviews with experienced practitioners from 15 of these organizations. The common factors that inhibit both time and cost control during construction projects were first identified. Subsequently 90 mitigating measures have been developed for the top five leading inhibiting factors—design changes, risks/uncertainties, inaccurate evaluation of project time/duration, complexities and non-performance of subcontractors were recommended. These mitigating measures were classified as: preventive, predictive, corrective and organizational measures. They can be used as a checklist of good practice and help project managers to improve the effectiveness of control of their projects. Journal: Construction Management and Economics Pages: 509-526 Issue: 5 Volume: 28 Year: 2010 Keywords: Cost control, interview, practice, project control, project management, X-DOI: 10.1080/01446191003674519 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003674519 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:5:p:509-526 Template-Type: ReDIF-Article 1.0 Author-Name: Abdulaziz Jarkas Author-X-Name-First: Abdulaziz Author-X-Name-Last: Jarkas Title: The influence of buildability factors on rebar fixing labour productivity of beams Abstract: Buildability is one of the most important factors affecting construction labour productivity. Nonetheless, an extensive search of the literature revealed a dearth of research into its effects on in situ reinforced concrete construction, especially at the rebar fixing trade level. Buildability factors affecting rebar fixing labour productivity of major structural elements, such as foundations, columns, walls, beams and slabs, are yet to be investigated and quantified. In comparison with the other constituents of the reinforced concrete frame, rebar fixing in beams is one of the most labour-intensive and time-consuming activities, therefore, the objective of this research is to quantify the effects and relative influence of buildability factors on fixing labour productivity of beams. To achieve this objective, a large volume of productivity data was collected and analysed using the categorical interaction-regression method. As a result, the effects of the variability of beam sizes, rebar diameter, stirrups diameter, reinforcement quantity, beam dimensions, and span geometry are determined. The findings show a significant influence of these factors on the labour efficiency of the fixing operation, which may be used to provide designers and construction managers with feedback on how well the designs of this activity consider the requirements of buildability, and the consequences of designers' decisions on the labour productivity of the operation. In addition, a set of recommendations are presented, which upon implementation, can improve the buildability level of this activity, thus translate into higher labour productivity and more efficient utilization of resources. Journal: Construction Management and Economics Pages: 527-543 Issue: 5 Volume: 28 Year: 2010 Keywords: Reinforced concrete beams, labour productivity, buildability, rebar fixing, characteristic bar diameter, X-DOI: 10.1080/01446191003703482 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003703482 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:5:p:527-543 Template-Type: ReDIF-Article 1.0 Author-Name: Russell Kenley Author-X-Name-First: Russell Author-X-Name-Last: Kenley Title: Construction Cost Management: Learning from Case Studies Abstract: Journal: Construction Management and Economics Pages: 545-546 Issue: 5 Volume: 28 Year: 2010 X-DOI: 10.1080/01446190903552502 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903552502 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:5:p:545-546 Template-Type: ReDIF-Article 1.0 Author-Name: Yu Song Author-X-Name-First: Yu Author-X-Name-Last: Song Title: Building Cycles: Growth and Instability Abstract: Journal: Construction Management and Economics Pages: 546-546 Issue: 5 Volume: 28 Year: 2010 X-DOI: 10.1080/01446191003674493 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003674493 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:5:p:546-546 Template-Type: ReDIF-Article 1.0 Author-Name: Mike Bresnen Author-X-Name-First: Mike Author-X-Name-Last: Bresnen Author-Name: Chris Harty Author-X-Name-First: Chris Author-X-Name-Last: Harty Title: Editorial: objects, knowledge sharing and knowledge transformation in projects Abstract: Journal: Construction Management and Economics Pages: 549-555 Issue: 6 Volume: 28 Year: 2010 X-DOI: 10.1080/01446193.2010.495850 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.495850 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:6:p:549-555 Template-Type: ReDIF-Article 1.0 Author-Name: Jennifer Whyte Author-X-Name-First: Jennifer Author-X-Name-Last: Whyte Author-Name: Sunila Lobo Author-X-Name-First: Sunila Author-X-Name-Last: Lobo Title: Coordination and control in project-based work: digital objects and infrastructures for delivery Abstract: A major infrastructure project is used to investigate the role of digital objects in the coordination of engineering design work. From a practice-based perspective, research emphasizes objects as important in enabling cooperative knowledge work and knowledge sharing. The term 'boundary object' has become used in the analysis of mutual and reciprocal knowledge sharing around physical and digital objects. The aim is to extend this work by analysing the introduction of an extranet into the public-private partnership project used to construct a new motorway. Multiple categories of digital objects are mobilized in coordination across heterogeneous, cross-organizational groups. The main findings are that digital objects provide mechanisms for accountability and control, as well as for mutual and reciprocal knowledge sharing; and that different types of objects are nested, forming a digital infrastructure for project delivery. Reconceptualizing boundary objects as a digital infrastructure for delivery has practical implications for management practices on large projects and for the use of digital tools, such as building information models, in construction. It provides a starting point for future research into the changing nature of digitally enabled coordination in project-based work. Journal: Construction Management and Economics Pages: 557-567 Issue: 6 Volume: 28 Year: 2010 Keywords: Infrastructure, knowledge flows, design process, digital techniques, practice, X-DOI: 10.1080/01446193.2010.486838 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.486838 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:6:p:557-567 Template-Type: ReDIF-Article 1.0 Author-Name: Nicholas Berente Author-X-Name-First: Nicholas Author-X-Name-Last: Berente Author-Name: Ryan Baxter Author-X-Name-First: Ryan Author-X-Name-Last: Baxter Author-Name: Kalle Lyytinen Author-X-Name-First: Kalle Author-X-Name-Last: Lyytinen Title: Dynamics of inter-organizational knowledge creation and information technology use across object worlds: the case of an innovative construction project Abstract: Organizational research argues that under relational forms of governance a high degree of both information pooling and physical interaction are necessary for inter-organizational knowledge creation. Yet, recent studies of information and communication technologies (ICTs) suggest that both practices at the same time are sometimes unnecessary. We address this discrepancy by developing a framework whereby the intensity and proportion of these inter-organizational practices are affected by the object world congruence between designers within and across partnering firms, and the level to which a common information technology platform is embedded in their activity. Through a multi-level case study of a Frank Gehry construction project we illustrate how designers with highly congruent object worlds, due to a strongly embedded common information technology platform, could jointly create knowledge despite decreased physical interaction. Conversely, designers from firms with incongruent object worlds or with congruent object worlds lacking a strongly embedded common ICT platform demanded a higher degree of physical interaction for effective knowledge creation. Our research suggests a dynamic, evolutionary model of inter-organizational knowledge creation influenced by variation in object world congruence and the levels of embedding a common ICT platform. Journal: Construction Management and Economics Pages: 569-588 Issue: 6 Volume: 28 Year: 2010 Keywords: Inter-organizational systems, information pooling, information technology, knowledge creation, project governance, X-DOI: 10.1080/01446193.2010.489926 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.489926 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:6:p:569-588 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Author-Name: Pernilla Gluch Author-X-Name-First: Pernilla Author-X-Name-Last: Gluch Title: Managing knowledge in platforms: boundary objects and stocks and flows of knowledge Abstract: Previous research suggests that construction industry companies use relatively little formal managerial procedures when managing knowledge. Instead, many construction companies are relying on informal networks and social capital as conduits for the sharing of knowledge. However, objects play an important role in organizations as vehicles for the sharing of knowledge. The use of platforms, standardized packages of prescribed components, routines and practices, in a major Scandinavian construction company (SCC), demonstrates that platforms are potentially useful when sharing and accumulating knowledge. The platform concept is a boundary object integrating various functions and activities and standardizing work procedures while at the same time leaving some room for contingencies and local conditions. SCC's use of platforms contributes to the understanding of knowledge sharing practices by emphasizing the role of formally enacted objects and tools and by underlining the need for bridging and bonding the stocks and flows of knowledge in construction companies. Journal: Construction Management and Economics Pages: 589-599 Issue: 6 Volume: 28 Year: 2010 Keywords: Platforms, knowledge sharing, boundary objects, construction, X-DOI: 10.1080/01446190903450061 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903450061 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:6:p:589-599 Template-Type: ReDIF-Article 1.0 Author-Name: Clementinah Ndhlovu Rooke Author-X-Name-First: Clementinah Ndhlovu Author-X-Name-Last: Rooke Author-Name: John Alfred Rooke Author-X-Name-First: John Alfred Author-X-Name-Last: Rooke Author-Name: Lauri Koskela Author-X-Name-First: Lauri Author-X-Name-Last: Koskela Author-Name: Patricia Tzortzopoulos Author-X-Name-First: Patricia Author-X-Name-Last: Tzortzopoulos Title: Using the physical properties of artefacts to manage through-life knowledge flows in the built environment: an initial exploration Abstract: Effective through-life management of built facilities requires effective through-life knowledge management to support it. The KIM (Immortal Information and Through-Life Knowledge Management) project attempted to develop such an approach, based on a dichotomy of knowledge and information. Knowledge is conceived in terms of communities of practice. An initial philosophical analysis demonstrates deficiencies in this conception. Drawing inspiration from production theory, a tripartite analysis is offered, suggesting that knowledge flows consist of: social practices, information and physical properties. Literature on physical properties from design studies, production management and ethnomethodology is briefly reviewed to demonstrate the information bearing functions of physical properties. Fieldwork conforming to the unique adequacy requirement of methods was carried out on construction sites, in hotel and hospital facilities during the use stage of their life cycles. Safety barriers on construction sites were found to have informational properties beyond their function as a physical barrier. The quality of information delivered by wayfinding signs was found to depend upon both the physical placement of the signs in relation to the surrounding environment and the physical layout of the sign itself. It was found that social practices are institutionalized to repair the knowledge flow when the physically instantiated wayfinding system breaks down. Finally, through the investigation of practices surrounding emergency resuscitation equipment, it was found that if the physical properties of information are not designed to mesh with the work practices of the setting, this will lead to a breakdown in the knowledge flow. It is suggested that elements of knowledge management, ethnomethodology, production management and design studies might be integrated to form the basis of a hybrid discipline. Journal: Construction Management and Economics Pages: 601-613 Issue: 6 Volume: 28 Year: 2010 Keywords: Knowledge management, design, through-life management, ethnomethodology, production theory, product-service, X-DOI: 10.1080/01446193.2010.489925 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.489925 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:6:p:601-613 Template-Type: ReDIF-Article 1.0 Author-Name: Mike Bresnen Author-X-Name-First: Mike Author-X-Name-Last: Bresnen Title: Keeping it real? Constituting partnering through boundary objects Abstract: Despite the wealth of research on partnering in construction, comparatively little work has attempted to understand partnering as a socially constructed and emergent phenomenon (Bresnen, 2009). Taking a practice-based approach, this paper deploys the concept of boundary object (e.g. Star and Griesemer, 1989) to explore the mechanisms associated with partnering in the construction industry context. Building upon the observations that such objects are themselves emergent phenomena and can either enable or hinder communication/knowledge sharing, the paper uses exploratory case study research to examine the ways in which the mechanisms used to initiate and develop a partnering relationship (charters, contracts, selection mechanisms and the like) are used to achieve integration across organizational boundaries. The analysis emphasizes the highly situated and localized nature of partnering in practice and assesses the implications for attempts to develop more generic and precise definitions and guidelines for implementing partnering in the industry more widely. Journal: Construction Management and Economics Pages: 615-628 Issue: 6 Volume: 28 Year: 2010 Keywords: Partnering, practice, boundary objects, X-DOI: 10.1080/01446191003587711 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003587711 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:6:p:615-628 Template-Type: ReDIF-Article 1.0 Author-Name: Daniel Sage Author-X-Name-First: Daniel Author-X-Name-Last: Sage Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: Naomi Brookes Author-X-Name-First: Naomi Author-X-Name-Last: Brookes Title: Who reads the project file? Exploring the power effects of knowledge tools in construction project management Abstract: Various critical authors have questioned the salience, efficacy and power effects of formal project management bodies of knowledge (PMBoKs). As a result project management knowledge tools are increasingly being conceptualized along more flexible, adaptable, reflexive, democratic and informal terms. A central driver for this shift is that PM knowledge will be more relevant and useful for practitioners if it can be reflexively tailored to fit local project scenarios, emergent problems and different communities of practice, rather than projects being structured to fit generic 'best practice' ideals. Hence new knowledge tools increasingly would appear critical to alleviate various detrimental power effects associated with bureaucratic knowledge practices within project-based industries, not least construction. This assumption is examined through a study of a formal and codified project management knowledge tool—a project file—within a small team of project practitioners in a large civil engineering consultancy. Various concepts of power related to actor-network theory (ANT) are mobilized to understand how non-human artefacts can enact power and knowledge in nuanced ways within organizations. This theoretically informed study will aid both researchers and practitioners interested in the consequences of developing prescriptive or reflexive project management knowledge within construction contexts and beyond. Journal: Construction Management and Economics Pages: 629-639 Issue: 6 Volume: 28 Year: 2010 Keywords: Knowledge, power, project management, actor-network theory, X-DOI: 10.1080/01446191003725154 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003725154 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:6:p:629-639 Template-Type: ReDIF-Article 1.0 Author-Name: Rachael Luck Author-X-Name-First: Rachael Author-X-Name-Last: Luck Title: Using objects to coordinate design activity in interaction Abstract: The coordination of design is a multi-faceted problem in construction. In design interactions in particular the real-time coordination of design activity is a persistent concern. The use of objects to coordinate the activity of design is studied as this happens in interactions between an architect and a building user group, in a setting where maintaining awareness of the design situation is important. An account of ways in which this was accomplished and how design activity is coordinated through interactional practices is provided. The empirical analyses examine design interaction from an ethnomethodological/conversation analysis (EM/CA) informed perspective to examine: ways in which mutual orientation to design issues are accomplished, how objects can provide a resource for the recognition of the activities of others and ways in which objects might be observable as momentarily intelligible. Subtle interactional practices involving talk, gesture and gaze were some of the small ways in which mutual orientation to the design actions of others became observable. The production of actions sequentially, in response to another's action, marked the real-time coordination of design moves in this setting. The relevance of accounts of micro-interaction to develop understanding of design activity and how it is coordinated are considered. Journal: Construction Management and Economics Pages: 641-655 Issue: 6 Volume: 28 Year: 2010 Keywords: Coordination, design, interaction, objects, talk-in-interaction, X-DOI: 10.1080/01446193.2010.489924 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.489924 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:6:p:641-655 Template-Type: ReDIF-Article 1.0 Author-Name: Libby Schweber Author-X-Name-First: Libby Author-X-Name-Last: Schweber Author-Name: Chris Harty Author-X-Name-First: Chris Author-X-Name-Last: Harty Title: Actors and objects: a socio-technical networks approach to technology uptake in the construction sector Abstract: We explore the contribution of socio-technical networks approaches to construction management research. These approaches are distinctive for their analysis of actors and objects as mutually constituted within socio-technical networks. They raise questions about the ways in which the content, meaning and use of technology is negotiated in practice, how particular technical configurations are elaborated in response to specific problems and why certain paths or solutions are adopted rather than others. We illustrate this general approach with three case studies: a historical study of the development of reinforced concrete in France, the UK and the US, the recent introduction of 3D-CAD software into four firms and an analysis of the uptake of environmental assessment technologies in the UK since 1990. In each we draw out the ways in which various technologies shaped and were shaped by different socio-technical networks. We conclude with a reflection on the contributions of socio-technical network analysis for more general issues including the study of innovation and analyses of context and power. Journal: Construction Management and Economics Pages: 657-674 Issue: 6 Volume: 28 Year: 2010 Keywords: Socio-technical systems, socio-technical networks, CM research, methodology, practice, 3D CAD, reinforced concrete, environmental assessment systems, X-DOI: 10.1080/01446191003702468 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003702468 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:6:p:657-674 Template-Type: ReDIF-Article 1.0 Author-Name: Hans Kjellberg Author-X-Name-First: Hans Author-X-Name-Last: Kjellberg Title: Struggling to perform a warehouse: buildings as symbols and tools Abstract: The built environment and the way in which it is understood critically affect many business enterprises. Despite its importance, few studies have explicitly investigated the process through which changes to the built environment are introduced into ongoing businesses. To this end the methodological principles of the sociology of translation (ANT) were employed to generate a historical account of one such change process. Specifically, the account describes how a major Swedish food wholesaler introduced one-storey warehouses into their operations. This introduction was linked to a transformation of the warehouse as such: in the 1940s the wholesaler viewed its warehouses as symbols ('outward signs of inner strength') while ideas from the US suggested another identity—that of a tool for wholesale operations. The efforts of the wholesaler to realize this new identity included investments in metrologies, organization schemes, and concrete, suggesting that theoretical perspectives on objects are not generally applicable but require perspective-specific investments in 'words and their worlds'. Viewing the realization of an object-perspective as a performation struggle (Callon, 2007) it is suggested that this process of adjustment unfolds through interplay between presenting and re-presenting the world. Journal: Construction Management and Economics Pages: 675-694 Issue: 6 Volume: 28 Year: 2010 Keywords: Measurement, technological change, strategic planning, socio-technical systems, organizational learning, wholesaling, performation, X-DOI: 10.1080/01446191003702476 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003702476 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:6:p:675-694 Template-Type: ReDIF-Article 1.0 Author-Name: Kjell Tryggestad Author-X-Name-First: Kjell Author-X-Name-Last: Tryggestad Author-Name: Susse Georg Author-X-Name-First: Susse Author-X-Name-Last: Georg Author-Name: Tor Hernes Author-X-Name-First: Tor Author-X-Name-Last: Hernes Title: Constructing buildings and design ambitions Abstract: Project goals are conceptualized in the construction management literature as either stable and exogenously given or as emerging endogenously during the construction process. Disparate as these perspectives may be, they both overlook the role that material objects used in construction processes can play in transforming knowledge and thereby shaping project goals. Actor-network theory is used to explore the connection between objects and knowledge with the purpose of developing an adaptive and pragmatic approach to goals in construction. Based on a case study of the construction of a skyscraper, emphasis is given to how design ambitions emerge in a process of goal translation, and to how, once these ambitions are materialized, tensions between aesthetic and functional concerns emerge and are resolved. These tensions are resolved through trials of strength as the object—the building—is elaborated and circulates across sites in various forms, e.g. artistic sketches, drawings and models. Given that initial goal accuracy is often seen as a key success factor, these insights have theoretical and practical implications for the management and evaluation of the construction project. Journal: Construction Management and Economics Pages: 695-705 Issue: 6 Volume: 28 Year: 2010 Keywords: Design ambitions, project goals, knowledge, evaluation, X-DOI: 10.1080/01446191003755441 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003755441 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:6:p:695-705 Template-Type: ReDIF-Article 1.0 Author-Name: Ing Liang Wong Author-X-Name-First: Ing Liang Author-X-Name-Last: Wong Author-Name: Srinath Perera Author-X-Name-First: Srinath Author-X-Name-Last: Perera Author-Name: Philip Eames Author-X-Name-First: Philip Author-X-Name-Last: Eames Title: Goal directed life cycle costing as a method to evaluate the economic feasibility of office buildings with conventional and TI-facades Abstract: Transparent insulation systems (TI-systems) of less than 20cm thick have been developed as an alternative to opaque wall insulation and windows, which provide a financial return to building occupants when applied to building facades. Lack of detailed cost analysis of TI-systems is a major constraint to the application of TI-wall and TI-glazing in buildings. A goal directed life cycle costing (LCC) technique and sensitivity analysis used to evaluate the economic feasibility of TI-applications in office buildings form the basis of this research. It was undertaken as part of research to determine optimum energy and cost performance of TI-systems for external cladding of high-rise and low-rise office buildings in temperate and tropical climates. The LCC of the buildings with conventional facades were compared with those with TI-facades. The results show that LCC can be used to evaluate the economic feasibility of low carbon technologies such as TI-systems effectively. A detailed account is provided of how different sources of cost data can be captured, collected and integrated to perform selective goal directed LCC analysis in the absence of detailed historical LCC data. The use of the goal directed LCC method and cost influence diagram presented in this research can be adopted as a standard method for assessing the economic feasibility of applying low carbon technologies to buildings. Journal: Construction Management and Economics Pages: 715-735 Issue: 7 Volume: 28 Year: 2010 Keywords: Life cycle cost, transparent insulation system, discounted cash flow, cost influence diagrams, X-DOI: 10.1080/01446191003753867 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003753867 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:7:p:715-735 Template-Type: ReDIF-Article 1.0 Author-Name: Duzgun Agdas Author-X-Name-First: Duzgun Author-X-Name-Last: Agdas Author-Name: Ralph Ellis Author-X-Name-First: Ralph Author-X-Name-Last: Ellis Title: The potential of XML technology as an answer to the data interchange problems of the construction industry Abstract: The complex supply chain relations of the construction industry, coupled with the substantial amount of information to be shared on a regular basis between the parties involved, make the traditional paper-based data interchange methods inefficient, error prone and expensive. The successful information technology (IT) applications that enable seamless data interchange, such as the Electronic Data Interchange (EDI) systems, have generally failed to be successfully implemented in the construction industry. An alternative emerging technology, Extensible Markup Language (XML), and its applicability to streamline business processes and to improve data interchange methods within the construction industry are analysed, as is the EDI technology to identify the strategic advantages that XML technology provides to overcome the barriers to implementation. In addition, the successful implementation of XML-based automated data interchange platforms for a large organization, and the proposed benefits thereof, are presented as a case study. Journal: Construction Management and Economics Pages: 737-746 Issue: 7 Volume: 28 Year: 2010 Keywords: Information technology, electronic data interchange, extensible markup language, X-DOI: 10.1080/01446191003767503 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003767503 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:7:p:737-746 Template-Type: ReDIF-Article 1.0 Author-Name: Oluwole Alfred Olatunji Author-X-Name-First: Oluwole Alfred Author-X-Name-Last: Olatunji Title: The impact of oil price regimes on construction cost in Nigeria Abstract: Construction costs in Nigeria are often high and unpredictable. The pattern of variability is not explained by inflationary indices of common goods and services, but rather it is reactive to boom-and-burst shocks that are triggered by oil price regimes. Pearson's correlation analysis is deployed to examine the relationships between the dynamics of crude oil price regimes (volume of crude oil export and price), selected indices of macrovariability—lending rate (prime), inflation rate and aggregate GDP growth, and supply deficit (demand-output gap) of local cement production. Analysis shows that construction cost is high because of high cost of finance and wild volatility that are stimulated by frictions in oil price regimes. Moreover, while the Nigerian construction industry shows positive growth and significant contribution to aggregate GDP growth in the past decade, the oil industry has persistently failed to trigger positive GDP growth. Furthermore, the variables under examination (as listed above) are also subjected to regression analysis to develop a mathematical model for predicting construction costs, relative to crude oil shock and defined macrovariability indices. Recommendations are made on how to avoid multicollinearity in similar studies and for areas of further studies. Journal: Construction Management and Economics Pages: 747-759 Issue: 7 Volume: 28 Year: 2010 Keywords: Oil economics, construction costs, macrovariability, gross domestic product, national income, X-DOI: 10.1080/01446191003725162 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003725162 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:7:p:747-759 Template-Type: ReDIF-Article 1.0 Author-Name: Venny Chandra Author-X-Name-First: Venny Author-X-Name-Last: Chandra Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: Mapping stakeholders' cultural learning in the hospital briefing process Abstract: In the context of a major hospital redevelopment project, briefing is conceived as an organic and cyclical process of cultural learning whereby project and hospital representatives gradually converge upon a shared meaning of each other's values, beliefs and needs over time. Using a comparative cause mapping that draws on a case study approach and interviews, it was found that the clinicians' understanding of the key cultural concepts differed significantly from all other groups and that clinicians' ability to influence hospital design outcomes is constrained by their relative social marginalization in the briefing process. It follows that hospital facilities would better meet client needs if the briefing process is managed as a process through which project participants interact to socially construct a common understanding of project objectives and requirements; and if knowledge about facility requirements is not merely 'given' information but is the result of cultural learning involving social processes among the briefing participants. Journal: Construction Management and Economics Pages: 761-769 Issue: 7 Volume: 28 Year: 2010 Keywords: Briefing, cultural learning, comparative cause mapping, hospital, partnering, X-DOI: 10.1080/01446191003758163 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003758163 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:7:p:761-769 Template-Type: ReDIF-Article 1.0 Author-Name: Salam Al-bizri Author-X-Name-First: Salam Author-X-Name-Last: Al-bizri Author-Name: Colin Gray Author-X-Name-First: Colin Author-X-Name-Last: Gray Title: Management framework for technology clusters implementation Abstract: Much of the construction industry improvement agenda has been focused on achieving integration of the design and construction processes. However, the current approaches do not create an organizational framework to deal with the full integration of the supply chains for component based construction. The real construction supply chain of clients, designers, specialist designers, specialist manufacturers, constructors and assemblers is not integrated into one group with a common purpose. A major and ongoing challenge is to manage the essential grouping of contributors and participants, many of whom are involved for varying times on a relatively short-term basis. Grouping, by using technology clusters, addresses many of these challenges as it creates a commonly shared sub-organization and culture that aids the removal of barriers to efficient and quality production. A technology cluster approach is a management philosophy and its principles can be applied whatever the procurement approach, although managed forms of procurement provide a better framework. Our studies of projects that have adopted a clustering approach have provided an understanding of the implementation issues of technology clusters and established the consequent changes in organizational design and management necessary to achieve full integration of the supply chain. Journal: Construction Management and Economics Pages: 771-782 Issue: 7 Volume: 28 Year: 2010 Keywords: Integration, procurement, supply chain, technology clusters, X-DOI: 10.1080/01446191003725170 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003725170 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:7:p:771-782 Template-Type: ReDIF-Article 1.0 Author-Name: Pertti Lahdenpera Author-X-Name-First: Pertti Author-X-Name-Last: Lahdenpera Title: Conceptualizing a two-stage target-cost arrangement for competitive cooperation Abstract: The owner may involve design and construction service providers in a project at different stages of planning and design. Early involvement of the versatile know-how of service providers places the owner at the services providers' mercy as to pricing. Late involvement, when design is close to completion, allows using price competition to ensure reasonable pricing. Then, design usually does not involve interplay between the key parties to benefit the project. The aim of the conceptualization is to overcome the above-mentioned problem by generating a novel type of two-stage target-cost contracting system which combines early selection and price containment. There the calculated tender price is based on both the owner's estimates and the tenderers' unit cost and overhead data while the project scope is not yet fully established. Selected service providers then develop the project and its designs in cooperation with the owner before the actual target-cost is set. Incentives have been created to lower the target-cost below the earlier calculated tender price. The idea is to spur actors to invest especially in the critical pre-implementation development phase. Subsequent risk sharing is believed to increase the cooperation between parties further. The model offers a means, especially for European public owners, to enter into a cooperative relationship that is of value in the case of projects involving special challenges and a great deal of uncertainty. The European Procurement Act requires costs to be taken into account in the selection. Journal: Construction Management and Economics Pages: 783-796 Issue: 7 Volume: 28 Year: 2010 Keywords: Incentive contracts, target-cost, early contractor involvement, public sector procurement, alliancing, X-DOI: 10.1080/01446193.2010.487534 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.487534 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:7:p:783-796 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Title: The culture of complaint in construction: affirmative reflections on its role and function Abstract: Anecdotal evidence and literature searches suggest that the construction industry is generally portrayed in negative terms; it is conservative, risk-reluctant, unable to produce innovation, and so forth. This 'culture of complaint' occasionally surfacing in talks and writing is examined as what is in essence ideological, that is, rather than being a marginal gesture of little social and cultural significance, complaining is serving as a functional mechanism enabling, inter alia, a sense of community, the warding off of criticism, and to cope with perceived uncertainties. The commonplace dismissal of the construction industry is thus worthy of more systematic scholarly attention. Journal: Construction Management and Economics Pages: 797-803 Issue: 7 Volume: 28 Year: 2010 Keywords: Complaint, organization culture, ideology, X-DOI: 10.1080/01446191003789457 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003789457 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:7:p:797-803 Template-Type: ReDIF-Article 1.0 Author-Name: Sai On Cheung Author-X-Name-First: Sai On Author-X-Name-Last: Cheung Title: Relational Contracting for Construction Excellence: Principles, Practices and Case Studies Abstract: Journal: Construction Management and Economics Pages: 805-806 Issue: 7 Volume: 28 Year: 2010 X-DOI: 10.1080/01446193.2010.488268 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.488268 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:7:p:805-806 Template-Type: ReDIF-Article 1.0 Author-Name: Gonzalo Lizarralde Author-X-Name-First: Gonzalo Author-X-Name-Last: Lizarralde Title: Collaborative Relationships in Construction: Developing Frameworks and Networks Abstract: Journal: Construction Management and Economics Pages: 806-807 Issue: 7 Volume: 28 Year: 2010 X-DOI: 10.1080/01446193.2010.487533 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.487533 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:7:p:806-807 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Clare Lingard Author-X-Name-First: Helen Clare Author-X-Name-Last: Lingard Author-Name: Tracy Cooke Author-X-Name-First: Tracy Author-X-Name-Last: Cooke Author-Name: Nick Blismas Author-X-Name-First: Nick Author-X-Name-Last: Blismas Title: Safety climate in conditions of construction subcontracting: a multi-level analysis Abstract: A multi-level safety climate model was tested in the Australian construction industry. Subcontracted workers' perceptions of the organizational safety response (OSR) and supervisor safety response (SSR) in their own organization and that of the principal contractor were measured using a safety climate survey administered at a large hospital construction project in Melbourne. One hundred and fourteen construction workers completed the survey, representing nine subcontractors engaged at the project. Two requisite conditions for the existence of group-level safety climates, i.e. (1) within-group homogeneity; and (2) between-group variation were satisfied for perceptions of subcontractors' OSR and SSR. This supports the contention that subcontractors working in a single construction project exhibit a unique group-level safety climate. Subcontracted workers also discriminated between group-level safety climates (i.e. the SSR) in their own and in the principal contractor's organizations. The results suggest some cross-level influence. Perceptions of the SSR were positively predicted by perceptions of the OSR in both the principal and subcontractor organizations. Perceptions of the OSR of the principal contractor were also a significant predictor of the perceived OSR and SSR in the subcontractor organizations. Perceptions of the subcontractors' SSR were a significant predictor of the rate of lost-time and medical treatment incidents reported by the subcontractor. Although perceptions of the principal contractor's SSR were not directly related to subcontractors' injury rates, they were a significant predictor of subcontractors' SSR, revealing an indirect link. The results suggest that supervisory personnel (e.g. foremen and leading hands) play an important role in shaping safety performance in subcontracted workgroups. Journal: Construction Management and Economics Pages: 813-825 Issue: 8 Volume: 28 Year: 2010 Keywords: Occupational health and safety, organizational safety response, supervisor safety response, lost-time injuries, medical treatment injuries, X-DOI: 10.1080/01446190903480035 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903480035 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:8:p:813-825 Template-Type: ReDIF-Article 1.0 Author-Name: Shi Chao Fan Author-X-Name-First: Shi Chao Author-X-Name-Last: Fan Author-Name: Qi Ping Shen Author-X-Name-First: Qi Ping Author-X-Name-Last: Shen Author-Name: Xiaochun Luo Author-X-Name-First: Xiaochun Author-X-Name-Last: Luo Title: Group decision support systems in value management Abstract: Value management (VM) practitioners often encounter problems of lack of active participation and insufficient time and information in decision analysis. The use of a group decision support system (GDSS) is proposed to overcome the above problems by improving the efficiency and effectiveness of VM studies. In order to identify the critical success factors (CSFs) for implementing GDSS in VM studies, an experimental study was conducted to simulate the use of GDSS in VM studies, and then a questionnaire survey was conducted to collect the views of the participants. Factor analysis was used to explore the underlying critical success factors, and the results indicated that certain requirements must be met for the successful application of GDSS in VM studies. In particular, a VM team with an appropriate computer skills mix, and GDSS with good utility were believed to be the most significant underlying factors. Besides these, two other factors, system capabilities and experimental settings, should be also considered in order to achieve a successful application of GDSS in VM studies. Journal: Construction Management and Economics Pages: 827-838 Issue: 8 Volume: 28 Year: 2010 Keywords: Value management, case-based reasoning, group decision support system, construction briefing, critical success factors, X-DOI: 10.1080/01446191003758171 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003758171 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:8:p:827-838 Template-Type: ReDIF-Article 1.0 Author-Name: Ahim Kim Author-X-Name-First: Ahim Author-X-Name-Last: Kim Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Title: Performance of minority firms providing construction management services in the US transportation sector Abstract: The preferential selection of minority firms in federally assisted contracts, state contracts and large metropolitan contracts has been in effect in the US for the purpose of meeting affirmative action goals, but this practice has also raised questions about the quality of contract performance. A survey of 93 firms was conducted for a comparative investigation of the performance of minority vs. non-minority construction management (CM) firms. Minority CM firms include firms owned by ethnic minorities, disabled persons and women. An assessment model was developed following an extensive literature review on contemporary performance measurement tools. The model was converted into a survey that was administered to prequalified minority and non-minority firms that provided CM services in the transportation sector in the US. When a Mann-Whitney test was administered to the collected data regardless of firm size and age, it was found that non-minority CM firms outperformed minority CM firms. However, it was also found that minority CM firms were smaller and younger than non-minority CM firms. When 'large and old' minority and non-minority CM firms were compared, no significant differences were found in performance. But when 'small and young' minority and non-minority CM firms were compared, it was found that minority firms were outperformed by non-minority firms financially. It is concluded that 'small and young' minority firms particularly suffer from the liability created by smallness and newness. Journal: Construction Management and Economics Pages: 839-851 Issue: 8 Volume: 28 Year: 2010 Keywords: Construction management services, minority firms, women-owned firms, equal opportunity, diversity, firm performance, X-DOI: 10.1080/01446193.2010.483331 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.483331 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:8:p:839-851 Template-Type: ReDIF-Article 1.0 Author-Name: Tatsiana Haponava Author-X-Name-First: Tatsiana Author-X-Name-Last: Haponava Author-Name: Saad Al-Jibouri Author-X-Name-First: Saad Author-X-Name-Last: Al-Jibouri Title: Influence of process performance during the construction stage on achieving end-project goals Abstract: Within a project environment, good process performance can be seen as indicative of eventual success of achieving end-project goals. A model is proposed for identifying the links between process performance during construction and end-project goals. The model is developed using process mapping technique to identify a number of process-based key performance indicators (KPIs) designed for use in controlling process performance in the construction stage. These KPIs were then linked to generic project goals to measure the perceived degree of influence of process performance on the achievement of end-project goals. The strength of these links within the model was established through a number of in-depth interviews with respondents. Analysis of the results using methods of ranking and statistics has shown that some processes are perceived to have stronger relationships with the end-project goals than others. The proposed process-based KPIs hence offer an opportunity for control of the processes during the construction stage and eventually to influence the projects' outcomes. In addition to the management of project time and cost, the model provides a broader focus of control that includes other multiple aspects such as the management of interactions between internal and external stakeholders as well as of information and quality management. Journal: Construction Management and Economics Pages: 853-869 Issue: 8 Volume: 28 Year: 2010 Keywords: Process performance, key performance indicators, construction stage, control, X-DOI: 10.1080/01446193.2010.487535 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.487535 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:8:p:853-869 Template-Type: ReDIF-Article 1.0 Author-Name: Jasper Kremers Author-X-Name-First: Jasper Author-X-Name-Last: Kremers Author-Name: Bas Rietjens Author-X-Name-First: Bas Author-X-Name-Last: Rietjens Author-Name: Hans Voordijk Author-X-Name-First: Hans Author-X-Name-Last: Voordijk Author-Name: Sirp De Boer Author-X-Name-First: Sirp Author-X-Name-Last: De Boer Title: Construction contracting and civil-military interaction Abstract: There is a need for improved insights into the contracting process for construction projects that the military contract out to civil contractors in the specific setting of civil-military interaction (CMI) in regions that are suffering from instability and armed conflict. The core questions are: what are the key criteria for contracting out CMI projects in out-of-area operations, and what contracting methods are appropriate? First, we discuss possible methods and key criteria for contracting out CMI projects. Following this, a case study based in the Uruzgan province of Afghanistan explores key criteria for contracting out CMI projects. Based on this case study, the following five CMI-related criteria have been identified: generating information on the civilian environment; contributing to building local capacity; process transparency; force acceptance and local participation; and contracting as a tool for stability. These criteria dominate more regular criteria such as cost and time. Some methods frequently used in developed economies, for example the open public tender procedure, seem less appropriate when contracting out CMI projects within a military mission. In CMI projects, contracting most closely resembles the multiple negotiated tender procedure. Future projects can use the identified range of methods and key criteria in designing an improved contracting process. Journal: Construction Management and Economics Pages: 871-883 Issue: 8 Volume: 28 Year: 2010 Keywords: Contracting, tendering, Afghanistan, military mission, criteria, X-DOI: 10.1080/01446191003762256 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003762256 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:8:p:871-883 Template-Type: ReDIF-Article 1.0 Author-Name: Mark Dunlop Taylor Author-X-Name-First: Mark Dunlop Author-X-Name-Last: Taylor Title: A definition and valuation of the UK offsite construction sector Abstract: The offsite construction sector is now established as a significant contributor to the delivery of UK construction industry output. The exact value of this contribution is questionable and has been subject to substantial debate in recent literature. Existing offsite construction sector valuation methodologies have been based upon market research questionnaires and estimates of turnover and manufacturing output. Considerable attention has been given to the definition of the terms used to describe the various constituent technologies and manufacturing processes. However there has been limited reference to its size, sector classification, employment statistics and value added to the UK gross domestic output. A method is presented for the determination of the UK offsite construction sector gross output and value added. Historical data for the period 1998 to 2008 with growth forecasts up to 2013 are offered. A breakdown of the sector, examining the common standard industrial activity classification codes (SIC), the gross output and value added for each sub-sector is provided. The results show that there has been significant underestimation of the gross output and value added when compared to previous studies. An understanding of the broad and diverse nature of the offsite construction sector is provided with data that demonstrate an overview of the sector's historical performance. The data will assist government and industry in benchmarking, market research and forecasting the further growth and diffusion of offsite construction techniques. Journal: Construction Management and Economics Pages: 885-896 Issue: 8 Volume: 28 Year: 2010 Keywords: Offsite construction, prefabrication, gross output, value added, X-DOI: 10.1080/01446193.2010.480976 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.480976 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:8:p:885-896 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Agapiou Author-X-Name-First: Andrew Author-X-Name-Last: Agapiou Title: Labour Conditions for Construction: Decent Work, Building Cities and the Role of Local Authorities Abstract: Journal: Construction Management and Economics Pages: 897-898 Issue: 8 Volume: 28 Year: 2010 X-DOI: 10.1080/01446193.2010.492839 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.492839 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:8:p:897-898 Template-Type: ReDIF-Article 1.0 Author-Name: Richard Fellows Author-X-Name-First: Richard Author-X-Name-Last: Fellows Title: Understanding Organisational Culture in the Construction Industry Abstract: Journal: Construction Management and Economics Pages: 898-900 Issue: 8 Volume: 28 Year: 2010 X-DOI: 10.1080/01446193.2010.498480 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.498480 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:8:p:898-900 Template-Type: ReDIF-Article 1.0 Author-Name: Per Erik Eriksson Author-X-Name-First: Per Erik Author-X-Name-Last: Eriksson Title: Partnering: what is it, when should it be used, and how should it be implemented? Abstract: The interest in construction partnering has increased during the last decade. Much research has, however, found that cooperation and its benefits are not easily obtained, partly due to a lack of understanding of the partnering concept and when and how to implement it. The aim is therefore to increase this understanding by investigating three research questions: (1) What is partnering? (2) When should partnering be used and to what extent? (3) How should partnering be implemented? A thorough literature review and four case studies are utilized to develop a definition of partnering and discuss when and how partnering should be implemented through cooperative procurement procedures. Partnering is defined as a cooperative governance form that is based on core and optional cooperative procurement procedures to such an extent that cooperation-based coopetition is facilitated. Mandatory core procedures are: soft parameters in bid evaluation, compensation form based on open books, and usage of the core collaborative tools start-up workshop, joint objectives, follow-up workshops, teambuilding, and conflict resolution techniques. Complementary optional procedures are: early involvement of contractors in concurrent engineering, limited bid invitation, joint selection and involvement of subcontractors in broad partnering teams, collaborative contractual clauses, incentives based on group performance, usage of complementary collaborative tools (e.g. partnering questionnaire, facilitator, joint risk management, joint project office, and joint IT tools), and increased focus on contractors' self-control. Journal: Construction Management and Economics Pages: 905-917 Issue: 9 Volume: 28 Year: 2010 Keywords: Partnering, procurement, cooperation, governance, case study, X-DOI: 10.1080/01446190903536422 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446190903536422 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:9:p:905-917 Template-Type: ReDIF-Article 1.0 Author-Name: Maria Balatbat Author-X-Name-First: Maria Author-X-Name-Last: Balatbat Author-Name: Cho-yi Lin Author-X-Name-First: Cho-yi Author-X-Name-Last: Lin Author-Name: David Carmichael Author-X-Name-First: David Author-X-Name-Last: Carmichael Title: Comparative performance of publicly listed construction companies: Australian evidence Abstract: Understanding the performance of publicly listed Australian construction companies, in comparison with other Australian listed companies, is vital to the construction sector's continuous access to capital from the public equity market. Evidence on the performance of construction companies that do business in building and/or civil infrastructure is presented and compared with the Australian All Ordinaries Index and a portfolio of publicly listed (blue chip) companies. Using fundamental analysis, a comprehensive assessment on a range of financial and performance indicators is provided (including share prices, equity valuation multiples and profitability ratios) over the 10-year period, 1998 to 2007. The results show that, apart from the period when the Goods and Services Tax was introduced in 2000, the performance of publicly listed Australian construction companies in most of the indicators assessed is comparable to the largest traded shares on the Australian Securities Exchange. The empirical evidence is encouraging and could potentially elicit interest and confidence for investors to invest in construction companies. Journal: Construction Management and Economics Pages: 919-932 Issue: 9 Volume: 28 Year: 2010 Keywords: Financial ratios, company performance, market performance, X-DOI: 10.1080/01446193.2010.501805 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.501805 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:9:p:919-932 Template-Type: ReDIF-Article 1.0 Author-Name: Yan Li Author-X-Name-First: Yan Author-X-Name-Last: Li Author-Name: Chunlu Liu Author-X-Name-First: Chunlu Author-X-Name-Last: Liu Title: Malmquist indices of total factor productivity changes in the Australian construction industry Abstract: Construction is an important industry and forms a vital part of national economics in the world. Factors affecting the productivity of the construction industry should be measured appropriately to reflect its development situation and economic performance. The Malmquist index method with a novel decomposition technique is employed to estimate the total factor productivity of the Australian construction industry during the period 1990-2007 and to analyse the factors affecting the technological change in the industry. Research results exemplified by two input variables and one output variable elaborate how construction technology, pure technical efficiency and scale economy take effect in the change of construction productivity. In addition, based on temporal and spatial comparisons, the analysis for construction productivities reveals their changes over time and across the country. Proposals and recommendations are expected to be beneficial for policy making and strategic decisions to improve the performance of the Australian construction industry. Journal: Construction Management and Economics Pages: 933-945 Issue: 9 Volume: 28 Year: 2010 Keywords: Australia, construction industry, data analysis envelopment, Malmquist total factor productivity, X-DOI: 10.1080/01446191003762231 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003762231 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:9:p:933-945 Template-Type: ReDIF-Article 1.0 Author-Name: Yu-lin Huang Author-X-Name-First: Yu-lin Author-X-Name-Last: Huang Author-Name: Wei Lin Author-X-Name-First: Wei Author-X-Name-Last: Lin Title: Does debt structure matter? Estimating contractor default barrier by the down-and-out call option approach Abstract: The down-and-out call option approach was used to analyse contractor financial risk under shorter-term debt structures. The maximum likelihood method was applied to estimate contractor default barriers and probabilities implied by stock prices series and actual debt maturities calculated from historical debt data. Results indicate that the default barriers implied by shorter-term debt structures are higher than previous estimates using longer-term debt structures. Further regression analysis shows that implied barriers do not reflect the full effects of asset quality in ameliorating financial distress. Hence, the implied default barriers tend to be higher than the actual default barriers. When applying the DOC approach, if the implied barrier is not calibrated to reflect the borrower's asset quality, the barrier will tend to overestimate default probability. This has important implications on contractor financial risk monitoring, security pricing and short-term financial planning. Journal: Construction Management and Economics Pages: 947-958 Issue: 9 Volume: 28 Year: 2010 Keywords: Financial risk, down-and-out call option, maximum likelihood method, regression analysis, financial planning, X-DOI: 10.1080/01446191003762264 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003762264 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:9:p:947-958 Template-Type: ReDIF-Article 1.0 Author-Name: Yat-Hung Chiang Author-X-Name-First: Yat-Hung Author-X-Name-Last: Chiang Author-Name: Eddie Cheng Author-X-Name-First: Eddie Author-X-Name-Last: Cheng Title: Construction loans and industry development: the case of Hong Kong Abstract: Building contractors are generally small private firms. Bank loans are their major, if not only, source of external finance. However, building and construction loans represent a mere minuscule portion of all bank loans in Hong Kong, suggesting that contractors may have been neglected by banks. With the case of Hong Kong, this study examines the lack of supply and demand of construction finance, and the implications for industry competition and innovation. Contractors' perceptions were solicited through a questionnaire survey. Key issues identified were further explored in subsequent interviews. The results were then triangulated with secondary data. It is found that although contractors do not usually have enough assets to pledge as collateral, they generally do not need to borrow that much. The provision of interim payments has enabled them to work with small capital outlay. However, the interim payment mechanism has induced a low barrier to entry, which has helped perpetuate the vicious circle of labour intensiveness of building construction, exploitation of labour-only subcontracting, proliferation of small subcontractors and intense rivalry between firms. The findings conclude that contractors' limited access to finance generally and bank loans in particular has posed a major barrier to innovation and hence industry development. Journal: Construction Management and Economics Pages: 959-969 Issue: 9 Volume: 28 Year: 2010 Keywords: Construction companies, finance, industry development, Hong Kong, X-DOI: 10.1080/01446193.2010.494679 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.494679 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:9:p:959-969 Template-Type: ReDIF-Article 1.0 Author-Name: Timothy Jones Author-X-Name-First: Timothy Author-X-Name-Last: Jones Author-Name: Yongwei Shan Author-X-Name-First: Yongwei Author-X-Name-Last: Shan Author-Name: Paul Goodrum Author-X-Name-First: Paul Author-X-Name-Last: Goodrum Title: An investigation of corporate approaches to sustainability in the US engineering and construction industry Abstract: Sustainability involves focusing on a project's impact in three areas: (1) environmental; (2) economical; and (3) societal. In reality, companies' approaches in the three areas are not evenly distributed. A study of current trends in the US construction industry related to the emerging focus on sustainable construction will be of great value for the engineering and construction industry to recognize the differences in corporate approaches to sustainability, for the sake of team alignment. A random cross-section of 300 companies, consisting of 150 owner companies, 75 contractor companies and 75 design firms representing a variety of industries, was selected from annual company data assembled by the weekly construction news publication Engineering News Record (ENR). To identify sustainability-related concepts within the context of these company documents, content analyses and chi-square statistical analyses were performed on the selected companies' publicly available annual reports and mission/vision/values statements. The primary objectives are to: (1) identify concepts of sustainability that are currently being emphasized within the US engineering and construction industry, possibly at the expense of other concepts; and (2) develop an understanding of the relationships between various company and industry groups related to the fundamental concepts of sustainable construction. Journal: Construction Management and Economics Pages: 971-983 Issue: 9 Volume: 28 Year: 2010 Keywords: Sustainability, society, economic, environment, content analysis, X-DOI: 10.1080/01446191003789465 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003789465 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:9:p:971-983 Template-Type: ReDIF-Article 1.0 Author-Name: Jouko Lennart Lehtonen Author-X-Name-First: Jouko Lennart Author-X-Name-Last: Lehtonen Author-Name: Juhani Matti Kiiras Author-X-Name-First: Juhani Matti Author-X-Name-Last: Kiiras Title: Cost modelling in underpinning projects Abstract: Large refurbishment projects are characterized by highly varied costs from one project to another. In Finnish underpinning, only retrospective analysis of costs has been available for the owner's decision process. In order to develop tools for pre-tender cost estimating and for comparison of different design solutions and evaluation of tenders of the underpinning project, two different cost models have been developed for research. In both models developed, the minimum data required is the pile length. In the more detailed model, the assessment is based on the design solution, including known pile types and the load transfer classification. Both models are easy to use, and the percentage of explained variance is fairly good in the more detailed model. Journal: Construction Management and Economics Pages: 985-995 Issue: 9 Volume: 28 Year: 2010 Keywords: Cost modelling, refurbishment, underpinning, X-DOI: 10.1080/01446193.2010.487537 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.487537 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:9:p:985-995 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Author-Name: Keith Cattell Author-X-Name-First: Keith Author-X-Name-Last: Cattell Author-Name: Peter Edwards Author-X-Name-First: Peter Author-X-Name-Last: Edwards Author-Name: Jonathan Marks Author-X-Name-First: Jonathan Author-X-Name-Last: Marks Title: Perceptions of HIV/AIDS policies and treatment programmes by Western Cape construction firms Abstract: The HIV/AIDS pandemic poses a substantial long-term threat to economic development in South Africa. A questionnaire survey explored the perceptions of a sample of construction firms in the Western Cape regarding HIV/AIDS policy and treatment programmes. The findings show that there is no universal view about the long-term threat of HIV/AIDS. Most organizations have awareness policies in place but prevention and treatment policies are less common. Treatment programmes are the least implemented of all intervention services due to insufficient resource capacity, the potential stigmatization of infected persons, and low take-up rates. Despite an acknowledgement of the benefits flowing from mounting treatment programmes, doubt exists as to their financial viability. Journal: Construction Management and Economics Pages: 997-1006 Issue: 9 Volume: 28 Year: 2010 Keywords: HIV/AIDS, treatment programmes, construction organizations, South Africa, X-DOI: 10.1080/01446193.2010.495987 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.495987 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:9:p:997-1006 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Atkinson Author-X-Name-First: Andrew Author-X-Name-Last: Atkinson Author-Name: Rebecca Westall Author-X-Name-First: Rebecca Author-X-Name-Last: Westall Title: The relationship between integrated design and construction and safety on construction projects Abstract: The occurrence of accidents and injuries continues to be a major problem in construction worldwide. Even though accident statistics have been improving in most markets there are significant areas requiring further attention. The extent of integrated working between designers and constructors may be an instrumental factor. A comparison is undertaken of the accident performance of 55 large construction projects in the UK, with varying levels of design/construction integration as represented by procurement path. Although a statistical relationship between high levels of integration and low levels of accidents was weak, a follow-up interview study provided strong support, suggesting that a lack of significance was related to the unreliability of the statistics available. The interview study also indicated reasons for this link. A key element in improved safety was seen to be better communications and a more positive relationship between designers and constructors. Further research into designing for safety for all procurement paths is recommended. Journal: Construction Management and Economics Pages: 1007-1017 Issue: 9 Volume: 28 Year: 2010 Keywords: Safety, accidents, integrated working, architectural design, X-DOI: 10.1080/01446193.2010.504214 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.504214 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:9:p:1007-1017 Template-Type: ReDIF-Article 1.0 Author-Name: Lara Jaillon Author-X-Name-First: Lara Author-X-Name-Last: Jaillon Author-Name: Chi-Sun Poon Author-X-Name-First: Chi-Sun Author-X-Name-Last: Poon Title: Design issues of using prefabrication in Hong Kong building construction Abstract: Prefabrication techniques have been adopted for the last two decades in public housing projects in Hong Kong, but the use of prefabrication in the private sector was encouraged only after the implementation of the Joint Practices Notes which promote its use. Although previous studies acknowledge the environmental benefits of using prefabrication, only a few studies have addressed sustainable design concepts (closed-loop) in the adoption of precast construction. A questionnaire survey was administered to experienced Hong Kong construction professionals, and case studies of recently completed building projects were compiled to ascertain the use of prefabrication with reference to life cycle approach. The findings revealed that prefabrication, combined with modular design and standard components, saved time and construction/design costs, as buildings systems were used across projects. However, in some projects, specific site conditions restricted the use of similar prefabricated building systems across projects. Surprisingly only a few participants addressed life cycle design concepts such as design for deconstruction when adopting precast construction. Also, although it is common knowledge that flexible and demountable prefabricated building systems would result in efficient use of resources, their use is seldom practised in Hong Kong. Journal: Construction Management and Economics Pages: 1025-1042 Issue: 10 Volume: 28 Year: 2010 Keywords: Hong Kong, life cycle design, prefabrication, precast concrete, sustainable construction, X-DOI: 10.1080/01446193.2010.498481 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.498481 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:10:p:1025-1042 Template-Type: ReDIF-Article 1.0 Author-Name: Sutapa Das Author-X-Name-First: Sutapa Author-X-Name-Last: Das Author-Name: M. Y. L. Chew Author-X-Name-First: M. Y. L. Author-X-Name-Last: Chew Author-Name: Kim Leng Poh Author-X-Name-First: Kim Leng Author-X-Name-Last: Poh Title: Multi-criteria decision analysis in building maintainability using analytical hierarchy process Abstract: A building maintainability (BM) approach is the only plausible solution to balance a decreasing budget and increasing standards of modern commercial buildings. There is no decision-analysis framework for BM management while many objective and subjective parameters add to its complexity and hinder direct comparison of various building systems contributing to overall BM. A model was developed to compare nine major building systems, namely: basement, facade, wet area, roof, sanitary plumbing, HVAC, elevator, electrical and fire protection system. Analytical hierarchy process was chosen to address complex BM parameters. From a questionnaire survey and face-to-face interviews with 37 experts in facilities management, BM was found to depend on technical viability of services and business profile controlled by building height and location respectively. For various location-height combinations, individual sets of priorities were derived for each building system and the results were supported logically. HVAC was the highest contributor to BM followed by elevator and facade. The proposed generic method can be directly applied to both new and existing commercial buildings in Singapore and extended to other building types or climate. This precise but simple platform for multi-criteria decision analysis promises higher BM and economic returns for any commercial property. Journal: Construction Management and Economics Pages: 1043-1056 Issue: 10 Volume: 28 Year: 2010 Keywords: Analytical hierarchy process, building maintainability, commercial property, decision analysis, facilities management, X-DOI: 10.1080/01446193.2010.501806 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.501806 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:10:p:1043-1056 Template-Type: ReDIF-Article 1.0 Author-Name: Liang Shan Author-X-Name-First: Liang Author-X-Name-Last: Shan Author-Name: Michael Garvin Author-X-Name-First: Michael Author-X-Name-Last: Garvin Author-Name: Raman Kumar Author-X-Name-First: Raman Author-X-Name-Last: Kumar Title: Collar options to manage revenue risks in real toll public-private partnership transportation projects Abstract: The revenue risk is of great importance to ensure the success of a real toll public-private partnership (PPP) transportation project. Past research has proposed a revenue guarantee put option as an alternative way to quantify and potentially manage this risk. A practical, or commercial, limitation of this type of option is its requirement for an upfront premium payment, and a concessionaire is likely to shy away from additional monetary requirements. A collar option, which is a combination of a put and call option, not only overcomes this barrier but it also provides other benefits. Modifications to the basic collar's structure can redistribute downside losses and upside profits to fulfil stakeholders' needs and thus improve the effectiveness of risk management. The terms, applicability and limitations of a collar option are discussed, and a numerical example is developed to illustrate how to determine the strike prices of a collar option. Journal: Construction Management and Economics Pages: 1057-1069 Issue: 10 Volume: 28 Year: 2010 Keywords: Infrastructure, public-private partnerships, real options, revenue risk, risk management, X-DOI: 10.1080/01446193.2010.506645 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.506645 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:10:p:1057-1069 Template-Type: ReDIF-Article 1.0 Author-Name: Fredrik Nordin Author-X-Name-First: Fredrik Author-X-Name-Last: Nordin Author-Name: Christina Oberg Author-X-Name-First: Christina Author-X-Name-Last: Oberg Author-Name: Beata Kollberg Author-X-Name-First: Beata Author-X-Name-Last: Kollberg Author-Name: Tomas Nord Author-X-Name-First: Tomas Author-X-Name-Last: Nord Title: Building a new supply chain position: an exploratory study of companies in the timber housing industry Abstract: Innovation is an important source of growth for many companies. It is also challenging, as it may require that the companies build a new position in the supply chain. The literature is devoid of analysis of different ways to build such positions in the construction industry. The purpose here is to explore the challenges involved in implementing innovations that require companies to establish new positions in a construction supply chain. Three in-depth case studies in the Swedish timber housing industry illustrate different challenges that arise with the different modes of repositioning of organic growth, collaboration and acquisition, and with moving either backward or forward in the supply chain. Organic growth is a slow process that prevents companies from taking a first-mover advantage. Acquisitions can involve difficulties with exploiting acquired competences. Collaboration brings the risks of diversity of interests and transient solutions. Furthermore, and as shown in the cases studied, challenges are associated with pre-existing competencies and relationships, with technology-oriented companies facing customer-related difficulties and market-oriented companies mainly facing ones involving technological solutions. The construction industry's idiosyncrasies amplify these challenges, as its fragmentation makes it difficult to connect with external companies at new positions. Stronger ties with business partners are likely to enable construction companies to exploit more easily innovations that require repositioning in the supply chain. Journal: Construction Management and Economics Pages: 1071-1083 Issue: 10 Volume: 28 Year: 2010 Keywords: Innovation, supply chain management, case study, Sweden, X-DOI: 10.1080/01446193.2010.494680 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.494680 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:10:p:1071-1083 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Clare Lingard Author-X-Name-First: Helen Clare Author-X-Name-Last: Lingard Author-Name: Valerie Francis Author-X-Name-First: Valerie Author-X-Name-Last: Francis Author-Name: Michelle Turner Author-X-Name-First: Michelle Author-X-Name-Last: Turner Title: The rhythms of project life: a longitudinal analysis of work hours and work-life experiences in construction Abstract: A diary data collection method was used to collect data from project-based construction workers in a large civil engineering construction project in Melbourne, Australia. Data capturing the number of hours worked, satisfaction with work-life balance and capacity to complete required tasks at work and at home were collected for 21 consecutive weeks. A strong correlation was found between hours worked each week and participants' work-life experiences. Data were subjected to time series modelling procedures and weekly work hours were found to significantly predict participants' capacity to complete tasks at work and at home, but not their satisfaction with work-life balance. The impact of work leading up to a major project milestone was found to increase the predictive capacity of the time series models, indicating that project events have a significant impact upon the work-life experiences of project-based workers. The period of intense work prior to the milestone (the opening of a new ramp on to an operating freeway) contributed significantly to an immediate reduction in capacity to complete tasks at home. Further time series modelling revealed that recovery opportunities associated with workers taking a short, temporary break from work can also contribute to improved work-life balance. It is proposed that construction organizations use the naturally fluctuating workloads implicit in project work to 'build' recovery opportunities into project schedules. Journal: Construction Management and Economics Pages: 1085-1098 Issue: 10 Volume: 28 Year: 2010 Keywords: Work hours, work-family balance, diary studies, project work, X-DOI: 10.1080/01446193.2010.480977 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.480977 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:10:p:1085-1098 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Clare Lingard Author-X-Name-First: Helen Clare Author-X-Name-Last: Lingard Author-Name: Tracy Cooke Author-X-Name-First: Tracy Author-X-Name-Last: Cooke Author-Name: Nick Blismas Author-X-Name-First: Nick Author-X-Name-Last: Blismas Title: Properties of group safety climate in construction: the development and evaluation of a typology Abstract: A safety climate survey was conducted in three Australian construction industry organizations. Workers' perceptions of their supervisors' safety response (SSR) and co-workers' safety response (CSR) were measured as facets of group safety climate. A two-dimensional schema was developed based upon the strength and the level of group safety climate. The resulting framework was used to position the 40 workgroups included in the sample within one of four group safety climate types. A non-parametric Kruskal Wallis test revealed that workgroups in which members share a strong consensus that co-workers should treat safety as a priority had a significantly lower injury frequency rate than other workgroups in the sample. While no significant differences between the injury frequency rates of workgroups positioned in the four safety climate types were found for the other facets of group safety climate, workgroups with strong and high (i.e. strongly supportive) safety climates related to supervisors' safety expectations and co-workers' actual safety behaviour reported injury frequency rates on average two-thirds the magnitude of the remaining workgroups in the sample. Although limited by the reliance on retrospective and insensitive measurement for the dependent variable (i.e. injury frequency rates), the research provides preliminary evidence for the importance of considering both the strength and level of group safety climates in the construction industry. Future research should seek to replicate and extend this research by examining the antecedents of group safety climate strength and level in the construction context. Journal: Construction Management and Economics Pages: 1099-1112 Issue: 10 Volume: 28 Year: 2010 Keywords: Group safety climate, supervisors' safety response, co-workers' safety response, climate strength, climate level, X-DOI: 10.1080/01446193.2010.501807 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.501807 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:10:p:1099-1112 Template-Type: ReDIF-Article 1.0 Author-Name: Douglas Gransberg Author-X-Name-First: Douglas Author-X-Name-Last: Gransberg Title: Life Cycle Costing for Engineers Abstract: Journal: Construction Management and Economics Pages: 1113-1114 Issue: 10 Volume: 28 Year: 2010 X-DOI: 10.1080/01446193.2010.508500 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.508500 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:10:p:1113-1114 Template-Type: ReDIF-Article 1.0 Author-Name: Graeme Larsen Author-X-Name-First: Graeme Author-X-Name-Last: Larsen Title: Managing Construction Projects (2nd edition) Abstract: Journal: Construction Management and Economics Pages: 1115-1116 Issue: 10 Volume: 28 Year: 2010 X-DOI: 10.1080/01446193.2010.513397 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.513397 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:10:p:1115-1116 Template-Type: ReDIF-Article 1.0 Author-Name: John Twyford Author-X-Name-First: John Author-X-Name-Last: Twyford Title: Building Law Encyclopaedia Abstract: Journal: Construction Management and Economics Pages: 1117-1117 Issue: 10 Volume: 28 Year: 2010 X-DOI: 10.1080/01446193.2010.517775 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.517775 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:10:p:1117-1117 Template-Type: ReDIF-Article 1.0 Author-Name: David Alexander Author-X-Name-First: David Author-X-Name-Last: Alexander Title: Rebuilding after Disasters: From Emergency to Sustainability Abstract: Journal: Construction Management and Economics Pages: 1117-1119 Issue: 10 Volume: 28 Year: 2010 X-DOI: 10.1080/01446193.2010.517776 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.517776 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:10:p:1117-1119 Template-Type: ReDIF-Article 1.0 Author-Name: Roine Leiringer Author-X-Name-First: Roine Author-X-Name-Last: Leiringer Author-Name: Jan Brochner Author-X-Name-First: Jan Author-X-Name-Last: Brochner Title: Editorial: service-led construction projects Abstract: Journal: Construction Management and Economics Pages: 1123-1129 Issue: 11 Volume: 28 Year: 2010 X-DOI: 10.1080/01446193.2010.532591 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.532591 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:11:p:1123-1129 Template-Type: ReDIF-Article 1.0 Author-Name: Neil Alderman Author-X-Name-First: Neil Author-X-Name-Last: Alderman Author-Name: Chris Ivory Author-X-Name-First: Chris Author-X-Name-Last: Ivory Title: Service-led projects: understanding the meta-project context Abstract: The service-led project is driven by the demand for long-term service provision based on the output of a conventional capital good. The project management implications of the extended timeframe for such projects are considered and the added risks and uncertainties associated with planning for an unknown future business environment. Detailed case studies of three service-led engineering projects in the context of port facilities, high-speed trains and sludge treatment are examined. The findings indicate that service-led projects exist within the context of a meta-project that encompasses a consideration of critical activities beyond the normal remit of the project manager. Aligning project stakeholders around a vision for the meta-project becomes a key task in the successful management of the service-led project. Journal: Construction Management and Economics Pages: 1131-1143 Issue: 11 Volume: 28 Year: 2010 Keywords: Service-led projects, networks, integration, project management, meta-project vision, X-DOI: 10.1080/01446193.2010.506644 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.506644 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:11:p:1131-1143 Template-Type: ReDIF-Article 1.0 Author-Name: Hans Lind Author-X-Name-First: Hans Author-X-Name-Last: Lind Author-Name: Lena Borg Author-X-Name-First: Lena Author-X-Name-Last: Borg Title: Service-led construction: is it really the future? Abstract: In recent years it has been argued that bundling construction with operation/maintenance can increase profits in the construction sector. This idea is critically evaluated using different theoretical frameworks and the main points are: innovative organizational models only lead to higher profits in the short run, unless the firm can reduce long-run competition. Many firms should however be able to bundle construction and maintenance. Several arguments have been put forward for the proposition that bundling is more efficient, but none of them are very strong. Knowledge about the construction phase is difficult to transfer also within firms, and it is not clear how a construction firm can build up knowledge of the long-run effects of different construction alternatives. A long-run contract for certain services is—just as a construction contract—difficult to write in a way that does not lead to surprises and future problems, so the gain from this perspective is not clear. The initiative for bundling came from the public sector; it was not an innovation from the private sector looking for higher profits. The motives for the public sector seem more related to financing and risk for cost overruns and delays. Taking over risk leads to higher profits, but this is just compensation for the risk and nothing more, if it is a competitive market. Journal: Construction Management and Economics Pages: 1145-1153 Issue: 11 Volume: 28 Year: 2010 Keywords: Service-led construction, bundling, PPP, PFI, X-DOI: 10.1080/01446193.2010.529452 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.529452 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:11:p:1145-1153 Template-Type: ReDIF-Article 1.0 Author-Name: Jens Roehrich Author-X-Name-First: Jens Author-X-Name-Last: Roehrich Author-Name: Michael Lewis Author-X-Name-First: Michael Author-X-Name-Last: Lewis Title: Towards a model of governance in complex (product-service) inter-organizational systems Abstract: Traditional business models coped with the complexity inherent in buying complex capital assets that will be operated and maintained over many years by a division of labour based on subsets of the value chain. Recently, customers in a wide range of sectors are not buying subcontract production or construction capacity but procuring business 'solutions'. As a result, inter-organizational interactions are changing in terms of their scale, scope and dynamic, requiring us to reconsider those mechanisms that coordinate inter-organizational behaviour. Correspondingly, a conceptual model is developed that explores how contractual and relational mechanisms interact across different levels of analysis and over time. Reflecting on the implications of the model highlights how contractual and relational governance mechanisms are distinct but inseparable parts of a governance continuum, involving multi-level interactions and transitions. Given that these interactions/transitions influence the behaviour of exchange partners and impact on the effectiveness of the overall governance mix, these (albeit conceptual) insights should be beneficial to academics, practitioners and policy makers involved in complex product-service systems. Journal: Construction Management and Economics Pages: 1155-1164 Issue: 11 Volume: 28 Year: 2010 Keywords: Product-service systems, inter-organizational governance, contracts, trust, complexity, X-DOI: 10.1080/01446191003762249 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003762249 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:11:p:1155-1164 Template-Type: ReDIF-Article 1.0 Author-Name: Andreas Hartmann Author-X-Name-First: Andreas Author-X-Name-Last: Hartmann Author-Name: Andrew Davies Author-X-Name-First: Andrew Author-X-Name-Last: Davies Author-Name: Lars Frederiksen Author-X-Name-First: Lars Author-X-Name-Last: Frederiksen Title: Learning to deliver service-enhanced public infrastructure: balancing contractual and relational capabilities Abstract: Public agencies in construction increasingly involve the private sector in the provision of various public goods and services. With the extension of private sector involvement, public agencies are confronted with the need to acquire new capabilities. The results of two comparative case studies from the UK and the Netherlands show that the level and focus of capability learning change over time. Public agencies follow different learning trajectories and need to address the dynamic character of the learning in order to successfully employ (a) contractual and (b) relational capabilities in their exchange relationships. Journal: Construction Management and Economics Pages: 1165-1175 Issue: 11 Volume: 28 Year: 2010 Keywords: Capability building, learning trajectory, public agency, X-DOI: 10.1080/01446193.2010.521942 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.521942 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:11:p:1165-1175 Template-Type: ReDIF-Article 1.0 Author-Name: Mieke Hoezen Author-X-Name-First: Mieke Author-X-Name-Last: Hoezen Author-Name: John van Rutten Author-X-Name-First: John Author-X-Name-Last: van Rutten Author-Name: Hans Voordijk Author-X-Name-First: Hans Author-X-Name-Last: Voordijk Author-Name: Geert Dewulf Author-X-Name-First: Geert Author-X-Name-Last: Dewulf Title: Towards better customized service-led contracts through the competitive dialogue procedure Abstract: Recently, for the procurement of complex contracts the European Commission (EC) has developed the competitive dialogue (CD) procedure, a procurement system aimed at aligning the complex demands of principals with the possible solutions of contractors. The major question is how, in the practice of procuring service-led contracts by the CD procedure, will the dialogue conversations be affected by tension between the CD procedure's principles of transparency and confidentiality? A single case study of a large infrastructural project procured through the CD procedure has been conducted to find an answer to this question. It is concluded that the dialogue offered by the CD procedure in the Dutch Second Coen Tunnel project helped to align the complex demands with the several available solutions without harming the confidentiality principle or stimulating cherry picking. The procedure could be improved by the provision of standardized documents and actual, adequate and improved information about the project context. Journal: Construction Management and Economics Pages: 1177-1186 Issue: 11 Volume: 28 Year: 2010 Keywords: Contractor selection, infrastructure, procurement, X-DOI: 10.1080/01446193.2010.506517 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.506517 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:11:p:1177-1186 Template-Type: ReDIF-Article 1.0 Author-Name: Ad Straub Author-X-Name-First: Ad Author-X-Name-Last: Straub Title: Competences of maintenance service suppliers servicing end-customers Abstract: Service-led construction projects imply major changes in methods and work processes for contractors and a need to reorganize the contracting company. A major change within a performance-based approach is that contractors act as maintenance-engineering consultants to clients and as service providers to end-customers. Offering new services demands additional resources, skills and competences of contractors. In performance-based maintenance partnerships contractors have the responsibility for the agreed performance of building components and clients' and end-customers' satisfaction during the entire contract period by handling planned and reactive maintenance. End-customers are particularly concerned with reactive or daily maintenance. Satisfaction is affected by the result of maintenance and especially the maintenance service delivery process. Maintenance contractors need knowledge about concepts such as whole-life costing, key performance indicators and service levels, and need communication and empathy skills, especially in dealing with end-customers. Journal: Construction Management and Economics Pages: 1187-1195 Issue: 11 Volume: 28 Year: 2010 Keywords: Competences, end-customers, maintenance, performance-based projects, service delivery, X-DOI: 10.1080/01446193.2010.500672 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.500672 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:11:p:1187-1195 Template-Type: ReDIF-Article 1.0 Author-Name: Per Erik Eriksson Author-X-Name-First: Per Erik Author-X-Name-Last: Eriksson Title: Understanding the Construction Client Abstract: Journal: Construction Management and Economics Pages: 1197-1198 Issue: 11 Volume: 28 Year: 2010 X-DOI: 10.1080/01446191003702450 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446191003702450 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:11:p:1197-1198 Template-Type: ReDIF-Article 1.0 Author-Name: Scott Fernie Author-X-Name-First: Scott Author-X-Name-Last: Fernie Title: Clients Driving Innovation Abstract: Journal: Construction Management and Economics Pages: 1198-1199 Issue: 11 Volume: 28 Year: 2010 X-DOI: 10.1080/01446193.2010.509401 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.509401 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:11:p:1198-1199 Template-Type: ReDIF-Article 1.0 Author-Name: Ahmed El-Sheikh Author-X-Name-First: Ahmed Author-X-Name-Last: El-Sheikh Author-Name: Stephen Pryke Author-X-Name-First: Stephen Author-X-Name-Last: Pryke Title: Network gaps and project success Abstract: Project success and client satisfaction are results of collaborative actions by project actors throughout the entire project life cycle. One principal factor in project success is the application of effective management tools. Gap analysis helps to achieve client satisfaction. However, gap analysis is unable to deal with the organic nature of information exchange between project actors. Social network analysis (SNA) enables the identification and analysis of information exchange and communication patterns in synergy with projects. Two case studies were carried out to identify gaps in the current linear project management approach. Gap analysis and SNA were used to analyse each project and to examine the research hypothesis on the use of SNA to identify network management gaps in projects. The gap analysis showed gaps of execution and conformance, which were confirmed by SNA. There was little evidence of project governance outside the project contractual arrangements during project execution. The current application approach of different management tools is limited in providing a whole-project view. The combined application of gap analysis and SNA can help practitioners to exceed client expectations. Journal: Construction Management and Economics Pages: 1205-1217 Issue: 12 Volume: 28 Year: 2010 Keywords: Client satisfaction, gap analysis, project management, social network analysis, X-DOI: 10.1080/01446193.2010.506643 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.506643 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:12:p:1205-1217 Template-Type: ReDIF-Article 1.0 Author-Name: Patrick Zou Author-X-Name-First: Patrick Author-X-Name-Last: Zou Author-Name: Jie Li Author-X-Name-First: Jie Author-X-Name-Last: Li Title: Risk identification and assessment in subway projects: case study of Nanjing Subway Line 2 Abstract: Underground subways are constructed in major cities across China to overcome the transportation problems in the urbanization process. The aim is to develop a comprehensive risk checklist associated with subway projects and a methodology to assess the risks at the early stage of a project. Based on the analysis of accidents that have happened in previous projects, a review of current literature and the results of interviews, a comprehensive risk checklist was developed, followed by proposing a risk analysis methodology using fuzzy analytical hierarchy process (AHP). Then the Nanjing Subway Line 2 project was analysed using the proposed risk checklist and fuzzy AHP method. The data were obtained through interviews and two rounds of questionnaire surveys with the personnel directly involved in the Nanjing Subway Line 2 project. The results of risk identification and assessment are presented and their managerial implications are discussed. The information presented here should be relevant to both academics and practitioners in the field of subway project management. Journal: Construction Management and Economics Pages: 1219-1238 Issue: 12 Volume: 28 Year: 2010 Keywords: Subway project, risk identification, risk checklist, risk assessment, fuzzy analytical hierarchy process, X-DOI: 10.1080/01446193.2010.519781 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.519781 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:12:p:1219-1238 Template-Type: ReDIF-Article 1.0 Author-Name: Nakhon Kokkaew Author-X-Name-First: Nakhon Author-X-Name-Last: Kokkaew Author-Name: Nicola Chiara Author-X-Name-First: Nicola Author-X-Name-Last: Chiara Title: Modelling completion risk using stochastic critical path-envelope method: a BOT highway project application Abstract: In integrated project delivery methods such as build-operate-transfer (BOT), a thorough financial risk analysis model should incorporate completion risk analysis into operation risk analysis as the timing of financial events such as refinancing and debt servicing depend on the construction completion date. During construction, project managers always have opportunities to react to negative events and to take corrective actions whenever possible to recover late-running schedules. These opportunities to react are 'real options' embedded in the construction process. However, current models of completion risk analysis ignore this feature of project managers. A reliable construction completion risk model for project feasibility studies should capture a manager's option to react to unforeseen, negative events. A novel approach for modelling construction completion risk analysis is developed by combining stochastic critical path method with the envelope method (SCP-EM). The SCP-EM approach can model the option-like feature of management feedback reactions in a straightforward fashion. The proposed approach, if applied correctly during the project feasibility study stage, enhances the project finance risk model by helping analysts properly evaluate financial risk arising from completion delay. Journal: Construction Management and Economics Pages: 1239-1254 Issue: 12 Volume: 28 Year: 2010 Keywords: Monte Carlo simulation, build-operate-transfer, risk analysis, project scheduling, envelope method, X-DOI: 10.1080/01446193.2010.521755 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.521755 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:12:p:1239-1254 Template-Type: ReDIF-Article 1.0 Author-Name: James Wong Author-X-Name-First: James Author-X-Name-Last: Wong Author-Name: S. Thomas Ng Author-X-Name-First: S. Thomas Author-X-Name-Last: Ng Title: Forecasting construction tender price index in Hong Kong using vector error correction model Abstract: Reliable short- to medium-term prediction of the tender price index (TPI) is crucial to construction stakeholders, and this has stimulated the interest of the research community to seek a more analytical method for TPI forecast. The purpose of this study is to establish an econometric model for accurately predicting the tender price movements based on a group of associated financial and macroeconomic variables. Applying Johansen's method for multivariate cointegration analysis, the tender price was found to be cointegrated with the gross domestic product, construction output and building cost. A vector error correction (VEC) model imposing the cointegration restriction was then developed for the purpose of forecasting. The model was verified against various diagnostic statistical criteria and compared with the Box-Jenkins and regression models. With a mean absolute percentage error for a three-year ahead forecast at 2.9% level, the developed VEC model outperforms the Box-Jenkins and regression models, and is proven to be efficient and reliable in forecasting the short- to medium-term tender price movements. The model can assist estimators to predict the TPI pattern in advance, and it can also help the public sector in planning for the construction workload to improve the stability of the construction market. Although the VEC model developed focuses on the Hong Kong construction market, the econometric technique can be applied to modelling other economic variables. Journal: Construction Management and Economics Pages: 1255-1268 Issue: 12 Volume: 28 Year: 2010 Keywords: Cost estimate, econometric modelling, tender price index, vector error correction model, forecast, X-DOI: 10.1080/01446193.2010.487536 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.487536 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:12:p:1255-1268 Template-Type: ReDIF-Article 1.0 Author-Name: Yinggang Wang Author-X-Name-First: Yinggang Author-X-Name-Last: Wang Author-Name: Paul Goodrum Author-X-Name-First: Paul Author-X-Name-Last: Goodrum Author-Name: Carl Haas Author-X-Name-First: Carl Author-X-Name-Last: Haas Author-Name: Robert Glover Author-X-Name-First: Robert Author-X-Name-Last: Glover Author-Name: Sharam Vazari Author-X-Name-First: Sharam Author-X-Name-Last: Vazari Title: Analysis of the benefits and costs of construction craft training in the United States based on expert perceptions and industry data Abstract: The case for or against craft training in construction from the perspective of constructors, owners, governments, workers, and other stakeholders is not completely clear, despite several studies to date. The business case for investing in construction craft training is examined from the employer's perspective on a construction project. A survey of 93 training directors and construction managers from throughout the US construction industry was used to collect quantitative estimates regarding craft training benefits and learning rates. Using these data, a benefit to cost ratio was calculated for a hypothetical typical industrial project (the CII model plant). According to the analyses, the estimated benefit to cost ratios range from 1.5:1 to 3.0:1. While these ratios are based on expert opinion, the results were triangulated with actual data from company training and project performance records as well as results from other research studies. The estimated benefit to cost ratios on the study's hypothetical industrial project are sensitive to the craft workers' employment duration, assuming that the training is provided by a single employer. Training durations are likely to be longer under a 'community training' model in which firms collaborate to sponsor training and workers have greater opportunities to continue in their training programme as they move from firm to firm. Nevertheless, the results contribute to a growing body of evidence that an investment in craft training is economically attractive for an employer, even over a typical project life cycle. Journal: Construction Management and Economics Pages: 1269-1285 Issue: 12 Volume: 28 Year: 2010 Keywords: Workforce, labour, training, X-DOI: 10.1080/01446193.2010.524238 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.524238 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:12:p:1269-1285 Template-Type: ReDIF-Article 1.0 Author-Name: Xiaoling Zhang Author-X-Name-First: Xiaoling Author-X-Name-Last: Zhang Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Yuzhe Wu Author-X-Name-First: Yuzhe Author-X-Name-Last: Wu Author-Name: Kunhui Ye Author-X-Name-First: Kunhui Author-X-Name-Last: Ye Title: A regional construction R&D evaluation system for China Abstract: Expenditure on R&D in China's construction industry has been relatively low in comparison with many developed countries for a number of years—a situation considered to be a major barrier to the industry's competitiveness in general and unsatisfactory as regards industry development of the 31 regions involved. A major problem with this is the lack of a sufficiently sophisticated method of objectively evaluating R&D activity in what are quite complex circumstances considering the size and regional differences that exist in this part of the world. A regional construction R&D evaluation system (RCRES) is presented, aimed at rectifying the situation. This is based on 12 indicators drawn from the Chinese Government's R&D Inventory of Resources in consultation with a small group of experts in the field, and further factor analysed into three groups. From this, the required evaluation is obtained by a simple formula. Examination of the results provides a ranking list of the R&D performance of each of the 31 regions, indicating a general disproportion between coastal and inland regions and highlighting regions receiving special emphasis or currently lacking in development. The understanding on this is vital for the future of China's construction industry. Journal: Construction Management and Economics Pages: 1287-1300 Issue: 12 Volume: 28 Year: 2010 Keywords: China, construction industry, factor analysis, research and development, X-DOI: 10.1080/01446193.2010.508501 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.508501 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:12:p:1287-1300 Template-Type: ReDIF-Article 1.0 Author-Name: Najimu Saka Author-X-Name-First: Najimu Author-X-Name-Last: Saka Author-Name: John Lowe Author-X-Name-First: John Author-X-Name-Last: Lowe Title: The impact of the petroleum sector on the output of the Nigerian construction sector Abstract: The petroleum sector plays an important role in the Nigerian economy, as it is the single largest revenue earner of the country and one of the largest contributors to the gross domestic product (GDP). This study estimated the impact of petroleum and gas revenue on the performance of the construction sector using a polynomial distributed lag model. We extracted data on the petroleum and gas sector (PGS), the GDP and construction sector output (CNS) for this study from the Central Bank of Nigeria (CBN) Statistical Bulletin. The analysis employed econometric methodology, which includes testing for stationarity and co-integration as well as estimating the distributed lag model. The result shows that the petroleum and gas revenue significantly affected construction output for three consecutive years starting from their year of occurrence. The study concluded that the PGS has a far-reaching impact on the growth and development of the construction sector. It therefore recommends supporting the channelling of funds from the petroleum sector into development of constructed facilities infrastructure. Journal: Construction Management and Economics Pages: 1301-1312 Issue: 12 Volume: 28 Year: 2010 Keywords: Construction sector, gross domestic product, econometrics, Nigeria, X-DOI: 10.1080/01446193.2010.509402 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.509402 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:12:p:1301-1312 Template-Type: ReDIF-Article 1.0 Author-Name: Rebecca Jane Loudoun Author-X-Name-First: Rebecca Author-X-Name-Last: Jane Loudoun Title: Injuries sustained by young males in construction during day and night work Abstract: The increased participation of young workers in the construction industry is matched by a growing realization of the vulnerability of these workers in terms of occupational injury and disease. The impact of organizational issues on injury rates for young workers is examined. This is an under-researched area where physical and psychological development influences have traditionally dominated. Data from the Australian Bureau of Statistics on labour force participation and work hours and data from the Queensland Injury Surveillance Unit on patients presenting at hospital emergency departments were used to examine incidence and severity of injuries sustained by young workers in construction on different shifts. Analyses indicated a different pattern of injury for young workers and workers outside this age category. Young workers were consistently more likely to be injured than all other workers, and this injury rate ratio increased significantly on night shift, suggesting that injury prevention strategies should consider the temporal pattern of work for young workers in construction. Journal: Construction Management and Economics Pages: 1313-1320 Issue: 12 Volume: 28 Year: 2010 Keywords: Injury, labour markets, occupational health and safety, X-DOI: 10.1080/01446193.2010.521760 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.521760 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:12:p:1313-1320 Template-Type: ReDIF-Article 1.0 Author-Name: Bee-Lan Oo Author-X-Name-First: Bee-Lan Author-X-Name-Last: Oo Author-Name: Derek Drew Author-X-Name-First: Derek Author-X-Name-Last: Drew Author-Name: Goran Runeson Author-X-Name-First: Goran Author-X-Name-Last: Runeson Title: Competitor analysis in construction bidding Abstract: Bidding strategies vary from contractor to contractor, each of which will have different degrees of sensitivity towards the factors affecting their bidding decisions. A competitor analysis using a linear mixed model is proposed for use by contractors as part of a more informed approach in identifying key competitors, and as a basis for formulating bidding strategies. The competitiveness between bids is examined according to: (i) project size, (ii) work sector; (iii) work nature; and (iv) number of bidders. The model was tested empirically by application to a bidding dataset obtained from a large Hong Kong contractor. Allowing for different degrees of sensitivity towards the four bidding variables across competing contractors (i.e. with the model parameters that varied across competing contractors), the results indicate that competitiveness in bidding of this contractor is generally greater than the majority of its competitors. Journal: Construction Management and Economics Pages: 1321-1329 Issue: 12 Volume: 28 Year: 2010 Keywords: Bidding, competitor analysis, competitiveness, X-DOI: 10.1080/01446193.2010.520721 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.520721 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:12:p:1321-1329 Template-Type: ReDIF-Article 1.0 Author-Name: David Oloke Author-X-Name-First: David Author-X-Name-Last: Oloke Title: Developing a Safety and Health Program Abstract: Journal: Construction Management and Economics Pages: 1331-1331 Issue: 12 Volume: 28 Year: 2010 X-DOI: 10.1080/01446193.2010.519780 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.519780 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:12:p:1331-1331 Template-Type: ReDIF-Article 1.0 Author-Name: John-Paris Pantouvakis Author-X-Name-First: John-Paris Author-X-Name-Last: Pantouvakis Title: Collaborative Construction Information Management Abstract: Journal: Construction Management and Economics Pages: 1331-1333 Issue: 12 Volume: 28 Year: 2010 X-DOI: 10.1080/01446193.2010.518972 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.518972 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:28:y:2010:i:12:p:1331-1333 Template-Type: ReDIF-Article 1.0 Author-Name: Titus Kivaa Mbiti Author-X-Name-First: Titus Kivaa Author-X-Name-Last: Mbiti Author-Name: Nick Blismas Author-X-Name-First: Nick Author-X-Name-Last: Blismas Author-Name: Ron Wakefield Author-X-Name-First: Ron Author-X-Name-Last: Wakefield Author-Name: Ric Lombardo Author-X-Name-First: Ric Author-X-Name-Last: Lombardo Title: System archetypes underlying the problematic behaviour of construction activity in Kenya Abstract: Construction activity in Kenya fluctuates excessively and grows very slowly. This feature causes adverse effects on the construction industry. When a drastic fall in construction activity occurs, the industry loses its production capacity; manpower moves to other industries in the country and abroad and many construction firms go bankrupt. During recovery, the shortage of contractors leads to increase in tender prices and sometimes poor quality work. These problems are best understood by modelling the construction industry as a system, because the systems approach to problem resolution involves an overarching study of the forces that give rise to the problems while simultaneously avoiding the distractions arising from excessive scrutiny of the problems themselves. In this paper, a system dynamics study of the construction industry of Kenya is presented. The system archetypes underlying the problematic behaviour of the industry are observed to be the balancing process with a delay phenomenon, coupled with the limits to growth phenomenon. It is recommended that (1) regulation of the response of the industry to changes in demand for its services; and (2) expansion of the construction market, could minimize fluctuations in construction activity and foster continual growth of the activity in Kenya. Journal: Construction Management and Economics Pages: 3-13 Issue: 1 Volume: 29 Year: 2011 Keywords: Construction industry, construction output, system dynamics, system archetypes, Kenya, X-DOI: 10.1080/01446193.2010.529924 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.529924 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:1:p:3-13 Template-Type: ReDIF-Article 1.0 Author-Name: Jin Wu Author-X-Name-First: Jin Author-X-Name-Last: Wu Author-Name: Mohan Kumaraswamy Author-X-Name-First: Mohan Author-X-Name-Last: Kumaraswamy Author-Name: Gary Soo Author-X-Name-First: Gary Author-X-Name-Last: Soo Title: Dubious benefits from future exchange: an explanation of payment arrears from 'continuing clients' in Mainland China Abstract: Clients and contractors are frequently advised to adopt a collaborative attitude and approach in construction projects in general, with 'continuing clients', i.e. clients with continuous large projects portfolios, expected to be in the forefront of such initiatives. Although such a governance approach has been argued to be beneficial in construction transactions, it is not uncommon to hear contractors complaining that clients do not fulfil their payment obligations. For example, in Mainland China, a large proportion of deliberate payment arrears are from 'continuing clients'. Gametric models are used in this research to show that three prerequisites are needed for inducing continuing clients to be cooperative. Empirical evidence from legislation and a questionnaire survey indicates that these preconditions are not fulfilled in Mainland China. Prevalent institutional arrangements, differentials in appreciation of the value of relationships, and opaque payment track records are found to contribute to continuing clients' deviation from the often advocated amicable approaches. Thus, transaction attributes seem to only suggest a theoretically optimal governance structure from the perspective of transaction costs, but other factors may also substantially influence parties' calculation and choice. Journal: Construction Management and Economics Pages: 15-23 Issue: 1 Volume: 29 Year: 2011 Keywords: Payment arrears, opportunism, collaboration, transaction cost, game theory, X-DOI: 10.1080/01446193.2010.521757 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.521757 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:1:p:15-23 Template-Type: ReDIF-Article 1.0 Author-Name: Weizhuo Lu Author-X-Name-First: Weizhuo Author-X-Name-Last: Lu Author-Name: Thomas Olofsson Author-X-Name-First: Thomas Author-X-Name-Last: Olofsson Author-Name: Lars Stehn Author-X-Name-First: Lars Author-X-Name-Last: Stehn Title: A lean-agile model of homebuilders' production systems Abstract: A lean-agile model of homebuilders' production systems is proposed in this research. Value stream mapping is utilized to clarify the proposed lean-agile model, in which pull and Kanban are used to ensure smooth production upstream of the de-coupling point, while fluctuating market demands in terms of variety of homes and variability of volumes are managed by the agile process downstream of the de-coupling point. The de-coupling point is used to provide components to downstream agile process and shield upstream smooth production from market fluctuations. A simulation model is developed to evaluate and validate the effectiveness of the proposed lean-agile model. Simulation experiments show that the lean-agile model prevents the accumulation of high inventory levels and thus provides better customization opportunities for clients compared to even-flow-construction. It also provides a more stable process with shorter cycle times compared to sales-driven production. The proposed lean-agile model offers new possibilities for homebuilders to manage the balance between meeting fluctuating market demands and stabilizing the production system. Journal: Construction Management and Economics Pages: 25-35 Issue: 1 Volume: 29 Year: 2011 Keywords: Agile, housing construction, lean, simulation, X-DOI: 10.1080/01446193.2010.531027 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.531027 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:1:p:25-35 Template-Type: ReDIF-Article 1.0 Author-Name: Yan Chang Author-X-Name-First: Yan Author-X-Name-Last: Chang Author-Name: Suzanne Wilkinson Author-X-Name-First: Suzanne Author-X-Name-Last: Wilkinson Author-Name: Regan Potangaroa Author-X-Name-First: Regan Author-X-Name-Last: Potangaroa Author-Name: Erica Seville Author-X-Name-First: Erica Author-X-Name-Last: Seville Title: Identifying factors affecting resource availability for post-disaster reconstruction: a case study in China Abstract: The availability of resources allows for the rapid and cost-effective delivery of a construction project. For rebuilding programmes after a disaster, the need for better understanding of factors affecting resource availability and their potential impacts on resourcing outcomes can be of crucial importance to effective reconstruction performance. Drawing on an empirical survey in China following the 2008 Wenchuan earthquake, the critical factors affecting resource availability for post-quake reconstruction of housing are identified. Resource availability in a post-disaster situation is not only associated with (1) project-related factors such as quantity of resources required, project schedule, project resourcing plan, and resource procurement lead time; and (2) factors related to the reconstruction practitioners, including competency of resourcing manager and qualification of contractor; but is also related to (3) factors external to reconstruction projects including legislation and policy, general economic environment, and resource transportation cost and method. To address these factors, a multi-sector approach is needed for reconstruction decision makers and practitioners. A planned procurement strategy in the implementing contractors, a range of training initiatives for small and medium businesses, along with augmented regulatory, economic and transport infrastructure systems are likely to improve resource availability for post-disaster rebuilding projects. Journal: Construction Management and Economics Pages: 37-48 Issue: 1 Volume: 29 Year: 2011 Keywords: Disasters, post-disaster reconstruction, resource availability, construction projects, China, X-DOI: 10.1080/01446193.2010.521761 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.521761 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:1:p:37-48 Template-Type: ReDIF-Article 1.0 Author-Name: Abdul-Rashid Abdul-Aziz Author-X-Name-First: Abdul-Rashid Author-X-Name-Last: Abdul-Aziz Author-Name: David Pengiran Ngau Author-X-Name-First: David Pengiran Author-X-Name-Last: Ngau Author-Name: Yoke Mui Lim Author-X-Name-First: Yoke Mui Author-X-Name-Last: Lim Author-Name: Azlan Raofuddin Nuruddin Author-X-Name-First: Azlan Raofuddin Author-X-Name-Last: Nuruddin Title: Internationalization of Malaysian quantity surveying firms: exploring the best fit models Abstract: The internationalization of services has been largely under-researched, more so in respect of developing countries. In light of this, the various models on firm internationalization were tested to determine which of them best fits the internationalization of Malaysian quantity surveying (QS) firms. The models were a combination of the old and more recent. In doing so, the 'what', 'where', 'how', 'which' and 'why' of the subject matter were addressed. Data were collected using the mixed method, combining a postal questionnaire survey, follow-up interviews and secondary data. The findings point to certain models (i.e. liability of foreignness concept, network theory, internalization theory and international entrepreneurship) having a good fit with the subject matter in comparison to others (i.e. resource-based theory, eclectic paradigm, stage growth theory and 'born global'). Based on the findings and in view of Malaysia's impending liberalization of services by 2012, certain recommendations are made for those firms that are still insular in orientation, notably the necessity for top management to have the internationalization drive and business networks they should leverage on. Malaysia's export promotion agencies must also have targeted efforts to increase the export of QS services. Journal: Construction Management and Economics Pages: 49-58 Issue: 1 Volume: 29 Year: 2011 Keywords: International business, models, quantity surveying, Malaysia, X-DOI: 10.1080/01446193.2010.519782 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.519782 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:1:p:49-58 Template-Type: ReDIF-Article 1.0 Author-Name: Seli-super-˙n Gundes Author-X-Name-First: Seli-super-˙n Author-X-Name-Last: Gundes Title: Exploring the dynamics of the Turkish construction industry using input-output analysis Abstract: Construction is commonly regarded as an important industry in economic policy making owing to its strong interactions with other sectors in the economy. Using six national input-output (IO) tables compiled to date and economic data for the period between 1969 and 2006, the behaviour of the Turkish construction sector and its relationships to investment, income and to other sectors in the economy are examined. Analysis reveals that the construction industry is losing its propulsive role and that it tends to exaggerate the fluctuations of the economy. The examination of lead and lag times between changes in GNP, construction activity and investments show that public sector spending cuts, in particular, have significant effects on the amplitude and the timing of slumps of the industry. The analysis of linkage indicators indicates that for the whole period under consideration the construction industry has high linkages with only one other industry. Thus the 'leading' role it plays in the economy is questioned. Journal: Construction Management and Economics Pages: 59-68 Issue: 1 Volume: 29 Year: 2011 Keywords: Construction sector, input-output analysis, backward linkage, forward linkage, Turkey, X-DOI: 10.1080/01446193.2010.529925 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.529925 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:1:p:59-68 Template-Type: ReDIF-Article 1.0 Author-Name: Derek Thomson Author-X-Name-First: Derek Author-X-Name-Last: Thomson Title: A pilot study of client complexity, emergent requirements and stakeholder perceptions of project success Abstract: Construction industry reliance on performance metrics fixed at the project outset is being superseded by increasing use of emergent client judgments to characterize success. Clients may still consider a project that fails to meet formalized time, cost and performance goals successful if it satisfies emergent requirements not understood during initial briefing. Construction practitioners do not routinely recognize that client awareness of requirements improves as projects progress. Internal conflict among the client stakeholders and their reflections on the emerging project solution help client stakeholders to better understand their needs. Dissatisfaction results when these emergent requirements are not acknowledged. The need for practitioners to recognize and respond to these issues is explored by a paradigmatic case study of an office relocation and refurbishment project. The role of the 'project sponsor' as a synthesizer of client requirements and reflections on the emerging solution was observed to be subverted by stakeholders in a client body who found their emergent requirements were not acknowledged by construction practitioners. By characterizing the harmful effect of pluralistic client complexity and emergent requirements on perceptions of project success, the rationale for a revised project sponsor role to better address these influences on perceptions of project success is contributed. Journal: Construction Management and Economics Pages: 69-82 Issue: 1 Volume: 29 Year: 2011 Keywords: Case study, client requirements, complexity, project sponsor, stakeholder, X-DOI: 10.1080/01446193.2010.519399 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.519399 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:1:p:69-82 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Brown Author-X-Name-First: Andrew Author-X-Name-Last: Brown Author-Name: Florence Phua Author-X-Name-First: Florence Author-X-Name-Last: Phua Title: Subjectively construed identities and discourse: towards a research agenda for construction management Abstract: Identity issues are under-explored in construction management. We provide a brief introduction to the organization studies literature on subjectively construed identities, focusing on discourse, agency, relations of power and identity work. The construction management literature is investigated in order to examine identity concerns as they relate to construction managers centred on (1) professionalism; (2) ethics; (3) relational aspects of self-identity; (4) competence, knowledge and tools; and (5) national culture. Identity, we argue, is a key performance issue, and needs to be accounted for in explanations of the success and failure of projects. Our overriding concern is to raise identity issues in order to demonstrate their importance to researchers in construction management and to spark debate. The purpose of this work is not to provide answers or to propose prescriptive models, but to explore ideas, raise awareness and to generate questions for further programmatic research. To this end, we promote empirical work and theorizing by outlining elements of a research agenda which argues that 'identity' is a potentially generative theme for scholars in construction management. Journal: Construction Management and Economics Pages: 83-95 Issue: 1 Volume: 29 Year: 2011 Keywords: Identity, discourse, construction manager, performance, research agenda, X-DOI: 10.1080/01446193.2010.531028 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.531028 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:1:p:83-95 Template-Type: ReDIF-Article 1.0 Author-Name: Onur Dursun Author-X-Name-First: Onur Author-X-Name-Last: Dursun Author-Name: Christian Stoy Author-X-Name-First: Christian Author-X-Name-Last: Stoy Title: Time-cost relationship of building projects: statistical adequacy of categorization with respect to project location Abstract: Construction duration is one of the key elements to determine the success of a project. Several models have been developed to provide precise predictions of construction duration. The datasets in previous studies comprise observations from particular countries. This precludes examination of the role of project location at the country level for modelling construction duration. The aim, therefore, is to test the statistical adequacy of categorizing projects with respect to their locations for modelling construction duration. A formal procedure to evaluate the adequacy of categorizing observations is also presented. It is intended to contribute to the epistemology of modelling construction duration. The dataset was generated from a global client. It contains information on 246 projects from 25 different countries. This creates a categorical variable for location. Bromilow's time-cost model is chosen to assess the adequacy of this categorization. A full model with indicator and interaction variables is compared to a restricted one. Parameter estimation was performed according to the ordinary least squares method. F-statistics are calculated and the probability of the value is significant. The results show that two distinct groups with substantial changes in model parameters exist in the dataset. It is also noted that conclusions are valid over the selected population. Journal: Construction Management and Economics Pages: 97-106 Issue: 1 Volume: 29 Year: 2011 Keywords: Bromilow's time-cost model, categorization, project location, F-ratio, X-DOI: 10.1080/01446193.2010.528437 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.528437 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:1:p:97-106 Template-Type: ReDIF-Article 1.0 Author-Name: Anne Landin Author-X-Name-First: Anne Author-X-Name-Last: Landin Title: Construction Stakeholder Management Abstract: Journal: Construction Management and Economics Pages: 107-107 Issue: 1 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2010.529923 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.529923 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:1:p:107-107 Template-Type: ReDIF-Article 1.0 Author-Name: Yu-Hsiu Hung Author-X-Name-First: Yu-Hsiu Author-X-Name-Last: Hung Author-Name: Tonya Smith-Jackson Author-X-Name-First: Tonya Author-X-Name-Last: Smith-Jackson Author-Name: Woodrow Winchester Author-X-Name-First: Woodrow Author-X-Name-Last: Winchester Title: Use of attitude congruence to identify safety interventions for small residential builders Abstract: The construction industry has experienced high numbers of occupational injuries and fatalities over the years. To address this issue, differences in safety attitudes and behaviours were explored among construction workers, first-line supervisors, and project managers in small residential construction companies with respect to recommendations for safety interventions. A triangulation design consisting of observation (shadowing), subjective quantitative (questionnaire), and subjective qualitative (interview) methods was used to obtain different but complementary data on the same safety challenges. Shadowing was utilized to explore onsite safety problems and/or risky behaviours resulting from safety attitudinal discrepancies among the three groups. Questionnaires were administered to identify salient themes for the observed practices. Semi-structured interviews were conducted to explore the causes of the observed safety problems. Results revealed that first-line supervisors did not enforce safety rules strictly or consistently, and that significant differences in safety attitudes and risk perceptions were observed among the three groups. Results also support a tendency among subcontractors to practise risky behaviours, even though they generally articulated a desire to avoid injuries. The recommended interventions include holding regular safety meetings between managers and workers, implementing informal training to supplement formal training, and closely examining and reviewing the appropriateness of health and safety policies. Journal: Construction Management and Economics Pages: 113-130 Issue: 2 Volume: 29 Year: 2011 Keywords: Safety, small business, X-DOI: 10.1080/01446193.2010.521758 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.521758 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:2:p:113-130 Template-Type: ReDIF-Article 1.0 Author-Name: Melissa Teo Author-X-Name-First: Melissa Author-X-Name-Last: Teo Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: Community-based protest against construction projects: a case study of movement continuity Abstract: Community-based activism against proposed construction projects is growing. Many protests are poorly managed and escalate into long-term and sometimes acrimonious disputes which damage communities, firms and the construction industry as a whole. Using a thematic storytelling approach which draws on ethnographic method, within a single case study framework, new insights into the social forces that shape and sustain community-based protest against construction projects are provided. A conceptual model of protest movement continuity is presented which highlights the factors that sustain protest continuity over time. The model illustrates how social contagion leads to common community perceptions of development risk and opportunity, to a positive internalization of collective values and identity, to a strategic utilization of social capital and an awareness of the need to manage the emotional dynamics of protest through mechanisms such as symbolic artefacts. Journal: Construction Management and Economics Pages: 131-144 Issue: 2 Volume: 29 Year: 2011 Keywords: Protest, construction project, community relations, contagion, social networks, X-DOI: 10.1080/01446193.2010.535545 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.535545 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:2:p:131-144 Template-Type: ReDIF-Article 1.0 Author-Name: Jing Yang Author-X-Name-First: Jing Author-X-Name-Last: Yang Author-Name: Geoffrey Qiping Shen Author-X-Name-First: Geoffrey Qiping Author-X-Name-Last: Shen Author-Name: Lynda Bourne Author-X-Name-First: Lynda Author-X-Name-Last: Bourne Author-Name: Christabel Man-Fong Ho Author-X-Name-First: Christabel Man-Fong Author-X-Name-Last: Ho Author-Name: Xiaolong Xue Author-X-Name-First: Xiaolong Author-X-Name-Last: Xue Title: A typology of operational approaches for stakeholder analysis and engagement Abstract: Stakeholder analysis and engagement are the main tasks in stakeholder management. To identify operational approaches for stakeholder analysis and engagement, six interviews and a questionnaire survey were conducted in Hong Kong, and an additional 15 interviews were held in Australia. The main finding is a typology of practical approaches for practitioners in construction. A total of 30 approaches are comprised in the typology, and they are classified by application. To test the usefulness of the typology, action research is applied to two real-life projects in Australia. The implication is that the selection of the approaches is an art and a contingency approach as well, requiring practitioners' judgments. Each approach has its strengths and limitations, so the most appropriate way for effective stakeholder management is to use a combination of elements from each approach as circumstances dictate. This study can serve as a reference for the systematic consideration of the project management team about the operational approaches for stakeholder management in construction projects. Journal: Construction Management and Economics Pages: 145-162 Issue: 2 Volume: 29 Year: 2011 Keywords: Stakeholder analysis, stakeholder engagement, contingency, X-DOI: 10.1080/01446193.2010.521759 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.521759 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:2:p:145-162 Template-Type: ReDIF-Article 1.0 Author-Name: Yong-Woo Kim Author-X-Name-First: Yong-Woo Author-X-Name-Last: Kim Author-Name: Sang-Chul Kim Author-X-Name-First: Sang-Chul Author-X-Name-Last: Kim Title: Cost analysis of information technology-assisted quality inspection using activity-based costing Abstract: One of the critical factors in quality control is the efficient management of quality field inspections. A method was developed to assess the cost impact of process improvements in construction jobsite management. Through the development of a prototype quality inspection system together with project database and mobile technology, the efficiency of a quality inspection system as a pilot study is examined. A time-driven activity-based costing (ABC) is used in evaluating the quantifying process costs attributable to the implementation of a new field inspection system. Inspection costs were reduced when the current inspection process is replaced by a new inspection prototype process using a project database and mobile technology. The cost analysis results also show that a new approach (1) identifies the inspection activities before and after the re-engineering process; (2) computes the cost driver rate before and after the re-engineering process; and (3) enables the performance of the scenario analysis by manipulating the volume of cost drivers under different scenarios. Journal: Construction Management and Economics Pages: 163-172 Issue: 2 Volume: 29 Year: 2011 Keywords: Activity-based costing, cost analysis, personal digital assistant, quality inspection, X-DOI: 10.1080/01446193.2010.538708 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.538708 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:2:p:163-172 Template-Type: ReDIF-Article 1.0 Author-Name: Anita Liu Author-X-Name-First: Anita Author-X-Name-Last: Liu Author-Name: Richard Fellows Author-X-Name-First: Richard Author-X-Name-Last: Fellows Author-Name: Martin Tuuli Author-X-Name-First: Martin Author-X-Name-Last: Tuuli Title: The role of corporate citizenship values in promoting corporate social performance: towards a conceptual model and a research agenda Abstract: Performance of corporations, under the stakeholder approach, is not measured in financial terms only; modern corporations have significant responsibilities beyond those to their shareholders. A value-laden concept such as sustainable construction, which emerges from a multi-stakeholder perspective, involves participation of the whole supply chain and incorporates the notion of corporate social responsibility (CSR). Creating sustainable habitats has societal as well as economic implications. While the UK government's Department of Trade and Industry is promoting CSR as a business contribution to sustainable development, many have argued that corporate citizenship takes shape at the point of government failure in the facilitation of citizen's rights. Recent research demonstrates varying degrees of corporate social performance (CSP) in different sectors and there are differing relationships between CSP and innovation in the real estate and construction sectors. A conceptual model linking corporate citizenship values (CCV) and CSP through corporate behaviour (BCORP) from a CSR and stakeholder theory perspective is developed. The proposed model presents avenues for future research and represents a significant first step towards modelling the important link between CCV and CSP. Journal: Construction Management and Economics Pages: 173-183 Issue: 2 Volume: 29 Year: 2011 Keywords: Corporate social performance, corporate social responsibility, stakeholder theory, X-DOI: 10.1080/01446193.2010.538706 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.538706 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:2:p:173-183 Template-Type: ReDIF-Article 1.0 Author-Name: Mark John Gannon Author-X-Name-First: Mark John Author-X-Name-Last: Gannon Author-Name: Nigel John Smith Author-X-Name-First: Nigel John Author-X-Name-Last: Smith Title: An effective outline business case to facilitate successful decision-making Abstract: Historically the public sector's outline business case for Light Rapid Transit/Metro public-private partnership projects delivered in the United Kingdom has frequently failed to address the project affordability decision. As a consequence the business cases have had to be reworked, redeveloped or have required the project to be revoked, in each case wasting significant amounts of public and private sector time and money. The development and testing of an effective outline business case to facilitate successful project affordability decision-making for PPP projects is described. A mixed methods research approach was adopted utilizing a case study research methodology, interviews with PPP experts to identify business case critical success factors and application of the analytical hierarchical process to assess their effectiveness. The Delphi technique was used to verify and validate the effectiveness of the outline business case. The findings demonstrated that the success of the outline business case in practice relies on three critical success factors: the degree of political support, achieving a balance between political PPP ideology and the market's acceptance of the contractual model and the level of transparency and commitment from suppliers. These factors are major uncertainties, are difficult to represent accurately within the business case and signify a major constraint to the sponsor forecasting the project's affordability. Journal: Construction Management and Economics Pages: 185-197 Issue: 2 Volume: 29 Year: 2011 Keywords: Public-private partnership, business case, project affordability, project decision-making, analytical hierarchical process, X-DOI: 10.1080/01446193.2010.538707 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.538707 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:2:p:185-197 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Title: In the circuit of credibility: construction workers and the norms of 'a good job' Abstract: In the contemporary managerial regime, managerial control is increasingly being maintained through indirect forms of control, centring on identities and ideologies and instituting the co-workers as enterprising, self-regulating subjects. The construction industry has, over time, managed to maintain a craft tradition whereby individual skills rather than engineered work routines have been favoured, resulting in management control largely having been decentralized to work teams. A study of construction work at three sites suggests that managerial control is embedded in collectively enacted norms concerning what constitutes 'good work'. The capacity to perform in accordance with such norms is translated into credibility, a reputation for being capable of adhering to the norms of good work. The construction industry and onsite construction work thus operate on the basis of an 'economy of reputation' or a 'circuit of credibility', prescribing what constitutes adequate performance and imposing sanctions on underachieving individuals or companies. Such norms and circuits of credibility serve to protect the role and status of construction workers and to maintain jurisdiction over fields of expertise, but they may also have a conservating effect on the industry, being severely criticized in terms of failing to bring about innovations and lower production costs. Journal: Construction Management and Economics Pages: 199-209 Issue: 2 Volume: 29 Year: 2011 Keywords: Norms, credibility, reputation, management control, X-DOI: 10.1080/01446193.2010.526623 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.526623 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:2:p:199-209 Template-Type: ReDIF-Article 1.0 Author-Name: Elisabeth Campagnac Author-X-Name-First: Elisabeth Author-X-Name-Last: Campagnac Title: Governance and Knowledge Management for Public Private Partnerships Abstract: Journal: Construction Management and Economics Pages: 211-213 Issue: 2 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2010.532810 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.532810 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:2:p:211-213 Template-Type: ReDIF-Article 1.0 Author-Name: Denise Gravitt Author-X-Name-First: Denise Author-X-Name-Last: Gravitt Title: Location-Based Management for Construction: Planning, Scheduling and Control Abstract: Journal: Construction Management and Economics Pages: 215-215 Issue: 2 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2010.542469 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.542469 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:2:p:215-215 Template-Type: ReDIF-Article 1.0 Author-Name: Rodger Edwards Author-X-Name-First: Rodger Author-X-Name-Last: Edwards Title: Intelligent Buildings and Building Automation Abstract: Journal: Construction Management and Economics Pages: 216-217 Issue: 2 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2010.542470 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.542470 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:2:p:216-217 Template-Type: ReDIF-Article 1.0 Author-Name: Venny Chandra Author-X-Name-First: Venny Author-X-Name-Last: Chandra Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: Communicating about organizational culture in the briefing process: case study of a hospital project Abstract: A new hospital building represents a rare opportunity to align the physical environment of healthcare with contemporary healthcare needs and models of healthcare delivery to help ensure optimal health outcomes. The effectiveness of interaction between project stakeholders from the hospital and design teams during the briefing process of any hospital project is critical in ensuring this alignment occurs. Therefore it is important to explore the process of knowledge sharing during this project briefing stage. Using thematic content analysis to explore communication exchanges between these project stakeholders, we show that knowledge exchanged during the briefing process is acquired not only explicitly but implicitly through social processes whereby participants attempt to socially construct a common understanding of the project. In particular, the importance of constructive conflict in driving this process is critical. This has implications for health planners, project managers, facilities managers and health professions engaged in the briefing process of hospital projects. In particular, it highlights the importance of providing the correct environment and enough time for culturally conducive social interaction and knowledge sharing to occur between the many stakeholders involved. Journal: Construction Management and Economics Pages: 223-231 Issue: 3 Volume: 29 Year: 2011 Keywords: Hospitals, briefing, culture, conflict, knowledge, stakeholders, facilities management, X-DOI: 10.1080/01446193.2010.521756 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.521756 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:3:p:223-231 Template-Type: ReDIF-Article 1.0 Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Author-Name: H. L. Guo Author-X-Name-First: H. L. Author-X-Name-Last: Guo Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Ting Huang Author-X-Name-First: Ting Author-X-Name-Last: Huang Author-Name: K. Y. N. Chan Author-X-Name-First: K. Y. N. Author-X-Name-Last: Chan Author-Name: Greg Chan Author-X-Name-First: Greg Author-X-Name-Last: Chan Title: Rethinking prefabricated construction management using the VP-based IKEA model in Hong Kong Abstract: Prefabricated construction is regarded by many as an effective and efficient approach to improving construction processes and productivity, ensuring construction quality and reducing time and cost in the construction industry. However, many problems occur with this approach in practice, including higher risk levels and cost or time overruns. In order to solve such problems, it is proposed that the IKEA model of the manufacturing industry and VP technology are introduced into a prefabricated construction process. The concept of the IKEA model is identified in detail and VP technology is briefly introduced. In conjunction with VP technology, the applications of the IKEA model are presented in detail, i.e. design optimization, production optimization and installation optimization. Furthermore, through a case study of a prefabricated hotel project in Hong Kong, it is shown that the VP-based IKEA model can improve the efficiency and safety of prefabricated construction as well as reducing cost and time. Journal: Construction Management and Economics Pages: 233-245 Issue: 3 Volume: 29 Year: 2011 Keywords: Prefabricated construction, IKEA model, Virtual Prototyping, design optimization, construction optimization, X-DOI: 10.1080/01446193.2010.545994 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.545994 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:3:p:233-245 Template-Type: ReDIF-Article 1.0 Author-Name: Abu Naser Chowdhury Author-X-Name-First: Abu Naser Author-X-Name-Last: Chowdhury Author-Name: Po-Han Chen Author-X-Name-First: Po-Han Author-X-Name-Last: Chen Author-Name: Robert Tiong Author-X-Name-First: Robert Author-X-Name-Last: Tiong Title: Analysing the structure of public-private partnership projects using network theory Abstract: In public-private partnership projects (PPP), the relationships between the participants are established through a variety of contractual agreements between financiers, government, contractors, operators and customers. Raising funds, linking various participants legally and financially, ensuring supply, and producing and marketing products depend on well-established financial and legal structures of PPP. Though numerous research studies have been conducted to establish and justify the structure of PPP projects based on contractual agreements between participating stakeholders and on existing legal frameworks of a host country, there are still questions left unanswered. Examples are: What are the factors that influence the structuring of PPP? Who are the key stakeholders? And what are the roles of participating partners in a PPP project? However, not much work has been done. Application of network theory can help fill these gaps and identify and distinguish potential stakeholders in PPP affiliation and can effectively contribute to an in-depth analysis of the relationships between participating partners. The analysis can identify important features like core-peripheral stakeholder(s), influential intermediary participants and their interdependence, and influences of a PPP structure on its substantive outcome. With the introduction of the network theory, a more thorough analysis of PPP structures can be achieved which may provide valuable information to project sponsors as well as legal and financial advisers. Journal: Construction Management and Economics Pages: 247-260 Issue: 3 Volume: 29 Year: 2011 Keywords: Public-private partnership, structure, network, stakeholder, Pakistan, X-DOI: 10.1080/01446193.2010.537354 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.537354 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:3:p:247-260 Template-Type: ReDIF-Article 1.0 Author-Name: S. Z. S. Tabish Author-X-Name-First: S. Z. S. Author-X-Name-Last: Tabish Author-Name: Kumar Neeraj Jha Author-X-Name-First: Kumar Neeraj Author-X-Name-Last: Jha Title: Analyses and evaluation of irregularities in public procurement in India Abstract: Public procurement is prone to corruption, which in the global construction market alone accounts for an estimated US$340 billion per year. There is a growing need for procurement systems to be able to fight corruption and improve the effectiveness, efficiency, fairness and transparency of public procurement. A comprehensive list of irregularities in public procurement is derived from irregularities observed during technical vigilance inspections by experts and reported cases. The research involved a questionnaire survey, Delphi method and an empirical investigation of the dynamics of irregular practices in public procurement. The survey revealed the top 15 most frequent irregularities. The irregularities have been classified under five categories: transparency, professional standards, fairness, contract monitoring and regulation and procedural irregularities. The ranking of these categories reveals that transparency is the key factor requiring prime attention. The other categories are of nearly equal importance. A framework for good procurement is developed and actions proposed under five categories to curb corruption in public procurement. The framework and the irregularities can be related systematically to various aspects of combating corruption, and hence should fulfil the urgent need of policy-makers, professional staff, regulators and consumers. Journal: Construction Management and Economics Pages: 261-274 Issue: 3 Volume: 29 Year: 2011 Keywords: Corruption, India, irregularities, public sector procurement, X-DOI: 10.1080/01446193.2010.549138 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.549138 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:3:p:261-274 Template-Type: ReDIF-Article 1.0 Author-Name: Samuel Laryea Author-X-Name-First: Samuel Author-X-Name-Last: Laryea Title: Quality of tender documents: case studies from the UK Abstract: Tendering is one of the stages in construction procurement that requires extensive information and documents exchange. However, tender documents are not always clear in practice. The aim of this study was to ascertain the clarity and adequacy of tender documents used in practice. Access was negotiated into two UK construction firms and the whole tender process for two projects was shadowed for six to seven weeks in each firm using an ethnographic approach. A significant amount of tender queries, amendments and addenda were recorded. This showed that quality of tender documentation is still a problem in construction despite the existence of Co-ordinated Project Information (1987) and British Standard 1192 (1984, 1990, 2007) that are meant to help in producing clear and consistent project information. Poor quality tender documents are a source of inaccurate estimates, claims and disputes on contracts. Six recommendations are presented to help in improving the quality of tender documentation. Further research is needed into the recommendations to help improve the quality of tender documents, perhaps in conjunction with an industry-wide investigation into the level of incorporation of CPI principles in practice. Journal: Construction Management and Economics Pages: 275-286 Issue: 3 Volume: 29 Year: 2011 Keywords: Case study, contractor, tender documentation, tendering, UK, X-DOI: 10.1080/01446193.2010.540019 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.540019 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:3:p:275-286 Template-Type: ReDIF-Article 1.0 Author-Name: Jasper Mbachu Author-X-Name-First: Jasper Author-X-Name-Last: Mbachu Author-Name: Marcel Frei Author-X-Name-First: Marcel Author-X-Name-Last: Frei Title: Diagnosing the strategic health of an organization from SWOT analysis results: case study of the Australasian cost management profession Abstract: To achieve strategic goals and success in the long term, every organization needs to be in a good state of health. It is argued that the strategic health of an organization depends on how the key strengths are leveraged to exploit prime opportunities, while at the same time, minimize exposure of the critical weaknesses to the serious threats in the external environment. Based on a SWOT analysis (strengths, weaknesses, opportunities and threats), the Strategic Health Index (SHI) was developed as a conceptual tool for diagnosing the strategic health of an organization. Application of the developed model was demonstrated in the assessment of the strategic health status of the Australasian cost management profession using analysed feedback from a convenience sample of 15 senior cost managers in Australia and New Zealand. Results show that expertise in procurement and cost consultancy was the key strength most leveraged to exploit identified opportunities, while lack of flexibility and versatility of service was the key weakness exposing the profession the most to the identified threats. Based on the SHI values, the overall strategic health of the cost management profession was diagnosed to be positive, in spite of its key weaknesses and threats. While these results specifically relate to cost managers, application of the model is highly recommended for use by business managers and others interested in assessing the long-term health and survival of their organizations. Journal: Construction Management and Economics Pages: 287-303 Issue: 3 Volume: 29 Year: 2011 Keywords: Cost engineering, organizational analysis, strategic analysis, strategic management, strategic planning, SWOT analysis, X-DOI: 10.1080/01446193.2010.547865 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.547865 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:3:p:287-303 Template-Type: ReDIF-Article 1.0 Author-Name: Yongwei Shan Author-X-Name-First: Yongwei Author-X-Name-Last: Shan Author-Name: Paul Goodrum Author-X-Name-First: Paul Author-X-Name-Last: Goodrum Author-Name: Dong Zhai Author-X-Name-First: Dong Author-X-Name-Last: Zhai Author-Name: Carl Haas Author-X-Name-First: Carl Author-X-Name-Last: Haas Author-Name: Carlos Caldas Author-X-Name-First: Carlos Author-X-Name-Last: Caldas Title: The impact of management practices on mechanical construction productivity Abstract: Over recent decades, sporadic advancements in machinery and construction materials have to some extent increased construction productivity in the United States. However, there is evidence that additional productivity improvement opportunities exist. One way to improve direct work rates and likewise the potential to increase construction craft productivity is through better planning and management. Utilizing a dataset from the Construction Industry Institute Benchmarking and Metrics programme with 41 sampled projects, the relationship between the level of implementation of different management programmes and mechanical craft productivity is examined. The implementation of several management programmes, including pre-project planning, team building, automation and integration of information systems and safety had a positive correlation with improved mechanical productivity. In fact, the statistical results show that projects with advanced implementation of the selected management programmes experienced significant mechanical productivity advantages over projects with weak implementation. Journal: Construction Management and Economics Pages: 305-316 Issue: 3 Volume: 29 Year: 2011 Keywords: Automation, labour productivity, pre-project planning, safety, team building, X-DOI: 10.1080/01446193.2010.538070 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.538070 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:3:p:305-316 Template-Type: ReDIF-Article 1.0 Author-Name: Michael Hiete Author-X-Name-First: Michael Author-X-Name-Last: Hiete Author-Name: Anna Kuhlen Author-X-Name-First: Anna Author-X-Name-Last: Kuhlen Author-Name: Frank Schultmann Author-X-Name-First: Frank Author-X-Name-Last: Schultmann Title: Analysing the interdependencies between the criteria of sustainable building rating systems Abstract: Various building rating systems have been developed to assess the 'green' or sustainable performance of buildings. Most systems make use of hierarchical criteria systems to evaluate the buildings with respect to the different aspects of sustainability. Often, these criteria show complex interdependencies between each other. Taking the German building rating system as an example, the Decision-Making Trial and Evaluation Laboratory (DEMATEL) method is used to analyse such interdependencies and to characterize the criteria. Users of the rating system might benefit from this information, e.g. when focusing on cause criteria counting on that an improvement there will also result in improvements of dependent criteria. Rating system developers might remove strongly related criteria and correct the criteria weighting for identified interdependencies. Journal: Construction Management and Economics Pages: 323-328 Issue: 4 Volume: 29 Year: 2011 Keywords: Building performance, certification, Germany, sustainable construction, X-DOI: 10.1080/01446193.2011.558105 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.558105 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:4:p:323-328 Template-Type: ReDIF-Article 1.0 Author-Name: Hsien-Hung Herman Yeh Author-X-Name-First: Hsien-Hung Herman Author-X-Name-Last: Yeh Title: Adjustment behaviour of capital structure over the business cycles: evidence from the construction industry of Taiwan Abstract: Prior studies have found that firms may deviate from the target capital structure in the short run and adjust towards the target in the long run. However, little attention has been given to the adjustment behaviour of capital structure in the construction industry over the business cycles, in particular within the context of emerging markets. The partial adjustment model with the GMM (i.e. generalized method of moments) estimation is used to examine the adjustment behaviour of capital structure in the construction industry within the context of Taiwan during the period 1982 to 2007. The results suggest that, first, the average rate of adjustment is 26.3% of the adjustment gap between the target debt ratios and the previous debt ratios for firms in the construction industry of Taiwan. However, the average rate of adjustment towards the target debt ratios has slowed down after the Asian financial crisis of 1997. Secondly, firms with the financial constraint of over-leverage relative to the target debt ratios have lower debt ratios than those firms with the financial constraint of under-leverage. In addition, the difference in debt ratios between firms with the financial constraint of over-leverage and under-leverage has become narrower after the Asian financial crisis. Lastly, the findings suggest that macroeconomic conditions do not have a significant, negative effect on debt ratios. Journal: Construction Management and Economics Pages: 329-340 Issue: 4 Volume: 29 Year: 2011 Keywords: Capital structure, financial constraint, macroeconomic conditions, construction industry, Taiwan, X-DOI: 10.1080/01446193.2011.562910 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.562910 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:4:p:329-340 Template-Type: ReDIF-Article 1.0 Author-Name: Margaret Chan Author-X-Name-First: Margaret Author-X-Name-Last: Chan Title: Fatigue: the most critical accident risk in oil and gas construction Abstract: Construction work in oil and gas projects is both challenging and hazardous. The occupational hazards are often associated with fatigue and stress, and an accident is one possible outcome. The purpose of the two-part study was to identify the new and emergent risks within the top 10 ranked risks and to evaluate their contribution to accidents. Three hundred and twenty stakeholders, from four oil and gas construction projects in mainland China participated in the survey questionnaire. Fifteen workers, who have experienced actual fatigue-related accidents, were also interviewed. All of the stakeholders unanimously ranked fatigue as the most critical risk perceived to cause accidents with emotional disturbance, the emergent risk. This is the first time that fatigue has been identified as the leading accident risk in the construction industry. It was further reported as a trigger risk to a bundle of other synergetic risks. The new discovery confirms the need to consider fatigue as a complex multidimensional phenomenon and the lynchpin to reducing accidents. These findings have created new responses to the problem of accident causation and alternative views to accident mitigation. The discoveries will open new opportunities for future research in the areas of fatigue and stress risk management in construction. Journal: Construction Management and Economics Pages: 341-353 Issue: 4 Volume: 29 Year: 2011 Keywords: Accident, China, fatigue, gas construction, oil construction, X-DOI: 10.1080/01446193.2010.545993 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2010.545993 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:4:p:341-353 Template-Type: ReDIF-Article 1.0 Author-Name: Ashraf Elazouni Author-X-Name-First: Ashraf Author-X-Name-Last: Elazouni Author-Name: Osama Salem Author-X-Name-First: Osama Author-X-Name-Last: Salem Title: Progress monitoring of construction projects using pattern recognition techniques Abstract: Project monitoring involves collecting the actual-progress data, and comparing them against the relevant planned-progress data to evaluate the overall project progress at specified cut-off dates. Inevitable issues including variations in reporting skills as well as the willingness to record accurate data impact on the quality of the collected data. Comparison against multiple possible benchmarks (one-to-many) rather than a single benchmark (one-to-one) offers the potential to alleviate the negative impact of low-quality data on the progress evaluation. Special patterns, which can be readily manipulated within computer programs, are devised to encode the planned and actual progress at the cut-off dates. Basically, pattern recognition techniques are utilized to classify the multiple patterns representing the planned progress at a given cut-off date and the classification is used to evaluate the pattern representing the actual progress at the same date. The pattern recognition techniques generalize a virtual benchmark to represent the planned progress based on multiple patterns generated at a given cut-off date and representing possible benchmarks. In addition to the alleviation of the negative impact of low-quality data on the progress evaluation, the generalization feature potentially encourages a long-run attitude in site personnel to report high-quality data. Finally, the pattern recognition concept and technique proved their robustness to monitor and evaluate the overall progress of the projects based on the technique of critical path method. Journal: Construction Management and Economics Pages: 355-370 Issue: 4 Volume: 29 Year: 2011 Keywords: Progress monitoring, project control, pattern recognition, artificial neural network, statistical models, X-DOI: 10.1080/01446193.2011.554846 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.554846 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:4:p:355-370 Template-Type: ReDIF-Article 1.0 Author-Name: Jutta Schade Author-X-Name-First: Jutta Author-X-Name-Last: Schade Author-Name: Thomas Olofsson Author-X-Name-First: Thomas Author-X-Name-Last: Olofsson Author-Name: Marcus Schreyer Author-X-Name-First: Marcus Author-X-Name-Last: Schreyer Title: Decision-making in a model-based design process Abstract: Decisions early in the design process have a big impact on the life cycle performance of a building. The outcome of a construction project can be improved if different design options can rapidly be analysed to assist the client and design team in making informed decisions in the design process. A model-based design approach can facilitate the decision-making process if the design alternatives' performances can be evaluated and compared. A decision-making framework using a performance-based design process in the early design phase is proposed. It is developed to support decision-makers to take informed decisions regarding the life cycle performance of a building. A scenario is developed in order to demonstrate the proposed framework of evaluating the different design alternatives' energy performance. The framework is applicable to decision-making in a structured design process, where design alternatives consisting of both objective and subjective evaluation criteria can be evaluated. Journal: Construction Management and Economics Pages: 371-382 Issue: 4 Volume: 29 Year: 2011 Keywords: Decision making, design process, energy, design decision, BIM, X-DOI: 10.1080/01446193.2011.552510 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.552510 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:4:p:371-382 Template-Type: ReDIF-Article 1.0 Author-Name: Mohamed Issa Author-X-Name-First: Mohamed Author-X-Name-Last: Issa Author-Name: Mohamed Attalla Author-X-Name-First: Mohamed Author-X-Name-Last: Attalla Author-Name: Jeff Rankin Author-X-Name-First: Jeff Author-X-Name-Last: Rankin Author-Name: A. John Christian Author-X-Name-First: A. John Author-X-Name-Last: Christian Title: Energy consumption in conventional, energy-retrofitted and green LEED Toronto schools Abstract: Green buildings have been marketed as the economical, energy-efficient alternative to conventional buildings. This is despite little existing empirical evidence to prove their energy efficiency, especially in Canada. To overcome this limitation, the electricity and gas consumption quantities and costs of a sample of 10 conventional, 20 energy-retrofitted and three green Toronto schools following the Leadership in Energy and Environmental Design Rating (LEED) System for New Construction were analysed in this study. The analysis conducted over eight years for conventional and energy-retrofitted schools, and since their inception for green schools, showed surprisingly that energy-retrofitted and green schools spent 37% more on electricity than conventional schools. Nevertheless, green schools spent 56% and 41% less on gas than conventional and energy-retrofitted schools respectively. Their total energy costs were also 28% lower than conventional and energy-retrofitted schools. Nevertheless, these savings do not always justify their construction cost premiums. The study showed that more research was needed to overcome the scarcity of data on green buildings in Canada. There was a need to focus on analysing more green buildings, of various types, and over longer study periods in order to better understand why some green buildings do not live up to expectations. Journal: Construction Management and Economics Pages: 383-395 Issue: 4 Volume: 29 Year: 2011 Keywords: Energy consumption, green buildings, cost, X-DOI: 10.1080/01446193.2011.552511 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.552511 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:4:p:383-395 Template-Type: ReDIF-Article 1.0 Author-Name: Kun Hu Author-X-Name-First: Kun Author-X-Name-Last: Hu Author-Name: Hazhir Rahmandad Author-X-Name-First: Hazhir Author-X-Name-Last: Rahmandad Author-Name: Tonya Smith-Jackson Author-X-Name-First: Tonya Author-X-Name-Last: Smith-Jackson Author-Name: Woodrow Winchester Author-X-Name-First: Woodrow Author-X-Name-Last: Winchester Title: Factors influencing the risk of falls in the construction industry: a review of the evidence Abstract: Falls are a significant public health risk and a leading cause of non-fatal and fatal injuries among construction workers worldwide. A more comprehensive understanding of casual factors leading to fall incidents is essential to prevent falls in the construction industry. However, an extensive overview of causal factors is missing from the literature. In this paper, 536 articles on factors contributing to the risk of falls were retrieved. One hundred and twenty-one (121) studies met the criteria for relevance and quality to be coded, and were synthesized to provide an overview. In lieu of the homogeneity needed across studies to conduct a structured meta-analysis, a literature synthesis method based on macro-variables was advanced. This method provides a flexible approach to aggregating previous findings and assessing agreement across those studies. Factors commonly associated with falls included working surfaces and platforms, workers' safety behaviours and attitudes, and construction structure and facilities. Significant differences across qualitative and quantitative studies were found in terms of focus, and areas with limited agreement in previous research were identified. The findings contribute to research on the causes of falls in construction, developing engineering controls, informing policy and intervention design to reduce the risk of falls, and improving research synthesis methods. Journal: Construction Management and Economics Pages: 397-416 Issue: 4 Volume: 29 Year: 2011 Keywords: Accident causes, causal map, literature synthesis methods, safety, X-DOI: 10.1080/01446193.2011.558104 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.558104 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:4:p:397-416 Template-Type: ReDIF-Article 1.0 Author-Name: Matthew Hallowell Author-X-Name-First: Matthew Author-X-Name-Last: Hallowell Author-Name: Behzad Esmaeili Author-X-Name-First: Behzad Author-X-Name-Last: Esmaeili Author-Name: Paul Chinowsky Author-X-Name-First: Paul Author-X-Name-Last: Chinowsky Title: Safety risk interactions among highway construction work tasks Abstract: Recent research has produced frameworks for integrating safety risk data into project schedules, visual models and other construction planning tools. Unfortunately, only a few studies have attempted to quantify base-level safety risk for construction tasks and no study has attempted to quantify the degree to which spatial and temporal interactions among tasks contribute to the potential for injury. A research study was performed to quantify the impact that pair-wise spatial and temporal interactions have on the base-level risk of 25 common highway construction work tasks in the United States. Six hundred risk interactions were quantified by obtaining and aggregating over 23 500 individual ratings from certified experts using the Delphi method. The results indicate that incompatible tasks may increase the base-level risk up to 60%. The most incompatible highway construction tasks are: (1) installing curbs and gutters and installing rigid pavement; and (2) construction zone traffic control and installing rigid pavement. Additionally, watering and dust palliatives and pavement marking is the one compatible task pair and there are 45 neutral task pairs. The resulting database and analysis have the potential to increase the efficacy of existing frameworks for integration of safety risk data with project planning tools. Journal: Construction Management and Economics Pages: 417-429 Issue: 4 Volume: 29 Year: 2011 Keywords: Project management, risk analysis, safety, X-DOI: 10.1080/01446193.2011.552512 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.552512 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:4:p:417-429 Template-Type: ReDIF-Article 1.0 Author-Name: Raj Kapur Shah Author-X-Name-First: Raj Kapur Author-X-Name-Last: Shah Author-Name: Nashwan Dawood Author-X-Name-First: Nashwan Author-X-Name-Last: Dawood Title: An innovative approach for generation of a time location plan in road construction projects Abstract: Existing linear scheduling methods for earthwork activities lack accurate scheduling locations in road construction projects. Project planners and construction managers largely depend on subjective decisions for the allocation of resources at correct locations. This has caused uncertainties in planning and scheduling, and consequently delays and cost overruns of projects. Accurate information of working locations is vital for efficient resource planning, scheduling and equipment mobilisation. A theoretical framework for a virtual construction prototype model is developed using the theory of location-based planning and this is used as the basis of sensitivity analysis to identify critical factors affecting road construction. An arithmetic algorithm is developed by incorporating road design data, sectional quantities, variable productivity data, unit cost, site access points and haulage distance. The model generates a time location plan automatically with the aim to provide location-based scheduling information of earthwork activities. Weekly progress profiles, terrain surfaces, cost profiles and S-curve are the other outputs of the model. Data and information collected from the case studies are used to demonstrate functionalities of the model. Critical factors controlling the productivity of earthwork activities such as different types of equipment, soil characteristics and site access points were used to display the sensitivity effect by means of 'what-if scenarios'. The model is a valuable tool in analysing impacts of different factors associated with productivity data and resource planning from location aspects in the earthwork construction projects. Journal: Construction Management and Economics Pages: 435-448 Issue: 5 Volume: 29 Year: 2011 Keywords: Earthworks planning, linear scheduling, productivity, time location plan, sensitivity analysis, X-DOI: 10.1080/01446193.2011.563785 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.563785 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:5:p:435-448 Template-Type: ReDIF-Article 1.0 Author-Name: Yong-Woo Kim Author-X-Name-First: Yong-Woo Author-X-Name-Last: Kim Author-Name: Seungheon Han Author-X-Name-First: Seungheon Author-X-Name-Last: Han Author-Name: Sungwon Shin Author-X-Name-First: Sungwon Author-X-Name-Last: Shin Author-Name: Kunhee Choi Author-X-Name-First: Kunhee Author-X-Name-Last: Choi Title: A case study of activity-based costing in allocating rebar fabrication costs to projects Abstract: How to improve cost allocation for reinforced steel bar (rebar) is an ongoing topic of debate among construction manufacturers and contractors. Traditionally, many fabrication shops have used a single overhead-cost pool accounting system. However, a new costing method, activity-based costing (ABC), may provide more advantages than the traditional system. In this case study, a single overhead-cost pool system is compared with the ABC method to demonstrate how ABC improves cost allocation and provides other benefits. The case study findings indicate that ABC provides such benefits as (1) accurate manufacturing costs; (2) cost information on processes; and (3) information on cost drivers. This paper also bridges the construction and cost accounting literature. Our study contributes to the construction management literature by offering a different cost allocation method to refine fabrication costs assigned to projects. The findings are expected to serve as a reference for industry professionals who recognize the shortcomings of a traditional single overhead-cost pool system and are in need of a more accurate costing system. Journal: Construction Management and Economics Pages: 449-461 Issue: 5 Volume: 29 Year: 2011 Keywords: Rebar fabrication, activity-based costing, overhead cost allocation, X-DOI: 10.1080/01446193.2011.570354 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.570354 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:5:p:449-461 Template-Type: ReDIF-Article 1.0 Author-Name: Ajibade Ayodeji Aibinu Author-X-Name-First: Ajibade Ayodeji Author-X-Name-Last: Aibinu Author-Name: Florence Yean Yng Ling Author-X-Name-First: Florence Yean Yng Author-X-Name-Last: Ling Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Title: Structural equation modelling of organizational justice and cooperative behaviour in the construction project claims process: contractors' perspectives Abstract: A cooperative attitude is essential for successful teamwork in construction. The levels of conflict and dispute on construction projects are conceptualized as forms of cooperative/uncooperative attitude. A theoretical model demonstrates how conflict intensity, contractors' dispute tendencies and six identified constructs of organizational justice interact with and relate to each other. The model is tested using a structural equation modelling technique with partial least-squares estimation. It uses survey data obtained from 41 contractors regarding their project experience. The results suggest that perceptions about organizational justice either promote or hinder cooperative behaviour in the construction project delivery process. Organizational justice, or at least people's perceptions of it, influenced 38% of conflict intensity levels, and altered 46% of contractors' tendencies to dispute. Perceptions about the quantum of claims approved (favourability of the outcome and the perceived fairness of the outcome) influenced the levels of conflict and dispute. However, the way people are treated (quality of treatment) and the way claims are administered (quality of decision-making) have the largest impact on the model developed. Cooperative behaviour can be promoted on projects by managing construction claims in a proactive manner and by proper implementation of the claims mechanism. Journal: Construction Management and Economics Pages: 463-481 Issue: 5 Volume: 29 Year: 2011 Keywords: Claims, cooperation, conflict, organizational justice, structural equation model, X-DOI: 10.1080/01446193.2011.564195 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.564195 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:5:p:463-481 Template-Type: ReDIF-Article 1.0 Author-Name: Abdulaziz Jarkas Author-X-Name-First: Abdulaziz Author-X-Name-Last: Jarkas Author-Name: Malcolm Horner Author-X-Name-First: Malcolm Author-X-Name-Last: Horner Title: Revisiting the applicability of learning curve theory to formwork labour productivity Abstract: The learning phenomenon has proved applicable in various industries, especially those associated with mass productions, such as aircraft and automobile assembly. The learning process in labour-intensive industries is assumed to be more significant in the sense that automated work is constrained by the fact that machines cannot benefit from previous experience and therefore would not 'learn' to run any faster or increase the rate of production. Several previous investigations into the applicability of learning curve theory to the construction industry proved the importance of this concept to labour productivity. Nevertheless, a thorough examination of the literature revealed a dearth of research into the effect of learning on the formwork operation of building floors. Consequently, the objective of this research is to explore the influence of recurring building floor configurations on formwork labour productivity. To achieve this objective, formwork labour inputs from 45 multi-storey in situ reinforced concrete building frames were collected and analysed using the straight-line learning curve model. The cumulative average input for each cycle, i.e. floor, and its associated cycle number were modelled using the least squares method. According to the learning curve theory, we expect the labour inputs to decrease by a certain percentage, as the cycle number increases. Based on the results obtained, there is very little evidence for that. Journal: Construction Management and Economics Pages: 483-493 Issue: 5 Volume: 29 Year: 2011 Keywords: Formwork, labour inputs, labour productivity, learning curve theory, learning phenomenon, X-DOI: 10.1080/01446193.2011.562911 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.562911 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:5:p:483-493 Template-Type: ReDIF-Article 1.0 Author-Name: Sofia Pemsel Author-X-Name-First: Sofia Author-X-Name-Last: Pemsel Author-Name: Kristian Widen Author-X-Name-First: Kristian Author-X-Name-Last: Widen Title: Bridging boundaries between organizations in construction Abstract: Organizations have boundaries that serve various purposes; for example, differentiating internal operations from external activities and controlling flows of information. Boundaries can however hinder knowledge exchange in inter-organizational collaboration, leading to less effective outcomes. Empirical results from comparative case studies on how boundaries between organizations in a project can be bridged effectively to support knowledge exchange are presented. End-user organizations and real estate companies form the subjects of the enquiry. The results show that the depth of involvement of the end-user organization varies widely and, with it, the use of bridging roles and activities. To identify bridging strategies that can foster productive knowledge exchange in inter-organizational collaboration, it is necessary to understand contextual aspects of end-users' needs to ensure the availability of sufficient competence within, and time for, the project team to perform its duties. Journal: Construction Management and Economics Pages: 495-506 Issue: 5 Volume: 29 Year: 2011 Keywords: Organizational boundaries, communication, bridging strategies, end-users, projects, X-DOI: 10.1080/01446193.2011.563786 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.563786 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:5:p:495-506 Template-Type: ReDIF-Article 1.0 Author-Name: John Gambatese Author-X-Name-First: John Author-X-Name-Last: Gambatese Author-Name: Matthew Hallowell Author-X-Name-First: Matthew Author-X-Name-Last: Hallowell Title: Factors that influence the development and diffusion of technical innovations in the construction industry Abstract: Some technical innovations diffuse rapidly throughout the construction industry while others take a long time or are never integrated into everyday practice. Understanding the initiation, development, implementation and outcomes of successful technical innovations within the construction industry provides guidance for the improvement of the innovation process. To further this understanding, innovation generating organizations (IGOs) in the construction industry were surveyed and the data were statistically analysed. Two sources were used to identify newly developed products, technologies and management strategies: the Construction Innovation Forum's NOVA Award website and the Emerging Construction Technologies (ECT) website. A total of 233 innovative products were identified from the two websites. The results showed that there are many statistically significant motivating factors for investment in the initial development of successful technical innovation, barriers and enablers to efficient diffusion and innovation outcomes on construction projects. Additionally, successful development, implementation and diffusion of an innovative product required an average of 38 months, 4700 worker-hours and $836 000. Journal: Construction Management and Economics Pages: 507-517 Issue: 5 Volume: 29 Year: 2011 Keywords: Innovation, design, technology, X-DOI: 10.1080/01446193.2011.570355 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.570355 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:5:p:507-517 Template-Type: ReDIF-Article 1.0 Author-Name: S. Thomas Ng Author-X-Name-First: S. Author-X-Name-Last: Thomas Ng Author-Name: Ryan Fan Author-X-Name-First: Ryan Author-X-Name-Last: Fan Author-Name: James Wong Author-X-Name-First: James Author-X-Name-Last: Wong Title: An econometric model for forecasting private construction investment in Hong Kong Abstract: Acknowledging the importance of the private construction market and a close linkage between private construction investment, public sector output and general economic conditions, there is a strong motivation to develop reliable models to forecast private construction investment. Based on the Hong Kong scenario, two modelling approaches, namely the vector error correction (VEC) and the multiple regression models are developed and compared for their modelling accuracy and ability to handle non-stationary time series data. The result suggests that private construction investment in Hong Kong can be predicted by reference to public investment in construction, gross domestic product (GDP) and unemployment rate. All in all, the VEC model is considered more accurate and robust in handling non-stationary data. Through the VEC model, it is possible to confirm that the crowding-in effect of public work programmes, though minimal, is discernible in private construction investment in Hong Kong. Yet private construction investment is more sensitive to general economic conditions, as represented by GDP and unemployment rate. The GDP could represent the ability of investors to pay for construction items, while the unemployment rate is used as a proxy for the willingness of end-users to purchase the construction items. The models proposed should help policy and decision makers formulate suitable policies and strategies to sustain the construction industry in the medium to long run. Journal: Construction Management and Economics Pages: 519-534 Issue: 5 Volume: 29 Year: 2011 Keywords: Private construction investment, vector error correction model, regression analysis, stationarity, crowding-in effect, X-DOI: 10.1080/01446193.2011.570356 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.570356 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:5:p:519-534 Template-Type: ReDIF-Article 1.0 Author-Name: Fen-may Liou Author-X-Name-First: Fen-may Author-X-Name-Last: Liou Author-Name: Chien-hui Yang Author-X-Name-First: Chien-hui Author-X-Name-Last: Yang Author-Name: Boarliang Chen Author-X-Name-First: Boarliang Author-X-Name-Last: Chen Author-Name: Weichi Chen Author-X-Name-First: Weichi Author-X-Name-Last: Chen Title: Identifying the Pareto-front approximation for negotiations of BOT contracts with a multi-objective genetic algorithm Abstract: The build-operate-transfer (BOT) project is formulated based upon cooperative partnerships among various public and private parties. Win-win negotiation solutions are especially essential for parties that usually have conflicts of interests. A simulation-based multi-objective genetic algorithm (SMOGA) procedure is developed to address conflicts among the objectives of three parties: government and consumer interests that focus on users' rights and social welfare; the private investor's pursuit of profit maximization; and lenders who want to control the solvency risk of the concessionaire. Taking the Kaohsiung cable car project in Taiwan as an example, the SMOGA procedure is used to seek terms and conditions lying on or near the Pareto frontier for BOT projects with multi-objectives. Monte Carlo simulation is conducted first to determine the project risks and generate the sample data used as the input of the genetic algorithm (GA). The GA subsequently generates a number of combinations of concessional terms and conditions that approximately and simultaneously optimize the three conflicting objectives. The GA-generated approximate Pareto frontier provides a decision space of financial and concessional terms and conditions that satisfies all parties and facilitates the negotiations of BOT contracts. Journal: Construction Management and Economics Pages: 535-548 Issue: 5 Volume: 29 Year: 2011 Keywords: Build-operate-transfer, genetic algorithms, Monte Carlo simulation, Pareto frontier, X-DOI: 10.1080/01446193.2011.564196 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.564196 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:5:p:535-548 Template-Type: ReDIF-Article 1.0 Author-Name: John Gambatese Author-X-Name-First: John Author-X-Name-Last: Gambatese Author-Name: Matthew Hallowell Author-X-Name-First: Matthew Author-X-Name-Last: Hallowell Title: Enabling and measuring innovation in the construction industry Abstract: Innovation is vital to successful, long-term company performance in the construction industry. Understanding the innovation process, how innovation can be enhanced and how it can be measured are key steps to managing and enhancing innovation. The factors that affect innovation on a project were identified, as well as how these factors can be used to measure the level of innovation on a project, and the practices and processes that encourage and facilitate innovative changes. Case studies of construction projects in the United States revealed three necessary components of innovation: idea generation, opportunity and diffusion. A variety of practices are used to optimize each component including support and commitment from the owner/client and firm upper management, workforce and project team integration and diversity. Applying the practices identified in the research leads to enhanced innovation through better communication among project team members, integration of the design and construction disciplines, more efficient designs, development of unique ways of completing work and sharing of the lessons learned. The end result of innovation will be projects that successfully meet and exceed cost, quality, schedule and safety goals. Journal: Construction Management and Economics Pages: 553-567 Issue: 6 Volume: 29 Year: 2011 Keywords: Integrated team, innovation, organizational culture, organizational behaviour, project management, X-DOI: 10.1080/01446193.2011.570357 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.570357 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:6:p:553-567 Template-Type: ReDIF-Article 1.0 Author-Name: Hong Zhang Author-X-Name-First: Hong Author-X-Name-Last: Zhang Author-Name: Feng Xing Author-X-Name-First: Feng Author-X-Name-Last: Xing Author-Name: Juan Liu Author-X-Name-First: Juan Author-X-Name-Last: Liu Title: Rehabilitation decision-making for buildings in the Wenchuan area Abstract: The disastrous Wenchuan earthquake in 2008 claimed around 100 000 lives and caused direct economic losses of around RMB 845.1 billion. The tragedy has also led to accusations regarding poor or inadequate seismic resistant capabilities of buildings. Seismic rehabilitation, which includes repairing and strengthening existing or damaged buildings, is required to reduce losses in any future earthquakes. It is difficult to determine an appropriate rehabilitation option, especially for subjective or emotional building owners, because of the rehabilitation costs and the probabilistic nature of earthquake occurrences. A decision-making tree (DMT) model is proposed and constructed to help determine an economically feasible rehabilitation option. The required information, such as available rehabilitation options and costs, possible earthquake intensities and probabilities, possible damage, probabilities and loss of buildings is analysed and identified. Case analyses demonstrate the capability of the DMT model in making decisions on rehabilitation options for the buildings damaged during the Wenchuan earthquake, thus avoiding subjectivities or emotions. Journal: Construction Management and Economics Pages: 569-578 Issue: 6 Volume: 29 Year: 2011 Keywords: Decision-making tree, seismic rehabilitation, Wenchuan earthquake, buildings, economic losses, X-DOI: 10.1080/01446193.2011.569732 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.569732 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:6:p:569-578 Template-Type: ReDIF-Article 1.0 Author-Name: Budi Hartono Author-X-Name-First: Budi Author-X-Name-Last: Hartono Author-Name: Chee Meng Yap Author-X-Name-First: Chee Meng Author-X-Name-Last: Yap Title: Understanding risky bidding: a prospect-contingent perspective Abstract: A descriptive research school of thought provides the context for an examination of contractors' risky bid mark-up decisions in a competitive bidding setting. Grounded in prospect theory and the one-reason decision model, a contingency-based theoretical model was developed to explain and to predict bid mark-up decisions in light of four identified determinants, namely: perceived 'rate of returns', 'revenues', 'project backlogs' and 'project strategic importance'. Three scenarios according to this model were verified by means of a self-administered survey in the Singapore construction industry. By using cluster analysis, five groups of bidders with distinctive bid profiles were identified and the associated bid mark-ups were calculated. The emerging groups provide an empirical illustration on how the theoretical model is utilized. For instance, one group of bidders (n = 16) demonstrates a scenario of the model in which participating bidders had considered the reported project bid as having high strategic importance to their organizations and hence made aggressive, low bid mark-ups. The theoretically grounded framework could be used by contractors to improve their own bidding strategy in anticipating the likely behaviour of the competitors. Journal: Construction Management and Economics Pages: 579-593 Issue: 6 Volume: 29 Year: 2011 Keywords: Bidding, mark-up, contingency, cluster analysis, prospect theory, X-DOI: 10.1080/01446193.2011.569733 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.569733 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:6:p:579-593 Template-Type: ReDIF-Article 1.0 Author-Name: Cheryl Chi Author-X-Name-First: Cheryl Author-X-Name-Last: Chi Author-Name: Amy Nicole Javernick-Will Author-X-Name-First: Amy Author-X-Name-Last: Nicole Javernick-Will Title: Institutional effects on project arrangement: high-speed rail projects in China and Taiwan Abstract: Previous studies recognize institutional impacts on the arrangement of large infrastructure projects but they have not analysed the process by which a host country's institutions shape infrastructure projects. Institutional theory was applied as an analytical lens to identify different effects of regulatory, normative and cultural institutions on project arrangements. A cross-case comparative study of high-speed rail projects in China and Taiwan was conducted to investigate the processes through which political cultures and industrial structures determined the decisions for project arrangements, including delivery method, financing, participants' roles, the degree of private and foreign participation, and organization. Longitudinal archival methods combined with exploratory case studies were employed to examine project decisions by analysing government regulations, official publications, news articles, project documents and 20 interviews. A conceptual model was presented to integrate the findings. The political culture in each host country defines the political goals and legitimate approaches of large infrastructure projects, while industrial structure limits feasible alternatives for project arrangements. Collectively, they shape project arrangements and largely dictate the roles played by the government, private enterprises and foreign actors. Journal: Construction Management and Economics Pages: 595-611 Issue: 6 Volume: 29 Year: 2011 Keywords: Project arrangements, political culture, industrial structure, infrastructure, project, X-DOI: 10.1080/01446193.2011.569734 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.569734 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:6:p:595-611 Template-Type: ReDIF-Article 1.0 Author-Name: Selin Gundes Author-X-Name-First: Selin Author-X-Name-Last: Gundes Title: Input structure of the construction industry: a cross-country analysis, 1968-90 Abstract: During the past several decades, globalization has led to the integration of product markets. Rapid increases in cross-border economic, social, technological and cultural exchange have become the key elements of knowledge diffusion and thus technology spillovers among countries. As a result, the debate as to whether absolute convergence occurs at the cross-country level has increasingly attracted the attention of researchers. The aim of this study is to examine the changes in the input structure of the construction industry in nine developed countries between the late 1960s and 1990 and to evaluate whether convergence occurs at input industry level. The analysis of the technical coefficients for 35 industries reveals that, across countries and over time, not only the key inputs but also the new high and low input industries are similar. The estimation of variance factors on the other hand suggests that (1) during the sample period, the input structure of the industry is dominated by divergence rather than convergence; (2) among the input industries, services in particular tend for convergence; and (3) manufacturing inputs provide a mixed picture where only a few inputs show convergence and the remaining inputs show in general weak divergence. Journal: Construction Management and Economics Pages: 613-621 Issue: 6 Volume: 29 Year: 2011 Keywords: Construction sector, input structure, cross-country analysis, X-DOI: 10.1080/01446193.2011.563787 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.563787 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:6:p:613-621 Template-Type: ReDIF-Article 1.0 Author-Name: Benjamin Murray Author-X-Name-First: Benjamin Author-X-Name-Last: Murray Author-Name: Hedley Smyth Author-X-Name-First: Hedley Author-X-Name-Last: Smyth Title: Franchising in the US remodelling market: growth opportunities and barriers faced by general contractors Abstract: Residential remodelling contractors operate in a highly fragmented, disaggregated market. Competition and consolidation arise from other market actors, thus remodellers have diminished bargaining power and higher market risk since they traditionally service geographically specific markets. Franchising theories may provide a competitive business strategy to parallel consolidation in other actors. Yet a small population of remodelling franchises are listed in the US. The vast majority of these franchises were in specialty trades and only one general contracting franchise was represented. This raises the question as to what extent there are barriers to franchising in practice for general contractors in the US remodelling industry and whether opportunities exist for growth through franchising. First, economic theories of franchising are evaluated against secondary quantitative data and extant literature. Second, interviews were conducted among non-franchising, general remodellers. Two principal findings emerge. Human capital requirements are found to be a primary barrier to franchising. A second finding is the perceptual barrier among key decision-makers in founder-controlled firms. Therefore, the barriers are largely perceptual. The finding is reflected upon by introducing upper-echelon theory and ultimately suggests that as the profiles of company owners change, the perceptual barrier to franchising may be of lesser significance. Journal: Construction Management and Economics Pages: 623-634 Issue: 6 Volume: 29 Year: 2011 Keywords: Barriers to entry, franchising, general contractor, remodelling, X-DOI: 10.1080/01446193.2011.566622 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.566622 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:6:p:623-634 Template-Type: ReDIF-Article 1.0 Author-Name: Mohamed Abdel-Wahab Author-X-Name-First: Mohamed Author-X-Name-Last: Abdel-Wahab Author-Name: Bernard Vogl Author-X-Name-First: Bernard Author-X-Name-Last: Vogl Title: Trends of productivity growth in the construction industry across Europe, US and Japan Abstract: Productivity is a key driver for economic growth and prosperity in any country. The pursuit of productivity growth requires an understanding of the factors affecting productivity. The trend of productivity growth, along with the possible factors underlying such growth across Europe, the US and Japan, is thus examined. In particular, there is a focus on comparing the productivity performance of the construction sector to that of other industries. Using the recently released EU KLEMS1 database,2 a growth accounting framework was adopted to assess the contribution of the following factors to productivity growth (during 1971-2005): capital, labour quality and total factor productivity (TFP). It was found that there is a general slowdown in labour productivity growth in total industries including construction across major OECD countries, with the exception of the UK. The differences in labour productivity growth between construction and total industries can be largely explained by construction's poor TFP performance. With the exception of the UK, TFP negatively contributed to labour productivity growth in the period 1990-2005, suggesting that the industry has become less efficient in combining the factors of production. That phenomenon seems to be consistent across all selected countries and warrants further investigation. Indeed a better understanding of the factors underlying productivity growth in OECD countries is a prerequisite for effective intervention of policy makers to support sustained productivity growth. Journal: Construction Management and Economics Pages: 635-644 Issue: 6 Volume: 29 Year: 2011 Keywords: Productivity, growth accounting, skills, capital, X-DOI: 10.1080/01446193.2011.573568 File-URL: http://www.tandfonline.com/doi/abs/10.1080/01446193.2011.573568 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:6:p:635-644 Template-Type: ReDIF-Article 1.0 Author-Name: Marco K.W. Yu Author-X-Name-First: Marco K.W. Author-X-Name-Last: Yu Author-Name: Graham Ive Author-X-Name-First: Graham Author-X-Name-Last: Ive Title: Orders and output in UK construction statistics: new methodology and old problems Abstract: The Office for National Statistics in the UK has developed and adopted a new method for collecting and publishing construction statistics. The analysis of the revised construction new orders series and the associated new UK Department for Business, Innovation and Skills (BIS) output price index for all new construction leads to three conclusions: (1) the new indices have corrected two significant methodological errors, namely the underestimation of the number of main contractors and the underestimation of inflation by BIS output price indices for new construction; (2) the new indices addressed a concern, the orders--output ‘credibility gap’, in the construction output forecasting literature; and (3) care should be taken when using the revised orders series and new output price index for historic research because a ‘credibility gap’ exists between the two back series prior to 1990. Journal: Construction Management and Economics Pages: 653-658 Issue: 7 Volume: 29 Year: 2011 Month: 3 X-DOI: 10.1080/01446193.2011.574713 File-URL: http://hdl.handle.net/10.1080/01446193.2011.574713 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:7:p:653-658 Template-Type: ReDIF-Article 1.0 Author-Name: Emad Elbeltagi Author-X-Name-First: Emad Author-X-Name-Last: Elbeltagi Author-Name: Ossama A. Hosny Author-X-Name-First: Ossama A. Author-X-Name-Last: Hosny Author-Name: Ahmed Elhakeem Author-X-Name-First: Ahmed Author-X-Name-Last: Elhakeem Author-Name: Mohamed Emam Abd-Elrazek Author-X-Name-First: Mohamed Emam Author-X-Name-Last: Abd-Elrazek Author-Name: Ahmed Abdullah Author-X-Name-First: Ahmed Author-X-Name-Last: Abdullah Title: Selection of slab formwork system using fuzzy logic Abstract: Formwork plays an important role in building construction. The selection of an appropriate formwork system can reduce project cost, improve quality and speed up the construction process. Although the selection of an appropriate formwork system requires years of experience in formwork design, few experienced personnel may be available, especially in small/medium size contracting companies. With the lack of such experts, the costly outsourcing option becomes essential otherwise the selection of a particular formwork system might not be appropriate. A structured approach is developed to help decision makers in small/medium Egyptian construction companies to select the appropriate horizontal formwork system(s) for their projects. This can be achieved by recognizing the project governing factors affecting the selection process. Based on these factors, a knowledge base is developed to facilitate the process. A fuzzy logic system is used to automate the process and overcome ambiguity and uncertainty in the selection process. The system is shown to be useful and accurate in its application to a real-life case. A survey of formwork experts reveals its ease of use. Further research will expand the system to consider vertical formwork selection to ensure full compatibility. Journal: Construction Management and Economics Pages: 659-670 Issue: 7 Volume: 29 Year: 2011 Month: 5 X-DOI: 10.1080/01446193.2011.590144 File-URL: http://hdl.handle.net/10.1080/01446193.2011.590144 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:7:p:659-670 Template-Type: ReDIF-Article 1.0 Author-Name: Mariagrazia Squicciarini Author-X-Name-First: Mariagrazia Author-X-Name-Last: Squicciarini Author-Name: Anna-Leena Asikainen Author-X-Name-First: Anna-Leena Author-X-Name-Last: Asikainen Title: A value chain statistical definition of construction and the performance of the sector Abstract: Existing statistical analyses often fail to capture the true scope of the economic impact of the construction sector. They account for the construction of buildings, civil engineering, and construction specialized activities, as defined by Section F of the Statistical Classification of Economic Activities (or NACE) used in the European Community, but overlook related activities such as the manufacture of construction products and architectural and engineering services. This shortcoming is addressed and a wider definition of the construction sector is proposed that encompasses the whole value chain of the industry. Going beyond the ‘core’ construction sector section (Section F), activities from other NACE sectors that fully or principally depend upon or are functional to core construction activities are considered. These ‘non-core’ classes relate to ‘pre-production’ activities, such as the provision of intermediate goods and services; various ‘support’ activities and ‘post-production’ functions such as maintenance and management services. Equivalent broad definitions of the construction sector based on the North American Industry Classification System (NAICS) and the International Standard Industrial Classification (ISIC) are also developed to allow for optimum comparisons across countries and over time. Using detailed data from Finland and the Community Innovation Survey 4 (CIS4), core and non-core activities are characterized and quantified. Evidence suggests that indicators measuring the composition, structure, value added, skills, and R&D input and output of the construction sector change substantially when a broader definition of the sector is applied. Policies targeting the ‘wide’ construction sector, and exploiting the innovation, growth and productivity leverage potential of non-core activities are thus advocated. Journal: Construction Management and Economics Pages: 671-693 Issue: 7 Volume: 29 Year: 2011 Month: 3 X-DOI: 10.1080/01446193.2011.577438 File-URL: http://hdl.handle.net/10.1080/01446193.2011.577438 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:7:p:671-693 Template-Type: ReDIF-Article 1.0 Author-Name: Chia Fah Choy Author-X-Name-First: Chia Fah Author-X-Name-Last: Choy Title: Revisiting the ‘Bon curve’ Abstract: Bon’s proposition of an inverted U-shaped relationship between the share of construction activities and stages of economic development, which is commonly known as the ‘Bon curve’, has been explored in earlier studies. The previous studies adopted cross-sectional comparison comprising a number of selected countries over a period of time. This study revisits Bon’s theories with data maintained by the United Nations Statistics Division, which covers 205 economies from 1970 to 2009. Analysis of variance (ANOVA) and post hoc tests and quadratic regression were used in the verification process. Cross-sectional comparison and longitudinal analysis were used to verify Bon’s propositions. The inverted U-shaped relationship between construction activities and level of development was not confirmed when the aggregated data of all countries over time were considered simultaneously. The relationships across countries at a given time were not confirmed in the majority of the yearly aggregated data. The relationships within countries over time were confirmed in 78 economies, mostly from high and upper-middle income countries. Bon’s proposition of ‘volume follows share’ was not confirmed. Declines in construction were found in most of the high income economies. In conclusion, Bon’s curve is to be interpreted as explaining variation within the developed economies over time. Journal: Construction Management and Economics Pages: 695-712 Issue: 7 Volume: 29 Year: 2011 Month: 4 X-DOI: 10.1080/01446193.2011.578959 File-URL: http://hdl.handle.net/10.1080/01446193.2011.578959 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:7:p:695-712 Template-Type: ReDIF-Article 1.0 Author-Name: Patricia Carrillo Author-X-Name-First: Patricia Author-X-Name-Last: Carrillo Author-Name: Jenny Harding Author-X-Name-First: Jenny Author-X-Name-Last: Harding Author-Name: Alok Choudhary Author-X-Name-First: Alok Author-X-Name-Last: Choudhary Title: Knowledge discovery from post-project reviews Abstract: Many construction companies conduct reviews on project completion to enhance learning and to fulfil quality management procedures. Often these reports are filed away never to be seen again. This means that potentially important knowledge that may assist other project teams is not exploited. In order to ascertain whether useful knowledge can be gleaned from such reports, Knowledge Discovery from Text (KDT) and text mining (TM) are applied. Text mining avoids the need for a manual search through a vast number of reports, potentially of different formats and foci, to seek trends that may be useful for current and future projects. Pilot tests were used to analyse 48 post-project review reports. The reports were first reviewed manually to identify key themes. They were then analysed using text mining software to investigate whether text mining could identify trends and uncover useful knowledge from the reports. Pilot tests succeeded in finding common occurrences across different projects that were previously unknown. Text mining could provide a potential solution and would aid project teams to learn from previous projects. However, a lot of work is currently required before the text mining tests are conducted and the results need to be examined carefully by those with domain knowledge to validate the results obtained. Journal: Construction Management and Economics Pages: 713-723 Issue: 7 Volume: 29 Year: 2011 Month: 5 X-DOI: 10.1080/01446193.2011.588953 File-URL: http://hdl.handle.net/10.1080/01446193.2011.588953 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:7:p:713-723 Template-Type: ReDIF-Article 1.0 Author-Name: Sara Jane Wilkinson Author-X-Name-First: Sara Jane Author-X-Name-Last: Wilkinson Author-Name: Richard Reed Author-X-Name-First: Richard Author-X-Name-Last: Reed Title: Examining and quantifying the drivers behind alterations and extensions to commercial buildings in a central business district Abstract: The drive to undertake building adaptation has increased in momentum, the primary reason being adaptation can be less expensive than new build and conventionally result in faster project delivery times. The issue of sustainable development is another clear driver for adaptation and collectively buildings contribute around half of all greenhouse gas emissions. At the same time governments seek effective and efficient ways of reducing the contribution of cities to climate change and building adaptation appears to offer a practical means of reducing building-related emissions. One example is the ‘1200 building program’ which aims to increase adaptation rates with a target of 1200 city centre office adaptations by 2020 as part of the strategy to achieve carbon neutrality. Through a longitudinal examination of building adaptations it is possible to identify the nature and extent of typical levels of adaptation, as well as determining the inter-relationship between different types of adaptation and building attributes. Melbourne city centre was used for a case study which analysed 5290 building adaptation events between 1998 and 2008. The findings promote the adaptive reuse of buildings in specific circumstances and are directly applicable for increasing sustainability in the built environment. The case study focused on existing buildings in a global city to ensure relevance to urban centres where existing commercial buildings can become part of the solution to mitigate climate change. Journal: Construction Management and Economics Pages: 725-735 Issue: 7 Volume: 29 Year: 2011 Month: 5 X-DOI: 10.1080/01446193.2011.588954 File-URL: http://hdl.handle.net/10.1080/01446193.2011.588954 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:7:p:725-735 Template-Type: ReDIF-Article 1.0 Author-Name: Jie Gong Author-X-Name-First: Jie Author-X-Name-Last: Gong Author-Name: John D. Borcherding Author-X-Name-First: John D. Author-X-Name-Last: Borcherding Author-Name: Carlos H. Caldas Author-X-Name-First: Carlos H. Author-X-Name-Last: Caldas Title: Effectiveness of craft time utilization in construction projects Abstract: Achieving efficient craft time utilization in the execution of construction projects is of great interest to project stakeholders. Craft time utilization assessment methods, such as work sampling and five-minute rating, measure the effectiveness of labour utilization, expose excessive non-productive time in the execution of construction activities, and reflect the soundness of workface planning. Onsite time utilization studies were conducted on 98 construction projects during the period 1972--2009. Statistic analyses were performed on the collected data to investigate the evolution of direct work rates and crew effectiveness over time, to gain understanding on craft time utilization patterns, and to identify improvement opportunities. The results of analyses suggest that, among other findings, the direct work ratio in construction projects and crew effectiveness in various construction activities have not improved during this period, and there is a statistically significant difference on crew effectiveness across different types of activities as well as in activities with different team size. The findings provide baselines to support the definition of craft time utilization targets in productivity improvement initiatives. Journal: Construction Management and Economics Pages: 737-751 Issue: 7 Volume: 29 Year: 2011 Month: 6 X-DOI: 10.1080/01446193.2011.595013 File-URL: http://hdl.handle.net/10.1080/01446193.2011.595013 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:7:p:737-751 Template-Type: ReDIF-Article 1.0 Author-Name: Erika Levander Author-X-Name-First: Erika Author-X-Name-Last: Levander Author-Name: Susanne Engström Author-X-Name-First: Susanne Author-X-Name-Last: Engström Author-Name: Ylva Sardén Author-X-Name-First: Ylva Author-X-Name-Last: Sardén Author-Name: Lars Stehn Author-X-Name-First: Lars Author-X-Name-Last: Stehn Title: Construction clients’ ability to manage uncertainty and equivocality Abstract: While risk and uncertainty management have received much attention within construction management research, management of information interpretation remains unexplored. Situations that are generally overlooked are those where increased amounts and flow of information are not the solution to the human problem of managing multiple meanings of information and conflicting interpretations, i.e. ‘equivocality’. The aim is to identify and differentiate between construction clients’ uncertainty and equivocality about industrialized construction in Sweden, and, in the light of those findings, to evaluate clients’ current information processing practice on investment decisions in new-build in order to assess and discuss clients’ ability to manage uncertainty and equivocality. Based on information processing theory, analysis of aggregated data from three previous studies shows that there is a need to manage both uncertainty and equivocality. At the same time, clients’ ability to do this is found to be limited. Consequently, when industrialized construction moves clients beyond their current frame of reference, clients’ information processing practice does not support decision making. It is also proposed that differentiating between uncertainty and equivocality will enable a more profound understanding of the sequential order for information processing, i.e. that one must define questions (reduce equivocality) before one can find answers to the questions (reduce uncertainty). Journal: Construction Management and Economics Pages: 753-764 Issue: 7 Volume: 29 Year: 2011 Month: 6 X-DOI: 10.1080/01446193.2011.595423 File-URL: http://hdl.handle.net/10.1080/01446193.2011.595423 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:7:p:753-764 Template-Type: ReDIF-Article 1.0 Author-Name: Jim Meikle Author-X-Name-First: Jim Author-X-Name-Last: Meikle Title: Modern Construction Economics: Theory and Application Journal: Construction Management and Economics Pages: 765-766 Issue: 7 Volume: 29 Year: 2011 Month: 7 X-DOI: 10.1080/01446193.2011.587440 File-URL: http://hdl.handle.net/10.1080/01446193.2011.587440 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:7:p:765-766 Template-Type: ReDIF-Article 1.0 Author-Name: K.C. Iyer Author-X-Name-First: K.C. Author-X-Name-Last: Iyer Author-Name: Mohammed Sagheer Author-X-Name-First: Mohammed Author-X-Name-Last: Sagheer Title: A real options based traffic risk mitigation model for build-operate-transfer highway projects in India Abstract: Build-operate-transfer (BOT) has been one of the preferred models of public--private partnership (PPP) for attracting private capital in the Indian highway sector. In BOT projects the traffic demand is considered a critical risk. Through a concession agreement called the model concession agreement (MCA) a standardized risk allocation framework has been adopted for BOT highway projects in India. If the actual traffic volume deviates from the projected traffic, the MCA suggests varying the length of the concession period (by a pre-agreed formula) to mitigate the traffic demand risk. This arrangement has the limitation of guaranteeing the concessionaire against the shortfall in traffic demand while it bestows unlimited gain otherwise. Past researchers have also examined only the possibility of revenue guarantees to protect the concessionaire from downside risks due to variation in traffic. Therefore, a traffic band is proposed: a combination of traffic floor and traffic cap—which can ensure certainty as to the revenue streams of the private investor, while preventing him from appropriating windfall gains due to higher-than-expected traffic demand through an equitable risk and revenue sharing mechanism. A traffic band being quite analogous to financial options, the paper suggests use of a ‘put’ option held by the concessionaire to determine the traffic floor, while a ‘call’ option held by the government serves as the traffic ceiling. Application of the real options analogy to a real life case study using binomial lattice method indicates enhancement to the net present value of the project. Journal: Construction Management and Economics Pages: 771-779 Issue: 8 Volume: 29 Year: 2011 Month: 6 X-DOI: 10.1080/01446193.2011.597412 File-URL: http://hdl.handle.net/10.1080/01446193.2011.597412 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:8:p:771-779 Template-Type: ReDIF-Article 1.0 Author-Name: Eddie Chi-Man Hui Author-X-Name-First: Eddie Chi-Man Author-X-Name-Last: Hui Author-Name: Ivan Ng Author-X-Name-First: Ivan Author-X-Name-Last: Ng Author-Name: Otto Muk-Fai Lau Author-X-Name-First: Otto Muk-Fai Author-X-Name-Last: Lau Title: Speculative bubbles in mass and luxury properties: an investigation of the Hong Kong residential market Abstract: Fluctuations in housing prices not only affect the financial well-being of corporations and households, but also influence the stability of economies. One of the results derived from such fluctuations is known as price bubbles. We aim to investigate whether such housing price bubbles did exist in two different residential markets of Hong Kong. The results indicate that there are bubbles in the Hong Kong housing markets before 2003, and later within the luxury market by 2008. As to what the government could do to curb speculative activities with regard to housing, the introduction of a capital gains tax on short-term transactions of flats as well as a higher housing supply are regarded as effective means. Journal: Construction Management and Economics Pages: 781-793 Issue: 8 Volume: 29 Year: 2011 Month: 7 X-DOI: 10.1080/01446193.2011.610329 File-URL: http://hdl.handle.net/10.1080/01446193.2011.610329 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:8:p:781-793 Template-Type: ReDIF-Article 1.0 Author-Name: Ioannis E. Tsolas Author-X-Name-First: Ioannis E. Author-X-Name-Last: Tsolas Title: Modelling profitability and effectiveness of Greek-listed construction firms: an integrated DEA and ratio analysis Abstract: Existing research on construction performance measurement is dominated by project level studies, and the firm stakeholders require the development of models that compare performance in terms of efficiency. A new framework that integrates data envelopment analysis (DEA) and ratio analysis using a two-step approach is described to evaluate performance in terms of profitability and effectiveness of a sample of construction firms listed on the Athens Exchange. In the first step, profitability and effectiveness are assessed by employing DEA and by using the profit margin (i.e. income-to-sales ratio), respectively. In the second step, a Tobit and an ordinary least squares model are used in order to identify the drivers of profitability efficiency and effectiveness, respectively. Results do point out positive links between profitability efficiency and effectiveness. Profitability inefficiency can be explained by the size and expenses-to-total revenue ratio, whereas effectiveness can be explained only by the latter explanatory variable. The research framework may benefit not only Greek construction firms, but also firms in other countries to quantify their performance and improve their competitive advantages. Journal: Construction Management and Economics Pages: 795-807 Issue: 8 Volume: 29 Year: 2011 Month: 7 X-DOI: 10.1080/01446193.2011.610330 File-URL: http://hdl.handle.net/10.1080/01446193.2011.610330 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:8:p:795-807 Template-Type: ReDIF-Article 1.0 Author-Name: S.Z.S. Tabish Author-X-Name-First: S.Z.S. Author-X-Name-Last: Tabish Author-Name: Kumar Neeraj Jha Author-X-Name-First: Kumar Neeraj Author-X-Name-Last: Jha Title: Identification and evaluation of success factors for public construction projects Abstract: Achieving success in public construction projects is difficult because it requires economy, efficiency, quality, fairness and transparency. Such projects are taken up on the requisition of owners/clients and almost always involve multiple entities and are also accountable to external financial audit and vigilance agencies. Identification of the success factors is considered the key to achieving success in these projects. Through an extensive literature review, 36 success attributes were identified and a questionnaire-based survey was undertaken to elicit views of professionals on these success attributes. The responses from 105 professionals with an average of 22 years of experience in public construction projects in India were collected and analysed. The factor analysis yielded four success factors: awareness of and compliance with rules and regulations; pre-project planning and clarity in scope; effective partnering among project participants; and external monitoring and control. These four success factors were also used in multivariate linear regression in order to explore their relative significance for overall performance, and compliance with anti-corruption and financial norms. The most significant factor for overall performance is awareness of and compliance with rules and regulations. The results would be helpful to public construction project professionals in taking proactive measures for successful completion of public projects. Journal: Construction Management and Economics Pages: 809-823 Issue: 8 Volume: 29 Year: 2011 Month: 8 X-DOI: 10.1080/01446193.2011.611152 File-URL: http://hdl.handle.net/10.1080/01446193.2011.611152 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:8:p:809-823 Template-Type: ReDIF-Article 1.0 Author-Name: Christian Henjewele Author-X-Name-First: Christian Author-X-Name-Last: Henjewele Author-Name: Ming Sun Author-X-Name-First: Ming Author-X-Name-Last: Sun Author-Name: Peter Fewings Author-X-Name-First: Peter Author-X-Name-Last: Fewings Title: Critical parameters influencing value for money variations in PFI projects in the healthcare and transport sectors Abstract: Achieving good value for money (VFM) is the principal objective of any private finance initiative (PFI) project while sustaining it throughout the contract life is the greatest challenge. Empirical evidence is required to understand uncertainties surrounding VFM of PFI before finding effective ways to improve it. Variations in costs, time and client requirements are explored, between successive review stages of PFI projects from the strategic business case stage through to the operational phase. The magnitudes of these variations are established and critical parameters that influence them are identified. The research methods include a documentary analysis of the full business cases of five PFI projects and a questionnaire survey of 44 PFI projects from the healthcare and transport sectors in the UK. The findings reveal that the current VFM assessment of PFI projects is often carried out under conditions of considerable uncertainty with frequent changes in costs, timescales and client requirements. The list of critical parameters can help practitioners to identify priority areas and achieve a long-lasting VFM. The study broadens the understanding of whole life aspects of VFM of PFI projects and the interactivity of project parameters at different stages. Journal: Construction Management and Economics Pages: 825-839 Issue: 8 Volume: 29 Year: 2011 Month: 5 X-DOI: 10.1080/01446193.2011.592204 File-URL: http://hdl.handle.net/10.1080/01446193.2011.592204 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:8:p:825-839 Template-Type: ReDIF-Article 1.0 Author-Name: Emrah Acar Author-X-Name-First: Emrah Author-X-Name-Last: Acar Author-Name: Yasemin Göç Author-X-Name-First: Yasemin Author-X-Name-Last: Göç Title: Prediction of risk perception by owners’ psychological traits in small building contractors Abstract: Risk decisions in small companies are not only based on the rational evaluations of the likelihood and magnitude of risks, but also rely on the personal traits of the owners, who are the dominant or single decision makers in their organizations. The major hypothesis of this paper is that risk management decisions in a small organization cannot be separated from the personality of its owner. Studying the risk perception of owners may be important to understand the ways they handle risky and ambiguous situations across different domains and to devise project risk management strategies that fit in with the particular needs of small companies. Owners’ risk perception related to building projects was statistically predicted by their psychological and demographic traits along with a set of organizational variables. Statistical analyses of data from 32 small general contractors specializing in residential and commercial building construction portray the risk-taking profile of owners and suggest that individuals with low risk propensity in health and financial domains have a higher risk perception, which is also positively associated with organizational size. These findings confirm the domain-specific nature of risk taking and provide a basis to examine thoroughly the project management strategies and actions at individual level in the case of smaller companies. Journal: Construction Management and Economics Pages: 841-852 Issue: 8 Volume: 29 Year: 2011 Month: 8 X-DOI: 10.1080/01446193.2011.611521 File-URL: http://hdl.handle.net/10.1080/01446193.2011.611521 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:8:p:841-852 Template-Type: ReDIF-Article 1.0 Author-Name: Colin C. Williams Author-X-Name-First: Colin C. Author-X-Name-Last: Williams Author-Name: Sara J. Nadin Author-X-Name-First: Sara J. Author-X-Name-Last: Nadin Author-Name: Jan Windebank Author-X-Name-First: Jan Author-X-Name-Last: Windebank Title: Undeclared work in the European construction industry: evidence from a 2007 Eurobarometer survey Abstract: A widespread assumption has been that undeclared work is rife in the European construction industry. Despite this, there have been no European-wide surveys of the prevalence and character of undeclared work in this sector of the economy. To fill this gap, the findings are reported of a 2007 Eurobarometer survey on undeclared work involving 26 659 face-to-face interviews undertaken in 27 European Union member states. This reveals the widespread prevalence of undeclared work in the European construction industry along with its heterogeneous forms and uneven distribution both spatially and across different groups of the construction workforce. It then evaluates what needs to be done to tackle this problem. The argument is that doing nothing is seldom an option because this leaves intact the existing negative impacts of undeclared work on construction businesses, the construction workforce, customers and governments. Pursuing the eradication of such work is neither effective nor necessarily desirable since most governments wish to move such endeavour into the declared realm rather than simply eradicate it. In consequence, this paper advocates a policy approach of facilitating the formalization of declared work and then details a range of preventative, curative and commitment policy measures for achieving this in the European construction industry. Journal: Construction Management and Economics Pages: 853-867 Issue: 8 Volume: 29 Year: 2011 Month: 7 X-DOI: 10.1080/01446193.2011.610331 File-URL: http://hdl.handle.net/10.1080/01446193.2011.610331 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:8:p:853-867 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Fenn Author-X-Name-First: Peter Author-X-Name-Last: Fenn Title: Mediation in the Construction Industry: An International Review Journal: Construction Management and Economics Pages: 869-869 Issue: 8 Volume: 29 Year: 2011 Month: 8 X-DOI: 10.1080/01446193.2011.602353 File-URL: http://hdl.handle.net/10.1080/01446193.2011.602353 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:8:p:869-869 Template-Type: ReDIF-Article 1.0 Author-Name: Ernst Jan De Place Hansen Author-X-Name-First: Ernst Jan Author-X-Name-Last: De Place Hansen Author-Name: Jacob Norvig Larsen Author-X-Name-First: Jacob Norvig Author-X-Name-Last: Larsen Title: Employment and winter construction: a comparative analysis of Denmark and western European countries with a similar climate Abstract: Reduced seasonal building activity in the construction sector is often assumed to be related to hard winter conditions for building activities and poor working conditions for construction workers, resulting in higher costs and poor quality of building products, particularly in the northern hemisphere. Can climatic conditions alone explain the sizeable difference in reduction in building activity in the construction sector in European countries in the winter months, or are other factors such as technology, economic cycles and schemes for financial compensation influential as well? What possibilities exist for reducing seasonal variation in employment? In addition to a literature review related to winter construction, European and national employment and meteorological data were studied. Finally, ministerial acts, ministerial orders or other public policy documents related to winter construction were scrutinized in order to identify and compare economic incentives and compensation schemes intended to increase winter working in construction in Denmark and other western European countries. Overall, economic development in the construction sector and the level of compensation or the duration of contracts for workers is more likely to explain differences in seasonal activity than climatic or technological factors. Journal: Construction Management and Economics Pages: 875-890 Issue: 9 Volume: 29 Year: 2011 Month: 8 X-DOI: 10.1080/01446193.2011.617762 File-URL: http://hdl.handle.net/10.1080/01446193.2011.617762 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:9:p:875-890 Template-Type: ReDIF-Article 1.0 Author-Name: Alan Griffith Author-X-Name-First: Alan Author-X-Name-Last: Griffith Title: Delivering best value in the small works portfolio of public sector organizations when using preferred contractors Abstract: The use of preferred contractors through a partnering arrangement is a prominent method of relationship-based procurement. The approach is frequently applied to managing the small works portfolio of public authorities. While the apparent benefits to client organizations of employing preferred contractors are widely known, questions surrounding the timeliness, duration, risk, disruption, quality and cost of works in the public sector are often rightly asked. The process and practices involved in small works procurement and management are crucial to the successful management of a public authority’s portfolio and they are examined in this research with the support of three case studies. The findings highlight that: the characteristics of small works, which are of fundamental influence on their effective undertaking, are often misunderstood; the criteria describing successful small works are not well recognized; small works are sometimes inappropriately planned and undertaken inefficiently; and the worksite environment and local inhabitants are largely ignored when works are carried out. To improve the procurement and management of individual small works and the wider small works portfolio there must be better oversight practices during procurement and throughout works administration by public authorities and their contracted partners coupled with more effective management and onsite supervision by contractors. Journal: Construction Management and Economics Pages: 891-900 Issue: 9 Volume: 29 Year: 2011 Month: 8 X-DOI: 10.1080/01446193.2011.617377 File-URL: http://hdl.handle.net/10.1080/01446193.2011.617377 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:9:p:891-900 Template-Type: ReDIF-Article 1.0 Author-Name: Kumar Neeraj Jha Author-X-Name-First: Kumar Neeraj Author-X-Name-Last: Jha Author-Name: CT Chockalingam Author-X-Name-First: CT Author-X-Name-Last: Chockalingam Title: Prediction of schedule performance of Indian construction projects using an artificial neural network Abstract: Approximately 42% of Indian government-funded construction projects are facing time overruns. With a number of challenging projects around the corner, there is a definite need to overcome these delays. In an earlier study conducted by one of the authors, 55 project performance attributes were identified based on expert opinions and literature surveys, which were subsequently reduced to 20 factors (11 success and nine failure factors) using factor analysis. A second-stage questionnaire survey based on these factors was used to identify the significant schedule performance factors. The analysis of the survey responses led us to conclude that factors such as: a project manager’s competence; monitoring and feedback by project participants; commitment of all project participants; owner’s competence; interaction between external project participants; and good coordination between project participants significantly affect schedule performance. The survey also provided the basis for the development of a schedule performance prediction model. For this, an artificial neural network (ANN) method was used to construct the model, and the best was determined to be a 6-3-1 feed-forward neural network based on a back-propagation algorithm with a mean absolute percentage deviation (MAPD) of 11%. This enables project team members to understand the factors they must monitor closely in order to complete the projects on schedule and to predict performance throughout the course of the project. Journal: Construction Management and Economics Pages: 901-911 Issue: 9 Volume: 29 Year: 2011 Month: 7 X-DOI: 10.1080/01446193.2011.608691 File-URL: http://hdl.handle.net/10.1080/01446193.2011.608691 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:9:p:901-911 Template-Type: ReDIF-Article 1.0 Author-Name: R. David Espinoza Author-X-Name-First: R. David Author-X-Name-Last: Espinoza Title: Contingency estimating using option pricing theory: closing the gap between theory and practice Abstract: Valuation of contingency budgets for construction projects considering technical and market uncertainties as well as the time it takes to execute the project can be estimated using option pricing theory. Although option pricing theory provides an attractive framework for calculation of contingency budgets, it typically results in complex highly non-linear partial differential equations that require the use of numerical algorithms and computer intensive techniques, thus making it difficult for practitioners to adopt this valuation technique. An attempt to bridge the gap between theory and practice is made by proposing an equivalent linear stochastic process to model the complex non-linear random variation with time of the technical and market uncertainty for projects. The approximation allows estimation of contingency budgets using either closed-form solutions for pricing options, or the intuitive binomial approach. To validate the proposed equivalent linear solution, its results were compared to the solution to the non-linear partial differential equation that governs the pricing of contingency budgets solved by Monte Carlo simulations. A parametric study of the error shows that the proposed approximation to estimate contingency budgets compares well with the results obtained from simulation. The main advantages of the proposed solution are its simplicity and straightforward implementation. Journal: Construction Management and Economics Pages: 913-927 Issue: 9 Volume: 29 Year: 2011 Month: 7 X-DOI: 10.1080/01446193.2011.610328 File-URL: http://hdl.handle.net/10.1080/01446193.2011.610328 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:9:p:913-927 Template-Type: ReDIF-Article 1.0 Author-Name: Angela McCabe Author-X-Name-First: Angela Author-X-Name-Last: McCabe Author-Name: Rachel Parker Author-X-Name-First: Rachel Author-X-Name-Last: Parker Author-Name: Kerry Brown Author-X-Name-First: Kerry Author-X-Name-Last: Brown Title: Social outcomes in the construction industry: the case of the Western Australian ‘Percent for Art’ policy Abstract: Social outcomes, in particular intangible social outcomes, are generally difficult to achieve in the construction industry due to the predominantly episodic, fragmented and heavily regulated nature of construction that presupposes a tendency towards mainstream construction processes and design. The Western Australian ‘Percent for Art’ policy is recognized for stimulating social outcomes, by creating richer and more aesthetically pleasing social environments through the incorporation of artwork into public buildings. A case study of four Percent for Art projects highlights the role of the Artwork Selection Committee in incorporating artwork into construction. A total of 20 semi-structured interviews were conducted with committee members and policy officers. Data analysis involved a combination of pattern coding and matrix categorization, and resulted in the identification of the committee’s three key elements of collaborative communication, democratic decision-making and project champions. The findings suggest these key elements foster the interaction, communication and relationships needed to facilitate feedback, enhance relationships, create cross-functional teams and lower project resistance, which are all necessary to overcome constraints to social outcomes in construction. The findings provide greater insight into the mechanisms for achieving social outcomes and a basis for future discussion about the processes for achieving social outcomes in the construction industry. Journal: Construction Management and Economics Pages: 929-941 Issue: 9 Volume: 29 Year: 2011 Month: 7 X-DOI: 10.1080/01446193.2011.605794 File-URL: http://hdl.handle.net/10.1080/01446193.2011.605794 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:9:p:929-941 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Title: The overworked site manager: gendered ideologies in the construction industry Abstract: Organizations are sites where gendered ideologies are established and played out and in the case of the construction industry there is a strong underrepresentation of women and ethnic minorities in certain positions such as site managers. Masculine ideologies here denote the totality of norms, belief and assumptions that serve to enact specific images of e.g. leadership work. In the case of the Swedish construction industry, the site manager role is enacted as a paternal figure having full control of the situation, always in the position to take care of emerging and unforeseen events, and spending long hours at work. Such site management role is thus reproducing gender ideologies, imposing expectations on individual site managers, and erecting entry barriers for e.g. women or individuals not willing to forsake family life. The managerial implications are that the construction industry needs to critically evaluate what demands are put on site managers and how to create more balanced leadership positions. Journal: Construction Management and Economics Pages: 943-955 Issue: 9 Volume: 29 Year: 2011 Month: 5 X-DOI: 10.1080/01446193.2011.588955 File-URL: http://hdl.handle.net/10.1080/01446193.2011.588955 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:9:p:943-955 Template-Type: ReDIF-Article 1.0 Author-Name: Sanjay Sampat Wakchaure Author-X-Name-First: Sanjay Sampat Author-X-Name-Last: Wakchaure Author-Name: Kumar Neeraj Jha Author-X-Name-First: Kumar Neeraj Author-X-Name-Last: Jha Title: Prioritization of bridges for maintenance planning using data envelopment analysis Abstract: Resources—especially funds allotted—for the maintenance of bridges, are generally scanty. Thus, it becomes difficult to select bridges for maintenance from among several competing bridges to ensure their safety and serviceability to the desired level. A bridge health index is considered a reasonably accurate depiction of the condition of a bridge and hence is the basis for most of the decisions on fund allocation. However, it still remains to be seen whether such a decision-making tool results in an efficient fund allocation. From data collected on Indian bridges, it is observed that fund allocation based on bridge condition is not always judicious. Rather, a number of factors affect the final decision on fund allocation. Hence, an alternative approach of data envelopment analysis (DEA) has been used for scoring the efficiency of 14 bridges selected for the study. Depending on the availability of data, this method can take into account other factors besides the bridge health index that influence decisions on maintenance planning. The variables selected for the DEA are: bridge health index, deck area of the bridge, maintenance cost of the bridge, and the age of the bridge. The allocation of funds for the maintenance of bridges based on DEA has proved to be comparatively more efficient. This has been illustrated with the help of a numerical example. The proposed method would enable bridge authorities to formulate better strategies for planning and executing bridge maintenance activities in a cost-effective manner. Journal: Construction Management and Economics Pages: 957-968 Issue: 9 Volume: 29 Year: 2011 Month: 8 X-DOI: 10.1080/01446193.2011.614267 File-URL: http://hdl.handle.net/10.1080/01446193.2011.614267 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:9:p:957-968 Template-Type: ReDIF-Article 1.0 Author-Name: Heng Jiang Author-X-Name-First: Heng Author-X-Name-Last: Jiang Author-Name: Chunlu Liu Author-X-Name-First: Chunlu Author-X-Name-Last: Liu Title: Forecasting construction demand: a vector error correction model with dummy variables Abstract: Modelling the level of demand for construction is vital in policy formulation and implementation as the construction industry plays an important role in a country’s economic development process. In construction economics, research efforts on construction demand modelling and forecasting are various, but few researchers have considered the impact of global economy events in construction demand modelling. An advanced multivariate modelling technique, namely the vector error correction (VEC) model with dummy variables, was adopted to predict demand in the Australian construction market. The results of prediction accuracy tests suggest that the general VEC model and the VEC model with dummy variables are both acceptable for forecasting construction economic indicators. However, the VEC model that considers external impacts achieves higher prediction accuracy than the general VEC model. The model estimates indicate that the growth in population, changes in national income, fluctuations in interest rates and changes in householder expenditure all play significant roles when explaining variations in construction demand. The VEC model with disturbances developed can serve as an experimentation using an advanced econometrical method which can be used to analyse the effect of specific events or factors on the construction market growth. Journal: Construction Management and Economics Pages: 969-979 Issue: 9 Volume: 29 Year: 2011 Month: 8 X-DOI: 10.1080/01446193.2011.611522 File-URL: http://hdl.handle.net/10.1080/01446193.2011.611522 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:9:p:969-979 Template-Type: ReDIF-Article 1.0 Author-Name: S.Z.S. Tabish Author-X-Name-First: S.Z.S. Author-X-Name-Last: Tabish Author-Name: Kumar Neeraj Jha Author-X-Name-First: Kumar Neeraj Author-X-Name-Last: Jha Title: The impact of anti-corruption strategies on corruption free performance in public construction projects Abstract: Despite extensive efforts, corruption in public procurement has reached epidemic proportions and has become one of the major challenges for management. Because corrupt practices mostly occur under wraps, the task of combating corruption becomes even more difficult. In the course of a review of the extant literature on the theme a number of independent constructs with the potential to develop anti-corruption strategies have been identified. A research model was developed on the basis of the hypothesis that anti-corruption strategies lead to corruption free performance in public construction projects. A questionnaire survey was administered and 105 responses were collected. ‘Anti-corruption strategies’ was defined as a second order construct composed of four latent constructs: leadership, rules and regulations, training and fear of punishment. The structural equation modelling (SEM) technique was used to test the hypothesized positive inter-relations between anti-corruption strategies and corruption free performance. The significance of the role of management leadership, rules and regulations, training, as well as fear of punishment is highlighted to help policy makers and construction institutions in understanding the role of various anti-corruption strategies in public construction projects so that they may contribute to this important endeavour in achieving the goal of promoting economy, efficiency, quality, fairness and transparency. Journal: Construction Management and Economics Pages: 21-35 Issue: 1 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2011.654128 File-URL: http://hdl.handle.net/10.1080/01446193.2011.654128 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:1:p:21-35 Template-Type: ReDIF-Article 1.0 Author-Name: Abdul-Rashid Abdul-Aziz Author-X-Name-First: Abdul-Rashid Author-X-Name-Last: Abdul-Aziz Title: Control mechanisms exercised in Malaysian housing public-private partnerships Abstract: There is a dearth of publications on the actual implementation of housing public-private partnerships (PPPs), especially in developing countries. Control mechanisms used by public agencies in Malaysia under PPP arrangements to ensure private partner compliance were examined. The governance archetypes which prevailed in the PPP relationships were also identified. The control mechanisms typology prepared by management accounting scholars was used as the theoretical framework. Qualitative data, mainly from informants, were collected from 10 public agencies using the multi-case approach. The case studies were found to adopt specific control mechanisms when choosing suitable partners (exploratory phase), crafting the agreement (contract phase) and firming up control activities (execution phase). These mechanisms are associated with bureaucracy and hybrid governance archetypes, but not the market governance archetype. Recommendations to improve the effectiveness of certain control mechanisms deployed by the case studies are presented at the end of the paper. Public agencies in Malaysia and abroad which share the same housing PPP variant as Malaysia’s are recommended to adopt transferable best practices contained within the respective control mechanisms. Construction management scholars should consider adopting the control mechanism typology for their own research undertakings. Journal: Construction Management and Economics Pages: 37-55 Issue: 1 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2011.654129 File-URL: http://hdl.handle.net/10.1080/01446193.2011.654129 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:1:p:37-55 Template-Type: ReDIF-Article 1.0 Author-Name: Ximing Ruan Author-X-Name-First: Ximing Author-X-Name-Last: Ruan Author-Name: Edward G. Ochieng Author-X-Name-First: Edward G. Author-X-Name-Last: Ochieng Author-Name: Andrew D.F. Price Author-X-Name-First: Andrew D.F. Author-X-Name-Last: Price Author-Name: Charles O. Egbu Author-X-Name-First: Charles O. Author-X-Name-Last: Egbu Title: Knowledge integration process in construction projects: a social network analysis approach to compare competitive and collaborative working Abstract: Research on knowledge integration across organizational boundaries is still very limited because of the assumption that knowledge is a critical asset, which should be secured within organizational boundaries. A variety of knowledge management frameworks have presented the same common characteristics, including information sharing as the basis for knowledge management, a supportive culture, trust and proximity. Social network analysis is used to examine the knowledge integration process in collaborative and competitive working systems on four case study projects based on public sector organizations. This involved shadowing participants and conducting interviews. Participants were selected from a set of functional teams according to their role. Five participants were interviewed from each project in order to check the validity and reliability of the data. The knowledge integration patterns are presented by quantitative methods using the social network analysis approach. Journal: Construction Management and Economics Pages: 5-19 Issue: 1 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2011.654127 File-URL: http://hdl.handle.net/10.1080/01446193.2011.654127 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:1:p:5-19 Template-Type: ReDIF-Article 1.0 Author-Name: Pertti Lahdenperä Author-X-Name-First: Pertti Author-X-Name-Last: Lahdenperä Title: Making sense of the multi-party contractual arrangements of project partnering, project alliancing and integrated project delivery Abstract: Collaborative construction project arrangements have been the subject of many development efforts owing to the frustration felt toward the opportunism inherent in traditional contracting. Globally, three approaches have stood out: project partnering, project alliancing and integrated project delivery. These so-called relational project delivery arrangements have much in common. This study aims to clarify the similarities and differences between the arrangements by examining their key concepts and features one by one and in relation to each other; the motivation behind each is also examined. Early involvement of key parties, transparent financials, shared risk and reward, joint decision-making, and a collaborative multi-party agreement are some of the features incorporated in all the arrangements to a varying degree. Beyond the numerous details, divergent applications and constant evolution presented, the study also recognizes project alliancing as a project delivery system in its own right due to its contractual structure that integrated project delivery aims to imitate while introducing some management approaches not included in project alliancing. Project partnering, although developed in leaps and bounds since its introduction, takes a more conservative approach to work scope and liabilities. Similarly, project alliancing takes relational contracting to the extreme compared to the current forms of integrated project delivery and, especially, project partnering. Journal: Construction Management and Economics Pages: 57-79 Issue: 1 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2011.648947 File-URL: http://hdl.handle.net/10.1080/01446193.2011.648947 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:1:p:57-79 Template-Type: ReDIF-Article 1.0 Author-Name: David William Cattell Author-X-Name-First: David William Author-X-Name-Last: Cattell Title: An overview of component unit pricing theory Abstract: Component unit pricing (CUP) theory presents a fresh approach to item pricing, described as the process of distributing the overall price among its constituent component items. This theory provides explanation and proof that different distributions of mark-up among the items of a project produce different levels of reward for contractors, while exposing them to different degrees of risk. The theory describes the three identified sources of these rewards, namely those of improved cash flow, escalation in compensation and valuations of likely variations. In addition, it also provides the first explanation of the three risks involved, namely the risk of ‘rejection’, the risk of ‘reaction’ and the risk of ‘being wrong’. In combination, it provides a means by which both the rewards as well as these risks can now be measured given any pricing scenario. This theory gives effect to fuzzy constraints on the price of each item, providing a scientific basis by which to identify more extreme prices when pursuing more profit and more restrained prices when seeking to reduce risk. Overall, it provides a basis by which to moderate these two objectives in the pursuit of the maximization of a contractor’s utility. A test on a hypothetical project indicates an improvement of more than 150% on utility, if a contractor applies this theory, compared to the position when balanced prices are used instead. Journal: Construction Management and Economics Pages: 81-92 Issue: 1 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2011.648948 File-URL: http://hdl.handle.net/10.1080/01446193.2011.648948 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:1:p:81-92 Template-Type: ReDIF-Article 1.0 Author-Name: Anita Liu Author-X-Name-First: Anita Author-X-Name-Last: Liu Title: Corporate Strategy in Construction: Understanding Today’s Theory and Practice Journal: Construction Management and Economics Pages: 93-95 Issue: 1 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2011.648946 File-URL: http://hdl.handle.net/10.1080/01446193.2011.648946 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:1:p:93-95 Template-Type: ReDIF-Article 1.0 Author-Name: Ani Raiden Author-X-Name-First: Ani Author-X-Name-Last: Raiden Title: Harvesting and Managing Knowledge in Construction Journal: Construction Management and Economics Pages: 95-97 Issue: 1 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2011.651482 File-URL: http://hdl.handle.net/10.1080/01446193.2011.651482 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:1:p:95-97 Template-Type: ReDIF-Article 1.0 Author-Name: Roberta Pellegrino Author-X-Name-First: Roberta Author-X-Name-Last: Pellegrino Author-Name: Nicola Costantino Author-X-Name-First: Nicola Author-X-Name-Last: Costantino Author-Name: Roberto Pietroforte Author-X-Name-First: Roberto Author-X-Name-Last: Pietroforte Author-Name: Silvio Sancilio Author-X-Name-First: Silvio Author-X-Name-Last: Sancilio Title: Construction of multi-storey concrete structures in Italy: patterns of productivity and learning curves Abstract: The achievement of expected site productivity is one of the main characteristics of successfully completed projects. The productivity rates of concrete construction according to the learning curve theory are discussed in this paper. The study builds upon the records of variable productivity rates achieved in the erection of 15 multi-storey concrete structures in Southern Italy and the discussion of the factors behind such variability. In this last regard, a multilevel regression analysis identifies the most important factors. The repetitive work that characterizes these structures provides distinct opportunities for productivity enhancement. Learning curve theory is applied to quantify such an improvement by using a straight-line model. The quantification of learning rates, ranging from 85% to 95%, is useful for the labour cost and time planning of future concrete structures in the region. In the case of Italian sites, the application of the learning curve would be more beneficial if more effort were spent in the planning and control of the initial construction site operations and in the constructability analysis of design documents. Journal: Construction Management and Economics Pages: 103-115 Issue: 2 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.660776 File-URL: http://hdl.handle.net/10.1080/01446193.2012.660776 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:2:p:103-115 Template-Type: ReDIF-Article 1.0 Author-Name: Eddie Chi-Man Hui Author-X-Name-First: Eddie Chi-Man Author-X-Name-Last: Hui Author-Name: Tony K.K. Lo Author-X-Name-First: Tony K.K. Author-X-Name-Last: Lo Author-Name: Jia Chen Author-X-Name-First: Jia Author-X-Name-Last: Chen Author-Name: Ziyou Wang Author-X-Name-First: Ziyou Author-X-Name-Last: Wang Title: Housing and consumer markets in urban China Abstract: In China, the real estate sector has been one of the most powerful driving forces in economic development over the past two decades. The housing sector, particularly, has a strong wealth effect on consumption. This has attracted much attention not only in academia but also in society at large. Yet little is known about the relationship between housing and consumption in urban China. An investigation into the causal relationship between the money flow of the housing market and that of the consumer market for local citizens in urban China applies a recently developed method: renormalized partial directed coherence (renormalized PDC). This is an advanced tool to exclude the indirect relationships between the housing and consumer markets. Since the original renormalized PDC cannot show the result numerically, we quantify the relationships by developing a set of criteria for further discussion within the renormalized PDC framework. The empirical work reveals two major findings: (1) the retail price level is quite useful in predicting the housing turnover-income ratio; (2) the rental price is one of the most important factors affecting the fluctuation of retail prices for the case of urban areas in China. A housing turnover-income ratio (HTIR) is developed to evaluate the money flow into the housing market, which provides a new way to carry out data analysis when the usual indicators might be inappropriate. The research provides a reference point for economic policymaking for the relationship between the money flow into the housing market and the money flow into the consumer market. Journal: Construction Management and Economics Pages: 117-131 Issue: 2 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2011.654130 File-URL: http://hdl.handle.net/10.1080/01446193.2011.654130 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:2:p:117-131 Template-Type: ReDIF-Article 1.0 Author-Name: Sanjay S. Wakchaure Author-X-Name-First: Sanjay S. Author-X-Name-Last: Wakchaure Author-Name: Kumar Neeraj Jha Author-X-Name-First: Kumar Neeraj Author-X-Name-Last: Jha Title: Determination of bridge health index using analytical hierarchy process Abstract: Owners of bridges all over the world are facing the task of maintaining them within limited resources. The allocation of resources among the competing deteriorating bridges is a difficult task. Bridge health indices are used for deciding the priority of bridges for maintenance, and for the allocation of resources. Ascertaining the relative importance of bridge components is a prime requirement in the development of the indices. Based on the available literature and preliminary discussions with experts in this field, the bridge components were grouped into seven categories and a questionnaire was developed. The responses to the questionnaire were used in the analytical hierarchy process for deciding the weights (relative importance) of each bridge component. Consequently, based on the literature review, different condition states were defined, and a quantification of different distress types, corresponding to each of the condition states, was made. The weights and condition states of different bridge components were used to develop a bridge health index. The condition states were obtained using visual inspection, according to the definition. The index can be applied easily by different stakeholders for ranking a number of bridges in a bridge stock for maintenance actions, thereby optimizing resources. Journal: Construction Management and Economics Pages: 133-149 Issue: 2 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.658075 File-URL: http://hdl.handle.net/10.1080/01446193.2012.658075 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:2:p:133-149 Template-Type: ReDIF-Article 1.0 Author-Name: Huimin Li Author-X-Name-First: Huimin Author-X-Name-Last: Li Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Author-Name: Zhuofu Wang Author-X-Name-First: Zhuofu Author-X-Name-Last: Wang Title: Transaction-related issues and construction project performance Abstract: Transaction cost economics deals with costs incurred at the pre-contract phase such as the costs of conducting market research, exploring financial opportunities, conducting a feasibility study, organizing a bidding/negotiation and managing design; and with costs incurred in the post-contract phase such as the costs of administering the contract, administering change orders and claims, resolving disputes and managing incentives. Many researchers have investigated the factors that affect project performance over the years, but neglected to consider transaction-related issues. The effects of transaction-related issues on project performance are investigated in this study. Project performance is measured on the basis of completion within budget and on schedule, compliance with quality standards, and satisfaction of the owner. Transaction-related issues include the magnitude of transaction costs, the uncertainty in the transaction environment, and the owner’s and the contractor’s roles in the transaction. Hypotheses are tested by using a structural equation model using data collected from a survey administered to construction owners. The findings indicate that project performance can be stronger if the uncertainty in the transaction environment is minimized, transaction costs are kept low, and owners and contractors are sensitive to transaction-related issues. Journal: Construction Management and Economics Pages: 151-164 Issue: 2 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.655254 File-URL: http://hdl.handle.net/10.1080/01446193.2012.655254 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:2:p:151-164 Template-Type: ReDIF-Article 1.0 Author-Name: Katie Shawn Dewlaney Author-X-Name-First: Katie Shawn Author-X-Name-Last: Dewlaney Author-Name: Matthew Hallowell Author-X-Name-First: Matthew Author-X-Name-Last: Hallowell Title: Prevention through design and construction safety management strategies for high performance sustainable building construction Abstract: Recent studies have found that Leadership in Energy and Environmental Design (LEED) buildings have a higher injury rate than traditional non-LEED buildings and that 12 of the LEED credits increase risks for construction workers. The objective was to identify and describe risk mitigation strategies that reduce the safety risk associated with the design and construction of high performance sustainable projects by conducting extensive interviews with experienced designers and constructors. Fortunately, feasible prevention techniques through design and construction safety management strategies exist and can be used to mitigate the safety risk associated with the design features and means and methods of construction used to achieve LEED certification. Most commonly, designers and contractors identified prefabrication, effective site layout and alternative products as methods to prevent injuries that specifically relate to the hazards of each sustainable element. The results of the interviews and results from previous research were organized into a decision support tool built in Adobe LiveCycle. Practitioners may use the findings and the tool to enhance safety for construction workers, an aspect of sustainability that is not currently addressed in the LEED Program. Researchers may also use the techniques described as a starting point for lifecycle safety analyses for sustainable buildings. Journal: Construction Management and Economics Pages: 165-177 Issue: 2 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2011.654232 File-URL: http://hdl.handle.net/10.1080/01446193.2011.654232 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:2:p:165-177 Template-Type: ReDIF-Article 1.0 Author-Name: Russell Kenley Author-X-Name-First: Russell Author-X-Name-Last: Kenley Title: Managing Change in Construction Projects: A Knowledge-based Approach Journal: Construction Management and Economics Pages: 179-180 Issue: 2 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.655751 File-URL: http://hdl.handle.net/10.1080/01446193.2012.655751 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:2:p:179-180 Template-Type: ReDIF-Article 1.0 Author-Name: John Connaughton Author-X-Name-First: John Author-X-Name-Last: Connaughton Title: Who Needs Migrant Workers? Labour Shortages, Immigration, and Public Policy Journal: Construction Management and Economics Pages: 180-183 Issue: 2 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.655249 File-URL: http://hdl.handle.net/10.1080/01446193.2012.655249 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:2:p:180-183 Template-Type: ReDIF-Article 1.0 Author-Name: Allan Ashworth Author-X-Name-First: Allan Author-X-Name-Last: Ashworth Title: The Impact of Building Information Modelling: Transforming Construction Journal: Construction Management and Economics Pages: 183-185 Issue: 2 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.655250 File-URL: http://hdl.handle.net/10.1080/01446193.2012.655250 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:2:p:183-185 Template-Type: ReDIF-Article 1.0 Author-Name: Fang Dongping Author-X-Name-First: Fang Author-X-Name-Last: Dongping Author-Name: Wang Tao Author-X-Name-First: Wang Author-X-Name-Last: Tao Title: Green Buildings and the Law Journal: Construction Management and Economics Pages: 185-187 Issue: 2 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.655251 File-URL: http://hdl.handle.net/10.1080/01446193.2012.655251 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:2:p:185-187 Template-Type: ReDIF-Article 1.0 Author-Name: Pim M. A. Polesie Author-X-Name-First: Pim M. A. Author-X-Name-Last: Polesie Title: Reducing the use of resources in medium-sized Swedish construction enterprises: production managers’ views Abstract: What construction firms do—and do not do—to reduce the use of resources in construction projects is explored by adopting production managers’ views of their firms’ onsite activities. A literature review and empirical data are combined; 15 production managers have been asked how they perceived their company’s compliance with 31 recommendations to reduce the use of resources. The managers perceived their firms to primarily focus on identifying their customers’ real needs, stimulating employees to undertake further education, and striving for long-term customer--supplier relationships. In contrast, they perceived that less attention was directed to making use of all of the week’s hours, to supporting their main suppliers in their development, and planning feedback and training after project completion. The use of resources is examined by focusing on the perceived low priority given to gathering information and knowledge, as well as to reducing time and the need for long-term relationships with customers in contrast to short-term relationships with suppliers. The managers adopted a project-specific approach mainly to the use of material resources. A more holistic view of resources could enable the development of novel solutions in construction. Journal: Construction Management and Economics Pages: 193-202 Issue: 3 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.658823 File-URL: http://hdl.handle.net/10.1080/01446193.2012.658823 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:3:p:193-202 Template-Type: ReDIF-Article 1.0 Author-Name: Manuel Schoenwitz Author-X-Name-First: Manuel Author-X-Name-Last: Schoenwitz Author-Name: Mohamed Naim Author-X-Name-First: Mohamed Author-X-Name-Last: Naim Author-Name: Andrew Potter Author-X-Name-First: Andrew Author-X-Name-Last: Potter Title: The nature of choice in mass customized house building Abstract: There is a need to explore the actual uptake of specification options by clients in the context of the self-build housing industry. In so doing all the components in a house that can be customized were categorized so as to highlight the features that must be customizable and those that can be standardized. Through a longitudinal study of a German house builder, data from 16 projects over a 35-year time horizon have been collected. The extent of choice made in these projects has been determined by comparing the original standard building specification with the actual finalized fit-out specification of the project. In scrutinizing the collected data it became apparent that the number of changes made by the clients increased considerably over the timespan studied. More importantly, clients appreciated the freedom of choice as they were prepared to spend increasing amounts on customization. In particular specification options were made in the sanitary, internal design and façade categories. Moreover the results revealed that offering a high degree of choice is appropriate for most, but not all, components for the case house builder. Key areas for choice include those relating to sanitary ware and the façade. Journal: Construction Management and Economics Pages: 203-219 Issue: 3 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.664277 File-URL: http://hdl.handle.net/10.1080/01446193.2012.664277 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:3:p:203-219 Template-Type: ReDIF-Article 1.0 Author-Name: Ranon Chotibhongs Author-X-Name-First: Ranon Author-X-Name-Last: Chotibhongs Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Title: Analysis of collusive bidding behaviour Abstract: Researchers have attempted to develop methods that detect collusive bidding. But no method can detect collusion with certainty unless it is based on legal evidence. A method is proposed to detect collusive bidding behaviour that improves the performance of previous methods. It analyses the historical bidding data provided by a construction owner in a two-step approach which is mainly based on a multiple regression model. The first step involves identifying the potential cartel bidders using the residual test and the cost structure stability test developed in earlier work. The second step is the focus of this paper and involves comparing the behaviour of the potential cartel bidders and non-cartel bidders by analysing bid distributions, their cost dispersion, and the differences in their cost structures. After conducting the second step of the study, it was found that the suspected cartel bidders identified in Step 1 behaved in ways to confirm collusion. Also, in an unrelated search, it was found that two of the six potential cartel bidders who were identified in this study had been audited by the public agency for bid fraud, and that another potential cartel bidder had been found guilty by the courts and forbidden from doing business with the public agency. Journal: Construction Management and Economics Pages: 221-231 Issue: 3 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.661443 File-URL: http://hdl.handle.net/10.1080/01446193.2012.661443 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:3:p:221-231 Template-Type: ReDIF-Article 1.0 Author-Name: Steven Devaney Author-X-Name-First: Steven Author-X-Name-Last: Devaney Author-Name: Deb Roberts Author-X-Name-First: Deb Author-X-Name-Last: Roberts Title: Who gets the jobs? Factors influencing the employability of property and construction graduates in the UK Abstract: Against a background of a strongly performing property market, the last decade saw a significant rise in numbers of entrants to undergraduate and postgraduate built environment programmes in the UK. The growth in postgraduate numbers reflected the emergence of conversion programmes with the result that, across a range of built environment pathways, employers can choose between different types of graduate: those straight from an undergraduate degree, those who have completed an additional postgraduate course or those who have taken, following a first degree in another discipline, a conversion programme in property or construction at postgraduate level. A bivariate probit modelling approach is used to explore whether having a postgraduate taught (PGT) qualification systematically improves the probability of finding graduate level employment. Different built environment programmes are considered, while controlling for other factors that may influence employment outcomes, including university type, mode of study, gender, ethnicity and age. The results suggest that a postgraduate degree in land and property management significantly increases the probability of gaining graduate level employment, but this is not so for construction, quantity surveying or building surveying. The findings are discussed in the wider context of changes in UK higher education. Journal: Construction Management and Economics Pages: 233-246 Issue: 3 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2011.654233 File-URL: http://hdl.handle.net/10.1080/01446193.2011.654233 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:3:p:233-246 Template-Type: ReDIF-Article 1.0 Author-Name: Hans Lind Author-X-Name-First: Hans Author-X-Name-Last: Lind Title: Sustainable Buildings in Practice: What the Users Think Journal: Construction Management and Economics Pages: 247-248 Issue: 3 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.655252 File-URL: http://hdl.handle.net/10.1080/01446193.2012.655252 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:3:p:247-248 Template-Type: ReDIF-Article 1.0 Author-Name: Pierre Bonnal Author-X-Name-First: Pierre Author-X-Name-Last: Bonnal Title: Project Management Journal: Construction Management and Economics Pages: 248-250 Issue: 3 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.655253 File-URL: http://hdl.handle.net/10.1080/01446193.2012.655253 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:3:p:248-250 Template-Type: ReDIF-Article 1.0 Author-Name: David Boyd Author-X-Name-First: David Author-X-Name-Last: Boyd Title: The Architecture of Information: Architecture, Interaction Design and the Patterning of Digital Information Journal: Construction Management and Economics Pages: 250-251 Issue: 3 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.656134 File-URL: http://hdl.handle.net/10.1080/01446193.2012.656134 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:3:p:250-251 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Pichura Author-X-Name-First: Alexander Author-X-Name-Last: Pichura Title: The Architect’s Portfolio: Planning, Design, Production Journal: Construction Management and Economics Pages: 252-253 Issue: 3 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.656670 File-URL: http://hdl.handle.net/10.1080/01446193.2012.656670 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:3:p:252-253 Template-Type: ReDIF-Article 1.0 Author-Name: Michele Lancione Author-X-Name-First: Michele Author-X-Name-Last: Lancione Title: Architecture in the Space of Flows Journal: Construction Management and Economics Pages: 253-255 Issue: 3 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.663095 File-URL: http://hdl.handle.net/10.1080/01446193.2012.663095 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:3:p:253-255 Template-Type: ReDIF-Article 1.0 Author-Name: Chung-Fah Huang Author-X-Name-First: Chung-Fah Author-X-Name-Last: Huang Author-Name: Ho-Chi Lien Author-X-Name-First: Ho-Chi Author-X-Name-Last: Lien Title: An empirical analysis of the influences of corporate social responsibility on organizational performance of Taiwan’s construction industry: using corporate image as a mediator Abstract: Corporate social responsibility (CSR) has become a hot issue for modern enterprises recently. The primary purpose of this study was to investigate the relationships of CSR and organizational performance. The secondary purpose was to determine whether the effect of CSR on organizational performance could be mediated by corporate image. To fulfil the primary purpose, a questionnaire-based survey was used to measure CSR, corporate image and overall organizational performance in Taiwan’s construction industry. Two hundred and eighty-one valid samples were collected and statistically analysed using factor analysis, correlation analysis and hierarchical regression analysis. The analysis results suggest that CSR is positively correlated with corporate image and organizational performance. Additionally, levels of corporate image are positively associated with organizational performance levels. The results also indicate that corporate image may serve as a mediator between CSR and organizational performance, meaning that companies benefit from investment in CSR realization, even if they also have a positive corporate image. Journal: Construction Management and Economics Pages: 263-275 Issue: 4 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.668620 File-URL: http://hdl.handle.net/10.1080/01446193.2012.668620 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:4:p:263-275 Template-Type: ReDIF-Article 1.0 Author-Name: Timothy Michael Rose Author-X-Name-First: Timothy Michael Author-X-Name-Last: Rose Author-Name: Karen Manley Author-X-Name-First: Karen Author-X-Name-Last: Manley Title: Adoption of innovative products on Australian road infrastructure projects Abstract: Product innovation is an important contributor to the performance of infrastructure projects in the construction industry. Maximizing the potential for innovative product adoption is a challenging task due to the complexities of the construction innovation system. A qualitative methodology involving interviews with major construction project stakeholders is employed to address the research question: ‘What are the main obstacles to the adoption of innovative products in the road industry?’ The characteristics of six key product innovation obstacles in Australian road projects are described. The six key obstacles are: project goal misalignment, client pressures, weak contractual relations, lack of product trialling, inflexible product specifications and product liability concerns. A snapshot of the dynamics underlying these obstacles is provided. There are few such assessments in the literature, despite the imperative to improve construction innovation rates globally in order to deliver road infrastructure projects of increasing size and complexity. Key obstacles are interpreted through an open innovation construct, providing direction for policy to enhance the uptake of innovation across the construction product supply network. Early evidence suggests the usefulness of an open innovation construct that integrates three conceptual lenses: network governance, absorptive capacity and knowledge intermediation, in order to interpret product adoption obstacles in the context of Australian road infrastructure projects. The paper also provides practical advice and direction for government and industry organizations that wish to promote the flow of innovative product knowledge across the construction supply network. Journal: Construction Management and Economics Pages: 277-298 Issue: 4 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.665173 File-URL: http://hdl.handle.net/10.1080/01446193.2012.665173 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:4:p:277-298 Template-Type: ReDIF-Article 1.0 Author-Name: David Greenwood Author-X-Name-First: David Author-X-Name-Last: Greenwood Author-Name: Shuwei Wu Author-X-Name-First: Shuwei Author-X-Name-Last: Wu Title: Establishing the association between collaborative working and construction project performance based on client and contractor perceptions Abstract: The assumption that forms of collaborative working (for example, partnering) can have a substantial beneficial impact on project performance underlies many of the proposed reform agendas in the UK construction sector. The majority of supporting evidence is, however, either anecdotal or limited to individual cases. This shortfall is addressed and aspects of project performance are evaluated relative to different degrees of collaborative working. To achieve this, project performance and collaborative working were first analysed into identified constituents. For clarity, these were referred to as attributes (of collaborative working) and indicators (in the case of project performance). This permitted the operationalization of the two concepts into a more measurable format. Data from 44 projects were evaluated. The results indicate a positive linear relationship between collaborative working and project performance. Further, by seeking associations between these disaggregated attributes (of collaborative working) and indicators (of project performance) a richer picture emerged of how the association between the two headline concepts might possibly be explained. Aside from its theoretical contribution, the work has a practical implication in terms of how project performance might be improved. Journal: Construction Management and Economics Pages: 299-308 Issue: 4 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.666801 File-URL: http://hdl.handle.net/10.1080/01446193.2012.666801 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:4:p:299-308 Template-Type: ReDIF-Article 1.0 Author-Name: Derek Thomson Author-X-Name-First: Derek Author-X-Name-Last: Thomson Author-Name: Ammar Kaka Author-X-Name-First: Ammar Author-X-Name-Last: Kaka Author-Name: Laura Pronk Author-X-Name-First: Laura Author-X-Name-Last: Pronk Author-Name: Chaham Alalouch Author-X-Name-First: Chaham Author-X-Name-Last: Alalouch Title: The use of freelisting to elicit stakeholder understanding of the benefits sought from healthcare buildings Abstract: The process of elicitation and synthesis of the collective understanding of a cultural domain held by a group of stakeholders is challenging. This problem typifies the pre-project activity from which a coherent understanding of the benefits sought from infrastructure investment must emerge to inform the business case rationale. The anthropological freelisting method is evaluated as a solution by determining its ability to be operationalized in a practical form for project application. Using data from the stakeholders of a large NHS Scotland building project, the use of multidimensional scaling for data analysis is compared with participatory pilesorting to determine which freelisting protocol balances insight with practicality. Neither approach is found to offer an ideal method of characterizing sought benefits. The social construction of pilesorting promotes reliability while the analytical rigour of multidimensional scaling remains attractive to auditors. Their distinct insights suggest that both approaches should be combined in future and used alongside further post-elicitation devices from anthropology such as cultural consensus modelling or structured conceptualization. Journal: Construction Management and Economics Pages: 309-323 Issue: 4 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.658824 File-URL: http://hdl.handle.net/10.1080/01446193.2012.658824 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:4:p:309-323 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Allan Author-X-Name-First: Andrew Author-X-Name-Last: Allan Title: Climate and Architecture Torben Dahl (ed.), Routledge, London, 2010 168 pp., ISBN 978 0 415 56309 3, £25.99 (pb) Journal: Construction Management and Economics Pages: 325-328 Issue: 4 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.666800 File-URL: http://hdl.handle.net/10.1080/01446193.2012.666800 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:4:p:325-328 Template-Type: ReDIF-Article 1.0 Author-Name: Joseph Voros Author-X-Name-First: Joseph Author-X-Name-Last: Voros Title: Constructing Futures: Industry Leaders and Futures Thinking in Construction Journal: Construction Management and Economics Pages: 328-331 Issue: 4 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.665170 File-URL: http://hdl.handle.net/10.1080/01446193.2012.665170 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:4:p:328-331 Template-Type: ReDIF-Article 1.0 Author-Name: Hans Voordijk Author-X-Name-First: Hans Author-X-Name-Last: Voordijk Title: Contemporary Issues in Construction in Developing Countries Journal: Construction Management and Economics Pages: 331-333 Issue: 4 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.665171 File-URL: http://hdl.handle.net/10.1080/01446193.2012.665171 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:4:p:331-333 Template-Type: ReDIF-Article 1.0 Author-Name: William Ibbs Author-X-Name-First: William Author-X-Name-Last: Ibbs Title: Commercial Conflict Management and Dispute Resolution Journal: Construction Management and Economics Pages: 333-334 Issue: 4 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.665172 File-URL: http://hdl.handle.net/10.1080/01446193.2012.665172 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:4:p:333-334 Template-Type: ReDIF-Article 1.0 Author-Name: Mattias Jacobsson Author-X-Name-First: Mattias Author-X-Name-Last: Jacobsson Author-Name: Henrik C.J. Linderoth Author-X-Name-First: Henrik C.J. Author-X-Name-Last: Linderoth Title: User perceptions of ICT impacts in Swedish construction companies: ‘it’s fine, just as it is’ Abstract: The use of information and communication technologies (ICT) in construction companies has been growing steadily during the last decade. However, few studies inquire into either perceptions of the impact of actual ICT use or perceptions among different occupational groups in construction companies. The aim of the paper is to explore users’ general perceptions of ICT impacts in the post-adoption stage and analyse the implications for construction management practice. A mixed methods approach was used. Quantitative data were collected using a web-based survey both in a major construction company and among medium-sized companies in Sweden. Data from 294 returned completed questionnaires were analysed with t-tests and multiple regression analysis. In addition, participant observations and semi-structured interviews were conducted within the major construction company in order to strengthen the analysis. It can be concluded that respondents are generally fairly satisfied with the ICT. Differences in perceptions among occupational groups can be explained by the nature of work tasks and the original intentions for using ICT as a means of control and calculation. Even if respondents perceive that a further development of ICT could improve competitiveness, they do not want to increase their use of it in their workplaces. They basically think that ‘it is fine, just as it is’. This indicates that a challenge in construction management is to investigate how prevailing and new ICT applications can be used to develop the industry. Journal: Construction Management and Economics Pages: 339-357 Issue: 5 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.672757 File-URL: http://hdl.handle.net/10.1080/01446193.2012.672757 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:5:p:339-357 Template-Type: ReDIF-Article 1.0 Author-Name: Lennon H.T. Choy Author-X-Name-First: Lennon H.T. Author-X-Name-Last: Choy Author-Name: Winky K.O. Ho Author-X-Name-First: Winky K.O. Author-X-Name-Last: Ho Author-Name: Stephen W.K. Mak Author-X-Name-First: Stephen W.K. Author-X-Name-Last: Mak Title: Housing attributes and Hong Kong real estate prices: a quantile regression analysis Abstract: By nature, people’s tastes and preferences are unique and diverse so that a constant coefficient of each housing attribute produced by ordinary least squares (OLS) is not able to fully describe the behaviour of homebuyers of different classes. To complement the least squares, quantile regression is used to identify how real estate prices respond differently to a change in one unit of housing attribute at different quantiles. Theoretically, quantile regression can be utilized to estimate the implicit price for each housing attribute across the distribution of real estate prices, allowing specific percentiles of prices to be more influenced by certain housing attributes when compared to other percentiles. Empirical results demonstrate that most housing attributes, such as apartment size, age and floor level, command different prices at different quantiles. With the use of this approach, the efficiency of the mortgage markets is enhanced by offering more accurate prediction of real estate prices at the lower and upper price distribution. Journal: Construction Management and Economics Pages: 359-366 Issue: 5 Volume: 30 Year: 2012 Month: 3 X-DOI: 10.1080/01446193.2012.677542 File-URL: http://hdl.handle.net/10.1080/01446193.2012.677542 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:5:p:359-366 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Clare Lingard Author-X-Name-First: Helen Clare Author-X-Name-Last: Lingard Author-Name: Tracy Cooke Author-X-Name-First: Tracy Author-X-Name-Last: Cooke Author-Name: Nick Blismas Author-X-Name-First: Nick Author-X-Name-Last: Blismas Title: Designing for construction workers’ occupational health and safety: a case study of socio-material complexity Abstract: Drawing upon an empirical analysis of the design and construction of a food processing facility, a theoretical understanding of the impact of design decision-making on the occupational health and safety (OHS) of construction workers is developed. It is argued that current policy and legislative approaches to Construction Hazard Prevention through Design (CHPtD) are inherently limited because they do not adequately reflect the socio-material complexity of decision-making in construction design. Specifically, the simplistic attribution of responsibility to a single socio-technical actor, ‘the designer’, does not reflect the multiple and disparate influences that impact upon OHS outcomes. Nor do existing CHPtD policy frameworks, management processes and tools recognize the manner in which the interactions and associations between relevant project stakeholders and various non-human artefacts shape (and are also influenced by) the evolution of design decisions. Drawing on actor-network theory (ANT) and using embedded units within a case study approach, the interactions between human actors and non-human artefacts are explored in relation to the design of four components of the food processing facility. The way in which design decisions unfolded and shaped OHS experiences during the construction stage of the project is revealed. The research highlights limitations inherent in current approaches to the management of CHPtD and the need to develop a more robust theoretically based approach to integrating OHS considerations into construction design practice. Journal: Construction Management and Economics Pages: 367-382 Issue: 5 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.667569 File-URL: http://hdl.handle.net/10.1080/01446193.2012.667569 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:5:p:367-382 Template-Type: ReDIF-Article 1.0 Author-Name: Daria Zimina Author-X-Name-First: Daria Author-X-Name-Last: Zimina Author-Name: Glenn Ballard Author-X-Name-First: Glenn Author-X-Name-Last: Ballard Author-Name: Christine Pasquire Author-X-Name-First: Christine Author-X-Name-Last: Pasquire Title: Target value design: using collaboration and a lean approach to reduce construction cost Abstract: Target costing is an effective management technique that has been used in manufacturing for decades to achieve cost predictability during new product development. Adoption of this technique promises benefits for the construction industry as it struggles to raise the number of successful outcomes and certainty of project delivery in terms of cost, quality and time. Target value design is a management approach that takes the best features of target costing and adapts them to the peculiarities of construction. The concept of target value design is introduced based on the results of action research carried out on 12 construction projects in the USA. It has been shown that systemic application of target value design leads to significant improvement of project performance—the final cost of projects was on average 15% less than market cost. The construction industry already has approaches that have similarities with elements of the target value design process or use the same terminology, e.g. partnering and target cost contracts, cost planning, etc. Following an exploration of the similarities and differences target value design is positioned as a form of target costing for construction that offers a more reliable route to successful project outcomes. Journal: Construction Management and Economics Pages: 383-398 Issue: 5 Volume: 30 Year: 2012 Month: 3 X-DOI: 10.1080/01446193.2012.676658 File-URL: http://hdl.handle.net/10.1080/01446193.2012.676658 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:5:p:383-398 Template-Type: ReDIF-Article 1.0 Author-Name: Li Liu Author-X-Name-First: Li Author-X-Name-Last: Liu Author-Name: Xuerong Wang Author-X-Name-First: Xuerong Author-X-Name-Last: Wang Author-Name: Zhaohan Sheng Author-X-Name-First: Zhaohan Author-X-Name-Last: Sheng Title: Achieving ambidexterity in large, complex engineering projects: a case study of the Sutong Bridge project Abstract: Complex engineering projects typically face unique challenges that demand both exploring innovative solutions and exploiting existing capabilities. However, it is difficult to manage both exploitation and exploration in the same organizational unit owing to the different organizational support required for each. The solutions to managing the tension involve separating the two approaches into separate organizational units—structural separation, or separating by time—temporal separation, or by creating an organizational context that empowers employees to pursue both. Structural separation may not work because of the predominant need for integration at project level due to the fragmented nature of the construction industry and the co-location of project team. Instead, temporal separation could be an effective mechanism of separation. Creating the appropriate project context could facilitate project ambidexterity. Extant studies on ambidexterity focus on the organizational level which may not apply at project level. This study examines the effects of the above three antecedents to project ambidexterity. The key findings are that ambidexterity can be achieved during the limited lifespan of a complex engineering project through: (1) partitioning the two approaches in different project phases and then integrating the two; (2) implementing policies and financial support aiming at facilitating contextual ambidexterity both at and above project level. Journal: Construction Management and Economics Pages: 399-409 Issue: 5 Volume: 30 Year: 2012 Month: 3 X-DOI: 10.1080/01446193.2012.679948 File-URL: http://hdl.handle.net/10.1080/01446193.2012.679948 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:5:p:399-409 Template-Type: ReDIF-Article 1.0 Author-Name: Christian Brockmann Author-X-Name-First: Christian Author-X-Name-Last: Brockmann Title: Managing Construction Logistics Journal: Construction Management and Economics Pages: 411-414 Issue: 5 Volume: 30 Year: 2012 Month: 3 X-DOI: 10.1080/01446193.2012.675439 File-URL: http://hdl.handle.net/10.1080/01446193.2012.675439 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:5:p:411-414 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Chinowsky Author-X-Name-First: Paul Author-X-Name-Last: Chinowsky Title: Collaborative Working in Construction Journal: Construction Management and Economics Pages: 414-415 Issue: 5 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.667136 File-URL: http://hdl.handle.net/10.1080/01446193.2012.667136 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:5:p:414-415 Template-Type: ReDIF-Article 1.0 Author-Name: Chris Ivory Author-X-Name-First: Chris Author-X-Name-Last: Ivory Title: Images of Projects Journal: Construction Management and Economics Pages: 415-416 Issue: 5 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.667137 File-URL: http://hdl.handle.net/10.1080/01446193.2012.667137 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:5:p:415-416 Template-Type: ReDIF-Article 1.0 Author-Name: Kjell Tryggestad Author-X-Name-First: Kjell Author-X-Name-Last: Tryggestad Title: Perspectives on Projects Journal: Construction Management and Economics Pages: 416-420 Issue: 5 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.667568 File-URL: http://hdl.handle.net/10.1080/01446193.2012.667568 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:5:p:416-420 Template-Type: ReDIF-Article 1.0 Author-Name: Qian Shi Author-X-Name-First: Qian Author-X-Name-Last: Shi Author-Name: Jian Zuo Author-X-Name-First: Jian Author-X-Name-Last: Zuo Author-Name: George Zillante Author-X-Name-First: George Author-X-Name-Last: Zillante Title: Exploring the management of sustainable construction at the programme level: a Chinese case study Abstract: Sustainable construction is achieved by the implementation of sustainable development principles in the construction industry. The complexity and higher level of inter-project conflicts that occur in large-scale projects mean that the implementation of sustainable construction in those projects is substantially different from that in smaller scale projects. A case study approach has been adopted to analyse the planning and implementation of sustainable construction in the Shanghai World Expo 2010 across the entire programme lifecycle. As one of the largest programmes in China, the Shanghai World Expo 2010 has the potential to serve as a showcase for the application of sustainable development principles in construction. The key factors that need to be considered in order to promote sustainable construction at the programme level are identified. These include the establishment of a dedicated department to coordinate various stakeholders’ efforts and the release of conceptual guidelines and management regulations. In addition, a framework is proposed to implement sustainable construction at the programme management level. Journal: Construction Management and Economics Pages: 425-440 Issue: 6 Volume: 30 Year: 2012 Month: 4 X-DOI: 10.1080/01446193.2012.683200 File-URL: http://hdl.handle.net/10.1080/01446193.2012.683200 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:6:p:425-440 Template-Type: ReDIF-Article 1.0 Author-Name: David Boyd Author-X-Name-First: David Author-X-Name-Last: Boyd Author-Name: David Bentley Author-X-Name-First: David Author-X-Name-Last: Bentley Title: A critique of conceptions of design and management in construction projects Abstract: Construction is about changing the world in the future from our intentions. This involves organizing and manipulating the physical and social world through design, management and craft. These require thinking about the desired end product but also the means of achieving it. Thinking is set in social norms, here called pre-conceptualizations, which configure our conceptions and give them social validity, forming expectations of what can happen and how to improve it. The conventional pre-conceptualization of construction design and management is critiqued using a case study. This pre-conceptualization is shown to be backward looking where the future is assumed to be like the past and knowledge is ascribed to individuals. The causes of failure then appear evident and knowable inducing maladaptive management and blame of individuals. However, design/management is in reality forward looking; events cannot be seen with such significance looking into the future. Two alternative pre-conceptualizations are presented and their implications explored. The first acknowledges evolution, which works against intent, thus explaining deviations. The second involves complexity science where intentions are emergent phenomena and socially constituted, thus explaining improvisation and improvement. In conclusion, new pre-conceptualizations are required to avoid blame cultures, facilitate creative solutions and develop enduring improvements. Journal: Construction Management and Economics Pages: 441-454 Issue: 6 Volume: 30 Year: 2012 Month: 4 X-DOI: 10.1080/01446193.2012.688136 File-URL: http://hdl.handle.net/10.1080/01446193.2012.688136 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:6:p:441-454 Template-Type: ReDIF-Article 1.0 Author-Name: Will Jennings Author-X-Name-First: Will Author-X-Name-Last: Jennings Title: Why costs overrun: risk, optimism and uncertainty in budgeting for the London 2012 Olympic Games Abstract: The systematic under-estimation of costs in budgeting for large-scale projects raises the vexing question of why there are such incongruities between the projections made at initial stages and the eventual outturn cost. As a first step to understanding the sources of such budgeting overruns in the context of the Olympics, this research note outlines how the costs of the London 2012 Olympic Games were under-estimated in a series of budget forecasts, identifying sources of error and categorizing these according to the effects on budgeting of: (1) inattention to risk inside government; (2) biases in decision-making in the evaluation and use of information; and (3) uncertainty in project management and administration. These factors are accentuated through the planning and budgeting context, as estimates at different stages of the process serve alternative purposes and entail varying levels of knowledge and scrutiny. Journal: Construction Management and Economics Pages: 455-462 Issue: 6 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.668200 File-URL: http://hdl.handle.net/10.1080/01446193.2012.668200 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:6:p:455-462 Template-Type: ReDIF-Article 1.0 Author-Name: Liisa Lehtiranta Author-X-Name-First: Liisa Author-X-Name-Last: Lehtiranta Author-Name: Sami Kärnä Author-X-Name-First: Sami Author-X-Name-Last: Kärnä Author-Name: Juha-Matti Junnonen Author-X-Name-First: Juha-Matti Author-X-Name-Last: Junnonen Author-Name: Päivi Julin Author-X-Name-First: Päivi Author-X-Name-Last: Julin Title: The role of multi-firm satisfaction in construction project success Abstract: Construction project success depends on the multi-firm project organizations involved working together satisfactorily. Yet, satisfaction within multi-firm relationships has rarely been examined as a determinant of construction project success. A pioneering study is carried out to evaluate the extent to which construction project participants’ perception of each other’s performance reflects on the owner’s perception of project success. The data represent 580 performance evaluations carried out among the project owners, project consultants, main contractors and designers. The owner-evaluated performance factors related to the project goals form a dependent variable called Project Success. Dependencies between Project Success and the various performance factors are identified based on Pearson’s correlation coefficients. Dependencies were discovered between Project Success and all owner-related relationships and all but one of the non-owner-related relationships. Preliminary sets of discipline-specific and evaluator-specific success factors are identified. The results support the proposition that satisfaction within both owner-related and non-owner-related relationships is reflected on success. Therefore, researchers and practitioners are encouraged to consider project success in terms of multi-firm satisfaction and to engage with multi-firm performance measurement to better understand the heterogeneous performance factors contributing to multi-firm project success. Journal: Construction Management and Economics Pages: 463-475 Issue: 6 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.669485 File-URL: http://hdl.handle.net/10.1080/01446193.2012.669485 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:6:p:463-475 Template-Type: ReDIF-Article 1.0 Author-Name: X.-X. Yuan Author-X-Name-First: X.-X. Author-X-Name-Last: Yuan Title: Bayesian method for the correlated competitive bidding model Abstract: A multivariate competitive bidding model takes into account the correlation among competitors in determination of markup size. However, parameter estimation for the multivariate model is a challenging issue. A simplified, piecemeal style statistical method was proposed for low-dimension problems. However, this method may cause significant estimation errors when applied to complex bidding situations. A refined Bayesian statistical method based on Markov chain Monte Carlo (MCMC) simulation is developed that can be employed in practical bidding problems. To deal with missing values in bid data, a data augmentation technique is integrated in the MCMC process. The proposed Bayesian method is shown through case studies to be robust for complex bidding situations and also insensitive to the selection of the prior models of the correlation matrix. An important feature of the proposed Bayesian method is that it allows a project manager to quantify statistical uncertainties of parameter estimation and their effects on markup decisions. The optimal markup is represented by a posterior distribution which paints a complete picture of the uncertainties involved in the markup size decision. Journal: Construction Management and Economics Pages: 477-491 Issue: 6 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.666802 File-URL: http://hdl.handle.net/10.1080/01446193.2012.666802 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:6:p:477-491 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Fenn Author-X-Name-First: Peter Author-X-Name-Last: Fenn Title: Introduction to Building Procurement Journal: Construction Management and Economics Pages: 493-494 Issue: 6 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.668198 File-URL: http://hdl.handle.net/10.1080/01446193.2012.668198 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:6:p:493-494 Template-Type: ReDIF-Article 1.0 Author-Name: Valerie Caven Author-X-Name-First: Valerie Author-X-Name-Last: Caven Title: Organization Management in Construction Journal: Construction Management and Economics Pages: 494-496 Issue: 6 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.668703 File-URL: http://hdl.handle.net/10.1080/01446193.2012.668703 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:6:p:494-496 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Lemer Author-X-Name-First: Andrew Author-X-Name-Last: Lemer Title: The EcoEdge: Urgent Design Challenges in Building Sustainable Cities Journal: Construction Management and Economics Pages: 496-498 Issue: 6 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.669484 File-URL: http://hdl.handle.net/10.1080/01446193.2012.669484 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:6:p:496-498 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Chan Author-X-Name-First: Paul Author-X-Name-Last: Chan Title: Heathrow’s Terminal 5: History in the Making Journal: Construction Management and Economics Pages: 498-500 Issue: 6 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.668619 File-URL: http://hdl.handle.net/10.1080/01446193.2012.668619 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:6:p:498-500 Template-Type: ReDIF-Article 1.0 Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Title: Construction Quality Management: Principles and Practice Journal: Construction Management and Economics Pages: 500-501 Issue: 6 Volume: 30 Year: 2012 Month: 3 X-DOI: 10.1080/01446193.2012.675440 File-URL: http://hdl.handle.net/10.1080/01446193.2012.675440 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:6:p:500-501 Template-Type: ReDIF-Article 1.0 Author-Name: Adrian Wilkinson Author-X-Name-First: Adrian Author-X-Name-Last: Wilkinson Author-Name: Stewart Johnstone Author-X-Name-First: Stewart Author-X-Name-Last: Johnstone Author-Name: Keith Townsend Author-X-Name-First: Keith Author-X-Name-Last: Townsend Title: Changing patterns of human resource management in construction Journal: Construction Management and Economics Pages: 507-512 Issue: 7 Volume: 30 Year: 2012 Month: 7 X-DOI: 10.1080/01446193.2012.711562 File-URL: http://hdl.handle.net/10.1080/01446193.2012.711562 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:7:p:507-512 Template-Type: ReDIF-Article 1.0 Author-Name: Valerie Caven Author-X-Name-First: Valerie Author-X-Name-Last: Caven Author-Name: Marie Diop Author-X-Name-First: Marie Author-X-Name-Last: Diop Title: Architecture: a ‘rewarding’ career? An Anglo-French comparative study of intrinsic rewards in the architecture profession Abstract: Careers in architecture are characterized by higher levels of job insecurity and lower levels of remuneration than other equivalent professions. Likewise, the ‘traditional’ rewards associated with professional employment—professional power, status and recognition—have been eroded. Raising the question of what are the rewards associated with an architectural career, the concepts of informal networks and relationships in particular are examined as compensation for the poor financial rewards. Drawing upon the rewards literature in conjunction with professional identity and career management data from 84 in-depth interviews with UK and France-based architects, adopting a grounded theory method within the interpretive paradigm, findings show these relationships provide a significant amount of intrinsic satisfaction and thus reward which has been hitherto overlooked. The importance of these relationships could not be foreseen nor can they be actively planned but exist as a powerful intrinsic reward. Journal: Construction Management and Economics Pages: 513-523 Issue: 7 Volume: 30 Year: 2012 Month: 9 X-DOI: 10.1080/01446193.2011.627356 File-URL: http://hdl.handle.net/10.1080/01446193.2011.627356 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:7:p:513-523 Template-Type: ReDIF-Article 1.0 Author-Name: Christer Thörnqvist Author-X-Name-First: Christer Author-X-Name-Last: Thörnqvist Author-Name: Charles Woolfson Author-X-Name-First: Charles Author-X-Name-Last: Woolfson Title: When tender turns tough: posted workers and the tendering regime in the Swedish construction industry Abstract: The outcome of the so-called Laval case and related judgments of the European Court of Justice (ECJ) has led to a debate about the future of the European social model. Although several analyses have focused on the downside of the judgments, in particular on the risk of ‘wage dumping’, one important but overlooked aspect is the connection to tendering regimes. This lacuna is crucial to labour recruitment practices in the construction industry because of the important role of public authorities as buyers of large construction services within the European Union. The research question is whether rigidity in how public authorities are required to tender contracts strengthens downward pressure on wages and induces a deterioration in working conditions. Case study material from Sweden is used in the context of extensive previous research and preliminary findings from an ongoing research project. Because of the short time span since the rulings of the ECJ there is only anecdotal evidence for establishing a mutually reinforcing connection between the system for awarding tenders in Swedish construction and the wider impacts of Laval on the labour market. Nevertheless, new evidence suggests that labour recruitment and human resource management practices are being shaped by a tendering regime governed by requirements of ‘cost flexibility’. Journal: Construction Management and Economics Pages: 525-533 Issue: 7 Volume: 30 Year: 2012 Month: 11 X-DOI: 10.1080/01446193.2011.640338 File-URL: http://hdl.handle.net/10.1080/01446193.2011.640338 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:7:p:525-533 Template-Type: ReDIF-Article 1.0 Author-Name: Gregor Gall Author-X-Name-First: Gregor Author-X-Name-Last: Gall Title: Industrial conflict in the engineering construction industry in Britain Abstract: The militant and unofficial grassroots-led engineering construction strikes of 2009 starkly indicated that the industrial relations of the engineering construction industry in Britain can be characterized and termed as old-fashioned, adversarial and robust. This article takes these strikes as its point of departure to provide an overview of the nature and contours of the contemporary industrial relations of the engineering construction industry (ECI). This demonstrates that not only is this characterization broadly correct but it is surprising in as much as it forms a break with the previous decades of industrial relations in the ECI. The article provides a synopsis of the strikes in 2009 and a contextualized analysis of the social dynamics underpinning them. This is followed by an examination of the nature of the labour market, cycles of engineering construction activity, and processes of industrial relations in the ECI, where the 2009 strikes are used as a prism by which to view them. Thereafter, the issue of assessing the nature and extent of industrial conflict is returned to. Journal: Construction Management and Economics Pages: 535-544 Issue: 7 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.661442 File-URL: http://hdl.handle.net/10.1080/01446193.2012.661442 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:7:p:535-544 Template-Type: ReDIF-Article 1.0 Author-Name: Florence T.T. Phua Author-X-Name-First: Florence T.T. Author-X-Name-Last: Phua Title: Do national cultural differences affect the nature and characteristics of HRM practices? Evidence from Australian and Hong Kong construction firms on remuneration and job autonomy Abstract: Human resource management (HRM) plays a pivotal role in attracting and retaining talent. However, there is growing recognition in international HRM literature that the adoption of the widely accepted US/Harvard-inspired HRM model ignores the influences of cultural contexts on HRM practices in different countries. This notion has not been empirically investigated in the construction industry. Based on survey responses from 604 construction professionals from Australia and Hong Kong, this study examines whether: (1) national cultural differences influence individuals’ preferences for types of remuneration and job autonomy; (2) actual organizational HRM practices reflect such preferences; and (3) gaps between individuals’ preferences and actual organizational HRM practices affect job satisfaction. The results showed significant differences in HRM preferences between Australian and Hong Kong respondents and these are reflected in the distinct types of HRM practices adopted by construction firms in the two countries. The findings further indicated that the gap between individuals’ preferences and actual organizational HRM practices is associated with job satisfaction. The results support existing mainstream research and highlight the deficiency of the acultural treatment of HRM that is still apparent in construction management literature. An uncritical literature in the area not only hinders theory development but also potentially undermines the ability of construction firms to attract, recruit and retain scarce talent. Journal: Construction Management and Economics Pages: 545-556 Issue: 7 Volume: 30 Year: 2012 Month: 3 X-DOI: 10.1080/01446193.2012.682074 File-URL: http://hdl.handle.net/10.1080/01446193.2012.682074 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:7:p:545-556 Template-Type: ReDIF-Article 1.0 Author-Name: Peihua Zhang Author-X-Name-First: Peihua Author-X-Name-Last: Zhang Author-Name: Fung Fai Ng Author-X-Name-First: Fung Fai Author-X-Name-Last: Ng Title: Analysis of knowledge sharing behaviour in construction teams in Hong Kong Abstract: Knowledge sharing in construction teams is important for improved project performance and successful project delivery. The purpose of this study is to analyse psychological motivations underlying individual knowledge sharing behaviour in Hong Kong construction teams using the theory of planned behaviour (TPB). A questionnaire survey was conducted among professionals from 172 construction companies in Hong Kong. A total of 231 usable questionnaires were collected. Structural equation modelling (SEM) is applied to test the research model and hypotheses. The research results indicate that professionals’ knowledge sharing behaviour in construction teams is only significantly predicted by their intention to share knowledge rather than perceived behavioural control over knowledge sharing, implying that knowledge sharing behaviour is largely under the professionals’ volitional control. The research results also indicate that professionals’ knowledge sharing intention is dominantly affected by attitude and perceived behavioural control but weakly influenced by subjective norm, which is different from other groups of professionals in prior studies. Several managerial implications are suggested for construction companies to manage employees’ knowledge sharing behaviour in construction teams. It is one of the first studies to employ social psychological theory to examine knowledge sharing behaviour in the construction context. However, the research model only shows predictive power and lacks explanatory power. Nevertheless, it provides a starting point for future researchers to further explore the salient beliefs underlying attitude and perceived behavioural control so as to explain knowledge sharing behaviour in the construction sector. Journal: Construction Management and Economics Pages: 557-574 Issue: 7 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.669838 File-URL: http://hdl.handle.net/10.1080/01446193.2012.669838 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:7:p:557-574 Template-Type: ReDIF-Article 1.0 Author-Name: Dirk Lindebaum Author-X-Name-First: Dirk Author-X-Name-Last: Lindebaum Author-Name: Peter J. Jordan Author-X-Name-First: Peter J. Author-X-Name-Last: Jordan Title: Relevant but exaggerated: the effects of emotional intelligence on project manager performance in construction Abstract: The construction industry is traditionally seen as being slow to adopt new management techniques, especially in the domain of human resources. Recent studies have argued that emotional intelligence (EI) may be key to improved project manager performance in construction. Indeed, some researchers have argued that EI improves all types of work performance. We dispute this notion, and argue that context and nature of tasks are neglected issues in studies of EI and performance at work. The construction industry provides a unique context to test this proposition. We collected data using a sample of 55 project managers in the UK construction industry using a cross-sectional survey design. Findings suggest that project managers’ levels of EI are linked to most relational performance dimensions. However, project manager EI was not associated with cognitive task related performance dimensions. Therefore, we argue that, while contributing to some aspects of project manager performance, the benefits of EI in this present context should not be overstated. Rather, it should be only one of a set of competencies that are required by successful construction project managers. Journal: Construction Management and Economics Pages: 575-583 Issue: 7 Volume: 30 Year: 2012 Month: 5 X-DOI: 10.1080/01446193.2011.593184 File-URL: http://hdl.handle.net/10.1080/01446193.2011.593184 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:7:p:575-583 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Raisbeck Author-X-Name-First: Peter Author-X-Name-Last: Raisbeck Title: Distributed Intelligence in Design Journal: Construction Management and Economics Pages: 585-590 Issue: 7 Volume: 30 Year: 2012 Month: 7 X-DOI: 10.1080/01446193.2012.683199 File-URL: http://hdl.handle.net/10.1080/01446193.2012.683199 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:7:p:585-590 Template-Type: ReDIF-Article 1.0 Author-Name: Chen-Yu Chang Author-X-Name-First: Chen-Yu Author-X-Name-Last: Chang Title: Adjudication in the Building Industry (3rd edn) Journal: Construction Management and Economics Pages: 590-594 Issue: 7 Volume: 30 Year: 2012 Month: 7 X-DOI: 10.1080/01446193.2012.671951 File-URL: http://hdl.handle.net/10.1080/01446193.2012.671951 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:7:p:590-594 Template-Type: ReDIF-Article 1.0 Author-Name: Stefan Olander Author-X-Name-First: Stefan Author-X-Name-Last: Olander Title: Life Cycle Assessment in the Built Environment Journal: Construction Management and Economics Pages: 594-596 Issue: 7 Volume: 30 Year: 2012 Month: 7 X-DOI: 10.1080/01446193.2012.673727 File-URL: http://hdl.handle.net/10.1080/01446193.2012.673727 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:7:p:594-596 Template-Type: ReDIF-Article 1.0 Author-Name: Ole Jonny Klakegg Author-X-Name-First: Ole Jonny Author-X-Name-Last: Klakegg Title: Art and Practice of Managing Projects Journal: Construction Management and Economics Pages: 596-598 Issue: 7 Volume: 30 Year: 2012 Month: 7 X-DOI: 10.1080/01446193.2012.682731 File-URL: http://hdl.handle.net/10.1080/01446193.2012.682731 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:7:p:596-598 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Clare Lingard Author-X-Name-First: Helen Clare Author-X-Name-Last: Lingard Author-Name: Tracy Cooke Author-X-Name-First: Tracy Author-X-Name-Last: Cooke Author-Name: Nick Blismas Author-X-Name-First: Nick Author-X-Name-Last: Blismas Title: Designing for construction workers’ occupational health and safety: a case study of socio-material complexity Journal: Construction Management and Economics Pages: 599-599 Issue: 7 Volume: 30 Year: 2012 Month: 7 X-DOI: 10.1080/01446193.2012.709401 File-URL: http://hdl.handle.net/10.1080/01446193.2012.709401 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:7:p:599-599 Template-Type: ReDIF-Article 1.0 Author-Name: Naomi Brookes Author-X-Name-First: Naomi Author-X-Name-Last: Brookes Title: What is engineering construction and why is it important? Towards a research agenda Journal: Construction Management and Economics Pages: 603-607 Issue: 8 Volume: 30 Year: 2012 Month: 8 X-DOI: 10.1080/01446193.2012.709414 File-URL: http://hdl.handle.net/10.1080/01446193.2012.709414 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:603-607 Template-Type: ReDIF-Article 1.0 Author-Name: Christian Koch Author-X-Name-First: Christian Author-X-Name-Last: Koch Title: Contested overruns and performance of offshore wind power plants Abstract: Offshore wind power plants are expected to expand rapidly in the coming years. These large engineering construction projects are important for climate change mitigation. The paper contributes to socio-technical understanding of engineering construction. Cost, time, delays and performance results of selected British plants are investigated, with a focus on strategic misrepresentation. This megaproject concept is combined with a socio-technical content analysis of offshore wind farms and provides a technologically precise and contemporary conceptualization in comparison with complex engineering and megaproject approaches. Based on publicly available data, budget and time overruns and underperformance are demonstrated. Budget overruns range from 0% to 65%; time overruns from 9% to 100%, Operational performance indicators reveal plants far below and just below estimations. These are all indications of strategic misrepresentation, but according to project players, the delays originate from weather, product technology, site features and processes. The findings thus indicate a latent controversy regarding reasons for overruns. A socio-technical variant of reference class forecasting (RCF) is developed to explore whether RCF could improve the estimates. Socio-technical RCF is developed for 10 plants that share foundation, national and geotechnical conditions. This provides an illustrative example of a proposed uplift for London Array. Such an RCF should be orchestrated with more governance mechanisms in order to improve future investments in engineering construction, including offshore plants. Journal: Construction Management and Economics Pages: 609-622 Issue: 8 Volume: 30 Year: 2012 Month: 4 X-DOI: 10.1080/01446193.2012.687830 File-URL: http://hdl.handle.net/10.1080/01446193.2012.687830 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:609-622 Template-Type: ReDIF-Article 1.0 Author-Name: Giorgio Locatelli Author-X-Name-First: Giorgio Author-X-Name-Last: Locatelli Author-Name: Mauro Mancini Author-X-Name-First: Mauro Author-X-Name-Last: Mancini Title: Looking back to see the future: building nuclear power plants in Europe Abstract: The so-called ‘nuclear renaissance’ in Europe is promulgated by the execution of two large engineering projects involving the construction of two European Pressurized Reactors (EPRs) in Flamanville, France and Olkiluoto in Finland. As both projects have faced budget overruns and delays, this paper analyses their governance and history to derive lessons useful for the construction of future projects. Analysis indicates that the reasons for these poor outcomes are: overoptimistic estimations, first-of-a-kind (FOAK) issues and undervaluation of regulation requirements. These pitfalls have the potential to impact on many other engineering construction projects and highlight fruitful areas of further research into project performance. Journal: Construction Management and Economics Pages: 623-637 Issue: 8 Volume: 30 Year: 2012 Month: 4 X-DOI: 10.1080/01446193.2012.684884 File-URL: http://hdl.handle.net/10.1080/01446193.2012.684884 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:623-637 Template-Type: ReDIF-Article 1.0 Author-Name: Nancy Madter Author-X-Name-First: Nancy Author-X-Name-Last: Madter Author-Name: Naomi J. Brookes Author-X-Name-First: Naomi J. Author-X-Name-Last: Brookes Author-Name: Denise A. Bower Author-X-Name-First: Denise A. Author-X-Name-Last: Bower Author-Name: George Hagan Author-X-Name-First: George Author-X-Name-Last: Hagan Title: Exploring project management continuing professional development in engineering construction Abstract: Project management is a critical organizational capability in the engineering construction sector: the development of that capability through continuing professional development (CPD) is, therefore, of substantive interest to practitioners and researchers alike. The aim of this investigation was to explore current practice in CPD in engineering construction. This was achieved by undertaking a cross-case analysis of the experiences of project management CPD in 17 organizations. The analysis revealed a highly unsystematic approach to CPD and a very limited adaptation of CPD to the engineering construction context. The impact of introducing more structured and contextualized approaches to CPD on the effectiveness of project managers needs to be investigated further. Journal: Construction Management and Economics Pages: 639-651 Issue: 8 Volume: 30 Year: 2012 Month: 3 X-DOI: 10.1080/01446193.2012.674211 File-URL: http://hdl.handle.net/10.1080/01446193.2012.674211 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:639-651 Template-Type: ReDIF-Article 1.0 Author-Name: Richard Fellows Author-X-Name-First: Richard Author-X-Name-Last: Fellows Author-Name: Anita M.M. Liu Author-X-Name-First: Anita M.M. Author-X-Name-Last: Liu Title: Managing organizational interfaces in engineering construction projects: addressing fragmentation and boundary issues across multiple interfaces Abstract: Extensive and increasing specialization in construction has prompted much criticism—that fragmentation leads to poor performance. Such issues are magnified on engineering construction projects due to their size, complexity, financing, duration and execution by many organizations, often from several diverse countries. Theory, research perspectives and findings of boundary management studies are examined in the context of management of engineering construction projects. The objectives are to investigate theory and practices of boundary management; to examine how boundary management operates on engineering construction projects; and to produce a research agenda for studying further, important aspects of boundary management impacting on engineering construction projects. Conclusions are that the emerging theories provide insights but it is the nature of the markets—notably, the diverse objectives of stakeholders and the procedures and their practices in pursuit of self-oriented benefits—which are the main impediments to achieving greater coordination and collaboration. On complex engineering construction projects, many requirements are emergent and project participants co-evolve to yield self-organizing governance as projects progress within an often fixed formal framework. Recognition of performance interdependence among participants is an essential underpinning of commitment and cooperation; development and use of appropriate boundary management through boundary spanning and boundary objects can foster interaction and coordination even with participants’ retention of their individual goals. Journal: Construction Management and Economics Pages: 653-671 Issue: 8 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.668199 File-URL: http://hdl.handle.net/10.1080/01446193.2012.668199 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:653-671 Template-Type: ReDIF-Article 1.0 Author-Name: Christine Pasquire Author-X-Name-First: Christine Author-X-Name-Last: Pasquire Title: Positioning Lean within an exploration of engineering construction Abstract: Engineering construction has specific characteristics that separate it from other types of construction such as technical complexity, onerous safety, health and environmental regulations, duality of new build combined with maintenance and repair, largely owner/user commissioning clients, value propositions revolving around a production Process, etc. The recent Gibson report (Gibson, 2009) highlighted several significant problems associated with engineering construction in the UK arising, in many cases, from skill shortages and poor client--contractor relationships. Informal observation and a literature review enable 12 factors to be proposed that differentiate engineering construction from other forms of construction. A new paradigm for the construction sector is Lean construction. This is an adaptation of Lean production and is based on a philosophy that focuses on delivering improved value through the assembly of problem-solving networks of knowledgeable and skilled people. Accepting that Lean construction exists in theory as a method for improving a raft of construction production issues, the question is asked here as to whether it is also relevant to the set of additional factors identified as applying specifically to production in an engineering construction context. The discussion concludes that Lean construction principles can be applied in engineering construction and that an improvement in value could be achieved. Note: throughout this paper the word ‘process’ is used in two contexts—the design and construction process and the end Process that is the function of the client business, e.g. water treatment Process, food manufacturing Process. The context is distinguished by the capitalization of the first letter. Journal: Construction Management and Economics Pages: 673-685 Issue: 8 Volume: 30 Year: 2012 Month: 4 X-DOI: 10.1080/01446193.2012.689431 File-URL: http://hdl.handle.net/10.1080/01446193.2012.689431 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:673-685 Template-Type: ReDIF-Article 1.0 Author-Name: David Greenwood Author-X-Name-First: David Author-X-Name-Last: Greenwood Author-Name: Barry James Gledson Author-X-Name-First: Barry James Author-X-Name-Last: Gledson Title: The efficient scheduling of resources in engineering construction projects: reflections on a case study from Iran Abstract: A particular problem for productivity in engineering construction projects is poor front-end planning, in particular, the lack of attention to resource-loaded schedules. In such projects, resources are highly specific and constrained, resulting in conflicts that can compromise planned durations and add cost. There are many techniques available for mitigating these conflicts. These have been extensively reported and compared in the literature and some have been adopted into commercially available computerized scheduling packages that are used by most major contractors. Project managers normally have access only to the techniques offered by the software that their organizations happen to use. In the reported case, a heuristic algorithm developed by academics was implemented and tested against a well-known standard software scheduling tool on the construction of a combined-cycle power plant in Iran. When results were compared, the performance of the manually applied algorithm was found to be superior in its ability to provide acceptable time--cost trade-offs. The underlying argument is twofold. First, that deficiencies in planning (particularly the reconciliation of resource constraints with completion targets) are responsible for poor productivity in engineering construction projects. Second, as improved techniques for optimizing ‘resource-loaded’ schedules are continually being sought and devised, they should be made available to project managers; and the best way for this to happen is for them to be incorporated into commercially available project management software. Journal: Construction Management and Economics Pages: 687-695 Issue: 8 Volume: 30 Year: 2012 Month: 6 X-DOI: 10.1080/01446193.2012.704595 File-URL: http://hdl.handle.net/10.1080/01446193.2012.704595 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:687-695 Template-Type: ReDIF-Article 1.0 Author-Name: Tony Maplesden Author-X-Name-First: Tony Author-X-Name-Last: Maplesden Title: Bridging the academia/industry divide in engineering construction research Journal: Construction Management and Economics Pages: 697-698 Issue: 8 Volume: 30 Year: 2012 Month: 5 X-DOI: 10.1080/01446193.2012.697179 File-URL: http://hdl.handle.net/10.1080/01446193.2012.697179 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:697-698 Template-Type: ReDIF-Article 1.0 Author-Name: David Edwards Author-X-Name-First: David Author-X-Name-Last: Edwards Title: Researching skills requirements for engineering construction: a UK perspective Journal: Construction Management and Economics Pages: 698-700 Issue: 8 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.671526 File-URL: http://hdl.handle.net/10.1080/01446193.2012.671526 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:698-700 Template-Type: ReDIF-Article 1.0 Author-Name: Tim Podesta Author-X-Name-First: Tim Author-X-Name-Last: Podesta Title: Picturing the emerging engineering construction research agenda: reflections on the Managing Engineering Construction special issue Journal: Construction Management and Economics Pages: 700-702 Issue: 8 Volume: 30 Year: 2012 Month: 1 X-DOI: 10.1080/01446193.2012.663096 File-URL: http://hdl.handle.net/10.1080/01446193.2012.663096 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:700-702 Template-Type: ReDIF-Article 1.0 Author-Name: John Oliver Author-X-Name-First: John Author-X-Name-Last: Oliver Title: Knowledge requirements for capability development in complex project delivery Journal: Construction Management and Economics Pages: 702-703 Issue: 8 Volume: 30 Year: 2012 Month: 4 X-DOI: 10.1080/01446193.2012.690071 File-URL: http://hdl.handle.net/10.1080/01446193.2012.690071 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:702-703 Template-Type: ReDIF-Article 1.0 Author-Name: Graham M. Winch Author-X-Name-First: Graham M. Author-X-Name-Last: Winch Title: Industrial Megaprojects: Concepts, Strategies and Practices for Success Journal: Construction Management and Economics Pages: 705-708 Issue: 8 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.665996 File-URL: http://hdl.handle.net/10.1080/01446193.2012.665996 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:705-708 Template-Type: ReDIF-Article 1.0 Author-Name: Brian Atkin Author-X-Name-First: Brian Author-X-Name-Last: Atkin Title: Planning Major Projects Journal: Construction Management and Economics Pages: 708-710 Issue: 8 Volume: 30 Year: 2012 Month: 3 X-DOI: 10.1080/01446193.2012.674210 File-URL: http://hdl.handle.net/10.1080/01446193.2012.674210 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:708-710 Template-Type: ReDIF-Article 1.0 Author-Name: Janet Druker Author-X-Name-First: Janet Author-X-Name-Last: Druker Title: Lean Culture for the Construction Industry: Building Responsible and Committed Project Teams Journal: Construction Management and Economics Pages: 710-711 Issue: 8 Volume: 30 Year: 2012 Month: 3 X-DOI: 10.1080/01446193.2012.679947 File-URL: http://hdl.handle.net/10.1080/01446193.2012.679947 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:710-711 Template-Type: ReDIF-Article 1.0 Author-Name: Samin Shokri Author-X-Name-First: Samin Author-X-Name-Last: Shokri Author-Name: Carl T. Haas Author-X-Name-First: Carl T. Author-X-Name-Last: Haas Title: Risk Management for Design and Construction Journal: Construction Management and Economics Pages: 711-713 Issue: 8 Volume: 30 Year: 2012 Month: 5 X-DOI: 10.1080/01446193.2012.690883 File-URL: http://hdl.handle.net/10.1080/01446193.2012.690883 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:711-713 Template-Type: ReDIF-Article 1.0 Author-Name: Elisabeth Campagnac Author-X-Name-First: Elisabeth Author-X-Name-Last: Campagnac Title: Engineers: A Study of Structural Designers Matthew Wells, Routledge, London, 2010 256pp, ISBN 978 0 415 32526 4, £25.00 (pb) Journal: Construction Management and Economics Pages: 713-714 Issue: 8 Volume: 30 Year: 2012 Month: 2 X-DOI: 10.1080/01446193.2012.672756 File-URL: http://hdl.handle.net/10.1080/01446193.2012.672756 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:8:p:713-714 Template-Type: ReDIF-Article 1.0 Author-Name: Aaron Maano Anvuur Author-X-Name-First: Aaron Maano Author-X-Name-Last: Anvuur Author-Name: Mohan Kumaraswamy Author-X-Name-First: Mohan Author-X-Name-Last: Kumaraswamy Author-Name: Richard Fellows Author-X-Name-First: Richard Author-X-Name-Last: Fellows Title: Perceptions of status and TMO workgroup cooperation: implications for project governance Abstract: Achieving and sustaining the cooperation of individuals with their temporary multi-organization (TMO) workgroups is, arguably, one of the most enduring challenges facing the construction sector. A mediational model connecting pride and self-respect to each of four dimensions of cooperative behaviour—in-role, compliance, extra-role, and deference—is tested in a survey sample of 140 construction professionals in Hong Kong. Bootstrap tests of the indirect effect of pride on cooperative behaviour suggest that self-respect fully mediates the influence of pride on in-role behaviour and compliance behaviour, and partially mediates the influence of pride on extra-role behaviour. The results also suggest that pride has no effect on deference behaviour. While needing corroboration by future research, the findings suggest that viable strategies designed to foster pride and self-respect could engender and sustain cooperation in construction TMO workgroups, and support ongoing efforts to reform construction. The bootstrapping procedures for testing intervening variable models are elaborated in the hope that this will encourage more process analysis research in construction. Journal: Construction Management and Economics Pages: 719-737 Issue: 9 Volume: 30 Year: 2012 Month: 9 X-DOI: 10.1080/01446193.2012.688137 File-URL: http://hdl.handle.net/10.1080/01446193.2012.688137 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:9:p:719-737 Template-Type: ReDIF-Article 1.0 Author-Name: Jacopo Torriti Author-X-Name-First: Jacopo Author-X-Name-Last: Torriti Title: Multiple-project discount rates for cost-benefit analysis in construction projects: a formal risk model for microgeneration renewable energy technologies Abstract: The traditional economic approach for appraising the costs and benefits of construction project net present values involves the calculation of net returns for each investment option under different discount rates. An alternative approach consists of multiple-project discount rates based on risk modelling. The example of a portfolio of microgeneration renewable energy technology is presented to demonstrate that risks and future available budget for re-investment can be taken into account when setting discount rates for construction project specifications in the presence of uncertainty. A formal demonstration is carried out through a reversed intertemporal approach of applied general equilibrium. It is demonstrated that risk and the estimated available budget for future re-investment can be included in the simultaneous assessment of the costs and benefits of multiple projects. Journal: Construction Management and Economics Pages: 739-747 Issue: 9 Volume: 30 Year: 2012 Month: 9 X-DOI: 10.1080/01446193.2012.692165 File-URL: http://hdl.handle.net/10.1080/01446193.2012.692165 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:9:p:739-747 Template-Type: ReDIF-Article 1.0 Author-Name: Leentje Volker Author-X-Name-First: Leentje Author-X-Name-Last: Volker Title: Procuring architectural services: sensemaking in a legal context Abstract: Decision makers involved in selecting an architect for a building project in the public domain have to comply with European procurement regulations. The blend of the legal requirements and the subjective elements of architectural design creates a situation in which the legal rationale often clashes with the organizational sensemaking process that decision makers experience. Hence, being aware of the origin of these conflicts could have important managerial implications for the design of a tender process. A competition and a tender case were selected to collect data by observation, interviewing and document analysis. The incremental and iterative character of making sense of supply and demand and the implicit ways of aggregating value judgements in order to make a final procurement decision were found to be the main underlying decision processes in procuring architectural services. Being aware of these characteristics in the design of a tender process would significantly reduce the chance of conflictive situations. Journal: Construction Management and Economics Pages: 749-759 Issue: 9 Volume: 30 Year: 2012 Month: 9 X-DOI: 10.1080/01446193.2012.667138 File-URL: http://hdl.handle.net/10.1080/01446193.2012.667138 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:9:p:749-759 Template-Type: ReDIF-Article 1.0 Author-Name: Shahin Mokhlesian Author-X-Name-First: Shahin Author-X-Name-Last: Mokhlesian Author-Name: Magnus Holm&#E9;n Author-X-Name-First: Magnus Author-X-Name-Last: Holm&#E9;n Title: Business model changes and green construction processes Abstract: Green construction or sustainable construction differs from traditional construction in terms of the materials and processes used. To profit from green construction, firms may need to change their business models, including their offers, activities, networks and revenue models. However there is no explicit study on what changes are required or common in construction companies’ business models when they are involved in green construction projects. To systematize prior research a literature review identified changes in business model elements. The results showed that (1) most business model elements can change in a non-trivial manner as a consequence of green construction; (2) value configuration, cost structure, partner networks and capability are the elements emphasized in literature and are expected to be the most difficult and important to change; and (3) to be successful, firms may need to simultaneously change the business model elements of capability, value configuration and partner network on the one hand, and value proposition, cost structure and capability on the other hand. Journal: Construction Management and Economics Pages: 761-775 Issue: 9 Volume: 30 Year: 2012 Month: 9 X-DOI: 10.1080/01446193.2012.694457 File-URL: http://hdl.handle.net/10.1080/01446193.2012.694457 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:9:p:761-775 Template-Type: ReDIF-Article 1.0 Author-Name: David James Bryde Author-X-Name-First: David James Author-X-Name-Last: Bryde Author-Name: Ralf Schulmeister Author-X-Name-First: Ralf Author-X-Name-Last: Schulmeister Title: Applying Lean principles to a building refurbishment project: experiences of key stakeholders Abstract: Lean construction can be conceptualized as a process-oriented approach derived from the Toyota Production System (TPS). Elements of the approach include pull-driven scheduling, minimizing stock held on site, visual management, levelling workloads and teamwork. While there has been empirical study of Lean in relation to new-builds there is a need to analyse its applicability to other contexts, such as refurbishments. The effect of using Lean on the refurbishment of a municipal building in Germany is investigated in this study. Participant observation, archival project documentation and semi-structured interviews are used to collect data on the use of Lean. The findings indicate the difficulty of applying Lean to refurbishment projects, particularly operating pull-drive scheduling, and the experience of the project brings into question the practicalities of applying the fundamental Lean principle of having a smooth level flow of work to refurbishment projects. Minimizing stock held on site with JIT delivery of materials also proved problematic, which was exacerbated by the commercial arrangements between subcontractors and suppliers providing no incentive to Lean. The use of the visual management aspects of Lean, such as performance charts, coupled with weekly meetings, were easier to adapt to the project and generally had a beneficial impact. Journal: Construction Management and Economics Pages: 777-794 Issue: 9 Volume: 30 Year: 2012 Month: 9 X-DOI: 10.1080/01446193.2012.700405 File-URL: http://hdl.handle.net/10.1080/01446193.2012.700405 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:9:p:777-794 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Löwstedt Author-X-Name-First: Martin Author-X-Name-Last: Löwstedt Author-Name: Christine Räisänen Author-X-Name-First: Christine Author-X-Name-Last: Räisänen Title: ‘Playing back-spin balls’: narrating organizational change in construction Abstract: What does change mean for organizational members? Although researchers have attempted to capture its intrinsic complexities, there remains uncertainty as to what change really is and how it happens. Drawing on a longitudinal interpretative case study of change in a large Swedish construction company, a narrative approach is used to elicit middle managers’ stories of change episodes over the past two decades. These stories have then been compared with the narratives of the same episodes in governing documents. We found that the lived and the formal narratives, respectively, depicted two very different interpretations and enactments of change: the former described a discontinuous process of discrete contingencies demanding immediate short-term responses whereas the latter described a proactive incremental strategic plan. A narrative approach to the study of organizational change contributes to deeper insights into the ramifications of an organization’s socio-cultural system by enabling the capture of significant variations, contradictions and tensions, both for organizational members and for the researchers who study change. Journal: Construction Management and Economics Pages: 795-806 Issue: 9 Volume: 30 Year: 2012 Month: 9 X-DOI: 10.1080/01446193.2012.693189 File-URL: http://hdl.handle.net/10.1080/01446193.2012.693189 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:9:p:795-806 Template-Type: ReDIF-Article 1.0 Author-Name: Andr� Dor�e Author-X-Name-First: Andr� Author-X-Name-Last: Dor�e Title: Making Sense of Construction Improvement Journal: Construction Management and Economics Pages: 807-809 Issue: 9 Volume: 30 Year: 2012 Month: 9 X-DOI: 10.1080/01446193.2012.675078 File-URL: http://hdl.handle.net/10.1080/01446193.2012.675078 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:9:p:807-809 Template-Type: ReDIF-Article 1.0 Author-Name: Paolo Tombesi Author-X-Name-First: Paolo Author-X-Name-Last: Tombesi Title: Spatial Agency: Other Ways of Doing Architecture Journal: Construction Management and Economics Pages: 809-811 Issue: 9 Volume: 30 Year: 2012 Month: 9 X-DOI: 10.1080/01446193.2012.682732 File-URL: http://hdl.handle.net/10.1080/01446193.2012.682732 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:9:p:809-811 Template-Type: ReDIF-Article 1.0 Author-Name: Denise Gravitt Author-X-Name-First: Denise Author-X-Name-Last: Gravitt Title: Eco-Urban Design Journal: Construction Management and Economics Pages: 811-812 Issue: 9 Volume: 30 Year: 2012 Month: 9 X-DOI: 10.1080/01446193.2012.682733 File-URL: http://hdl.handle.net/10.1080/01446193.2012.682733 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:9:p:811-812 Template-Type: ReDIF-Article 1.0 Author-Name: Michaela Schaffhauser-Linzatti Author-X-Name-First: Michaela Author-X-Name-Last: Schaffhauser-Linzatti Title: Construction Management: Subcontractor Scopes of Work Journal: Construction Management and Economics Pages: 812-814 Issue: 9 Volume: 30 Year: 2012 Month: 9 X-DOI: 10.1080/01446193.2012.686667 File-URL: http://hdl.handle.net/10.1080/01446193.2012.686667 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:9:p:812-814 Template-Type: ReDIF-Article 1.0 Author-Name: Alison Furber Author-X-Name-First: Alison Author-X-Name-Last: Furber Author-Name: Sarah Duncan Author-X-Name-First: Sarah Author-X-Name-Last: Duncan Author-Name: Simon David Smith Author-X-Name-First: Simon David Author-X-Name-Last: Smith Author-Name: Martin Crapper Author-X-Name-First: Martin Author-X-Name-Last: Crapper Title: The health and safety implications of socio-cultural context for community construction projects in developing countries Abstract: Community participation in construction during rural infrastructure projects in developing countries is encouraged by many non-governmental organizations. The health and safety aspects of this type of development model have not previously been adequately researched, however. The aim is to identify the socio-cultural factors that motivate community members to participate in construction activities which they perceive as hazardous during a case study of a water and sanitation project in rural Ghana. This is a step towards understanding how health and safety can be more effectively managed during community development projects. A qualitative approach has been taken, using interview, observation and reflection. It was found that the communal culture of the local context resulted in community members feeling pressurized to participate in hazardous construction activities. Local customary laws further compelled individuals as they were concerned they could be fined or arrested should they not fulfil their communal obligations. Further work is required to determine the boundaries within which findings apply but it is likely that there are implications for others managing community construction projects both in Ghana and further afield. Journal: Construction Management and Economics Pages: 857-867 Issue: 10 Volume: 30 Year: 2012 Month: 10 X-DOI: 10.1080/01446193.2012.707324 File-URL: http://hdl.handle.net/10.1080/01446193.2012.707324 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:10:p:857-867 Template-Type: ReDIF-Article 1.0 Author-Name: Hemanta Doloi Author-X-Name-First: Hemanta Author-X-Name-Last: Doloi Author-Name: Anil Sawhney Author-X-Name-First: Anil Author-X-Name-Last: Sawhney Author-Name: K.C. Iyer Author-X-Name-First: K.C. Author-X-Name-Last: Iyer Title: Structural equation model for investigating factors affecting delay in Indian construction projects Abstract: The rapid growth of the Indian construction sector over the last few decades and recurring failure in on-time delivery highlight the need for a systematic analysis of the factors influencing delay. A theoretical structural equation model representing the influence of four key latent variables on project delays in the Indian construction industry has been developed. Data collected from a questionnaire survey and personal interviews, with 77 valid responses from clients, contractors and designers or architects, were used to further formulate and analyse the model. The results of the structural equation model suggest that client’s influence is one of the most significant factors affecting time performance on Indian projects. Client’s influence is also found to be one of the key contributing factors resulting in lack of commitment and contractor’s inefficiency in the project. Lack of efficient construction planning plays the second key role in adverse time performance. While the effect of lack of commitment on contractor’s inefficiency is highly significant, neither of these two factors has any direct impact on time delay in projects. Contrary to the notion that the contractor is the only party responsible for delay in construction projects, the results clearly highlight the importance of the role of clients and technical expertise in planning in achieving satisfactory time performance on Indian projects. It is hoped that these research findings will contribute significantly to the Indian construction industry’s efforts in addressing the root causes of delay and enhancing the time performance on projects. Journal: Construction Management and Economics Pages: 869-884 Issue: 10 Volume: 30 Year: 2012 Month: 10 X-DOI: 10.1080/01446193.2012.717705 File-URL: http://hdl.handle.net/10.1080/01446193.2012.717705 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:10:p:869-884 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Anthony Bowen Author-X-Name-First: Paul Anthony Author-X-Name-Last: Bowen Author-Name: Peter J. Edwards Author-X-Name-First: Peter J. Author-X-Name-Last: Edwards Author-Name: Keith Cattell Author-X-Name-First: Keith Author-X-Name-Last: Cattell Title: Corruption in the South African construction industry: a thematic analysis of verbatim comments from survey participants Abstract: Corruption is a pervasive stain on the construction industry in many countries. South Africa is no exception. A questionnaire survey showed that corruption there is perceived to be widespread. Beyond the quantitative survey findings, thematic analysis was used to explore the verbatim comments offered by many survey participants. This analysis clarified the nature and extent of corruption more precisely and four predominant themes emerged: involvement in corruption, forms of corruption, factors that may give rise to corrupt activities, and the means of combating corruption. Public officials are thought to be actively involved in acts of corruption, particularly in the soliciting of bribes and in tender manipulation. Professional consultants and other actors in the construction supply chain are not above reproach. Forms of corruption centre largely on appointment and tender irregularities, and to a lesser extent on contract administration and closeout irregularities. Factors instrumental in corruption include the skills shortage within the industry, a perceived absence of deterrents and sanctions, and poor ethical standards. Procedural impediments, fear of victimization and personal attitudes all act as barriers to combating corruption. While confirming opportunity, pressure and self-justification as the three pillars of the Cressey ‘Fraud Triangle’ theory of corruption, the research findings suggest that a more dynamic interpretation of this model is advisable. In addressing corruption, at least in the public sector, improvements in procurement processes are needed along with shifts towards higher standards of ethical behaviour among public sector employees at all levels. Greater procurement process transparency (in both public and private sectors of the industry) would address the worst effects of undue political interference and nepotism. The South African construction industry (particularly its statutory professional councils and contractor affiliation bodies), together with public sector agencies and private sector client associations, should collaborate to adopt a more proactive stance against corruption, and be more engaged with detecting and reporting it. Journal: Construction Management and Economics Pages: 885-901 Issue: 10 Volume: 30 Year: 2012 Month: 10 X-DOI: 10.1080/01446193.2012.711909 File-URL: http://hdl.handle.net/10.1080/01446193.2012.711909 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:10:p:885-901 Template-Type: ReDIF-Article 1.0 Author-Name: Caroline T.W. Chan Author-X-Name-First: Caroline T.W. Author-X-Name-Last: Chan Title: The principal factors affecting construction project overhead expenses: an exploratory factor analysis approach Abstract: Estimation is the first step in the project development process. Information technology provides an efficient platform for estimators to obtain quotations and specifications for their bid estimates. However, in practice, project overhead estimation relies heavily on the professional judgement and intuition of the estimators. This reduces the overall accuracy and reliability of the bid and a better understanding of the factors affecting project overheads is fundamental before any improved estimating methods can be devised. Unfortunately, the published literature on this topic is very limited. Using exploratory factor analysis, we aim to bridge the current knowledge gap by highlighting the principal factors affecting project overheads. Questionnaires detailing 27 variables were sent to quantity surveying managers of large contractors in Hong Kong. Seventy-nine valid responses were analysed by exploratory factor analysis. From the results, eight factors were extracted with their latent properties identified with reference to the expert opinions collected from telephone interviews. The findings clarify some misconceptions about the factors affecting project overheads and provide useful evidence for practitioners and researchers to understand project overheads. Estimators who address the identified factors when assessing future project overhead costs can improve the accuracy of their cost estimates and project budgets. Journal: Construction Management and Economics Pages: 903-914 Issue: 10 Volume: 30 Year: 2012 Month: 10 X-DOI: 10.1080/01446193.2012.717706 File-URL: http://hdl.handle.net/10.1080/01446193.2012.717706 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:10:p:903-914 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Gardiner Author-X-Name-First: Paul Author-X-Name-Last: Gardiner Title: Cost-benefit Analysis: Cases and Materials Journal: Construction Management and Economics Pages: 1011-1012 Issue: 11 Volume: 30 Year: 2012 Month: 11 X-DOI: 10.1080/01446193.2012.688985 File-URL: http://hdl.handle.net/10.1080/01446193.2012.688985 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:11:p:1011-1012 Template-Type: ReDIF-Article 1.0 Author-Name: Christian Brockmann Author-X-Name-First: Christian Author-X-Name-Last: Brockmann Title: Construction Project Scheduling and Control (CourseSmart), 2nd edn Journal: Construction Management and Economics Pages: 1012-1013 Issue: 11 Volume: 30 Year: 2012 Month: 11 X-DOI: 10.1080/01446193.2012.694456 File-URL: http://hdl.handle.net/10.1080/01446193.2012.694456 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:11:p:1012-1013 Template-Type: ReDIF-Article 1.0 Author-Name: Clara Greed Author-X-Name-First: Clara Author-X-Name-Last: Greed Title: Builders: Class, Gender and Ethnicity in the Construction Industry Journal: Construction Management and Economics Pages: 1013-1017 Issue: 11 Volume: 30 Year: 2012 Month: 11 X-DOI: 10.1080/01446193.2012.717704 File-URL: http://hdl.handle.net/10.1080/01446193.2012.717704 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:11:p:1013-1017 Template-Type: ReDIF-Article 1.0 Author-Name: Kalle Kähkönen Author-X-Name-First: Kalle Author-X-Name-Last: Kähkönen Title: Programming and Scheduling Techniques Journal: Construction Management and Economics Pages: 1017-1019 Issue: 11 Volume: 30 Year: 2012 Month: 11 X-DOI: 10.1080/01446193.2012.728708 File-URL: http://hdl.handle.net/10.1080/01446193.2012.728708 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:11:p:1017-1019 Template-Type: ReDIF-Article 1.0 Author-Name: Baabak Ashuri Author-X-Name-First: Baabak Author-X-Name-Last: Ashuri Author-Name: Seyed Mohsen Shahandashti Author-X-Name-First: Seyed Mohsen Author-X-Name-Last: Shahandashti Author-Name: Jian Lu Author-X-Name-First: Jian Author-X-Name-Last: Lu Title: Empirical tests for identifying leading indicators of ENR Construction Cost Index Abstract: Engineering News-Record (ENR) publishes its Construction Cost Index (CCI) monthly. CCI is the weighted average price of construction activities in 20 United States (US) cities. CCI has widely been used for cost estimation, bid preparation and investment planning. Cost estimators and investment planners are not only interested in the current CCI, but also are interested in forecasting changes in CCI trends. However, CCI is subject to significant variations that are difficult to predict. An important step towards forecasting CCI trends is to identify its leading indicators. The research objective is to identify the leading indicators of CCI using empirical tests. The results of Granger causality tests show that consumer price index, crude oil price, producer price index, GDP, employment levels in construction, number of building permits, number of housing starts and money supply are the leading indicators of CCI. The results of Johansen’s cointegration tests show that money supply and crude oil price are the leading indicators with long-term relationships with CCI. These findings contribute to the body of knowledge in CCI forecasting. CCI can be predicted more accurately using its leading indicators. Cost estimators and capital project planners can benefit from better forecasting through reduction in uncertainty about future construction costs. Journal: Construction Management and Economics Pages: 917-927 Issue: 11 Volume: 30 Year: 2012 Month: 11 X-DOI: 10.1080/01446193.2012.728709 File-URL: http://hdl.handle.net/10.1080/01446193.2012.728709 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:11:p:917-927 Template-Type: ReDIF-Article 1.0 Author-Name: Daisy Yeung Author-X-Name-First: Daisy Author-X-Name-Last: Yeung Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: A method for systematically pooling data in very early stage construction price forecasting Abstract: Client owners usually need an estimate or forecast of their likely building costs in advance of detailed design in order to confirm the financial feasibility of their projects. Because of their timing in the project life cycle, these early stage forecasts are characterized by the minimal amount of information available concerning the new (target) project to the point that often only its size and type are known. One approach is to use the mean contract sum of a sample, or base group, of previous projects of a similar type and size to the project for which the estimate is needed. Bernoulli’s law of large numbers implies that this base group should be as large as possible. However, increasing the size of the base group inevitably involves including projects that are less and less similar to the target project. Deciding on the optimal number of base group projects is known as the homogeneity or pooling problem. A method of solving the homogeneity problem is described involving the use of closed form equations to compare three different sampling arrangements of previous projects for their simulated forecasting ability by a cross-validation method, where a series of targets are extracted, with replacement, from the groups and compared with the mean value of the projects in the base groups. The procedure is then demonstrated with 450 Hong Kong projects (with different project types: Residential, Commercial centre, Car parking, Social community centre, School, Office, Hotel, Industrial, University and Hospital) clustered into base groups according to their type and size. Journal: Construction Management and Economics Pages: 929-939 Issue: 11 Volume: 30 Year: 2012 Month: 11 X-DOI: 10.1080/01446193.2012.733402 File-URL: http://hdl.handle.net/10.1080/01446193.2012.733402 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:11:p:929-939 Template-Type: ReDIF-Article 1.0 Author-Name: Farid Sedighi Author-X-Name-First: Farid Author-X-Name-Last: Sedighi Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: Employer-of-choice characteristics in the construction industry Abstract: In many countries, ageing populations, skills shortages and increasing inter-sector labour competition has made graduate recruitment and retention a priority in the construction industry. Understanding what constitutes an employer-of-choice in the eyes of graduates is important in meeting this challenge. A survey of 160 undergraduates across 26 international universities concluded that the top three most important workplace characteristics for university students on construction courses are: positive work relationships, being able to learn on the job, and a workplace that is passionate about work. Distinct gender differences were exposed between preferences as were differences in preferences compared to the preferences of graduates in other industries. These findings contribute to our understanding of how students make choices about employers, what factors are important in making those decisions and how these factors vary between different graduate groups. They also contribute to our understanding of how to design better recruitment strategies to attract talent to the construction sector in an environment where demand is anticipated to exceed supply for some time ahead. Journal: Construction Management and Economics Pages: 941-950 Issue: 11 Volume: 30 Year: 2012 Month: 11 X-DOI: 10.1080/01446193.2012.694458 File-URL: http://hdl.handle.net/10.1080/01446193.2012.694458 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:11:p:941-950 Template-Type: ReDIF-Article 1.0 Author-Name: Eddie Chi-Man Hui Author-X-Name-First: Eddie Chi-Man Author-X-Name-Last: Hui Author-Name: Cong Liang Author-X-Name-First: Cong Author-X-Name-Last: Liang Author-Name: Ziyou Wang Author-X-Name-First: Ziyou Author-X-Name-Last: Wang Author-Name: Bo-Tong Song Author-X-Name-First: Bo-Tong Author-X-Name-Last: Song Author-Name: Qi Gu Author-X-Name-First: Qi Author-X-Name-Last: Gu Title: Real estate bubbles in China: a tale of two cities Abstract: As housing markets have overheated recently in urban China, housing price bears substantial risk. The issue of housing price bubbles in these markets has become a popular and significant topic among consumers, policymakers and academia alike. In particular, Guangzhou and Shenzhen, as the most important markets for revealing the condition of the housing market in the Pearl River Delta, have attracted much attention in the period of prosperity. As such, an investigation into the bubble issue in these two cities is conducted by using an improved model, the time-varying risk model. The empirical work reveals that explosive bubbles did periodically (2003 Q1 to 2006 Q2 and 2009 Q2 to 2010 Q1) have an impact on the two markets. For the rest of the period, housing markets in both Guangzhou and Shenzhen are found to be significantly influenced by macro adjustments and various economic events. The implication of the research provides a reference for policymaking in addressing the issue of softening in China’s real estate market. Journal: Construction Management and Economics Pages: 951-961 Issue: 11 Volume: 30 Year: 2012 Month: 11 X-DOI: 10.1080/01446193.2012.714871 File-URL: http://hdl.handle.net/10.1080/01446193.2012.714871 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:11:p:951-961 Template-Type: ReDIF-Article 1.0 Author-Name: Jacob R. Tucker Author-X-Name-First: Jacob R. Author-X-Name-Last: Tucker Author-Name: Annie R. Pearce Author-X-Name-First: Annie R. Author-X-Name-Last: Pearce Author-Name: Richard D. Bruce Author-X-Name-First: Richard D. Author-X-Name-Last: Bruce Author-Name: Andrew P. McCoy Author-X-Name-First: Andrew P. Author-X-Name-Last: McCoy Author-Name: Thomas H. Mills Author-X-Name-First: Thomas H. Author-X-Name-Last: Mills Title: The perceived value of green professional credentials to credential holders in the US building design and construction community Abstract: The popularity of green construction professional credentials has increased dramatically in recent years in the United States and abroad, due in part to the mainstream development of sustainable construction in the building design and construction community. The aim was to compare the perceived value of three broad-spectrum green building professional credentials currently available in the North American construction market: Green Globes Professional, LEED Green Associate and Green Advantage Certified Practitioner. Perceived professional and personal value derived from holding credentials, including but not limited to impacts on compensation, promotion, education, industry recognition and self-confidence, were evaluated for a sample of credential holders using an online survey instrument. Invitations were successfully delivered to 6670 certified and non-certified design and construction professionals. Of those surveyed, 730 responded to the Qualtrics survey. A one-way analysis of variance (ANOVA) was used to detect significant differences between the reported perceptions of different credential holders. The results revealed that Green Globes Professionals and LEED Green Associates agree more strongly than Green Advantage Certified Practitioners that earning their credentials resulted in positive professional and personal impacts. No significant differences between the perceptions of Green Globes Professionals and LEED Green Associates were identified. Journal: Construction Management and Economics Pages: 963-979 Issue: 11 Volume: 30 Year: 2012 Month: 11 X-DOI: 10.1080/01446193.2012.728710 File-URL: http://hdl.handle.net/10.1080/01446193.2012.728710 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:11:p:963-979 Template-Type: ReDIF-Article 1.0 Author-Name: Srinivasa S. Ponnaluru Author-X-Name-First: Srinivasa S. Author-X-Name-Last: Ponnaluru Author-Name: Thomas L. Marsh Author-X-Name-First: Thomas L. Author-X-Name-Last: Marsh Author-Name: Michael Brady Author-X-Name-First: Michael Author-X-Name-Last: Brady Title: Spatial price analysis of used construction equipment: the case of excavators Abstract: Equipment represents one of the largest input expenditures for the construction sector and other firms. Yet, prices of used construction equipment have not been widely studied in the economic literature. A spatial hedonic price function is specified and estimated for used excavators sold by auction in North America from 1996 to 2006. The results indicate that prices of used excavators differ significantly for various reasons. Controlling for characteristics of the machinery, we find evidence of regional price variation and ‘within sale’ spatial effects. Prices also vary between auction houses themselves. Journal: Construction Management and Economics Pages: 981-994 Issue: 11 Volume: 30 Year: 2012 Month: 11 X-DOI: 10.1080/01446193.2012.723129 File-URL: http://hdl.handle.net/10.1080/01446193.2012.723129 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:11:p:981-994 Template-Type: ReDIF-Article 1.0 Author-Name: Mehmet Egemen Ozbek Author-X-Name-First: Mehmet Egemen Author-X-Name-Last: Ozbek Author-Name: Jesus M. de la Garza Author-X-Name-First: Jesus M. Author-X-Name-Last: de la Garza Author-Name: Konstantinos Triantis Author-X-Name-First: Konstantinos Author-X-Name-Last: Triantis Title: Efficiency measurement of the maintenance of paved lanes using data envelopment analysis Abstract: While the road maintenance performance measurement systems that are currently in use investigate maintenance level of service (i.e. effectiveness of the road maintenance), the fundamental relationship between the maintenance level of service and the budget requirements (i.e. the efficiency of road maintenance) has not received as much attention. Given that not knowing how ‘efficient’ transportation agencies are in being ‘effective’ can lead to excessive and unrealistic maintenance budget expectations, there is a need for a performance measurement system that can assess the overall efficiency of road maintenance operations. To address this need, a framework was developed and implemented to assess the relative cost efficiency of eight counties in Virginia, USA in maintaining the paved lanes of the Interstate roads. Such framework is developed using a methodology known as data envelopment analysis which is based on the production theory and principles of linear programming. The results indicate that the Rockbridge County is the most efficient and the Roanoke County is the least efficient in maintaining the paved lanes. The findings of this research are intended to be used as guides for benchmarking as well as managerial actions and policy making for decision making with respect to road maintenance. Journal: Construction Management and Economics Pages: 995-1009 Issue: 11 Volume: 30 Year: 2012 Month: 11 X-DOI: 10.1080/01446193.2012.725939 File-URL: http://hdl.handle.net/10.1080/01446193.2012.725939 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:11:p:995-1009 Template-Type: ReDIF-Article 1.0 Author-Name: Xian Zheng Author-X-Name-First: Xian Author-X-Name-Last: Zheng Author-Name: Kwong Wing Chau Author-X-Name-First: Kwong Wing Author-X-Name-Last: Chau Author-Name: Eddie Chi-Man Hui Author-X-Name-First: Eddie Chi-Man Author-X-Name-Last: Hui Title: The impact of property price on construction output Abstract: The interaction between the construction market and the overall economy has attracted much attention, but few studies have investigated the influence of the property market on the construction market in terms of property price. The disaggregated data of Hong Kong’s housing and retail construction sectors are collected to investigate the impact of property price on construction output. The newly developed autoregressive distributed lag (ARDL) bounds testing approach and the error correction (EC)-based Granger causality test are employed. The bounds testing results suggest that there exist stable long-run relationships between construction output and property price for both housing and retail construction sectors. Specifically, a 1.00% increase in the housing price and retail price lead to a 0.55% and 0.42% increase in construction outputs for the two sectors respectively. In addition, the Granger causality tests confirm a distinct long-run causal flow from property price to construction output. Furthermore, the proposed ARDL approach provides an effective method for forecasting construction output. Journal: Construction Management and Economics Pages: 1025-1037 Issue: 12 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2012.714872 File-URL: http://hdl.handle.net/10.1080/01446193.2012.714872 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:12:p:1025-1037 Template-Type: ReDIF-Article 1.0 Author-Name: Mohamad Kassem Author-X-Name-First: Mohamad Author-X-Name-Last: Kassem Author-Name: Nashwan Dawood Author-X-Name-First: Nashwan Author-X-Name-Last: Dawood Author-Name: Donald Mitchell Author-X-Name-First: Donald Author-X-Name-Last: Mitchell Title: A decision support system for the selection of curtain wall systems at the design development stage Abstract: In high rise building construction projects, curtain wall is one of the most widely used exterior finishing components and has a major influence on the overall building operational costs and efficiency in terms of CO2 emissions. The selection of curtain wall systems involves numerous technical, environmental and economic factors, and impacts on all project stages from concept design, through manufacture to installation and operation. The current way this important decision is being made in the business process, and its simplification, are two important issues that are still unexplored in the literature. After investigating the drawbacks of the current business process using a retrospective case study and an industrial survey, a decision support system (DSS), which consists of a process framework and an integrated relational database as a central repository for the main curtain wall systems and their engineering parameters, is proposed as a potential solution. The DSS developed not only enables the resolution of the main issue of the selection of curtain wall systems at the early design development stage but it also helps specifiers identify multiple technical and commercial options that could be presented to clients in real time. Journal: Construction Management and Economics Pages: 1039-1053 Issue: 12 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2012.725940 File-URL: http://hdl.handle.net/10.1080/01446193.2012.725940 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:12:p:1039-1053 Template-Type: ReDIF-Article 1.0 Author-Name: Fah Choy Chia Author-X-Name-First: Fah Choy Author-X-Name-Last: Chia Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Goran Runeson Author-X-Name-First: Goran Author-X-Name-Last: Runeson Author-Name: Adrian Bridge Author-X-Name-First: Adrian Author-X-Name-Last: Bridge Title: An analysis of construction productivity in Malaysia Abstract: The construction industry is an industry of major strategic importance. Its level of productivity has a significant effect on national economic growth. Productivity indicators are examined. The indicators consist of labour productivity, capital productivity, labour competitiveness, capital intensity and added value content of data, which are obtained from the published census/biannual surveys of the construction industry between the years 1999 and 2011 from the Department of Statistics of Malaysia. The results indicated that there is an improvement in the labour productivity, but the value-added content is declining. The civil engineering and special trades subsectors are more productive than the residential and non-residential subsectors in terms of labour productivity because machine-for-labour substitution is a more important process in those subsectors. The capital-intensive characteristics of civil engineering and special trade works enable these subsectors to achieve higher added value per labour cost but not the capital productivity. The added value per labour cost is lower in larger organizations despite higher capital productivity. However, the capital intensity is lower and unit labour cost is higher in the larger organizations. Journal: Construction Management and Economics Pages: 1055-1069 Issue: 12 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2012.711910 File-URL: http://hdl.handle.net/10.1080/01446193.2012.711910 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:12:p:1055-1069 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Vivien W. Chow Author-X-Name-First: Vivien W. Author-X-Name-Last: Chow Author-Name: Denny Mcgeorge Author-X-Name-First: Denny Author-X-Name-Last: Mcgeorge Title: Modelling the risks of extreme weather events for Australasian hospital infrastructure using rich picture diagrams Abstract: Anticipated increases in the frequency of extreme weather events in the future are likely to expose hospital infrastructure to new risks which are poorly understood. Traditional approaches to risk identification and analysis produce linear, narrow and static risk profiles which fail to consider complex sub-system interdependencies that may assist or hinder healthcare delivery during an extreme weather event. The ability to create resilient hospitals depends on new risk management methodologies which provide an understanding of these complex relationships. Focus groups with key stakeholders in three hospitals in Australia are used to construct rich picture diagrams (RPDs) of hospital infrastructure interdependencies under different extreme weather event scenarios. They show that the risks posed to hospitals by extreme weather events cannot be considered in isolation from the surrounding infrastructure, emergency management systems, health systems and communities in which they are imbedded. The new insights provided have major governance and policy implications for agencies responsible for ensuring that hospital infrastructure can continue to support the delivery of effective health services during extreme weather events. Journal: Construction Management and Economics Pages: 1071-1086 Issue: 12 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2012.725941 File-URL: http://hdl.handle.net/10.1080/01446193.2012.725941 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:12:p:1071-1086 Template-Type: ReDIF-Article 1.0 Author-Name: Florence Yean Yng Ling Author-X-Name-First: Florence Yean Yng Author-X-Name-Last: Ling Author-Name: Phuong Quynh Tran Author-X-Name-First: Phuong Quynh Author-X-Name-Last: Tran Title: Effects of interpersonal relations on public sector construction contracts in Vietnam Abstract: Public owners and private contractors and consultants are expected to maintain arm’s length relationships with each other to avoid any accusation of corruption. In the context of public construction projects in Vietnam, this study examines: the relational contracting (RC) related behavioural patterns that lead to better interpersonal relations during the construction stage and at the end of the project among public project owners, and private contractors and consultants; and the extent to which better interpersonal relations affect project performance. Using a questionnaire survey, data were collected from public owners and private contractors and consultants in Vietnam. Correlation analysis shows that there exist several behavioural patterns that significantly affect interpersonal relations among project team members during the construction stage and at the end of the project, and the general harmony during the construction stage. It was also found that cost performance is significantly correlated with project harmony level. Schedule performance is significantly correlated with interpersonal relations between project team members during the construction stage, and at the end of the project. The findings indicate the important role that interpersonal relations play in project outcomes and vice versa. The behavioural patterns that are found to be significantly correlated with harmony during the construction stage and/or relationships among project team members suggest that concrete actions may be taken by owners, consultants and contractors to improve relationships, and thereby improve cost and schedule outcomes. It is recommended that owners, consultants and contractors adopt some of the behavioural patterns identified. Journal: Construction Management and Economics Pages: 1087-1101 Issue: 12 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2012.729848 File-URL: http://hdl.handle.net/10.1080/01446193.2012.729848 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:12:p:1087-1101 Template-Type: ReDIF-Article 1.0 Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Title: New Aspects of Quantity Surveying Practice Journal: Construction Management and Economics Pages: 1103-1105 Issue: 12 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2012.723128 File-URL: http://hdl.handle.net/10.1080/01446193.2012.723128 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:12:p:1103-1105 Template-Type: ReDIF-Article 1.0 Author-Name: Helena Johnsson Author-X-Name-First: Helena Author-X-Name-Last: Johnsson Title: Construction Purchasing and Supply Chain Management Journal: Construction Management and Economics Pages: 1105-1107 Issue: 12 Volume: 30 Year: 2012 Month: 8 X-DOI: 10.1080/01446193.2012.722223 File-URL: http://hdl.handle.net/10.1080/01446193.2012.722223 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:12:p:1105-1107 Template-Type: ReDIF-Article 1.0 Author-Name: Göran Lindahl Author-X-Name-First: Göran Author-X-Name-Last: Lindahl Title: Innovations in Hospital Architecture Journal: Construction Management and Economics Pages: 1107-1109 Issue: 12 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2012.723808 File-URL: http://hdl.handle.net/10.1080/01446193.2012.723808 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:12:p:1107-1109 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Allan Author-X-Name-First: Andrew Author-X-Name-Last: Allan Title: Infrastructure Sustainability and Design Journal: Construction Management and Economics Pages: 1109-1112 Issue: 12 Volume: 30 Year: 2012 Month: 12 X-DOI: 10.1080/01446193.2012.727009 File-URL: http://hdl.handle.net/10.1080/01446193.2012.727009 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:30:y:2012:i:12:p:1109-1112 Template-Type: ReDIF-Article 1.0 Author-Name: Jin-Lee Kim Author-X-Name-First: Jin-Lee Author-X-Name-Last: Kim Title: Genetic algorithm stopping criteria for optimization of construction resource scheduling problems Abstract: Genetic algorithms (GAs) have been widely applied in the civil and construction engineering management research domain to solve difficult and complex problems such as resource-constrained project scheduling problems (RCPSPs). Generally, a trial-and-error calibration approach is used to identify values for the GA parameters. Unlike with other parameters, few studies have been done, theoretically or experimentally, for determining when to terminate GA for optimization of the RCPSP. Two genetic algorithm stopping conditions are compared to demonstrate their suitability for application in the RCPSP and to assess their ability in searching optimal solutions efficiently. The extensive computational results show that the Elitist GA, when using the unique schedule method, provides 10% more optimum values than those obtained from the Elitist GA when using the iteration method with 24% less computational time. The unique schedule stopping approach can be valuable for GA users to design their purpose driven GA for optimization of the RCPSP as it provides a better near-optimal solution with reduced computational time. Journal: Construction Management and Economics Pages: 3-19 Issue: 1 Volume: 31 Year: 2013 Month: 1 X-DOI: 10.1080/01446193.2012.697181 File-URL: http://hdl.handle.net/10.1080/01446193.2012.697181 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:1:p:3-19 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Raisbeck Author-X-Name-First: Peter Author-X-Name-Last: Raisbeck Author-Name: Llewellyn C.M. Tang Author-X-Name-First: Llewellyn C.M. Author-X-Name-Last: Tang Title: Identifying design development factors in Australian PPP projects using an AHP framework Abstract: In Australia consortiums will come together and create an initial design concept or sketch design at the public--private partnership (PPP) bid stage. If the bid is successful this initial design is then developed further. However, a winning bid may have been evaluated on financial criteria alone and the consortium’s capability to develop the design through to project delivery may not have been thoroughly evaluated. In theory, design is a key process in PPP projects and the aim of the research was to understand what capabilities are important in the development of a design through this process. To clarify these issues, a range of activities and organizational factors linked to design development are proposed using the analytic hierarchy process (AHP) method. This method was chosen in order to see which design development factors were ranked more highly by experts. In this research the hierarchy was designed employing the categories of exploratory and exploitative design development. Below each of these overarching categories, there were four design development functional distinctions: the two exploratory distinctions were Design (D) and Design Management (DM). The two exploitative distinctions were Design Support (DS) and Design Infrastructure (DI). A further list of 36 design development sub-criteria was developed under the above categories. These sub-criteria formed the basis of a survey of respondents drawn from a database of industry sources in the public domain as well as a list gathered from a large developer involved in PPP projects. It included relatively senior managers, PPP project managers and architects. Survey respondents identified a recent PPP project that they had worked on. From the 36 responses it can be seen that the exploratory Design (D) and Design Management (DM) activities were ranked more highly than the exploitative activities of Design Support (DS) and Design Infrastructure (DI) associated with a PPP project organization. This suggests that PPP frameworks should account for these exploratory factors as well as the exploitative factors associated with compliance, quality systems and project team infrastructure. This indicates that in PPP projects design development through the effective management of an initial design is a critical factor. Journal: Construction Management and Economics Pages: 20-39 Issue: 1 Volume: 31 Year: 2013 Month: 1 X-DOI: 10.1080/01446193.2012.729133 File-URL: http://hdl.handle.net/10.1080/01446193.2012.729133 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:1:p:20-39 Template-Type: ReDIF-Article 1.0 Author-Name: Håkan Håkansson Author-X-Name-First: Håkan Author-X-Name-Last: Håkansson Author-Name: Malena Ingemansson Author-X-Name-First: Malena Author-X-Name-Last: Ingemansson Title: Industrial renewal within the construction network Abstract: The construction business network is generally seen as conservative and non-innovative, for which a number of reasons have been identified. One of these reasons relates to the special inter-organizational setting that exists within the industry. The starting point of our study was to investigate whether there is any truth in this perceived lack of innovation. One reason for the industry’s bad reputation could be that the way innovation generally is defined and measured is unsuitable for the construction business. Therefore, renewal was used as the central concept of change in our investigation. The second issue concerns factors that either assist or impede renewal, and the ambition was to identify those factors driving, as well as those hindering renewal. In order to identify the degree of renewal, as well as the factors affecting it, we conducted a survey of Swedish construction companies. The resulting picture shows a clear connection between the inter-organizational interfaces within the industry and how renewal takes place. The total renewal activity is on a considerable level with more than 60% having made changes visible from the customer’s point of view. The most active interface is also in relation to customers, while the relationship to suppliers generally is more distant. Finally, the project focus which characterizes the industry affects what type of renewal takes place, and exposes the lack of knowledge transfer between individual projects and actors as an important hindrance to renewal in the construction network. Journal: Construction Management and Economics Pages: 40-61 Issue: 1 Volume: 31 Year: 2013 Month: 1 X-DOI: 10.1080/01446193.2012.737470 File-URL: http://hdl.handle.net/10.1080/01446193.2012.737470 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:1:p:40-61 Template-Type: ReDIF-Article 1.0 Author-Name: Craig Langston Author-X-Name-First: Craig Author-X-Name-Last: Langston Title: The role of coordinate-based decision-making in the evaluation of sustainable built environments Abstract: In an era when sustainability and climate change mitigation are paramount, it is important that built environment professionals make robust and transparent decisions regarding future development. A new approach is outlined and tested for assessing sustainability for built infrastructure using a quadrant model and 3D spatial coordinates. The chosen method involves a case study of a high performance green building in Australia that was constructed in 2008. The investigation demonstrates that the model is practical and produces an appropriate outcome, which is then compared with seven other generic types of built infrastructure. The inclusion of development scale or influence in the model is an important feature that can lead to differences in ranking preference. The findings support embedding essential environmental considerations objectively into decision-making processes via the use of an economic ratio (return on investment to energy usage), a social ratio (functional performance to loss of habitat) and a measure of sustainability risk as x, y and z coordinates respectively, plotted in 3D space. Journal: Construction Management and Economics Pages: 62-77 Issue: 1 Volume: 31 Year: 2013 Month: 1 X-DOI: 10.1080/01446193.2012.738920 File-URL: http://hdl.handle.net/10.1080/01446193.2012.738920 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:1:p:62-77 Template-Type: ReDIF-Article 1.0 Author-Name: Carole Boudeau Author-X-Name-First: Carole Author-X-Name-Last: Boudeau Title: Design team meetings and the coordination of expertise: the roof garden of a hospital Abstract: The coordination of work and expertise in construction projects is often treated in terms of models or formal rules. However, much is to be gained, if we are to understand it, by examining actual coordination practices. The objective in this article is to address practices of coordination of expertise in the context of design team meetings. The focus is specifically on conversational practices between the structural engineer and the landscape architect who are part of the design team in a healthcare infrastructure project. The central argument is that the coordination of expertise relied on and was organized by mundane and everyday methods, and not by formal and abstract ones. This argument is drawn from ethnomethodology, a form of sociological analysis that focuses on the situated methods by which activities are produced, but shares concerns found in the literature on actual project management practices. The ethnomethodological stance, however, offers a different perspective on the significance of the empirical reality of projects and a possibility to incorporate within this literature a concern with the ordinary methodical organization of project activities. Journal: Construction Management and Economics Pages: 78-89 Issue: 1 Volume: 31 Year: 2013 Month: 1 X-DOI: 10.1080/01446193.2012.738301 File-URL: http://hdl.handle.net/10.1080/01446193.2012.738301 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:1:p:78-89 Template-Type: ReDIF-Article 1.0 Author-Name: Gerard de Valence Author-X-Name-First: Gerard de Author-X-Name-Last: Valence Title: Construction management strategies: a theory of construction management By Milan Radosavljevic and John Bennett, Wiley-Blackwell, London, 2012. ISBN 978-0-470-65609-9, £39.99 (pb) Journal: Construction Management and Economics Pages: 90-93 Issue: 1 Volume: 31 Year: 2013 Month: 1 X-DOI: 10.1080/01446193.2012.736025 File-URL: http://hdl.handle.net/10.1080/01446193.2012.736025 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:1:p:90-93 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Emmitt Author-X-Name-First: Stephen Author-X-Name-Last: Emmitt Title: Construction Innovation and Process Improvement Akintola Akintoye, Jack Goulding and Girma Zawdie (eds), Wiley-Blackwell, London 2012, 456 pp, ISBN 978 1 4051 5648 6, £72.50 (hb) Journal: Construction Management and Economics Pages: 93-95 Issue: 1 Volume: 31 Year: 2013 Month: 1 X-DOI: 10.1080/01446193.2012.729846 File-URL: http://hdl.handle.net/10.1080/01446193.2012.729846 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:1:p:93-95 Template-Type: ReDIF-Article 1.0 Author-Name: Bland Tomkinson Author-X-Name-First: Bland Author-X-Name-Last: Tomkinson Title: Post-disaster Reconstruction of the Built Environment: Rebuilding for Resilience Edited by Dilanthi Amaratunga and Richard Haigh, Wiley-Blackwell, London, 2011 336 pp, ISBN 978 1 4443 3356 5, £75.00 (hb) Journal: Construction Management and Economics Pages: 95-96 Issue: 1 Volume: 31 Year: 2013 Month: 1 X-DOI: 10.1080/01446193.2012.729847 File-URL: http://hdl.handle.net/10.1080/01446193.2012.729847 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:1:p:95-96 Template-Type: ReDIF-Article 1.0 Author-Name: Chen-Yu Chang Author-X-Name-First: Chen-Yu Author-X-Name-Last: Chang Title: A critical review of the application of TCE in the interpretation of risk allocation in PPP contracts Abstract: Along with the rise of public--private partnerships (PPPs) as a mainstream procurement system, we have seen a growing interest in studies of risk allocation in these projects. One of the serious academic endeavours is to apply both transaction cost economics (TCE) and the resource-based view (RBV) to explain risk allocation patterns found in PPP projects. The existing literature along these lines is deficient in three aspects: inappropriate choice of unit of analysis; poor specification of governance structure; and misinterpretation of asset specificity. A way for improvement is to analyse risk allocation in the context of PPP procurement in its entirety. Journal: Construction Management and Economics Pages: 99-103 Issue: 2 Volume: 31 Year: 2013 Month: 2 X-DOI: 10.1080/01446193.2012.726365 File-URL: http://hdl.handle.net/10.1080/01446193.2012.726365 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:2:p:99-103 Template-Type: ReDIF-Article 1.0 Author-Name: Lena Elisabeth Bygballe Author-X-Name-First: Lena Elisabeth Author-X-Name-Last: Bygballe Author-Name: H?kan H?kansson Author-X-Name-First: H?kan Author-X-Name-Last: H?kansson Author-Name: Marianne Jahre Author-X-Name-First: Marianne Author-X-Name-Last: Jahre Title: A critical discussion of models for conceptualizing the economic logic of construction Abstract: The construction industry has developed a certain economic logic that reflects the way in which tasks, parts, and units are organized and related to each other in order to create economic benefits in the construction process. Four different models in the literature portray this logic. We examine how they complement and constitute alternatives to understandings of the economic logic of the construction industry. Along with transaction cost economics, we have identified three more empirically based models: a project-oriented model, a supply-chain-oriented model, and a network-oriented model. Associated with different streams of research, these models are discussed in terms of the typical problems and key interdependencies in the construction process they address, and the type of solutions they suggest, including organizing principles for how construction parties should relate to each other. The findings show how examining different models provides a comprehensive, albeit non-exhaustive overview and an explanation of why the construction process is organized in the way it is. There is a need for increased awareness of the utilization of models (or combinations of models) and the models must also be seen as arguments in a broader discussion of how the construction process could or should function. Journal: Construction Management and Economics Pages: 104-118 Issue: 2 Volume: 31 Year: 2013 Month: 2 X-DOI: 10.1080/01446193.2012.745645 File-URL: http://hdl.handle.net/10.1080/01446193.2012.745645 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:2:p:104-118 Template-Type: ReDIF-Article 1.0 Author-Name: Stefan Christoffer Gottlieb Author-X-Name-First: Stefan Christoffer Author-X-Name-Last: Gottlieb Author-Name: Kim Haugb?lle Author-X-Name-First: Kim Author-X-Name-Last: Haugb?le Title: Contradictions and collaboration: partnering in-between systems of production, values and interests Abstract: For more than a decade, partnering has been pursued as a promising way of overcoming the drawbacks of the building process. Despite intense and repeated efforts, promises have only to some extent been satisfied. Based on an example case study of a partnering project, activity theory is applied in an analysis of how project outcomes are shaped mutually by the underlying dynamics of construction and innovative initiatives like partnering. The case was studied through a combination of questionnaire surveys, interactive workshops, semi-structured qualitative research interviews and onsite observations. Three main findings are presented. First, that the dynamics of construction can be understood as the interrelation of three activity systems on production, values and interests. Second, partnering as a change strategy is overlaid on existing practice rather than substituting it. Third, partnering may reduce some contradictions but induces others simultaneously. In conclusion, the potential of partnering as a change strategy depends on the ability to understand and manage contradictions in and between existing institutionalized activity systems in construction of production, values and interests. Journal: Construction Management and Economics Pages: 119-134 Issue: 2 Volume: 31 Year: 2013 Month: 2 X-DOI: 10.1080/01446193.2012.756141 File-URL: http://hdl.handle.net/10.1080/01446193.2012.756141 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:2:p:119-134 Template-Type: ReDIF-Article 1.0 Author-Name: Robert Gerth Author-X-Name-First: Robert Author-X-Name-Last: Gerth Author-Name: Albert Boqvist Author-X-Name-First: Albert Author-X-Name-Last: Boqvist Author-Name: Marcus Bjelkemyr Author-X-Name-First: Marcus Author-X-Name-Last: Bjelkemyr Author-Name: Bengt Lindberg Author-X-Name-First: Bengt Author-X-Name-Last: Lindberg Title: Design for construction: utilizing production experiences in development Abstract: The design process has a significant impact on the performance and profitability of a housing project. Therefore, decisions made during the design process should take into consideration knowledge and experience from other processes in previously accomplished projects, specifically from the production phase. How to capture and use production experience in housing has not gained enough interest, possibly leading to sub-optimal improvements during the construction process. This motivates research on how onsite production experience from similar previous projects can be captured and used to improve constructability without risking customer values. Based on the concept of constructability, ‘design for manufacturing and assembly’ and the theory of waste, the method ‘design for construction’ (DFC) has been developed. The four-step model complements the conventional construction process, and consists of the following steps: (1) specify customer values and similar previous projects; (2) identify onsite waste and cost drivers in previous projects; (3) develop criteria to evaluate constructability; and (4) evaluate constructability of the design. The DFC method is exemplified and tested through a case study, in which it was shown that the method facilitated identification of all problems that were considered in the investigated project. The method also highlighted other project obstacles that potentially could have been solved to improve constructability. Journal: Construction Management and Economics Pages: 135-150 Issue: 2 Volume: 31 Year: 2013 Month: 2 X-DOI: 10.1080/01446193.2012.756142 File-URL: http://hdl.handle.net/10.1080/01446193.2012.756142 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:2:p:135-150 Template-Type: ReDIF-Article 1.0 Author-Name: R?is?n Murphy Author-X-Name-First: R?is?n Author-X-Name-Last: Murphy Title: Strategic planning in construction professional service firms: a study of Irish QS practices Abstract: The role and usefulness of strategic planning has been documented over several decades of strategic management research. Despite the significant body of existing knowledge in the field of strategic planning, there remains limited empirical investigation of the construction sector, specifically professional service firms operating within it. The construction sector is hugely important to the Irish economy, yet until now, no empirical investigation has been undertaken to determine the strategic planning process in construction professional service firms in Ireland. A two-phase mixed methods study was undertaken to ascertain the extent of strategic planning within quantity surveying (QS) practices in Ireland. Characteristics of the strategic planning process differ between practices to such a degree that three groups of practices are apparent. Groups are differentiated along dimensions of size and ownership structure, which influence the generic strategies and competitive positioning of practices. Strategic planning process formality and the existence of a written plan are positively associated with large practices that form part of a global organization. Informal strategic planning is undertaken in practices without a written strategic plan but tends to be tactical (project-based) rather than strategic in nature. The realization of the need for systematic strategic planning in QS practices is, however, beginning to emerge, given the turbulent environment within which the firms are competing. While the conclusions are specific to the QS profession, the research has been designed such that it has potential to be applied to other professional service firms. Journal: Construction Management and Economics Pages: 151-166 Issue: 2 Volume: 31 Year: 2013 Month: 2 X-DOI: 10.1080/01446193.2012.736026 File-URL: http://hdl.handle.net/10.1080/01446193.2012.736026 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:2:p:151-166 Template-Type: ReDIF-Article 1.0 Author-Name: Florence T.T. Phua Author-X-Name-First: Florence T.T. Author-X-Name-Last: Phua Title: Construction management research at the individual level of analysis: current status, gaps and future directions Abstract: Individual-level constructs are seldom taken into consideration in construction management research relating to project performance. This is antithetical to the objectives of properly conceptualizing and contextualizing the research we do because many project performance outcomes, such as the extent of cooperation and level of communication or teamwork are influenced and moderated by individuals' perceptions, values and behaviour. A brief review of the literature in organizational studies centred on culture, identity, empowerment and trust is offered. These constructs are then explored in relation to project performance issues and outcomes, and it is noted that they are predominantly studied at the project and industry levels. We argue that focusing these constructs at the individual unit of analysis has significant implications for project performance and therefore their effects need to be systematically accounted for in explanations of the success and failure of projects. Far from being prescriptive, the aim is to generate interest and awareness for more focused research at the individual level of analysis in order to add new insights and perspectives to critical performance questions in construction management. To this end, a research agenda is outlined, arguing that construction management research integrating individual-level constructs and broader, macro-contextual issues will help define and enhance the legitimacy of the field. Journal: Construction Management and Economics Pages: 167-179 Issue: 2 Volume: 31 Year: 2013 Month: 2 X-DOI: 10.1080/01446193.2012.707325 File-URL: http://hdl.handle.net/10.1080/01446193.2012.707325 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:2:p:167-179 Template-Type: ReDIF-Article 1.0 Author-Name: Cindy L. Menches Author-X-Name-First: Cindy L. Author-X-Name-Last: Menches Author-Name: Juan Chen Author-X-Name-First: Juan Author-X-Name-Last: Chen Title: Using ecological momentary assessment to understand a construction worker’s daily disruptions and decisions Abstract: Capturing the momentary decisions and actions made by construction workers in response to workflow disruptions is challenging because, until now, there has not been a minimally disruptive data collection method that allows workers to identify their decision process ‘in the moment’. However, an Ecological Momentary Assessment (EMA) method—designed to capture momentary work experiences in natural settings—can provide researchers with detailed information about the daily challenges experienced by workers during the course of performing their tasks. An explanation of the method is provided, along with examples of the types of research questions that can be addressed and appropriate analysis techniques. The EMA method is being used on a federally funded research programme in the United States that is investigating how construction workers adapt to workflow disruptions by improvising their decisions and actions. Consequently, this article demonstrates the use of the method by presenting an idiographic study of William, an electrical construction worker. The evaluation of William’s disruptions, decisions and actions elucidated an important relationship: every one of William’s disruptions required an improvisational action in order for him to continue working. The EMA method opens the door to the development of new theories about rapid decisions and subsequent actions on construction sites. Journal: Construction Management and Economics Pages: 180-194 Issue: 2 Volume: 31 Year: 2013 Month: 2 X-DOI: 10.1080/01446193.2012.717707 File-URL: http://hdl.handle.net/10.1080/01446193.2012.717707 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:2:p:180-194 Template-Type: ReDIF-Article 1.0 Author-Name: Ksenia Chmutina Author-X-Name-First: Ksenia Author-X-Name-Last: Chmutina Title: Building for a Changing Climate: The Challenge for Construction, Planning and Energy Journal: Construction Management and Economics Pages: 195-197 Issue: 2 Volume: 31 Year: 2013 Month: 2 X-DOI: 10.1080/01446193.2012.757337 File-URL: http://hdl.handle.net/10.1080/01446193.2012.757337 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:2:p:195-197 Template-Type: ReDIF-Article 1.0 Author-Name: Clara Greed Author-X-Name-First: Clara Author-X-Name-Last: Greed Title: Human Resource Management in Construction: Critical Perspectives Journal: Construction Management and Economics Pages: 197-200 Issue: 2 Volume: 31 Year: 2013 Month: 2 X-DOI: 10.1080/01446193.2012.751492 File-URL: http://hdl.handle.net/10.1080/01446193.2012.751492 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:2:p:197-200 Template-Type: ReDIF-Article 1.0 Author-Name: Valerie Caven Author-X-Name-First: Valerie Author-X-Name-Last: Caven Title: Human Resource Management in Construction Journal: Construction Management and Economics Pages: 200-202 Issue: 2 Volume: 31 Year: 2013 Month: 2 X-DOI: 10.1080/01446193.2012.745941 File-URL: http://hdl.handle.net/10.1080/01446193.2012.745941 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:2:p:200-202 Template-Type: ReDIF-Article 1.0 Author-Name: Lucio Soibelman Author-X-Name-First: Lucio Author-X-Name-Last: Soibelman Title: Integral Sustainable Design Journal: Construction Management and Economics Pages: 202-203 Issue: 2 Volume: 31 Year: 2013 Month: 2 X-DOI: 10.1080/01446193.2012.735368 File-URL: http://hdl.handle.net/10.1080/01446193.2012.735368 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:2:p:202-203 Template-Type: ReDIF-Article 1.0 Author-Name: Mengchun Zhang Author-X-Name-First: Mengchun Author-X-Name-Last: Zhang Author-Name: Dongping Fang Author-X-Name-First: Dongping Author-X-Name-Last: Fang Title: A cognitive analysis of why Chinese scaffolders do not use safety harnesses in construction Abstract: Chinese scaffolders not using safety harnesses is commonplace, despite scaffolders being constantly exposed to fall hazards on construction sites and the use of safety harnesses being required by law. The causes of Chinese scaffolders not using safety harnesses are explored through theoretical analyses and empirical tests. In theoretical analyses, based on Surry’s model, the major cause of scaffolders not using safety harnesses was identified as their personal decisions not to do so. The theory of planned behaviour (TPB) was used to analyse why scaffolders decided not to use safety harnesses. In empirical tests, scaffolders on seven sites completed questionnaires developed based on TPB, and nine safety officers participated in a focus group meeting to collect their views on scaffolders’ use of safety harnesses. In addition, two scaffolders, one gangmaster, one safety officer, and one foreman were interviewed to verify the results of the questionnaire survey. Empirical tests results show that the inconvenience and discomfort of using safety harnesses, underestimating the risk of not using safety harnesses, negative pressures from gangmasters, foremen, and safety officers, and lack of safety lines are causes of scaffolders deciding not to use safety harnesses. Measures enhancing the use of safety harnesses are proposed based on the results of empirical tests. Journal: Construction Management and Economics Pages: 207-222 Issue: 3 Volume: 31 Year: 2013 Month: 3 X-DOI: 10.1080/01446193.2013.764000 File-URL: http://hdl.handle.net/10.1080/01446193.2013.764000 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:3:p:207-222 Template-Type: ReDIF-Article 1.0 Author-Name: Abraham Park Author-X-Name-First: Abraham Author-X-Name-Last: Park Author-Name: Chen-Yu Chang Author-X-Name-First: Chen-Yu Author-X-Name-Last: Chang Title: Impacts of construction events on the project equity value of the Channel Tunnel project Abstract: With the growing strains on public resources, many governments in recent years have turned to the private sector for infrastructure project financing. The special purpose vehicles (SPVs) taking on such projects usually have a two-stage business model: a construction stage followed by an operating stage. However, the project risk in stage 1 is very high, and in most cases, the impacts of specific construction events on project risk and capital cost are unobservable owing to lack of informational transparency. Eurotunnel (the Channel Tunnel project) is unique in that the share price data for the entire construction period are publicly available. Based on event study methodology, empirical tests were conducted for several well-documented Eurotunnel construction events to measure and assess the project risk and the impacts of such events on the SPV’s equity value. The test results show that: (1) during the construction stage, efforts to better manage the interests and incentives of contractors produce more significant positive impact on investors than efforts for cost containment; (2) during the construction stage, meeting the project deadline is a higher investor priority than containing construction cost; and (3) once the construction phase is complete, the investors’ priority then becomes the overall cost and the impact of construction events on the expected returns from investment. Finally, the level of risk and the potential conflicts of interest that arise during the construction phase of a mega infrastructure project are such that turning to IPOs to provide equity capital may not be appropriate. Journal: Construction Management and Economics Pages: 223-237 Issue: 3 Volume: 31 Year: 2013 Month: 3 X-DOI: 10.1080/01446193.2012.761715 File-URL: http://hdl.handle.net/10.1080/01446193.2012.761715 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:3:p:223-237 Template-Type: ReDIF-Article 1.0 Author-Name: Gunnar Lucko Author-X-Name-First: Gunnar Author-X-Name-Last: Lucko Title: Supporting financial decision-making based on time value of money with singularity functions in cash flow models Abstract: Existing budgeting approaches differ in whether or not they consider the time value of money. A novel use of singularity functions in construction management has the potential to enhance cash flow models in order to maximize their net present value. This type of function can model a complete schedule, which serves as the underlying timeline for all financial transactions. Their variable amounts and constraints are expressed by singularity functions, converted from costs via bills into payments, and compounded towards the overall net present value for financial decision-making. Contributions to the body of knowledge include deriving exact amounts of interest on variable balances for any duration, creating a valuation algorithm, and exploring how the uneven solution space that cash flow profiles create can be searched successfully with a genetic algorithm. Journal: Construction Management and Economics Pages: 238-253 Issue: 3 Volume: 31 Year: 2013 Month: 3 X-DOI: 10.1080/01446193.2012.750728 File-URL: http://hdl.handle.net/10.1080/01446193.2012.750728 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:3:p:238-253 Template-Type: ReDIF-Article 1.0 Author-Name: Grace Ding Author-X-Name-First: Grace Author-X-Name-Last: Ding Author-Name: Perry John Forsythe Author-X-Name-First: Perry John Author-X-Name-Last: Forsythe Title: Sustainable construction: life cycle energy analysis of construction on sloping sites for residential buildings Abstract: In 2010, the Australian residential construction sector contributed about 28% of the value of all construction and was responsible for 8% of the total energy consumption. Residential construction will continue to increase to cope with the demand due to population growth. Owing to land scarcity, construction on sloping sites has become a common construction method for residential development in Australia. This method has economic benefits but poses environmental issues as it damages topsoil, disturbs natural drainage and groundwater pathways and imposes additional stress on soil under fill. The life cycle energy consumption of the construction process is examined in relation to residential projects on sloping sites on a range of slopes and soil types in New South Wales, Australia. Forty-one detached dwellings were selected and a service life of 60 years assumed for the study. The research findings reveal that the slope for each type of soil has a positive correlation with life cycle energy consumption. As part of the onsite construction process, the results also show that the energy consumption of construction on sloping sites plays a significant factor in the life cycle energy analysis of a building. Journal: Construction Management and Economics Pages: 254-265 Issue: 3 Volume: 31 Year: 2013 Month: 3 X-DOI: 10.1080/01446193.2012.761716 File-URL: http://hdl.handle.net/10.1080/01446193.2012.761716 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:3:p:254-265 Template-Type: ReDIF-Article 1.0 Author-Name: Maartje Van Reedt Dortland Author-X-Name-First: Maartje Author-X-Name-Last: Van Reedt Dortland Author-Name: Hans Voordijk Author-X-Name-First: Hans Author-X-Name-Last: Voordijk Author-Name: Geert Dewulf Author-X-Name-First: Geert Author-X-Name-Last: Dewulf Title: Real options in project coalitions in Dutch health care: two case studies of construction projects Abstract: Uncertainties affecting health organizations inevitably influence real estate decisions since real estate is required to facilitate the primary process in cure and care. Decisions have to be taken when there is little knowledge about the future. Therefore, flexibility is needed in the process of designing, constructing and operating real estate. Real options provide an approach to gain greater insight into flexibility. The aim is to analyse whether real options can be recognized in the real estate strategies of health organizations and what real options are provided by various forms of project coalition. Two case studies reveal that real options thinking can indeed be recognized in specific real estate strategies. The choice of certain real options is partly a result of the type of project coalition applied. Further development of real options thinking in real estate management in cure and care creates opportunities to deal with future uncertainties. Journal: Construction Management and Economics Pages: 266-286 Issue: 3 Volume: 31 Year: 2013 Month: 3 X-DOI: 10.1080/01446193.2012.738921 File-URL: http://hdl.handle.net/10.1080/01446193.2012.738921 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:3:p:266-286 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Gardiner Author-X-Name-First: Paul Author-X-Name-Last: Gardiner Title: Sustainability and design ethics By Tom Russ, CRC Press, London, 2010. ISBN 978-1-43-980854-2, £39.99 (pb) Journal: Construction Management and Economics Pages: 287-288 Issue: 3 Volume: 31 Year: 2013 Month: 3 X-DOI: 10.1080/01446193.2012.757335 File-URL: http://hdl.handle.net/10.1080/01446193.2012.757335 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:3:p:287-288 Template-Type: ReDIF-Article 1.0 Author-Name: Christine R?is?nen Author-X-Name-First: Christine Author-X-Name-Last: R?is?nen Title: Culture in International Construction Wilco Tijhuis and Richard Fellows, Spon Press, London, 2011 224 pp, ISBN 978 0 415 47275 3, £65.00 (hb) Journal: Construction Management and Economics Pages: 288-291 Issue: 3 Volume: 31 Year: 2013 Month: 3 X-DOI: 10.1080/01446193.2012.737469 File-URL: http://hdl.handle.net/10.1080/01446193.2012.737469 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:3:p:288-291 Template-Type: ReDIF-Article 1.0 Author-Name: Chen-Yu Chang Author-X-Name-First: Chen-Yu Author-X-Name-Last: Chang Title:Flood Hazards Jessica Lamond, Colin Booth, Felix Hammond and David Proverbs (eds), CRC Press, London, 2011 387 pp, ISBN 978 1 4398262 5 6, £82.00 (hb) Journal: Construction Management and Economics Pages: 291-296 Issue: 3 Volume: 31 Year: 2013 Month: 3 X-DOI: 10.1080/01446193.2012.745940 File-URL: http://hdl.handle.net/10.1080/01446193.2012.745940 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:3:p:291-296 Template-Type: ReDIF-Article 1.0 Author-Name: Niels-Jørgen Aagaard Author-X-Name-First: Niels-Jørgen Author-X-Name-Last: Aagaard Title: Whole Life Costing: A New Approach Peter Caplehorn, Routledge, London, 2012 136 pp., ISBN 978 0 415 43423 2, £34.99 (pb) Journal: Construction Management and Economics Pages: 296-300 Issue: 3 Volume: 31 Year: 2013 Month: 3 X-DOI: 10.1080/01446193.2012.756140 File-URL: http://hdl.handle.net/10.1080/01446193.2012.756140 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:3:p:296-300 Template-Type: ReDIF-Article 1.0 Author-Name: Huan Yang Author-X-Name-First: Huan Author-X-Name-Last: Yang Author-Name: Weisheng Lu Author-X-Name-First: Weisheng Author-X-Name-Last: Lu Title: Niche comparisons: toward a new approach for analysing competition and organizational performance in the international construction market Abstract: Over the past few decades, studies on competition and organizational performance in the international construction market have been prolific. Construction companies are founded, then grow, compete, evolve, and die in the international landscape, a common process from an ecological perspective. However, few studies have considered the international construction market from this perspective. Using niche theory, which was initially populated in the field of natural bio-ecology and then introduced to business management and economics, a NW/O-L (niche width/overlap and location) framework is established in this study. With this framework, the niche evolution of the top 225 international contractors is explored along two dimensions—product and geography. The effects of a proper niche on an international construction company’s performance are also investigated using the cluster analysis method. It was discovered that, despite fluctuations over time, the contractor’s niche is highly related to its performance in the international construction market. The most appropriate niche for international construction contractors is a wide niche width, with a small niche overlap and with its location near to the market centre with comparatively more market resources. However, only a few contractors can survive in this niche, as the majority of contractors are in a narrow niche width, with a comparatively large niche overlap and far from the market centre. Contractors which do not fit either of these two niches have proved to be poor performers in this study. Journal: Construction Management and Economics Pages: 307-321 Issue: 4 Volume: 31 Year: 2013 Month: 4 X-DOI: 10.1080/01446193.2013.777753 File-URL: http://hdl.handle.net/10.1080/01446193.2013.777753 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:4:p:307-321 Template-Type: ReDIF-Article 1.0 Author-Name: Annika Feige Author-X-Name-First: Annika Author-X-Name-Last: Feige Author-Name: Patrick Mcallister Author-X-Name-First: Patrick Author-X-Name-Last: Mcallister Author-Name: Holger Wallbaum Author-X-Name-First: Holger Author-X-Name-Last: Wallbaum Title: Rental price and sustainability ratings: which sustainability criteria are really paying back? Abstract: Given the centrality of the price mechanism to resource allocation in market economies, the effect of sustainable construction on real estate prices has become an increasingly important empirical issue for market participants and policy makers in the real estate sector. Drawing upon a sample of approximately 2500 residential building units in Switzerland, this study assesses the effects of buildings’ sustainability on their rental prices. In contrast to the vast majority of previous studies that have focused on the price effects of eco-labels, this study investigates the effects of individual sustainability attributes. Overall, we find a positive relationship between the environmental performance of residential buildings and their rental levels. Sustainable building characteristics, especially those which enhance the water efficiency, the health and comfort level and the building’s safety and security, have significant positive price effects. It is argued that the unexpected negative relationship between energy performance and rental prices is attributed to the bundling of energy costs and rents in Swiss lease structures. Journal: Construction Management and Economics Pages: 322-334 Issue: 4 Volume: 31 Year: 2013 Month: 4 X-DOI: 10.1080/01446193.2013.769686 File-URL: http://hdl.handle.net/10.1080/01446193.2013.769686 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:4:p:322-334 Template-Type: ReDIF-Article 1.0 Author-Name: Ren-Jye Dzeng Author-X-Name-First: Ren-Jye Author-X-Name-Last: Dzeng Author-Name: Jih-Shong Wu Author-X-Name-First: Jih-Shong Author-X-Name-Last: Wu Title: Efficiency measurement of the construction industry in Taiwan: a stochastic frontier cost function approach Abstract: Construction firms require a large cash flow, thereby creating a significant financial leverage. Therefore, identifying a highly effective cost efficiency model is essential for construction firms, especially under the pressure of competition in today’s global market. This research used stochastic frontier analysis (SFA) to model and measure the cost efficiency of construction firms in Taiwan, and to investigate the relationships between input resources and cost efficiency. The main findings include: (1) subcontracting reduces labour capacity; (2) larger firms can be more cost efficient; (3) appropriate financial leverage increases cost efficiency and capital; and (4) reducing equipment costs increases cost efficiency. These findings can help construction firms to strategically adjust the management of their firm and improve cost efficiency. Journal: Construction Management and Economics Pages: 335-344 Issue: 4 Volume: 31 Year: 2013 Month: 4 X-DOI: 10.1080/01446193.2013.787162 File-URL: http://hdl.handle.net/10.1080/01446193.2013.787162 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:4:p:335-344 Template-Type: ReDIF-Article 1.0 Author-Name: Andreas Hartmann Author-X-Name-First: Andreas Author-X-Name-Last: Hartmann Author-Name: Marieke Hietbrink Author-X-Name-First: Marieke Author-X-Name-Last: Hietbrink Title: An exploratory study on the relationship between stakeholder expectations, experiences and satisfaction in road maintenance Abstract: Despite the increased attention paid by road agencies to the needs of infrastructure stakeholders, little is known about how the satisfaction or dissatisfaction of infrastructure stakeholders with the agencies’ service provision is formed. From the perspective of public agencies the relationship between expectations, experiences and satisfaction of infrastructure stakeholders affected by road maintenance is explored. Drawing upon data collected during a road maintenance project in the Netherlands it is shown that expectations only played a minor role in the formation of satisfaction. Moreover, depending on the contextual setting of the maintenance project, the importance of highway performance impacts for the formation of satisfaction through expectations and experiences changed. The results suggest that the value-in-use experience and the time dependence of expectations account for the switch in importance and the limited role of expectations. A main conclusion is that road agencies should redirect their effort from trying to determine and meet stakeholder expectations to allowing stakeholders to experience the improvements of a maintenance project. Journal: Construction Management and Economics Pages: 345-358 Issue: 4 Volume: 31 Year: 2013 Month: 4 X-DOI: 10.1080/01446193.2013.768772 File-URL: http://hdl.handle.net/10.1080/01446193.2013.768772 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:4:p:345-358 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Gruneberg Author-X-Name-First: Stephen Author-X-Name-Last: Gruneberg Author-Name: Keith Folwell Author-X-Name-First: Keith Author-X-Name-Last: Folwell Title: The use of gross fixed capital formation as a measure of construction output Abstract: There is a need to model construction industries in different countries for international construction marketing purposes and global construction and environmental policy. In the absence of a common method of construction data collection and analysis, estimates of the size of national construction industries use econometric models. One such approach relates contractors’ output to its share of gross fixed capital formation (GFCF), and uses this relationship in one economy to estimate construction output in another country. To examine the relationship between contractors’ output and GFCF a number of regressions were run. As GFCF is available for all countries, two candidate measures are evaluated as proxies for construction output, namely total GFCF and the construction element of GFCF. A strong relationship is found to exist between UK construction output and GFCF. This is significant as a validation of UK measures of construction output, although the two data series are compiled separately using different samples and some statistical variation would therefore be expected. The paper supports the use of the total construction element in GFCF as a proxy for construction output. This work therefore prepares the way for further modelling of construction output internationally using detailed construction data and GFCF. Journal: Construction Management and Economics Pages: 359-368 Issue: 4 Volume: 31 Year: 2013 Month: 4 X-DOI: 10.1080/01446193.2013.790555 File-URL: http://hdl.handle.net/10.1080/01446193.2013.790555 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:4:p:359-368 Template-Type: ReDIF-Article 1.0 Author-Name: Mehmet Nihat Hanioglu Author-X-Name-First: Mehmet Nihat Author-X-Name-Last: Hanioglu Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Title: Teaming/timing sequences in hotel development projects Abstract: Branding secures easier financing, higher rates and occupancies and repeat business in the hospitality industry. Hotel operators use architectural and interior design elements to create uniquely differentiated products for their brands. Owing to the expected benefits, hotel owners often involve brand chain hotel operators in designing their properties. However, although they are heavily involved in the design, hotel operators leave it to the owner to deal with the construction of the property and with the challenge of accomplishing the design intent while completing the project on time and within budget. The teaming/timing sequences available for a prospective hotel owner are analysed. The consequences of the timing for adding the builder to the project team in different project delivery methods are identified. Also, the best practices relative to design coordination, constructability reviews, value engineering, mock-up room reviews, price confirmation, and project handover are considered. A custom software program ‘HotPlan’ is developed to assist owners in generating conflict-free sequences of teaming/timing options and evaluating the consequences of their preferences. Comparisons of the HotPlan-generated sequences allow users to pick the alternative that most agrees with their intentions. The study is relevant to other types of projects such as residential and office buildings, airports, and hospitals where the operator of the facility may participate in the development process right from the start. Journal: Construction Management and Economics Pages: 369-385 Issue: 4 Volume: 31 Year: 2013 Month: 4 X-DOI: 10.1080/01446193.2013.778417 File-URL: http://hdl.handle.net/10.1080/01446193.2013.778417 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:4:p:369-385 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Lemer Author-X-Name-First: Andrew Author-X-Name-Last: Lemer Title: Design Innovation for the Built Environment: Research by Design and the Renovation of Practice Journal: Construction Management and Economics Pages: 386-388 Issue: 4 Volume: 31 Year: 2013 Month: 4 X-DOI: 10.1080/01446193.2012.757336 File-URL: http://hdl.handle.net/10.1080/01446193.2012.757336 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:4:p:386-388 Template-Type: ReDIF-Article 1.0 Author-Name: Paula Cardellino Author-X-Name-First: Paula Author-X-Name-Last: Cardellino Title: The Design of Learning Spaces Journal: Construction Management and Economics Pages: 388-391 Issue: 4 Volume: 31 Year: 2013 Month: 4 X-DOI: 10.1080/01446193.2012.757338 File-URL: http://hdl.handle.net/10.1080/01446193.2012.757338 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:4:p:388-391 Template-Type: ReDIF-Article 1.0 Author-Name: Kjell Tryggestad Author-X-Name-First: Kjell Author-X-Name-Last: Tryggestad Title: Sustainable Buildings and Infrastructure: Paths to the Future Journal: Construction Management and Economics Pages: 391-394 Issue: 4 Volume: 31 Year: 2013 Month: 4 X-DOI: 10.1080/01446193.2013.770893 File-URL: http://hdl.handle.net/10.1080/01446193.2013.770893 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:4:p:391-394 Template-Type: ReDIF-Article 1.0 Author-Name: Rafael Sacks Author-X-Name-First: Rafael Author-X-Name-Last: Sacks Title: Modern Construction: Lean Project Delivery and Integrated Practices Journal: Construction Management and Economics Pages: 394-396 Issue: 4 Volume: 31 Year: 2013 Month: 4 X-DOI: 10.1080/01446193.2013.763999 File-URL: http://hdl.handle.net/10.1080/01446193.2013.763999 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:4:p:394-396 Template-Type: ReDIF-Article 1.0 Author-Name: David James Bryde Author-X-Name-First: David James Author-X-Name-Last: Bryde Author-Name: Ralf Schulmeister Author-X-Name-First: Ralf Author-X-Name-Last: Schulmeister Title: Applying Lean principles to a building refurbishment project: experiences of key stakeholders Journal: Construction Management and Economics Pages: 397-397 Issue: 4 Volume: 31 Year: 2013 Month: 4 X-DOI: 10.1080/01446193.2013.789703 File-URL: http://hdl.handle.net/10.1080/01446193.2013.789703 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:4:p:397-397 Template-Type: ReDIF-Article 1.0 Author-Name: Richard Fellows Author-X-Name-First: Richard Author-X-Name-Last: Fellows Author-Name: Anita M.M. Liu Author-X-Name-First: Anita M.M. Author-X-Name-Last: Liu Title: Use and misuse of the concept of culture Abstract: Culture is an all-pervading construct of human existence but its conceptualization is contested. As such, it is problematic to define or measure culture as different paradigms adopt radically different approaches. Emic approaches are, essentially, inward-looking and, via a constructivist paradigm, assert that a culture can be investigated validly only from that culture's own perspective (idiographic). Etic approaches are concerned with an outside view, especially for cross-cultural investigations, and so tend to adopt a positivist perspective using surveys, models and dimensions (nomothetic). With increasing acceptance of varying conceptualizations, multiple methodologies and methods of research, founded on alternative philosophical stances, differing approaches to researching culture are pursued. However, several important issues of debate remain and are addressed, especially surrounding the seminal work of Geert Hofstede. Further concerns relate to levels of analyses (notably, the ecological fallacy and its reverse), scales of measurement for data collection and analysis, and their combination into indices. How people adapt to and accommodate different cultures is addressed, including structuring of organizational relationships (alliances, etc.) and the enduring debate over whether culture can be managed and the likely consequences of cultural management endeavours. Thus, the approach of positive criticism is adopted in this review of theory and literature to address the main issues in both the topic of culture and its philosophical underpinnings, and of how research methodologies and methods have been used in researching culture. Aspects of good practice and of less good practice are identified throughout to assist researchers and to stimulate further rigorous research into culture in construction. Primary findings emphasize the imperative of coherent and consistent uses of models and levels of analysis, care and rigour in use of scales and attention to the impacts of language and culture on data from respondents. Journal: Construction Management and Economics Pages: 401-422 Issue: 5 Volume: 31 Year: 2013 Month: 5 X-DOI: 10.1080/01446193.2013.794296 File-URL: http://hdl.handle.net/10.1080/01446193.2013.794296 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:5:p:401-422 Template-Type: ReDIF-Article 1.0 Author-Name: Henry A. Odeyinka Author-X-Name-First: Henry A. Author-X-Name-Last: Odeyinka Author-Name: John Lowe Author-X-Name-First: John Author-X-Name-Last: Lowe Author-Name: Ammar P. Kaka Author-X-Name-First: Ammar P. Author-X-Name-Last: Kaka Title: Artificial neural network cost flow risk assessment model Abstract: Previous attempts have been made to model cash flow forecast at the tender stage using net cash flow, value flow and cost flow approaches. Despite these efforts, significant variations between the actual and modelled forecasts were still observable. The main cause identified is the issue of risk inherent in construction. Using the cost flow approach, a model is developed to assess the impacts of risk occurring during the construction stage on the initial forecast cost flow. A questionnaire survey and case study approach were employed. As a first step, a questionnaire survey was administered to UK construction contractors to determine the significant risk factors impacting on their cost flow forecast. Using mean ranking analysis, the survey yielded 11 significant risk factors. The second stage of data collection involves the collection of forecast and actual cost flow data from case study projects to establish their variations at predetermined time periods. Using the significant risk factors identified in the first phase, relevant construction professionals who worked on the case study projects were requested to score the extent of risk occurrence that resulted in the observed variations. A combination of these two sets of data was used to model the impact of risk on cost flow forecast using an artificial neural network back propagation algorithm. The model enables a contractor to predict the likely changes to a cost flow profile due to risks occurring in the construction stage. Journal: Construction Management and Economics Pages: 423-439 Issue: 5 Volume: 31 Year: 2013 Month: 5 X-DOI: 10.1080/01446193.2013.802363 File-URL: http://hdl.handle.net/10.1080/01446193.2013.802363 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:5:p:423-439 Template-Type: ReDIF-Article 1.0 Author-Name: James Pinder Author-X-Name-First: James Author-X-Name-Last: Pinder Author-Name: Robert Schmidt III Author-X-Name-First: Robert Author-X-Name-Last: Schmidt III Author-Name: Jim Saker Author-X-Name-First: Jim Author-X-Name-Last: Saker Title: Stakeholder perspectives on developing more adaptable buildings Abstract: Despite longstanding interest in the issue of adaptability, there has been very little research into the motives and obstacles to constructing more adaptable buildings, particularly from the perspective of the stakeholders involved in the building development process. The purpose of this study was to explore the reasons why more buildings are not constructed to be more adaptable, first through a review of the literature and then through interviews with industry stakeholders in the UK, including architects, developers, engineers, property agents and local authority planners. The literature review and stakeholder interviews revealed a wide range of motives for constructing for adaptability, such as a desire to reduce life cycle costs, to produce 'future-proof' buildings, and to ensure that buildings are easier to sell and let. However, the literature and interviews also revealed many obstacles to creating more adaptable buildings, including an assumption that adaptability always costs more, a lack of life cycle costing, uncertainty about the benefits of adaptability, fragmentation between industry stakeholders and short-term development models. The research highlighted the need to develop a better understanding of the costs and benefits of developing more adaptable buildings so that industry stakeholders can make more informed decisions about their buildings under conditions of uncertainty. Journal: Construction Management and Economics Pages: 440-459 Issue: 5 Volume: 31 Year: 2013 Month: 5 X-DOI: 10.1080/01446193.2013.798007 File-URL: http://hdl.handle.net/10.1080/01446193.2013.798007 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:5:p:440-459 Template-Type: ReDIF-Article 1.0 Author-Name: Yang Miang Goh Author-X-Name-First: Yang Miang Author-X-Name-Last: Goh Author-Name: David Chua Author-X-Name-First: David Author-X-Name-Last: Chua Title: Neural network analysis of construction safety management systems: a case study in Singapore Abstract: A neural network analysis was conducted on a quantitative occupational safety and health management system (OSHMS) audit with accident data obtained from the Singapore construction industry. The analysis is meant to investigate, through a case study, how neural network methodology can be used to understand the relationship between OSHMS elements and safety performance, and identify the critical OSHMS elements that have significant influence on the occurrence and severity of accidents in Singapore. Based on the analysis, the model may be used to predict the severity of accidents with adequate accuracy. More importantly, it was identified that the three most significant OSHMS elements in the case study are: incident investigation and analysis, emergency preparedness, and group meetings. The findings imply that learning from incidents, having well-prepared consequence mitigation strategies and open communication can reduce the severity and likelihood of accidents on construction worksites in Singapore. It was also demonstrated that a neural network approach is feasible for analysing empirical OSHMS data to derive meaningful insights on how to improve safety performance. Journal: Construction Management and Economics Pages: 460-470 Issue: 5 Volume: 31 Year: 2013 Month: 5 X-DOI: 10.1080/01446193.2013.797095 File-URL: http://hdl.handle.net/10.1080/01446193.2013.797095 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:5:p:460-470 Template-Type: ReDIF-Article 1.0 Author-Name: David Espinoza Author-X-Name-First: David Author-X-Name-Last: Espinoza Author-Name: Jeremy W.F. Morris Author-X-Name-First: Jeremy W.F. Author-X-Name-Last: Morris Title: Decoupled NPV: a simple, improved method to value infrastructure investments Abstract: Despite its shortcomings, because of its simplicity, the net present value (NPV) technique (or its close relative, the internal rate of return) remains the valuation method most widely used by investors. In this method, all risks associated with a project are lumped into a single parameter (i.e. the risk premium) that is added to the risk-free interest rate to obtain a risk-adjusted discount rate; thus, in essence, the time value of money is adjusted for risk. However, because risk and time are two separate variables, accounting for risk in this manner can lead to substantial valuation errors, particularly for long-term investments which are typical for large infrastructure projects. In this paper, an alternative valuation method that decouples the time value of money from the risk associated with a project is presented. The proposed method, termed decoupled net present value (DNPV), is also simple yet flexible, consistent and robust. The method allows investors to integrate heuristic (i.e. experience based) techniques with sophisticated probabilistic and stochastic techniques to price the risk associated with the value of the asset created and/or the investment needed to create the asset. The proposed method results in a consistent valuation free from the problems typically associated with traditional net present value applications and, more importantly, allows a seamless integration of project risk assessment/management performed by technical experts into the project financial valuation. Journal: Construction Management and Economics Pages: 471-496 Issue: 5 Volume: 31 Year: 2013 Month: 5 X-DOI: 10.1080/01446193.2013.800946 File-URL: http://hdl.handle.net/10.1080/01446193.2013.800946 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:5:p:471-496 Template-Type: ReDIF-Article 1.0 Author-Name: Malcolm Horner Author-X-Name-First: Malcolm Author-X-Name-Last: Horner Title: Construction Law: An Introduction for Engineers, Architects, and Contractors Journal: Construction Management and Economics Pages: 497-497 Issue: 5 Volume: 31 Year: 2013 Month: 5 X-DOI: 10.1080/01446193.2013.763998 File-URL: http://hdl.handle.net/10.1080/01446193.2013.763998 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:5:p:497-497 Template-Type: ReDIF-Article 1.0 Author-Name: George Ofori Author-X-Name-First: George Author-X-Name-Last: Ofori Title: Conflict in Construction Journal: Construction Management and Economics Pages: 497-501 Issue: 5 Volume: 31 Year: 2013 Month: 5 X-DOI: 10.1080/01446193.2013.767465 File-URL: http://hdl.handle.net/10.1080/01446193.2013.767465 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:5:p:497-501 Template-Type: ReDIF-Article 1.0 Author-Name: Aoife M. Finneran Author-X-Name-First: Aoife M. Author-X-Name-Last: Finneran Author-Name: Alistair Gibb Author-X-Name-First: Alistair Author-X-Name-Last: Gibb Title: Construction Safety and Health Journal: Construction Management and Economics Pages: 501-502 Issue: 5 Volume: 31 Year: 2013 Month: 5 X-DOI: 10.1080/01446193.2013.770542 File-URL: http://hdl.handle.net/10.1080/01446193.2013.770542 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:5:p:501-502 Template-Type: ReDIF-Article 1.0 Author-Name: Denise Gravitt Author-X-Name-First: Denise Author-X-Name-Last: Gravitt Title: Risk and Insurance in Construction Journal: Construction Management and Economics Pages: 502-503 Issue: 5 Volume: 31 Year: 2013 Month: 5 X-DOI: 10.1080/01446193.2013.783703 File-URL: http://hdl.handle.net/10.1080/01446193.2013.783703 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:5:p:502-503 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Title: Occupational health and safety in the construction industry Journal: Construction Management and Economics Pages: 505-514 Issue: 6 Volume: 31 Year: 2013 Month: 6 X-DOI: 10.1080/01446193.2013.816435 File-URL: http://hdl.handle.net/10.1080/01446193.2013.816435 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:6:p:505-514 Template-Type: ReDIF-Article 1.0 Author-Name: Dylan Tutt Author-X-Name-First: Dylan Author-X-Name-Last: Tutt Author-Name: Sarah Pink Author-X-Name-First: Sarah Author-X-Name-Last: Pink Author-Name: Andy R.J. Dainty Author-X-Name-First: Andy R.J. Author-X-Name-Last: Dainty Author-Name: Alistair Gibb Author-X-Name-First: Alistair Author-X-Name-Last: Gibb Title: 'In the air' and below the horizon: migrant workers in UK construction and the practice-based nature of learning and communicating OHS Abstract: Local, tacit and normally unspoken OHS (occupational health and safety) knowledge and practices can too easily be excluded from or remain below the industry horizon of notice, meaning that they remain unaccounted for in formal OHS policy and practice. In this article we stress the need to more systematically and routinely tap into these otherwise 'hidden' communication channels, which are central to how everyday safe working practices are achieved. To demonstrate this approach this paper will draw on our ethnographic research with a gang of migrant curtain wall installers on a large office development project in the north of England. In doing so we reflect on the practice-based nature of learning and sharing OHS knowledge through examples of how workers' own patterns of successful communication help avoid health and safety problems. These understandings, we argue, can be advanced as a basis for the development of improved OHS measures, and of organizational knowing and learning. Journal: Construction Management and Economics Pages: 515-527 Issue: 6 Volume: 31 Year: 2013 Month: 6 X-DOI: 10.1080/01446193.2012.756145 File-URL: http://hdl.handle.net/10.1080/01446193.2012.756145 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:6:p:515-527 Template-Type: ReDIF-Article 1.0 Author-Name: Behzad Esmaeili Author-X-Name-First: Behzad Author-X-Name-Last: Esmaeili Author-Name: Matthew Hallowell Author-X-Name-First: Matthew Author-X-Name-Last: Hallowell Title: Integration of safety risk data with highway construction schedules Abstract: The construction industry is characterized by a relatively high injury and illness rate compared to other industries. Within the construction industry, the highway construction and maintenance sector is one of the most dangerous. To improve safety in this sector, proactive methods of safety improvement and reliable risk data are needed. The safety risk quantification is the first step towards integrating safety data into design and planning. To enhance the current preconstruction safety practices, safety risks of highway construction and maintenance tasks were quantified and a decision support system was developed and tested that integrates safety risk data into the project schedules. Relative safety risks were quantified for 25 common highway construction tasks using the Delphi method. To ensure valid and reliable results, experts were selected according to rigorous requirements and multiple controls were employed to decrease cognitive biases. The data were incorporated into a decision support system called Scheduled-based Safety Risk Assessment and Management (SSRAM) that facilitates integration of safety risk data with project schedules. The resulting data-driven system produces predictive plots of safety risk over time based on the temporal and spatial interactions among concurrent activities. To test the utility of the decision support system and the validity of the underlying risk data, the system was tested on 11 active case study projects in the US. It was found that the database and associated decision support tool produce accurate and reliable risk forecasts that increase the viability of existing safety preconstruction activities. Journal: Construction Management and Economics Pages: 528-541 Issue: 6 Volume: 31 Year: 2013 Month: 6 X-DOI: 10.1080/01446193.2012.739288 File-URL: http://hdl.handle.net/10.1080/01446193.2012.739288 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:6:p:528-541 Template-Type: ReDIF-Article 1.0 Author-Name: Gerard Francis Ayers Author-X-Name-First: Gerard Francis Author-X-Name-Last: Ayers Author-Name: John F. Culvenor Author-X-Name-First: John F. Author-X-Name-Last: Culvenor Author-Name: Jim Sillitoe Author-X-Name-First: Jim Author-X-Name-Last: Sillitoe Author-Name: Dennis Else Author-X-Name-First: Dennis Author-X-Name-Last: Else Title: Meaningful and effective consultation and the construction industry of Victoria, Australia Abstract: Consultation between employers and employees is mandated under Australian occupational health and safety legislation. For consultation to be considered meaningful and effective, it is generally accepted that moral and ethical principles such as trust, honesty, commitment and respect need to be recognized and applied by individuals during consultation. It is also considered that an organization's level of cultural maturity is an important element in the ability of individuals to freely engage in meaningful and effective consultation. If the value of consultation is best reflected in the degree of input and control that workers have regarding the very decisions that affect them, and if the level of worker involvement is a reflection of an organization's level of cultural maturity, it is debateable whether the notion of applying moral and ethical principles during consultation, and the adoption of the paradigm of organizational and cultural maturity, have been successfully developed and embraced in the commercial and industrial sector of the construction industry of Victoria, Australia. Journal: Construction Management and Economics Pages: 542-567 Issue: 6 Volume: 31 Year: 2013 Month: 6 X-DOI: 10.1080/01446193.2012.726366 File-URL: http://hdl.handle.net/10.1080/01446193.2012.726366 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:6:p:542-567 Template-Type: ReDIF-Article 1.0 Author-Name: Rayyan Alsamadani Author-X-Name-First: Rayyan Author-X-Name-Last: Alsamadani Author-Name: Matthew Hallowell Author-X-Name-First: Matthew Author-X-Name-Last: Hallowell Author-Name: Amy Nicole Javernick-Will Author-X-Name-First: Amy Nicole Author-X-Name-Last: Javernick-Will Title: Measuring and modelling safety communication in small work crews in the US using social network analysis Abstract: Effective safety communication between all parties in a construction project is essential for optimal safety performance. Literature suggests that open safety communication across all levels of the organization enhances safety success. Previous studies have found that open communication and frequent interaction between employees and supervisors differentiate construction companies that have low accident rates from companies that have high rates. Through interviews with construction crew members on active construction projects in the Rocky Mountain region of the US, the patterns of safety communication were identified, modelled, and quantified. Social network analysis (SNA) was utilized to obtain measures of safety communication such as centrality, density, and betweenness within small crews and to generate sociograms that visually depicted communication patterns within effective and ineffective safety networks. A cross-case comparison revealed that the frequency and method of communication are important differentiators between project teams with low and high accident rates. Specifically, top performing crews: (1) have formal safety communication from management on at least a weekly basis; (2) have informal safety communication on a weekly basis; (3) undergo formal safety training; and (4) use all proposed safety communication methods on a monthly basis. In addition, typical SNA metrics, including density, centrality and betweenness, are not significant parameters to distinguish high from low performing crews. Journal: Construction Management and Economics Pages: 568-579 Issue: 6 Volume: 31 Year: 2013 Month: 6 X-DOI: 10.1080/01446193.2012.685486 File-URL: http://hdl.handle.net/10.1080/01446193.2012.685486 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:6:p:568-579 Template-Type: ReDIF-Article 1.0 Author-Name: Michael Behm Author-X-Name-First: Michael Author-X-Name-Last: Behm Author-Name: Arthur Schneller Author-X-Name-First: Arthur Author-X-Name-Last: Schneller Title: Application of the Loughborough Construction Accident Causation model: a framework for organizational learning Abstract: In order for the construction industry to improve its poor safety performance it needs to learn from its safety mistakes and put the lessons learned to good use. Incident investigation theories and techniques vary widely in the peer-reviewed literature. The Loughborough Construction Accident Causation (ConAC) model was applied to State Department of Transportation construction accidents, and is proposed as a tool to facilitate organizational learning in the construction industry. Details of the methodology utilized are described so that it can be duplicated in research and in practice. By investigating 27 DOT construction incidents, the research demonstrates how the model can be used both in research and in practice. The model yielded 6.63 causes/factors/influences identified per incident, and correlated the causes to determine relationships. Incident causality is complex and multi-faceted. The Loughborough model facilitates a holistic view of incident causality and thus organizational learning. Journal: Construction Management and Economics Pages: 580-595 Issue: 6 Volume: 31 Year: 2013 Month: 6 X-DOI: 10.1080/01446193.2012.690884 File-URL: http://hdl.handle.net/10.1080/01446193.2012.690884 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:6:p:580-595 Template-Type: ReDIF-Article 1.0 Author-Name: Heng Li Author-X-Name-First: Heng Author-X-Name-Last: Li Author-Name: Greg Chan Author-X-Name-First: Greg Author-X-Name-Last: Chan Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Integrating real time positioning systems to improve blind lifting and loading crane operations Abstract: Mobile/tower cranes are the most essential forms of construction plant in use in the construction industry but are also the subject of several safety issues. Of these, blind lifting has been found to be one of the most hazardous of crane operations. To improve the situation, a real-time monitoring system that integrates the use of a Global Positioning System (GPS) and Radio Frequency Identification (RFID) is developed. This system aims to identify unauthorized work or entrance of personnel within a pre-defined risk zone by obtaining positioning data of both site workers and the crane. The system alerts to the presence of unauthorized workers within a risk zone-currently defined as 3m from the crane. When this happens, the system suspends the power of the crane and a warning signal is generated to the safety management team. In this way the system assists the safety management team to manage the safety of hundreds of workers simultaneously. An onsite trial with debriefing interviews is presented to illustrate and validate the system in use. Journal: Construction Management and Economics Pages: 596-605 Issue: 6 Volume: 31 Year: 2013 Month: 6 X-DOI: 10.1080/01446193.2012.756144 File-URL: http://hdl.handle.net/10.1080/01446193.2012.756144 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:6:p:596-605 Template-Type: ReDIF-Article 1.0 Author-Name: Zhipeng Zhou Author-X-Name-First: Zhipeng Author-X-Name-Last: Zhou Author-Name: Javier Irizarry Author-X-Name-First: Javier Author-X-Name-Last: Irizarry Author-Name: Qiming Li Author-X-Name-First: Qiming Author-X-Name-Last: Li Title: Applying advanced technology to improve safety management in the construction industry: a literature review Abstract: Technology application is deemed an effective way to further construction safety management. Various technologies have been adopted for construction safety, including information communication technology (ICT), sensor-based technology, 3S (GIS/GPS/RS) technology, radio frequency identification (RFID) and virtual reality. A review of previous studies in the area of technology applications for construction safety would be indispensable for the main stakeholders in this field to share innovative research findings and gain access to future research trends. A three-step method was used to obtain relevant publications (119 papers met the ultimate selection criteria) and compile a database of the findings. The results present a general review of technology application for construction safety from the aspects of number of papers published annually, publication type, publication name, country/region of distribution, research level, project phase and project type. Corresponding analysis was performed with the collected data and the radar chart was used for analysing the trend of technology application for construction safety and the trend of research topics. Five research gaps were identified in the review process. The trends and gaps can serve as motivation for researchers and practitioners to work on the next generation of studies and the development of future effective measures, which can ensure a safe construction environment. Journal: Construction Management and Economics Pages: 606-622 Issue: 6 Volume: 31 Year: 2013 Month: 6 X-DOI: 10.1080/01446193.2013.798423 File-URL: http://hdl.handle.net/10.1080/01446193.2013.798423 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:6:p:606-622 Template-Type: ReDIF-Article 1.0 Author-Name: Fred Sherratt Author-X-Name-First: Fred Author-X-Name-Last: Sherratt Author-Name: Peter Farrell Author-X-Name-First: Peter Author-X-Name-Last: Farrell Author-Name: Rod Noble Author-X-Name-First: Rod Author-X-Name-Last: Noble Title: UK construction site safety: discourses of enforcement and engagement Abstract: Developments in safety management on large UK construction sites have seen a paradigm shift from enforcement-based systems to safety-culture programmes, which seek to engage with the workforce to create fully cooperative and safety-conscious sites. Founded in social constructionism, recent research sought out the master discourses of safety on large UK construction sites through the examination of safety signage, talk around safety and safety documentation. Two of the most prominent discourses of safety on sites were found to be safety as enforcement and safety as engagement, reflecting the change in safety management strategies. These discourses were found to be interrelated in their constructions of safety, yet also varied in their associations with practice, responsibility, social interactions and the management hierarchy of the sites. These findings develop the current understanding of safety found on sites, with relation to the hierarchical structures of safety management and the discourses of enforcement and engagement in practice. The findings have significance for the safety practices of large UK contractors in developing and improving their safety-culture programmes, as well as suggesting potential new directions in the academic research of safety in construction. Journal: Construction Management and Economics Pages: 623-635 Issue: 6 Volume: 31 Year: 2013 Month: 6 X-DOI: 10.1080/01446193.2012.747689 File-URL: http://hdl.handle.net/10.1080/01446193.2012.747689 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:6:p:623-635 Template-Type: ReDIF-Article 1.0 Author-Name: Eric Daniel Marks Author-X-Name-First: Eric Daniel Author-X-Name-Last: Marks Author-Name: Jochen Teizer Author-X-Name-First: Jochen Author-X-Name-Last: Teizer Title: Method for testing proximity detection and alert technology for safe construction equipment operation Abstract: The US construction industry continues to be among the leading industries for workplace fatalities after experiencing 818 fatalities in 2009. Approximately 21% of these fatalities resulted from workers being struck by an object or piece of construction equipment. The nature of construction sites often produces hazardous conditions by requiring ground workers and heavy construction equipment to operate in close proximity. The primary objective is to present a method for testing proximity detection and alert systems. Experimental trials were designed to deploy emerging radio frequency (RF) remote sensing technology to demonstrate the ability of the test method to evaluate the capability of proximity detection and alert systems to provide alerts when heavy construction equipment and workers are in too close proximity to each other. Numerous field experiments were designed and conducted to emulate typical interactions between workers on foot and construction equipment. These devices were installed on pieces of construction equipment in an outdoor environment to evaluate the test method for proximity detection and alert systems. Experimental results show that proximity detection and alert technologies can provide alerts to equipment operators at different pre-calibrated proximity alert ranges. The results suggest that the presented testing method adequately evaluated the reliability and effectiveness of the proximity detection and alert technology in the construction environment. Journal: Construction Management and Economics Pages: 636-646 Issue: 6 Volume: 31 Year: 2013 Month: 6 X-DOI: 10.1080/01446193.2013.783705 File-URL: http://hdl.handle.net/10.1080/01446193.2013.783705 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:6:p:636-646 Template-Type: ReDIF-Article 1.0 Author-Name: Marianne Forman Author-X-Name-First: Marianne Author-X-Name-Last: Forman Title: Inertia and change: lean construction and health and safety work on construction sites Abstract: Lean construction has been articulated as a concept that can solve health and safety (H&S) problems at construction sites. The question is whether it is that simple. Lean construction and H&S work can be perceived as two different societal change programmes. The focus in this article is on how organizations implement the change programmes and what new forms of practice they stabilize as a result of the implementation process. In particular, the stabilization of new routines for coupling production planning and H&S work are investigated. Applied theories lie within the areas of change processes in organizations, H&S and construction management. The method was based on three qualitative case studies. Three major Danish contractors were involved in the investigation, and for each contractor a construction project was studied on site over a six-month period. Contractors are project-based companies and it seemed that the change programmes and the stabilized new practices that relate production planning and H&S work at construction sites were dependent on the relationship between the functional departments at the company and the construction project, the organizational location of the key actors that drive the change programmes, the 'softness' of the concepts that are implemented and the perception of H&S. Journal: Construction Management and Economics Pages: 647-660 Issue: 6 Volume: 31 Year: 2013 Month: 6 X-DOI: 10.1080/01446193.2013.765953 File-URL: http://hdl.handle.net/10.1080/01446193.2013.765953 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:6:p:647-660 Template-Type: ReDIF-Article 1.0 Author-Name: J�rgen Melzner Author-X-Name-First: J�rgen Author-X-Name-Last: Melzner Author-Name: Sijie Zhang Author-X-Name-First: Sijie Author-X-Name-Last: Zhang Author-Name: Jochen Teizer Author-X-Name-First: Jochen Author-X-Name-Last: Teizer Author-Name: Hans-Joachim Bargst�dt Author-X-Name-First: Hans-Joachim Author-X-Name-Last: Bargst�dt Title: A case study on automated safety compliance checking to assist fall protection design and planning in building information models Abstract: Worldwide occupational safety statistics show that the construction industry in many countries experiences one of the highest accident rates of all industry sectors. Falls remain a major concern as they contribute to very serious injuries or even fatalities on construction projects around the world. Since the standards and rules for protective safety equipment vary by country, the growing numbers of internationally operating companies are in need of tools that allow ubiquitous understanding and planning of safety regardless of the country where they operate. The problem is examined using a customizable automatic safety rule-checking platform for building information models. The applied rule-based checking algorithms are designed to be add-ons to existing building information modelling (BIM) software and can check models for safety hazards early in the design and planning process. Once hazards have been identified preventative safety equipment can be designed, estimated, and included in the construction schedule before construction starts. A case study implements the safety rule-checking platform on a high-rise building project. Fall protection regulations from both the USA and Germany are applied to the developed rule-checking platform. Visualization of the safety information further explains the differences in the results once country-specific safety-regulative standards are applied on the same building information model. The case study also indicates that the role of BIM in safety design and planning can effectively assist the traditional safety decision-making process for fall protection equipment. Journal: Construction Management and Economics Pages: 661-674 Issue: 6 Volume: 31 Year: 2013 Month: 6 X-DOI: 10.1080/01446193.2013.780662 File-URL: http://hdl.handle.net/10.1080/01446193.2013.780662 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:6:p:661-674 Template-Type: ReDIF-Article 1.0 Author-Name: Graeme D. Larsen Author-X-Name-First: Graeme D. Author-X-Name-Last: Larsen Author-Name: Jennifer Whyte Author-X-Name-First: Jennifer Author-X-Name-Last: Whyte Title: Safe construction through design: perspectives from the site team Abstract: How does the work of designers impact on the safety of operatives at the construction site? Safety research and policy emphasize the importance of designing for safe construction, yet the interface between design and construction is poorly understood: accidents have multiple causes making it hard to establish causal links between design choices and safety outcomes. An in-depth case study of a major station project examines how professionals on the construction site perceive and manage the safety challenges of a building design. Analyses reveal understandings that, on the project studied, design has an impact on safety because of: (1) the timing of design work, where the volume of late design changes increased the difficulty of planning safe procedures, e.g. for working at height, lifting heavy items, refurbishing and demolishing old buildings; and (2) inputs from design stakeholders with insufficient practical knowledge of construction and operation required unplanned work-arounds, e.g. to coordinate different sub-systems, provide maintenance access, and manage loads during construction. These findings suggest that safety suffers where projects are under-designed, and that alongside regulation, there is a need for robust management attention to the contractual structures, incentives, processes and tools that enable clients and designers to understand material practices of construction and operation. Journal: Construction Management and Economics Pages: 675-690 Issue: 6 Volume: 31 Year: 2013 Month: 6 X-DOI: 10.1080/01446193.2013.798424 File-URL: http://hdl.handle.net/10.1080/01446193.2013.798424 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:6:p:675-690 Template-Type: ReDIF-Article 1.0 Author-Name: Christian Koch Author-X-Name-First: Christian Author-X-Name-Last: Koch Title: From crew to country? Local and national construction safety cultures in Denmark Abstract: Accidents in construction have motivated a range of prevention methods and efforts with more or less success. Cultural explanations are of crucial importance in understanding risk at work and this contribution adds to the growing body of qualitative studies of safety culture. Symbolic interactionism is used as a conceptual ethnographic framework to include integration, differentiation, ambiguity and the multiple configuration of safety cultures. The primary case is a carpenter's crew of 28 men engaged in renovation work. The analysis reveals the overarching common integrative culture to be characterized by pride in work. This culture overlaps with four cultures named mastering, framework and rules, drawing board and plan, and ties that bind, found using the differentiation perspective. Ambiguous perceptions are found regarding possibilities for prevention and risk, which differ according to time, place and actor. This result is juxtaposed with cultures found in four other ethnographic studies from Denmark covering 10 companies. Although these studies find 25 different safety cultures, a national pattern showing a configuration of reactive and proactive safety cultures does seem prevalent. Accident prevention methods need to be more sensitive to different safety cultures, on site and in companies, but can also use national mechanisms such as training. Journal: Construction Management and Economics Pages: 691-703 Issue: 6 Volume: 31 Year: 2013 Month: 6 X-DOI: 10.1080/01446193.2013.787490 File-URL: http://hdl.handle.net/10.1080/01446193.2013.787490 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:6:p:691-703 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Title: Design Risk Management: Contribution to Health and Safety Journal: Construction Management and Economics Pages: 704-706 Issue: 6 Volume: 31 Year: 2013 Month: 6 X-DOI: 10.1080/01446193.2013.808352 File-URL: http://hdl.handle.net/10.1080/01446193.2013.808352 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:6:p:704-706 Template-Type: ReDIF-Article 1.0 Author-Name: Gonzalo Lizarralde Author-X-Name-First: Gonzalo Author-X-Name-Last: Lizarralde Author-Name: Stella Tomiyoshi Author-X-Name-First: Stella Author-X-Name-Last: Tomiyoshi Author-Name: Mario Bourgault Author-X-Name-First: Mario Author-X-Name-Last: Bourgault Author-Name: Juan Malo Author-X-Name-First: Juan Author-X-Name-Last: Malo Author-Name: Georgia Cardosi Author-X-Name-First: Georgia Author-X-Name-Last: Cardosi Title: Understanding differences in construction project governance between developed and developing countries Abstract: Whereas most experts recognize the substantial differences in the construction sector between developed and developing countries, very little is known about how and to what extent construction project governance actually differs between the two contexts. In order to shed light on these differences, a suitable definition of project governance must be adopted and identical variables must be assessed in developed and developing contexts. Three characteristics of temporary multi-organizations that conduct construction projects (used here as categories of analysis) help identify these differences: formal structuring, informal structuring, and the role and participation of stakeholders. Based on three case studies, a survey, and semi-directed interviews, significant differences are found in how power and authority are exercised (and leadership styles applied), in the use of informality and in the roles assumed by stakeholders. Although the analysis of such differences is often considered a diagnosis of problems to be 'fixed' in projects in developing countries, we believe that these differences should be read as project governance mechanisms of adaptation to different environmental conditions, and therefore key elements that need to be fully understood by professionals working in developing countries. Journal: Construction Management and Economics Pages: 711-730 Issue: 7 Volume: 31 Year: 2013 Month: 7 X-DOI: 10.1080/01446193.2013.825044 File-URL: http://hdl.handle.net/10.1080/01446193.2013.825044 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:7:p:711-730 Template-Type: ReDIF-Article 1.0 Author-Name: Bingsheng Liu Author-X-Name-First: Bingsheng Author-X-Name-Last: Liu Author-Name: Xueqing Wang Author-X-Name-First: Xueqing Author-X-Name-Last: Wang Author-Name: Yuan Chen Author-X-Name-First: Yuan Author-X-Name-Last: Chen Author-Name: Yinghua Shen Author-X-Name-First: Yinghua Author-X-Name-Last: Shen Title: Market structure of China's construction industry based on the Panzar-Rosse model Abstract: The structure-conduct-performance (SCP) paradigm posits that market structure determines market performance, and the generally low productivity of China's construction industry is a reflection of the irrationality of its market structure. Currently, the main approaches for measuring market structure can be classified as either structural approaches or non-structural approaches. Because the statistical data on structural approaches is one-sided, the indicators for the Panzar-Rosse model (a non-structural approach) for the construction industry can be selected by examining the Panzar-Rosse model and comparing the characteristics of the construction industry with those of the banking industry. The Panzar-Rosse model is employed to assess the market structure of 21 listed companies in China's construction industry during the period from 2009 to 2011. The analysis revealed that China's construction industry operates under conditions of monopolistic competition with free-entry equilibrium. The methods and results of the research are expected to contribute to the advancement of theories related to and methods of analysing the market structure of industries other than the banking industry. Journal: Construction Management and Economics Pages: 731-745 Issue: 7 Volume: 31 Year: 2013 Month: 7 X-DOI: 10.1080/01446193.2013.817679 File-URL: http://hdl.handle.net/10.1080/01446193.2013.817679 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:7:p:731-745 Template-Type: ReDIF-Article 1.0 Author-Name: Amirhosein Jafari Author-X-Name-First: Amirhosein Author-X-Name-Last: Jafari Title: A contractor pre-qualification model based on the quality function deployment method Abstract: Contractors play a significant role in construction projects and selection of the most appropriate contractor for the project is a critical decision for clients. The pre-qualification of construction contractors is accounted as a very important step in contractor selection for every project. The main purpose of pre-qualification is to identify an array of eligible contractors, which is required for post-qualification steps and further considerations. Although there have been numerous models for contractor pre-qualification, there are inadequate researches to present a contractor pre-qualification model with consideration of the project objectives or the project owner's requirements. A new contractor pre-qualification model was developed with the aim of resolving this issue. This model employs the quality function deployment (QFD) method, and considers both the project owner's requirements and the contractor's abilities. The results reveal that consideration of the project objectives or the project owner's requirements and expectations can influence contractor pre-qualification. Journal: Construction Management and Economics Pages: 746-760 Issue: 7 Volume: 31 Year: 2013 Month: 7 X-DOI: 10.1080/01446193.2013.825045 File-URL: http://hdl.handle.net/10.1080/01446193.2013.825045 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:7:p:746-760 Template-Type: ReDIF-Article 1.0 Author-Name: MD Asrul Masrom Author-X-Name-First: MD Asrul Author-X-Name-Last: Masrom Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Adrian Bridge Author-X-Name-First: Adrian Author-X-Name-Last: Bridge Title: Determinants of contractor satisfaction Abstract: Performance in the construction industry is increasingly scrutinized as a result of the delays, cost overruns and poor quality of the industry's products and services. Increasingly, disputes, conflicts and mismatches of objectives among participants are contributory factors. Performance measurement approaches have been developed to overcome these problems. However, these approaches focus primarily on objective measures to the exclusion of subjective measures, particularly those concerning contractor satisfaction (Co-S). The contractor satisfaction model (CoSMo) developed here is intended to rectify the situation. Data derived from a questionnaire survey of 75 large contractors in Malaysia in respect of a key project are analysed to identify participant factors and their strength of relationship with Co-S dimensions. The results are presented in the form of eight regression equations. The outcome is a tool for use by project participants to provide a better understanding of how they, and the project, affect contractor satisfaction. The developed model sheds some light on a hitherto unknown aspect of construction management in providing an increased awareness of the importance of major Malaysian construction contractors' needs in the execution of successful projects. Journal: Construction Management and Economics Pages: 761-779 Issue: 7 Volume: 31 Year: 2013 Month: 7 X-DOI: 10.1080/01446193.2013.814919 File-URL: http://hdl.handle.net/10.1080/01446193.2013.814919 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:7:p:761-779 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Barrett Author-X-Name-First: Peter Author-X-Name-Last: Barrett Title: Enhancing Building Performance Journal: Construction Management and Economics Pages: 780-781 Issue: 7 Volume: 31 Year: 2013 Month: 7 X-DOI: 10.1080/01446193.2013.783704 File-URL: http://hdl.handle.net/10.1080/01446193.2013.783704 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:7:p:780-781 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Allan Author-X-Name-First: Andrew Author-X-Name-Last: Allan Title: Zero-Carbon Homes: A Road Map Journal: Construction Management and Economics Pages: 782-787 Issue: 7 Volume: 31 Year: 2013 Month: 7 X-DOI: 10.1080/01446193.2013.780661 File-URL: http://hdl.handle.net/10.1080/01446193.2013.780661 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:7:p:782-787 Template-Type: ReDIF-Article 1.0 Author-Name: John M. Kamara Author-X-Name-First: John M. Author-X-Name-Last: Kamara Title: Requirements Engineering for Computer Integrated Environments in Construction Journal: Construction Management and Economics Pages: 787-789 Issue: 7 Volume: 31 Year: 2013 Month: 7 X-DOI: 10.1080/01446193.2013.787489 File-URL: http://hdl.handle.net/10.1080/01446193.2013.787489 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:7:p:787-789 Template-Type: ReDIF-Article 1.0 Author-Name: Hans Voordijk Author-X-Name-First: Hans Author-X-Name-Last: Voordijk Title: Facilities Change Management Journal: Construction Management and Economics Pages: 789-791 Issue: 7 Volume: 31 Year: 2013 Month: 7 X-DOI: 10.1080/01446193.2013.787487 File-URL: http://hdl.handle.net/10.1080/01446193.2013.787487 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:7:p:789-791 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Gardiner Author-X-Name-First: Paul Author-X-Name-Last: Gardiner Title: Moving from Project Management to Project Leadership: A Practical Guide to Leading Groups Journal: Construction Management and Economics Pages: 792-793 Issue: 7 Volume: 31 Year: 2013 Month: 7 X-DOI: 10.1080/01446193.2013.797092 File-URL: http://hdl.handle.net/10.1080/01446193.2013.797092 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:7:p:792-793 Template-Type: ReDIF-Article 1.0 Author-Name: Abigail Powell Author-X-Name-First: Abigail Author-X-Name-Last: Powell Author-Name: Katherine J. C. Sang Author-X-Name-First: Katherine J. C. Author-X-Name-Last: Sang Title: Equality, diversity and inclusion in the construction industry Journal: Construction Management and Economics Pages: 795-801 Issue: 8 Volume: 31 Year: 2013 Month: 8 X-DOI: 10.1080/01446193.2013.837263 File-URL: http://hdl.handle.net/10.1080/01446193.2013.837263 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:8:p:795-801 Template-Type: ReDIF-Article 1.0 Author-Name: Nick Rumens Author-X-Name-First: Nick Author-X-Name-Last: Rumens Title: Queering men and masculinities in construction: towards a research agenda Abstract: The topic of gender in the construction industry now commands a substantial literature given complaints about gender segregation and the dominance of men, culturally and numerically, within the sector. However, there is not enough research that problematizes men and masculinities as diverse and multiple, or investigates how gender binaries are implicated in sustaining heteronormativity within the construction scholarship, thereby marginalizing research on sexualities. The possibilities for 'queering' current research agendas are examined in regard to 'men' and 'masculinities', by introducing queer theory as a conceptual resource for disrupting and destabilizing facile notions of gender and sexuality as fixed, stable and universal. It is argued that analyses about men and masculinities in construction must take into account how men are situated in relation to formations of difference such as gender and sexuality. In so doing, concerns are expressed and new concepts and research questions are suggested with the primary aim of promoting but not prescribing further empirical research and theorizing. Journal: Construction Management and Economics Pages: 802-815 Issue: 8 Volume: 31 Year: 2013 Month: 8 X-DOI: 10.1080/01446193.2013.765021 File-URL: http://hdl.handle.net/10.1080/01446193.2013.765021 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:8:p:802-815 Template-Type: ReDIF-Article 1.0 Author-Name: Paul W. Chan Author-X-Name-First: Paul W. Author-X-Name-Last: Chan Title: Queer eye on a 'straight' life: deconstructing masculinities in construction Abstract: The male-ness or masculine nature of the construction industry has often been blamed for the problems of equality and diversity in the sector. Yet, what constitutes masculinity in construction is rarely problematized. Conventionally, masculinity in construction tended to be associated with the subordination and harassment of minority groups (e.g. women, non-heterosexuals), and the ideals of keeping fit in order to meet the tough, physical demands of construction work. Therefore an attempt was made to expand the conceptualization of alternative masculinities in construction. By deploying queer theory, the life stories of nine non-heterosexuals working in trade and professional occupations in the construction industry were analysed to explore how a range of different masculinities played out in the social interactions in their personal and working lives. The findings suggest that conventional hegemonic masculinity, while present, is not the only form of masculinity that subordinates minority groups in construction. Rather, other non-hegemonic forms of masculinity (e.g. found in homo-social contexts) also serve to exclude both men and women. Nevertheless, examples were also identified of minorities countering such exclusionary forms of masculinity through, for instance, 'friendship' alliances at work, which could offer possibilities for building a more inclusive workplace in construction. Journal: Construction Management and Economics Pages: 816-831 Issue: 8 Volume: 31 Year: 2013 Month: 8 X-DOI: 10.1080/01446193.2013.832028 File-URL: http://hdl.handle.net/10.1080/01446193.2013.832028 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:8:p:816-831 Template-Type: ReDIF-Article 1.0 Author-Name: Tessa Wright Author-X-Name-First: Tessa Author-X-Name-Last: Wright Title: Uncovering sexuality and gender: an intersectional examination of women's experience in UK construction Abstract: UK employers have been broadening their equality and diversity activities to include the issue of sexual orientation; however, the construction industry has been slow to follow. Equally there is a lack of research on the experiences of lesbian, gay, bisexual and transgender (LGBT) workers in construction. While women's sexuality soon becomes a focus of interest when they enter male-dominated work, little research has discussed how sexual minorities-and in particular lesbians-fare in such environments. This article examines how both gender and sexuality interact to shape women's working lives within the UK construction sector, drawing on 22 interviews and a focus group with heterosexual women and lesbians in male-dominated occupations in construction. While women share common experiences of heightened interest and questioning, open lesbians can sometimes minimize the sexualized content of workplace interactions. However the potential for exclusion on the basis of minority sexuality also exists. Sexual harassment appears less prevalent for women in professional occupations than in the past, while women in the manual trades reported that the problem persists. Lesbians can experience different forms of harassment, however, from heterosexual women, while employers are less developed in their response to homophobic harassment. Journal: Construction Management and Economics Pages: 832-844 Issue: 8 Volume: 31 Year: 2013 Month: 8 X-DOI: 10.1080/01446193.2013.794297 File-URL: http://hdl.handle.net/10.1080/01446193.2013.794297 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:8:p:832-844 Template-Type: ReDIF-Article 1.0 Author-Name: Teresa Marchant Author-X-Name-First: Teresa Author-X-Name-Last: Marchant Title: Keep going: career perspectives on ageing and masculinity of self-employed tradesmen in Australia Abstract: The ageing workforce has implications for skills retention and equity in construction and ageing of self-employed tradesmen. The aims here were to define older tradesmen and present their experience of ageing along with the implications for masculinity. Ageing, the ageing workforce and construction management informed this conversation about diversity and skills shortages, how tradesmen negotiate ageing, the way it is perceived and how it impacts on masculinity. A phenomenological research design, with 20, in-depth interviews from independent tradesmen was deployed. Older tradesman defined themselves by physical capacity to work, rather than chronological age. Self-initiated strategies increased longevity and consisted of work adjustments such as paying for extra labour and machines and scheduling less onerous work. If widely adopted, such accommodations for the mainstream construction workforce might shift the masculine culture of the industry for specific equity groups. There were numerous possibilities for alternative work, but many disadvantages were identified. Suggestions for the industry about retention included self-care and personalized work adjustments. Recommendations for individuals included proactively planning retirement, particularly in terms of superannuation and other non-housing investment alternatives. Journal: Construction Management and Economics Pages: 845-860 Issue: 8 Volume: 31 Year: 2013 Month: 8 X-DOI: 10.1080/01446193.2013.808353 File-URL: http://hdl.handle.net/10.1080/01446193.2013.808353 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:8:p:845-860 Template-Type: ReDIF-Article 1.0 Author-Name: Louisa Smith Author-X-Name-First: Louisa Author-X-Name-Last: Smith Title: Trading in gender for women in trades: embodying hegemonic masculinity, femininity and being a gender hotrod Abstract: The construction industry remains male dominated despite reforms in recruitment, training and some workplaces since the 1970s. That said some women do still enter the industry. The aim of this research was to explore the embodied experiences of women who work in a particular area of construction, that of manual skilled trades. Fifteen tradeswomen between the ages of 21 and 60 were interviewed using a life history framework. Unstructured and in-depth, the life history interviews covered a broad range of topics including family history, education, embodiment, sexuality and work. This method aimed to contextualize participants' experiences of work within broader relations, allowing a space for participants to discuss their labour processes beyond a conception of them as challenging. The central finding of the research was that gender was not experienced as stable or simple. Instead gender was contradictory. Some women also found that being 'outside' the expectations of masculine cultures allowed them to use their gender as a resource to work more smartly and more safely. From the experiences of women in trades, pleasure is theorized as a useful point of connection between women and between women and men in male dominated work cultures. Journal: Construction Management and Economics Pages: 861-873 Issue: 8 Volume: 31 Year: 2013 Month: 8 X-DOI: 10.1080/01446193.2013.833339 File-URL: http://hdl.handle.net/10.1080/01446193.2013.833339 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:8:p:861-873 Template-Type: ReDIF-Article 1.0 Author-Name: Valerie Caven Author-X-Name-First: Valerie Author-X-Name-Last: Caven Author-Name: Elena Navarro Astor Author-X-Name-First: Elena Navarro Author-X-Name-Last: Astor Title: The potential for gender equality in architecture: an Anglo-Spanish comparison Abstract: The practice of architecture is very similar in different national settings despite what may be very different sociological and cultural origins of the profession, the attendant variances in how work is organized and distinctions in equality and gender roles. The aim of this paper is to examine the quest for equality in architecture for women in the UK and Spain reporting the findings of a comparative study into women architects' careers in the two countries. Within the qualitative paradigm, semi-structured in-depth interviews were carried out with a total of 55 women architects in the UK and Spain. Findings indicate surprising differences in levels and terms of equality for women in the two countries and marked differences in women's experiences of working as an architect. Women have come to the profession in Spain much later than their British counterparts and, somewhat surprisingly, are present in greater numbers. However, despite there being more of a 'critical mass' this has not served to improve their situation; they report much higher levels of discrimination and find it difficult to progress in their careers. Conclusions argue for a stronger approach by the professional bodies to help improve the position of women. Journal: Construction Management and Economics Pages: 874-882 Issue: 8 Volume: 31 Year: 2013 Month: 8 X-DOI: 10.1080/01446193.2013.766358 File-URL: http://hdl.handle.net/10.1080/01446193.2013.766358 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:8:p:874-882 Template-Type: ReDIF-Article 1.0 Author-Name: Tanzina Choudhury Author-X-Name-First: Tanzina Author-X-Name-Last: Choudhury Title: Experiences of women as workers: a study of construction workers in Bangladesh Abstract: In Bangladesh, women's mobility is culturally constrained and women need to negotiate with patriarchy in order to join the male dominated labour market outside the home. A large number of men continue to be highly resistant to women's paid employment, partly because of the social norm of purdah and partly because they tend to consider it a shameful reflection on their ability as breadwinners, and hence on their masculine identity. While surmounting these constraints, women enter into full-time paid employment. However, the treatment of both men and women is not equal and this is particularly so in the construction sector. Thus, engaging in paid employment is not an easy decision to make and once women eventually join the labour force they experience mixed outcomes. It appears that paid work, on the one hand, confers on women greater economic autonomy and mobility and, on the other, exposes them to different sorts of deprivation and exploitation. In investigating these issues, the narratives of female construction workers were used to describe their experiences. Journal: Construction Management and Economics Pages: 883-898 Issue: 8 Volume: 31 Year: 2013 Month: 8 X-DOI: 10.1080/01446193.2012.756143 File-URL: http://hdl.handle.net/10.1080/01446193.2012.756143 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:8:p:883-898 Template-Type: ReDIF-Article 1.0 Author-Name: Ani Birgit Raiden Author-X-Name-First: Ani Birgit Author-X-Name-Last: Raiden Author-Name: Christine R�is�nen Author-X-Name-First: Christine Author-X-Name-Last: R�is�nen Title: Striving to achieve it all: men and work-family-life balance in Sweden and the UK Abstract: Although there is a vast literature on issues of work-life balance, most of the research is grounded on the traditional view of work-life balance as a female-oriented entitlement. So far little attention has been paid to how men balance their work-life situations, especially the 'new men' who are keen to share the family care. We contribute to filling this gap by critically examining how male academics in construction-related departments at universities in Sweden and the UK construct their relationships with family and work. Narrative analysis was applied on in-depth interviews with seven academics from each country, who were at different phases in their careers. Three core narratives emerged from the data: family connected with partner; work as key priority; and desire to pursue personal projects, all of which competed for the narrators' sparse time. The narrative that by far received most space and most storylines in all the interviews was 'work as priority', implying that in spite of gender equality policies and campaigns, work-life balance remains a female-oriented concern. Both Swedish and British men in our sample found juggling family and life most challenging. This work-family-life triad left many feeling that they had no time to do a good job in any sphere and in Sweden in particular combination pressure was intense. Curiously, despite these tensions and increasing demands for many of our respondents work remains a positive construct, possibly because of the strong conceptual identification of 'self' as an academic. Journal: Construction Management and Economics Pages: 899-913 Issue: 8 Volume: 31 Year: 2013 Month: 8 X-DOI: 10.1080/01446193.2013.802364 File-URL: http://hdl.handle.net/10.1080/01446193.2013.802364 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:8:p:899-913 Template-Type: ReDIF-Article 1.0 Author-Name: Sandra Manley Author-X-Name-First: Sandra Author-X-Name-Last: Manley Author-Name: Ann De Graft-Johnson Author-X-Name-First: Ann De Author-X-Name-Last: Graft-Johnson Title: Towards inclusion: rethinking architectural education Abstract: In 2009, concerned at the low profile of disabled architects, the Royal Institute of British Architects commissioned the University of the West of England, Bristol to undertake research into the experiences of disabled people both as students and as practitioners of architecture. The aim of the research was to assess the current situation and identify and distil best practice in encouraging and enabling disabled people to pursue an architectural career. The research method included online questionnaires and interviews with disabled people who were either studying or practising as architects. Support workers, with a variety of roles and remits in both education and practice, were interviewed to assess the level and quality of provision and to determine attitudes towards disabled people. Websites of schools of architecture and practices were analysed. Significant issues were revealed relating to the representation and participation of disabled people in architectural education and employment. In particular, the educational ethos, curriculum and delivery raised concerns, as education acts as a gatekeeper to the profession. It is concluded that architecture schools and practitioners need to be proactive in creating more inclusive cultures and approaches to design which in turn could benefit the design of the built environment. Journal: Construction Management and Economics Pages: 914-927 Issue: 8 Volume: 31 Year: 2013 Month: 8 X-DOI: 10.1080/01446193.2013.797093 File-URL: http://hdl.handle.net/10.1080/01446193.2013.797093 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:8:p:914-927 Template-Type: ReDIF-Article 1.0 Author-Name: Marcus Ormerod Author-X-Name-First: Marcus Author-X-Name-Last: Ormerod Author-Name: Rita Newton Author-X-Name-First: Rita Author-X-Name-Last: Newton Title: Construction as a career choice for young disabled people: dispelling the myths Abstract: Disabled people want to have the same opportunities and experiences as everyone else, yet owing to a number of barriers they are often excluded from meaningful employment. There are few statistics available in the UK to provide an accurate understanding of the number of disabled people within construction, and there remains a lack of research on employment, disability and construction. The perceptions of, and barriers faced by, young disabled people in considering potential employment in the construction industry were investigated. A participatory research approach was adopted which places disabled people at the heart of the research process. A mix of interviews and mini focus groups was undertaken with a total of 49 participants drawn from the North West of England. The need for inclusive approaches within the construction industry came across strongly, with participants preferring to be treated equally rather than being treated favourably. Disabled young people are unlikely to consider employment within construction without better awareness raising by industry-both employers and professional institutions-of the range and scope of opportunities available, and a dispelling of the myths that construction is for able-bodied, fit, men. Journal: Construction Management and Economics Pages: 928-938 Issue: 8 Volume: 31 Year: 2013 Month: 8 X-DOI: 10.1080/01446193.2013.777465 File-URL: http://hdl.handle.net/10.1080/01446193.2013.777465 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:8:p:928-938 Template-Type: ReDIF-Article 1.0 Author-Name: Helena Johnsson Author-X-Name-First: Helena Author-X-Name-Last: Johnsson Title: Production strategies for pre-engineering in house-building: exploring product development platforms Abstract: Construction is a trade where the dominating production strategy is engineer-to-order. House-builders can pre-engineer their design to different degrees, resulting in variations of the engineer-to-order strategy: design-to-order, adapt-to-order, and engineer-to-stock. This variation causes different settings for the use of platforms in house-building. The aim of this research is to diversify the engineer-to-order production strategy and its consequences for platform organization by studying its use in house-building. The multiple case study on four engineering/contractor firms reports the core capabilities for engineer-to-order firms: procurement and tendering, market knowledge, engineering, multi-skilled manufacturing, and coordination of sales and manufacturing. Design-to-order, adapt-to-order and engineer-to stock were shown to be production strategies in use in house-building. In design-to-order platforms parts of the platform are undefined while engineer-to-stock platforms are fully predefined. Coordination between market and manufacturing is a crucial capability when engaging in platform organization. When an engineering firm and a contractor collaborate to fulfil client needs, the coordination capability between market and manufacturing was shown to be low. The case study shows that specialized contractors who integrate the supply chain towards a specific market segment benefit fully from the platform concept, while contractors with a wider scope could focus on standardization of processes rather than products. Journal: Construction Management and Economics Pages: 941-958 Issue: 9 Volume: 31 Year: 2013 Month: 9 X-DOI: 10.1080/01446193.2013.828846 File-URL: http://hdl.handle.net/10.1080/01446193.2013.828846 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:9:p:941-958 Template-Type: ReDIF-Article 1.0 Author-Name: Yee Cheong Yong Author-X-Name-First: Yee Cheong Author-X-Name-Last: Yong Author-Name: Nur Emma Mustaffa Author-X-Name-First: Nur Emma Author-X-Name-Last: Mustaffa Title: Critical success factors for Malaysian construction projects: an empirical assessment Abstract: Although extensive research has been undertaken on the critical success factors (CSFs) for construction projects, very little of this research contains information specific to the local context. While several local studies have been conducted within a similar research boundary, variables with growing importance in the literature, the human-related factors, have yet to garner much attention. Therefore, the main objective of this study was to gain a renewed understanding of the emerging trend of CSFs considered by various stakeholders in the local industry. This was achieved through a comparative study of 48 Malaysian construction stakeholders classified into three categories, namely, developers, consultants and contractors. The Kruskal-Wallis one-way analysis of variance (ANOVA) on 46 factors suggests that the stakeholders favour a more balanced approach to CSFs. Apart from the 'hard' factors, there is a strong consistency among the perception of project stakeholders in recognizing the significance of human-related 'soft' factors. The analysis further reveals that the high scoring factors are mostly related to three major aspects: (1) project personnel; (2) commitment and communication; and (3) site management and supervision. Implementation of human-related factors will help to stimulate an atmosphere of trust among stakeholders amidst a widespread adversarial attitude in the industry. Journal: Construction Management and Economics Pages: 959-978 Issue: 9 Volume: 31 Year: 2013 Month: 9 X-DOI: 10.1080/01446193.2013.828843 File-URL: http://hdl.handle.net/10.1080/01446193.2013.828843 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:9:p:959-978 Template-Type: ReDIF-Article 1.0 Author-Name: David Arditi Author-X-Name-First: David Author-X-Name-Last: Arditi Author-Name: Pernilla Gluch Author-X-Name-First: Pernilla Author-X-Name-Last: Gluch Author-Name: Marie Holmdahl Author-X-Name-First: Marie Author-X-Name-Last: Holmdahl Title: Managerial competencies of female and male managers in the Swedish construction industry Abstract: The construction industry is one of the most male dominated industries around the world, not only when it comes to workers, but also as regards managers. Only 5% of the managers in the Swedish construction industry are women. The managerial competencies of individuals working as managers in the Swedish construction industry are researched to get a clearer understanding of the situation, and to investigate if this lack of balance between male and female managers has to do with differences in managerial competence. The management development questionnaire provided by Human Resource Development Press was sent to 143 managers in the Swedish construction industry and 112 respondents (44 women and 68 men) assessed themselves in 20 competencies, resulting in a response rate of 78%. The Mann-Whitney U test showed that female and male managers possess equal managerial competencies in 17 of the 20 competencies. Male managers rated themselves as having better managerial competency than females in two of the 20 competencies, namely 'resilience' and 'decision making'. Female managers rated themselves as having better managerial competency than males in 'sensitivity', which follows the social norm of what is expected of a woman. It was also found that both groups scored high in decision making, reflecting traditional virtues of construction managers as decisive and active. The most important result is not the differences but the many similarities between women and men working as managers in the construction industry. Thus, it is concluded that female managers are as competent as male managers in the Swedish construction industry. Journal: Construction Management and Economics Pages: 979-990 Issue: 9 Volume: 31 Year: 2013 Month: 9 X-DOI: 10.1080/01446193.2013.828845 File-URL: http://hdl.handle.net/10.1080/01446193.2013.828845 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:9:p:979-990 Template-Type: ReDIF-Article 1.0 Author-Name: Maryam Sanaei Author-X-Name-First: Maryam Author-X-Name-Last: Sanaei Author-Name: Amy Nicole Javernick-Will Author-X-Name-First: Amy Nicole Author-X-Name-Last: Javernick-Will Author-Name: Paul Chinowsky Author-X-Name-First: Paul Author-X-Name-Last: Chinowsky Title: The influence of generation on knowledge sharing connections and methods in construction and engineering organizations headquartered in the US Abstract: Four generations of employees: Traditionalists, Baby boomers, Generation X and Generation Y, are now working together in organizations. This demographic diversity can provide benefits for construction and engineering organizations, but it can also hinder knowledge sharing across organizations. Because well-distributed knowledge sharing connections (KSCs) increase knowledge sharing across the entire organization, thereby enhancing performance, managers are focusing on how to facilitate these connections. With four generations working together within organizations, managers need to ascertain how to span generational boundaries to increase organizational knowledge sharing and to (1) determine whether generational attributes of employees impact on knowledge sharing patterns; and (2) identify the most frequent knowledge sharing (KS) methods that each generation uses to share knowledge within communities of practice (CoPs) in construction and engineering companies. To address this, data were obtained from 734 employees within three CoPs in two construction and engineering organizations headquartered in the United States. Using a unit of analysis of KSCs, the generational attributes of CoP members were mapped to their existing KSCs, along with their preferences for methods to share knowledge, to analyse the influence of generation on these connections. Findings show that even though survey respondents rated generational attributes as not important for maintaining KSCs, the generational attributes of employees influenced the existence of KSCs. Moreover, results indicate that there was no difference between generations in using the most popular KS methods of personal discussion and e-mail, while significant differences were observed in the use of instant messaging and meetings for different generations. Journal: Construction Management and Economics Pages: 991-1004 Issue: 9 Volume: 31 Year: 2013 Month: 9 X-DOI: 10.1080/01446193.2013.835490 File-URL: http://hdl.handle.net/10.1080/01446193.2013.835490 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:9:p:991-1004 Template-Type: ReDIF-Article 1.0 Author-Name: Rafael Sacks Author-X-Name-First: Rafael Author-X-Name-Last: Sacks Author-Name: Amotz Perlman Author-X-Name-First: Amotz Author-X-Name-Last: Perlman Author-Name: Ronen Barak Author-X-Name-First: Ronen Author-X-Name-Last: Barak Title: Construction safety training using immersive virtual reality Abstract: Construction workers' ability to identify and assess risks is acquired through training and experience and is among the key factors that determine their behaviour and thus their safety. Yet researchers have questioned the effectiveness of conventional safety training. This research tested the hypotheses that safety training in a virtual reality (VR) construction site would be feasible and more effective, in terms of workers' learning and recall in identifying and assessing construction safety risks, than would equivalent training using conventional methods. Sixty-six subjects were provided training in construction safety and their safety knowledge was tested prior to the training, immediately afterward, and one month later. Half of the subjects received traditional classroom training with visual aids; the other half were trained using a 3D immersive VR power-wall. Significant advantage was found for VR training for stone cladding work and for cast-in-situ concrete work, but not for general site safety. VR training was more effective in terms of maintaining trainees' attention and concentration. Training with VR was more effective over time, especially in the context of cast-in-situ concrete works. Given the need for improved training and the advantages of training using VR, incorporation of VR in construction safety training is strongly recommended. Journal: Construction Management and Economics Pages: 1005-1017 Issue: 9 Volume: 31 Year: 2013 Month: 9 X-DOI: 10.1080/01446193.2013.828844 File-URL: http://hdl.handle.net/10.1080/01446193.2013.828844 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:9:p:1005-1017 Template-Type: ReDIF-Article 1.0 Author-Name: Hans Lind Author-X-Name-First: Hans Author-X-Name-Last: Lind Title: Construction Quality: Do It Right or Pay the Price Journal: Construction Management and Economics Pages: 1018-1019 Issue: 9 Volume: 31 Year: 2013 Month: 9 X-DOI: 10.1080/01446193.2013.805883 File-URL: http://hdl.handle.net/10.1080/01446193.2013.805883 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:9:p:1018-1019 Template-Type: ReDIF-Article 1.0 Author-Name: Naomi Brookes Author-X-Name-First: Naomi Author-X-Name-Last: Brookes Title: Construction Project Management Journal: Construction Management and Economics Pages: 1019-1020 Issue: 9 Volume: 31 Year: 2013 Month: 9 X-DOI: 10.1080/01446193.2013.787488 File-URL: http://hdl.handle.net/10.1080/01446193.2013.787488 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:9:p:1019-1020 Template-Type: ReDIF-Article 1.0 Author-Name: Ezekiel Chinyio Author-X-Name-First: Ezekiel Author-X-Name-Last: Chinyio Title: Project Management: Systems, Principles, and Applications Journal: Construction Management and Economics Pages: 1020-1021 Issue: 9 Volume: 31 Year: 2013 Month: 9 X-DOI: 10.1080/01446193.2013.804627 File-URL: http://hdl.handle.net/10.1080/01446193.2013.804627 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:9:p:1020-1021 Template-Type: ReDIF-Article 1.0 Author-Name: Dylan Tutt Author-X-Name-First: Dylan Author-X-Name-Last: Tutt Author-Name: Sarah Pink Author-X-Name-First: Sarah Author-X-Name-Last: Pink Author-Name: Andy R.J. Dainty Author-X-Name-First: Andy R.J. Author-X-Name-Last: Dainty Author-Name: Alistair Gibb Author-X-Name-First: Alistair Author-X-Name-Last: Gibb Title: Building networks to work: an ethnographic study of informal routes into the UK construction industry and pathways for migrant up-skilling Abstract: The UK construction industry labour market is characterized by high levels of self-employment, subcontracting, informality and flexibility. A corollary of this, and a sign of the increasing globalization of construction, has been an increasing reliance on migrant labour, particularly that from the Eastern European Accession states. Yet, little is known about how migrant workers' experiences within and outside work shape their work in the construction sector. In this context better qualitative understandings of the social and communication networks through which migrant workers gain employment, create routes through the sector and develop their role/career are needed. We draw on two examples from a short-term ethnographic study of migrant construction worker employment experiences and practices in the town of Crewe in Cheshire, UK, to demonstrate how informal networks intersect with formal elements of the sector to facilitate both recruitment and up-skilling. Such research knowledge, we argue, offers new evidence of the importance of attending to migrant workers' own experiences in the development of more transparent recruitment processes. Journal: Construction Management and Economics Pages: 1025-1037 Issue: 10 Volume: 31 Year: 2013 Month: 10 X-DOI: 10.1080/01446193.2013.834066 File-URL: http://hdl.handle.net/10.1080/01446193.2013.834066 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:10:p:1025-1037 Template-Type: ReDIF-Article 1.0 Author-Name: Scott Fernie Author-X-Name-First: Scott Author-X-Name-Last: Fernie Author-Name: Stuart Tennant Author-X-Name-First: Stuart Author-X-Name-Last: Tennant Title: The non-adoption of supply chain management Abstract: Largely taken for granted within the UK construction sector has been a view that supply chain management theory is robust, relevant and reliable. As such it has formed a substantial aspect of previous and contemporary policy and government funded research. Despite this, the general view of its development and diffusion over the last 15 years within the construction industry has been problematic. Coincidentally, prevailing debates within the supply chain management academic community point to the lack of unified theory, models of diffusion and strong connections to organization theory. Using Straussian grounded theory, iterations between data and organization theory provided a fresh perspective on the development and diffusion of supply chain management in construction. This inductive research provided contextually rich explanations for development and diffusion that explicitly connected with and drew upon robust, relevant and reliable theories of institutions, innovation diffusion, triads, quasifirms and mechanisms of organizational governance. These explanations challenge the simplistic assumption that chains and networks of organizations are holistically managed and controlled by any single organization or institution in the construction industry. The debate therefore shifts away from proselytizing supply chain management towards research that explores the rigour, relevance and reliability of supply chain management assumptions in construction. The gap between industry practice and policy is exposed and the question is posed: to what extent policy and practice do, or should, constitute a recursive relationship. Journal: Construction Management and Economics Pages: 1038-1058 Issue: 10 Volume: 31 Year: 2013 Month: 10 X-DOI: 10.1080/01446193.2013.830186 File-URL: http://hdl.handle.net/10.1080/01446193.2013.830186 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:10:p:1038-1058 Template-Type: ReDIF-Article 1.0 Author-Name: Xueqing Wang Author-X-Name-First: Xueqing Author-X-Name-Last: Wang Author-Name: Yuan Chen Author-X-Name-First: Yuan Author-X-Name-Last: Chen Author-Name: Bingsheng Liu Author-X-Name-First: Bingsheng Author-X-Name-Last: Liu Author-Name: Yinghua Shen Author-X-Name-First: Yinghua Author-X-Name-Last: Shen Author-Name: Hui Sun Author-X-Name-First: Hui Author-X-Name-Last: Sun Title: A total factor productivity measure for the construction industry and analysis of its spatial difference: a case study in China Abstract: In the context of unbalanced regional economic development in China, there are large regional differences in the development of the construction industry. These long-standing and increasing differences not only influence the total productivity of China's construction industry but also hinder effective resource distribution. Total factor productivity (TFP) is a measure of long-term economic growth and a comprehensive industry-level productivity measure. The objectives are to put forward a set of systematic methodologies for selecting a productivity index, to develop a TFP measure for the construction industry and to conduct an analysis of spatial differences. First, the input and output index system of the construction industry is established, and China's construction industry TFP is measured with the DEA-Malmquist index. Second, spatial differences in the construction industry TFP are analysed in terms of the coefficient of variation (CV) and using spatial clustering analysis. The results indicate that China's construction industry TFP has improved steadily. This improvement has been due mainly to improvements in pure technology efficiency, technological progress and scale efficiency. In the past five years, the CV of China's construction industry productivity has generally been small and has changed only slightly. China's construction industry TFP for all regions exhibits a ladder-like distribution that is different from the distribution by economic areas among the central, western and eastern regions. Journal: Construction Management and Economics Pages: 1059-1071 Issue: 10 Volume: 31 Year: 2013 Month: 10 X-DOI: 10.1080/01446193.2013.826371 File-URL: http://hdl.handle.net/10.1080/01446193.2013.826371 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:10:p:1059-1071 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Vivien Chow Author-X-Name-First: Vivien Author-X-Name-Last: Chow Author-Name: Tracie Harvison Author-X-Name-First: Tracie Author-X-Name-Last: Harvison Title: Inter-agency governance risk in managing hospital responses to extreme weather events in New South Wales, Australia: a facilities management perspective of shared situational awareness Abstract: Extreme weather is predicted to become more frequent and severe into the future. While our understanding of hospital infrastructure vulnerability to such events has advanced considerably in recent years, current approaches to healthcare facilities management treat hospitals in isolation from their surrounding governance infrastructure. However, recent research indicates that if hospital resilience is to be properly understood, health infrastructure must be managed holistically, as part of a much larger governance system of interdependent organizations. The inter-agency governance risks associated with this system are currently ignored in the facilities management literature. To explore these risks, an in-depth case study of 24 agencies in the state of New South Wales, Australia is presented. The results show that facilities managers are embedded in a highly complex and dynamic array of governance boundaries which are largely unresolved and misunderstood. A number of practical strategies are presented which could be adopted to significantly improve facilities manager's integration into this system. These include: mapping hospital dependency on other agencies to build surge capacity; resolving overlapping operational boundaries with other agencies; proactive risk reduction for critical external support infrastructure; understanding potential conflicts with the objectives external agencies in responding to an extreme weather event. Journal: Construction Management and Economics Pages: 1072-1082 Issue: 10 Volume: 31 Year: 2013 Month: 10 X-DOI: 10.1080/01446193.2013.853128 File-URL: http://hdl.handle.net/10.1080/01446193.2013.853128 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:10:p:1072-1082 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Title: Bridges: The Science and Art of the World's Most Inspiring Structures Journal: Construction Management and Economics Pages: 1083-1084 Issue: 10 Volume: 31 Year: 2013 Month: 10 X-DOI: 10.1080/01446193.2013.829238 File-URL: http://hdl.handle.net/10.1080/01446193.2013.829238 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:10:p:1083-1084 Template-Type: ReDIF-Article 1.0 Author-Name: Christian Brockmann Author-X-Name-First: Christian Author-X-Name-Last: Brockmann Title: Construction Management: New Directions Journal: Construction Management and Economics Pages: 1084-1089 Issue: 10 Volume: 31 Year: 2013 Month: 10 X-DOI: 10.1080/01446193.2013.824107 File-URL: http://hdl.handle.net/10.1080/01446193.2013.824107 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:10:p:1084-1089 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Baldwin Author-X-Name-First: Andrew Author-X-Name-Last: Baldwin Title: Managing Environmentally Sustainable Innovation: Insights from the Construction Industry Journal: Construction Management and Economics Pages: 1089-1091 Issue: 10 Volume: 31 Year: 2013 Month: 10 X-DOI: 10.1080/01446193.2013.824108 File-URL: http://hdl.handle.net/10.1080/01446193.2013.824108 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:10:p:1089-1091 Template-Type: ReDIF-Article 1.0 Author-Name: Denise Gravitt Author-X-Name-First: Denise Author-X-Name-Last: Gravitt Title: Construction Safety Journal: Construction Management and Economics Pages: 1091-1092 Issue: 10 Volume: 31 Year: 2013 Month: 10 X-DOI: 10.1080/01446193.2013.829240 File-URL: http://hdl.handle.net/10.1080/01446193.2013.829240 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:10:p:1091-1092 Template-Type: ReDIF-Article 1.0 Author-Name: Sunila Lobo Author-X-Name-First: Sunila Author-X-Name-Last: Lobo Title: Business Models for Renewable Energy in the Built Environment Journal: Construction Management and Economics Pages: 1092-1094 Issue: 10 Volume: 31 Year: 2013 Month: 10 X-DOI: 10.1080/01446193.2013.842648 File-URL: http://hdl.handle.net/10.1080/01446193.2013.842648 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:10:p:1092-1094 Template-Type: ReDIF-Article 1.0 Author-Name: Jason Santoso Author-X-Name-First: Jason Author-X-Name-Last: Santoso Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: Expatriate management in Australian multinational enterprises Abstract: Globalization, uncertain domestic markets and increasing competition are encouraging construction firms to internationalize. Although expatriates are commonly used by many construction companies to establish and manage overseas operations, there has been little research into the challenges of managing these people. Through case studies of five Australian construction firms and semi-structured interviews with 10 human resource managers and 36 expatriates, the question of how construction firms select, deploy, develop and support expatriate managers on overseas projects is explored. The results show that firms tend to adopt a highly pragmatic approach to expatriate recruitment and see the process as a logistical rather than a developmental challenge. Selection processes are often reactive, ad hoc and intuitive and based more on technical knowledge than softer behavioural skills and knowledge. Preparation for expatriate assignments is often outsourced, many expatriates feel unsupported while overseas, repatriation is poorly managed and overseas assignments are often seen as a barrier to career progression rather than an investment. These findings are at odds with contemporary research in international human resource management and are important because a major determinant of international project performance is effective human resource management. The findings also contribute to the design of better expatriate human resource management systems. Journal: Construction Management and Economics Pages: 1098-1109 Issue: 11 Volume: 31 Year: 2013 Month: 11 X-DOI: 10.1080/01446193.2013.853129 File-URL: http://hdl.handle.net/10.1080/01446193.2013.853129 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:11:p:1098-1109 Template-Type: ReDIF-Article 1.0 Author-Name: Richard Davies Author-X-Name-First: Richard Author-X-Name-Last: Davies Author-Name: Chris Harty Author-X-Name-First: Chris Author-X-Name-Last: Harty Title: Measurement and exploration of individual beliefs about the consequences of building information modelling use Abstract: Information and communication technology (ICT) is becoming increasingly important in construction although the rate of adoption is considered slow and the industry faces specific implementation challenges. Mainstream information systems research has shown that individuals' beliefs and expectations of the consequences of ICT use predict subsequent usage. We describe the development of scales to measure beliefs about the consequences of building information modelling (BIM) and their use in a survey of employees of a large construction contracting organization in the United Kingdom. Scales for performance expectancy, effort expectancy, social influence, facilitating conditions, compatibility, and attitude toward using technology were adapted from existing measures. In an analysis of responses from 762 construction employees the scales showed acceptable measurement properties. Expectations about the consequences of BIM use were broadly favourable although there is a need for more data for comparisons. The structure of the responses showed that expectations that BIM would enhance job performance were strongly related to expectations that BIM use was compatible with preferred and existing ways of working. Results also suggest that social influence is complex and may be multidimensional. Journal: Construction Management and Economics Pages: 1110-1127 Issue: 11 Volume: 31 Year: 2013 Month: 11 X-DOI: 10.1080/01446193.2013.848994 File-URL: http://hdl.handle.net/10.1080/01446193.2013.848994 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:11:p:1110-1127 Template-Type: ReDIF-Article 1.0 Author-Name: Che khairil Izam Che Ibrahim Author-X-Name-First: Che khairil Izam Author-X-Name-Last: Che Ibrahim Author-Name: Seosamh B. Costello Author-X-Name-First: Seosamh B. Author-X-Name-Last: Costello Author-Name: Suzanne Wilkinson Author-X-Name-First: Suzanne Author-X-Name-Last: Wilkinson Title: Development of a conceptual team integration performance index for alliance projects Abstract: Project alliancing, also known as collaborative contracting, is designed to foster integration practice between multidisciplinary teams involved in delivering construction projects. If continuous improvement in project alliances is to be achieved through the use of integrated teams, a means of assessing how well teams integrate and how that integration changes over time needs to be introduced. As part of a wider study to develop an assessment tool for team integration in road construction alliance projects, key indicators (KIs) are identified for measuring team integration practice. It is necessary to identify not only the relevant KIs, but also which indicators are dominant, thereby focusing the attention of owners and non-owner participants (NOPs) on those that will have the greatest impact on alliance team integration. Seventeen experienced road construction alliance practitioners participated in four rounds of a Delphi questionnaire to identify the KIs. The resulting seven team integration practice KIs were: team leadership; trust and respect; a single team focus on project objectives and key result areas (KRAs); collective understanding; commitment from project alliance board; creation of single and co-located alliance team; and free flow communication. A conceptual alliance team integration performance index (ATIPI) was then developed based on the identified KIs and their relative significance. The ATIPI takes the form of a linear additive weighting model, consisting of a measure for each of the identified KIs and a corresponding weighting coefficient, identified as part of this research. A linear additive weighting model is considered appropriate based on the lack of correlation between the KIs, thus suggesting that they can be considered as independent variables in the ATIPI. The measures for each KI will be determined as part of future research and will result in a fully working model for the ATIPI. Journal: Construction Management and Economics Pages: 1128-1143 Issue: 11 Volume: 31 Year: 2013 Month: 11 X-DOI: 10.1080/01446193.2013.854399 File-URL: http://hdl.handle.net/10.1080/01446193.2013.854399 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:11:p:1128-1143 Template-Type: ReDIF-Article 1.0 Author-Name: David Boyd Author-X-Name-First: David Author-X-Name-Last: Boyd Title: Using events to connect thinking and doing in knowledge management Abstract: Knowledge management (KM) is disputed in concept and practice. This is related to the conventional objectivist view, where knowledge is independent, generic and passive, thus disconnecting thinking about practice from doing practice. A practice-based view is presented as being applicable to construction where practitioners compose action from past experience using intuition, situation awareness, analogical thinking and dialogue. Results from Knowledge Event Management demonstrate such composition in construction events. This view develops the KM proposition from being 'to think better about practice' to one of 'supporting people to act better in practice'. Such improvement is facilitated by learning from events in practice. Events are sensitive points of deep learning, critical to the recall of learning, and effective in the communication of learning within social contexts. Events are analogues for future practice of doing as ideas are for thinking. Improvement in practice requires changing analogues and using analogues more proficiently when composing practice. Organizational improvement then takes place through individuals working collectively both through seeing the consequences of action and from sharing narratives of events in a critical manner. Objectivist knowledge can be used as part of this critical challenge. This can be facilitated and encouraged by active management. Journal: Construction Management and Economics Pages: 1144-1159 Issue: 11 Volume: 31 Year: 2013 Month: 11 X-DOI: 10.1080/01446193.2013.866260 File-URL: http://hdl.handle.net/10.1080/01446193.2013.866260 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:11:p:1144-1159 Template-Type: ReDIF-Article 1.0 Author-Name: Hans Voordijk Author-X-Name-First: Hans Author-X-Name-Last: Voordijk Title: Managing Project Supply Chains Journal: Construction Management and Economics Pages: 1160-1162 Issue: 11 Volume: 31 Year: 2013 Month: 11 X-DOI: 10.1080/01446193.2013.829239 File-URL: http://hdl.handle.net/10.1080/01446193.2013.829239 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:11:p:1160-1162 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew C. Lemer Author-X-Name-First: Andrew C. Author-X-Name-Last: Lemer Title: Architectural Theories of the Environment: Posthuman Territory Journal: Construction Management and Economics Pages: 1162-1164 Issue: 11 Volume: 31 Year: 2013 Month: 11 X-DOI: 10.1080/01446193.2013.835055 File-URL: http://hdl.handle.net/10.1080/01446193.2013.835055 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:11:p:1162-1164 Template-Type: ReDIF-Article 1.0 Author-Name: Denise Gravitt Author-X-Name-First: Denise Author-X-Name-Last: Gravitt Title: Eco-efficient Construction and Building Materials Journal: Construction Management and Economics Pages: 1164-1165 Issue: 11 Volume: 31 Year: 2013 Month: 11 X-DOI: 10.1080/01446193.2013.833665 File-URL: http://hdl.handle.net/10.1080/01446193.2013.833665 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:11:p:1164-1165 Template-Type: ReDIF-Article 1.0 Author-Name: Kristian Kreiner Author-X-Name-First: Kristian Author-X-Name-Last: Kreiner Title: Organizational Behaviour in Construction Journal: Construction Management and Economics Pages: 1165-1169 Issue: 11 Volume: 31 Year: 2013 Month: 11 X-DOI: 10.1080/01446193.2013.843785 File-URL: http://hdl.handle.net/10.1080/01446193.2013.843785 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:11:p:1165-1169 Template-Type: ReDIF-Article 1.0 Author-Name: Lars Walter Author-X-Name-First: Lars Author-X-Name-Last: Walter Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Title: The role of organizational objects in construction projects: the case of the collapse and restoration of the Tj�rn Bridge Abstract: The construction industry immutably produces built environments that directly influence the everyday lives of human beings. Nevertheless, materiality, defined as intransient physical matter socially enacted in the form of artefacts and objects as well as built constructions, is often overlooked and simply regarded as passive and inert matter. In contrast, a growing body of literature recognizes the agency of materiality and examines how materiality and agency are co-produced. When examining a spectacular event like the collapse of the Tj�rn Bridge on Sweden's west coast, it is argued that organizational objects are capable of interpellating various actors, thus enabling informed and adequate action. The concepts of the organizational object and interpellation are thus useful analytical terms when examining construction project organization, helping scholars of the construction industry and practising managers to rethink the role of materiality as something that both acts and is acted upon. Journal: Construction Management and Economics Pages: 1172-1185 Issue: 12 Volume: 31 Year: 2013 Month: 12 X-DOI: 10.1080/01446193.2013.868632 File-URL: http://hdl.handle.net/10.1080/01446193.2013.868632 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:12:p:1172-1185 Template-Type: ReDIF-Article 1.0 Author-Name: Chen-Yu Chang Author-X-Name-First: Chen-Yu Author-X-Name-Last: Chang Title: When might a project company break up? The perspective of risk-bearing capacity Abstract: Public-private partnerships (PPPs) have developed into a mainstream alternative procurement solution for the provision of public services. The aim is to explore a crucial but hitherto ignored issue in the study of PPPs: at what point a project company might break up. The project company's two-stage break-up in the National Physical Laboratory PFI project inspired this research in which a formal model is developed to demonstrate that contract break-up decisions can be plausibly explained through quasi-rent changes. This finding brings to the foreground the importance of taking into account risk-bearing capability in the design of project governance. How to achieve a level of risk-bearing capacity through the optimal use of financial, organizational and contractual means is a research area worthy of future exploration. Journal: Construction Management and Economics Pages: 1186-1198 Issue: 12 Volume: 31 Year: 2013 Month: 12 X-DOI: 10.1080/01446193.2013.868015 File-URL: http://hdl.handle.net/10.1080/01446193.2013.868015 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:12:p:1186-1198 Template-Type: ReDIF-Article 1.0 Author-Name: Xianbo Zhao Author-X-Name-First: Xianbo Author-X-Name-Last: Zhao Author-Name: Bon-Gang Hwang Author-X-Name-First: Bon-Gang Author-X-Name-Last: Hwang Author-Name: Sui Pheng Low Author-X-Name-First: Sui Pheng Author-X-Name-Last: Low Title: Critical success factors for enterprise risk management in Chinese construction companies Abstract: Construction businesses are risky ventures and enterprise risk management (ERM) has been advocated in construction companies. To ensure ERM success and the subsequent benefits, it is necessary to understand the key activities of ERM. The objectives are to identify the critical success factors (CSFs) for ERM and analyse the interrelationships among these CSFs in Chinese construction companies (CCCs). To achieve this objective, 16 CSFs were identified through a comprehensive literature review and 89 completed survey questionnaires were received. The results of the analysis show that the three most important CSFs are 'commitment of the board and senior management', 'risk identification, analysis and response' and 'objective setting'. Additionally, the three underlying CSF groupings are (1) execution and integration; (2) communication and understanding; and (3) commitment and involvement of top management. The commitment and involvement of top management positively contributed to the communication and understanding as well as the execution and integration of ERM, while the communication and understanding facilitated the execution and integration of ERM. The proposed framework indicating the key ERM practices and the inter-grouping relationships provides an in-depth understanding of ERM in CCCs, compared with the existing not so relevant ERM frameworks in various other industries. Journal: Construction Management and Economics Pages: 1199-1214 Issue: 12 Volume: 31 Year: 2013 Month: 12 X-DOI: 10.1080/01446193.2013.867521 File-URL: http://hdl.handle.net/10.1080/01446193.2013.867521 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:12:p:1199-1214 Template-Type: ReDIF-Article 1.0 Author-Name: Ole Jonny Klakegg Author-X-Name-First: Ole Jonny Author-X-Name-Last: Klakegg Title: Modern Construction Management Journal: Construction Management and Economics Pages: 1215-1217 Issue: 12 Volume: 31 Year: 2013 Month: 12 X-DOI: 10.1080/01446193.2013.867519 File-URL: http://hdl.handle.net/10.1080/01446193.2013.867519 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:12:p:1215-1217 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Gruneberg Author-X-Name-First: Stephen Author-X-Name-Last: Gruneberg Title: Construction Contract Preparation and Management: From Concept to Completion Journal: Construction Management and Economics Pages: 1217-1219 Issue: 12 Volume: 31 Year: 2013 Month: 12 X-DOI: 10.1080/01446193.2013.867520 File-URL: http://hdl.handle.net/10.1080/01446193.2013.867520 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:31:y:2013:i:12:p:1217-1219 Template-Type: ReDIF-Article 1.0 Author-Name: Brian Atkin Author-X-Name-First: Brian Author-X-Name-Last: Atkin Title: Industrialized building Journal: Construction Management and Economics Pages: 1-6 Issue: 1-2 Volume: 32 Year: 2014 Month: 2 X-DOI: 10.1080/01446193.2014.882005 File-URL: http://hdl.handle.net/10.1080/01446193.2014.882005 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:1-2:p:1-6 Template-Type: ReDIF-Article 1.0 Author-Name: Robert Ågren Author-X-Name-First: Robert Author-X-Name-Last: Ågren Author-Name: Robert D. Wing Author-X-Name-First: Robert D. Author-X-Name-Last: Wing Title: Five moments in the history of industrialized building Abstract: Industrialized building has drawn in ideas from many pioneering researchers during its decades of development; in this brief recapitulation we present some observations on selected moments in the history that have significantly shaped the approach to building construction. The first formative movement identified is prefabrication, as used by Joseph Paxton during construction of the Crystal Palace. Prefabrication inspired Frank Lloyd Wright's American System Built Homes, and enabled the development of Le Corbusier's mass production ideas in the Modern Frug�s Quarter project. Early forerunners saw connections with the automotive industry; Le Corbusier developed a house called Citrohan and Buckminster Fuller wanted to create 'houses like Fords'. From prefabrication followed the concept of building in sub-assemblies, as showcased by Walter Gropius in his T�rten estate; Konrad Wachsmann took this notion further into modularization and mass production with the creation of factory-produced panel and space frame systems. At much the same time Buckminster Fuller proposed the modular Dymaxion house, which included a functioning bathroom delivered in four pieces. In 1962 John Habraken presented ideas which led to what are now called open systems, suggesting standardized dimensions in the modularization in order to enable a wide array of choices for end-users. Even today not all the expectations of industrialized building have been realized, and it is instructive to look back at the origins of some of the fundamental concepts which form the backbone of this subject. Journal: Construction Management and Economics Pages: 7-15 Issue: 1-2 Volume: 32 Year: 2014 Month: 2 X-DOI: 10.1080/01446193.2013.825374 File-URL: http://hdl.handle.net/10.1080/01446193.2013.825374 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:1-2:p:7-15 Template-Type: ReDIF-Article 1.0 Author-Name: Tomonari Yashiro Author-X-Name-First: Tomonari Author-X-Name-Last: Yashiro Title: Conceptual framework of the evolution and transformation of the idea of the industrialization of building in Japan Abstract: Previous studies speculate on the implications of the industrialization of building (IB); however, there is no clear consensus on its definition. The implications of IB are assumed to be differentiated by its social, economic, and technological contexts. A conceptual framework is proposed to describe the implications through issues embodied in the idea of IB. Categories of issues within the framework are: prerequisites related to introducing innovative methods, manufacturing technologies, production technologies, functionality and life cycle management, organizational management, supply chain maturity, purpose and motivation, and constraints. How effectively the conceptual framework describes the evolution and transformation of the idea of IB is examined using case studies in Japan. Following on from previous research, six types of idea of IB are specified. These are: IB embodied in prefabricated houses in the 1940s, mass construction-oriented IB, component-based IB, mass customization-oriented IB, platform-oriented IB and service providing-oriented IB. A conceptual framework is offered that explains these types of idea of IB. The relevance and discontinuity of issues associated with each type of idea of IB are discussed. Similarities and differences in descriptions provided by the framework effectively illustrate the process of the evolution and transformation of the idea of IB in Japan. It is concluded that the proposed conceptual framework is an effective method for describing the idea of IB in specific contexts. Journal: Construction Management and Economics Pages: 16-39 Issue: 1-2 Volume: 32 Year: 2014 Month: 2 X-DOI: 10.1080/01446193.2013.864779 File-URL: http://hdl.handle.net/10.1080/01446193.2013.864779 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:1-2:p:16-39 Template-Type: ReDIF-Article 1.0 Author-Name: Xiaolin Zhai Author-X-Name-First: Xiaolin Author-X-Name-Last: Zhai Author-Name: Richard Reed Author-X-Name-First: Richard Author-X-Name-Last: Reed Author-Name: Anthony Mills Author-X-Name-First: Anthony Author-X-Name-Last: Mills Title: Factors impeding the offsite production of housing construction in China: an investigation of current practice Abstract: The promotion of offsite production is a possible future strategic direction for the construction industry as it provides economic, environmental and social benefits. However, in China, the uptake of offsite production, particularly in the housing sector, is relatively low and few studies have identified and examined the reasons behind this trend. This research gap is addressed and factors that inhibit the wider use of offsite production in China's housing construction industry are investigated. A questionnaire survey was carried out, examining the views of 110 construction professionals in China including developers, designers, contractors, manufacturers and suppliers. Factor analysis of 21 separate variables was undertaken which extracted six principal factors, namely: 'constructability implementation', 'social climate and attitudes', 'architectural performance', 'costing', 'supply chain' and 'preparatory stage'. The findings identify both barriers and challenges to increasing the uptake of offsite production in China. This provides a rare insight about the housing construction industry in China with possible implications for other developing countries that are seeking to identify and overcome barriers to the wider uptake of offsite production. Journal: Construction Management and Economics Pages: 40-52 Issue: 1-2 Volume: 32 Year: 2014 Month: 2 X-DOI: 10.1080/01446193.2013.787491 File-URL: http://hdl.handle.net/10.1080/01446193.2013.787491 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:1-2:p:40-52 Template-Type: ReDIF-Article 1.0 Author-Name: Henric Jonsson Author-X-Name-First: Henric Author-X-Name-Last: Jonsson Author-Name: Martin Rudberg Author-X-Name-First: Martin Author-X-Name-Last: Rudberg Title: Classification of production systems for industrialized building: a production strategy perspective Abstract: The purpose is to develop a matrix for classifying production systems for construction with various degrees of industrialization. Previous attempts to classify industrialized production systems for construction focus on dimensions such as the design process, the product technology, or the supply chain structure, but none of them acknowledge the importance of how orders are actually won in the market and that different market segments have different requirements. Using production strategy theory as a base, a matrix is developed linking market requirements, via the product offering, to the design of the production system. The matrix positions typical production systems based on their respective degrees of product standardization and volumes relative to the degree of offsite production. Similar to production systems in manufacturing, production systems for construction also deliver manufacturing outputs at different levels, indicating that the choice of production system will affect the competitiveness of the company. The applicability of the matrix is exemplified through three case illustrations of concepts for industrialized building, and these show that the matrix can be used to analyse the production systems' relative strengths and weaknesses. The matrix can also be used as a guide when developing new, or adjusting existing, production systems for industrialized building so that they will match market requirements and offer competitiveness. Journal: Construction Management and Economics Pages: 53-69 Issue: 1-2 Volume: 32 Year: 2014 Month: 2 X-DOI: 10.1080/01446193.2013.812226 File-URL: http://hdl.handle.net/10.1080/01446193.2013.812226 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:1-2:p:53-69 Template-Type: ReDIF-Article 1.0 Author-Name: Gustav Jansson Author-X-Name-First: Gustav Author-X-Name-Last: Jansson Author-Name: Helena Johnsson Author-X-Name-First: Helena Author-X-Name-Last: Johnsson Author-Name: Dan Engstr�m Author-X-Name-First: Dan Author-X-Name-Last: Engstr�m Title: Platform use in systems building Abstract: The practice of reusing processes and technical solutions leads to the formation of product platforms in house building. Product platforms originate from industries employing a make-to-order production strategy, e.g. the automotive industry. To test how the product platform concept is useful in engineer-to-order production strategies, a case study at two Swedish house-builders was made. Key factors that affect platform use in systems buildings were sought. The smaller company operates a supplier-led platform focusing on commonalities in process knowledge. There is less definition of the product itself to allow for distinctiveness in the product offer. The larger company has a decentralized business and operates a client-driven platform with fragmented standardization. Focus is put on creating commonality through defining the product and handling distinctiveness through an iterative design procedure. Product families were not in use at the case study companies. The companies transform standardized platform solutions into project uniqueness by using support methods. Four platform support methods emerged from the case studies: design planning, collaborative design, design optimization, and requirements iteration. The balance between commonality and distinctiveness in the platform is important to attend to in each house-building project. The engineer-to-order production strategy hinders the implementation of a fully parameterized platform. The product platform concept is therefore expanded with support methods to handle distinctiveness, i.e. project uniqueness. The product platform assets: components, processes, relationships and knowledge, are present also in platforms used in systems building. Journal: Construction Management and Economics Pages: 70-82 Issue: 1-2 Volume: 32 Year: 2014 Month: 2 X-DOI: 10.1080/01446193.2013.793376 File-URL: http://hdl.handle.net/10.1080/01446193.2013.793376 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:1-2:p:70-82 Template-Type: ReDIF-Article 1.0 Author-Name: Johan Larsson Author-X-Name-First: Johan Author-X-Name-Last: Larsson Author-Name: Per Erik Eriksson Author-X-Name-First: Per Erik Author-X-Name-Last: Eriksson Author-Name: Thomas Olofsson Author-X-Name-First: Thomas Author-X-Name-Last: Olofsson Author-Name: Peter Simonsson Author-X-Name-First: Peter Author-X-Name-Last: Simonsson Title: Industrialized construction in the Swedish infrastructure sector: core elements and barriers Abstract: Improving productivity and innovation is a central challenge in all industries, but particularly in construction where improvements have been slow. To meet this challenge, a recent investigation into the actions of Swedish government clients has recognized needs to improve planning during project procurement phases, increase numbers of turnkey contracts and raise industrialization of the sector. In response, the Swedish Transportation Administration has launched a research and innovation programme to foster an industrial approach and identify ways to increase the standardization of products and processes. However, increasing industrialization has been difficult to achieve in the project-based construction industry except in the process-based housing sector. Further, there has been little research on the concept of industrialized infrastructure construction and barriers to its implementation. Opinions and attitudes of clients, consultants and contractors in the infrastructure sector were investigated in relation to the core elements of industrialized construction, and the barriers hindering its development. Opportunities and obstacles related to both product and process standardization for continuous improvements and the relationships between clients and contractors are revealed. Hence, the implementation of industrialized construction requires tightly focused governance at the outset of projects and profound changes to established attitudes, norms and regulations. Journal: Construction Management and Economics Pages: 83-96 Issue: 1-2 Volume: 32 Year: 2014 Month: 2 X-DOI: 10.1080/01446193.2013.833666 File-URL: http://hdl.handle.net/10.1080/01446193.2013.833666 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:1-2:p:83-96 Template-Type: ReDIF-Article 1.0 Author-Name: Per Erik Eriksson Author-X-Name-First: Per Erik Author-X-Name-Last: Eriksson Author-Name: Stefan Olander Author-X-Name-First: Stefan Author-X-Name-Last: Olander Author-Name: Henrik Szentes Author-X-Name-First: Henrik Author-X-Name-Last: Szentes Author-Name: Kristian Widén Author-X-Name-First: Kristian Author-X-Name-Last: Widén Title: Managing short-term efficiency and long-term development through industrialized construction Abstract: There is a strong need for a productive and innovative infrastructure sector because of its monetary value and importance for the development of a sustainable society. An increased level of industrialization is often proposed as a way to improve efficiency and productivity in construction projects. In prior literature on industrialized construction, there are however neither many studies addressing more long-term aspects of innovation and sustainability nor studies within the infrastructure context. Organizational theory suggests that firms need to be ambidextrous and focus on both long-term exploration of new knowledge and technologies and short-term exploitation of current knowledge and technologies, in order to achieve sustainable development. Therefore, an investigation of how both short-term exploitative performance objectives and long-term explorative development can be addressed when implementing industrialized construction in infrastructure projects was conducted. A case study consisting of four infrastructure projects shows that the main drivers for increased industrialization are of an exploitative nature, focusing on cost savings and increased productivity through more efficient processes. The main barriers to increased industrialization are however related to both explorative and exploitative activities. Hence, by managing the identified barriers and explicitly addressing both exploitation and exploration, industrialized construction can improve both short-term efficiency and long-term innovation and sustainability. Journal: Construction Management and Economics Pages: 97-108 Issue: 1-2 Volume: 32 Year: 2014 Month: 2 X-DOI: 10.1080/01446193.2013.814920 File-URL: http://hdl.handle.net/10.1080/01446193.2013.814920 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:1-2:p:97-108 Template-Type: ReDIF-Article 1.0 Author-Name: John Henrik Meiling Author-X-Name-First: John Henrik Author-X-Name-Last: Meiling Author-Name: Marcus Sandberg Author-X-Name-First: Marcus Author-X-Name-Last: Sandberg Author-Name: Helena Johnsson Author-X-Name-First: Helena Author-X-Name-Last: Johnsson Title: A study of a plan-do-check-act method used in less industrialized activities: two cases from industrialized housebuilding Abstract: In construction projects, a large number of deviations are usually found during inspections and adjusted in a reactive manner. For projects to become proactive, root causes need to be identified and eliminated as a part of a process of continuous improvement (CI). Plan-do-check-act (PDCA) methods are part of CI and have been used with success within the manufacturing industry for decades. Research studies of PDCA in construction are less common, which could be explained by the past dominance of the project-based nature of construction compared to the process-based nature of manufacture. Industrialized construction, however, has changed this picture somewhat, and it is of interest to find out how well it works for less industrialized activities in construction. A PDCA method was tested in two cases selected from one medium-sized Swedish industrialized housebuilder, which uses a building system based on offsite manufactured modules. Empirical results are based on systematic data gathered through interviews and participant observations. Results from the two cases show that the PDCA method worked even when processes were divided into industrialized parts within a factory and non-industrial parts at the construction site although this might lead to temporary corrective actions rather than permanent process actions. Journal: Construction Management and Economics Pages: 109-125 Issue: 1-2 Volume: 32 Year: 2014 Month: 2 X-DOI: 10.1080/01446193.2013.812227 File-URL: http://hdl.handle.net/10.1080/01446193.2013.812227 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:1-2:p:109-125 Template-Type: ReDIF-Article 1.0 Author-Name: Erika Hedgren Author-X-Name-First: Erika Author-X-Name-Last: Hedgren Author-Name: Lars Stehn Author-X-Name-First: Lars Author-X-Name-Last: Stehn Title: The impact of clients' decision-making on their adoption of industrialized building Abstract: Previous research has shown that client organizations' decision-making about new-build creates individual-level and organizational-level barriers to the adoption of Swedish industrialized building (IB). However, it has been proposed that clients may overcome barriers on both levels by allowing multiple meanings and conflicting interpretations to surface and interact with their decision-making. The aim is to test this proposition. Based on the theoretical fields of decision-making and organizational information processing, a framework for analysis has been developed. In the framework, three decision-making approaches are operationalized: rational, judgments and managing multiple meanings. Data were collected using in-depth interviews with key decision-makers from four Swedish professional clients differing on when and if they adopted IB: one early-adopter, two late-adopters and one non-adopter. The empirical findings support the proposition and show a relationship between how clients manage multiple meanings in their decision-making and their adoption of IB. The research adds to the understanding of how clients may overcome barriers to the adoption of IB on both individual and organizational levels. Moreover, it increases understanding about how clients might better cope with radical changes and innovations. Journal: Construction Management and Economics Pages: 126-145 Issue: 1-2 Volume: 32 Year: 2014 Month: 2 X-DOI: 10.1080/01446193.2013.833340 File-URL: http://hdl.handle.net/10.1080/01446193.2013.833340 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:1-2:p:126-145 Template-Type: ReDIF-Article 1.0 Author-Name: Louise Bildsten Author-X-Name-First: Louise Author-X-Name-Last: Bildsten Title: Buyer-supplier relationships in industrialized building Abstract: Close collaboration is considered important; but is close collaboration for all purchases necessary to create value-in-production? In construction as well as in other industries, companies purchase a variety of items that require different amounts of attention to the relationship with suppliers. Buyer-supplier relationships are investigated in relation to how they bring value-in-production in the industrialized building sector. An adaptation of the Kraljic model is applied to the context of industrialized housebuilding in Sweden. Different relationships and different purchased items are classified with the aim of revealing patterns that may prove useful when determining purchasing strategies intended to create value-in-production. Purchasing strategies were studied through data collection at four industrialized housebuilders. Analysis of these strategies suggests that the total product offer from suppliers in terms of customization, logistics and standardization plays an important role in the choice of suppliers in order to satisfy the requirement for efficient production. Long-term relationships enable the development of a specific way of working that adds value-in-production. A new purchasing portfolio model for determining the effectiveness of purchasing strategies on the production process is thus presented, where products are classified according to value-in-production. Journal: Construction Management and Economics Pages: 146-159 Issue: 1-2 Volume: 32 Year: 2014 Month: 2 X-DOI: 10.1080/01446193.2013.812228 File-URL: http://hdl.handle.net/10.1080/01446193.2013.812228 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:1-2:p:146-159 Template-Type: ReDIF-Article 1.0 Author-Name: Robert Schmidt Author-X-Name-First: Robert Author-X-Name-Last: Schmidt Author-Name: Kasper Sanchez Vibaek Author-X-Name-First: Kasper Sanchez Author-X-Name-Last: Vibaek Author-Name: Simon Austin Author-X-Name-First: Simon Author-X-Name-Last: Austin Title: Evaluating the adaptability of an industrialized building using dependency structure matrices Abstract: A relatively neglected aspect of sustainable development is the creation of an enduring built environment that can be adapted to suit changing circumstances. This presents a significant challenge: how to evaluate a building's adaptability. The premise is introduced that adaptability is enhanced through the use of analytical tools which can provide better control of the building's system architecture that enables easier, and less costly, user-driven adaptations. More specifically it investigates what a dependency structure matrix (DSM), a square (N × N) matrix-based model that visualizes the relationships between elements within a system, can reveal about the capacity for an industrialized building to accommodate change, through clustering and impact analyses. Clustering analysis attempts to assess the system architecture on generic principles of change by organizing it into discrete modules, while the impact analysis examines propagation in 30 change scenarios by tracing dependencies within the DSM. Feasibility assessments of the scenarios are compared with the knowledge of a system expert. The results indicate the DSM analysis provided insights beyond the intuition of the system expert regarding change propagation, while the system expert's knowledge of component characteristics and overall composition of the building proved beyond the capacity of the DSM. Additional conclusions are drawn from the case study regarding DSM construction and the analytical process. Journal: Construction Management and Economics Pages: 160-182 Issue: 1-2 Volume: 32 Year: 2014 Month: 2 X-DOI: 10.1080/01446193.2013.847274 File-URL: http://hdl.handle.net/10.1080/01446193.2013.847274 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:1-2:p:160-182 Template-Type: ReDIF-Article 1.0 Author-Name: Riduan Yunus Author-X-Name-First: Riduan Author-X-Name-Last: Yunus Author-Name: Jay Yang Author-X-Name-First: Jay Author-X-Name-Last: Yang Title: Improving ecological performance of industrialized building systems in Malaysia Abstract: For construction stakeholders to fully embrace sustainability, its long-term benefits and associated risks need to be identified through holistic approaches. Consensus among key stakeholders is very important to the improvement of the ecological performance of industrialized building systems (IBS), a building construction method gaining momentum in Malaysia. A questionnaire survey examines the relative significance of 16 potentially important sustainability factors for IBS applications. To present possible solutions, semi-structured interviews solicit views from experienced IBS practitioners, representing the professions involved. Three most critical factors agreed by key stakeholders are material consumption, waste generation and waste disposal. Using SWOT analysis, the positive and negative aspects of these factors are investigated, with action plans formulated for IBS design practitioners. The SWOT analysis based guidelines have the potential to become part of IBS design briefing documents against which sustainability solutions are contemplated, selected and implemented. Existing knowledge on ecological performance issues is extended by considering the unique characteristics of IBS and identifying not only the benefits, but also the potential risks and challenges of pursuing sustainability. This is largely missing in previous research efforts. Findings to date focus on providing much-needed assistance to IBS designers, who are at the forefront of decision-making with a significant level of project influence. Ongoing work will be directed towards other project development phases and consider the inherent linkage between design decisions and subsequent sustainability deliverables in the project life cycle. Journal: Construction Management and Economics Pages: 183-195 Issue: 1-2 Volume: 32 Year: 2014 Month: 2 X-DOI: 10.1080/01446193.2013.825373 File-URL: http://hdl.handle.net/10.1080/01446193.2013.825373 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:1-2:p:183-195 Template-Type: ReDIF-Article 1.0 Author-Name: Fredrik Wikberg Author-X-Name-First: Fredrik Author-X-Name-Last: Wikberg Author-Name: Thomas Olofsson Author-X-Name-First: Thomas Author-X-Name-Last: Olofsson Author-Name: Anders Ekholm Author-X-Name-First: Anders Author-X-Name-Last: Ekholm Title: Design configuration with architectural objects: linking customer requirements with system capabilities in industrialized house-building platforms Abstract: There are two main routes for customers of industrialized house building to follow: either rigid platforms offering preconfigured products, often called 'type houses', or more flexible platforms open to customization. The problem in customization is to link customer requirements with system opportunities. In axiomatic design processes, this problem is understood as the transformation of customer requirements in the architectural view into design parameters that are supported by the system. A new method is proposed that allows requirements and constraints of an industrialized building platform to be handled fully in the architectural view through configuration with so-called architectural objects. It is based upon established theories and complies with the rationale of separating platform development from product customization. An experimental study, using standard building information modelling software, shows that a hierarchical structure of architectural objects can support both the development, as well as the configuration process, of the platform. Modularization in the architectural view is believed to be an important first step to capturing user requirements in the development of platforms for a specific market segment. It is also anticipated that if these requirements can be conceptualized as architectural objects the capabilities in different configurator solutions can be made more transparent to the customer. Journal: Construction Management and Economics Pages: 196-207 Issue: 1-2 Volume: 32 Year: 2014 Month: 2 X-DOI: 10.1080/01446193.2013.864780 File-URL: http://hdl.handle.net/10.1080/01446193.2013.864780 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:1-2:p:196-207 Template-Type: ReDIF-Article 1.0 Author-Name: Staffan Brege Author-X-Name-First: Staffan Author-X-Name-Last: Brege Author-Name: Lars Stehn Author-X-Name-First: Lars Author-X-Name-Last: Stehn Author-Name: Tomas Nord Author-X-Name-First: Tomas Author-X-Name-Last: Nord Title: Business models in industrialized building of multi-storey houses Abstract: The business model construct has been widely used during the last decade, partly because of its potential to provide a holistic view of how companies do business. A test of how prefabrication could form the basis of a construction firm's business model can lead to an understanding of the potential for the competitiveness and profitability of industrialized building. The aim is to adapt a general business model construct and use it to empirically identify the most frequently used and the most viable business model. The theoretical perspective is employed to examine how a company does business and which activities and resources are mobilized through the distinction between strategic and operational effectiveness. The multiple case studies include five major Swedish companies that produce prefabricated timber building systems and the analysis is grounded in pattern-finding. The business model construct includes: market position, offering, and operational platform. The result indicates five business model elements: prefabrication mode, role in the building process, end-user segments, system augmentation and complementary resources. Applying this construct to the five case companies revealed that one out of seven models was found to be viable in terms of both 'market share' and decision-makers' opinions. One important conclusion is to take the prefabrication mode as the starting point for business model design and then adapt the other elements to a good fit. Journal: Construction Management and Economics Pages: 208-226 Issue: 1-2 Volume: 32 Year: 2014 Month: 2 X-DOI: 10.1080/01446193.2013.840734 File-URL: http://hdl.handle.net/10.1080/01446193.2013.840734 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:1-2:p:208-226 Template-Type: ReDIF-Article 1.0 Author-Name: Beverley M. Lloyd-walker Author-X-Name-First: Beverley M. Author-X-Name-Last: Lloyd-walker Author-Name: Anthony John Mills Author-X-Name-First: Anthony John Author-X-Name-Last: Mills Author-Name: Derek H.T. Walker Author-X-Name-First: Derek H.T. Author-X-Name-Last: Walker Title: Enabling construction innovation: the role of a no-blame culture as a collaboration behavioural driver in project alliances Abstract: A no-blame culture is widely accepted as a collaboration driver yet we see surprisingly scant literature on the theoretical underpinnings for the construction and project management context. A no-blame culture in project alliances, as conducted in Australasia, promotes innovative thinking in action. Innovation is dependent upon collaboration and true collaboration is inextricably linked with behavioural drivers. Foremost of these is a culture of openness and willingness to share the pain and gain from experimentation, one that requires that collaborators be protected from the threat of being blamed and held accountable for experimental failure. The Australasian project alliance procurement form has a unique 'no-blame' behavioural contract clause that can result in the type of breakthrough thinking crucial in developing a collaborative culture where innovation can evolve through a process of trial and error. Journal: Construction Management and Economics Pages: 229-245 Issue: 3 Volume: 32 Year: 2014 Month: 3 X-DOI: 10.1080/01446193.2014.892629 File-URL: http://hdl.handle.net/10.1080/01446193.2014.892629 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:3:p:229-245 Template-Type: ReDIF-Article 1.0 Author-Name: Thayaparan Gajendran Author-X-Name-First: Thayaparan Author-X-Name-Last: Gajendran Author-Name: Graham Brewer Author-X-Name-First: Graham Author-X-Name-Last: Brewer Author-Name: Siegfried Gudergan Author-X-Name-First: Siegfried Author-X-Name-Last: Gudergan Author-Name: Shankar Sankaran Author-X-Name-First: Shankar Author-X-Name-Last: Sankaran Title: Deconstructing dynamic capabilities: the role of cognitive and organizational routines in the innovation process Abstract: A better understanding of innovation processes might lead to productivity improvements. By focusing on a specific, economically relevant sector (construction) and on a specific type of firm (small to medium-sized enterprises, SMEs), the dynamic capabilities framework is extended by clarifying the roles of cognitive and organizational routines in organizational innovation processes. Insights generated from an in-depth case study of a medium-sized construction firm reveal that dynamic capabilities might diminish the relevance of an explicit innovation focus, because such capabilities have the potential to trigger emergent, incremental innovations. Accordingly, for construction SMEs, a development, rather than research, mode of innovation appears relatively more critical, as manifested in conscious cognitive routines and functional/integrative organizational routines. Journal: Construction Management and Economics Pages: 246-261 Issue: 3 Volume: 32 Year: 2014 Month: 3 X-DOI: 10.1080/01446193.2013.845306 File-URL: http://hdl.handle.net/10.1080/01446193.2013.845306 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:3:p:246-261 Template-Type: ReDIF-Article 1.0 Author-Name: Stewart Clegg Author-X-Name-First: Stewart Author-X-Name-Last: Clegg Author-Name: Kristian Kreiner Author-X-Name-First: Kristian Author-X-Name-Last: Kreiner Title: Fixing concrete: inquiries, responsibility, power and innovation Abstract: When public matters go spectacularly wrong an official inquiry often ensues. Such an inquiry, conducted by legal and professional personnel, is an opportunity for learning that carries an obligation to attribute responsibility. The post hoc fixing of responsibility may aid or hinder learning. Learning relates to innovation in products and organizational processes but also new mental models and realty constructions. Accidents are opportunities for such learning and innovation. The philosophical concept of responsibility is first investigated, drawing on Aristotle, before analysis of a major accident that occurred on a prestigious Danish project when fixing concrete beams and its aftermath in an official inquiry. The investigation shows how the accident constituted a watershed, substituting a logic of performativity with a logic of compliance made possible by re-invoking an old model of reality implicitly experimented with on site. Thus, while accidents offer opportunities for innovation, this case shows that they also harbour an obligation to nullify informal and incremental innovations in understanding construction. Journal: Construction Management and Economics Pages: 262-278 Issue: 3 Volume: 32 Year: 2014 Month: 3 X-DOI: 10.1080/01446193.2013.848996 File-URL: http://hdl.handle.net/10.1080/01446193.2013.848996 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:3:p:262-278 Template-Type: ReDIF-Article 1.0 Author-Name: Sa�d Boukendour Author-X-Name-First: Sa�d Author-X-Name-Last: Boukendour Author-Name: Will Hughes Author-X-Name-First: Will Author-X-Name-Last: Hughes Title: Collaborative incentive contracts: stimulating competitive behaviour without competition Abstract: One of the major and recurring problems in designing cost incentive contracts is related to setting target cost and a risk-sharing ratio. With the standard sharing formula, contractors or alliance partners are incentivized to artificially inflate their target cost in order to maximize profit and minimize risk. Knowing that, owners attempt to pressure contractors by using various mechanisms, which are time-consuming and may jeopardize collaborative relationships afterwards. A fair risk-sharing formula is suggested that incentivizes the contractors or alliance partners to truthfully submit their target cost. The main tangible benefit is in removing suspicion and fostering trust and collaborative relationships between the contracting parties. Journal: Construction Management and Economics Pages: 279-289 Issue: 3 Volume: 32 Year: 2014 Month: 3 X-DOI: 10.1080/01446193.2013.875215 File-URL: http://hdl.handle.net/10.1080/01446193.2013.875215 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:3:p:279-289 Template-Type: ReDIF-Article 1.0 Author-Name: Philip J. Davies Author-X-Name-First: Philip J. Author-X-Name-Last: Davies Author-Name: Stephen Emmitt Author-X-Name-First: Stephen Author-X-Name-Last: Emmitt Author-Name: Steven K. Firth Author-X-Name-First: Steven K. Author-X-Name-Last: Firth Title: Challenges for capturing and assessing initial embodied energy: a contractor's perspective Abstract: Initial embodied energy includes energy use during material, transportation, and construction life cycle phases up to project practical completion. Contractors have an important role to play in reducing initial embodied energy levels due to their significant involvement in preconstruction and onsite construction activities. Following an extensive literature review a comprehensive framework was designed to highlight the significance of initial embodied energy levels relative to specific construction packages, activities and subcontractors. This framework was then applied to a new UK industrial warehouse project using a case study approach. Capturing information from a live project during the entire construction phase helped highlight the practical challenges inherent when capturing and assessing initial embodied energy levels. A series of contractor current practices was reviewed to determine their compliance with the framework requirements. The findings revealed that the ground and upper floor, external slab and frame were the most significant construction packages in terms of embodied impacts. Many challenges embedded within the contractor's current practices in terms of data detail, legibility, and terminology were also revealed. The framework provides a practical approach for initial embodied energy assessment which can readily be adopted by contractors to help highlight opportunities to increase efficiency. Journal: Construction Management and Economics Pages: 290-308 Issue: 3 Volume: 32 Year: 2014 Month: 3 X-DOI: 10.1080/01446193.2014.884280 File-URL: http://hdl.handle.net/10.1080/01446193.2014.884280 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:3:p:290-308 Template-Type: ReDIF-Article 1.0 Author-Name: Chen-Yu Chang Author-X-Name-First: Chen-Yu Author-X-Name-Last: Chang Title: The Handbook of Organizational Economics Journal: Construction Management and Economics Pages: 309-313 Issue: 3 Volume: 32 Year: 2014 Month: 3 X-DOI: 10.1080/01446193.2013.872281 File-URL: http://hdl.handle.net/10.1080/01446193.2013.872281 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:3:p:309-313 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Allan Author-X-Name-First: Andrew Author-X-Name-Last: Allan Title: Sustainability and the Design of Transport Interchanges Journal: Construction Management and Economics Pages: 313-319 Issue: 3 Volume: 32 Year: 2014 Month: 3 X-DOI: 10.1080/01446193.2013.877149 File-URL: http://hdl.handle.net/10.1080/01446193.2013.877149 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:3:p:313-319 Template-Type: ReDIF-Article 1.0 Author-Name: Arshad Ali Javed Author-X-Name-First: Arshad Ali Author-X-Name-Last: Javed Author-Name: Patrick T.I. Lam Author-X-Name-First: Patrick T.I. Author-X-Name-Last: Lam Author-Name: Albert P.C. Chan Author-X-Name-First: Albert P.C. Author-X-Name-Last: Chan Title: Change negotiation in public-private partnership projects through output specifications: an experimental approach based on game theory Abstract: Public-private partnership (PPP) projects specify outputs rather than inputs. While changes are inevitable over long concession periods, output specifications should facilitate the negotiation of foreseeable changes. An experimental approach based on game theory was adopted to evaluate the effectiveness of different strategies for negotiating changes. A multi-stage bargaining process using the 'z-Tree' software was designed to simulate four change scenarios with three output specification versions encompassing different change management strategies in a computer laboratory. Under each change scenario, pairs of public and private participants negotiated on the sharing of additional costs incurred by changes in the life cycles of fictitious PPP projects based on the different versions of output specification. The time taken to reach settlement or negotiation breakdown was recorded together with the cost-sharing pattern, with feedback collected from the participants on the effectiveness of the specification strategies immediately after the experiment. It was found that a detailed and clear output specification incorporating a cost-sharing framework facilitates change negotiations. Although the first-mover advantage was recorded, the gaps were narrowed in the multi-stage bargains. A similar controlled experiment was conducted with university students for comparison. Findings should lead to improvements in output specifications for change negotiation of PPP projects. Journal: Construction Management and Economics Pages: 323-348 Issue: 4 Volume: 32 Year: 2014 Month: 4 X-DOI: 10.1080/01446193.2014.895846 File-URL: http://hdl.handle.net/10.1080/01446193.2014.895846 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:4:p:323-348 Template-Type: ReDIF-Article 1.0 Author-Name: Athena Roumboutsos Author-X-Name-First: Athena Author-X-Name-Last: Roumboutsos Author-Name: St�phane Saussier Author-X-Name-First: St�phane Author-X-Name-Last: Saussier Title: Public-private partnerships and investments in innovation: the influence of the contractual arrangement Abstract: Public-private partnership (PPP) policy strategies emphasize the ability of PPPs to foster innovation. Evidence reported in literature supports less the inherent quality of PPPs for innovation and more the importance of contributing factors. The contractual agreement is the setting of these factors. In this context, an analytical model based on behavioural economics is presented, with boundary conditions reflecting various contractual configurations. The analysis indicates why, from a purely economic point of view, the private party in a PPP arrangement has an incentive to invest in low risk incremental innovations, which impact on, and positively effect, cost savings during construction and operation. It is also identified that further innovations are hampered by the ability to produce verifiable improvements correlated to performance. Findings contribute to the subject of public procurement for innovation in PPPs and support public authorities regarding the rationale, potential and necessary framework conditions for the use of public procurement as an innovation policy tool. Journal: Construction Management and Economics Pages: 349-361 Issue: 4 Volume: 32 Year: 2014 Month: 4 X-DOI: 10.1080/01446193.2014.895849 File-URL: http://hdl.handle.net/10.1080/01446193.2014.895849 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:4:p:349-361 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Author-Name: Yvette Allen Author-X-Name-First: Yvette Author-X-Name-Last: Allen Author-Name: Peter Edwards Author-X-Name-First: Peter Author-X-Name-Last: Edwards Author-Name: Keith Cattell Author-X-Name-First: Keith Author-X-Name-Last: Cattell Author-Name: Leickness Simbayi Author-X-Name-First: Leickness Author-X-Name-Last: Simbayi Title: Guidelines for effective workplace HIV/AIDS intervention management by construction firms Abstract: Construction firms have an important role in combating HIV/AIDS in the South African construction industry. The HIV/AIDS intervention management practices of 12 construction firms in Cape Town are examined through interviews and documents. From thematic analysis, five themes emerged: construction firms' perceptions of HIV/AIDS as a threat to the firm; construction firm interventions; barriers to the success of interventions; the role of service providers; and state-led interventions. A tension exists in managing HIV/AIDS interventions as firms are concerned with productivity and profit maximization, but are becoming more engaged with corporate social responsibility and a higher duty of care towards employees. Interventions should extend beyond awareness and prevention campaigns to include testing and treatment programmes. A guideline checklist for such interventions is proposed. Partnering with specialized service providers is recommended, as well as engaging closely with public sector services. Firms successfully managing their HIV/AIDS response should share their experience with others struggling to respond. Employee issues of stigma and reluctance to disclose need to be addressed. Attention should be paid to the employment structure of the construction industry and to the needs of the informal sector. Journal: Construction Management and Economics Pages: 362-381 Issue: 4 Volume: 32 Year: 2014 Month: 4 X-DOI: 10.1080/01446193.2014.883080 File-URL: http://hdl.handle.net/10.1080/01446193.2014.883080 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:4:p:362-381 Template-Type: ReDIF-Article 1.0 Author-Name: Ruqaya Al-Sabah Author-X-Name-First: Ruqaya Author-X-Name-Last: Al-Sabah Author-Name: Carol C. Menassa Author-X-Name-First: Carol C. Author-X-Name-Last: Menassa Author-Name: Awad Hanna Author-X-Name-First: Awad Author-X-Name-Last: Hanna Title: Evaluating impact of construction risks in the Arabian Gulf Region from perspective of multinational architecture, engineering and construction firms Abstract: Although multinational firms use risk mitigation measures when venturing into new international markets, there has been little research into identifying and evaluating the impact of these risks on project and multinational firm performance in the Arabian Gulf Region (AGR). Risks encountered in the AGR are identified through a data collection process from multinational architecture, engineering and construction (AEC) companies with work experience in the AGR. The impact of these risks on four performance metrics (i.e. project cost, schedule and performance; and company performance) is then evaluated using relative importance index (RII), significance score (SS) and principal component analysis (PCA) for validation. The results indicate that multinational firms are potentially exposed to a total of 27 external risks and 47 internal risks. Of the 27 external risks, war threat, political instability, price inflation, resources availability and quality, authorities and regulations requirements, and inclement climate have the most significant impact on the four performance metrics. Of the 47 internal risks, defective late design documents, constructive changes and insufficient scope definition have the most significant impact on the four performance metrics. These findings can guide multinational AEC firms in the AGR in establishing effective risk mitigation plans. Journal: Construction Management and Economics Pages: 382-402 Issue: 4 Volume: 32 Year: 2014 Month: 4 X-DOI: 10.1080/01446193.2014.884281 File-URL: http://hdl.handle.net/10.1080/01446193.2014.884281 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:4:p:382-402 Template-Type: ReDIF-Article 1.0 Author-Name: Nunzia Carbonara Author-X-Name-First: Nunzia Author-X-Name-Last: Carbonara Author-Name: Nicola Costantino Author-X-Name-First: Nicola Author-X-Name-Last: Costantino Author-Name: Roberta Pellegrino Author-X-Name-First: Roberta Author-X-Name-Last: Pellegrino Title: Revenue guarantee in public-private partnerships: a fair risk allocation model Abstract: Public-private partnerships (PPPs) are adopted throughout the world for delivering public infrastructure. Despite the attractiveness of the PPP structure, its implementation has not been without trouble due to multiple uncertainties embedded with PPP projects. Private investors often require some mitigation of these risks through government support. One of the most common forms of government support is minimum revenue guarantee (MRG). A real option-based model is developed that uses a new mechanism for setting the revenue guarantee level secured by the government, which balances the private sector's profitability needs and the public sector's fiscal management interests and uses the concept of fairness for structuring MRGs. The model uses Monte Carlo simulation to take into account the uncertainty. The model is applied to the projected 1 kilometre long 'Camionale di Bari' toll road that will link the port of Bari (located in Puglia, Southern Italy) with the existing road network without affecting the urban traffic. It was found that government support is often needed to make the project attractive to private investors and that the developed model can be, for both public and private sectors, a valid tool for defining the fair value of the minimum amount of revenue secured by the government. Journal: Construction Management and Economics Pages: 403-415 Issue: 4 Volume: 32 Year: 2014 Month: 4 X-DOI: 10.1080/01446193.2014.906638 File-URL: http://hdl.handle.net/10.1080/01446193.2014.906638 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:4:p:403-415 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Pichura Author-X-Name-First: Alexander Author-X-Name-Last: Pichura Title: Project Management for Facility Constructions: A Guide for Engineers and Architects Journal: Construction Management and Economics Pages: 416-416 Issue: 4 Volume: 32 Year: 2014 Month: 4 X-DOI: 10.1080/01446193.2014.897735 File-URL: http://hdl.handle.net/10.1080/01446193.2014.897735 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:4:p:416-416 Template-Type: ReDIF-Article 1.0 Author-Name: Mattias Jacobsson Author-X-Name-First: Mattias Author-X-Name-Last: Jacobsson Author-Name: Philip Roth Author-X-Name-First: Philip Author-X-Name-Last: Roth Title: Towards a shift in mindset: partnering projects as engagement platforms Abstract: The last decade has seen shifts in both practice and research regarding client-supplier relationships. Cooperative project client-supplier relationships have become increasingly common, and have spurred a stream of vivid research on for example alliances and partnering. Despite increased attention, an insufficient understanding of the relationship dimension is identified, described as a 'black box'. Here it is suggested that a key to unlock this 'black box' is to focus on the everyday practice and the role of the mindset of involved actors throughout the project. We argue that running partnering projects involves more deeply rooted changes than previously recognized. Changes relate to the mindset among involved actors, where service (instead of merely products or production) becomes the core denominator. First we aim to illustrate that a partnering project, if well functioning, can be understood as an engagement platform, and second we aim to discuss the consequences if this is acknowledged in practice. The case, a successful Swedish partnering project, is explored from a service-dominant logic perspective and it is suggested that successful partnering projects are to be defined as engagement platforms. A refined categorization of the components of partnering is provided and the implications of a shift in mindset discussed. Journal: Construction Management and Economics Pages: 419-432 Issue: 5 Volume: 32 Year: 2014 Month: 5 X-DOI: 10.1080/01446193.2014.895847 File-URL: http://hdl.handle.net/10.1080/01446193.2014.895847 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:5:p:419-432 Template-Type: ReDIF-Article 1.0 Author-Name: Tarek Hegazy Author-X-Name-First: Tarek Author-X-Name-Last: Hegazy Author-Name: Dina A. Saad Author-X-Name-First: Dina A. Author-X-Name-Last: Saad Title: A microeconomic perspective on infrastructure rehabilitation Abstract: Allocating limited capital-renewal (rehabilitation) funds among a large number of competing infrastructure assets has been a tremendous challenge for municipalities and public agencies. However, in the literature, there have been only limited efforts to provide economic approaches that can optimize, test, and justify fund-allocation decisions. In an effort to introduce such mechanisms, theories from microeconomics that maximize the return (utility) from consumer spending on multiple goods were adopted. To test the applicability of microeconomic concepts in the infrastructure fund-allocation problem, two case studies related to pavement sections and building components were carried out. An advanced mathematical optimization model was first developed and applied to the case studies to obtain optimum fund-allocation decisions. Then, the optimum decisions were analysed with respect to consumer theory to test the applicability of this theory in the fund-allocation problem. The analysis proved that the tested microeconomic approach applies perfectly to the infrastructure domain and that optimum decisions are achieved at an economic balance/equilibrium among the different expenditure categories. In essence, the wealth of well-established consumer theory has been introduced for its potential adoption in the infrastructure domain to improve and better justify infrastructure rehabilitation decisions. Journal: Construction Management and Economics Pages: 433-445 Issue: 5 Volume: 32 Year: 2014 Month: 5 X-DOI: 10.1080/01446193.2013.879193 File-URL: http://hdl.handle.net/10.1080/01446193.2013.879193 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:5:p:433-445 Template-Type: ReDIF-Article 1.0 Author-Name: Alistair Gibb Author-X-Name-First: Alistair Author-X-Name-Last: Gibb Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Michael Behm Author-X-Name-First: Michael Author-X-Name-Last: Behm Author-Name: Tracy Cooke Author-X-Name-First: Tracy Author-X-Name-Last: Cooke Title: Construction accident causality: learning from different countries and differing consequences Abstract: Fundamental questions remain about the practical value and generalizability of accident causation frameworks for explaining construction accidents. Relevant causality literature is reviewed; three research projects compared and implications of accident causation theories for accident investigation and analysis discussed, particularly for accidents with differing consequences and in different national contexts. The effectiveness of the UK accident causality framework ConAC (Construction Accident Causality) in identifying occupational accident causes in different industry contexts (Australia and the USA) is evaluated; and the implications of the choice of theoretical framework in the analysis of construction accident causation considered. The ConAC framework was developed from a real-time analysis of 100 relatively minor construction accidents. The Australian study used this framework to analyse the National Coroners reports of 258 construction fatalities and the USA study used it to develop research instruments for interviews regarding 27 construction accidents of varying consequences. The results suggest that the ConAC framework is helpful for the analysis of the causes of accidents with outcomes of differing severity. The studies also suggest that it has international applicability despite differing occupational health and safety legislative contexts and industrial arrangements. Furthermore, significant learning can be obtained from considering underlying causes of accidents. Journal: Construction Management and Economics Pages: 446-459 Issue: 5 Volume: 32 Year: 2014 Month: 5 X-DOI: 10.1080/01446193.2014.907498 File-URL: http://hdl.handle.net/10.1080/01446193.2014.907498 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:5:p:446-459 Template-Type: ReDIF-Article 1.0 Author-Name: Terence Lam Author-X-Name-First: Terence Author-X-Name-Last: Lam Author-Name: Keith Gale Author-X-Name-First: Keith Author-X-Name-Last: Gale Title: Highway maintenance: impact of framework agreements upon project financial performance Abstract: Use of frameworks is recognized by the UK Industrial Strategy: Government and Industry in Partnership as an innovative procurement method that may be used to deliver cost savings. Support for potential efficiencies from use of frameworks by practitioners is, at best, mixed. A single case study was conducted to investigate the financial performance of frameworks for highway maintenance projects within the context of a major county council. Results from independent samples t-tests of 60 framework and 60 traditional discrete projects verified that use of a framework revealed no significant changes in production costs of tender prices, but significant reductions in total transaction costs for engagement and performance monitoring. These findings suggest that use of framework procurement methods can support significant cost savings when used within a public sector environment. Journal: Construction Management and Economics Pages: 460-472 Issue: 5 Volume: 32 Year: 2014 Month: 5 X-DOI: 10.1080/01446193.2014.892628 File-URL: http://hdl.handle.net/10.1080/01446193.2014.892628 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:5:p:460-472 Template-Type: ReDIF-Article 1.0 Author-Name: Carol Jewell Author-X-Name-First: Carol Author-X-Name-Last: Jewell Author-Name: Roger Flanagan Author-X-Name-First: Roger Author-X-Name-Last: Flanagan Author-Name: Weisheng Lu Author-X-Name-First: Weisheng Author-X-Name-Last: Lu Title: The dilemma of scope and scale for construction professional service firms Abstract: Construction professional service (CPS) firms sell expertise and provide innovative solutions for projects founded on their knowledge, experience, and technical competences. Large CPS firms seeking to grow will often seek new opportunities in their domestic market and overseas by organic or inorganic growth through mergers, alliances, and acquisitions. Growth can also come from increasing market penetration through vertical, horizontal, and lateral diversification. Such growth, hopefully, leads to economies of scope and scale in the long term, but it can also lead to diseconomies, when the added cost of integration and the increased complexity of diversification no longer create tangible and intangible benefits. The aim of this research is to investigate the key influences impacting on the growth in scope and scale for large CPS firms. Qualitative data from the interviews were underpinned by secondary data from CPS firms' annual reports and analysts' findings. The findings showed five key influences on the scope and scale of a CPS firm: the importance of growth as a driver; the influence of the ownership of the firm on the decision for growth in scope and scale; the optimization of resources and capabilities; the need to serve changing clients' needs; and the importance of localization. The research provides valuable insights into the growth strategies of international CPS firms. A major finding of the research is the influence of ownership on CPS firms' growth strategies which has not been highlighted in previous research. Journal: Construction Management and Economics Pages: 473-486 Issue: 5 Volume: 32 Year: 2014 Month: 5 X-DOI: 10.1080/01446193.2013.879194 File-URL: http://hdl.handle.net/10.1080/01446193.2013.879194 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:5:p:473-486 Template-Type: ReDIF-Article 1.0 Author-Name: Stefan Olander Author-X-Name-First: Stefan Author-X-Name-Last: Olander Title: Performance-Based Contracts for Road Projects Journal: Construction Management and Economics Pages: 487-488 Issue: 5 Volume: 32 Year: 2014 Month: 5 X-DOI: 10.1080/01446193.2014.911930 File-URL: http://hdl.handle.net/10.1080/01446193.2014.911930 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:5:p:487-488 Template-Type: ReDIF-Article 1.0 Author-Name: Russell Kenley Author-X-Name-First: Russell Author-X-Name-Last: Kenley Title: Productivity improvement in the construction process Journal: Construction Management and Economics Pages: 489-494 Issue: 6 Volume: 32 Year: 2014 Month: 6 X-DOI: 10.1080/01446193.2014.930500 File-URL: http://hdl.handle.net/10.1080/01446193.2014.930500 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:6:p:489-494 Template-Type: ReDIF-Article 1.0 Author-Name: Shabtai Isaac Author-X-Name-First: Shabtai Author-X-Name-Last: Isaac Author-Name: Ronie Navon Author-X-Name-First: Ronie Author-X-Name-Last: Navon Title: Can project monitoring and control be fully automated? Abstract: An extended research programme has examined over the past two decades how productivity in construction projects can be improved through the development of models for project monitoring and control, which process automatically collected data on the actual project performance. Tests that were conducted with these models demonstrate that this approach can help overcome some of the limitations of existing manual methods. However, they also indicate that certain manually obtained data are still required in addition to the automatically collected data. A framework for semi-automated project monitoring and control is proposed, in which both manually and automatically collected data can be incorporated. This framework integrates the monitoring of projects with their control by taking into account the impact on productivity of existing deviations from the planned performance, and of the controlling actions that are proposed to deal with these deviations. Journal: Construction Management and Economics Pages: 495-505 Issue: 6 Volume: 32 Year: 2014 Month: 6 X-DOI: 10.1080/01446193.2013.795653 File-URL: http://hdl.handle.net/10.1080/01446193.2013.795653 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:6:p:495-505 Template-Type: ReDIF-Article 1.0 Author-Name: Rolf B�chmann-Slorup Author-X-Name-First: Rolf Author-X-Name-Last: B�chmann-Slorup Title: Applying critical chain buffer management theory in location-based management Abstract: Guidelines for prioritizing buffers on location-based management (LBM) projects are established through the use of critical chain theory (CCT). Buffer management theory in LBM has gained little attention from the research community. CCT builds on the assumption that each task is, either consciously or unconsciously, given a certain time buffer with which to cope with unpredicted events, and that these buffers become a large part of the project lead time. However, CCT suggests that these buffers entail inherent waste within schedules and fail to protect both critical activities and projects. CCT assumes that time estimates become self-fulfilling prophecies, as practitioners tend to procrastinate, and the buffers are often wasted. In addition, excess time rarely benefits the project if activities do finish early, because succeeding activities are unlikely to begin before the planned date. Although the criticisms by CCT also apply to LBM projects, CCT is based on the critical path method, and the guidelines from CCT must be adapted to the criticality principle of LBM theory. Accordingly, the contribution to the body of knowledge of this article is guidelines of buffer placement and prioritization in LBM that are based on critical chain buffer management theory. Journal: Construction Management and Economics Pages: 506-519 Issue: 6 Volume: 32 Year: 2014 Month: 6 X-DOI: 10.1080/01446193.2013.797094 File-URL: http://hdl.handle.net/10.1080/01446193.2013.797094 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:6:p:506-519 Template-Type: ReDIF-Article 1.0 Author-Name: Alan D. Russell Author-X-Name-First: Alan D. Author-X-Name-Last: Russell Author-Name: Ngoc Tran Author-X-Name-First: Ngoc Author-X-Name-Last: Tran Author-Name: Sheryl Staub-French Author-X-Name-First: Sheryl Author-X-Name-Last: Staub-French Title: Searching for value: construction strategy exploration and linear planning Abstract: Examined is how contractor or construction manager decision making and judgment in response to client objectives and project constraints can be aided by a structured approach to construction strategy selection and assessment using time-space project process and product modelling. The context studied is one of high-rise construction. Construction strategy is expressed in terms of strategy modes and tactical variables and accompanying values, which in turn are expressed in terms of a formal plan using a linear planning modelling paradigm. Highlighted is the important role that data visualization can play in both formulating strategy and assessing its workability via the medium of linear planning graphics complemented with other data representations that make use of quantitative product model data. Of particular interest is the ability to formulate and assess alternative construction strategies in a relatively fast and cost effective manner in order to achieve best value as a function of project constraints, context, and project participant objectives. Included in the assessment task is consideration of the impact of strategy on construction process productivity and production rates by way of performance metrics that relate directly to strategy workability. The concepts presented are illustrated through their application to a large-scale, mixed-use project. Journal: Construction Management and Economics Pages: 520-547 Issue: 6 Volume: 32 Year: 2014 Month: 6 X-DOI: 10.1080/01446193.2013.808354 File-URL: http://hdl.handle.net/10.1080/01446193.2013.808354 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:6:p:520-547 Template-Type: ReDIF-Article 1.0 Author-Name: Umberto C. Gatti Author-X-Name-First: Umberto C. Author-X-Name-Last: Gatti Author-Name: Giovanni C. Migliaccio Author-X-Name-First: Giovanni C. Author-X-Name-Last: Migliaccio Author-Name: Susan M. Bogus Author-X-Name-First: Susan M. Author-X-Name-Last: Bogus Author-Name: Suzanne Schneider Author-X-Name-First: Suzanne Author-X-Name-Last: Schneider Title: An exploratory study of the relationship between construction workforce physical strain and task level productivity Abstract: The monitoring of construction workforce physical strain can be a valuable management strategy in improving workforce productivity, safety, health, and quality of work. Nevertheless, clear relationships between workforce performance and physical strain have yet to be established. An exploratory investigation of the relationship between task level productivity and physical strain was conducted. Nine participants individually performed a four-hour simulated construction task while a wearable physiological status monitor continuously assessed their physiological condition. Heart rate, relative heart rate, and breathing rate were utilized as predictors of physical strain, and task level-single factor productivity was used as an index of productivity. Numerous regression models were generated using the collected data. This investigation initially unsuccessfully attempted to establish a relationship between physiological condition and productivity at the individual worker level. However, an analysis of the regression models showed that there is a relationship between productivity and either heart rate or relative heart rate at the group level, and that this relationship is parabolic. Breathing rate was proved to not be a significant predictor of productivity. Research results significantly improve understanding of the relationship between work physiology and task productivity. Researchers and practitioners may use the tested monitoring devices, analysis methods, and results to design further applied studies and to improve workforce productivity. Journal: Construction Management and Economics Pages: 548-564 Issue: 6 Volume: 32 Year: 2014 Month: 6 X-DOI: 10.1080/01446193.2013.831463 File-URL: http://hdl.handle.net/10.1080/01446193.2013.831463 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:6:p:548-564 Template-Type: ReDIF-Article 1.0 Author-Name: Ahmet Anil Sezer Author-X-Name-First: Ahmet Anil Author-X-Name-Last: Sezer Author-Name: Jan Br�chner Author-X-Name-First: Jan Author-X-Name-Last: Br�chner Title: The construction productivity debate and the measurement of service qualities Abstract: Since the 1960s, researchers have provided short-term and long-term explanations for low productivity growth in the construction industry. In retrospect, the main challenge appears to be the measurement of changes in heterogeneous input and output qualities. The aim here is to review earlier construction productivity research and to compare it with more recent approaches to quality measurement used when analysing services productivity, ultimately intending to provide guidance for using performance data from construction projects. Relying on the EU KLEMS database, industries with similar patterns of productivity growth are identified, primarily the business services industry. In services productivity analyses, the attempts to introduce output quality measures reflecting customer satisfaction are particularly interesting, as this creates a link to productivity effects on clients. A conclusion is that it should be possible to use the increasing volume of performance indicator data collected for construction project benchmarking for extending the range of output quality variables. However, resource constraints imply that it is infeasible to base industry productivity statistics on project level data reflecting customer satisfaction and customer productivity effects. Journal: Construction Management and Economics Pages: 565-574 Issue: 6 Volume: 32 Year: 2014 Month: 6 X-DOI: 10.1080/01446193.2013.831464 File-URL: http://hdl.handle.net/10.1080/01446193.2013.831464 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:6:p:565-574 Template-Type: ReDIF-Article 1.0 Author-Name: Gunnar Lucko Author-X-Name-First: Gunnar Author-X-Name-Last: Lucko Author-Name: Thaís Da C.L. Alves Author-X-Name-First: Thaís Da C.L. Author-X-Name-Last: Alves Author-Name: Vanessa Lira Angelim Author-X-Name-First: Vanessa Lira Author-X-Name-Last: Angelim Title: Challenges and opportunities for productivity improvement studies in linear, repetitive, and location-based scheduling Abstract: Despite theoretical advancements in alternative project planning methods the extent of their practical implementation varies strongly; it has been limited especially in the US construction industry. The family of linear, repetitive, and location-based scheduling techniques holds significant but barely substantiated promise by containing multiple variables of interest for integrated analysis and optimization. Yet it is necessary to provide empirical evidence that using such techniques can improve productivity to increase credibility and acceptance by practitioners, because claims of conceptual superiority are only sporadically supported with detailed measures. An analysis is performed to identify relevant decision-making variables, extract challenges that currently limit the corpus of quantitative productivity studies on alternative scheduling to its insufficient size, and reveal opportunities to expand it in breadth and depth. Variables are categorized by their relevance to time, activity, resource and location, as well as the managerial approach. Challenges include the diverse definitions of productivity itself, issues related to achieving generalizability, and the detailed steps of data collection, preparation, and analysis. Opportunities include the guidance from existing but rare studies and well-established research methods such as case studies that can be applied. This is illustrated with a sample project of a high-rise apartment building in Brazil. If alternative methods can be proven to be measurably better for specific applications, there might be a paradigm shift from merely defaulting to traditional but problematic network-based scheduling toward consciously choosing the planning method based on its potential benefits for a project. Journal: Construction Management and Economics Pages: 575-594 Issue: 6 Volume: 32 Year: 2014 Month: 6 X-DOI: 10.1080/01446193.2013.845305 File-URL: http://hdl.handle.net/10.1080/01446193.2013.845305 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:6:p:575-594 Template-Type: ReDIF-Article 1.0 Author-Name: Hassan Nasir Author-X-Name-First: Hassan Author-X-Name-Last: Nasir Author-Name: Hani Ahmed Author-X-Name-First: Hani Author-X-Name-Last: Ahmed Author-Name: Carl Haas Author-X-Name-First: Carl Author-X-Name-Last: Haas Author-Name: Paul M. Goodrum Author-X-Name-First: Paul M. Author-X-Name-Last: Goodrum Title: An analysis of construction productivity differences between Canada and the United States Abstract: Comparisons of industry sectors in advanced economies since the 1960s show that the construction sector has lagged in productivity growth rates, especially in the United States. Although the US and Canadian economies are highly integrated, Canada's experience differs in key ways. Analysis of these differences offers insight into fundamental construction productivity drivers. Three levels of analyses of construction productivity in the US are provided in this study. The first analysis compared international levels of labour productivity growth. The second compared construction productivity between the US and Canada, and the third analysed cost estimating data from RS Means estimating manuals to measure the changes in labour and partial factor productivity in the US from 1995 to 2009. Statistical significance testing indicates that labour productivity remained nearly constant in the building sub-sector and that partial factor productivity has improved at an annual compound rate of 0.66%. This supports previous findings that US construction has stagnated but is still improving in Canada, with wage differentials and training systems as potential drivers of this difference. While growth rates of productivity seem to decline with higher absolute levels of productivity, there is no evidence that high absolute productivity levels preclude significant growth. Journal: Construction Management and Economics Pages: 595-607 Issue: 6 Volume: 32 Year: 2014 Month: 6 X-DOI: 10.1080/01446193.2013.848995 File-URL: http://hdl.handle.net/10.1080/01446193.2013.848995 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:6:p:595-607 Template-Type: ReDIF-Article 1.0 Author-Name: Olli Sepp�nen Author-X-Name-First: Olli Author-X-Name-Last: Sepp�nen Author-Name: Jake Evinger Author-X-Name-First: Jake Author-X-Name-Last: Evinger Author-Name: Christopher Mouflard Author-X-Name-First: Christopher Author-X-Name-Last: Mouflard Title: Effects of the location-based management system on production rates and productivity Abstract: Location-based management systems (LBMSs) are becoming more commonly used to plan and control production in construction projects. The main use has been to compress durations and improve resource efficiency through real-time production control and forecasting. LBMS theory proposes that instead of continuously updating the plan with actualized completion dates, as with the critical path method (CPM), control actions can be used to manage an effective response to deviations in production in order to realign the schedule forecast with the approved plan. Three healthcare construction projects in California were monitored to document the effects of planning and control decisions on production rates, resources and labour consumption. First, the authors hypothesize that proposed control actions based on the system led to real actions in the field. Second, these control actions helped in controlling production rates. Third, control actions decreased subcontractor labour consumption. The results show that control actions were implemented as a response to production alarms and half of the implemented control actions were able to prevent production problems. Many control actions successfully improved production and labour consumption rates with a long-term impact. However, adding resources often increased labour consumption and negated part of the expected production rate benefit. Journal: Construction Management and Economics Pages: 608-624 Issue: 6 Volume: 32 Year: 2014 Month: 6 X-DOI: 10.1080/01446193.2013.853881 File-URL: http://hdl.handle.net/10.1080/01446193.2013.853881 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:6:p:608-624 Template-Type: ReDIF-Article 1.0 Author-Name: Nimesha Vilasini Author-X-Name-First: Nimesha Author-X-Name-Last: Vilasini Author-Name: Thomas Neitzert Author-X-Name-First: Thomas Author-X-Name-Last: Neitzert Author-Name: James Rotimi Author-X-Name-First: James Author-X-Name-Last: Rotimi Title: Developing and evaluating a framework for process improvement in an alliance project: a New Zealand case study Abstract: 'Lean thinking' holds out the promise of dramatic improvements in construction production processes, especially in waste minimization. While there exist empirical studies of 'leanness' with regard to non-relational-type projects, there is a need to analyse its applicability in relational contexts, such as an alliance. The application of 'lean' to a project alliance in a viaduct replacement in New Zealand is investigated here. The primary objective is to define a framework to streamline improvements in processes and to verify the applicability of the defined framework to a real construction alliance project. Participant observations, project documentation and action research meetings were used to collect data on the waste identification and elimination processes. The findings indicate that the construction work in a project alliance can be improved considerably by eliminating or reducing waste. Moreover, the savings are substantial, as the processes investigated were cyclic and repetitive. This framework is equally suited to waste detection and improvements at the site level. Project organizations should detect needs and opportunities for process change and transform processes accordingly. The current lack of any waste elimination technique, which could provide a significant competitive advantage for industry participants, has been established. Organizational conditions exist in project alliances that help to disseminate and sustain the lean concept. Journal: Construction Management and Economics Pages: 625-640 Issue: 6 Volume: 32 Year: 2014 Month: 6 X-DOI: 10.1080/01446193.2013.874565 File-URL: http://hdl.handle.net/10.1080/01446193.2013.874565 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:6:p:625-640 Template-Type: ReDIF-Article 1.0 Author-Name: Arno J. Van der Vlist Author-X-Name-First: Arno J. Author-X-Name-Last: Van der Vlist Author-Name: Marien H. Vrolijk Author-X-Name-First: Marien H. Author-X-Name-Last: Vrolijk Author-Name: Geert P.M.R. Dewulf Author-X-Name-First: Geert P.M.R. Author-X-Name-Last: Dewulf Title: On information and communication technology and production cost in construction industry: evidence from the Netherlands Abstract: The interplay between information and communication technology (ICT) and the competitiveness of construction firms is considered. More specifically, the question is whether firms that invest in information and communication technology have a production cost advantage. The economics literature hypothesizes that ICT brings about a production cost advantage, as ICT brings flexibility and improves the planning, organization and control of work. To test this proposition for the construction industry, a production cost function allowing for the inclusion of ICT is formulated. Using statistical nearest-neighbour matching methods it is possible to identify the effect of ICT on production costs thereby controlling for economic moderators. Data from a sample of Dutch construction firms reveal that those firms that installed ICT capital do have a production cost advantage. The results indicate further that firms need a minimum level of ICT capital to fully benefit from its production cost advantage. Journal: Construction Management and Economics Pages: 641-651 Issue: 6 Volume: 32 Year: 2014 Month: 6 X-DOI: 10.1080/01446193.2014.911932 File-URL: http://hdl.handle.net/10.1080/01446193.2014.911932 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:6:p:641-651 Template-Type: ReDIF-Article 1.0 Author-Name: Simon D Smith Author-X-Name-First: Simon D Author-X-Name-Last: Smith Title: Conference Issue: ARCOM 29-super-th Annual Conference Journal: Construction Management and Economics Pages: 653-657 Issue: 7-8 Volume: 32 Year: 2014 Month: 8 X-DOI: 10.1080/01446193.2014.938087 File-URL: http://hdl.handle.net/10.1080/01446193.2014.938087 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:7-8:p:653-657 Template-Type: ReDIF-Article 1.0 Author-Name: L�on L. olde Scholtenhuis Author-X-Name-First: L�on L. Author-X-Name-Last: olde Scholtenhuis Author-Name: Andr� G. Dor�e Author-X-Name-First: Andr� G. Author-X-Name-Last: Dor�e Title: High reliability organizing at the boundary of the CM domain Abstract: The construction management (CM) domain regularly develops and explores new theories and perspectives. These new insights can shift the existing paradigm radically, they can be assimilated smoothly, or they can stall as they are debated at CM's domain boundary. During our current research, we experience that the concepts from high reliability organizing (HRO) are caught in such a debate. We elaborate this debate from the viewpoint of two distinctive scientific traditions and evaluate the main premises that hold HRO at CM's boundaries. It seems that reductionist scientific traditions underlie much of the critique which currently diverts debate off into an unproductive intellectual cul-de-sac. An alternative pragmatic approach would allow CM's HRO researchers to avoid the confines of the reductionist arguments as it redirects minds and action on productive and practical research to achieving more reliable construction project performance, as well as dealing better with health and safety issues. Above all, the examination of the HRO boundary debate in CM may help other researchers experiencing impasses in their debates to explore whether these debates address the actual notions at stake or are restricted by deeply held views rooted in scientific traditions. Journal: Construction Management and Economics Pages: 658-664 Issue: 7-8 Volume: 32 Year: 2014 Month: 8 X-DOI: 10.1080/01446193.2014.913801 File-URL: http://hdl.handle.net/10.1080/01446193.2014.913801 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:7-8:p:658-664 Template-Type: ReDIF-Article 1.0 Author-Name: Frank R. Bijleveld Author-X-Name-First: Frank R. Author-X-Name-Last: Bijleveld Author-Name: Andr� G. Dor�e Author-X-Name-First: Andr� G. Author-X-Name-Last: Dor�e Title: Method-based learning: a case in the asphalt construction industry Abstract: Traditional working practices in the construction industry rely heavily on the onsite experience and craftsmanship (the tacit knowledge) of operators and teams. This results in implicit learning and lengthy learning cycles. The aims of the research are to develop a deeper insight into construction processes and to instigate a change from current implicit learning to explicit method-based learning. To change to explicit method-based learning, Kolb's experiential learning model was introduced into current practices and 'explicating the process' was added to this learning cycle. Further 'reflective observation' and 'abstract conceptualization' were incorporated explicitly during an actual road construction project using feedback sessions with an asphalting team. The adopted learning framework was found to be applicable and useful in the quest for enhanced learning capabilities and improved process control. Fusing Kolb's learning model with onsite collected data was vital in explicating tacit knowledge and implicit processes. The approach enabled a meaningful discussion with operators to unravel their intentions and reasoning behind the chosen strategies. Explicit method-based learning, as here, leads to improved quality awareness, better understanding of the processes and their interdependencies, and improved communication with and within the asphalting team. Journal: Construction Management and Economics Pages: 665-681 Issue: 7-8 Volume: 32 Year: 2014 Month: 8 X-DOI: 10.1080/01446193.2014.887211 File-URL: http://hdl.handle.net/10.1080/01446193.2014.887211 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:7-8:p:665-681 Template-Type: ReDIF-Article 1.0 Author-Name: Dominic D. Ahiaga-Dagbui Author-X-Name-First: Dominic D. Author-X-Name-Last: Ahiaga-Dagbui Author-Name: Simon D. Smith Author-X-Name-First: Simon D. Author-X-Name-Last: Smith Title: Dealing with construction cost overruns using data mining Abstract: One of the main aims of any construction client is to procure a project within the limits of a predefined budget. However, most construction projects routinely overrun their cost estimates. Existing theories on construction cost overrun suggest a number of causes ranging from technical difficulties, optimism bias, managerial incompetence and strategic misrepresentation. However, much of the budgetary decision-making process in the early stages of a project is carried out in an environment of high uncertainty with little available information for accurate estimation. Using non-parametric bootstrapping and ensemble modelling in artificial neural networks, final project cost-forecasting models were developed with 1600 completed projects. This helped to extract information embedded in data on completed construction projects, in an attempt to address the problem of the dearth of information in the early stages of a project. It was found that 92% of the 100 validation predictions were within ±10% of the actual final cost of the project while 77% were within ±5% of actual final cost. This indicates the model's ability to generalize satisfactorily when validated with new data. The models are being deployed within the operations of the industry partner involved in this research to help increase the reliability and accuracy of initial cost estimates. Journal: Construction Management and Economics Pages: 682-694 Issue: 7-8 Volume: 32 Year: 2014 Month: 8 X-DOI: 10.1080/01446193.2014.933854 File-URL: http://hdl.handle.net/10.1080/01446193.2014.933854 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:7-8:p:682-694 Template-Type: ReDIF-Article 1.0 Author-Name: Maarten E.J. Rutten Author-X-Name-First: Maarten E.J. Author-X-Name-Last: Rutten Author-Name: Andr� G. Dor�e Author-X-Name-First: Andr� G. Author-X-Name-Last: Dor�e Author-Name: Johannes I.M. Halman Author-X-Name-First: Johannes I.M. Author-X-Name-Last: Halman Title: Together on the path to construction innovation: yet another example of escalation of commitment? Abstract: Collaborative innovation projects are projects in which firms join forces to cooperate in the development and commercialization of a new building product, system, or service. They represent an example of the type of inter-firm relationships that are said to enhance construction innovation. Organizational behaviour research, however, suggests that firms participating in such innovation projects run the risk of escalating commitment and may continue to invest for irrational reasons. It is therefore relevant to examine whether Dutch firms that invest, in collaboration with other firms, in the development and commercialization of a new building product, system, or service are susceptible to this escalation. Two escalation effects were investigated: the effect of expected loss of sunk costs, and the effect of perceived project stage. A survey was undertaken of 154 firms participating in 25 collaborative innovation projects. The results suggest that firms in the population under study are unlikely to fall victim to either of the two escalation effects. Rather, the negative association found between the expected loss of sunk costs and likelihood of continuing investment raises the question as to whether firms become more cautious when they have spent a lot. Journal: Construction Management and Economics Pages: 695-704 Issue: 7-8 Volume: 32 Year: 2014 Month: 8 X-DOI: 10.1080/01446193.2014.933855 File-URL: http://hdl.handle.net/10.1080/01446193.2014.933855 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:7-8:p:695-704 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Tansey Author-X-Name-First: Paul Author-X-Name-Last: Tansey Author-Name: John P. Spillane Author-X-Name-First: John P. Author-X-Name-Last: Spillane Author-Name: Xianhai Meng Author-X-Name-First: Xianhai Author-X-Name-Last: Meng Title: Linking response strategies adopted by construction firms during the 2007 economic recession to Porter's generic strategies Abstract: The time period bridging the years 2007 to 2012 will be remembered as one characterized by dramatic changes in the Irish and UK construction industries. Construction companies witnessed unprecedented changes in the environment, namely the coincidence of a sharp economic downturn, the significant decline of public works, a reduction in lending, increased competition, and structural changes in the marketplace. Nevertheless, little has been documented on what response strategies construction companies adopt as a result of an economic recession. Based on four exploratory case studies, a taxonomy framework of the response strategies adopted by Irish and UK construction companies during the 2007 economic recession was developed relative to Porter's generic strategies of cost leadership, differentiation, and focus. Porter's model is a well-known theoretical framework among business strategists and industrial economists worldwide. The analysis provides strong support for the adoption of cost leadership strategies as a means to surviving the 2007 economic recession. The case studies further suggest that cost control initiatives are one of the most important attributes in companies' responses to the 2007 recession. The findings provide valuable assistance for construction contractors in developing effective strategies and thus reducing business failures during recessionary periods. Journal: Construction Management and Economics Pages: 705-724 Issue: 7-8 Volume: 32 Year: 2014 Month: 8 X-DOI: 10.1080/01446193.2014.933856 File-URL: http://hdl.handle.net/10.1080/01446193.2014.933856 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:7-8:p:705-724 Template-Type: ReDIF-Article 1.0 Author-Name: Chuanjing Ju Author-X-Name-First: Chuanjing Author-X-Name-Last: Ju Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Title: Institutional determinants of construction safety management strategies of contractors in Hong Kong Abstract: Workplace safety in the construction industry of Hong Kong is regulated by a mix of enforcement and performance-based approaches. The two approaches are underpinned by different institutional structures and lead to divergent safety practices. To examine how contractors strategically respond to the complex institutional demands for safety performance, contractors' day-to-day site safety practices were investigated. Safety practice data were obtained from 62 open-ended interviews and project archives in a case study. Different supervision patterns, i.e. enforcement and localized approaches were found to coexist on site. Discrepancies were found between workers' self-reported safety awareness and safety awareness assessed by their supervisors. The evidence suggests that contractors implemented compromise and avoidance strategies. The complex institutional environment, especially the incompatible progress and safety requirements, was found to be a key determinant of mixed site safety practices. Institutional theory is explored as a possible theoretical perspective to explain contractors' safety management strategies. An institutional level change of safety management strategies is suggested. Journal: Construction Management and Economics Pages: 725-736 Issue: 7-8 Volume: 32 Year: 2014 Month: 8 X-DOI: 10.1080/01446193.2014.909048 File-URL: http://hdl.handle.net/10.1080/01446193.2014.909048 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:7-8:p:725-736 Template-Type: ReDIF-Article 1.0 Author-Name: Fred Sherratt Author-X-Name-First: Fred Author-X-Name-Last: Sherratt Title: Exploring 'Zero Target' safety programmes in the UK construction industry Abstract: Zero Target safety management programmes have become prominent on the UK sites of large construction contractors, who promote 'Zero Harm', 'Mission Zero' or 'Target Zero' on their hoardings and corporate websites. However, while Zero Target programmes may inspire increased commitment to safety from some, they may also cause detachment in others who feel it an unattainable goal for a high-risk industry. Examination of the practical realities of such Zero Target safety programmes has been undertaken, to illuminate and understand their position and potential impact on UK construction site health and safety management. A social constructionist methodology was employed, with discourse analysis of corporate websites, reports and promotional materials from five large contractors currently operating Zero Target safety programmes on their UK sites, supplemented by conversations with site management and operatives working on such sites. Zero was constructed as both a philosophy and a target, the corporate and site voices developing alternative visions of zero in practice. There is incoherence and inconsistency within the understandings of zero, which may affect the practical successes of Zero Target safety programmes, but zero was also found to have a very necessary place within industry safety management, in order to support future improvements in practice. Journal: Construction Management and Economics Pages: 737-748 Issue: 7-8 Volume: 32 Year: 2014 Month: 8 X-DOI: 10.1080/01446193.2014.894248 File-URL: http://hdl.handle.net/10.1080/01446193.2014.894248 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:7-8:p:737-748 Template-Type: ReDIF-Article 1.0 Author-Name: Martine Buser Author-X-Name-First: Martine Author-X-Name-Last: Buser Author-Name: Christian Koch Author-X-Name-First: Christian Author-X-Name-Last: Koch Title: Is this none of the contractor's business? Social sustainability challenges informed by literary accounts Abstract: In Sweden many suburbs built at the end of the 1960s are in need of physical renovation to comply with new energy regulations. Some of these neighbourhoods face serious social challenges which also need to be tackled. The three largest Swedish contractors, usually very active in providing technical and environmentally friendly renovation, claim now they can provide social sustainability solutions on a commercial basis. For many years the problems of deprived suburbs have attracted the attention and the care of the public institutions, and though many initiatives have been carried out to address these issues, results have been sometimes quite limited. To discuss the social challenges linked to suburbs' renovation, an alternative method is proposed: the analysis of literary accounts. The goal is to assess whether stories relating the lives of residents in deprived Swedish suburbs can inform and therefore contribute to the development of socially sustainable solutions. Referring to the literature on social sustainability, this qualitative and explorative study uses critical discourse analysis as the method. Results suggest that focusing on renovated housing, employment, social services and leisure activities is not enough to rehabilitate disadvantaged neighbourhoods. They also indicate some specific problems linked to the built environment that contractors could help to solve. Journal: Construction Management and Economics Pages: 749-759 Issue: 7-8 Volume: 32 Year: 2014 Month: 8 X-DOI: 10.1080/01446193.2014.927898 File-URL: http://hdl.handle.net/10.1080/01446193.2014.927898 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:7-8:p:749-759 Template-Type: ReDIF-Article 1.0 Author-Name: William H. Collinge Author-X-Name-First: William H. Author-X-Name-Last: Collinge Author-Name: Chris F. Harty Author-X-Name-First: Chris F. Author-X-Name-Last: Harty Title: Stakeholder interpretations of design: semiotic insights into the briefing process Abstract: Briefing phase interactions between clients and designers are recognized as social engagements, characterized by communicative sign use, where conceptual ideas are gradually transformed into potential design solutions. A semiotic analysis of briefing communications between client stakeholders and designers provides evidence of the significance and importance of stakeholder interpretation and understanding of design, empirical data being drawn from a qualitative study of NHS hospital construction projects in the UK. It is contended that stakeholders engage with a project through communicative signs and artefacts of design, referencing personal cognitive knowledge in acts of interpretation that may be different from those of designers and externally appointed client advisers. Such interpretations occur in addition to NHS client and design team efforts to 'engage' with and 'understand' stakeholders using a variety of methods. Social semiotic theorizations indicate how narrative strategies motivate the formulation of signs and artefacts in briefing work, the role of sign authors and sign readers being elucidated as a result. Findings are contextualized against current understandings of briefing communications and stakeholder management practices, a more socially attuned understanding of breifing countering some of the process-led improvement models that have characterized much of the post-Egan report literature. A stakeholder interpretation model is presented as one potential method to safeguard against unforeseen interpretations occurring, the model aligning with the proposal for a more measured recognition of how designs can trigger interpretations among client stakeholders. Journal: Construction Management and Economics Pages: 760-772 Issue: 7-8 Volume: 32 Year: 2014 Month: 8 X-DOI: 10.1080/01446193.2014.894247 File-URL: http://hdl.handle.net/10.1080/01446193.2014.894247 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:7-8:p:760-772 Template-Type: ReDIF-Article 1.0 Author-Name: Daniel Sage Author-X-Name-First: Daniel Author-X-Name-Last: Sage Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: Kjell Tryggestad Author-X-Name-First: Kjell Author-X-Name-Last: Tryggestad Author-Name: Lise Justesen Author-X-Name-First: Lise Author-X-Name-Last: Justesen Author-Name: Jan Mouritsen Author-X-Name-First: Jan Author-X-Name-Last: Mouritsen Title: Building with wildlife: project geographies and cosmopolitics in infrastructure construction Abstract: Across many construction projects, and especially infrastructure projects, efforts to mitigate potential loss of biodiversity and habitat are significant concerns, and at times politically controversial. And yet, thus far, very little research has addressed the interplay of humans and animals within construction projects. Instead those interested in the politics and ethics of human-animal relations, or animal studies, have arguably focused far more on more stable and contained sites, whether organizations like zoos, farms or laboratories, or other places like homes and parks. These largely ethnographic studies inevitably perhaps downplay the unplanned, unexpected and highly politically and ethically charged, collision of hitherto rather separate human and animal geographies. Yet it is often within such colliding spaces, where animal geographies are unexpectedly found at the heart of human projects, that we formulate our respect and response to both animals and indeed other humans. We develop an examination of such encounters, with conceptual reference to actor-network theory, and documented empirically through case studies of two infrastructure projects; the findings of our research are relevant to both construction project management and future animal studies. Journal: Construction Management and Economics Pages: 773-786 Issue: 7-8 Volume: 32 Year: 2014 Month: 8 X-DOI: 10.1080/01446193.2014.911933 File-URL: http://hdl.handle.net/10.1080/01446193.2014.911933 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:7-8:p:773-786 Template-Type: ReDIF-Article 1.0 Author-Name: Clare Shipton Author-X-Name-First: Clare Author-X-Name-Last: Shipton Author-Name: Will Hughes Author-X-Name-First: Will Author-X-Name-Last: Hughes Author-Name: Dylan Tutt Author-X-Name-First: Dylan Author-X-Name-Last: Tutt Title: Change management in practice: an ethnographic study of changes to contract requirements on a hospital project Abstract: Changes to client requirements are inevitable during construction. Industry discourse is concerned with minimizing and controlling changes. However, accounts of practices involved in making changes are rare. In response to calls for more research into working practices, an ethnographic study of a live hospital project was undertaken to explore how changes are made. A vignette of a meeting exploring the investigation of changes illustrates the issues. This represents an example from the ethnographic fieldwork, which produced many observations. There was a strong emphasis on using change management procedures contained within the contract to investigate changes, even when it was known that the change was not required. For the practitioners, this was a way of demonstrating best practice, transparent and accountable decision-making regarding changes. Hence, concerns for following procedures sometimes overshadowed considerations about whether or not a change was required to improve the functionality of the building. However, the procedures acted as boundary objects between the communities of practice involved on the project by coordinating the work of managing changes. Insights suggest how contract procedures facilitate and impede the making of changes, which can inform policy guidance and contract drafting. Journal: Construction Management and Economics Pages: 787-803 Issue: 7-8 Volume: 32 Year: 2014 Month: 8 X-DOI: 10.1080/01446193.2014.915336 File-URL: http://hdl.handle.net/10.1080/01446193.2014.915336 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:7-8:p:787-803 Template-Type: ReDIF-Article 1.0 Author-Name: John-Paul Smiley Author-X-Name-First: John-Paul Author-X-Name-Last: Smiley Author-Name: Scott Fernie Author-X-Name-First: Scott Author-X-Name-Last: Fernie Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Title: Understanding construction reform discourses Abstract: Attempts to drive change and reform of the UK construction industry have been an ongoing concern for numerous stakeholders, both in government and across industry, for years. The issue is a seemingly perennially topical one which shows little sign of abating. Scholarly analyses of the reform agenda have tended to adopt a Critical Theory perspective. Such an approach, however, lacks a certain nuance and perhaps only reveals one layer of social reality. What is arguably lacking is a more fundamental exposition concerning the historical, social and cultural explanatory forces at play. While it is illuminating to expose vested interests, ideology and power, what has led to the development of various views? How have they come to achieve such high accord in discussions? Drawing on the works of Max Weber, Georg Simmel and Barbara Adam, this paper seeks to develop a broader theoretical lens. It considers the wider socio-cultural structures and forces that influence behaviour, shape and constrain these views. This approach will contribute to a much needed broader philosophical and theoretical debate within the construction management community (and beyond) on the need to better engage with, and understand, the sources influencing the issue of policy formulation and diffusion. Journal: Construction Management and Economics Pages: 804-815 Issue: 7-8 Volume: 32 Year: 2014 Month: 8 X-DOI: 10.1080/01446193.2014.909049 File-URL: http://hdl.handle.net/10.1080/01446193.2014.909049 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:7-8:p:804-815 Template-Type: ReDIF-Article 1.0 Author-Name: Robert Close Author-X-Name-First: Robert Author-X-Name-Last: Close Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: Breaking down the site hoardings: attitudes and approaches to community consultation during construction Abstract: As the general public become more empowered, informed and educated about the impact of business activities on their lives, they are demanding more involvement in construction projects which they perceive to affect their interests. The process of community consultation is traditionally seen as the responsibility of urban planners but residual community concerns often spill over into construction requiring construction professionals to also consult with communities. To investigate current attitudes and approaches towards community consultation during construction, 150 construction professionals were surveyed and 10 interviewed. The results indicate that the majority of the professionals involved during construction consider community consultation a burdensome, costly and time-consuming exercise. The community is seen as a liability rather than an asset and few construction professionals have the skills to consult effectively. There appears to be a widespread assumption that community consultation is the responsibility of town planners before work starts on site and that further interaction with the community is a nuisance, once construction starts. Journal: Construction Management and Economics Pages: 816-828 Issue: 7-8 Volume: 32 Year: 2014 Month: 8 X-DOI: 10.1080/01446193.2013.879195 File-URL: http://hdl.handle.net/10.1080/01446193.2013.879195 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:7-8:p:816-828 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Taggart Author-X-Name-First: Martin Author-X-Name-Last: Taggart Author-Name: Lauri Koskela Author-X-Name-First: Lauri Author-X-Name-Last: Koskela Author-Name: John Rooke Author-X-Name-First: John Author-X-Name-Last: Rooke Title: The role of the supply chain in the elimination and reduction of construction rework and defects: an action research approach Abstract: Since 2007, Ireland has suffered a circa 80% reduction in construction output. This has resulted in bankruptcy, unemployment and bad debt. Contractors have attached greater emphasis to production efficiency and cost reduction as a means of survival. An action research (AR) strategy was used to improve processes adopted by a small/medium enterprise (SME) contractor for the control of defects in its supply chain. It is conservatively estimated that rework, typically, accounts for circa 5% of total project costs. Rework is wasteful and presents an obvious target for improvement. The research reported here concerns the (first) diagnosing stage of the AR cycle only, involving: observation of fieldwork, analysis of contract documents, and semi-structured interviews with supply chain members. The results indicate potential for supply chain participants to identify root causes of defects and propose solutions, having regard to best practice to avoid reoccurrence. A lack of collaborative forums to contribute to production improvement was identified. Additionally the processes used to collect, manage and disseminate data were unstructured and uncoordinated, indicating scope for developing more efficient methods. The findings indicate a good understanding of the potential benefits for supply chain collaboration but suggest that the tools and knowledge to collaborate are currently lacking in the SME sector. Journal: Construction Management and Economics Pages: 829-842 Issue: 7-8 Volume: 32 Year: 2014 Month: 8 X-DOI: 10.1080/01446193.2014.904965 File-URL: http://hdl.handle.net/10.1080/01446193.2014.904965 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:7-8:p:829-842 Template-Type: ReDIF-Article 1.0 Author-Name: Terence Hogarth Author-X-Name-First: Terence Author-X-Name-Last: Hogarth Author-Name: Lynn Gambin Author-X-Name-First: Lynn Author-X-Name-Last: Gambin Title: Employer investment in Apprenticeships in England: an exploration of the sensitivity of employers in the construction sector to the net costs of training Abstract: Apprenticeships in England are undergoing major reform which will likely require employers to make a cash contribution to meeting the fees of their training providers. In return employers will be given more influence over the content of the training. If employers are expected to make a cash contribution this is likely to have an impact on their willingness to deliver Apprenticeships. Based on a series of employer case studies conducted between 1995 and 2011 an examination is provided of construction employers' sensitivity to the costs of delivering Apprenticeships. Because the cost to the employer is relatively high, and because there is a degree of uncertainty attached to recouping those costs, there is a distinct set of disincentives to construction employers providing Apprenticeships. This is important. First, the construction sector will need to recruit a large number of additional people into skilled trades jobs over the next 10 years as the sector's recovery gains pace and many existing employees retire. Second, Apprenticeships in the sector have an important role to play in young people's transition from school into work. A fall in the number of apprentices in the sector is likely to have important economic and social consequences. Journal: Construction Management and Economics Pages: 845-856 Issue: 9 Volume: 32 Year: 2014 Month: 9 X-DOI: 10.1080/01446193.2014.923577 File-URL: http://hdl.handle.net/10.1080/01446193.2014.923577 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:9:p:845-856 Template-Type: ReDIF-Article 1.0 Author-Name: Finn Orstavik Author-X-Name-First: Finn Author-X-Name-Last: Orstavik Title: Innovation as re-institutionalization: a case study of technological change in housebuilding in Norway Abstract: Case study can give important new insights into the systemic nature of construction innovation and the interrelationship between local innovation successes and structural forces shaping the sector. Even well-defined, modular innovations can have significant repercussions on the industry level. Recent innovation in building materials for wet rooms in Norway represents an attempt to modify only limited aspects of the established approach to housebuilding, but is made difficult by institutions and actors relying on established methods and existing building products. Institutions acting as innovation brokers can be very important for innovators. However, brokering is no panacea for promoting disruptive innovation. A broker can thwart rather than promote potentially useful but disruptive innovations. Because innovation is a re-institutionalization process, the third-party position needed for brokering effectively can be undermined, whenever a successful broker attains vested interests in the innovation outcomes it has helped bring forth. Methodologically, employing theories on technological innovation systems and on multilevel socio-technical systems shows that these are effective, complementary tools for analysis of innovation in construction. Only the latter incorporates the notion of innovation as creative destruction, and it is by drawing on this theory that the precariousness of the brokering role can be highlighted. Journal: Construction Management and Economics Pages: 857-873 Issue: 9 Volume: 32 Year: 2014 Month: 9 X-DOI: 10.1080/01446193.2014.895848 File-URL: http://hdl.handle.net/10.1080/01446193.2014.895848 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:9:p:857-873 Template-Type: ReDIF-Article 1.0 Author-Name: Fah Choy Chia Author-X-Name-First: Fah Choy Author-X-Name-Last: Chia Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Goran Runeson Author-X-Name-First: Goran Author-X-Name-Last: Runeson Author-Name: Adrian Bridge Author-X-Name-First: Adrian Author-X-Name-Last: Bridge Title: Economic development and construction productivity in Malaysia Abstract: The productivity of the construction industry has a significant effect on national economic growth. Gains from higher construction productivity flow through the economy, as all industries rely on construction to some extent as part of their business investment. Contractions and expansions of economic activity are common phenomena in an economy. Three construction cycles occurred between the years 1970 and 2011 in Malaysia. The relationships between construction productivity and economic development are examined by the partial correlation method to establish the underlying factors driving the change in construction productivity. Construction productivity is statistically significantly correlated with gross domestic product (GDP) per capita in a positive direction for the 1985-98 and 1998-2009 cycles, but not the 1970-85 cycle. Fluctuations in construction activities and the influx of foreign workers underlie the changes of construction productivity in the 1985-98 cycle. There was less fluctuation in construction activities in the 1998-2009 cycle, with changes being mainly due to the fiscal stimulation policies of the government in attempting to stabilize the economy. The intensive construction of mega-projects resulted in resource constraints and cost pressures during the 1980s and 1990s. A better management of the 'boom-bust' nature of the construction business cycle is required to maintain the capability and capacity of the industry. Journal: Construction Management and Economics Pages: 874-887 Issue: 9 Volume: 32 Year: 2014 Month: 9 X-DOI: 10.1080/01446193.2014.938086 File-URL: http://hdl.handle.net/10.1080/01446193.2014.938086 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:9:p:874-887 Template-Type: ReDIF-Article 1.0 Author-Name: Eric Shiu Author-X-Name-First: Eric Author-X-Name-Last: Shiu Author-Name: Zhizhong Jiang Author-X-Name-First: Zhizhong Author-X-Name-Last: Jiang Author-Name: Ghasem Zaefarian Author-X-Name-First: Ghasem Author-X-Name-Last: Zaefarian Title: Antecedents of behavioural commitment in inter-organizational relationships: a field study of the UK construction industry Abstract: Commitment is vital in inter-organizational relationships. It is important to understand what drives commitment which then affects the relationship between organizations. Commitment is a multidimensional construct and its dimensions can be broadly categorized into attitudinal and behavioural perspectives. In conventional practice, commitment researchers have tended to focus on the attitudinal perspective, while the behavioural perspective is largely ignored. In an attempt to buck that conventional trend commitment research is proposed along the unconventional but widely accepted as important behavioural perspective, building up a more complete understanding of the importance of behavioural commitment, as well as developing and validating a theoretical model that depicts precisely the relationship between behavioural commitment and its key driving factors. Accordingly a large-scale questionnaire survey has been conducted in the UK construction industry and 636 responses were collected. Structural equation modelling was then used to test the theoretical model. Results validate trust, reliance and dependence as the major antecedents of behavioural commitment. A new direction in commitment research adds new findings to the current body of commitment literature. Journal: Construction Management and Economics Pages: 888-903 Issue: 9 Volume: 32 Year: 2014 Month: 9 X-DOI: 10.1080/01446193.2014.915335 File-URL: http://hdl.handle.net/10.1080/01446193.2014.915335 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:9:p:888-903 Template-Type: ReDIF-Article 1.0 Author-Name: Timothy M. Rose Author-X-Name-First: Timothy M. Author-X-Name-Last: Rose Author-Name: Karen Manley Author-X-Name-First: Karen Author-X-Name-Last: Manley Title: Revisiting the adoption of innovative products on Australian road infrastructure projects Abstract: Construction product innovation can exert a positive influence on project and industry performance. However, guidance is scarce on product innovation diffusion for road infrastructure, in contrast to the large body of literature on the manufacturing industry. A conceptual framework is proposed to understand these processes. Advice is given to managers based on the framework and a large quantitative survey. The framework focuses on contextual characteristics that influence the decision to adopt new-to-industry product innovation, as part of a diffusion process. Case study data are interpreted within the revised framework to test its value and disaggregate the broad obstacles to innovation. A large quantitative survey was then conducted to rank the relative importance of the obstacles constraining the adoption of innovative products on road construction projects. The three most important obstacles were found to be: (1) overemphasis on up-front project costs during tender stage; (2) disagreement over who carries the risk of new product failure; and (3) adversarial contract relations. The results suggest refinements to the conceptual framework to make it a more powerful tool for categorizing and analysing construction innovation obstacles. Results also suggest well-resourced repeat interactions within complementary procurement and regulatory systems will enhance the project teams' ability to recognize and address innovation obstacles. Further, improved relationships are expected to decrease the need for an overly conservative approach to product approval and prescriptive specifications. Journal: Construction Management and Economics Pages: 904-917 Issue: 9 Volume: 32 Year: 2014 Month: 9 X-DOI: 10.1080/01446193.2014.938670 File-URL: http://hdl.handle.net/10.1080/01446193.2014.938670 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:9:p:904-917 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Payam Pirzadeh Author-X-Name-First: Payam Author-X-Name-Last: Pirzadeh Author-Name: Nick Blismas Author-X-Name-First: Nick Author-X-Name-Last: Blismas Author-Name: Ron Wakefield Author-X-Name-First: Ron Author-X-Name-Last: Wakefield Author-Name: Brian Kleiner Author-X-Name-First: Brian Author-X-Name-Last: Kleiner Title: Exploring the link between early constructor involvement in project decision-making and the efficacy of health and safety risk control Abstract: The position of the constructor in communication networks, including those before the commencement of construction, is likely related to the quality of work health and safety (WHS) outcomes realized. In order to examine the extent of this relationship, 23 cases were drawn from 10 participating construction projects in Australia and New Zealand. Social network analysis was used to mathematically and graphically model information exchanges in 13 of these cases. For each case, the quality of WHS risk control outcomes was measured. This measurement was based on an established 'hierarchy of control' in which risk controls are classified in descending order of effectiveness from the elimination of a hazard (the most effective) to the reliance on personal protective equipment (the least effective). Social network metrics were calculated reflecting: (1) the ratio of actual links among parties in the project network relative to the maximum number of links possible (network density); and (2) the extent to which the constructor communicated with other parties in pre-project planning and design stages (the constructors' degree centrality). Network metrics were compared for cases in which the risk control scores were higher and lower than average. The results showed a significant difference in constructors' pre-construction degree centrality for cases with high and low risk control scores. The results provide preliminary evidence as to the potential WHS benefits of ensuring that constructors' knowledge about construction methods, materials, WHS risks and means of risk control, are integrated into pre-construction decision-making. Journal: Construction Management and Economics Pages: 918-931 Issue: 9 Volume: 32 Year: 2014 Month: 9 X-DOI: 10.1080/01446193.2014.911931 File-URL: http://hdl.handle.net/10.1080/01446193.2014.911931 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:9:p:918-931 Template-Type: ReDIF-Article 1.0 Author-Name: Amin Akhavan Tabassi Author-X-Name-First: Amin Akhavan Author-X-Name-Last: Tabassi Author-Name: Mahyuddin Ramli Author-X-Name-First: Mahyuddin Author-X-Name-Last: Ramli Author-Name: Kamand M. Roufechaei Author-X-Name-First: Kamand M. Author-X-Name-Last: Roufechaei Author-Name: Arash Akhavan Tabasi Author-X-Name-First: Arash Akhavan Author-X-Name-Last: Tabasi Title: Team development and performance in construction design teams: an assessment of a hierarchical model with mediating effect of compensation Abstract: A high-performance construction workplace invests in its human resources and facilitates their technical and innovation skills through team development. Though team development has been explored in many studies, to date, little research has disentangled how team development and compensation methods enhance team performance in construction companies. Accordingly, team development as a hierarchical, reflective construct, incorporating six associated components was extended and the variables of the model in a nomological network analysed using partial least squares (PLS). As a result, with the help of PLS path modelling, a hierarchical team development construct with the mediating effects of compensation on the relationship between team development and team performance was developed. The research analysis was completed on a sample population of 128 construction design teams and the results lead to the development of a model that shows team development has a significant direct and indirect impact on team performance. The results also confirm the mediating role of group compensation on the relationship between team development and team performance. In general, it is suggested that the design teams achieved better performance when the leaders adapted team compensation methods consistent with the team development practices. Journal: Construction Management and Economics Pages: 932-949 Issue: 9 Volume: 32 Year: 2014 Month: 9 X-DOI: 10.1080/01446193.2014.935739 File-URL: http://hdl.handle.net/10.1080/01446193.2014.935739 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:9:p:932-949 Template-Type: ReDIF-Article 1.0 Author-Name: Steven Male Author-X-Name-First: Steven Author-X-Name-Last: Male Title: Professional Services Agreements Journal: Construction Management and Economics Pages: 950-952 Issue: 9 Volume: 32 Year: 2014 Month: 9 X-DOI: 10.1080/01446193.2014.933853 File-URL: http://hdl.handle.net/10.1080/01446193.2014.933853 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:9:p:950-952 Template-Type: ReDIF-Article 1.0 Author-Name: Yukiko Konno Author-X-Name-First: Yukiko Author-X-Name-Last: Konno Title: Japanese competitive bid entry qualifications: an examination of public works Abstract: This study summarises the independent competitive bid entry qualifications examination of public works in Japan. Contractors who wish to undertake public works must be scored by a nationwide standardised objective examination called Keiei Jikou Sinsa or Keisin in Japanese. They must be graded on the basis of the score of not only the objective examination but also an independent assessment by the orderers. This study explains the calculation of Keisin using a virtual contractor. This study also discusses the effectiveness of Keisin and the efficiency of the grading system. Keisin is used not only for bid entry qualifications in public works, but also to evaluate construction companies by the orderers of private works and financial institutions. Additionally, the Ministry of Land, Infrastructure, Transport and Tourism uses Keisin to promote subscription to social insurance and thus contribute to improve workers' lifelong protection. The Japanese grading system in public bids underpins competitive bidding among firms of similar scale and capability, while providing opportunities for SMEs in every industry class to obtain construction contracts as prime contractors. Journal: Construction Management and Economics Pages: 957-967 Issue: 10 Volume: 32 Year: 2014 Month: 10 X-DOI: 10.1080/01446193.2014.948465 File-URL: http://hdl.handle.net/10.1080/01446193.2014.948465 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:10:p:957-967 Template-Type: ReDIF-Article 1.0 Author-Name: Weisheng Lu Author-X-Name-First: Weisheng Author-X-Name-Last: Lu Title: Reliability of Engineering News-Record international construction data Abstract: Since the late 1970s, the Engineering News-Record (ENR) has produced annual lists ranking firms involved in development of the built environment on the basis of their international revenues. ENR lists, such as the Top 225 International Contractors and the Top 200 International Design Firms, have become popular datasets for international construction research. Nonetheless, given that the ENR data are self-reported, reviewers for journals and research funding bodies frequently question the reliability of the data. The aim of this research is to ascertain the extent to which the self-report ENR data can be considered reliable for international construction research. Inter-data reliability tests conducted to measure the levels of resemblance between the ENR data and annual report data of 51 sample companies found that, contrary to the prevalent view that companies reporting to the ENR tend to inflate their revenues, there are no systematic errors in the ENR data. Although slight discrepancies were found, ENR data can be confidently used for international construction research. Journal reviewers and editors should be more open to ENR international construction data, rather than taking the default position that the data are inherently and seriously problematic and thus automatically dismissing those studies that use such data. Journal: Construction Management and Economics Pages: 968-982 Issue: 10 Volume: 32 Year: 2014 Month: 10 X-DOI: 10.1080/01446193.2014.919403 File-URL: http://hdl.handle.net/10.1080/01446193.2014.919403 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:10:p:968-982 Template-Type: ReDIF-Article 1.0 Author-Name: Jaewhan Kim Author-X-Name-First: Jaewhan Author-X-Name-Last: Kim Author-Name: Peter Philips Author-X-Name-First: Peter Author-X-Name-Last: Philips Title: Remuneration and absenteeism on a large construction site Abstract: While scholarly consensus is that construction absenteeism is a serious and widespread problem, aggregate US and Canadian data show construction absenteeism rates substantially below cross-industry averages. While construction absenteeism research focuses on workplace culture and norms, contractors continue to manage absenteeism primarily as an individual problem. While remuneration and labour market conditions are generally acknowledged to influence construction absenteeism, little research has focused on these factors. High labour turnover in construction resolves the first two conundrums. Adapting to higher labour turnover by limiting investment in firm-specific human capital, contractors are quicker to fire absent workers reducing construction's measured absentee rates. Higher labour turnover also constrains contractors' ability to shape workplace culture while facilitating the individual treatment of absentee workers. The construction absentee literature's methodological focus on workplace surveys explains the absence of research on labour market conditioning of construction absenteeism. This case study using payroll data from a large, unionized US industrial construction site shows not only that absenteeism leads to discharge, but also, that absenteeism is a precursor of both quits and discharges for reasons other than absenteeism. Furthermore, a 1 percentage point increase in the unemployment rate reduced the probability that a worker would be fired for absenteeism by 48%; a $100 increase in weekly overtime pay reduced a worker's probability of being fired for absenteeism by 27% and a $100 increase in per diem or travel pay reduced a worker's probability of being fired for absenteeism by 75%. Journal: Construction Management and Economics Pages: 983-999 Issue: 10 Volume: 32 Year: 2014 Month: 10 X-DOI: 10.1080/01446193.2014.944550 File-URL: http://hdl.handle.net/10.1080/01446193.2014.944550 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:10:p:983-999 Template-Type: ReDIF-Article 1.0 Author-Name: Alex Albert Author-X-Name-First: Alex Author-X-Name-Last: Albert Author-Name: Matthew R. Hallowell Author-X-Name-First: Matthew R. Author-X-Name-Last: Hallowell Author-Name: Brian M. Kleiner Author-X-Name-First: Brian M. Author-X-Name-Last: Kleiner Title: Experimental field testing of a real-time construction hazard identification and transmission technique Abstract: Hazard identification and communication are integral to most construction methods, and every construction safety management activity. Unfortunately, in practice, significant hazards are often not recognized and communicated leading to sub-optimal hazard awareness at the crew level. To bridge this gap in performance, we conducted a two-year intensive research project focused on developing a strategy that increases the proportion of hazards identified, communicated, and managed. Specifically, we designed a hazard identification and transmission (HIT) board that is used in conjunction with energy-based retrieval mnemonics and facilitates identifying and communicating hazards during both the planning and the execution phases. The strength of this strategy lies in the fact that workers are able to detect and communicate hazards in real time using energy-source mnemonic cues, which significantly reduces cognitive demand. Following development, we conducted immersive field studies to evaluate the impact of the devised strategy on two projects in the United States. Data from six crews were gathered using the rigorous multiple baseline testing experimental approach and analysis was conducted using interrupted time-series regression models. The results indicate that the crews were able to recognize and communicate only an average of 54% of hazards in the baseline phase, but were able to recognize and communicate 77% during the planning phase after using the intervention. An additional 6% of hazards were identified and communicated in the execution phase. This represents the first known formal effort to evaluate a real-time hazard identification and communication strategy for the construction industry. Journal: Construction Management and Economics Pages: 1000-1016 Issue: 10 Volume: 32 Year: 2014 Month: 10 X-DOI: 10.1080/01446193.2014.929721 File-URL: http://hdl.handle.net/10.1080/01446193.2014.929721 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:10:p:1000-1016 Template-Type: ReDIF-Article 1.0 Author-Name: Yukiko Konno Author-X-Name-First: Yukiko Author-X-Name-Last: Konno Title: Default or exit? Empirical study on SMEs in the Japanese construction industry Abstract: The market size of Japan's construction industry is decreasing. Preventing several major contractors from controlling the bidding of public works projects requires a certain number of other participants to be involved. Therefore, analysing the factors that affect the defaults or exits of small and medium-sized enterprises (SMEs) can effectively contribute to the stable supply of public services and the fair competition of bids. This research examines the factors affecting the defaults and exits of prime contractors in the public works of SMEs in the Japanese construction industry. Using construction company evaluation (Keiei Jikou Sinsa or Keisin) data in Japan as a basis, the factors are analysed using the multinomial logit model. Some Keisin scores and financial and non-financial performance indicators significantly affect defaults and exits, but the influence of each variable between them differs. In particular, the findings where non-financial performance indicators are able to predict defaults and exits are unique. Consequently, if the data from SMEs are obtained, then the analytical method employed in this study is useful for predicting future exits and defaults. Journal: Construction Management and Economics Pages: 1017-1029 Issue: 10 Volume: 32 Year: 2014 Month: 10 X-DOI: 10.1080/01446193.2014.927068 File-URL: http://hdl.handle.net/10.1080/01446193.2014.927068 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:10:p:1017-1029 Template-Type: ReDIF-Article 1.0 Author-Name: Le Ma Author-X-Name-First: Le Author-X-Name-Last: Ma Author-Name: Chunlu Liu Author-X-Name-First: Chunlu Author-X-Name-Last: Liu Title: Did the late-2000s financial crisis influence construction labour productivity? Abstract: The late-2000s global financial crisis has wrought dramatic impacts on the construction industry. However, the issue of whether the crisis influenced the behaviours of the construction industry has not been addressed yet. This research presents an econometric approach to investigating the effects of the recent global financial crisis on construction labour productivity. By employing the error correction model and panel regression methods, the direct and indirect effects of the financial crisis on the changes in Australian construction labour productivity are explored at national and state levels. Neither the direct nor the indirect effects appear statistically significant. The results indicate that the direct effect of the financial crisis drives up construction labour productivity at the national level, while the indirect effect diminishes productivity. The effects of the financial crisis on the state construction labour productivity vary from state to state. The financial crisis influenced construction labour productivity directly and significantly in the northern and eastern regions, while the direct effects appear not significant in the other states and territories. The indirect effects of the financial crisis on productivity are statistically significant in three regions: the Australian Capital Territory, the Northern Territory and Western Australia. By comparison, the model with the financial effects fails to provide more accurate simulating results. As such, this research concludes that the influence of the late-2000s financial crisis on Australian national and state construction labour productivity is limited. Journal: Construction Management and Economics Pages: 1030-1047 Issue: 10 Volume: 32 Year: 2014 Month: 10 X-DOI: 10.1080/01446193.2014.944927 File-URL: http://hdl.handle.net/10.1080/01446193.2014.944927 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:10:p:1030-1047 Template-Type: ReDIF-Article 1.0 Author-Name: Robert Lundkvist Author-X-Name-First: Robert Author-X-Name-Last: Lundkvist Author-Name: John Henrik Meiling Author-X-Name-First: John Henrik Author-X-Name-Last: Meiling Author-Name: Marcus Sandberg Author-X-Name-First: Marcus Author-X-Name-Last: Sandberg Title: A proactive plan-do-check-act approach to defect management based on a Swedish construction project Abstract: In order to continuously improve quality and avoid reoccurrence of defects, defect management (DM) in construction needs to take a more proactive approach. The classification of construction information is important for the efficient exchange and integration of data between the many roles and phases of construction and facility management, but it also provides a framework for standardization, which in turn is paramount for improvement. In order to better understand how defects can be managed proactively we conducted a case study on inspection practices at a large construction project in Sweden, using observation and analysis of inspection reports. We identified opportunities and obstacles in the classification of defect data. The project's defect descriptions were often ambiguous and the records lacked important contextual information. We believe that this was because current practice is not designed with proactivity in mind, and there are only regulatory requirements on the data, making classification difficult. In addition, by viewing the project's practices through the lenses of continuous improvement and plan-do-check-act theory to identify missing or inadequate steps, we propose a framework for a proactive version of the current defect management process that could potentially help to prioritize improvement work and reduce the incidence of defects. Journal: Construction Management and Economics Pages: 1051-1065 Issue: 11 Volume: 32 Year: 2014 Month: 11 X-DOI: 10.1080/01446193.2014.966733 File-URL: http://hdl.handle.net/10.1080/01446193.2014.966733 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:11:p:1051-1065 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Moore Author-X-Name-First: Peter Author-X-Name-Last: Moore Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: Burnout of undergraduate construction management students in Australia Abstract: Burnout has been identified as a serious problem for the Australian construction industry, having negative effects at both individual and the organizational levels. While there is accumulating research into the causes and consequences of burnout for professionals working in the construction industry, we have little understanding of construction students' susceptibility to burnout. This is despite constantly increasing pressures to self-fund their studies and balance the extra demands of study, on top of work-life demands. Using the Maslach Burnout Inventory - Student Survey (MBI-SS), a survey of 369 construction management students from across eight Australian universities shows that Australian students suffer from considerably higher levels of burnout than comparative professional samples. Levels of burnout showed a relationship with both their time spent at work and their overall satisfaction with study and work life, raising important issues for both educators and employers. It was also found that academic study may not be the primary life domain of many of these students and that theoretically, the notion of work-life-study balance may be a more appropriate way, than traditional concepts of work-life balance, to conceptualize the challenges faced by these students. Journal: Construction Management and Economics Pages: 1066-1077 Issue: 11 Volume: 32 Year: 2014 Month: 11 X-DOI: 10.1080/01446193.2014.966734 File-URL: http://hdl.handle.net/10.1080/01446193.2014.966734 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:11:p:1066-1077 Template-Type: ReDIF-Article 1.0 Author-Name: Li-Ying Cheng Author-X-Name-First: Li-Ying Author-X-Name-Last: Cheng Author-Name: De-Cheng Wen Author-X-Name-First: De-Cheng Author-X-Name-Last: Wen Author-Name: Hong-Chang Jiang Author-X-Name-First: Hong-Chang Author-X-Name-Last: Jiang Title: The performance excellence model in construction enterprises: an application study with modelling and analysis Abstract: The key factors of successful application of the performance excellence model (PEM) in construction enterprises are explored from the angle of internal and external collaboration. A systematic review is employed to define the foundation of the PEM and to examine which part of the PEM can be problematic when it is applied in construction. Next, according to the research paradigm of grounded theory, TS Group is taken as a representative case to analyse the specific application of the PEM. Encoding and analysing the interview data enable the process and results chain for PEM implementation to be refined. With the help of a canonical model, the logical relationships among phenomenon, action strategy, and control results are displayed. Finally, the optimal operational framework for each key factor is designed to reveal their corresponding causal conditions, context and effect mechanism. Journal: Construction Management and Economics Pages: 1078-1092 Issue: 11 Volume: 32 Year: 2014 Month: 11 X-DOI: 10.1080/01446193.2014.956131 File-URL: http://hdl.handle.net/10.1080/01446193.2014.956131 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:11:p:1078-1092 Template-Type: ReDIF-Article 1.0 Author-Name: Martin L�wstedt Author-X-Name-First: Martin Author-X-Name-Last: L�wstedt Author-Name: Christine R�is�nen Author-X-Name-First: Christine Author-X-Name-Last: R�is�nen Title: Social identity in construction: enactments and outcomes Abstract: A social identity lens and theories of self-reinforcement are used to explore identity work and processes of identification at the micro-level in a large construction company. Rich data from a qualitative case study show that a strong collective identification is self-defining for the vast majority of managers in the organization, regardless of their role and function. This collective identification revolved around the trade of 'being a construction worker', associated with the traits of being practically oriented and of having a long professional background in construction. This collective identification seems to reinforce itself by a combination of pulling and pushing movements and/or 'being blind' vis-�-vis those that stand outside its self-defining core, content, and behaviours. The results of the study suggest that self-defining at the individual and group levels has implications for organizational performance and outcomes. It is also suggested that the use of a social identity lens can help increase understanding of interpersonal relations, collaboration, and change initiatives in the construction industry. Journal: Construction Management and Economics Pages: 1093-1105 Issue: 11 Volume: 32 Year: 2014 Month: 11 X-DOI: 10.1080/01446193.2014.956132 File-URL: http://hdl.handle.net/10.1080/01446193.2014.956132 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:11:p:1093-1105 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Anthony Bowen Author-X-Name-First: Paul Anthony Author-X-Name-Last: Bowen Author-Name: Rajen Govender Author-X-Name-First: Rajen Author-X-Name-Last: Govender Author-Name: Peter J. Edwards Author-X-Name-First: Peter J. Author-X-Name-Last: Edwards Author-Name: Keith Cattell Author-X-Name-First: Keith Author-X-Name-Last: Cattell Title: An integrated model of HIV/AIDS testing behaviour in the construction industry Abstract: The South African construction industry is one of the economic sectors most adversely affected by the HIV/AIDS pandemic. Prevalence rates exceed those of most other sectors. Little is known about the antibody testing behaviour of construction workers, and the determinants thereof. A field-administered questionnaire survey, using an item catalogue based on similar surveys, gathered data from 512 site-based construction employees in the Western Cape, South Africa. An integrated hypothesized conceptual model of testing behaviour, derived from the literature, was proposed as a starting point for data analysis. This model comprising demographic factors, lifestyle risk and condom use, alcohol consumption, drug use, knowledge about HIV/AIDS, prejudice towards HIV+ persons, and attitudinal fear of being tested, was used to explain testing behaviour. Bivariate analysis, regression modelling, and structural equation modelling were then used to test the conceptual model. A revised model was proposed. The findings indicate that: (1) employment type, alcohol consumption, drug use, and HIV/AIDS knowledge are the terminal predictors of testing behaviour; (2) knowledge about the disease is determined by education level and ethnicity; (3) age, gender, ethnicity and education behave as significant predictors of alcohol consumption; (4) drug use is predicted by employment type, education and alcohol consumption (marginally); and (5) the interrelationship between knowledge, prejudice, and fear of being tested is nuanced and complex. In strategies for positively influencing employee testing behaviour, employers should first ensure that effective communication is established with workers in all employment categories. Interventions relating to alcohol consumption and drug use by employees need particular attention. Existing peer educator training, and awareness campaign media, should be particularly sensitive to ethnic and cultural values that are likely to influence HIV/AIDS testing behaviour. Journal: Construction Management and Economics Pages: 1106-1129 Issue: 11 Volume: 32 Year: 2014 Month: 11 X-DOI: 10.1080/01446193.2014.958509 File-URL: http://hdl.handle.net/10.1080/01446193.2014.958509 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:11:p:1106-1129 Template-Type: ReDIF-Article 1.0 Author-Name: Dubem Ikediashi Author-X-Name-First: Dubem Author-X-Name-Last: Ikediashi Author-Name: Ikemefuna Mbamali Author-X-Name-First: Ikemefuna Author-X-Name-Last: Mbamali Title: Modelling the impact of outsourcing decisions on facilities management service-level performance: a case of Nigeria's public hospitals Abstract: The evolving trends within the facilities management (FM) domain over the past decades mean that it is becoming increasingly complex while the interrelationship between FM services provision and the decision to outsource has added more pressure to the issue of strategic decision management in FM. Using data from Nigeria's public hospitals, a developed conceptual model is tested in an attempt to understand the underlying attributes of outsourcing decisions and their links to FM services performance. The hypothesized model employs structural equation modelling (SEM) methodology to examine the relationships between five latent constructs of the outsourcing decision and their relative impact on FM services performance. Findings reveal that quality consideration is one of the most significant drivers impacting on service performance of FM services in hospitals. What is surprising, however, is the rejection of the proposition that strategy-related factors impact on service-level performance while social factors do not have a significant impact on service-level performance. It is hoped that these findings will contribute to the current methodological literature on the use of SEM for analysing complex interactions within the FM industry domain while they will avail practitioners of the key components of the outsourcing decision that are having the most significant impact on service performance. Journal: Construction Management and Economics Pages: 1130-1147 Issue: 11 Volume: 32 Year: 2014 Month: 11 X-DOI: 10.1080/01446193.2014.961497 File-URL: http://hdl.handle.net/10.1080/01446193.2014.961497 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:11:p:1130-1147 Template-Type: ReDIF-Article 1.0 Author-Name: Mirosław J. Skibniewski Author-X-Name-First: Mirosław J. Author-X-Name-Last: Skibniewski Title: Mobile and Pervasive Computing in Construction Journal: Construction Management and Economics Pages: 1148-1150 Issue: 11 Volume: 32 Year: 2014 Month: 11 X-DOI: 10.1080/01446193.2014.949810 File-URL: http://hdl.handle.net/10.1080/01446193.2014.949810 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:11:p:1148-1150 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Demian Author-X-Name-First: Peter Author-X-Name-Last: Demian Author-Name: David Walters Author-X-Name-First: David Author-X-Name-Last: Walters Title: The advantages of information management through building information modelling Abstract: As building information modelling (BIM) is positioned by governments and construction professionals as a solution to the problems in the construction industry, research is needed into the benefits BIM actually confers. The focus here is on the effectiveness of BIM as a medium for communicating information within a construction team. A case study of an offsite precast concrete fabrication facility was conducted. At the time of the study, the facility was supplying precast units for four public sector projects, and using four information management systems: e-mail, a construction project extranet tool, an Enterprise Resource Planning system and a new BIM-based system. The flow of information through the four media was measured and visualized as the projects progressed. This quantitative measurement of information flow was combined with qualitative data from interviews with facility staff. It was found that the introduction of the BIM-based system diverted information flow through the building model and away from the extranet system. The use of e-mail was largely unaffected. BIM allowed considerably more accurate, on-time and appropriate exchange of information. It is concluded it is possible to quantify some of the benefits of BIM to information management. This research paves the way for future research into the management of more construction project information linked more closely to building models. Journal: Construction Management and Economics Pages: 1153-1165 Issue: 12 Volume: 32 Year: 2014 Month: 12 X-DOI: 10.1080/01446193.2013.777754 File-URL: http://hdl.handle.net/10.1080/01446193.2013.777754 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:12:p:1153-1165 Template-Type: ReDIF-Article 1.0 Author-Name: Pia Storvang Author-X-Name-First: Pia Author-X-Name-Last: Storvang Author-Name: Ann H�jbjerg Clarke Author-X-Name-First: Ann H�jbjerg Author-X-Name-Last: Clarke Title: How to create a space for stakeholders' involvement in construction Abstract: The aim is to investigate how stakeholders can participate in the early phases of construction projects and how relevant insights can be gathered from stakeholders with very different backgrounds and interests. To gain these insights, it is important to understand how a space can be created to facilitate communication between professionals and stakeholders. The research draws on the literature of design and user-driven innovation in order to get a richer understanding of stakeholders' involvement in construction. The method applied is research based on three stakeholder workshops, interviews and observations from a single case study. The findings provide valuable information on six aspects of who the stakeholders are in construction, what these stakeholders can do in construction when involved, how to involve these stakeholders in a construction project, how a space can be staged and facilitated for the meeting of stakeholders, and what kind of information can be collected from the stakeholders to influence the development process. The findings show how creating and facilitating a workshop as a socio-technical space across boundaries can overcome barriers and improve stakeholders' involvement and thus provide better insights into their needs, values and concerns. Journal: Construction Management and Economics Pages: 1166-1182 Issue: 12 Volume: 32 Year: 2014 Month: 12 X-DOI: 10.1080/01446193.2014.966732 File-URL: http://hdl.handle.net/10.1080/01446193.2014.966732 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:12:p:1166-1182 Template-Type: ReDIF-Article 1.0 Author-Name: Sarel Lavy Author-X-Name-First: Sarel Author-X-Name-Last: Lavy Author-Name: John A. Garcia Author-X-Name-First: John A. Author-X-Name-Last: Garcia Author-Name: Phil Scinto Author-X-Name-First: Phil Author-X-Name-Last: Scinto Author-Name: Manish K. Dixit Author-X-Name-First: Manish K. Author-X-Name-Last: Dixit Title: Key performance indicators for facility performance assessment: simulation of core indicators Abstract: Assessing a facility's performance is important for measuring its contribution towards organizational goals. Among many approaches to performance assessment is the holistic key performance indicator (KPI) approach. However, there are numerous KPIs available, and the chosen KPI needs to be relevant to facility goals and must be calculated, analysed and evaluated to allow for the future state of the facility to be acceptable at the lowest cost. The value of several key descriptive analytics in facility performance assessment may be enhanced through the use of simulation. Simulation transforms the descriptive analytics into predictive and prescriptive analytics by allowing for the robust assessment of plans and future outcomes through the creation of multiple scenarios, in this case, for an education facility. The simulation approach quantifies the interrelationship and interdependence of KPIs, and is potentially effective in analysing how maintenance expenditures can be optimized to maintain a desired level of Condition Index as demonstrated by several simulation scenarios. Journal: Construction Management and Economics Pages: 1183-1204 Issue: 12 Volume: 32 Year: 2014 Month: 12 X-DOI: 10.1080/01446193.2014.970208 File-URL: http://hdl.handle.net/10.1080/01446193.2014.970208 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:12:p:1183-1204 Template-Type: ReDIF-Article 1.0 Author-Name: Heng Jiang Author-X-Name-First: Heng Author-X-Name-Last: Jiang Author-Name: Chunlu Liu Author-X-Name-First: Chunlu Author-X-Name-Last: Liu Title: A panel vector error correction approach to forecasting demand in regional construction markets Abstract: Reliable forecasting as to the level of aggregate demand for construction is of vital importance to developers, builders and policymakers. Previous construction demand forecasting studies mainly focused on temporal estimating using national aggregate data. The construction market can be better represented by a group of interconnected regions or local markets rather than a national aggregate, and yet regional forecasting techniques have rarely been applied. Furthermore, limited research has applied regional variations in construction markets to construction demand modelling and forecasting. A new comprehensive method is used, a panel vector error correction approach, to forecast regional construction demand using Australia's state-level data. The links between regional construction demand and general economic indicators are investigated by panel cointegration and causality analysis. The empirical results suggest that both long-run and causal links are found between regional construction demand and construction price, state income, population, unemployment rates and interest rates. The panel vector error correction model can provide reliable and robust forecasting with less than 10% of the mean absolute percentage error for a medium-term trend of regional construction demand and outperforms the conventional forecasting models (panel multiple regression and time series multiple regression model). The key macroeconomic factors of construction demand variations across regions in Australia are also presented. The findings and robust econometric techniques used are valuable to construction economists in examining future construction markets at a regional level. Journal: Construction Management and Economics Pages: 1205-1221 Issue: 12 Volume: 32 Year: 2014 Month: 12 X-DOI: 10.1080/01446193.2014.977800 File-URL: http://hdl.handle.net/10.1080/01446193.2014.977800 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:12:p:1205-1221 Template-Type: ReDIF-Article 1.0 Author-Name: Nader Naderpajouh Author-X-Name-First: Nader Author-X-Name-Last: Naderpajouh Author-Name: Makarand Hastak Author-X-Name-First: Makarand Author-X-Name-Last: Hastak Title: Quantitative analysis of policies for governance of emergent dynamics in complex construction projects Abstract: The complexity trend of construction projects is increasing, not only technologically but on several other fronts, such as the institutional diversity of the actors and the coupling of their interactions. As a result of this increase in complexity, projects frequently face the dynamics attributed to emerging actors, coalitions, contextual properties, or synergies. Reflecting this trend within the project governance framework provides a better understanding of the emergent risks that arise in the form of conflicts, project renegotiations, extreme modifications, or write-offs from projects. The aim of this study is to propose interactional analysis (IA) as a quantitative risk assessment (QRA) methodology to analyse and govern the emergent risks associated with the interactions in a system of systems (SoS), such as complex construction projects. Therefore, interactions are framed as the coupling of actors, and their associated emergent dynamics are quantified based on the equilibria of the interaction. Risk mitigation policies are then developed and analysed based on the associated interactional elements and mathematical functions. Policymakers can apply the methodology to develop policies and gauge their effectiveness in governance of the emergent dynamics within interactional contexts to overcome the challenges associated with infrastructure development. Journal: Construction Management and Economics Pages: 1222-1237 Issue: 12 Volume: 32 Year: 2014 Month: 12 X-DOI: 10.1080/01446193.2014.980835 File-URL: http://hdl.handle.net/10.1080/01446193.2014.980835 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:32:y:2014:i:12:p:1222-1237 Template-Type: ReDIF-Article 1.0 Author-Name: Jenni Korpela Author-X-Name-First: Jenni Author-X-Name-Last: Korpela Author-Name: Reijo Miettinen Author-X-Name-First: Reijo Author-X-Name-Last: Miettinen Author-Name: Teppo Salmikivi Author-X-Name-First: Teppo Author-X-Name-Last: Salmikivi Author-Name: Jaana Ihalainen Author-X-Name-First: Jaana Author-X-Name-Last: Ihalainen Title: The challenges and potentials of utilizing building information modelling in facility management: the case of the Center for Properties and Facilities of the University of Helsinki Abstract: Despite the promise of using building information modelling (BIM) during the whole life cycle of a building, there are only few studies of the actual uses of BIM and other information systems in facility management. We contribute to the discussion by analysing the Center for Properties and Facilities of the University of Helsinki. We ask (1) what kind of information tools for facility management the maintenance personnel use; (2) how the design data was handed over in the University's central library project; and (3) how designers and facility managers find the possibilities of integrating BIM models and maintenance information systems. In the library project, the data was handed over and archived for potential later use. The information for the maintenance manual, however, was collected separately by an outside consultant. The designers thought that models should be simplified to meet the needs of the maintenance. The representatives of the Center did not see that uses of BIM models would provide a significant added value in relation to the potential provided by the maintenance information systems already in use. They found as a possible next step the transfer of some information from BIM models to their facility management and maintenance systems. A partial, stepwise integration of the systems seems to be a realistic way forward. Journal: Construction Management and Economics Pages: 3-17 Issue: 1 Volume: 33 Year: 2015 Month: 1 X-DOI: 10.1080/01446193.2015.1016540 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1016540 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:1:p:3-17 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Michelle Turner Author-X-Name-First: Michelle Author-X-Name-Last: Turner Title: Improving the health of male, blue collar construction workers: a social ecological perspective Abstract: Construction workers are a high risk group for poor health and occupational disability. A participatory action research (PAR) project was undertaken at construction sites in Queensland, Australia. Using the PAR framework, a needs-based health promotion planning model was implemented. Health promotion measures were designed to address the 'SNAPO' health risk factors (i.e. smoking, nutrition, alcohol consumption, insufficient physical exercise and overweight/obesity). At the largest site participating in the research, preliminary health assessments revealed levels of physical health that were comparable with those of the general Australian population. The construction workers' mental health was poorer than that of the general Australian population. A consultation workshop with a representative group of workers at the site identified healthy eating, smoking cessation and physical exercise as priority areas for intervention. Several health promotion measures addressing these issues were implemented, including a quit smoking programme, a 'healthy options' menu in the site canteen, healthy eating and cooking workshops and onsite yoga and stretching sessions. A subset of workers at the site reported their health behaviour in weekly 'logs'. The log data revealed fluctuations in health behaviour over a 14-week period. Evaluation interviews and a focus group revealed environmental impediments to the adoption of healthy lifestyle behaviours. Workers identified the need to provide a work environment that is supportive of healthy behaviour as critical to the effectiveness of specific health promotion measures. Journal: Construction Management and Economics Pages: 18-34 Issue: 1 Volume: 33 Year: 2015 Month: 1 X-DOI: 10.1080/01446193.2014.997259 File-URL: http://hdl.handle.net/10.1080/01446193.2014.997259 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:1:p:18-34 Template-Type: ReDIF-Article 1.0 Author-Name: Yi Su Author-X-Name-First: Yi Author-X-Name-Last: Su Author-Name: Gunnar Lucko Author-X-Name-First: Gunnar Author-X-Name-Last: Lucko Title: Synthetic cash flow model with singularity functions for unbalanced bidding scenarios Abstract: Construction contractors may utilize unbalanced markup bidding strategies, e.g. front-loading, to seek more beneficial cash flows, or even protect their target profits. A difference between ethical and unethical unbalanced bidding is whether the bid has been mathematically or even materially modified: the former may be allowable, but the latter should be rejected, as it fails to cover even the cost of later activities. Unbalanced bidding adds to the complexity of cash flow models and requires a new model that can calculate different scenarios accurately and efficiently. Basic new theory is explored for unbalanced bidding in cash flow models by employing the range-based class of singularity functions. First, a new synthetic balanced cash flow model that can accurately consider the time value of money (TVM) and retainage is derived to serve as the foundation; second, various unbalanced markup functions including two-phase, linear, and non-linear types are defined both cumulatively and non-cumulatively; third, the performance of the extended synthetic cash flow model for unbalanced bidding is investigated mathematically. Journal: Construction Management and Economics Pages: 35-54 Issue: 1 Volume: 33 Year: 2015 Month: 1 X-DOI: 10.1080/01446193.2015.1012527 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1012527 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:1:p:35-54 Template-Type: ReDIF-Article 1.0 Author-Name: Rafael Sacks Author-X-Name-First: Rafael Author-X-Name-Last: Sacks Author-Name: Jennifer Whyte Author-X-Name-First: Jennifer Author-X-Name-Last: Whyte Author-Name: Dana Swissa Author-X-Name-First: Dana Author-X-Name-Last: Swissa Author-Name: Gabriel Raviv Author-X-Name-First: Gabriel Author-X-Name-Last: Raviv Author-Name: Wei Zhou Author-X-Name-First: Wei Author-X-Name-Last: Zhou Author-Name: Aviad Shapira Author-X-Name-First: Aviad Author-X-Name-Last: Shapira Title: Safety by design: dialogues between designers and builders using virtual reality Abstract: Designers can contribute to enhancing the safety of construction work by considering how their decisions impact on both the physical environment in which construction workers operate and the means and methods they use. To do so, however, designers require knowledge about safety hazards on site and the opportunity to examine their designs early in projects. Through a set of studies virtual reality tools were used to examine the potential for collaborative dialogue between designers and builders to provide a forum for learning and proactive change of a design to make a project safer to build. In the tests, participants viewed proposed designs using virtual reality to examine various alternative design and construction scenarios. The study shows that consultation and dialogue with an experienced construction professional are highly beneficial for designers to appreciate the implications of designs on safety, and that designers are more willing to adapt design details than to change aesthetic aspects of their designs. Journal: Construction Management and Economics Pages: 55-72 Issue: 1 Volume: 33 Year: 2015 Month: 1 X-DOI: 10.1080/01446193.2015.1029504 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1029504 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:1:p:55-72 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Rita Peihua Zhang Author-X-Name-First: Rita Author-X-Name-Last: Peihua Zhang Author-Name: Nick Blismas Author-X-Name-First: Nick Author-X-Name-Last: Blismas Author-Name: Ron Wakefield Author-X-Name-First: Ron Author-X-Name-Last: Wakefield Author-Name: Brian Kleiner Author-X-Name-First: Brian Author-X-Name-Last: Kleiner Title: Are we on the same page? Exploring construction professionals' mental models of occupational health and safety Abstract: Photographic Q-methodology was used to explore construction professionals' mental models of occupational health and safety (OHS). Sixty Australian construction professionals participated in the research, including 15 architects, 15 engineers, 15 constructors and 15 OHS professionals. Participants were asked to sort photographs depicting different building systems into a grid based upon their judgement of the likelihood of accidental injury resulting from the construction of each of the building systems depicted. Responses ranged from Rare (-2) to Almost certain (+2). Sorting patterns relating to eight photographs of different fa �ade systems were analysed using Q factor analysis. Three distinct sorting pattern types were identified in the data, representing clusters of participants whose sorting patterns were similar. These sorting pattern types cut across occupational/professional groups. Interpretation of the factors revealed substantial differences between the OHS judgements made by participants in the three clusters. Qualitative explanatory information revealed participants in the three clusters used different attributes when considering the likelihood of accidental injury. These attributes shaped their sorting patterns. The results suggest shared mental models (SMMs) are unlikely to exist in construction project teams, as each individual uses their own frame of reference to understand OHS. Opportunities exist to understand these different frames of reference and create more consistent team mental models of OHS. However, incorporating a diversity of viewpoints into project decision-making is recommended in order to produce effective decision-making in the choice or specification of building systems. Journal: Construction Management and Economics Pages: 73-84 Issue: 1 Volume: 33 Year: 2015 Month: 1 X-DOI: 10.1080/01446193.2015.1016541 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1016541 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:1:p:73-84 Template-Type: ReDIF-Article 1.0 Author-Name: Michaela Schaffhauser-Linzatti Author-X-Name-First: Michaela Author-X-Name-Last: Schaffhauser-Linzatti Title: People and Organizational Management in Construction Journal: Construction Management and Economics Pages: 85-89 Issue: 1 Volume: 33 Year: 2015 Month: 1 X-DOI: 10.1080/01446193.2014.993411 File-URL: http://hdl.handle.net/10.1080/01446193.2014.993411 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:1:p:85-89 Template-Type: ReDIF-Article 1.0 Author-Name: Chen-Yu Chang Author-X-Name-First: Chen-Yu Author-X-Name-Last: Chang Title: A festschrift for Graham Ive Journal: Construction Management and Economics Pages: 91-105 Issue: 2 Volume: 33 Year: 2015 Month: 2 X-DOI: 10.1080/01446193.2015.1039044 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1039044 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:2:p:91-105 Template-Type: ReDIF-Article 1.0 Author-Name: Graham M. Winch Author-X-Name-First: Graham M. Author-X-Name-Last: Winch Title: Project organizing as a problem in information Abstract: One of the most influential perspectives in business and management has been the Carnegie School, represented by such luminaries as James March, Hebert Simon, Oliver Williamson and Zur Shapira. The perspective underpins much of contemporary organization theory and organizational economics. Yet there have only been limited attempts to apply it to the domain of construction economics and management. An important exception to this statement is the application of Williamson's transaction cost economics to the governance of inter-firm relations in construction, but the opportunity is presently being missed for a more thorough-going application. The aim, therefore, is to suggest what such an application might look like and why it might be useful in stimulating new lines of research enquiry. The principal tenets of the Carnegie School are examined, as well as the central role of uncertainty and bounded rationality in those tenets. The contributions to organization theory of the Carnegie School are drawn upon to conceptualize project organizing as a problem in information, and suggest a new perspective on the microfoundations for that theory. Journal: Construction Management and Economics Pages: 106-116 Issue: 2 Volume: 33 Year: 2015 Month: 2 X-DOI: 10.1080/01446193.2015.1021703 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1021703 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:2:p:106-116 Template-Type: ReDIF-Article 1.0 Author-Name: GÖran Runeson Author-X-Name-First: GÖran Author-X-Name-Last: Runeson Author-Name: Gerard de Valence Author-X-Name-First: Gerard Author-X-Name-Last: de Valence Title: A critique of the methodology of building economics: trust the theories Abstract: Ive's most important contribution to good research was his promotion of existing theories and in particular, the use of the firm rather than the project, as the primary analytical unit. It is suggested that the current standard of research in building economics is poor, and that the failure to use existing theories shares a considerable responsibility for this problem. The predominance of poorly conceived and executed research has put us into a position where the conclusions of 80% of published research papers across the social sciences (which includes building economics) should probably be reversed because of poor methodology, research design and analysis. Peer review, rather than being one of the cornerstones of self-correcting science, is particularly problematic in building economics as it serves to isolate us from external monitoring. Replication, the second cornerstone of good science, has more or less disappeared from our journals as it's not considered prestigious. The end result is that there is no real quality control at the same time as quantity has become increasingly important for resource allocations and academic positions, seriously overextending the system for publications. The only way back to good research is to stop experimenting with fashionable but unsound methodologies and return to tried and tested theories and methodologies. Journal: Construction Management and Economics Pages: 117-125 Issue: 2 Volume: 33 Year: 2015 Month: 2 X-DOI: 10.1080/01446193.2015.1028955 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1028955 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:2:p:117-125 Template-Type: ReDIF-Article 1.0 Author-Name: Gerard de Valence Author-X-Name-First: Gerard Author-X-Name-Last: de Valence Author-Name: Goran Runeson Author-X-Name-First: Goran Author-X-Name-Last: Runeson Title: Graham Ive and the methodology of construction economics Abstract: Graham Ive's central contribution to our methodological debate was his insistence on the firm as the analytical unit. Ive argues we should reject theories if the aspect of construction we are examining does not satisfy the assumptions of a particular theoretical model. We see this in his rejection of neoclassical economic theories in the two topics discussed in this paper: the adoption of innovations in construction; and microeconomic analysis as it relates to price determination in the market for construction. The former requires studying not just participants in the building process, but also participants in the innovation process, and the latter uses post-Keynesian pricing theory where prices are set according to mark-up procedures and vary with costs, but not directly with demand. This is in contrast to the general equilibrium, perfectly competitive price setting of neoclassical economics. Ive and his collaborators show a way towards better research in their emphasis on theory and the insistence that for construction economics the analytical units are the industry and the firm, not the project. Ive's concern is that the processes involved in organizing the production of buildings should be seen as a distinctive and defining element of our analysis of the industry. Journal: Construction Management and Economics Pages: 126-133 Issue: 2 Volume: 33 Year: 2015 Month: 2 X-DOI: 10.1080/01446193.2015.1021702 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1021702 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:2:p:126-133 Template-Type: ReDIF-Article 1.0 Author-Name: Tullio Gregori Author-X-Name-First: Tullio Author-X-Name-Last: Gregori Author-Name: Roberto Pietroforte Author-X-Name-First: Roberto Author-X-Name-Last: Pietroforte Title: An input-output analysis of the construction sector in emerging markets Abstract: Construction is a major industry in fast growing countries and plays a leading role in the process of economic development. Using input-output tables, the performance of the construction sector in six emerging countries (Brazil, Russia, India, Indonesia, China and South Africa) is compared from 1995 to 2005. First, the construction performance in these developing economies, by using standard indicators based on value added, gross output, final demand and intermediate inputs, is investigated. Then, the similarity cosine index is introduced to assess structural change and differences in input expenditures between countries. This index is a useful tool for identifying input bundles that require a probing international comparison of construction performance. Journal: Construction Management and Economics Pages: 134-145 Issue: 2 Volume: 33 Year: 2015 Month: 2 X-DOI: 10.1080/01446193.2015.1021704 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1021704 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:2:p:134-145 Template-Type: ReDIF-Article 1.0 Author-Name: John Connaughton Author-X-Name-First: John Author-X-Name-Last: Connaughton Author-Name: Jim Meikle Author-X-Name-First: Jim Author-X-Name-Last: Meikle Author-Name: Satu Teerikangas Author-X-Name-First: Satu Author-X-Name-Last: Teerikangas Title: Mergers, acquisitions and the evolution of construction professional services firms Abstract: Whilst mergers and acquisitions are a favoured means of strategic renewal and expansion for firms, scant academic attention has been given to the growth patterns of construction professional services firms (CPSFs). The role of mergers and acquisitions in the evolution of CPSFs is examined. The findings are based on an analysis of the growth patterns of the top 25 CPSFs in the United Kingdom between 1988 and 2013. Since the 1990s, the increase in merger and acquisition activity has shaped the size, international presence, and multidisciplinary reach of the major CPSFs. However, CPSFs differ with respect to the intensity with which mergers and acquisitions are pursued. Whilst large, public limited companies are active acquirers, smaller and/or privately owned firms succeed in growing with a more selective acquisitive strategy, as they tend to rely more on organic growth. The findings call construction economists to attend to how acquisitions are radically changing the construction landscape and its main players. As the competitive advantage of firms is increasingly human capital-based, the example of the privately owned CPSFs that rely on organic modes of growth prompts a critical rethink of the role of mergers and acquisitions in firm growth. Journal: Construction Management and Economics Pages: 146-159 Issue: 2 Volume: 33 Year: 2015 Month: 2 X-DOI: 10.1080/01446193.2015.1037325 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1037325 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:2:p:146-159 Template-Type: ReDIF-Article 1.0 Author-Name: Tarja M�ki Author-X-Name-First: Tarja Author-X-Name-Last: M�ki Author-Name: Hannele Kerosuo Author-X-Name-First: Hannele Author-X-Name-Last: Kerosuo Title: Site managers' daily work and the uses of building information modelling in construction site management Abstract: The use of building information modelling (BIM) and related software tools is increasingly expanding in the work of site managers in construction projects. The early uses of BIM in the actual tasks of site managers are explored by examining the utilization of BIM in their work and the challenges in the deployment of the new digital tools for traditional project collaboration. The ethnographic method of the study consists of shadowing the site managers' work. The site managers actively used BIM and found it beneficial for their daily work. However, the use of BIM in construction sites is still limited because only a few managers have the competence to use BIM software tools, mobile tools are lacking, and the information content of the models needed for construction work is insufficient. Journal: Construction Management and Economics Pages: 163-175 Issue: 3 Volume: 33 Year: 2015 Month: 3 X-DOI: 10.1080/01446193.2015.1028953 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1028953 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:3:p:163-175 Template-Type: ReDIF-Article 1.0 Author-Name: Will Chancellor Author-X-Name-First: Will Author-X-Name-Last: Chancellor Author-Name: Malcolm Abbott Author-X-Name-First: Malcolm Author-X-Name-Last: Abbott Title: The Australian construction industry: is the shadow economy distorting productivity? Abstract: Estimates of the size and change in the Australian construction industry shadow economy value over time are provided and applied as a quality adjustment to Australian construction industry productivity growth from 1985 to 2012. The results indicate that the Australian construction industry shadow economy is growing and that by adjusting for the shadow economy, distortion is removed from construction industry productivity growth estimates. The findings create significant scope for future research into the estimation and the effect of shadow economic activity on productivity growth, not just in Australia but in other countries as well. Journal: Construction Management and Economics Pages: 176-186 Issue: 3 Volume: 33 Year: 2015 Month: 3 X-DOI: 10.1080/01446193.2015.1028954 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1028954 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:3:p:176-186 Template-Type: ReDIF-Article 1.0 Author-Name: Effah Ernest Ameyaw Author-X-Name-First: Effah Ernest Author-X-Name-Last: Ameyaw Author-Name: Albert P.C. Chan Author-X-Name-First: Albert P.C. Author-X-Name-Last: Chan Title: Risk allocation in public-private partnership water supply projects in Ghana Abstract: Appropriate risk allocation (RA) between public and private sectors according to their risk management (RM) capabilities is crucial for the success of public-private partnership (PPP) projects. The RA process in PPP water projects is examined, and a methodology based on fuzzy set theory is outlined with RA principles that can be used by public-private participants to arrive at fair RA decisions. Empirical data based on an industry-wide three-round Delphi questionnaire survey is used in this study to outline the methodology. The fuzzy set theory is employed for the RA analysis because it deals well with the complex multi-criteria problem of, and precisely accounts for the fuzziness inherent in human cognitive process that characterize, RA decision-making. Five risk factors are evaluated on each RA principle, analysed and assigned between the public and private sectors. The results show that it is appropriate to allocate risks according to both sectors' RM capability to manage them, using established RA principles and fuzzy set theory. The methodology renders the decision-making process more systematic and practical because the fuzzy theory approach allows decision makers to express their evaluations of both sectors' RM capabilities in descriptive qualitative terms. The results should assist public clients to establish efficient RA strategies and develop balanced RA schemes for PPP contracts, with a view to achieving a mutually acceptable RA with the private sector. Journal: Construction Management and Economics Pages: 187-208 Issue: 3 Volume: 33 Year: 2015 Month: 3 X-DOI: 10.1080/01446193.2015.1031148 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1031148 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:3:p:187-208 Template-Type: ReDIF-Article 1.0 Author-Name: Martina E. Murphy Author-X-Name-First: Martina E. Author-X-Name-Last: Murphy Author-Name: Srinath Perera Author-X-Name-First: Srinath Author-X-Name-Last: Perera Author-Name: George Heaney Author-X-Name-First: George Author-X-Name-Last: Heaney Title: Innovation management model: a tool for sustained implementation of product innovation into construction projects Abstract: Technological advancement and demand for economic growth are driving product innovation in the construction industry. However there is concern that the industry lacks the mechanisms to effectively implement new products. Recent studies have developed a method for identifying and evaluating the risks which impact on new technology adoption and two constructs were generated for improving implementation rates. The aim is to investigate whether the constructs can be integrated to develop a practical tool for use by project stakeholders desirous to generate innovation. Process modelling, statistical analysis and failure mode and effect analysis are used to align the constructs into a test model (TM). Three rounds of Delphi gain a consensus on the TM outputs and the results produce the innovation management model (IMM). The IMM is a simple process flowchart which establishes the prioritized sequence of stakeholder activities required to implement a new technology at key stages in the project process. The IMM has implications for selection of procurement methods and will instil confidence in stakeholders to adopt new technologies. Additionally it provides a risk-based approach for stakeholder competency mapping and for sustaining product innovation in construction projects. Journal: Construction Management and Economics Pages: 209-232 Issue: 3 Volume: 33 Year: 2015 Month: 3 X-DOI: 10.1080/01446193.2015.1031684 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1031684 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:3:p:209-232 Template-Type: ReDIF-Article 1.0 Author-Name: Chen-Yu Chang Author-X-Name-First: Chen-Yu Author-X-Name-Last: Chang Title: The Economics of Public-Private Partnerships: A Basic Guide Journal: Construction Management and Economics Pages: 233-238 Issue: 3 Volume: 33 Year: 2015 Month: 3 X-DOI: 10.1080/01446193.2015.1050965 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1050965 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:3:p:233-238 Template-Type: ReDIF-Article 1.0 Author-Name: Farook R. Hamzeh Author-X-Name-First: Farook R. Author-X-Name-Last: Hamzeh Author-Name: Emile Zankoul Author-X-Name-First: Emile Author-X-Name-Last: Zankoul Author-Name: Carel Rouhana Author-X-Name-First: Carel Author-X-Name-Last: Rouhana Title: How can 'tasks made ready' during lookahead planning impact reliable workflow and project duration? Abstract: The goal of lookahead planning is to make a plan more realistic as construction tasks move closer to execution. To improve the reliability of lookahead planning, the construction industry has benefited from implementing the Last Planner-super-® System (LPS) which emphasizes improved workflow during construction. Lookahead planning involves transforming work that 'should be done' into work that 'can be done'. This is accomplished by breaking down activities into the level of operations, designing operations, and making tasks ready by removing task constraints. The purpose of this research is to study, through computer simulation, the relationship between improving tasks made ready (TMR) in lookahead planning and the reliability of weekly work planning expressed as percent plan complete (PPC) and their impact on project duration. Results show that a high TMR can result in a reduced project duration but the same cannot be said about PPC, making a case for TMR serving as a better indicator for project duration than PPC. Journal: Construction Management and Economics Pages: 243-258 Issue: 4 Volume: 33 Year: 2015 Month: 4 X-DOI: 10.1080/01446193.2015.1047878 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1047878 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:4:p:243-258 Template-Type: ReDIF-Article 1.0 Author-Name: Pablo Ballesteros-P�rez Author-X-Name-First: Pablo Author-X-Name-Last: Ballesteros-P�rez Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Eugenio Pellicer Author-X-Name-First: Eugenio Author-X-Name-Last: Pellicer Author-Name: M. Carmen Gonz�lez-Cruz Author-X-Name-First: M. Carmen Author-X-Name-Last: Gonz�lez-Cruz Title: Scoring rules and abnormally low bids criteria in construction tenders: a taxonomic review Abstract: In the global construction context, the best value or most economically advantageous tender is becoming a widespread approach for contractor selection, as an alternative to other traditional awarding criteria such as the lowest price. In these multi-attribute tenders, the owner or auctioneer solicits proposals containing both a price bid and additional technical features. Once the proposals are received, each bidder's price bid is given an economic score according to a scoring rule, generally called an economic scoring formula (ESF) and a technical score according to pre-specified criteria. Eventually, the contract is awarded to the bidder with the highest weighted overall score (economic + technical). However, economic scoring formula selection by auctioneers is invariably and paradoxically a highly intuitive process in practice, involving few theoretical or empirical considerations, despite having been considered traditionally and mistakenly as objective, due to its mathematical nature. This paper provides a taxonomic classification of a wide variety of ESFs and abnormally low bids criteria (ALBC) gathered in several countries with different tendering approaches. Practical implications concern the optimal design of price scoring rules in construction contract tenders, as well as future analyses of the effects of the ESF and ALBC on competitive bidding behaviour. Journal: Construction Management and Economics Pages: 259-278 Issue: 4 Volume: 33 Year: 2015 Month: 4 X-DOI: 10.1080/01446193.2015.1059951 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1059951 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:4:p:259-278 Template-Type: ReDIF-Article 1.0 Author-Name: Benjamin Herazo Author-X-Name-First: Benjamin Author-X-Name-Last: Herazo Author-Name: Gonzalo Lizarralde Author-X-Name-First: Gonzalo Author-X-Name-Last: Lizarralde Title: The influence of green building certifications in collaboration and innovation processes Abstract: While the paradigm of sustainable development has largely influenced architecture projects worldwide, Green Building Certifications (GBCs) have become the new (increasingly mandatory) standard of project performance. Numerous studies have concentrated on the influence of sustainable development (SD) in the final product: the building. However, more research is still needed in order to understand how GBCs have influenced building processes, particularly collaboration and innovation within architecture projects. In order to fill this gap, this study presents results from 19 interviews with professionals in the built environment and examines three architecture projects conducted in Canada that received a widely popular GBC and were significantly influenced by SD principles during the design and building process. The research applies recent frameworks for exploring stakeholders' interests on GBCs and the collaboration and innovation practices developed by them. Research results show that processes within these projects are shaped by at least four tensions that can either enhance or hinder collaboration and innovation: strategic-tactical, collaborative-competitive, participative-effective and individual-collective. The study highlights the importance of understanding GBC as a process and not only as a final outcome, and thus, to better manage these tensions so that they contribute to product and process performance. Journal: Construction Management and Economics Pages: 279-298 Issue: 4 Volume: 33 Year: 2015 Month: 4 X-DOI: 10.1080/01446193.2015.1047879 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1047879 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:4:p:279-298 Template-Type: ReDIF-Article 1.0 Author-Name: Jessica Kaminsky Author-X-Name-First: Jessica Author-X-Name-Last: Kaminsky Title: The fourth pillar of infrastructure sustainability: tailoring civil infrastructure to social context Abstract: This research proposes technical performance over time as a fourth pillar of sustainability theory for infrastructure. It also describes a method that allows us to discover how changes in the technical pillar (operationalized as reduced breakage rates) may moderate the influence of the social pillar (operationalized as repair rates) on sanitation infrastructure outcomes. Oral histories were used to develop a history of sanitation for each of 152 poor households in four rural communities in Bangladesh that have gained access to sanitation in the past decade. Transcriptions and qualitative coding identified reported states of sanitation (for example, broken vs. functional) at three time steps. These were used to develop an initial vector and transition matrix for a Markov chain analysis. The breakage rate in this model was then adjusted to investigate the impact of improved technical durability on sanitation outcomes. For the case analysed here, we found that increasing infrastructure durability by 50% (an estimated increase of two years) increased the rate of functional sanitation system use at model convergence from 54% to 88%. Increases in durability also caused households to use private rather than shared systems. Beyond this specific case, the generalizable theory and method presented here are analytic tools that permit targeted technical accommodation of social contexts specific to individual project sites. Journal: Construction Management and Economics Pages: 299-309 Issue: 4 Volume: 33 Year: 2015 Month: 4 X-DOI: 10.1080/01446193.2015.1050425 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1050425 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:4:p:299-309 Template-Type: ReDIF-Article 1.0 Author-Name: M. Loosemore Author-X-Name-First: M. Author-X-Name-Last: Loosemore Author-Name: B. Lim Author-X-Name-First: B. Author-X-Name-Last: Lim Title: Inter-organizational unfairness in the construction industry Abstract: There are numerous examples of unfair inter-organizational business practices in the construction industry. Conflict and confrontation, corruption, bid-shopping, insecurity of payment and supply chain exploitation are just some examples which have been documented over several decades in many countries. There have been numerous initiatives to make the construction industry a fairer business environment, but these have been largely developed in a conceptual vacuum. Consequently, few advances have been made in making the industry a fairer place to do business. To address the lack of theory in this area and provide a conceptual foundation for future improvement, theories of organizational justice were used as the basis for a survey of 135 consultants, contractors, subcontractors and suppliers from across the Australian construction supply chain. The findings reveal that mainstream theories of justice may need refinement and reorganization to be applied to a construction industry context. Furthermore, in contrast to much previous research, the results indicate that levels of interpersonal, social and informational justice are high within the Australian construction industry. However, they also show that more can be done to improve levels of procedural and distributive justice, particularly in relation to subcontractors and suppliers in the construction supply chain. Many of these findings are transferable to other countries which are culturally, contractually and organizationally similar to the Australian construction industry. Journal: Construction Management and Economics Pages: 310-326 Issue: 4 Volume: 33 Year: 2015 Month: 4 X-DOI: 10.1080/01446193.2015.1057193 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1057193 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:4:p:310-326 Template-Type: ReDIF-Article 1.0 Author-Name: Ani Raiden Author-X-Name-First: Ani Author-X-Name-Last: Raiden Author-Name: Simon Smith Author-X-Name-First: Simon Author-X-Name-Last: Smith Title: Conference issue: 30th Annual ARCOM Conference Journal: Construction Management and Economics Pages: 329-333 Issue: 5-6 Volume: 33 Year: 2015 Month: 6 X-DOI: 10.1080/01446193.2015.1080905 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1080905 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:5-6:p:329-333 Template-Type: ReDIF-Article 1.0 Author-Name: Matilda H��k Author-X-Name-First: Matilda Author-X-Name-Last: H��k Author-Name: Lars Stehn Author-X-Name-First: Lars Author-X-Name-Last: Stehn Author-Name: Staffan Brege Author-X-Name-First: Staffan Author-X-Name-Last: Brege Title: The development of a portfolio of business models: a longitudinal case study of a building material company Abstract: Dynamic aspects of intended company change can be related to the development and management of a portfolio of business models with regard to competence deployment and to performance. A portfolio of business models is seen as a reflection of the realized strategy of a company, and the dynamics aspects of company change are connected to internal and external critical strategic incidents. The business model elements considered in this research are market position, offering, and operational platform enabling a differentiation between strategic and operational effectiveness. The evolution of a Swedish supplier of building components and systems during a 15-year period is examined. The process data consists of temporal phases where a shift of phase is defined as a change of a specific portfolio of business models. The concept of a portfolio of business models helped to discover new and conflicting standardized or customized business models that were not always intended by the company. The findings indicate that unawareness of intended actions led to unintended allocation of resources or integration mechanisms that negatively affected company performance. On the other hand gains can be achieved if a strategy is deliberately managed as a portfolio of business models which then also can be a tool for managing change in a company. Journal: Construction Management and Economics Pages: 334-348 Issue: 5-6 Volume: 33 Year: 2015 Month: 6 X-DOI: 10.1080/01446193.2015.1075052 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1075052 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:5-6:p:334-348 Template-Type: ReDIF-Article 1.0 Author-Name: Philippa Boyd Author-X-Name-First: Philippa Author-X-Name-Last: Boyd Author-Name: Graeme D. Larsen Author-X-Name-First: Graeme D. Author-X-Name-Last: Larsen Author-Name: Libby Schweber Author-X-Name-First: Libby Author-X-Name-Last: Schweber Title: The co-development of technology and new buildings: incorporating building integrated photovoltaics Abstract: Current approaches for the reduction of carbon emissions in buildings are often predicated on the integration of renewable technologies into building projects. Building integrated photovoltaics (BIPV) is one of these technologies and brings its own set of challenges and problems with a resulting mutual articulation of this technology and the building. A Social Construction of Technology (SCOT) approach explores how negotiations between informal groups of project actors with shared interests shape the ongoing specification of both BIPV and the building. Six main groups with different interests were found to be involved in the introduction of BIPV (Cost Watchers, Design Aesthetes, Green Guardians, Design Optimizers, Generation Maximizers and Users). Their involvement around three sets of issues (design changes from lack of familiarity with the technology, misunderstandings from unfamiliar interdependencies of trades and the effects of standard firm procedure) is followed. Findings underline how BIPV requires a level of integration that typically spans different work packages and how standard contractual structures inhibit the smooth incorporation of BIPV. Successful implementation is marked by ongoing (re-)design of both the building and the technology as informal fluid groups of project actors with shared interests address the succession of problems which arise in the process of implementation. Journal: Construction Management and Economics Pages: 349-360 Issue: 5-6 Volume: 33 Year: 2015 Month: 6 X-DOI: 10.1080/01446193.2015.1074262 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1074262 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:5-6:p:349-360 Template-Type: ReDIF-Article 1.0 Author-Name: Fred Sherratt Author-X-Name-First: Fred Author-X-Name-Last: Sherratt Author-Name: Martin Crapper Author-X-Name-First: Martin Author-X-Name-Last: Crapper Author-Name: Lydia Foster-Smith Author-X-Name-First: Lydia Author-X-Name-Last: Foster-Smith Author-Name: Sinead Walsh Author-X-Name-First: Sinead Author-X-Name-Last: Walsh Title: Safety and volunteer construction workers Abstract: The construction industry is dangerous, with 39 fatalities at work in the UK in 2012/13 and comparable and even larger figures reported worldwide. People also take part in construction on a voluntary basis; most volunteers have limited training and no technical qualification, whilst safety regulation frameworks range from being comparable to professional sectors to zero regulation in some international contexts. Unstructured interviews were undertaken with volunteer construction workers from two areas: those returning from international development projects and those regularly volunteering on UK heritage railways. Taking a social constructionist perspective, data was explored using discourse analysis to illuminate 'safety' within this unique construction 'industry'. Those with engineering or technical backgrounds developed more tangible constructions of safety, around risks and hazards, within their activities, yet volunteers without this experience also acknowledged a wider context of danger. Volunteers on overseas projects developed discourses of 'difference' between safety at home and safety outside the UK, associated with negative practices overseas yet with acceptance of their inevitability as part of the voluntary experience. Further work is proposed to determine whether these insights can contribute to improved safety management within the voluntary construction context. Journal: Construction Management and Economics Pages: 361-374 Issue: 5-6 Volume: 33 Year: 2015 Month: 6 X-DOI: 10.1080/01446193.2015.1024269 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1024269 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:5-6:p:361-374 Template-Type: ReDIF-Article 1.0 Author-Name: Natalie Galea Author-X-Name-First: Natalie Author-X-Name-Last: Galea Author-Name: Abigail Powell Author-X-Name-First: Abigail Author-X-Name-Last: Powell Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Louise Chappell Author-X-Name-First: Louise Author-X-Name-Last: Chappell Title: Designing robust and revisable policies for gender equality: lessons from the Australian construction industry Abstract: The construction industry remains the most male dominated sector in Australia. Several decades of formal gender equality initiatives by government and business have failed to bring about any meaningful change to the hierarchical and numerical representation of women in the sector. Drawing on new institutionalism, particularly the concepts of 'robustness' and 'revisability', the nature and intent of formal policies and programs that impact on gender equality are analysed in two large Australian multinational construction firms. Through in-depth interviews with senior management and a document analysis of formal policies, it is concluded that gender equality initiatives and broader policies are primarily focused on increasing the numbers of women in construction rather than addressing gender practices and outcomes. These policies lack many of the qualities of robustness and revisability, which impacts on their capacity to genuinely challenge the gendered norms, practices and narratives of the sector. Journal: Construction Management and Economics Pages: 375-389 Issue: 5-6 Volume: 33 Year: 2015 Month: 6 X-DOI: 10.1080/01446193.2015.1042887 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1042887 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:5-6:p:375-389 Template-Type: ReDIF-Article 1.0 Author-Name: Jonathan Gosling Author-X-Name-First: Jonathan Author-X-Name-Last: Gosling Author-Name: Mohamed Naim Author-X-Name-First: Mohamed Author-X-Name-Last: Naim Author-Name: Denis Towill Author-X-Name-First: Denis Author-X-Name-Last: Towill Author-Name: Wessam Abouarghoub Author-X-Name-First: Wessam Author-X-Name-Last: Abouarghoub Author-Name: Brian Moone Author-X-Name-First: Brian Author-X-Name-Last: Moone Title: Supplier development initiatives and their impact on the consistency of project performance Abstract: Many empirical studies exploring the impact of supply chain management on performance metrics have been undertaken in the manufacturing and retail sectors, espousing the positive outcomes attainable. Owing to a range of industry characteristics, some have questioned the effectiveness of such initiatives in the construction sector, and it has been noted that there is a lack of longitudinal empirical data in this setting. Exploiting a unique performance dataset gathered from a global construction company's archival records (1990-2013), the following question is addressed: 'what is the impact of supplier development initiatives on key performance indicators (KPIs) in a construction supply chain?'. Mobilizing established frameworks on relationship types and supplier development initiatives, suppliers are organized into relational categories, including 'strategic partners', 'preferred' and 'approved' suppliers. A combination of descriptive statistics, ANOVA and Levene's tests was used to analyse the data. The findings report a significant difference between the volatility of performance between different groups. The higher the level of partnership in the relational category, the more consistency there will be in performance. Suppliers in the approved category perform less well on the 'closeout' KPI, suggesting a need for initiatives with this category to help raise performance on closeout issues. Journal: Construction Management and Economics Pages: 390-403 Issue: 5-6 Volume: 33 Year: 2015 Month: 6 X-DOI: 10.1080/01446193.2015.1028956 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1028956 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:5-6:p:390-403 Template-Type: ReDIF-Article 1.0 Author-Name: Martin L�wstedt Author-X-Name-First: Martin Author-X-Name-Last: L�wstedt Title: 'Taking off my glasses in order to see': exploring practice on a building site using self-reflexive ethnography Abstract: There has recently been a growing interest for ethnographic studies in construction, predicated upon the belief that ethnographic research in the construction industry can provide a powerful way of illuminating construction practices in new ways. Focusing on the ethnographic method, it is demonstrated how a self-reflexive ethnography can contribute to a deeper understanding of the variations, contradictions and tensions underlying practices on a building site, thereby serving as a complement to other qualitative approaches. A short four-week ethnographic study illustrates how the subjective 'I' of the ethnographer can be used as an active producer of knowledge, by reflecting on how insights from an individual's role, both as an observer and as a worker, can account for the complex interplay between socialities and materialities on a building site. The results also contribute to the discussion regarding the length of ethnographic studies, by showing how valuable insights can be drawn from shorter 'ethnographic episodes', studied through a self-reflexive lens. Journal: Construction Management and Economics Pages: 404-414 Issue: 5-6 Volume: 33 Year: 2015 Month: 6 X-DOI: 10.1080/01446193.2015.1066021 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1066021 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:5-6:p:404-414 Template-Type: ReDIF-Article 1.0 Author-Name: Dennis O'Keeffe Author-X-Name-First: Dennis Author-X-Name-Last: O'Keeffe Author-Name: Derek Thomson Author-X-Name-First: Derek Author-X-Name-Last: Thomson Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Title: Evaluating the design of hospitals within a practice order network Abstract: Design evaluation is a complex and rich social practice that is organized and distinguished by its practical understandings, rules, general understandings and teleoaffective structures. This praxiographic study of a major National Health Service (NHS) hospital project uses practice theory to investigate the concept of design evaluation as 'a practice'. By applying Theodore Schatzki's site ontology, design evaluation practices are revealed to respond to dynamic teleoaffective structures that highlight the role of both practical intelligibility and the intertwined impact of external policy stipulations. Through this theoretical lens, fresh insight into the actuality of NHS hospital design evaluation praxis is provided that questions some of the axioms upon which such processes are assumed to operate. In particular, the appropriateness of the decontextualized and deterministic processes currently found in UK government design policy is questioned. It is posited that an approach to design evaluation grounded in Schatzki's practice theory has greater potential to improve the design quality of NHS healthcare buildings that could, in turn, improve patient healthcare outcomes. Journal: Construction Management and Economics Pages: 415-427 Issue: 5-6 Volume: 33 Year: 2015 Month: 6 X-DOI: 10.1080/01446193.2015.1072639 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1072639 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:5-6:p:415-427 Template-Type: ReDIF-Article 1.0 Author-Name: Lone Seboni Author-X-Name-First: Lone Author-X-Name-Last: Seboni Author-Name: Apollo Tutesigensi Author-X-Name-First: Apollo Author-X-Name-Last: Tutesigensi Title: Project manager-to-project allocations in practice: an empirical study of the decision-making practices of a multi-project based organization Abstract: Empirical studies that examine how managers make project manager-to-project (PM2P) allocation decisions in multi-project settings are currently limited. Such decisions are crucial to organizational success. An empirical study of the PM2P practice, conducted in the context of Botswana, revealed ineffective processes in terms of optimality in decision-making. A conceptual model to guide effective PM2P practices was developed. The focus of this study is on deploying the model as a lens to study the PM2P practices of a large organization, with a view to identifying and illustrating strengths and weaknesses. A case study was undertaken in the mining industry, where core activities in terms of projects are underground mineral explorations at identified geographical regions. A semi-structured interview protocol was used to collect data from 15 informants, using an enumeration. Integrated analysis of both data types (using univariate descriptive analysis for the quantitative data, content and thematic analysis for the qualitative data) revealed strengths in PM2P practices, demonstrated by informants' recognition of some important criteria to be considered. The key weaknesses were exemplified by a lack of effective management tools and techniques to match project managers to projects. The findings provide a novel perspective through which improvements in working practices can be made. Journal: Construction Management and Economics Pages: 428-443 Issue: 5-6 Volume: 33 Year: 2015 Month: 6 X-DOI: 10.1080/01446193.2015.1077981 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1077981 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:5-6:p:428-443 Template-Type: ReDIF-Article 1.0 Author-Name: Fred Sherratt Author-X-Name-First: Fred Author-X-Name-Last: Sherratt Title: Legitimizing public health control on sites? A critical discourse analysis of the Responsibility Deal Construction Pledge Abstract: As part of a wider programme, the UK Department of Health produced a Responsibility Deal Construction Pledge, seeking organizational commitment in improving the health of its workforce. Yet commercial involvement with the health of the worker beyond the workplace is a contentious issue, a fundamental challenge to personal freedoms. The exercise of this paternalistic or pastoral power should be questioned, and consequently the agendas and interests behind it have been explored through a critical discourse analysis of the press release of the Pledge. Workers' inability to make the 'right' decisions about their health was used as justification for corporate intervention to guide workers to their 'true' interests and the 'right' choices. The occupational health of individual construction workers on sites was negated for their wider contributions as a workforce to industry and the UK economy. Whilst the real interests of construction workers are likely to be served by a balance of good health and work, this should not be dictated by government, much less commercial organizations with vested interests in worker output. Concerns are raised for workers' health and well-being in terms of their fundamental autonomy, and an increasingly controlled relationship between productive activities and power relations. Journal: Construction Management and Economics Pages: 444-452 Issue: 5-6 Volume: 33 Year: 2015 Month: 6 X-DOI: 10.1080/01446193.2015.1013045 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1013045 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:5-6:p:444-452 Template-Type: ReDIF-Article 1.0 Author-Name: Amna Shibeika Author-X-Name-First: Amna Author-X-Name-Last: Shibeika Author-Name: Chris Harty Author-X-Name-First: Chris Author-X-Name-Last: Harty Title: Diffusion of digital innovation in construction: a case study of a UK engineering firm Abstract: The UK government is mandating the use of building information modelling (BIM) in large public projects by 2016. As a result, engineering firms are faced with challenges related to embedding new technologies and associated working practices for the digital delivery of major infrastructure projects. Diffusion of innovations theory is used to investigate how digital innovations diffuse across complex firms. A contextualist approach is employed through an in-depth case study of a large, international engineering project-based firm. The analysis of the empirical data, which was collected over a four-year period of close interaction with the firm, reveals parallel paths of diffusion occurring across the firm, where both the innovation and the firm context were continually changing. The diffusion process is traced over three phases: centralization of technology management, standardization of digital working practices, and globalization of digital resources. The findings describe the diffusion of a digital innovation as multiple and partial within a complex social system during times of change and organizational uncertainty, thereby contributing to diffusion of innovations studies in construction by showing a range of activities and dynamics of a non-linear diffusion process. Journal: Construction Management and Economics Pages: 453-466 Issue: 5-6 Volume: 33 Year: 2015 Month: 6 X-DOI: 10.1080/01446193.2015.1077982 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1077982 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:5-6:p:453-466 Template-Type: ReDIF-Article 1.0 Author-Name: Serdar Ulubeyli Author-X-Name-First: Serdar Author-X-Name-Last: Ulubeyli Author-Name: Volkan Arslan Author-X-Name-First: Volkan Author-X-Name-Last: Arslan Author-Name: Serkan Kivrak Author-X-Name-First: Serkan Author-X-Name-Last: Kivrak Title: A semiotic analysis of cartoons about occupational health and safety issues in the construction workplace Abstract: The construction industry in developed and developing countries is almost always among industries with poor safety records. In decreasing the numbers of safety incidents, society's perception of construction workers, who are the central part of the occupational health and safety issue, can be an important learning tool for these workers in terms of self-criticism. Therefore, society's perception of the responsibility of workers for occupational health and safety is presented by means of cartoons. For this objective, seven cartoons exhibited in the International Construction Accidents Cartoon Contest held in Turkey are examined through the General Theory of Verbal Humour, a semiotic analysis method. As the main finding, construction-based occupational health and safety perceptions of countries were found not to change significantly. Consequently, these results can have a function in guiding workers and worker unions to revise and manage the general perception of society about them. Moreover, such cartoons can be used as a lingua franca for occupational health and safety training in international construction projects where multinational migrant workers are employed. Journal: Construction Management and Economics Pages: 467-483 Issue: 5-6 Volume: 33 Year: 2015 Month: 6 X-DOI: 10.1080/01446193.2015.1024270 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1024270 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:5-6:p:467-483 Template-Type: ReDIF-Article 1.0 Author-Name: Anders Viking Author-X-Name-First: Anders Author-X-Name-Last: Viking Author-Name: Sofia Lidel�w Author-X-Name-First: Sofia Author-X-Name-Last: Lidel�w Title: Exploring industrialized housebuilders' interpretations of local requirements using institutional logics Abstract: Industrialized housebuilding contractors use standardized processes and building systems to improve time and cost efficiency. Recent governmental investigations argue that Swedish local planning authorities' requirement setting practices stifle the potential for increased industrialization. Yet, no previous research has accounted for the industrialized housebuilders' perspective. We aim to explore industrialized housebuilders' interpretations of local requirement setting, using institutional logics to increase the understanding of how structure and human agency influence the emergence of local requirements. Interviews were conducted with representatives of five industrialized housebuilders who together span the Swedish multi-family housing market. Findings indicate that industrialized housebuilders do not perceive intentional local requirement setting as problematic, yet struggle to cope with interpretive local requirement setting. Findings also necessitate distinguishing local requirement setting in the exercise of public authority from local requirement setting in public procurement. The agency structure dualism contributes an understanding of interpretive local requirement setting in the exercise of public authority as an expression of agency and of local requirement setting in public procurement as one of structure. Furthermore, using an institutional logics approach is found to provide an accentuation of human agency and the individual level of analysis that is often absent from construction management research. Journal: Construction Management and Economics Pages: 484-494 Issue: 5-6 Volume: 33 Year: 2015 Month: 6 X-DOI: 10.1080/01446193.2015.1050966 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1050966 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:5-6:p:484-494 Template-Type: ReDIF-Article 1.0 Author-Name: Bo Xiong Author-X-Name-First: Bo Author-X-Name-Last: Xiong Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Bo Xia Author-X-Name-First: Bo Author-X-Name-Last: Xia Title: Exploring and validating the internal dimensions of occupational stress: evidence from construction cost estimators in China Abstract: A recurring feature of modern practice is occupational stress of project professionals, with debilitating effects on the people concerned and indirectly affecting project success. Previous research outside the construction industry has involved the use of a psychology perceived stress questionnaire (PSQ) to measure occupational stress, resulting in the identification of one stressor, demand, and three sub-dimensional emotional reactions in terms of worry, tension and joy. The PSQ is translated into Chinese with a back translation technique and used in a survey of young construction cost professionals in China. Principal component analysis and confirmatory factor analysis are used to test the divisibility of occupational stress, little mentioned in previous research on stress in the construction context. In addition, structural equation modelling is used to assess nomological validity by testing the effects of the three dimensions on organizational commitment, the main finding of which is that lack of joy has the sole significant effect. The three-dimensional measurement framework facilitates the standardizing measurement of occupational stress. Further research will establish whether the findings are also applicable in other settings and explore the relations between stress dimensions and other managerial concepts. Journal: Construction Management and Economics Pages: 495-507 Issue: 5-6 Volume: 33 Year: 2015 Month: 6 X-DOI: 10.1080/01446193.2015.1050967 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1050967 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:5-6:p:495-507 Template-Type: ReDIF-Article 1.0 Author-Name: Anne Kokkonen Author-X-Name-First: Anne Author-X-Name-Last: Kokkonen Author-Name: Pauli Alin Author-X-Name-First: Pauli Author-X-Name-Last: Alin Title: Practice-based learning in construction projects: a literature review Abstract: Construction project managers often face problems when trying to change work practices. Management research addresses these problems by offering stylized and abstract models; unfortunately, they may say little about the actual work practices that managers want to change. Practice theory offers an alternative way to address practice-related managerial problems, arguing that learning is a central enabler of performing practices. While some early research on practice-based learning in construction management exists, an understanding of how this theory has been applied is lacking. To address this limitation, a systematic literature review of 15 published construction management articles was conducted, the articles being divided into five practice-related analytical categories: participation, context, meaning production, power and becoming a practitioner to identify the areas of theory discussed. Participation and context were discussed more in the published articles than meaning production, power and becoming a practitioner, which might suggest that the latter categories offer more possibilities for future research. Further, the articles were analysed through a Lakatosian research programme lens, showing that a progressive research programme exists in practice-based studies in construction management. These findings provide avenues for future construction management studies seeking to apply practice-based learning theory to understand learning in construction projects better. Journal: Construction Management and Economics Pages: 513-530 Issue: 7 Volume: 33 Year: 2015 Month: 7 X-DOI: 10.1080/01446193.2015.1062903 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1062903 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:7:p:513-530 Template-Type: ReDIF-Article 1.0 Author-Name: Yuvraj Gajpal Author-X-Name-First: Yuvraj Author-X-Name-Last: Gajpal Author-Name: Ashraf Elazouni Author-X-Name-First: Ashraf Author-X-Name-Last: Elazouni Title: Enhanced heuristic for finance-based scheduling of construction projects Abstract: Typically, construction contractors operate under cash-constrained operating conditions. The lag between the time when contractors spend money to accomplish work on site and the time when payments are actually made by clients, which partially compensate contractors for the accomplished work, constantly creates a finance deficit. Contractors often supplement finance deficits using external funds procured through establishing credit-line bank accounts which typically allow contractors to withdraw cash up to specified credit limits. This makes the task of project scheduling considering the constraints of specified finance very important for financial and operational planning. This scheduling concept and technique are referred to as finance-based scheduling. An enhanced heuristic is proposed to devise finance-based schedules of multiple projects within contractors' portfolios. The enhancement is achieved by replacing the exhaustive enumeration technique employed in the heuristic to specify activities' start times with a polynomial shifting algorithm. This enhancement resulted in a substantial reduction in the number of solutions explored before a feasible solution is encountered. The enhanced heuristic was validated through comparison with the integer programming technique using 240 problems of randomly generated networks of sizes that range from 30 to 240 activities. Further, it was proved that the enhanced heuristic can be easily scaled up to handle portfolios of multiple large-size projects. Journal: Construction Management and Economics Pages: 531-553 Issue: 7 Volume: 33 Year: 2015 Month: 7 X-DOI: 10.1080/01446193.2015.1063676 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1063676 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:7:p:531-553 Template-Type: ReDIF-Article 1.0 Author-Name: Hans Lind Author-X-Name-First: Hans Author-X-Name-Last: Lind Author-Name: Fredrik Brunes Author-X-Name-First: Fredrik Author-X-Name-Last: Brunes Title: Explaining cost overruns in infrastructure projects: a new framework with applications to Sweden Abstract: The aim is to both develop a new theory-based framework for analysing cost overruns, and to use this for an empirical study of cost overruns in infrastructure projects in Sweden. The conceptual part is based on a literature review and the empirical part is primarily based on a questionnaire to project managers. The framework has a descriptive part comprising two dimensions: when, during the process, the cost overrun arose and what part of the cost function was responsible: change in the product, change in quantities of the inputs and change in price of inputs. The explanatory part is a development of Flyvbjerg's theories and identifies four possible explanations: political/strategic aspects, psychological aspects, competence-related aspects and bad luck. The result from the empirical study is that most cost overruns occur in the initiation and planning stages up to the final design and are related to design changes and increases in the amount of inputs needed because of technical and administrative problems. Of the explanatory factors, there is most support for lack of competence and optimism bias. Journal: Construction Management and Economics Pages: 554-568 Issue: 7 Volume: 33 Year: 2015 Month: 7 X-DOI: 10.1080/01446193.2015.1064983 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1064983 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:7:p:554-568 Template-Type: ReDIF-Article 1.0 Author-Name: Tim Snippert Author-X-Name-First: Tim Author-X-Name-Last: Snippert Author-Name: Wiebe Witteveen Author-X-Name-First: Wiebe Author-X-Name-Last: Witteveen Author-Name: Hans Boes Author-X-Name-First: Hans Author-X-Name-Last: Boes Author-Name: Hans Voordijk Author-X-Name-First: Hans Author-X-Name-Last: Voordijk Title: Barriers to realizing a stewardship relation between client and vendor: the Best Value approach Abstract: This study identifies barriers to realizing a stewardship relation instead of a classic principal-agent relation between client and vendor through implementation of an innovative procurement and risk management method, the Best Value approach. This approach focuses on calculus-based trust development through the use of metrics and alignment of goals and risks between client and vendor. Barriers to realizing a stewardship relation are analysed with the use of a theoretical framework that incorporates agency theory and stewardship theory. Data was collected in 2013 and 2014 through project documentation and interviews for four case studies at the Dutch Highways Agency. Collected data was used to analyse the roles of the client and vendor, the scope and level of the products and the overall process of the clarification phase of the Best Value approach to identify barriers in practice. Case study findings are analysed and explained by agency theory and stewardship theory. From a theoretical perspective the Best Value approach shows large similarities with stewardship theory. In practice, however, the cases show that the often traditional background of project teams and the lack of experience with Best Value result in a control-oriented relationship between client and vendor characterized by information asymmetry, lack of transparency and distrust. These characteristics of the relationship between client and vendor inhibit the realization of a stewardship relation using the Best Value approach. Journal: Construction Management and Economics Pages: 569-586 Issue: 7 Volume: 33 Year: 2015 Month: 7 X-DOI: 10.1080/01446193.2015.1078902 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1078902 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:7:p:569-586 Template-Type: ReDIF-Article 1.0 Author-Name: Ka Chi Lam Author-X-Name-First: Ka Chi Author-X-Name-Last: Lam Author-Name: Olalekan Shamsideen Oshodi Author-X-Name-First: Olalekan Shamsideen Author-X-Name-Last: Oshodi Title: The capital budgeting evaluation practices (2014) of contractors in the Hong Kong construction industry Abstract: Capital budget evaluation plays a crucial role in financial management. This places a firm in a competitive position. Recent development points to the need for implementing capital budgeting in construction organizations due to the capital-intensive nature of construction business. The aim here is to investigate the trends in the practice of capital budget evaluation among construction contractors operating in Hong Kong over a 20-year period. A longitudinal survey approach is used; four cross-sectional surveys were conducted between 1994 and 2014. The findings indicate that 'formal financial evaluation' is the most common technique used for capital budget evaluation. In addition, the practice of capital budget evaluation is more pronounced in the large-sized firms. A comparative analysis of the results of the four surveys reveals that there are variations in the degree and frequency of use of capital budget evaluation techniques over the study period. Further research is needed to understand the challenges associated with the use of sophisticated capital budget evaluation techniques in the construction industry of Hong Kong. Journal: Construction Management and Economics Pages: 587-600 Issue: 7 Volume: 33 Year: 2015 Month: 7 X-DOI: 10.1080/01446193.2015.1073852 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1073852 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:7:p:587-600 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Pryke Author-X-Name-First: Stephen Author-X-Name-Last: Pryke Author-Name: Damir Lunic Author-X-Name-First: Damir Author-X-Name-Last: Lunic Author-Name: Sulafa Badi Author-X-Name-First: Sulafa Author-X-Name-Last: Badi Title: The effect of leader emotional intelligence on leader-follower chemistry: a study of construction project managers Abstract: Extending Nicolini's notion of project 'chemistry', a 'leader-follower chemistry' model associated with the quality of dyadic interpersonal communication in construction projects is developed. The focus is on the project manager as leader in an attempt to deepen understanding of the effect of a project manager's emotional intelligence (EI) on the quality of interpersonal communication with their followers, being other members of the project team. While a project manager's EI, with its associated emotional competencies, is often seen as critical in achieving good relationships with members of the project team, it remains a largely understudied concept, particularly in construction projects. Primary data collected using a series of analytical surveys and live observations of site-based project meetings was used to examine the relationship between a project manager's emotional competencies, particularly sensitivity and expressiveness, and leader-follower chemistry. Overall, 68 construction professionals participated in the study. The findings suggest that a project manager's emotional sensitivity and expressiveness (particularly head gestures) may explain variance in the quality of leader-follower chemistry. Based on the empirical evidence in the context of team communication, a leader-follower chemistry model is introduced, which emphasizes the importance of leaders' emotional sensitivity and expressiveness in a leader-follower communication dyad. The model may be particularly salient in complex project networks with a large number of prominent actors. Journal: Construction Management and Economics Pages: 603-624 Issue: 8 Volume: 33 Year: 2015 Month: 8 X-DOI: 10.1080/01446193.2015.1078901 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1078901 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:8:p:603-624 Template-Type: ReDIF-Article 1.0 Author-Name: Abdulaziz M. Jarkas Author-X-Name-First: Abdulaziz M. Author-X-Name-Last: Jarkas Author-Name: R. Malcolm W. Horner Author-X-Name-First: R. Malcolm W. Author-X-Name-Last: Horner Title: Creating a baseline for labour productivity of reinforced concrete building construction in Kuwait Abstract: Despite many technological advances, construction remains a labour intensive industry, and labour productivity remains the industry's predominant determinant of performance. However, there is a lack of evidence-based labour productivity 'baselines' with which researchers or industry practitioners can compare the efficiency of the labour force, and subsequently establish sensible benchmarks. A rigorous approach to determining baselines for labour productivity of in situ reinforced concrete trades for major building elements under normal operating conditions in the State of Kuwait has therefore been developed. The data were collected from 208 in situ reinforced concrete building projects between 2006 and 2013. The intermittent observation data collection technique which requires the researcher to carry out weekly site visits to audit site staff daily records was used. Projects observed included residential, office and commercial buildings ranging from 1000 to 15 000 m-super-2 in gross floor area, and US$300 000 to US$21 000 000 in construction cost, located across most major cities and suburbs within the State. For each dataset, the minimum, lower quartile, median, upper quartile and maximum labour productivity values are presented. Whilst the median and inter-quartile range represent the baseline or normal labour productivity range of the related activity, the lower and upper quartiles may be used as benchmarks to identify poor and exceptional performance. Although the metrics are specific to Kuwait, the principles of data collection, analysis and use are generic and could be applied to advantage in other countries. Journal: Construction Management and Economics Pages: 625-639 Issue: 8 Volume: 33 Year: 2015 Month: 8 X-DOI: 10.1080/01446193.2015.1085651 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1085651 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:8:p:625-639 Template-Type: ReDIF-Article 1.0 Author-Name: L.P. Andersen Author-X-Name-First: L.P. Author-X-Name-Last: Andersen Author-Name: I.L. Karlsen Author-X-Name-First: I.L. Author-X-Name-Last: Karlsen Author-Name: P. Kines Author-X-Name-First: P. Author-X-Name-Last: Kines Author-Name: T. Joensson Author-X-Name-First: T. Author-X-Name-Last: Joensson Author-Name: K.J. Nielsen Author-X-Name-First: K.J. Author-X-Name-Last: Nielsen Title: Social identity in the construction industry: implications for safety perception and behaviour Abstract: The construction industry has one of the highest frequency levels and rates of work-related injuries, yet the evidence for successful attempts to reduce injuries is generally lacking. The motivational and (safety) behavioural implications of social identification and social categorization among construction labourer work crews were investigated to ascertain how their interactions are affected by the social structure and organization of work. Semi-structured group interviews and mini interviews during work were carried out with 13 concrete work crews (totalling 53 persons) at five large construction sites. The organization of work fosters social identification within a crew, resulting in distancing from and social categorization of site management. Social identification influences safety behaviour in the crews, where worksite safety rules may meet resistance. Future safety initiatives at large construction sites should take into account the dynamics of social identification and categorization in the implementation of safety measures, e.g. by creating an alternative organization of work, thus making it easier for a work crew to identify themselves with the site management. Site/crew managers should consider how safety can become a salient and valued group norm by altering the social structure at the sites and/or fostering dual social identity. Journal: Construction Management and Economics Pages: 640-652 Issue: 8 Volume: 33 Year: 2015 Month: 8 X-DOI: 10.1080/01446193.2015.1087645 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1087645 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:8:p:640-652 Template-Type: ReDIF-Article 1.0 Author-Name: Yongcheng Fu Author-X-Name-First: Yongcheng Author-X-Name-Last: Fu Author-Name: Yongqiang Chen Author-X-Name-First: Yongqiang Author-X-Name-Last: Chen Author-Name: Shuibo Zhang Author-X-Name-First: Shuibo Author-X-Name-Last: Zhang Author-Name: Wenqian Wang Author-X-Name-First: Wenqian Author-X-Name-Last: Wang Title: Promoting cooperation in construction projects: an integrated approach of contractual incentive and trust Abstract: Contractual incentive and trust are two commonly used governance mechanisms that help to promote inter-organizational cooperation. Little is known, however, about the boundary conditions for the complementation of these two governance mechanisms. The aim is to investigate the interaction of contractual incentive and trust in promoting inter-organizational cooperation. A three-staged Stackelberg model was established and then solved by backward induction. Research results indicate that contractual incentive can motivate the contractor's task behaviours, while the effect of trust on relational behaviours is path-dependent. Three levels of factors (intra-organizational, inter-organizational and project factors) would affect the selection of the optimal incentive coefficient. Moreover, when the changing rate of the client's cost of effort is less than or equal to a threshold, contractual incentive and trust can be complementary. The study contributes to theory by offering nuanced insights into the governance mechanisms and addressing the complex contracting issues when mutual trust exists. In addition, this study can help to create favourable circumstances for the complementation between contractual incentive and trust, achieving a better project outcome and relational benefit. Journal: Construction Management and Economics Pages: 653-670 Issue: 8 Volume: 33 Year: 2015 Month: 8 X-DOI: 10.1080/01446193.2015.1087646 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1087646 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:8:p:653-670 Template-Type: ReDIF-Article 1.0 Author-Name: Samwel Alananga Author-X-Name-First: Samwel Author-X-Name-Last: Alananga Author-Name: Charles Lucian Author-X-Name-First: Charles Author-X-Name-Last: Lucian Author-Name: Moses Mpogole Kusiluka Author-X-Name-First: Moses Mpogole Author-X-Name-Last: Kusiluka Title: Significant cost-push factors in owner-built incremental housing construction in Tanzania Abstract: The owner-built incremental housing approach is highly prevalent in developing countries although its economic rationale is questionable. This study uses descriptive statistics and regression analysis to examine the flexibility of owner-built housing construction cost in response to different cost-push factors based on survey data on 43 main and 20 outbuilding projects implemented in Dar es Salaam Tanzania between 1990 and 2013. It has been observed that factor cost-flexibility of incremental construction is significantly enhanced through longer construction periods, the use of local cement and drainage system materials and larger built space. This flexibility is explained by the owner-builders' ability to internalize these cost-push factors over time which is reflected through lower annual construction costs facing owner-builders even at times of shortage in services and material supply, cost underestimation or high interest rate. These observations suggest that longer construction periods not only offer the cost-spread advantage but also allow a more thorough search for appropriate plot location, cheaper sources of materials, more affordable design and an appropriate match between changing life cycle housing needs and household income. Therefore, the incremental owner-built approach has lower annual construction costs not only because of the cost-spread effect of a longer construction period but also as a result of owner-builders' cost-saving choices made in terms of utilization of certain local materials, purchasing plots in less challenging environments, preferring single-storey over two-storey houses and avoiding complex house design. Journal: Construction Management and Economics Pages: 671-688 Issue: 8 Volume: 33 Year: 2015 Month: 8 X-DOI: 10.1080/01446193.2015.1090007 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1090007 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:8:p:671-688 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Lemer Author-X-Name-First: Andrew Author-X-Name-Last: Lemer Title: Life Cycle Costing: For the Analysis, Management and Maintenance of Civil Engineering Infrastructure Journal: Construction Management and Economics Pages: 689-691 Issue: 8 Volume: 33 Year: 2015 Month: 8 X-DOI: 10.1080/01446193.2015.1085069 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1085069 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:8:p:689-691 Template-Type: ReDIF-Article 1.0 Author-Name: Lars Sunding Author-X-Name-First: Lars Author-X-Name-Last: Sunding Author-Name: Anders Ekholm Author-X-Name-First: Anders Author-X-Name-Last: Ekholm Title: Applying social sciences to inspire behavioural change in the construction sector: an experimental study Abstract: In several reports, the construction industry has been criticized for inefficiencies, errors and increasing costs. Although the industry's critics and researchers implicitly call for a change in human behaviour, this is seldom explicitly problematized by any of them. It is rather seen as a natural consequence of the suggested measures for improvements. Researchers have begun to question if the influence of human psychology has not been underestimated in the present approach. After a review of different psychological theories an action research investigation of how psychological factors might contribute to the recurring problems in the construction sector and to the difficulties of changing it is carried out. An intervention method has been developed to counteract the tendency of various psychological functions that can distort information. It was found that the problems professionals are experiencing dramatically differ from those expressed in some critical reports. During the process, the professionals discovered their own role in the problem scenario. This shows a way to pay more attention to human/psychological issues in action design within the construction context, and what can happen when this is done. Journal: Construction Management and Economics Pages: 695-710 Issue: 9 Volume: 33 Year: 2015 Month: 9 X-DOI: 10.1080/01446193.2015.1090619 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1090619 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:9:p:695-710 Template-Type: ReDIF-Article 1.0 Author-Name: Vacharapoom Benjaoran Author-X-Name-First: Vacharapoom Author-X-Name-Last: Benjaoran Author-Name: Wisitsak Tabyang Author-X-Name-First: Wisitsak Author-X-Name-Last: Tabyang Author-Name: Nart Sooksil Author-X-Name-First: Nart Author-X-Name-Last: Sooksil Title: Precedence relationship options for the resource levelling problem using a genetic algorithm Abstract: The resource levelling problem (RLP) arises in project scheduling where the intention is to reduce the fluctuation of the resource demand. The solutions of the RLP are achieved through the rearrangement of the project activities under a constraint of preselected precedence relationships. To relieve the constraint, a new concept of the RLP with relationship options is initiated. An activity of the project network can have one or more alternative types of relationship with other activities as appropriate. An alternative relationship provides more float time and allows new possibilities for the arrangement of efficient patterns of the project resource demand. The scheduling problem model was formulated by using mathematical equations on spreadsheet software and solved by using the genetic algorithm based optimization. The prototype was tested in two different project instances. The test results demonstrated that this new model could calculate and arrange the project schedules for all selected alternative types of relationships. The model with relationship options provided consistent results for efficient resource utilization schedules, which were better than the one without relationship options. These schedules could decrease the resource demand fluctuation and the maximum resource demand level. This new model of the RLP with relationship options not only provides the additional flexibility to level the resource demands but also determines suitable types of relationships for the project activities. Journal: Construction Management and Economics Pages: 711-723 Issue: 9 Volume: 33 Year: 2015 Month: 9 X-DOI: 10.1080/01446193.2015.1100317 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1100317 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:9:p:711-723 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: Building a new third construction sector through social enterprise Abstract: Social enterprises are profit-making businesses which trade for a social purpose. They bridge the gap between welfare and work, providing employment opportunities for disadvantaged groups often excluded from employment in the construction industry. Social enterprises are a fast-growing part of a larger third economic sector. However, compared to other industries, there are relatively few social enterprises operating in construction and little is known about the challenges they face in doing so. In-depth interviews at 12 UK social enterprises reveal that many of the challenges faced by social enterprises in the construction industry are similar to those faced by social enterprises operating in other industries. These include: building trust, managing hybridity; securing finance; measuring social impact; and achieving scale. However, in addressing the lack of sector-specific insights in social enterprise research, challenges unique to construction are also identified. These include: procurement practices which favour industry incumbents; costly tender bureaucracy; established supply chain relationships; lack of experience of working with social enterprises; disingenuous corporate social responsibility practices; and fear that social enterprises will reduce competitiveness. Recommendations are made to resolve these challenges, enabling the construction sector to create an ecosystem where social enterprises can thrive. Questions to guide future research into this unexplored area are also proposed. Journal: Construction Management and Economics Pages: 724-739 Issue: 9 Volume: 33 Year: 2015 Month: 9 X-DOI: 10.1080/01446193.2015.1090006 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1090006 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:9:p:724-739 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Sarah Pink Author-X-Name-First: Sarah Author-X-Name-Last: Pink Author-Name: James Harley Author-X-Name-First: James Author-X-Name-Last: Harley Author-Name: Ruwini Edirisinghe Author-X-Name-First: Ruwini Author-X-Name-Last: Edirisinghe Title: Looking and learning: using participatory video to improve health and safety in the construction industry Abstract: Construction health and safety (H&S) is usually managed using a top-down approach of regulating workers' behaviour through the implementation and enforcement of prescriptive rules and procedures. This management approach privileges technical knowledge over knowledge based on workers' tacit and informal ways of knowing about H&S. The aim is to investigate the potential for participatory video to: (1) identify areas in which formal policies and procedures do not reflect H&S as practised by workers; (2) encourage creative thinking and elicit workers' ideas for H&S improvements; and (3) provide an effective mechanism for capturing and sharing tacit H&S knowledge in construction organizations. Interviews were conducted in two case study organizations (CSOs) in the Australian construction industry. The results suggest reflexive participatory video enabled workers and managers to view their work practices from a different perspective. Workers identified new hazards, reflected about the practical difficulties in performing work in accordance with documented procedures and reframed their work practices and developed safer ways of working. Workers described how the participatory video capturing the way they work enabled them to have more meaningful input into H&S decision-making than they had previously experienced. Workers also expressed a strong preference for receiving H&S information in a visual format and commented that video was better suited to communicating H&S 'know how' than written documents. The research is significant in providing initial evidence that participatory video has the potential to improve H&S in construction. Journal: Construction Management and Economics Pages: 740-751 Issue: 9 Volume: 33 Year: 2015 Month: 9 X-DOI: 10.1080/01446193.2015.1102301 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1102301 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:9:p:740-751 Template-Type: ReDIF-Article 1.0 Author-Name: Pablo Ballesteros-P�rez Author-X-Name-First: Pablo Author-X-Name-Last: Ballesteros-P�rez Author-Name: M. Carmen Gonz�lez-Cruz Author-X-Name-First: M. Carmen Author-X-Name-Last: Gonz�lez-Cruz Author-Name: Jose Luis Fuentes-Bargues Author-X-Name-First: Jose Luis Author-X-Name-Last: Fuentes-Bargues Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Analysis of the distribution of the number of bidders in construction contract auctions Abstract: The number of bidders, N, involved in a construction procurement auction is known to have an important effect on the value of the lowest bid and the mark-up applied by bidders. In practice, for example, it is important for a bidder to have a good estimate of N when bidding for a current contract. One approach, instigated by Friedman in 1956, is to make such an estimate by statistical analysis and modelling. Since then, however, finding a suitable model for N has been an enduring problem for researchers and, despite intensive research activity in the subsequent 30 years, little progress has been made, due principally to the absence of new ideas and perspectives. The debate is resumed by checking old assumptions, providing new evidence relating to concomitant variables and proposing a new model. In doing this and in order to ensure universality, a novel approach is developed and tested by using a unique set of 12 construction tender databases from four continents. This shows the new model provides a significant advancement on previous versions. Several new research questions are also posed and other approaches identified for future study. Journal: Construction Management and Economics Pages: 752-770 Issue: 9 Volume: 33 Year: 2015 Month: 9 X-DOI: 10.1080/01446193.2015.1090008 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1090008 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:9:p:752-770 Template-Type: ReDIF-Article 1.0 Author-Name: Brian Atkin Author-X-Name-First: Brian Author-X-Name-Last: Atkin Title: Megaproject Planning and Management: Essential Readings Journal: Construction Management and Economics Pages: 771-774 Issue: 9 Volume: 33 Year: 2015 Month: 9 X-DOI: 10.1080/01446193.2015.1090617 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1090617 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:9:p:771-774 Template-Type: ReDIF-Article 1.0 Author-Name: Bernard Vogl Author-X-Name-First: Bernard Author-X-Name-Last: Vogl Title: Measuring Construction: Prices, Output and Productivity Journal: Construction Management and Economics Pages: 775-777 Issue: 9 Volume: 33 Year: 2015 Month: 9 X-DOI: 10.1080/01446193.2015.1090616 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1090616 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:9:p:775-777 Template-Type: ReDIF-Article 1.0 Author-Name: Stefan Olander Author-X-Name-First: Stefan Author-X-Name-Last: Olander Title: Sustainable Building Adaptation: Innovations in Decision-making Journal: Construction Management and Economics Pages: 777-778 Issue: 9 Volume: 33 Year: 2015 Month: 9 X-DOI: 10.1080/01446193.2015.1090618 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1090618 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:9:p:777-778 Template-Type: ReDIF-Article 1.0 Author-Name: Marion M. Russell Author-X-Name-First: Marion M. Author-X-Name-Last: Russell Author-Name: Min Liu Author-X-Name-First: Min Author-X-Name-Last: Liu Author-Name: Simon M. Hsiang Author-X-Name-First: Simon M. Author-X-Name-Last: Hsiang Title: Planning for uncertainty: use of structural equation modelling to determine the causal structure of time buffer allocation Abstract: Construction personnel at every level of management are constantly planning and trying to figure out how to best deal with the uncertainty and variability of construction projects. The allocation of a time buffer in task planning is one method used to absorb variation caused by the inherent complexity and uncertainty present in construction. The research objective is to identify the causal structure used in planning for uncertainty and allocating a time buffer to construction project tasks. A time buffer questionnaire was developed and distributed to 175 companies across 37 states in the US. A structural equation modelling approach was used to develop mental models for field management personnel and upper management personnel based on both the frequency and severity response data collected. A total of 63 completed surveys from construction field managers were collected to validate the models. Contributions to the body of knowledge include (1) the development of causal structures for decision support through identification of risk areas, and the prioritization, prevention, and mitigation of those risks; and (2) the comparison of the field management models with the upper management models to identify both the shared key causes of buffer allocation and the differences in planning priorities. The contribution to practice is that the findings will help construction managers understand what drives the need for buffers in their construction schedules and allow them to focus efforts on strategically addressing the most critical areas of concern and uncertainty. Furthermore, the execution of a model survey serves to strengthen the findings of the data analysis and improve the overall models from a practical standpoint. Journal: Construction Management and Economics Pages: 783-798 Issue: 10 Volume: 33 Year: 2015 Month: 10 X-DOI: 10.1080/01446193.2015.1137335 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1137335 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:10:p:783-798 Template-Type: ReDIF-Article 1.0 Author-Name: Rajaa Alasad Author-X-Name-First: Rajaa Author-X-Name-Last: Alasad Author-Name: Ibrahim Motawa Author-X-Name-First: Ibrahim Author-X-Name-Last: Motawa Title: Dynamic demand risk assessment for toll road projects Abstract: To bridge the gap between supply of and increasing demand for roads, public--private partnership (PPP) concession contracts in which the investment cost is recovered via payments from the end users have been established. Although this mechanism has been seen as an efficient way for road projects to be completed on time and within budget, the demand risk faced during the operation stage has considerably limited this efficiency. Demand depends on a range of interrelated and dynamic factors such as the demographic and economic conditions. In addition, uncertainty is an inherent aspect of most demand-underlying factors which always make demand estimation inaccurate. However, this uncertainty is largely ignored by modellers where a single demand estimate is often used when evaluating the facility. The aim is to develop a system dynamics model to assess demand risk in road projects. The model captures the factors affecting demand and their relationships and simulates their change over time. By employing Monte Carlo simulation, the model assesses the likelihood and potential effect of an event on the outcome and provides a full picture of the various effects of potential risk. The model can help public, private, and financial stakeholders of PPP facilities make more informed decisions. Journal: Construction Management and Economics Pages: 799-817 Issue: 10 Volume: 33 Year: 2015 Month: 10 X-DOI: 10.1080/01446193.2016.1143561 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1143561 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:10:p:799-817 Template-Type: ReDIF-Article 1.0 Author-Name: Rita Peihua Zhang Author-X-Name-First: Rita Peihua Author-X-Name-Last: Zhang Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Steve Nevin Author-X-Name-First: Steve Author-X-Name-Last: Nevin Title: Development and validation of a multilevel safety climate measurement tool in the construction industry Abstract: Construction organizations are large and complex with decentralized structures, and characterized by non-routine work undertaken by semi-autonomous work groups. Construction workers’ perceptions of safety climate can form at different levels and vary between subunits. A multilevel safety climate measurement tool was proposed, which identified five important safety agents, i.e. client, principal contractor, supervisor, co-workers, and individual workers. Surveys were conducted at three construction projects commissioned by Fonterra Co-operative Group. A total of 356 participants completed the survey. The data was subject to scale reliability analysis and factor analysis. The results showed that all scales achieved satisfactory internal consistency and the multilevel factorial structure was generally supported. At the organizational level, the tool measures clients’ overall safety priority and safety actions, and principal contractors’ general commitment to safety. At the group level, the tool measures supervisors’ safety actions and safety expectations, and co-workers’ general safety values and practices. The tool also measures individual safety responses reflected by safety compliance and safety participation. The measurement tool would help construction organizations to diagnose potential weaknesses in their safety management practices for safety improvement and also help to develop a social and cultural work environment that is supportive of safety at all levels. Journal: Construction Management and Economics Pages: 818-839 Issue: 10 Volume: 33 Year: 2015 Month: 10 X-DOI: 10.1080/01446193.2015.1108451 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1108451 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:10:p:818-839 Template-Type: ReDIF-Article 1.0 Author-Name: Libby Schweber Author-X-Name-First: Libby Author-X-Name-Last: Schweber Title: Putting theory to work: the use of theory in construction research Abstract: Attention to epistemology, theory use and citation practices are all issues which distinguish academic disciplines from other ways of knowing. Examples from construction research are used to outline and reflect on these issues. In doing so, the discussion provides an introduction to some key issues in social research as well as a reflection on the current state of construction research as a field. More specifically, differences between positivist and interpretivist epistemologies, the role of theory in each and their use by construction researchers are discussed. Philosophical differences are illustrated by appeal to two published construction research articles by Reichstein et al. and Harty on innovation (Reichstein, Salter and Gann, 2005; Harty, 2008). An analysis of citations for each highlights different cumulativity strategies. The potential contribution of mixed research programmes, combining positivist and interpretivist research, is evaluated. The paper should be of interest to early researchers and to scholars concerned with the ongoing development of construction research as an academic field. Journal: Construction Management and Economics Pages: 840-860 Issue: 10 Volume: 33 Year: 2015 Month: 10 X-DOI: 10.1080/01446193.2015.1133918 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1133918 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:10:p:840-860 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Gardiner Author-X-Name-First: Paul Author-X-Name-Last: Gardiner Title: Relationship Management and the Management of Projects Journal: Construction Management and Economics Pages: 861-862 Issue: 10 Volume: 33 Year: 2015 Month: 10 X-DOI: 10.1080/01446193.2015.1127983 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1127983 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:10:p:861-862 Template-Type: ReDIF-Article 1.0 Author-Name: Louise Bildsten Author-X-Name-First: Louise Author-X-Name-Last: Bildsten Author-Name: Karen Manley Author-X-Name-First: Karen Author-X-Name-Last: Manley Title: A framework for understanding purchasing in building construction companies Abstract: Purchasing on the part of a building construction company involves actors inside and outside the organization. These actors are driven by different motives that influence purchasing decisions in different situations. An explicit framework that assists in understanding the different purchasing situations would be of benefit to companies and researchers. Through a study of purchasing theory and practices, including interviews with a number of building construction companies, a framework of purchasing is proposed. The framework covers all stages in the purchasing process and focuses on four factors: (1) purchasing situations; (2) level of complexity; (3) active roles and (4) supply chain involvement. The inter-relationships between these factors are discussed from the perspective of the companies. Journal: Construction Management and Economics Pages: 865-879 Issue: 11-12 Volume: 33 Year: 2015 Month: 12 X-DOI: 10.1080/01446193.2016.1164325 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1164325 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:11-12:p:865-879 Template-Type: ReDIF-Article 1.0 Author-Name: Mark A. Hinton Author-X-Name-First: Mark A. Author-X-Name-Last: Hinton Author-Name: Robert T. Hamilton Author-X-Name-First: Robert T. Author-X-Name-Last: Hamilton Title: Competitive tendering and individual behaviour in the construction industry: convenient immorality at work Abstract: How and why does the construction industry persist with competitive tendering as the dominant procurement model? This is a constructivist grounded theory view of construction industry procurement in New Zealand, explaining how industry actors have to behave. convenient immorality is a shared and accepted response by individuals intended to facilitate business outcomes within an environment of intense competition, driven by opportunism and asymmetric power relationships. Low trust due to convenient immorality behaviours will continue to frustrate attempts to replace competitive tendering as the dominant model for construction industry procurement. Journal: Construction Management and Economics Pages: 880-889 Issue: 11-12 Volume: 33 Year: 2015 Month: 12 X-DOI: 10.1080/01446193.2016.1170865 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1170865 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:11-12:p:880-889 Template-Type: ReDIF-Article 1.0 Author-Name: I. Krystallis Author-X-Name-First: I. Author-X-Name-Last: Krystallis Author-Name: P. Demian Author-X-Name-First: P. Author-X-Name-Last: Demian Author-Name: A.D.F Price Author-X-Name-First: A.D.F Author-X-Name-Last: Price Title: Using BIM to integrate and achieve holistic future-proofing objectives in healthcare projects Abstract: Future-proofing (FP) as a proactive initiative for asset management is an urgent need against uncertainty, particularly in health care due to unforeseeable demographic shifts and rapid advances in medical technology. Building information modelling (BIM) is a data-driven initiative, but a rigorous analysis between them will indicate that a synergy exists. The aim of this study is to develop a classification ontology of the interactions between FP and BIM by considering the perceptions of health care construction experts. Interviews with 13 senior managers were conducted adopting the method of interpretative phenomenological analysis and an interaction matrix of BIM capabilities for implementing holistic FP objectives has been developed. The outcome is a taxonomy analysis of 30 interactions with supporting empirical evidence which was further measured quantitatively. For benefits realization in the context of BIM and FP, the industry experts recognize FP as a strategy that supports organizational and building performance. BIM drives towards life cycle operation information and data maintainability via communicating the FP strategy from a whole-life perspective and ensuring knowledge transfer across all stages. Health care Operators and construction experts should be able to benefit from this taxonomy analysis as an aid to planning for FP throughout their BIM processes. Journal: Construction Management and Economics Pages: 890-906 Issue: 11-12 Volume: 33 Year: 2015 Month: 12 X-DOI: 10.1080/01446193.2016.1164326 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1164326 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:11-12:p:890-906 Template-Type: ReDIF-Article 1.0 Author-Name: Anumitra Mirti Chand Author-X-Name-First: Anumitra Mirti Author-X-Name-Last: Chand Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: A socio-ecological analysis of hospital resilience to extreme weather events Abstract: Hospitals play a critical role in helping communities respond effectively to extreme weather events (EWEs). Despite predictions of more EWEs, little is known about the process by which hospital infrastructure resilience to such events can be built. Using Gunderson and Holling’s Adaptive Cycle, a new theoretical perspective based on socio-ecological resilience theory is provided to understand this process. Data were collected using semi-structured interviews, observations of disaster drills and disaster planning meetings, as well as additional documentary analysis of past incident reports. The research findings were then refined and validated in a focus group meeting with respondents. The findings indicate that there are significant organizational barriers which prevent facilities managers improving the resilience of hospital facilities to future EWEs. It was found that the disaster planning process is ad hoc and non-inclusive, focused on man-made disasters and compliance driven, top-down approach, under-resourced and is driven by a general ignorance of the importance of resilient-built facilities to health care delivery during an EWE. It is concluded that to produce more resilient hospital infrastructure, there needs to be a more well-resourced, integrated and collaborative approach to disaster management planning which enables health facilities managers to play a more central role in disaster planning decisions. There also need to be better systems, technologies and training implemented to manage information about health infrastructure performance before, during and after EWEs. Journal: Construction Management and Economics Pages: 907-920 Issue: 11-12 Volume: 33 Year: 2015 Month: 12 X-DOI: 10.1080/01446193.2016.1165856 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1165856 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:11-12:p:907-920 Template-Type: ReDIF-Article 1.0 Author-Name: Mohammed A. Rajeh Author-X-Name-First: Mohammed A. Author-X-Name-Last: Rajeh Author-Name: John E. Tookey Author-X-Name-First: John E. Author-X-Name-Last: Tookey Author-Name: James Olabode Bamidele Rotimi Author-X-Name-First: James Olabode Bamidele Author-X-Name-Last: Rotimi Title: Developing a procurement path determination chart SEM-based approach Abstract: The choice of an appropriate procurement system is crucial to construction project success. Procurement selection is largely based on path determination charts, with at least eight key criteria needing to be weighted by decision-makers. Including certain criteria whilst ignoring client-borne transaction costs (TCs) resulting from environmental uncertainties simplifies this process. TCs are ‘unseen’ costs associated with pre- and post-contract work. The effects of uncertainties in the transaction environment and procurement systems on TCs are investigated, comparing the traditional and design-build procurement systems. A cross-sectional sample approach was deployed, involving survey questionnaire and results verification through ‘real-world’ cases. Data was sought from construction professionals in management, design and operation of construction projects. The research participants evaluate their time spent on procurement activities using a five-point Likert scale. Hypotheses of the relations between environmental uncertainties, procurement systems, and pre- and post-contract TCs are tested using a structural equation modelling (SEM) approach. The study found that TCs account for about 46.75% and 42.88% of the daily time spent by project managers in traditional and design-build procurement systems in New Zealand respectively. The study concludes that the TC concept is a useful framework for determining objective instead of subjective opinions for procurement decisions. Journal: Construction Management and Economics Pages: 921-941 Issue: 11-12 Volume: 33 Year: 2015 Month: 12 X-DOI: 10.1080/01446193.2016.1151538 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1151538 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:11-12:p:921-941 Template-Type: ReDIF-Article 1.0 Author-Name: Jessica Kaminsky Author-X-Name-First: Jessica Author-X-Name-Last: Kaminsky Title: Institutionalizing infrastructure: photo-elicitation of cultural-cognitive knowledge of development Abstract: Infrastructure that goes unused -- for example, after constructing the first water, electricity, sewers or road infrastructure in an infrastructure-poor community -- is a common issue in new infrastructure development in the global south. In this case, while infrastructure has diffused, it has not become institutionalized. To better understand this problem, photo-elicitation methods are used to explore cultural-cognitive frames used by research respondents as they create and explain photograph symbols that represent change in their built environment. For example, respondents advocate for infrastructure they have reason to believe outsiders will provide as they evaluate the infrastructure against local utility in an early phase of institutionalization. Respondents also frame the research undertaking as an opportunity to actively diffuse infrastructure practices they have recently adopted themselves. By making these and other frames explicit, the photo-elicitation method reveals the elusive cultural-cognitive pillar of institutionalization and also provides insight into sources of self-reporting bias. The method also has particular advantages for research dealing with disadvantaged respondents, reduces issues of free recall bias and increases the length and depth of research interviews. Given the relative novelty of this method in construction research, its theory, advantages and limitations are discussed in some depth. Journal: Construction Management and Economics Pages: 942-956 Issue: 11-12 Volume: 33 Year: 2015 Month: 12 X-DOI: 10.1080/01446193.2016.1167927 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1167927 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:33:y:2015:i:11-12:p:942-956 Template-Type: ReDIF-Article 1.0 Author-Name: William G. Robinson Author-X-Name-First: William G. Author-X-Name-Last: Robinson Author-Name: Paul W. Chan Author-X-Name-First: Paul W. Author-X-Name-Last: Chan Author-Name: Thomas Lau Author-X-Name-First: Thomas Author-X-Name-Last: Lau Title: Sensors and sensibility: examining the role of technological features in servitizing construction towards greater sustainability Abstract: The role played by the technological development of products in shaping more sustainable ways of working in the built environment is examined through a case study of a systems integrator of mechanical and electrical systems in the UK construction industry, ConstructCo. They are exploring ways in which they can improve the through-life performance of their systems through servitization. The aim was to understand how and why emergent technological features, stimulated by embedding new sensors within their systems, were affording different user groups within the organization’s value chain to act in more servitized ways. The case analysis found that new energy-metering sensors were integral to the development of greater transparency between ConstructCo and their clients. Equally evident were the various ways in which equipment-condition monitoring sensors were shaping a collective motive across ConstructCo’s supply chain towards exploring the justification for implementing predictive maintenance. The role played by new sensor technology in shaping ConstructCo’s pursuit of servitization highlights the need for research to pay greater attention to material agency when explaining how organizational practices accommodate the implementation and use of technological developments in construction. Furthermore, using servitization as the research context offers fresh insights into transitioning towards greater servitization in construction. Journal: Construction Management and Economics Pages: 4-20 Issue: 1 Volume: 34 Year: 2016 Month: 1 X-DOI: 10.1080/01446193.2016.1139146 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1139146 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:1:p:4-20 Template-Type: ReDIF-Article 1.0 Author-Name: Marina Bos-de Vos Author-X-Name-First: Marina Author-X-Name-Last: Bos-de Vos Author-Name: J.W.F. Hans Wamelink Author-X-Name-First: J.W.F. Hans Author-X-Name-Last: Wamelink Author-Name: Leentje Volker Author-X-Name-First: Leentje Author-X-Name-Last: Volker Title: Trade-offs in the value capture of architectural firms: the significance of professional value Abstract: Architectural firms often have difficulty generating profit from their services as they pursue not only commercial but also professional goals. These goals frequently conflict and have to be balanced during the process of value creation and value capture. So far, literature has focused on the interaction between the perceived use value for the customer and the fee that is paid to the firm. To better understand how professional service firms realize their organizational targets, professional value needs to be included. In this study, in-depth interviews with the architects and clients of nine housing projects provide insight into the content and process of value capture by architectural firms. The data reveal strategies by which architects tried to maximize the capture of professional value at the expense of profit or sometimes even their clients’ perceived use value. These trade-offs in value capture confirm the importance of professional value when studying value creation and capture in a professional service context. This paper provides an understanding of how architectural firms struggle to balance competing goals and highlights the importance of well-managed value capture. Journal: Construction Management and Economics Pages: 21-34 Issue: 1 Volume: 34 Year: 2016 Month: 1 X-DOI: 10.1080/01446193.2016.1177192 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1177192 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:1:p:21-34 Template-Type: ReDIF-Article 1.0 Author-Name: Tony Hopkin Author-X-Name-First: Tony Author-X-Name-Last: Hopkin Author-Name: Shu-Ling Lu Author-X-Name-First: Shu-Ling Author-X-Name-Last: Lu Author-Name: Phil Rogers Author-X-Name-First: Phil Author-X-Name-Last: Rogers Author-Name: Martin Sexton Author-X-Name-First: Martin Author-X-Name-Last: Sexton Title: Detecting defects in the UK new-build housing sector: a learning perspective Abstract: Rapid growth in the production of new homes in the UK is putting build quality under pressure as evidenced by an increase in the number of defects. Housing associations (HAs) contribute approximately 20% of the UK’s new housing supply. HAs are currently experiencing central government funding cuts and rental revenue reductions. As part of HAs’ quest to ramp up supply despite tight budget conditions, they are reviewing how they learn from defects. Learning from defects is argued as a means of reducing the persistent defect problem within the UK housebuilding industry, yet how HAs learn from defects is under-researched. The aim of this research is to better understand how HAs, in practice, learn from past defects to reduce the prevalence of defects in future new homes. The theoretical lens for this research is organizational learning. The results drawn from 12 HA case studies indicate that effective organizational learning has the potential to reduce defects within the housing sector. The results further identify that HAs are restricting their learning to focus primarily on reducing defects through product and system adaptations. Focusing on product and system adaptations alone suppresses HAs’ abilities to reduce defects in the future. Journal: Construction Management and Economics Pages: 35-45 Issue: 1 Volume: 34 Year: 2016 Month: 1 X-DOI: 10.1080/01446193.2016.1162316 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1162316 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:1:p:35-45 Template-Type: ReDIF-Article 1.0 Author-Name: Jan Gottsche Author-X-Name-First: Jan Author-X-Name-Last: Gottsche Author-Name: Mark Kelly Author-X-Name-First: Mark Author-X-Name-Last: Kelly Author-Name: Martin Taggart Author-X-Name-First: Martin Author-X-Name-Last: Taggart Title: Assessing the impact of energy management initiatives on the energy usage during the construction phase of an educational building project in Ireland Abstract: The construction industry is estimated to account for 40% of annual global energy use and 30% of annual greenhouse gas (GHG) emissions. The Intergovernmental Panel on Climate Change (IPCC) has suggested the construction sector as best placed to improve its energy performance in order to help Ireland to meet the European Union (EU) GHG reduction target of 20% by 2020. An action research (AR) approach was used to explore the construction phase energy reduction opportunities on a selected case study in the West of Ireland. The participating contractor’s current onsite energy management practices were benchmarked to inform the implementation of a series of quick-win measures at a cost of €706.04. The resultant savings of €19 853.03 represented 17.5% of the total expenditure on energy usage on site (€113 397) and resulted in an estimated saving of 5.5% of the assumed project profit (€358 800). A set of key performance indicators (KPIs) were calculated for both phases of the project with a 75% reduction in the cost of electricity per floor area from phase 1 to phase 2. The findings suggest that improving site energy use provides scope for the contractor to increase profit margins, improve resource efficiency and reduce environmental impacts. Journal: Construction Management and Economics Pages: 46-60 Issue: 1 Volume: 34 Year: 2016 Month: 1 X-DOI: 10.1080/01446193.2016.1162317 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1162317 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:1:p:46-60 Template-Type: ReDIF-Article 1.0 Author-Name: Niamh Murtagh Author-X-Name-First: Niamh Author-X-Name-Last: Murtagh Author-Name: Aeli Roberts Author-X-Name-First: Aeli Author-X-Name-Last: Roberts Author-Name: Richard Hind Author-X-Name-First: Richard Author-X-Name-Last: Hind Title: The relationship between motivations of architectural designers and environmentally sustainable construction design Abstract: Research on sustainability in construction design has tended to focus on technological, institutional and economic drivers, but there has been little change in the industry. Social scientific approaches offer insights on the lack of progress. However, few previous studies have investigated psychological factors despite the pivotal role of the individual professional decision-maker. The aim was to understand what personal motivations drive architectural designers to pursue sustainable design in their work and whether non-environmental motivations can drive sustainable outcomes. Twenty-eight architectural designers in 14 small firms in the London area were interviewed. Thematic analysis was conducted, informed by the self-determination theory of motivation. Although extrinsic motivators were noted, autonomous motivations including a moral imperative and personal commitment predominated. Further, the participants demonstrated other self-determined motivations including realization of self-identity, pursuit of quality in design and awareness of their work’s impact on people. These autonomous motivations align closely with sustainability principles including design for durability, high standards and technical expertise. The findings point to the risks of reliance on extrinisic motivators such as regulation, and the opportunities to engage architectural designers more extensively in sustainable design by linking sustainability to autonomous motivations. Journal: Construction Management and Economics Pages: 61-75 Issue: 1 Volume: 34 Year: 2016 Month: 1 X-DOI: 10.1080/01446193.2016.1178392 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1178392 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:1:p:61-75 Template-Type: ReDIF-Article 1.0 Author-Name: Johannes Hartwig Author-X-Name-First: Johannes Author-X-Name-Last: Hartwig Author-Name: Judit Kockat Author-X-Name-First: Judit Author-X-Name-Last: Kockat Title: Macroeconomic effects of energetic building retrofit: input-output sensitivity analyses Abstract: Energy efficiency measures in buildings are essential for climate protection, but are not always recognized by the investor in common profitability calculations. To provide a quantitative scientific base for policymakers, the aim is to identify and quantify the impact of these measures on Germany’s economy with a static open input-output model. Moreover, this investigation analyses how much the chosen base year affects the calculated macroeconomic impact, to obtain a clearer view of involved dynamics. The energy efficiency measures in buildings and their impact on energy demand and investments were simulated in the bottom-up building model INVERT/EE-Lab up to 2020. The methodological addition of this research is to identify and map the resulting impulses to the according macroeconomic sectors. Based on this stimulus a static input-output analysis is conducted using a range of base years. The results show that efficiency measures in buildings have a significant positive effect on macroeconomic key figures. The magnitude of the calculated impact depends on chosen base year data and varies for value added and employment. As a conclusion, the macroeconomic impact constitutes a co-benefit supporting the economic attractiveness of energy efficiency. However, studies based on a single base year dataset like many computable general equilibrium models may need to reflect the errors caused by that choice. Journal: Construction Management and Economics Pages: 79-97 Issue: 2 Volume: 34 Year: 2016 Month: 2 X-DOI: 10.1080/01446193.2016.1144928 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1144928 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:2:p:79-97 Template-Type: ReDIF-Article 1.0 Author-Name: Marieke Venselaar Author-X-Name-First: Marieke Author-X-Name-Last: Venselaar Author-Name: Vincent Gruis Author-X-Name-First: Vincent Author-X-Name-Last: Gruis Title: Studying intra-organizational dynamics in implementing supply chain partnering: a case study about work floor experiences in a Dutch housing association Abstract: This study aims at uncovering intra-organizational dynamics in implementing supply chain partnering. Narrative techniques are used in a qualitative case study in a Dutch housing association. This study shows how project leaders of a Dutch housing association perceive relationships in the internal supply chain and the strategies that they develop to cope with these relationships. Furthermore, it is argued that key values of SCP as understood by the project leaders -- such as sharing responsibilities and addressing feedback towards each other openly -- are not applied in intra-organizational relationships. Journal: Construction Management and Economics Pages: 98-109 Issue: 2 Volume: 34 Year: 2016 Month: 2 X-DOI: 10.1080/01446193.2016.1179772 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1179772 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:2:p:98-109 Template-Type: ReDIF-Article 1.0 Author-Name: Mei-yung Leung Author-X-Name-First: Mei-yung Author-X-Name-Last: Leung Author-Name: Qi Liang Author-X-Name-First: Qi Author-X-Name-Last: Liang Author-Name: Jingyu Yu Author-X-Name-First: Jingyu Author-X-Name-Last: Yu Title: Development of a mindfulness--stress--performance model for construction workers Abstract: Construction workers contribute to the success of projects on sites full of hazards and risks. Working in the construction industry is very stressful for them, while stress can impair their performance and safety. Mindfulness has been regarded as effective to manage stress and improve performance in general, while there is constant argument on the mindfulness characteristics. In addition, the effect of individual mindfulness characteristics on construction workers’ stress and performance still remains unknown. Therefore to fill in the research gap, a questionnaire survey was administered among construction workers. Nine mindfulness characteristics (framed into three theoretical categories), three stress types and three kinds of performance were identified. The results show that mindfulness characteristics indirectly improve construction workers’ performance by relieving their stress: (1) objective stress is mitigated by observation; (2) emotional stress is relieved by observation and awareness, and impairs construction workers’ organizational performance; and (3) physical stress is reduced by awareness, and worsens safety performance. Mindfulness characteristics also directly improve construction workers’ performance, namely description and observation enhance working performance; and awareness improves safety performance. However, the study interestingly found that the mindfulness attitude group has no effect on construction workers’ stress and performance, while decentering even harms their safety performance. The implications underlying the findings are discussed. Several recommendations are made for mitigating stress and improving performance. The mindfulness characteristics are grouped into theoretical categories, and the effects of each mindfulness characteristic on the stress and performance of construction workers are identified. Journal: Construction Management and Economics Pages: 110-128 Issue: 2 Volume: 34 Year: 2016 Month: 2 X-DOI: 10.1080/01446193.2016.1147652 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1147652 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:2:p:110-128 Template-Type: ReDIF-Article 1.0 Author-Name: Lauri Pulkka Author-X-Name-First: Lauri Author-X-Name-Last: Pulkka Author-Name: Miro Ristimäki Author-X-Name-First: Miro Author-X-Name-Last: Ristimäki Author-Name: Karoliina Rajakallio Author-X-Name-First: Karoliina Author-X-Name-Last: Rajakallio Author-Name: Seppo Junnila Author-X-Name-First: Seppo Author-X-Name-Last: Junnila Title: Applicability and benefits of the ecosystem concept in the construction industry Abstract: Inter-firm collaboration has increased significantly in the last decades. The concept of ecosystem has emerged to explain the nature and implications of businesses’ increasing reliance on networks. The ecosystem concept is intended to be generalizable across sectors, but research on ecosystems has focused on high-tech industries. Moreover, the construction industry has special features that differentiate it from other industries. In this paper, the concept of the ecosystem is introduced and developed in the context of the construction industry and the relationship between ecosystem characteristics and value creation in construction networks is examined. Based on a multiple-case study of six networks in the Finnish and Swedish construction industry, it is suggested that the ecosystem concept is applicable and offers a useful analytical lens for understanding value creation in the construction industry. The results suggest that operating according to ecosystem principles is positively connected to value creation in construction networks. Based on a cross-case analysis, a conceptual framework is presented on the main connections between ecosystem characteristics and value creation. The relevance of the ecosystem concept for the construction industry is predicted to grow in the future, as previous studies suggest that ecosystem-like features are being increasingly employed in construction networks. Journal: Construction Management and Economics Pages: 129-144 Issue: 2 Volume: 34 Year: 2016 Month: 2 X-DOI: 10.1080/01446193.2016.1179773 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1179773 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:2:p:129-144 Template-Type: ReDIF-Article 1.0 Author-Name: Xiancun Hu Author-X-Name-First: Xiancun Author-X-Name-Last: Hu Author-Name: Chunlu Liu Author-X-Name-First: Chunlu Author-X-Name-Last: Liu Title: Profitability performance assessment in the Australian construction industry: a global relational two-stage DEA method Abstract: Effective performance measurement drives performance and supports the development of construction. Only minimal literature measuring construction performance, efficiency and effectiveness simultaneously can be identified. A global relational two-stage data envelopment analysis (DEA) method is here proposed in order to produce effective and informative performance results. A relational two-stage DEA method systematically measures overall efficiency for a whole construction system and also yields scores for the individual stages of construction. The DEA results can be directly compared through global benchmark technology. The Australian construction industry is employed in order to implement the new method, in which profitability performance as a vital indicator of business survival, and its two dimensions of efficiency and effectiveness, are measured. The construction profitability performance and efficiency measures obtained provide evidence of underperformance and a slight imbalance in Australia between 1991 and 2012, while the measures obtained for the effectiveness factor indicate better achievement. The approach here developed promotes progress in modelling two-stage performance measurement and it can be replicated worldwide by construction projects, organizations or industries in order to quantify their performance, identify internal inefficiency components and recognize competitive advantages for promoting sustainable development. Journal: Construction Management and Economics Pages: 147-159 Issue: 3 Volume: 34 Year: 2016 Month: 3 X-DOI: 10.1080/01446193.2016.1180415 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1180415 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:3:p:147-159 Template-Type: ReDIF-Article 1.0 Author-Name: Bryan W. Franz Author-X-Name-First: Bryan W. Author-X-Name-Last: Franz Author-Name: Robert M. Leicht Author-X-Name-First: Robert M. Author-X-Name-Last: Leicht Title: An alternative classification of project delivery methods used in the United States building construction industry Abstract: Although many sources describe the project delivery methods available to owners, there is little empirical data on their defining characteristics. The objective of this research was to examine patterns in contract arrangements, procurement practices and compensation terms used in the US building construction industry. Survey data were collected for projects completed between 2008 and 2013 (N = 204) from owners and contractors belonging to large US professional organizations. A latent class analysis was used to identify five distinct patterns or ‘classes’ based upon eight characteristics of the project delivery process. These classes were defined as: (I) late builder and trade involvement, with an open, cost-based selection and lump sum contract (9% of projects in sample); (II) late builder and trade involvement, with a prequalified, cost-based selection and lump sum contract (19%); (III) early builder and late trade involvement, with a prequalified non-cost based selection and guaranteed maximum price (GMP) contract (26%); (IV) early builder and trade involvement, with a prequalified, cost-based selection and lump sum design-build (DB) contract (27%); (V) early builder and trade involvement, with a prequalified, non-cost based selection and GMP DB contract (18%). Compared to existing classifications of project delivery methods, these classes are data-driven typologies that represent how participants are procured and organized into a project team. The findings have implications as an alternative classification system in project delivery research and as guidance to owners considering their project delivery options. Journal: Construction Management and Economics Pages: 160-173 Issue: 3 Volume: 34 Year: 2016 Month: 3 X-DOI: 10.1080/01446193.2016.1183800 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1183800 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:3:p:160-173 Template-Type: ReDIF-Article 1.0 Author-Name: Andreas Ekeskär Author-X-Name-First: Andreas Author-X-Name-Last: Ekeskär Author-Name: Martin Rudberg Author-X-Name-First: Martin Author-X-Name-Last: Rudberg Title: Third-party logistics in construction: the case of a large hospital project Abstract: The construction supply chain is of temporary nature and complex, with many interactions between multiple actors in different construction projects. This challenging context typically leads to relatively higher costs and lower productivity, compared to other industries. Supply chain management (SCM) has been put forward as a mean to better handle this challenging context. As a part of SCM initiatives some construction industry stakeholders have turned to third-party logistics (TPL) providers, especially in large construction projects. The use of TPL providers is a new, and under-investigated, phenomenon in the construction industry. The main purpose of this study is thus to explore the use of a TPL provider in a large construction project and to analyse its resulting effects. Driving forces and possible concerns for implementing TPL are identified and the possibility for TPL to be a facilitator for implementing SCM in construction is investigated. The research is based on a literature review and an explorative case study of a large hospital project in Sweden, where the client and the main contractor have initiated the use of a TPL provider to coordinate sourcing and materials handling activities on site. The results show positive effects on establishing an effective interface between the construction site and the supply chain. The results also show that a TPL solution facilitates an increase in productive work at the construction site itself, a reduction of costs and an increased utilisation of site assets. On the downside, the study also shows a lack of SCM knowledge amongst the involved actors in the project, hindering them to reap the full potential of TPL. Journal: Construction Management and Economics Pages: 174-191 Issue: 3 Volume: 34 Year: 2016 Month: 3 X-DOI: 10.1080/01446193.2016.1186809 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1186809 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:3:p:174-191 Template-Type: ReDIF-Article 1.0 Author-Name: Khurram Iqbal Ahmad Khan Author-X-Name-First: Khurram Iqbal Ahmad Author-X-Name-Last: Khan Author-Name: Roger Flanagan Author-X-Name-First: Roger Author-X-Name-Last: Flanagan Author-Name: Shu-Ling Lu Author-X-Name-First: Shu-Ling Author-X-Name-Last: Lu Title: Managing information complexity using system dynamics on construction projects Abstract: The increase in e-commerce, the digitisation of design data and the interchange and sharing of information have made the construction sector more reliant upon IT infrastructure and systems. The design and production process is complex, dynamic, interconnected and dependent upon greater information mobility, requiring seamless exchange of data and information in real time. Small- and medium-sized enterprises (SMEs), in particular, specialty contractors, can utilise cost-effective collaboration technologies, such as cloud computing using software as a service, to help in the effective transfer of information and data. The system dynamics (SD) approach gives a better understanding of the dynamics of complex systems. SD methodology is used as a modelling and analysis tool to understand and identify the key drivers in the absorption of cloud computing for SMEs. The aim is to determine how the use of SD can improve the management of complexity of information flow, leading to improved performance for SMEs. SD is shown to be a viable tool to manage information complexity using cloud computing for performance improvement in construction. Journal: Construction Management and Economics Pages: 192-204 Issue: 3 Volume: 34 Year: 2016 Month: 3 X-DOI: 10.1080/01446193.2016.1190026 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1190026 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:3:p:192-204 Template-Type: ReDIF-Article 1.0 Author-Name: Tina Karrbom Gustavsson Author-X-Name-First: Tina Karrbom Author-X-Name-Last: Gustavsson Title: Liminal roles in construction project practice: exploring change through the roles of partnering manager, building logistic specialist and BIM coordinator Abstract: Industries have to adapt to changes in external environment. This adaption includes the development of new professional roles that challenge established structures, roles and communities of practice. In order to better understand the unfolding of construction project practice in an increasingly changeful world new professional roles are explored as liminal roles. The studied professional roles are partnering manager, building logistic specialist and BIM coordinator. Liminality is used as framework to understand descriptions of liminal experiences when negotiating boundary interfaces in construction project practice. Findings are both theoretical and practical and suggest that new professional roles practice multi-liminal work and acknowledge tensions that pose challenges for liminal roles to act as change agents. Journal: Construction Management and Economics Pages: 599-610 Issue: 11 Volume: 36 Year: 2018 Month: 11 X-DOI: 10.1080/01446193.2018.1464197 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1464197 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:11:p:599-610 Template-Type: ReDIF-Article 1.0 Author-Name: Bing Wang Author-X-Name-First: Bing Author-X-Name-Last: Wang Author-Name: Shuibo Zhang Author-X-Name-First: Shuibo Author-X-Name-Last: Zhang Author-Name: Xiuqin Wang Author-X-Name-First: Xiuqin Author-X-Name-Last: Wang Author-Name: Zhuo Feng Author-X-Name-First: Zhuo Author-X-Name-Last: Feng Title: The influence of quality benefit and marginal contribution on the optimal equity structure of the PPP projects: balancing public and private benefits Abstract: Public–private partnerships (PPPs) involve many different participants, and the equity allocation between them may influence the performance of PPP projects. While the optimal capital structure and equity capital structure of the project company have been extensively investigated, few studies have examined how to allocate equity shares among different private participants. Considering both public and private benefits, this study focuses on the optimal equity structure between construction contractor (CC) and operating contractor (OC). A game model is used to analyze how quality benefit and marginal contribution of CC and OC’s effort affect the optimal equity structure. The findings reveal that the private consortium expects the party (CC or OC) with higher marginal contribution of effort to own more equity shares, while government expects the party (CC or OC) with lower marginal contribution of effort to own more equity shares. Furthermore, a non-linear relationship between the optimal equity structure and government’s bargaining power is found. The results also manifest that the quality benefit of construction on operation is a nontrivial factor when designing the equity structure. If unconsidered, the CC’s optimal equity ratio will be either undervalued (when a higher construction quality can reduce the operating cost) or overvalued (when a higher construction quality can increase the operating cost). These findings can provide some insights into designing the equity structure for PPP projects in the bidding process. Journal: Construction Management and Economics Pages: 611-622 Issue: 11 Volume: 36 Year: 2018 Month: 11 X-DOI: 10.1080/01446193.2018.1468079 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1468079 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:11:p:611-622 Template-Type: ReDIF-Article 1.0 Author-Name: Richard F. Fellows Author-X-Name-First: Richard F. Author-X-Name-Last: Fellows Author-Name: Anita M. M. Liu Author-X-Name-First: Anita M. M. Author-X-Name-Last: Liu Title: Where do I go from here? Motivated reasoning in construction decisions Abstract: Early stage decisions have the greatest impact on construction projects and so, attention at conception and realization of projects is imperative. Decisions are influenced by actors’ interdependencies, thus, it is important to understand how actors determine meanings of their situations and actions. Meaning is derived from situational cues that are contextually bounded and, through actions, determines decisions’ outcomes via sensemaking. The objectives of this critical essay are to examine the impact of motivated reasoning on sensemaking and, thus, decision-making through scrutinising how actors make sense of projects and contexts to yield meanings. The focus of the discussion is on the human interactional aspects of decisions to examine potential bias, effected through the vague goals held by the actors, and the assumption of rationality, extending to bounded rationality, and how that leads to traps/pitfalls in decision-making. The discussion encompasses the concepts of sensemaking and of motivated reasoning in construction decisions from the perspectives of the dominant logic and the dynamic states of flux in the construction environment – in particular, the aspects of open-mindedness and directional bias, over-optimism, and attitudinal predispositions which impact on motivated reasoning of decision-makers in construction projects. This essay concludes that motivated reasoning, as a bias vector, operates to influence how actors arrive at understandings, reach decisions and behave to generate outcomes. The motivated reasoning perspective gives insight into the nature of decision-making in many project processes and the outcomes achieved. Journal: Construction Management and Economics Pages: 623-634 Issue: 11 Volume: 36 Year: 2018 Month: 11 X-DOI: 10.1080/01446193.2018.1472386 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1472386 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:11:p:623-634 Template-Type: ReDIF-Article 1.0 Author-Name: Rita Lavikka Author-X-Name-First: Rita Author-X-Name-Last: Lavikka Author-Name: Johanna Kallio Author-X-Name-First: Johanna Author-X-Name-Last: Kallio Author-Name: Thomas Casey Author-X-Name-First: Thomas Author-X-Name-Last: Casey Author-Name: Miimu Airaksinen Author-X-Name-First: Miimu Author-X-Name-Last: Airaksinen Title: Digital disruption of the AEC industry: technology-oriented scenarios for possible future development paths Abstract: Decision-makers in the architecture, engineering and construction (AEC) industry lack knowledge about the implementation of digitalization to generate value. We applied a scenario planning method developed by Schoemaker and Mavaddat to provide decision-makers with information for using digital data and technologies to create value for customers. We aim to theoretically understand how the scenario planning process helps AEC decision-makers to make sense of the future. Our findings show that boundary spanners are needed for steering the discussions among industry actors towards shared knowledge about the technological, social, economic and political changes needed at the industry level to optimize the benefits of digitalization. Our findings also show that boundary spanners apply scenario figures as boundary objects to cross knowledge boundaries. Based on our findings, we theoretically conceptualize scenario planning as a boundary-spanning activity that enables AEC decision-makers from different fields to share tacit knowledge and to cross knowledge boundaries. The practical implication is that scenario planning provides a method for AEC decision-makers to make sense of the changes needed to realize the preferred future for the industry. Journal: Construction Management and Economics Pages: 635-650 Issue: 11 Volume: 36 Year: 2018 Month: 11 X-DOI: 10.1080/01446193.2018.1476729 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1476729 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:11:p:635-650 Template-Type: ReDIF-Article 1.0 Author-Name: Mike Bresnen Author-X-Name-First: Mike Author-X-Name-Last: Bresnen Title: Being careful what we wish for? Challenges and opportunities afforded through engagement with business and management research Abstract: Despite the proliferation of work within construction management that draws upon management and organizational theory, two omissions stand out from the body of published work: the absence of any real debate about the values of rigour and relevance in research; and the under-use of dominant perspectives in business and management research (such as institutional theory) to frame construction management and organizational issues. Drawing specifically upon the ideas of institutional logics and institutional work, this paper explores the tensions, ironies and contradictions of the rigour-relevance debate; and the challenges and opportunities facing construction management research (CMR) and its institutions in furthering management and organizational research agendas. In doing so, attention is directed to the complex, contested and changing nature of the knowledge base within the business and management field; as well as key differences between that community of practice and CMR. Journal: Construction Management and Economics Pages: 24-34 Issue: 1-2 Volume: 35 Year: 2017 Month: 2 X-DOI: 10.1080/01446193.2016.1270462 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1270462 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:1-2:p:24-34 Template-Type: ReDIF-Article 1.0 Author-Name: Lauri Koskela Author-X-Name-First: Lauri Author-X-Name-Last: Koskela Title: Why is management research irrelevant? Abstract: At least since 1980, there has been a practically continuous, but somewhat fragmented discussion on the relevance of management research. This discussion has addressed practically all fields of management; here, besides general management, operations management, project management and construction management are examined in more detail. Although many different proposals have been made to rectify the situation, no definitive resolution has been found. In this paper, it is argued that prior analyses have not reached the root causes of the irrelevance problem. By an analysis of the recent history of management research, the following novel findings are reached. First, the root cause of the irrelevance is argued to lie in the 1959 reports on American business education, written by Pierson and Gordon & Howell. Second, while the proposed direction in the 1959 reports was deficient in several ways, the rejection of production as an integral part of organizations and management has been perhaps the most damaging feature of those reports. Third, current research on management suffers from a variety of immediate causes for irrelevance, insufficiently recognized by the scholarly community. It is suggested that reaching the root causes for irrelevance will facilitate finding suitable cures. Journal: Construction Management and Economics Pages: 4-23 Issue: 1-2 Volume: 35 Year: 2017 Month: 2 X-DOI: 10.1080/01446193.2016.1272759 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1272759 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:1-2:p:4-23 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Styre Author-X-Name-First: Alexander Author-X-Name-Last: Styre Title: Thinking about materiality: the value of a construction management and engineering view Abstract: The increased interest for materiality as an analytical category in the social sciences provide construction management and economics scholar with new possibilities to better exploit the detailed empirical data being collected in the construction industry and related fields. While constructivist and other idealist theories have tended to dominate the social sciences since at least the mid-sixties when the social sciences sought to release itself from the methodological dogmatism of the “hard sciences”, materiality is now recognized and subject to theorizing within different social science traditions. This article advocates a broad engagement with materiality within construction management research and presents a series of analytical concepts and empirical studies that stress how the built environment that human beings inhabit is far from passive, inert and stable as common sense thinking easily misleads analysts to believe. An image of materiality that recognizes an agential, dynamic and more fluid nature of materiality is thus arguably conducive to an intellectually stimulating construction management scholarship. Journal: Construction Management and Economics Pages: 35-44 Issue: 1-2 Volume: 35 Year: 2017 Month: 2 X-DOI: 10.1080/01446193.2016.1272760 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1272760 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:1-2:p:35-44 Template-Type: ReDIF-Article 1.0 Author-Name: Rafael Sacks Author-X-Name-First: Rafael Author-X-Name-Last: Sacks Author-Name: Olli Seppänen Author-X-Name-First: Olli Author-X-Name-Last: Seppänen Author-Name: Vitaliy Priven Author-X-Name-First: Vitaliy Author-X-Name-Last: Priven Author-Name: Jonathan Savosnick Author-X-Name-First: Jonathan Author-X-Name-Last: Savosnick Title: Construction flow index: a metric of production flow quality in construction Abstract: A new, process-oriented approach is needed in construction management. Lean construction emphasizes the concept of flow as a way to understand production in construction, yet there is still no accepted metric for measurement of flow quality. This has hampered research and practice. The proposed construction flow index (CFI) is a composite measure that reflects the quality of production flow in repetitive construction projects. It incorporates measures of work continuity for crews, processing continuity for locations, production rate variation, amounts of work in progress, interference and operation sequence logic. Expert knowledge was acquired to establish weights for the CFI parameters, and its use was tested in evaluating the planned and actual production flows for a number of projects. Project managers can use the CFI to evaluate the quality of their construction plans and to measure and communicate production flow quality status to trade crews, enabling management and improvement of production flow. The CFI is also a valuable tool for construction research. The CFI challenges traditional construction management by measuring flow, where standard practice only measures transformation (earned value). It challenges lean construction practice using the Last Planner System, suggesting that the percent plan complete measure of plan reliability is insufficient. Journal: Construction Management and Economics Pages: 45-63 Issue: 1-2 Volume: 35 Year: 2017 Month: 2 X-DOI: 10.1080/01446193.2016.1274417 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1274417 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:1-2:p:45-63 Template-Type: ReDIF-Article 1.0 Author-Name: Matthew R. Hallowell Author-X-Name-First: Matthew R. Author-X-Name-Last: Hallowell Author-Name: Dillon Alexander Author-X-Name-First: Dillon Author-X-Name-Last: Alexander Author-Name: John A. Gambatese Author-X-Name-First: John A. Author-X-Name-Last: Gambatese Title: Energy-based safety risk assessment: does magnitude and intensity of energy predict injury severity? Abstract: Although the quantity and quality of safety risk data have improved in recent years, available data do not link directly to natural principles and are, therefore, limited in their application and scientific extension. The present study aims to test the hypothesis that the quantity and intensity of energy observable prior to an incident predicts the severity of the incident. The hypothesis is built upon the theory that energy is translated to an injury through uncontrolled release of the energy, transfer of the energy to the human body and the vulnerability of the body and associated protective equipment. To test the hypothesis, a multi-phase experiment was conducted. First, over 500 injury reports were gathered from national databases and private companies. For each report, the leading information describing the work operations and environment and the lagging information describing the injury were extracted, separated and isolated. Second, the magnitude of the energy was estimated using only leading information. Once energy magnitude was quantified, the distribution was compared across injury severity levels using analysis of variance tests. As hypothesized, energy magnitude is a strong predictor of injury severity. Although computationally intensive, energy intensity, defined as the magnitude of energy divided by the area of contact between an object and the human body, showed strong predictive validity. This research indicates that energy-based safety risk analysis has predictive validity and is a promising line of scientific inquiry with the potential to increase our understanding of the natural phenomena that contribute to injuries. Journal: Construction Management and Economics Pages: 64-77 Issue: 1-2 Volume: 35 Year: 2017 Month: 2 X-DOI: 10.1080/01446193.2016.1274418 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1274418 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:1-2:p:64-77 Template-Type: ReDIF-Article 1.0 Author-Name: Roine Leiringer Author-X-Name-First: Roine Author-X-Name-Last: Leiringer Author-Name: Andy Dainty Author-X-Name-First: Andy Author-X-Name-Last: Dainty Title: Construction Management and Economics: New Directions Journal: Construction Management and Economics Pages: 1-3 Issue: 1-2 Volume: 35 Year: 2017 Month: 2 X-DOI: 10.1080/01446193.2017.1275159 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1275159 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:1-2:p:1-3 Template-Type: ReDIF-Article 1.0 Author-Name: Daniel John Sage Author-X-Name-First: Daniel John Author-X-Name-Last: Sage Title: Rethinking construction expertise with posthumanism Abstract: Expertise is commonly understood to be a distinct, even defining, aspect of being human: an attribute related to our efficacies to come to know and influence the, mostly non-human, world around us. In construction, expertise is commonly defined as the acquisition of skills and knowledge related to new technical processes, organizational routines, health and safety codes, even cultural norms. Despite the development of rule-following ‘expert systems’ in construction and beyond, the proposal that non-human technologies and artefacts can share our expertise is thus to be regarded with doubt: humans are human because of their lived expertise to undertake tasks faster and better than machines and other non-humans. Increasingly, however, this anthropocentric view of expertise can be challenged by a ‘posthuman turn’ that is gathering pace across the social sciences and humanities. The work of four seminal posthuman thinkers is drawn upon to evaluate the distinct, and varied, contribution that posthumanism might make to how we understand notions of construction expertise. Fictional examples of construction practices illustrate the challenge and theoretical and practical opportunities in rethinking construction expertise via posthumanism. Journal: Construction Management and Economics Pages: 446-457 Issue: 7-8 Volume: 34 Year: 2016 Month: 8 X-DOI: 10.1080/01446193.2015.1122201 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1122201 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:7-8:p:446-457 Template-Type: ReDIF-Article 1.0 Author-Name: Hans Voordijk Author-X-Name-First: Hans Author-X-Name-Last: Voordijk Author-Name: Arjen Adriaanse Author-X-Name-First: Arjen Author-X-Name-Last: Adriaanse Title: Engaged scholarship in construction management research: the adoption of information and communications technology in construction projects Abstract: The objective is to explore what engaged scholarship (ES) could mean for construction management research in facilitating interactions between practice and theory. ES aims to develop knowledge that advances both science and practice through engagement of scholars with practice. Three types of ES are discussed: practice research, design research and action research. These three kinds of ES are explained through their different knowledge–action relations: action theories or ‘knowledge about action’, design research or ‘knowledge for action’, and action research or ‘knowledge through action’. The relevance of these three types of ES in facilitating interactions between practice and theory is clarified through elaborating on a research programme on the adoption of information and communications technology (ICT) in construction projects. First, based on grounded theory, a model is developed to understand and explain why individuals and organizations are (not) using ICT in the intended way. Second, based on this model and expert interviews, solutions are designed to potential barriers to the successful use of ICT in construction projects. Third, interventions in construction projects based on these solutions are presented. It is argued that the different kinds of ES presuppose each other and are all needed to facilitate interactions between practice and theory in construction management research. Journal: Construction Management and Economics Pages: 536-551 Issue: 7-8 Volume: 34 Year: 2016 Month: 8 X-DOI: 10.1080/01446193.2016.1139145 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1139145 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:7-8:p:536-551 Template-Type: ReDIF-Article 1.0 Author-Name: Sittimont Kanjanabootra Author-X-Name-First: Sittimont Author-X-Name-Last: Kanjanabootra Author-Name: Brian Corbitt Author-X-Name-First: Brian Author-X-Name-Last: Corbitt Title: Reproducing knowledge in construction expertise: a reflexive theory, critical approach Abstract: An auto-ethnography and then analyses of narratives and ethnographies of other construction professionals are used to argue that reproduction of knowledge and expertise development is constrained by both normative professional thinking and a discourse of economic constraint generated by a highly competitive marketplace with a focus on time, cost, and quality trade-offs. The analysis of construction professionals’ narratives suggests that expertise development in construction is essentially an incremental process built on scenarios and influenced mostly by context and people, discourses of practices, legalities and professional expectations. Sometimes that incrementalism is distorted through radical innovation, but that is rare. Construction expertise in these stories is reproduced from base level learning and grows through practice. Practitioners, it is argued, accumulate knowledge and expertise, but the practice that emanates remains bounded within prevailing discourse which itself changes incrementally. Journal: Construction Management and Economics Pages: 561-577 Issue: 7-8 Volume: 34 Year: 2016 Month: 8 X-DOI: 10.1080/01446193.2016.1151064 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1151064 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:7-8:p:561-577 Template-Type: ReDIF-Article 1.0 Author-Name: Lloyd M. Scott Author-X-Name-First: Lloyd M. Author-X-Name-Last: Scott Title: Theory and research in construction education: the case for pragmatism Abstract: The education of the construction professional, like many others, has been shaped and nurtured by well-intentioned educationalists throughout the ages. While there has been much discourse around the theoretical underpinnings of construction education, not much has been set in writing. A philosophical position has not always been to the forefront of those pioneering and well-intentioned construction educationalists. There has been, rather, a ‘systems thinking’ approach, a sense of wanting to prepare an educational experience that would equip the future leaders in construction to ensure they would develop the knowledge, skills and competences to take their place in an ever-changing architecture, engineering and construction (AEC) industry. Now, at least around Europe, there is an ever-increasing attempt to identify the paradigms within which construction education sits comfortably, thus attempting to pave the way for the future. This could be called a philosophical positioning. There follows an exploration of the evolution of the education of the construction professional through a review of the literature and other sources in an attempt to make some sense of this journey. The paper also presents the discourse from the educational research perspective where the connection between the role of theory and philosophy has been a matter of discussion for many years. Biesta in his work calls for the intelligent use of theory and philosophy and advocates pragmatic positioning in regard to discourse. This pragmatic framework offers the freedom to gain control over what construction education constitutes as it offers a way of thinking that allows the educationalist freedom to challenge. What is presented and debated is the discussion that has been documented with a view to offering some perspective on its importance. Some philosophical perspective is also offered around the developments with the added suggestion that AEC is firmly seated in the ‘pragmatic’ paradigm. Much progress has been achieved to date but it is now time to offer a possible further step forward. While a pragmatic philosophical position is suggested it is not to imply that this is the only tool that might be used. The freedom to work within the pragmatic paradigm offers diversity that can draw together some of the thoughts that challenge and build the arguments about the role and position of theory in construction education. Journal: Construction Management and Economics Pages: 552-560 Issue: 7-8 Volume: 34 Year: 2016 Month: 8 X-DOI: 10.1080/01446193.2016.1151539 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1151539 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:7-8:p:552-560 Template-Type: ReDIF-Article 1.0 Author-Name: Anne Kokkonen Author-X-Name-First: Anne Author-X-Name-Last: Kokkonen Author-Name: Pauli Alin Author-X-Name-First: Pauli Author-X-Name-Last: Alin Title: Practitioners deconstructing and reconstructing practices when responding to the implementation of BIM Abstract: When managers are implementing change, practitioners are sometimes seen as the receivers of the change. However, practitioners often need to actively create the changes to daily practices because managers might not be familiar with the practices. Building information modelling (BIM), an important driver of organizational change, requires change not only by bringing new technology into use but also to the practices of collaboration between different professions. In their daily work, practitioners can create new practices through reflective learning. We have a limited understanding of how practitioners are actively involved in a change through reflective learning when implementing BIM. To address this limitation, we conducted a qualitative case study. Our primary data consist of interviews, which were analysed with insights from philosophy. We identified two methods of reflective learning from the data: deconstruction and reconstruction. Deconstruction occurs when the new requirements for the practices are based on different ideas of work, which asks practitioners to change their old ideas before creating new practices. Reconstruction does not necessarily require changes to the basic ideas of work but changes are seen more as improvements. Our research contributes to construction management literature by linking the reflective learning of practitioners to the change caused by BIM. Journal: Construction Management and Economics Pages: 578-591 Issue: 7-8 Volume: 34 Year: 2016 Month: 8 X-DOI: 10.1080/01446193.2016.1164327 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1164327 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:7-8:p:578-591 Template-Type: ReDIF-Article 1.0 Author-Name: Sidney Newton Author-X-Name-First: Sidney Author-X-Name-Last: Newton Title: The being of construction management expertise Abstract: Where logical positivism potentially leads to abstraction, social constructivism potentially leads to relativism. Neither perspective does full justice to the study of construction management expertise. Social realism aims to recover declarative knowledge (theory) as an integral component of expertise without denying a place for deliberate practice. The issue is how to bridge between explicit and implicit forms of knowledge. Returning to the account of tacit knowing proposed by Polanyi, the nature of expertise is characterized in both declarative and personal knowledge terms. This is a limited characterization of expertise, but the social realism enterprise raises a number of critical issues: the body of knowledge; human agency; and deliberate practice. From a social realism perspective the production of theory is critical to the exercise of expertise, but theory is meaningless in the context of professional practice unless and until it is embodied and enacted. It is the being of construction management that gives purpose and value to the theory. Journal: Construction Management and Economics Pages: 458-470 Issue: 7-8 Volume: 34 Year: 2016 Month: 8 X-DOI: 10.1080/01446193.2016.1164328 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1164328 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:7-8:p:458-470 Template-Type: ReDIF-Article 1.0 Author-Name: Karen Mogendorff Author-X-Name-First: Karen Author-X-Name-Last: Mogendorff Title: The building or enactment of expertise in context: what the performative turn in the social sciences may add to expertise research in construction management Abstract: Expertise tends to be seen as something people possess: one needs to have the knowledge, skills and competences to be able to do a job well, preferably better than others, under various conditions. In practice not all objectively relevant knowledge and expertise gets endorsed as such. In multi-party settings different forms of expertise tend to compete with one another. The latter is certainly true for the construction sector in which parties with different backgrounds, stakes and interests work together in order to create or maintain buildings and infrastructural works. Existing knowledge and expertise need to be performed in order to get treated as relevant to the interactional business at hand by the people one collaborates with. Whose expertise is treated as most salient may differ across interaction settings that make up the different phases of a project. So far, however, what expertise is treated as relevant when in the day-to-day management of construction projects and the effects thereof have been understudied. The argument put forward is that expertise research informed by the performative turn in the social sciences may enrich the construction management research agenda. Performative studies tend to further insight in what expertise ends up to being treated as relevant when in actual practice, e.g. by researching how various expertises are discursively positioned relative to one another in multi-party settings. Insight into how and when existing expertise counts may be of help in developing strategies to ensure that expertise that is considered relevant but is underused in practice may be optimally deployed in the future. General directions are provided for how expertise may be researched from a performative perspective in construction. Journal: Construction Management and Economics Pages: 484-491 Issue: 7-8 Volume: 34 Year: 2016 Month: 8 X-DOI: 10.1080/01446193.2016.1164329 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1164329 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:7-8:p:484-491 Template-Type: ReDIF-Article 1.0 Author-Name: Eva Marie P. Gacasan Author-X-Name-First: Eva Marie P. Author-X-Name-Last: Gacasan Author-Name: Mark W. Wiggins Author-X-Name-First: Mark W. Author-X-Name-Last: Wiggins Author-Name: Ben J. Searle Author-X-Name-First: Ben J. Author-X-Name-Last: Searle Title: The role of cues in expert project manager sensemaking Abstract: Sensemaking forms the foundation of expertise as it comprises the initial stage of information processing that influences judgement and decision-making. Two related studies were undertaken to investigate the role of cues in the context of expert project management. First, a qualitative study was conducted using the critical incident technique and involving nine project managers who had successfully delivered projects. The data were analysed by identifying the critical incidents and the associated cues that were used as the basis of sensemaking in project-related situations. These cues converged into three categories: feedback, context cues and tacit knowledge. The second study examined the construct validity of the cues that emerged in Study 1 using a cue utilization scale that was administered through an online survey. There were 23 experienced project managers and 78 naïve participants who participated in the study. Differences in patterns of cue utilization were evident between the two cohorts based on the perceived levels of project complexity and project phases. The research outcomes offer empirical support for the relationship between cues and sensemaking in project management, and provide a basis for further research into the acquisition of sensemaking skills and the development of cue-based training initiatives to facilitate the progression towards expert project management. Journal: Construction Management and Economics Pages: 492-507 Issue: 7-8 Volume: 34 Year: 2016 Month: 8 X-DOI: 10.1080/01446193.2016.1177190 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1177190 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:7-8:p:492-507 Template-Type: ReDIF-Article 1.0 Author-Name: Pernilla Gluch Author-X-Name-First: Pernilla Author-X-Name-Last: Gluch Author-Name: Petra Bosch-Sijtsema Author-X-Name-First: Petra Author-X-Name-Last: Bosch-Sijtsema Title: Conceptualizing environmental expertise through the lens of institutional work Abstract: Although a growing number of environmental experts have entered the scene within the Architecture Engineering and Construction (AEC) industry, studies of environmental experts’ role and agency remain limited. In order to gain more clarity regarding the agency of environmental experts in relation to construction project practice the theoretical lens of institutional work is applied. A multidimensional framework, linking agency with three forms of institutional work, is used in a conceptual discussion on how environmental experts adopt various types of agency to influence institutional change towards a sustainable development of the AEC industry. Due to the fragmented and distributed project-based environment, the application of institutional work in the AEC industry uncovers tensions between various forms of institutional work processes. A dynamic model is therefore suggested to capture these tensions. Besides illustrating tensions, the model envisions the locked-in maintaining of institutions performed by iterative and practical-evaluative agency. Journal: Construction Management and Economics Pages: 522-535 Issue: 7-8 Volume: 34 Year: 2016 Month: 8 X-DOI: 10.1080/01446193.2016.1177191 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1177191 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:7-8:p:522-535 Template-Type: ReDIF-Article 1.0 Author-Name: Mark Addis Author-X-Name-First: Mark Author-X-Name-Last: Addis Title: Tacit and explicit knowledge in construction management Abstract: In construction, better practice has been sought through the employment of knowledge management. Interest in tacit knowledge has grown due to its importance for raising performance at all organizational levels. Aspects of the limits which tacit knowledge places on knowledge management approaches in construction are considered with the focus being upon broad knowledge management categories rather than the details of particular methods. The distinction between knowing how and knowing that coupled with examination of whether the main mode of knowing is tacit or explicit is used to analyse the relationship between tacit and explicit knowledge in construction. There are significant general theoretical difficulties with incorporating tacit knowledge into the objectivist knowledge management approaches which predominate in construction particularly since methods for converting tacit to explicit knowledge are problematic. Improving performance requires appreciating the limitations of objectivist and practice-based knowledge management within the context of construction projects as the consideration of performance management measures illustrates. Journal: Construction Management and Economics Pages: 439-445 Issue: 7-8 Volume: 34 Year: 2016 Month: 8 X-DOI: 10.1080/01446193.2016.1180416 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1180416 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:7-8:p:439-445 Template-Type: ReDIF-Article 1.0 Author-Name: Ani Raiden Author-X-Name-First: Ani Author-X-Name-Last: Raiden Title: Horseplay, care and hands on hard work: gendered strategies of a project manager on a construction site Abstract: The discourse of managerial expertise favours rational analysis and masculine ideals but contemporary management literature also recognises the value of well-being and employee voice in the workplace. Drawing upon narrative analysis of interview data, we share unique insights into the lived experiences of Laura, one female project manager who recently managed a construction site in the Midlands in the UK. In contrast to previous research which indicates that female managers tend to conform to quite a traditional set of gender behaviours, Laura embraces a range of workplace appropriate gendered strategies, such as hard work and horseplay, together with sensitivity and caring. She draws from this mix of gendered strategies in negotiating between two different discourses of construction: one professional and one tough and practical. Her behaviour both reproduces the masculine ideals (through horseplay and heroic management) and opens up possibilities for modernizing construction management (by caring). It is this combination of strategies that is at the heart of tacit expertise for Laura. Theoretically, the discussion adds to the development of a more nuanced understanding of management expertise as situated and person-specific knowledge that draws on both the explicit and tacit. Specifically, the centrality of gendered strategies beyond the masculine ideals to success on site is highlighted. Journal: Construction Management and Economics Pages: 508-521 Issue: 7-8 Volume: 34 Year: 2016 Month: 8 X-DOI: 10.1080/01446193.2016.1182637 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1182637 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:7-8:p:508-521 Template-Type: ReDIF-Article 1.0 Author-Name: Paul W. Chan Author-X-Name-First: Paul W. Author-X-Name-Last: Chan Title: Expert knowledge in the making: using a processual lens to examine expertise in construction Abstract: Expertise in construction has typically been associated with the esoteric, where experts occupy privileged positions through their possession of specialist skills and knowledge. In this conceptual piece, an attempt is made to broaden this view of expertise found in the construction management literature by drawing on a reading of the process philosophical writings of Henri Bergson and others. Re-reading expertise from a processual standpoint, it is argued that our conceptualization of expertise in construction management should move beyond its treatment as a thing to bring to the fore expertise as an open-ended, ongoing, ever-evolving process of becoming. At the heart of this ontological shift of expertise in construction lies the emphasis on the tacit and recognition that expertise is, at the same time, interactional, intuitive and incidental. These ideas are illustrated in a vignette of environmental expertise in an airport context. Journal: Construction Management and Economics Pages: 471-483 Issue: 7-8 Volume: 34 Year: 2016 Month: 8 X-DOI: 10.1080/01446193.2016.1190851 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1190851 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:7-8:p:471-483 Template-Type: ReDIF-Article 1.0 Author-Name: Bingunath Ingirige Author-X-Name-First: Bingunath Author-X-Name-Last: Ingirige Title: Theorizing construction industry practice within a disaster risk reduction setting: is it a panacea or an illusion? Abstract: Construction industry practice is strongly influenced by the culture surrounding its operations and, with the prevailing emphasis on achieving efficiency, there is a strong focus on outcome metrics such as profitability and employee productivity. With the recent increases in natural hazard events worldwide, and the likelihood that this will worsen still further with anticipated climate changes, the industry is increasingly contributing to building resilience within disaster-affected communities. Existing industry expertise, its educational approaches and the related theoretical frameworks, however, all require adjustment if these changing needs are to be fully addressed. Most importantly, an agenda shift is required from the philosophical side and a more pragmatic approach is needed if community resilience goals and objectives are to be met, rather than the narrower focus of the current metrics-driven management system. A synthesis of the current literature is therefore presented, along with relevant case histories illustrating how such an agenda shift within a disaster management context may influence the development of appropriate theory, as well as impacting upon grass-roots educational requirements. The research concludes by discussing how the ‘mainstreaming’ of disaster management within construction industry practice could drive forward developments in theorizing expertise and educational provisions across the constituent disciplines. Journal: Construction Management and Economics Pages: 592-607 Issue: 7-8 Volume: 34 Year: 2016 Month: 8 X-DOI: 10.1080/01446193.2016.1200735 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1200735 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:7-8:p:592-607 Template-Type: ReDIF-Article 1.0 Author-Name: Mark Addis Author-X-Name-First: Mark Author-X-Name-Last: Addis Author-Name: David Boyd Author-X-Name-First: David Author-X-Name-Last: Boyd Author-Name: Ani Raiden Author-X-Name-First: Ani Author-X-Name-Last: Raiden Title: Special Issue: Theorizing Expertise in Construction Journal: Construction Management and Economics Pages: 433-438 Issue: 7-8 Volume: 34 Year: 2016 Month: 8 X-DOI: 10.1080/01446193.2016.1204801 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1204801 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:7-8:p:433-438 Template-Type: ReDIF-Article 1.0 Author-Name: Michael Falta Author-X-Name-First: Michael Author-X-Name-Last: Falta Author-Name: Natalie Gallery Author-X-Name-First: Natalie Author-X-Name-Last: Gallery Title: Unintended consequences of regulatory reporting requirements for small and medium size construction entities: Australian evidence Abstract: The Queensland Building Services Authority (QBSA) regulates the construction industry in Queensland, Australia, with licensing requirements creating differential financial reporting obligations, depending on firm size. Economic theories of regulation and behaviour provide a framework for investigating effects of the financial constraints and financial reporting requirements imposed by QBSA licensing. Data are analysed for all small and medium construction entities operating in Queensland between 2001 and 2006. Findings suggesting that construction licensees are categorizing themselves as smaller to avoid the more onerous and costly financial reporting of higher licensee categories are consistent with US findings from the 2002 Sarbanes-Oxley (SOX) regulation which created incentives for small firms to stay small to avoid the costs of compliance with more onerous financial reporting requirements. Such behaviour can have the undesirable economic consequences of adversely affecting employment, investment, wealth creation and financial stability. Insights and implications from the analysed QBSA processes are important for future policy reform and design, and useful to be considered where similar regulatory approaches are planned. Journal: Construction Management and Economics Pages: 1121-1135 Issue: 11 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.635666 File-URL: http://hdl.handle.net/10.1080/01446193.2011.635666 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:11:p:1121-1135 Template-Type: ReDIF-Article 1.0 Author-Name: X.-X. Yuan Author-X-Name-First: X.-X. Author-X-Name-Last: Yuan Title: A correlated bidding model for markup size decisions Abstract: Whereas competitive bidding models have been studied for more than five decades with many factors being considered and statistical methods proposed, the correlation among bids of different companies and its effects on markup decisions have not been explored. Through a multivariate competitive bidding model, the significance of the correlation is investigated in this paper. Mechanistic arguments and probabilistic analysis based on a breakdown of cost estimates show that bid ratios are positively correlated to one another. This fact is then incorporated as a priori information into a Bayesian statistical method to estimate the correlation coefficients from historical data with missing values. The effectiveness of the proposed Bayesian method has been demonstrated through a case study. The proposed bidding model has a flexible mathematical structure, which allows one to better characterize actual varying bidding patterns. It also includes the Friedman and Carr models as its special cases. Moreover, through the use of the streamlined Bayesian method, the new model can be implemented easily in practice. Journal: Construction Management and Economics Pages: 1101-1119 Issue: 11 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.637568 File-URL: http://hdl.handle.net/10.1080/01446193.2011.637568 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:11:p:1101-1119 Template-Type: ReDIF-Article 1.0 Author-Name: Wei Pan Author-X-Name-First: Wei Author-X-Name-Last: Pan Author-Name: Robert Sidwell Author-X-Name-First: Robert Author-X-Name-Last: Sidwell Title: Demystifying the cost barriers to offsite construction in the UK Abstract: Offsite construction has long been reported as an effective alternative to conventional construction, with wide-ranging benefits. However, a wider take-up has been inhibited by perceived cost barriers which are insufficiently studied. Such cost barriers are addressed, drawing on an examination of the cost performance of four types of construction method: pre-cast concrete cross-wall panel, in-situ reinforced concrete (RC) frame, steel frame and timber frame. Data were collected for 20 medium to high rise residential buildings of eight projects by a leading UK housebuilder over a five-year period (2004–08). In all cases, detailed cost comparisons were completed for build method selection. Cross-wall was found to be consistently cheaper than RC frame or steel frame by 11% to 32% in the projects. The process of developing and innovating cross-wall technology led to sustained cost savings up to 25% from its first use. Cross-wall construction also improved cost effectiveness of 20-storey high rise buildings over other solutions. Cost engineering means for achieving cost reduction and effectiveness are identified, which included efficiency learning, technological innovation, multinational partnering, and ‘in-house’ build management. The results prove the logic of the experience curve in improving the cost efficiency of offsite construction, and should encourage offsite construction in the future. Journal: Construction Management and Economics Pages: 1081-1099 Issue: 11 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.637938 File-URL: http://hdl.handle.net/10.1080/01446193.2011.637938 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:11:p:1081-1099 Template-Type: ReDIF-Article 1.0 Author-Name: Kaixun Sha Author-X-Name-First: Kaixun Author-X-Name-Last: Sha Title: Vertical governance of construction projects: an information cost perspective Abstract: A research framework is developed to analyse the vertical governance, or transaction relationships between the client and its first-tier suppliers of construction projects in terms of project procurement route and payment terms. Starting from the particularity of the construction industry, reduced treatments that Williamson used in governance structure analysis are revised, and an assumption of ‘second-order transformation’ is proposed: as the information gap reaches a given level, and the proportion of specialized knowledge to deal with uncertainty exceeds a certain degree, the approach of selecting the governance structure of construction projects might deviate from the path anticipated by canonical theories. Both uncertainty and information cost are included in the analysis framework, and a principal–agent model is developed to analyse the procurement route and payment terms of construction projects. It is concluded that the information gap and the relative cost coefficient of information are decisive factors that determine the vertical governance structure of construction projects. They determine not only the time when ‘second-order transformation’ occurs, but also the distribution of ‘weak incentive regions’. Journal: Construction Management and Economics Pages: 1137-1147 Issue: 11 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.637939 File-URL: http://hdl.handle.net/10.1080/01446193.2011.637939 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:11:p:1137-1147 Template-Type: ReDIF-Article 1.0 Author-Name: Richard Fellows Author-X-Name-First: Richard Author-X-Name-Last: Fellows Title: Mediation in the Construction Industry: An International Review Journal: Construction Management and Economics Pages: 1175-1177 Issue: 11 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.639378 File-URL: http://hdl.handle.net/10.1080/01446193.2011.639378 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:11:p:1175-1177 Template-Type: ReDIF-Article 1.0 Author-Name: Ekaterina Osipova Author-X-Name-First: Ekaterina Author-X-Name-Last: Osipova Author-Name: Per Eriksson Author-X-Name-First: Per Author-X-Name-Last: Eriksson Title: How procurement options influence risk management in construction projects Abstract: Before proceeding with a project, a client has to choose an appropriate procurement option that facilitates an effective project organization in general and a thorough risk management process in particular. By identifying three procurement variables that have a major influence on risk management: project delivery method, form of payment, and use of collaboration or partnering arrangements, the effect of each variable is studied. An exploratory study and a series of interviews with clients, contractors and consultants involved in 11 Swedish construction projects, were performed in order to examine how risk management was carried out in each project. Irrespective of the procurement option, many projects suffered from variations in cost affecting one or more actors. Risk management was not carried out systematically throughout project phases. However, in the projects with early involvement of the actors, their participation throughout the project, and opportunities for open dialogue and collaboration, a more thorough risk management process was found. While project delivery methods define formal risk allocation, the use of incentives and collaboration or partnering arrangements help to establish a collaborative approach to risk management. Journal: Construction Management and Economics Pages: 1149-1158 Issue: 11 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.639379 File-URL: http://hdl.handle.net/10.1080/01446193.2011.639379 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:11:p:1149-1158 Template-Type: ReDIF-Article 1.0 Author-Name: Elizabeth Jordan Author-X-Name-First: Elizabeth Author-X-Name-Last: Jordan Author-Name: Martha Gross Author-X-Name-First: Martha Author-X-Name-Last: Gross Author-Name: Amy Javernick-Will Author-X-Name-First: Amy Author-X-Name-Last: Javernick-Will Author-Name: Michael Garvin Author-X-Name-First: Michael Author-X-Name-Last: Garvin Title: Use and misuse of qualitative comparative analysis Abstract: Research in construction is often confronted with a trade-off of selecting either in-depth studies of small-N cases, which may affect generalization of findings, or statistical large-N studies, which may limit examination of causal links. Qualitative comparative analysis (QCA) provides a middle ground between these options, allowing researchers to analytically determine different combinations of conditions that produce an outcome in comparative studies. QCA has been applied extensively in other fields; however, the method has only recently started to gain traction in construction research. Guidance on the implementation of QCA is provided, including: a description of the method and its variants; stages required for its application; its benefits and critiques; applications in the construction field; and recommendations for scholars employing the method. QCA is a promising approach for probing causal links via investigations between variable-based, large-N analyses and qualitative, case-based, small-N studies. However, researchers must not use the method in haste or simply to obtain quantitative results from qualitative data. It requires significant time and rigour to determine and justify the conditions, outcomes and cases used in its application. QCA is well suited for research where interactions between conditions and outcomes are not well understood and can be used to build theory in the complex environment of construction. Journal: Construction Management and Economics Pages: 1159-1173 Issue: 11 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.640339 File-URL: http://hdl.handle.net/10.1080/01446193.2011.640339 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:11:p:1159-1173 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Editorial Journal: Construction Management and Economics Pages: 1079-1080 Issue: 11 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.643655 File-URL: http://hdl.handle.net/10.1080/01446193.2011.643655 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:11:p:1079-1080 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Forthcoming events Journal: Construction Management and Economics Pages: 1179-1179 Issue: 11 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.643657 File-URL: http://hdl.handle.net/10.1080/01446193.2011.643657 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:11:p:1179-1179 Template-Type: ReDIF-Article 1.0 Author-Name: Niamh Murtagh Author-X-Name-First: Niamh Author-X-Name-Last: Murtagh Author-Name: Loulwa Achkar Author-X-Name-First: Loulwa Author-X-Name-Last: Achkar Author-Name: Aeli Roberts Author-X-Name-First: Aeli Author-X-Name-Last: Roberts Title: The role of building control surveyors and their power in promoting sustainable construction Abstract: In England, building regulations govern aspects of a building’s environmental performance. The Building Control Surveyor reviews designs and on-site construction in order to evaluate, and ultimately certify, compliance with the regulations, but little research has been carried out to investigate the role of these professionals in promoting sustainable construction. A qualitative study was conducted, comprising semi-structured interviews with 21 building control surveyors and 4 key informants from professional bodies in England. The building surveyors initially positioned their power as wholly derived from the regulations, thus constraining their contribution on sustainability to regulation enforcement. However, this stood in contradiction to their recognition of being valued and influential members of the project team. Descriptions of day-to-day activities included sharing common goals with the team, providing guidance based on their knowledge and experience, and developing collaborative relationships. Based on theories of power, these practices may be seen as processes of power. The primary conclusion is that building control surveyors are indeed powerful in the project team, and, with greater recognition of the varied forms of power available to them above and beyond regulatory certification, they could extend their influence in daily working interactions to promote more sustainable construction. Journal: Construction Management and Economics Pages: 363-374 Issue: 7 Volume: 36 Year: 2018 Month: 7 X-DOI: 10.1080/01446193.2017.1397721 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1397721 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:7:p:363-374 Template-Type: ReDIF-Article 1.0 Author-Name: Sherif Zedan Author-X-Name-First: Sherif Author-X-Name-Last: Zedan Author-Name: Wendy Miller Author-X-Name-First: Wendy Author-X-Name-Last: Miller Title: Quantifying stakeholders’ influence on energy efficiency of housing: development and application of a four-step methodology Abstract: Identifying stakeholders’ influence on project outcomes, prioritizing their importance and managing their interests accordingly is an effective strategy for maximizing benefits for organizations. Quantifying the influence of stakeholders on energy efficiency of housing allows for the development of an engagement plan that takes into consideration stakeholders’ diverse goals, needs, levels of expertise, knowledge, authority, connectivity and closeness to decision-making processes throughout the different stages of the housing procurement. We present a theoretical approach for quantifying the influence of stakeholders on the thermal performance of housing. The quantification methodology builds on a number of stakeholder management approaches and is applied to Australian case studies for reflection and sense making. The quantification of the degree of influence is calculated by combining the rankings of stakeholders in six attributes that affect their influence on a building’s energy efficiency outcomes. Quantifying human influence on buildings’ energy efficiency can help future researchers and housing industry stakeholders in integrating the human aspect with technological, technical, economic and regulatory aspects to optimize the performance outcomes of energy efficient housing. Journal: Construction Management and Economics Pages: 375-393 Issue: 7 Volume: 36 Year: 2018 Month: 7 X-DOI: 10.1080/01446193.2017.1411599 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1411599 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:7:p:375-393 Template-Type: ReDIF-Article 1.0 Author-Name: J. Barraket Author-X-Name-First: J. Author-X-Name-Last: Barraket Author-Name: M. Loosemore Author-X-Name-First: M. Author-X-Name-Last: Loosemore Title: Co-creating social value through cross-sector collaboration between social enterprises and the construction industry Abstract: Emerging social procurement imperatives are driving new forms of cross-sector collaboration between private, public and social enterprise sectors in the construction industry. Yet there is little understanding of how and why social enterprises and private construction firms collaborate in meeting new social procurement imperatives and of the institutional and organizational factors shape these practices. Drawing on theoretical insights from governance, management and policy studies and three case studies of major organizations from across the construction social value chain, the organizational and institutional factors that drive cross-sector collaborations are explored. Documentary analysis of social procurement strategy and policy, non-participant observation of social procurement initiatives in action and in-depth interviews with senior social procurement champions suggest that existing processes of social value co-creation through supply chain relationships more closely reflect a cooperative than a collaborative model, are largely driven by commercial concerns and influenced by industry norms and institutional imperatives. It is concluded that there are significant differences in experience and opportunity for collaboration based on supply chain position and organizational scale and that these have notable effects on the co-creation of social value and the legitimacy of different social benefit providers in the construction industry. Journal: Construction Management and Economics Pages: 394-408 Issue: 7 Volume: 36 Year: 2018 Month: 7 X-DOI: 10.1080/01446193.2017.1416152 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1416152 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:7:p:394-408 Template-Type: ReDIF-Article 1.0 Author-Name: F.T.T. Phua Author-X-Name-First: F.T.T. Author-X-Name-Last: Phua Title: The role of organizational climate in socially embedding construction firms’ sustainability goals Abstract: Despite the growing interest in sustainability research, little scholarly attention, both conceptual and empirical, has been given to assessing the individual-level behavioural issues that affect sustainability outcomes. Still less research is undertaken to examine the mechanisms by which construction firms enable their sustainability goals to be socially embedded within their organizations to shape the behaviour and attitudes of employees. In an attempt to fill this gap, this paper draws from the extensive literature on organizational climate perspective to explain how organizational-level characteristics and processes can result in a strong, conducive climate that fosters shared perceptions and guide behaviours that are fundamental to the attainment of sustainability goals in organizations. From the critical review of this literature, this paper offers three research propositions and avenues in which they could be tested. The paper concludes with a broadened discussion of the theoretical and practical implications this framework has on advancing the sustainability discourse within CM discipline beyond the current largely technical, policy and institutional foci. Journal: Construction Management and Economics Pages: 409-421 Issue: 7 Volume: 36 Year: 2018 Month: 7 X-DOI: 10.1080/01446193.2018.1424348 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1424348 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:7:p:409-421 Template-Type: ReDIF-Article 1.0 Author-Name: Dilek U. Duman Author-X-Name-First: Dilek U. Author-X-Name-Last: Duman Author-Name: Stuart D. Green Author-X-Name-First: Stuart D. Author-X-Name-Last: Green Author-Name: Graeme D. Larsen Author-X-Name-First: Graeme D. Author-X-Name-Last: Larsen Title: Historical narratives as strategic resources: analysis of the Turkish international contracting sector Abstract: The Turkish contracting sector has an enviable reputation for operating in high-risk international markets. The sector’s ability to respond to market instability could meaningfully be construed as sectoral-level capability. We aim to demonstrate how history can be mobilised in a formalised “strategy text” to create a strategic narrative on the sectoral level. The Geography of Contractors as published by the Turkish Contractors Association (TCA) ostensively portrays the strategic development of Turkish international contractors over four decades. Such quasi-historical narratives are routinely mobilised for the purposes of creating a shared memory on the sectoral level. The chosen strategy text draws from multiple narrative fragments derived from past experience to generate a strategic agenda for the future. The representation given to multiple voices reflects the pluralistic nature of strategy making praxis. The overarching strategy narrative reflects a performative intent in legitimising some practices whilst discrediting others. Narrative analysis demonstrates the way in which actors, actions and events are positioned within a plot structure, with direct implications for the enactment of future strategic practices. The findings suggest that strategic actions can only ever be identified in retrospect and that such arguments are always made with an eye on the future. Journal: Construction Management and Economics Pages: 367-383 Issue: 7 Volume: 37 Year: 2019 Month: 7 X-DOI: 10.1080/01446193.2018.1529416 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1529416 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:7:p:367-383 Template-Type: ReDIF-Article 1.0 Author-Name: Long D. Nguyen Author-X-Name-First: Long D. Author-X-Name-Last: Nguyen Author-Name: Long Le-Hoai Author-X-Name-First: Long Author-X-Name-Last: Le-Hoai Author-Name: Dai Q. Tran Author-X-Name-First: Dai Q. Author-X-Name-Last: Tran Author-Name: Chau N. Dang Author-X-Name-First: Chau N. Author-X-Name-Last: Dang Author-Name: Chau V. Nguyen Author-X-Name-First: Chau V. Author-X-Name-Last: Nguyen Title: Effect of project complexity on cost and schedule performance in transportation projects Abstract: Project complexity is a contributing factor to project performance. Understanding how project complexity interacts with management actions and project performance is imperative. This study fills this knowledge gap by empirically exploring the relationship between construction project complexity and project performance and their interaction with resource allocation. Empirical data were collected from 79 transportation projects. Due to its capability to build several regression models by adding independent variables to previous models, moderated hierarchical regression analyses were conducted to identify the underlying effect of resource allocation on the project complexity and performance relationship. The results show that: (i) project complexity was significantly correlated with schedule growth (positive correlation) but not significantly correlated with cost growth; (ii) resource allocation was significantly correlated with schedule growth (negative correlation) but not with cost growth; and (iii) resource allocation had a buffering effect where increasing resource allocation significantly decreases the effect of project complexity on schedule growth. The findings from this study contribute to the extant literature on construction project complexity by empirically showing that the impact of project complexity on schedule performance interacts with the level of resource allocation. This understanding of the role of resource allocation may help construction managers and engineers to better administer and manage their complex transportation projects. The findings also imply that organizations should appropriately evaluate project complexity to allocate necessary resources to achieve project success. Journal: Construction Management and Economics Pages: 384-399 Issue: 7 Volume: 37 Year: 2019 Month: 7 X-DOI: 10.1080/01446193.2018.1532592 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1532592 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:7:p:384-399 Template-Type: ReDIF-Article 1.0 Author-Name: Bethan Morgan Author-X-Name-First: Bethan Author-X-Name-Last: Morgan Title: Organizing for digitalization through mutual constitution: the case of a design firm Abstract: As the pace of digital change accelerates, so the ability of firms in the construction industry to organize for digitalization is becoming increasingly important. While extant research identifies the diffusion of digital innovations in firms as a non-linear process influenced by embedded contextual elements stemming from several complex social systems, it does not address the relationship between these social systems. A longitudinal embedded case of the process followed by one incumbent firm as it adopts building information modelling (BIM) is presented. Data covers a 15-year period and charts the adoption process at multiple levels: user, firm and institution. The case supports existing research by showing that BIM adoption in the firm is successful through a combination of actions involving 1) investment and leadership support, 2) standards and policies and 3) training and skills development. Drawing on Gidden’s Structuration Theory, it contributes to this research by finding that the adoption of BIM is facilitated by a mutually constitutive relationship between user, firm and institution. Firms play a central role in enabling this relationship, by both attending to and enabling endogenous user-led change while seeking to influence exogenous institutional change. Journal: Construction Management and Economics Pages: 400-417 Issue: 7 Volume: 37 Year: 2019 Month: 7 X-DOI: 10.1080/01446193.2018.1538560 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1538560 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:7:p:400-417 Template-Type: ReDIF-Article 1.0 Author-Name: Andy Dainty Author-X-Name-First: Andy Author-X-Name-Last: Dainty Author-Name: Roine Leiringer Author-X-Name-First: Roine Author-X-Name-Last: Leiringer Title: Maintaining a relevant construction management and economics research community Journal: Construction Management and Economics Pages: 693-696 Issue: 12 Volume: 37 Year: 2019 Month: 12 X-DOI: 10.1080/01446193.2019.1687992 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1687992 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:12:p:693-696 Template-Type: ReDIF-Article 1.0 Author-Name: Francisco Pinheiro Catalão Author-X-Name-First: Francisco Author-X-Name-Last: Pinheiro Catalão Author-Name: Carlos Oliveira Cruz Author-X-Name-First: Carlos Oliveira Author-X-Name-Last: Cruz Author-Name: Joaquim Miranda Sarmento Author-X-Name-First: Joaquim Author-X-Name-Last: Miranda Sarmento Title: Exogenous determinants of cost deviations and overruns in local infrastructure projects Abstract: There is a significant concern about cost deviations and overruns in public projects, particularly by the local governments. The magnitude of expenditure on these infrastructure projects justifies the search for cost deviation reasons, particularly cost overruns. The existing literature also identifies a tendency towards cost overruns in infrastructure projects. However, the analysis of cost overruns determinants has mostly focused on endogenous project characteristics.This research uses a dataset of 4,305 public infrastructure projects, of which 3,338 are local projects, carried out in Portugal between 1980 and 2012. Exogenous determinants (e.g. political, institutional and governance, and economic-related) are also considered in the analysis. An average cost overrun of 19% (9 billion Euros in volume, with a 1 billion Euros overrun) is identified. It is found that central governments incur on an average cost overrun of 23% and local governments on 6%. The analysis confirmed that projects developed by local governments tend to perform better regarding cost deviations and overruns and that exogenous determinants (particularly the political, institutional and governance environment ones) have a strong impact on cost deviations and overruns. These findings on exogenous factors can help local governments to make better management decisions, enhancing governance and institutional frameworks to improve the decision-making process when launching new infrastructure. Journal: Construction Management and Economics Pages: 697-711 Issue: 12 Volume: 37 Year: 2019 Month: 12 X-DOI: 10.1080/01446193.2019.1576915 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1576915 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:12:p:697-711 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Galvin Author-X-Name-First: Peter Author-X-Name-Last: Galvin Author-Name: Stephane Tywoniak Author-X-Name-First: Stephane Author-X-Name-Last: Tywoniak Title: How organizational boundary choices impact capability development Abstract: As construction-oriented public sector agencies have outsourced more and more of their construction-related activities, they have often suffered from an inability to provide appropriate oversight due to degraded capabilities. This had led to calls for these agencies to rebuild capabilities across different technical areas. A firm’s boundary choices—make, buy, ally and dual modes (make and buy simultaneously)—may impact the ability of a firm to maintain and even build new capabilities, and in this article, we seek to investigate the impact that boundary choices have upon rebuilding capabilities and the extent to which organizations may make sub-optimal choices economically to potentially create opportunities for learning and knowledge sharing. Using qualitative data from three project-based public sector organizations managing large construction projects, we observed that neither pure make nor buy decisions assisted significantly in capability building. Dual modes provided firms with some opportunities to build capabilities, but the most successful decisions seemed to occur in respect of using intermediate governance modes such as alliances. We also observed that the boundary choice was just one dimension of the capability building process and suggest organizations require a multi-pronged strategy to rebuild capabilities over time. Journal: Construction Management and Economics Pages: 712-726 Issue: 12 Volume: 37 Year: 2019 Month: 12 X-DOI: 10.1080/01446193.2019.1582789 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1582789 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:12:p:712-726 Template-Type: ReDIF-Article 1.0 Author-Name: Abhilasha Panwar Author-X-Name-First: Abhilasha Author-X-Name-Last: Panwar Author-Name: Kumar Neeraj Jha Author-X-Name-First: Kumar Neeraj Author-X-Name-Last: Jha Title: A many-objective optimization model for construction scheduling Abstract: In recent years, the number of stakeholders of construction projects has significantly increased; this has required the simultaneous achievement of competing objectives, such as reductions in the time, cost, resources, and environmental impact of a project, for example. In order to achieve a balance between these objectives, several multiple-objective construction scheduling models have been reported in the literature. However, several challenges have been encountered, due to the complexities of modelling and visualizing more than three objectives simultaneously. Some of these challenges are addressed in this work via the development of a many-objective scheduling model (MOSM) based on a non-dominated sorting genetic algorithm for the simultaneous optimization of four objectives: time, cost, resources and environmental impact. Coordinate plots are used to visualize the trade-offs made between all four of these objectives. A weighted sum is introduced that offers the project team the freedom to choose an optimal solution, depending on the specific priorities of the project, and the practical application of the model is demonstrated via a case study. Our MOSM allows the optimal outcome to be achieved in construction projects with multiple objectives. Journal: Construction Management and Economics Pages: 727-739 Issue: 12 Volume: 37 Year: 2019 Month: 12 X-DOI: 10.1080/01446193.2019.1590615 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1590615 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:12:p:727-739 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Author index for volume 37 (2019) Journal: Construction Management and Economics Pages: 740-740 Issue: 12 Volume: 37 Year: 2019 Month: 12 X-DOI: 10.1080/01446193.2019.1690747 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1690747 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:12:p:740-740 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Thanks to our reviewers Journal: Construction Management and Economics Pages: 741-741 Issue: 12 Volume: 37 Year: 2019 Month: 12 X-DOI: 10.1080/01446193.2019.1691287 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1691287 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:12:p:741-741 Template-Type: ReDIF-Article 1.0 Author-Name: Wendy Guthrie Author-X-Name-First: Wendy Author-X-Name-Last: Guthrie Title: Responsible Corporate Strategy in Construction and Engineering: ‘Doing the Right Thing?’ Journal: Construction Management and Economics Pages: 1073-1074 Issue: 10 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.619993 File-URL: http://hdl.handle.net/10.1080/01446193.2011.619993 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:10:p:1073-1074 Template-Type: ReDIF-Article 1.0 Author-Name: Graeme Larsen Author-X-Name-First: Graeme Author-X-Name-Last: Larsen Title: Understanding the early stages of the innovation diffusion process: awareness, influence and communication networks Abstract: The themes of awareness and influence within the innovation diffusion process are addressed. The innovation diffusion process is typically represented as stages, yet awareness and influence are somewhat under-represented in the literature. Awareness and influence are situated within the contextual setting of individual actors but also within the broader institutional forces. Understanding how actors become aware of an innovation and then how their opinion is influenced is important for creating a more innovation-active UK construction sector. Social network analysis is proposed as one technique for mapping how awareness and influence occur and what they look like as a network. Empirical data are gathered using two modes of enquiry. This is done through a pilot study consisting of chartered professionals and then through a case study organization as it attempted to diffuse an innovation. The analysis demonstrates significant variations across actors’ awareness and influence networks. It is argued that social network analysis can complement other research methods in order to present a richer picture of how actors become aware of innovations and where they draw their influences regarding adopting innovations. In summarizing the findings, a framework for understanding awareness and influence associated with innovation within the UK construction sector is presented. Finally, with the UK construction sector continually being encouraged to be innovative, understanding and managing an actor’s awareness and influence network will be beneficial. The overarching conclusion thus describes the need not only to build research capacity in this area but also to push the boundaries related to the research methods employed. Journal: Construction Management and Economics Pages: 987-1002 Issue: 10 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.619994 File-URL: http://hdl.handle.net/10.1080/01446193.2011.619994 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:10:p:987-1002 Template-Type: ReDIF-Article 1.0 Author-Name: Jasper Mbachu Author-X-Name-First: Jasper Author-X-Name-Last: Mbachu Title: Sources of contractor’s payment risks and cash flow problems in the New Zealand construction industry: project team’s perceptions of the risks and mitigation measures Abstract: Little research is focused on payment risks which constitute the biggest obstacle to adequate cash flow and the contractor’s ability to successfully complete a project and maintain a viable business. To minimize risks and improve net cash flow in a project, the various ways in which the key stakeholders could contribute to the contractor’s payment risks and cash flow problems (the ‘problems’) were investigated along with the mitigation measures. Using a two-stage descriptive survey method, pilot interviews were conducted with contractors, subcontractors, project managers, designers and quantity surveyors (the ‘group’). A questionnaire was designed based on the constructs generated during unstructured pilot interviews and used to obtain feedback from 120 members of the ‘group’ through structured interviews. The feedback was analysed for risks using the multi-factor analytical technique. Results showed that employers were the most risky sources contributing 24% of the contractor’s ‘problems’ in a project. The contractors and subcontractors were evaluated as being ‘high’ risk sources contributing 19% and 17%, respectively. The consultants and suppliers were evaluated as ‘moderate’ and ‘very low’ risk sources, respectively, with overall 37% contribution. Ensuring valid payment and variation claims that are supported with well-documented evidence was a key mitigation measure suggested for addressing the critical risk factors attributed to the ‘group’. The findings could guide the project team’s risk management efforts, especially on how to efficiently allocate the available resources to address the risk factors with a view to achieving more satisfactory outcomes and profitability in a project. Journal: Construction Management and Economics Pages: 1027-1041 Issue: 10 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.623708 File-URL: http://hdl.handle.net/10.1080/01446193.2011.623708 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:10:p:1027-1041 Template-Type: ReDIF-Article 1.0 Author-Name: Temitope Egbelakin Author-X-Name-First: Temitope Author-X-Name-Last: Egbelakin Author-Name: Suzanne Wilkinson Author-X-Name-First: Suzanne Author-X-Name-Last: Wilkinson Author-Name: Regan Potangaroa Author-X-Name-First: Regan Author-X-Name-Last: Potangaroa Author-Name: Jason Ingham Author-X-Name-First: Jason Author-X-Name-Last: Ingham Title: Enhancing seismic risk mitigation decisions: a motivational approach Abstract: Implementing seismic risk mitigation is a major challenge in many earthquake-prone regions, despite the availability of a significant number of risk reduction measures such as technical design solutions and regulatory frameworks that include building codes, policies and regulations necessary to facilitate successful risk reduction activities. However, building owners have been found unwilling to retrofit their earthquake-prone buildings. The objective of this research is to investigate how to enhance buildings owners’ earthquake hazard preparedness decisions by adopting a motivational approach in order to reduce their vulnerability to earthquake risks. A multiple case studies approach was adopted and interviews conducted with the various stakeholders involved in seismic adjustments decisions. Significant intrinsic and extrinsic interventions such as intensifying and promoting the use of critical awareness motivators, financial and property market-based incentives necessary to enhance building owners’ decisions were revealed from the analysis of the qualitative data. These revealed intrinsic and extrinsic interventions offer plausible explanations regarding how human motivational orientation can be used to influence disaster preparedness decisions by increasing the salience of seismic risk issues. Journal: Construction Management and Economics Pages: 1003-1016 Issue: 10 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.629664 File-URL: http://hdl.handle.net/10.1080/01446193.2011.629664 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:10:p:1003-1016 Template-Type: ReDIF-Article 1.0 Author-Name: Svetlana Olbina Author-X-Name-First: Svetlana Author-X-Name-Last: Olbina Author-Name: Jimmie Hinze Author-X-Name-First: Jimmie Author-X-Name-Last: Hinze Author-Name: Christopher Arduengo Author-X-Name-First: Christopher Author-X-Name-Last: Arduengo Title: Drug testing practices in the US construction industry in 2008 Abstract: Drug testing is an effective way to improve jobsite safety, productivity and profits. Since drug use impairs the abilities of construction workers, many construction companies have implemented drug testing policies. The research aim was to identify the current drug testing practices of construction contractors. The research objectives were to determine: (1) the extent of the implementation of drug testing; (2) testing practices being used; (3) testing methods being used; (4) the most frequently drugs used; and (5) the use and prevalence of adulterants to cheat on drug tests. In 2008 the data were collected through surveys sent to US construction firms that were randomly selected from the Blue Book of Building and Construction. The results show that drug use continues to be a concern although the extent of drug use has declined in recent years. Most of the firms conduct both pre-employment drug screening and random drug testing. Marijuana and cocaine are the primary drugs used. Urine analysis continues to be the most common drug test used, while other testing methods are being explored with some hesitance. Cheating on drug tests appears to be a major concern. The results show that there is a statistically significant relationship between drug usage and safety performance. Journal: Construction Management and Economics Pages: 1043-1057 Issue: 10 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.631553 File-URL: http://hdl.handle.net/10.1080/01446193.2011.631553 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:10:p:1043-1057 Template-Type: ReDIF-Article 1.0 Author-Name: James Wilkins Author-X-Name-First: James Author-X-Name-Last: Wilkins Title: Construction workers’ perceptions of health and safety training programmes Abstract: As zero-accidents cultures expand in popularity, knowledge and implementation of safety regulations have become priorities for construction organizations. An expanded literature review revealed that many industry leaders have responded by increasing the frequency and content of health and safety training programmes; however the provision of training largely has remained consistent. Identifying workers’ conceptions of the training they receive is critical to the design and deployment of effective workplace education programmes. Utilizing a hybrid questionnaire of qualitative and quantitative components to assess perceptions and knowledge, data were collected from a sample (n = 121) representing construction professionals across the United States who had completed an OSHA 10-Hour Construction Safety Training Course. The data described a workforce dissatisfied with training effectiveness and characterized a widespread situation in which the distinguishing characteristics of adult learning had not been addressed by qualified trainers. Strong health and safety training programmes improve employee retention as well as compliance with health and safety requirements. Trainees are more likely to respond positively to training programmes when adult learning theories are integrated into safety trainer readiness programmes. Journal: Construction Management and Economics Pages: 1017-1026 Issue: 10 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.633538 File-URL: http://hdl.handle.net/10.1080/01446193.2011.633538 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:10:p:1017-1026 Template-Type: ReDIF-Article 1.0 Author-Name: Willie Tan Author-X-Name-First: Willie Author-X-Name-Last: Tan Title: Project Finance in Construction: A Structured Guide to Assessment Journal: Construction Management and Economics Pages: 1074-1075 Issue: 10 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.636369 File-URL: http://hdl.handle.net/10.1080/01446193.2011.636369 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:10:p:1074-1075 Template-Type: ReDIF-Article 1.0 Author-Name: Cordelia Hee Author-X-Name-First: Cordelia Author-X-Name-Last: Hee Author-Name: Florence Ling Author-X-Name-First: Florence Author-X-Name-Last: Ling Title: Strategies for reducing employee turnover and increasing retention rates of quantity surveyors Abstract: Quantity surveyors (QS) play an important role in the construction industry. There is therefore a need to reduce their job turnover, by minimizing their intention to quit the job (turnover intention) and improving their job satisfaction. Turnover intention was operationalized as the number of years QS are likely to remain in the profession (Y1) and in their present firms (Y2). The aims are to investigate job and jobholder characteristics that significantly affect Y1 and Y2; and provide recommendations to reduce QS’ turnover intentions. Using questionnaire survey, data were collected via e-mail from randomly selected QS in Singapore. Correlation analysis revealed that to reduce turnover, QS should be given competitive monetary and non-monetary benefits, and autonomy in decision making. To reverse turnover intention of well-performing QS who are ensconced in their firms, firms could enrich QS’ jobs so that their growth needs are met and they feel a sense of accomplishment. Certain characteristics of QS and their jobs give rise to job satisfaction, and therefore designing quantity surveying jobs that take in these characteristics may decrease turnover intention. The relevant characteristics that should be included in the design of QS’ jobs to increase retention rates are task significance, autonomy and feedback. Journal: Construction Management and Economics Pages: 1059-1072 Issue: 10 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.637569 File-URL: http://hdl.handle.net/10.1080/01446193.2011.637569 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:10:p:1059-1072 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Editorial Journal: Construction Management and Economics Pages: 985-986 Issue: 10 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.640177 File-URL: http://hdl.handle.net/10.1080/01446193.2011.640177 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:10:p:985-986 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Forthcoming events Journal: Construction Management and Economics Pages: 1077-1078 Issue: 10 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.640178 File-URL: http://hdl.handle.net/10.1080/01446193.2011.640178 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:10:p:1077-1078 Template-Type: ReDIF-Article 1.0 Author-Name: Meng Ye Author-X-Name-First: Meng Author-X-Name-Last: Ye Author-Name: Weisheng Lu Author-X-Name-First: Weisheng Author-X-Name-Last: Lu Author-Name: Roger Flanagan Author-X-Name-First: Roger Author-X-Name-Last: Flanagan Author-Name: Kunhui Ye Author-X-Name-First: Kunhui Author-X-Name-Last: Ye Title: Diversification in the international construction business Abstract: Economic globalization has created an interdependent market that allows companies to transcend traditional national boundaries to conduct business overseas. In the international construction market, companies often adopt diversification as a strategy for growth, for risk management or for both. However, the diversification patterns of international construction companies (ICCs) as a group are barely clear. The primary aim of this research is to cover this knowledge void by mapping ICCs’ diversification patterns in both business sectors and geographical dispersal. It starts from a literature review of diversification theories. Based on the review, a series of hypotheses relating to ICCs’ diversification are proposed. Data are gleaned from Engineering News-Record, i.e. Bloomberg and Capital IQ, ranging from 2001 to 2015. By testing the hypotheses, it is found that larger ICCs prefer to diversify than their smaller counterparts. Most of the ICCs tend to diversify to geographical markets with similar cultural or institutional environment. Market demands drive ICCs to diversify to different geographical markets while they are more prudential in venturing into new business sectors. The research provides not only valuable insights into diversification patterns of ICCs, but also a solid point of departure for future theoretical and empirical studies. Journal: Construction Management and Economics Pages: 348-361 Issue: 6 Volume: 36 Year: 2018 Month: 6 X-DOI: 10.1080/01446193.2017.1388530 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1388530 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:6:p:348-361 Template-Type: ReDIF-Article 1.0 Author-Name: Di Hu Author-X-Name-First: Di Author-X-Name-Last: Hu Author-Name: Yasser Mohamed Author-X-Name-First: Yasser Author-X-Name-Last: Mohamed Author-Name: Hosein Taghaddos Author-X-Name-First: Hosein Author-X-Name-Last: Taghaddos Author-Name: Ulrich (Rick) Hermann Author-X-Name-First: Ulrich (Rick) Author-X-Name-Last: Hermann Title: A simulation-based method for effective workface planning of industrial construction projects Abstract: The generation of well-defined and moderately sized field installation work packages for the construction workforce, referred to as workface planning, has been recently employed to plan large-scale industrial construction projects under tight schedules. However, traditional CPM-based scheduling of several thousand work packages (e.g. 5000 activities multiply by 10 work packages per activity on average) is a tedious, error prone process. Defining proper logics and controlling congestion among work packages crossing several work areas, and also effective resource allocation over time are other major challenges in workface planning. This paper presents a novel simulation-based framework to implement workface planning for large-scale industrial construction projects. This framework proposes a time-stepped discrete event simulation-based modelling for dynamic resource allocation based on congestion and other constraints on the job site. The proposed method is demonstrated and tested against traditional CPM-based solutions based on an actual case study. Journal: Construction Management and Economics Pages: 328-347 Issue: 6 Volume: 36 Year: 2018 Month: 6 X-DOI: 10.1080/01446193.2017.1390241 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1390241 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:6:p:328-347 Template-Type: ReDIF-Article 1.0 Author-Name: J. Riley Snyder Author-X-Name-First: J. Riley Author-X-Name-Last: Snyder Author-Name: Ozge Dilaver Author-X-Name-First: Ozge Author-X-Name-Last: Dilaver Author-Name: Lucy C. Stephenson Author-X-Name-First: Lucy C. Author-X-Name-Last: Stephenson Author-Name: Jan E. Mackie Author-X-Name-First: Jan E. Author-X-Name-Last: Mackie Author-Name: Simon D. Smith Author-X-Name-First: Simon D. Author-X-Name-Last: Smith Title: Agent-based modelling and construction – reconstructing antiquity’s largest infrastructure project Abstract: Archaeological remains around the world are testament that large-scale construction projects have been successfully carried out for millennia. This success is particularly evident through the great infrastructural works of the Roman Empire. Yet, it was when the capital was moved from Rome to Constantinople that the largest of these projects was undertaken. This megaproject of the fourth- and fifth-century water supply was made of hundreds of kilometres aqueduct channels and bridges that brought fresh water to the city’s complex system of reservoirs and cisterns. Unlike projects of the previous centuries, we are left with no written record of how this titanic project was undertaken and existing archaeological and historical commentaries on structures of this period do not provide details of organization of construction. We explore the nature of building Constantinople’s water supply through diverse sources of knowledge and the application of agent-based modelling – a method for simulating the actions, interactions and behaviours of autonomous agents and the resulting emergent properties of the system in which they are a part. This paper demonstrates the ability of ABM to develop and test richer hypotheses about historical construction organization and management than physical and historical evidence on their own. Journal: Construction Management and Economics Pages: 313-327 Issue: 6 Volume: 36 Year: 2018 Month: 6 X-DOI: 10.1080/01446193.2017.1403639 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1403639 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:6:p:313-327 Template-Type: ReDIF-Article 1.0 Author-Name: Benjamin Sanchez Author-X-Name-First: Benjamin Author-X-Name-Last: Sanchez Author-Name: Carl Haas Author-X-Name-First: Carl Author-X-Name-Last: Haas Title: Capital project planning for a circular economy Abstract: Achieving true sustainability in the conceptualization of new building projects requires radical change compared to traditional green-field projects; circular building principles in a circular economy must become a fundamental part of the process. These principles include product recovery management, life cycle assessment (LCA), design for disassembly sequence planning, adaptability, deconstruction, closed materials loops and dematerialization. These principles recognize the importance of the End-of-Life stage in existing buildings, including adaptive reuse as an attractive alternative in a circular economy. However, the early phases of capital project delivery lack well-developed methods to: (1) decide amongst green-field construction versus adaptive reuse, (2) pre-project planning for closed-loop cycle construction and (3) plan for the optimization of the benefits of adaptive reuse. In this article, we argue that the early capital projects delivery phases for a circular economy should have distinct stages, decision gates and more appropriate planning methods, such as selective disassembly, LCA monetization protocols and optimization methods. An investigation of related studies underpins the capital project planning framework proposed and the research that must still be accomplished to enable a more circular economy in the capital projects sector. Journal: Construction Management and Economics Pages: 303-312 Issue: 6 Volume: 36 Year: 2018 Month: 6 X-DOI: 10.1080/01446193.2018.1435895 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1435895 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:6:p:303-312 Template-Type: ReDIF-Article 1.0 Author-Name: Kent Jacob Nielsen Author-X-Name-First: Kent Jacob Author-X-Name-Last: Nielsen Title: A comparison of inspection practices within the construction industry between the Danish and Swedish Work Environment Authorities Abstract: Denmark has a 39% higher rate of fatal occupational injuries within construction than Sweden. Although there are only minor differences in the work environment legislation between the countries, there may be differences in how the legislation is enforced. The aim of the study was to describe and compare the inspection practices, within the construction industry, between the Danish and Swedish Work Environment Authorities. A mixed-method approach was employed combining observations of inspections, interviews with inspectors and questionnaire responses from inspected workplaces. The primary role of both Danish and Swedish inspectors was as controllers. A minor role was as experts. A third role of being a sounding board was only identified in a few instances in Sweden. Autonomy-supportive tactics were employed more regularly in Sweden while coercive tactics were more widespread in Denmark. Negative behaviour on behalf of the inspected party was also more widespread in Denmark while positive behaviour was more widespread in Sweden. Questionnaire data revealed that the inspected Swedish companies had a significantly more positive perception of the inspectors and the benefits of the inspections. There were differences in the enforcement practices of the Danish and Swedish inspectors, which may lead to greater adherence to health and safety regulations in Sweden. Journal: Construction Management and Economics Pages: 154-169 Issue: 3 Volume: 35 Year: 2017 Month: 3 X-DOI: 10.1080/01446193.2016.1231407 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1231407 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:3:p:154-169 Template-Type: ReDIF-Article 1.0 Author-Name: Jicai Liu Author-X-Name-First: Jicai Author-X-Name-Last: Liu Author-Name: Ruolan Gao Author-X-Name-First: Ruolan Author-X-Name-Last: Gao Author-Name: Charles Yuen Jen Cheah Author-X-Name-First: Charles Yuen Jen Author-X-Name-Last: Cheah Author-Name: Jian Luo Author-X-Name-First: Jian Author-X-Name-Last: Luo Title: Evolutionary game of investors’ opportunistic behaviour during the operational period in PPP projects Abstract: In public–private partnership (PPP) projects, during the operational period, private investors are prone to act opportunistically in pursuit of their own gain. Based on the perspectives of government’s administrative supervisory functions, this paper analyses the issue of strategic choice for opportunistic behaviour by the government and private investors during the operational period of projects using evolutionary game theory. The results show that there is not a single set of evolutionarily stable strategies (ESS) between the government and the investors. The end results of the evolutionary game are related to the initial states of the system. Conditions that would dissuade investors from adopting an opportunistic behaviour, and settings that would encourage government to supervise closely, are explored. Punishments set by the government, which would then lead to different ultimate choices made by these two parties, are also discussed. Finally, the paper proposes a few policy recommendations for government supervision on the basis of parametric analysis. The findings also serve as a reference for the decision-making process of the government and the investors. Journal: Construction Management and Economics Pages: 137-153 Issue: 3 Volume: 35 Year: 2017 Month: 3 X-DOI: 10.1080/01446193.2016.1237033 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1237033 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:3:p:137-153 Template-Type: ReDIF-Article 1.0 Author-Name: Wendy Jones Author-X-Name-First: Wendy Author-X-Name-Last: Jones Author-Name: Alistair Gibb Author-X-Name-First: Alistair Author-X-Name-Last: Gibb Author-Name: Chris Goodier Author-X-Name-First: Chris Author-X-Name-Last: Goodier Author-Name: Phil Bust Author-X-Name-First: Phil Author-X-Name-Last: Bust Title: Managing the unknown – Addressing the potential health risks of nanomaterials in the built environment Abstract: Nanomaterials offer significant potential for high performing new products in the built environment and elsewhere. However, there are uncertainties regarding their potential adverse health effects and the extent to which they are currently used. A desk study and interviews with those working across the construction, demolition and product manufacture sectors (n = 59) identified the current state of knowledge regarding nanomaterial use within the built environment. Some nanomaterials are potentially toxic, particularly those based on fibres; others are much less problematic but the evidence base is incomplete. Very little is known regarding the potential for exposure for those working with nano-enabled construction materials. Identifying which construction products contain nanomaterials, and which nanomaterials these might be, is very difficult due to inadequate labelling by product manufacturers. Consequently, those working with nano-enabled products typically have very limited knowledge or awareness of this. Further research is required regarding the toxicology of nanomaterials and the potential for exposure during construction and demolition. Better sharing of the information which is already available is also required through the construction, demolition and manufacture/supply chains. This is likely to be important for other innovative products and processes in construction, not just those which use nanomaterials. Journal: Construction Management and Economics Pages: 122-136 Issue: 3 Volume: 35 Year: 2017 Month: 3 X-DOI: 10.1080/01446193.2016.1241413 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1241413 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:3:p:122-136 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Benson Teck Heng Lim Author-X-Name-First: Benson Teck Heng Author-X-Name-Last: Lim Title: Linking corporate social responsibility and organizational performance in the construction industry Abstract: In the construction industry, the subject of corporate social responsibility (CSR) is becoming increasingly important as communities, employees and socially conscious clients expect firms to demonstrate they are good corporate citizens. However, while CSR research in construction has accelerated in recent years, it remains fragmented and unconceptualized and there is little understanding of the relationship between CSR and organizational performance, the types of CSR strategies employed and the strategic motivations behind them. To address this deficiency in current CSR knowledge and drawing upon contemporary CSR theory, a survey of 104 professionals from across the construction supply chain in Australia and New Zealand was undertaken. The results show that CSR initiatives in the construction sector are integrative, isolated, narrowly focussed (mainly on environmental activities), immature, compliance-based and operational rather than strategic. The link between CSR and economic performance increasingly espoused (and assumed) in much of the CSR literature does not appear to be accepted in practice with the main benefits being seen as relational in building corporate loyalty, brand and engagement with both internal and external stakeholders. By empirically showing that CSR in construction takes place within an integrative conceptual framework, our findings highlight the potential value of theoretical concepts such as stakeholder salience in moving this field of research forward. These approaches recognize the power that stakeholders (both internal and external) have over a business and the need to manage those relationships carefully in order to secure a licence to operate. Journal: Construction Management and Economics Pages: 90-105 Issue: 3 Volume: 35 Year: 2017 Month: 3 X-DOI: 10.1080/01446193.2016.1242762 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1242762 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:3:p:90-105 Template-Type: ReDIF-Article 1.0 Author-Name: Pablo Ballesteros-Pérez Author-X-Name-First: Pablo Author-X-Name-Last: Ballesteros-Pérez Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: On the distribution of bids for construction contract auctions Abstract: The statistical distribution representing bid values constitutes an essential part of many auction models and has involved a wide range of assumptions, including the Uniform, Normal, Lognormal and Weibull densities. From a modelling point of view, its goodness is defined by how well it enables the probability of a particular bid value to be estimated – a past bid for ex-post analysis and a future bid for ex-ante (forecasting) analysis. However, there is no agreement to date of what is the most appropriate form and empirical work is sparse. Twelve extant construction data-sets from four continents over different time periods are analysed in this paper for their fit to a variety of candidate statistical distributions assuming homogeneity of bidders (ID not known). The results show there is no one single fit-all distribution, but that the 3p Log-Normal, Fréchet/2p Log-Normal, Normal, Gamma and Gumbel generally rank the best ex-post and the 2p Log-Normal, Normal, Gamma and Gumbel the best ex-ante – with ex-ante having around three to four times worse fit than ex-post. Final comments focus on the results relating to the third and fourth standardized moments of the bids and a post hoc rationalization of the empirical outcome of the analysis. Journal: Construction Management and Economics Pages: 106-121 Issue: 3 Volume: 35 Year: 2017 Month: 3 X-DOI: 10.1080/01446193.2016.1247972 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1247972 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:3:p:106-121 Template-Type: ReDIF-Article 1.0 Author-Name: Linda Clarke Author-X-Name-First: Linda Author-X-Name-Last: Clarke Author-Name: Colin Gleeson Author-X-Name-First: Colin Author-X-Name-Last: Gleeson Author-Name: Christopher Winch Author-X-Name-First: Christopher Author-X-Name-Last: Winch Title: What kind of expertise is needed for low energy construction? Abstract: The construction industry is responsible for 40% of European Union (EU) end-use emissions but addressing this is problematic, as evident from the performance gap between design intention and on-site energy performance. There is a lack of the expertise needed for low energy construction (LEC) in the UK as the complex work processes involved require ‘energy literacy’ of all construction occupations, high qualification levels, broad occupational profiles, integrated teamworking, and good communication. This research identifies the obstacles to meeting these requirements, the nature of the expertise needed to break down occupational divisions and bridge those interfaces where the main heat losses occur, and the transition pathway implied. Obstacles include a decline in the level, breadth and quality of construction vocational education and training (VET), the lack of a learning infrastructure on sites, and a fragmented employment structure. To overcome these and develop enhanced understanding of LEC requires a transformation of the existing structure of VET provision and construction employment and a new curriculum based on a broader concept of agency and backed by rigorous enforcement of standards. This can be achieved through a radical transition pathway rather than market-based solutions to a low carbon future for the construction sector. Journal: Construction Management and Economics Pages: 78-89 Issue: 3 Volume: 35 Year: 2017 Month: 3 X-DOI: 10.1080/01446193.2016.1248988 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1248988 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:3:p:78-89 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Referees for Volume 34 (2016) Journal: Construction Management and Economics Pages: 170-179 Issue: 3 Volume: 35 Year: 2017 Month: 3 X-DOI: 10.1080/01446193.2017.1251175 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1251175 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:3:p:170-179 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Indexes for Volume 34 (2016) Journal: Construction Management and Economics Pages: 180-181 Issue: 3 Volume: 35 Year: 2017 Month: 3 X-DOI: 10.1080/01446193.2017.1251180 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1251180 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:3:p:180-181 Template-Type: ReDIF-Article 1.0 Author-Name: Gulnaz Aksenova Author-X-Name-First: Gulnaz Author-X-Name-Last: Aksenova Author-Name: Arto Kiviniemi Author-X-Name-First: Arto Author-X-Name-Last: Kiviniemi Author-Name: Tuba Kocaturk Author-X-Name-First: Tuba Author-X-Name-Last: Kocaturk Author-Name: Albert Lejeune Author-X-Name-First: Albert Author-X-Name-Last: Lejeune Title: From Finnish AEC knowledge ecosystem to business ecosystem: lessons learned from the national deployment of BIM Abstract: Government actors, public agencies, industry and academics have struggled to change the rules of the existing business ecosystem to support the networked practices that were envisioned back in the 1980s with the introduction of building information modelling (BIM). Despite the industry’s far-reaching technological capabilities, BIM has primarily assumed productivity improvement by individual firms, which has not lead to a systemic change in the Finnish architecture, engineering and construction (AEC) business ecosystem. A field study of the Finnish AEC industry has resulted in a critical understanding of why successful and intensive R&D at a national level and wide adoption of BIM technology in Finland has not led to the expected systemic evolution of its AEC business ecosystem. Additionally, a methodology based on inductive grounded theory and historical analysis has been used to capture and identify the evolving and dynamic relationships between various events and actors between 1965 and 2015, which, in turn, has aided in the identification and characterisation of the knowledge and innovation ecosystems. The research findings provide insights for BIM researchers and governments in terms of establishing new policies that will better align BIM adoption with the systemic evolution of business practices in the AEC business ecosystem. Journal: Construction Management and Economics Pages: 317-335 Issue: 6 Volume: 37 Year: 2019 Month: 6 X-DOI: 10.1080/01446193.2018.1481985 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1481985 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:6:p:317-335 Template-Type: ReDIF-Article 1.0 Author-Name: Peter Nørkjaer Gade Author-X-Name-First: Peter Author-X-Name-Last: Nørkjaer Gade Author-Name: Anne Nørkjaer Gade Author-X-Name-First: Anne Author-X-Name-Last: Nørkjaer Gade Author-Name: Kathrin Otrel-Cass Author-X-Name-First: Kathrin Author-X-Name-Last: Otrel-Cass Author-Name: Kjeld Svidt Author-X-Name-First: Kjeld Author-X-Name-Last: Svidt Title: A holistic analysis of a BIM-mediated building design process using activity theory Abstract: Building Information Modelling (BIM) is said to hold potential for increasing efficiency of the design processes in the building industry. However, designers struggle at times to apply the different BIM-tools. In order to understand this disjoint, it is necessary to understand first the existing practices of different specialists in the building design process in order to improve future development and implementation of BIM. The aim of this article is to investigate the consequences of using BIM-tools in a collaborative building design setting consisting of different specialists. A case study was carried out to trace when BIM-tools were used (or not) in an inter-organizational design process of a naval rescue station in Denmark. The design process was holistically examined through the lens of Activity Theory which is an analytical framework. Five key findings were identified: the mediating role of 3D visuals, real-world coupling with point cloud, rule-breaking to ensure design completion, inability to integrate BIM-analysis into the design and the use of heuristics to form and choose among design solutions. Journal: Construction Management and Economics Pages: 336-350 Issue: 6 Volume: 37 Year: 2019 Month: 6 X-DOI: 10.1080/01446193.2018.1533644 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1533644 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:6:p:336-350 Template-Type: ReDIF-Article 1.0 Author-Name: Kajsa Simu Author-X-Name-First: Kajsa Author-X-Name-Last: Simu Author-Name: Helena Lidelöw Author-X-Name-First: Helena Author-X-Name-Last: Lidelöw Title: Middle managers’ perceptions of operations strategies at construction contractors Abstract: Operations strategies focus on how a firm delivers value, while business strategies focus on what to deliver and where. Lean is an operations strategy prioritizing flow efficiency. In construction, empirical underpinning of operations strategies has been limited. The aim is to capture how perceptions of operations strategy in construction practice aligns with existing theories of operations strategy organized in decision categories. Nine in-depth interviews with contractor middle managers were transcribed and analyzed to capture their perceptions of operations strategies. Results show: (1) decision categories in construction differ from manufacturing, and (2) differences between resource and flow efficient operations strategies exist. A resource efficient strategy focuses cost and delivery as competitive criteria, while customer value is targeted in a flow efficient strategy. Proposed structural decision categories are standardization, organization and production planning, supply chain, and infrastructural decision categories are human resources, continuous improvement, long-term perspective, process vs. project, and performance measurements. Infrastructural categories are more difficult to replicate and render competitive advantage if successfully aligned with business strategy. An operations strategy strictly focused on project delivery, such as lean construction, is not automatically aligned with the business strategy, but can achieve satisfactory project performance. Journal: Construction Management and Economics Pages: 351-366 Issue: 6 Volume: 37 Year: 2019 Month: 6 X-DOI: 10.1080/01446193.2018.1542739 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1542739 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:6:p:351-366 Template-Type: ReDIF-Article 1.0 Author-Name: Christian Koch Author-X-Name-First: Christian Author-X-Name-Last: Koch Author-Name: Sami Paavola Author-X-Name-First: Sami Author-X-Name-Last: Paavola Author-Name: Henrik Buhl Author-X-Name-First: Henrik Author-X-Name-Last: Buhl Title: Social science and construction – an uneasy and underused relation Journal: Construction Management and Economics Pages: 309-316 Issue: 6 Volume: 37 Year: 2019 Month: 6 X-DOI: 10.1080/01446193.2019.1599160 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1599160 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:6:p:309-316 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Jemma Bridgeman Author-X-Name-First: Jemma Author-X-Name-Last: Bridgeman Title: The social impact of construction industry schools-based corporate volunteering Abstract: Despite the rapid growth of corporate volunteering in construction, there has been very little research in this area, particularly from a recipient’s perspective. To address this gap in knowledge, data were collected using surveys, reflective diaries, workbooks and a progress web, from 103 school pupils participating in one of the UK’s largest schools-based construction industry corporate volunteering programmes. The results show that corporate volunteering programmes which partner construction industry professionals with school students in a work-related activity-based learning environment can have a significant impact on student construction industry knowledge, perceptions, career choices, aspirations and employability skills. This is particularly the case for female students and for students whose learning styles do not align with traditional classroom-based pedagogies. It is recommended that more research is needed to classify and understand the different types of volunteering programmes that operate in the construction sector across multiple cohort groups, the factors that determine success and failure and the overall impact on the students and the wider community in the long term as well as the short term. There is also a need for more research into what it means for the companies involved and for the staff who volunteer. Journal: Construction Management and Economics Pages: 243-258 Issue: 5 Volume: 36 Year: 2018 Month: 5 X-DOI: 10.1080/01446193.2017.1355061 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1355061 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:5:p:243-258 Template-Type: ReDIF-Article 1.0 Author-Name: Pernilla Gluch Author-X-Name-First: Pernilla Author-X-Name-Last: Gluch Author-Name: Ingrid Svensson Author-X-Name-First: Ingrid Author-X-Name-Last: Svensson Title: On the nexus of changing public facilities management practices: purposive and co-creative actions across multiple levels Abstract: Building on a practice-oriented approach and the theoretical construct of institutional work, the organizational nexus of changing practices for public facilities management is conceptualized in a multi-level framework. To support the conceptual framework, changing management practices are illustrated with the help of real-life experiences gained in a case study of a strategy project in a Swedish public construction client organization with the goal of developing a strategic facilities plan. These real-life examples, captured through interviews and field observations, cohere with the research method of narrative inquiry. The framework envisions projective agencies of various actors, both human and non-human (objects), in change processes. Findings show how key actors, through collaborative co-creation processes, take different complementary roles when promoting new practices into a specific organizational setting. By jointly promoting a set of preferred arrangements they establish proto-institutions. In addition, various objects were attributed rhetorical agency to support new public FM practices in that these served as purposeful non-human actors, triggering and legitimizing actions taken. With focus on emerging institutions in the making and especially projective agencies for institutional change, this research contributes to furthered layered understandings on institutional work related to change in construction in general and specifically in public sustainable facilities management. Journal: Construction Management and Economics Pages: 259-275 Issue: 5 Volume: 36 Year: 2018 Month: 5 X-DOI: 10.1080/01446193.2017.1381751 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1381751 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:5:p:259-275 Template-Type: ReDIF-Article 1.0 Author-Name: Vanessa McDermott Author-X-Name-First: Vanessa Author-X-Name-Last: McDermott Author-Name: Rita Peihua Zhang Author-X-Name-First: Rita Peihua Author-X-Name-Last: Zhang Author-Name: Andrew Hopkins Author-X-Name-First: Andrew Author-X-Name-Last: Hopkins Author-Name: Jan Hayes Author-X-Name-First: Jan Author-X-Name-Last: Hayes Title: Constructing safety: investigating senior executive long-term incentive plans and safety objectives in the construction sector Abstract: In the private sector, incentive plans are one of the major means used by Boards of Directors to align the interests of senior management with organizational interests. However, research conducted in the energy and resources sector revealed a poor alignment between incentive plans and the need to have senior management focus on safety. The research discussed here examined long-term incentive plans (LTIPs) for senior executives in the construction sector to investigate whether these direct senior managers attention to long-term safety objectives and if they include any long-term safety indicators. Annual Reports of publicly listed companies in the Australian non-domestic construction sector were used as the major information source and subjected to content analysis. Despite a strong safety commitment expressed by all the companies, LTIPs were exclusively associated with financial indicators. Although safety indicators are included in Annual Reports, these only appear in short-term incentive plans, indicating that senior executives are not incentivized to align their long-term decision-making with long-term safety objectives. Findings from the research demonstrate that valid and meaningful safety indicators should be developed and included in LTIPs in order to better align the focus of senior management to include safety performance in the construction industry. Journal: Construction Management and Economics Pages: 276-290 Issue: 5 Volume: 36 Year: 2018 Month: 5 X-DOI: 10.1080/01446193.2017.1381752 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1381752 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:5:p:276-290 Template-Type: ReDIF-Article 1.0 Author-Name: David Oswald Author-X-Name-First: David Author-X-Name-Last: Oswald Author-Name: Fred Sherratt Author-X-Name-First: Fred Author-X-Name-Last: Sherratt Author-Name: Simon D. Smith Author-X-Name-First: Simon D. Author-X-Name-Last: Smith Author-Name: Matthew R. Hallowell Author-X-Name-First: Matthew R. Author-X-Name-Last: Hallowell Title: Exploring safety management challenges for multi-national construction workforces: a UK case study Abstract: Large construction projects frequently operate with multi-national workforces, utilizing migrant workers to provide both skilled and unskilled labour. Multi-national workforces are also brought together through joint ventures, as companies from different countries collaborate and share their expertise to construct large and complex construction projects. A multi-national joint venture in the UK provides the case study for an examination of the safety management challenges found on such projects. Whilst language and communication issues amongst workers are typically primary concerns, here they have not been prioritized. Instead, findings are presented that illuminate more nuanced and unquantifiable problems that faced the safety management team. An ethnographically informed approach was mobilized, with the lead researcher spending three years on the site with the safety team gathering data. Analysis revealed several challenges: problems with non-UK company compliance with UK legislation and standards; differences in working practices amongst both non-UK workers and their managers; differences associated with national cultures; and problems of poor worker welfare. It is suggested that awareness of these challenges should inform both the way in which such projects are initially contracted, as well as the development of more sophisticated safety management systems that better support multi-national construction projects in practice. Journal: Construction Management and Economics Pages: 291-301 Issue: 5 Volume: 36 Year: 2018 Month: 5 X-DOI: 10.1080/01446193.2017.1390242 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1390242 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:5:p:291-301 Template-Type: ReDIF-Article 1.0 Author-Name: Dylan Tutt Author-X-Name-First: Dylan Author-X-Name-Last: Tutt Author-Name: Sarah Pink Author-X-Name-First: Sarah Author-X-Name-Last: Pink Title: Refiguring global construction challenges through ethnography Journal: Construction Management and Economics Pages: 475-480 Issue: 9 Volume: 37 Year: 2019 Month: 9 X-DOI: 10.1080/01446193.2019.1643570 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1643570 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:9:p:475-480 Template-Type: ReDIF-Article 1.0 Author-Name: Henning Grosse Author-X-Name-First: Henning Author-X-Name-Last: Grosse Title: An insider’s point of view: autoethnography in the construction industry Abstract: This practitioner-researcher’s work addresses the lack of autoethnographies in construction management and highlights what they might contribute. I explore my experiences running a construction company in Germany and pursuing practitioner-research as a part-time researcher. I use reflexive autoethnography to explore my emotions and thoughts drawn from a conflict with an architect using background knowledge, perspective taking and self-questioning. Reflexivity is a recurring critique and questioning of my actions and understandings, which helped me to explore underlying assumptions and reasons for my thoughts and feelings. I identify three forms of reflexivity, which interacts in an ongoing hermeneutic process. These are “reflexivity on practice”, which refers to the retrospective reflexivity, “reflexivity in practice”. which signals how I reflexively act in practice, and “reflexivity of practice”, which is inherent reflexivity in practice. My research can be seen as a transformative process as I progress from management thinking to researcher thinking. As I reflexively deconstruct my own understanding, I also advance the understanding of the processes I explore. Subsequently, I am better equipped to navigate my business environment. Sharing these experiences might help others to advance their reflexive skills and my unique insider perspective might provide deeper insights into the construction industry. Thus, autoethnographies will contrast outsider’s perspectives and offer material for further reflection. Journal: Construction Management and Economics Pages: 481-498 Issue: 9 Volume: 37 Year: 2019 Month: 9 X-DOI: 10.1080/01446193.2018.1501156 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1501156 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:9:p:481-498 Template-Type: ReDIF-Article 1.0 Author-Name: Christian Koch Author-X-Name-First: Christian Author-X-Name-Last: Koch Author-Name: Casper Siebken Schultz Author-X-Name-First: Casper Siebken Author-X-Name-Last: Schultz Title: The production of defects in construction – an agency dissonance Abstract: The costs of defects and quality issues in construction can be significant for stakeholders and can include societal consequences. The aim is to address how failures and defects are produced and handled in the social practices of construction projects and specially to scrutinize the unintended consequences of both structured and chaotic problem solving. The argument is based on a longitudinal ethnographic study of a dwelling project, encompassing just over 100 days of fieldwork. Structuration theory was applied to understand the interrelations between project actors and structures in the handling and redressing of quality issues and to elucidate unintended consequences of the practices. The analytical strategy was abductive, allowing theory and empirical material to inform each other. Two cases were selected; the well-structured process of erecting concrete panels and the chaotic processes of building a penthouse. The results show how routine and experience are helpful, but also how they maintain an “acceptable” level of defects, which should change the widespread appreciation of experience as being positive for building quality. The unintended consequences of routinized practices are corroborated by the lack of knowledge sharing beyond the project. Both reactive and proactive problem-solving practices are important, but the reactive tend to dominate. Journal: Construction Management and Economics Pages: 499-512 Issue: 9 Volume: 37 Year: 2019 Month: 9 X-DOI: 10.1080/01446193.2018.1519253 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1519253 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:9:p:499-512 Template-Type: ReDIF-Article 1.0 Author-Name: Wajihah Hamid Author-X-Name-First: Wajihah Author-X-Name-Last: Hamid Author-Name: Dylan Tutt Author-X-Name-First: Dylan Author-X-Name-Last: Tutt Title: “Thrown away like a banana leaf”: precarity of labour and precarity of place for Tamil migrant construction workers in Singapore Abstract: Despite labouring for three decades in Singapore, and being connected to the existing Tamil diasporic community there, Tamil migrant construction workers have been left out of state rhetoric and face economic marginalization and social exclusion. In this article, we draw on rich ethnographic data on their everyday experiences of working construction and living in Singapore, and we espouse the distinctive qualities and mission of ethnographically-informed methodologies to enact change in this space. The methods include in-depth interviews with 11 Tamil labourers, and the subsequent use of worker photo diaries, known as auto-photography, with a total of 108 photographs taken. All the participants either worked construction, were on medical leave, or were seeking compensation after workplace injury. The analysis of the interview data develops themes around precarity and discrimination on construction sites (precarity of work), and the exclusory social practices experienced by workers in their offsite world (precarity of place). Following the goals of decolonized research, our innovative methods have enabled Tamil construction workers to present their lives through their own lens. By involving migrant construction workers, we identify new sites of inquiry and knowledge in examining the inequalities and injustices they face. Journal: Construction Management and Economics Pages: 513-536 Issue: 9 Volume: 37 Year: 2019 Month: 9 X-DOI: 10.1080/01446193.2019.1595075 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1595075 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:9:p:513-536 Template-Type: ReDIF-Article 1.0 Author-Name: Ian J. Ewart Author-X-Name-First: Ian J. Author-X-Name-Last: Ewart Title: The social consequences of minor innovations in construction Abstract: Innovation studies in construction focus on a desire to increase economics and efficiency at a large scale. This has resulted in a skewed perspective that sees only major corporations with substantial R&D resources, complex projects, or national interests at the heart of innovation. By adopting anthropological methods, it becomes possible to examine the two aims of this paper: to demonstrate that an accumulation of minor innovations can have significant consequences; and to show that these are inherently social rather than purely economic. Results come from fieldwork studying the improvisatory house-building practices of the Kelabit people of rural Borneo, tracing changes to the technologies used for roofing and foundations, and describes how these are mutually entangled with new social structures. The conclusion is that we should think more broadly about the forms and effects of innovation in construction and recognize the significance of improvisation at the level of the individual or small group. Journal: Construction Management and Economics Pages: 537-549 Issue: 9 Volume: 37 Year: 2019 Month: 9 X-DOI: 10.1080/01446193.2019.1614202 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1614202 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:9:p:537-549 Template-Type: ReDIF-Article 1.0 Author-Name: Ruth M. Dowsett Author-X-Name-First: Ruth M. Author-X-Name-Last: Dowsett Author-Name: Chris F. Harty Author-X-Name-First: Chris F. Author-X-Name-Last: Harty Title: Assessing the implementation of BIM – an information systems approach Abstract: Much attention has been paid to measuring the perceived benefits of Building Information Modelling (BIM). Yet despite an increase its adoption throughout the construction industry, important links between implementation, support and benefits are yet to be explored. We examine the constitutive elements of the BIM implementation process of two case studies implementing and using BIM: the first is a large urban regeneration project, and the second is a healthcare project. A well-recognised model of system success is mobilized from the field of information systems (ISs) to reveal that irrespective of project size and type, BIM benefits are confined to technically discrete productivity and efficiency gains when there is limited focus on the organizational aspects of BIM adoption. This paper focuses on the disconnections between organizational and project level BIM implementation using the DeLone and McLean Model as an analytical framework to systematically examine the benefits of BIM to each project in relation to the implementation approach employed. This study highlights the significance of these interdependencies and argues for a more comprehensive approach to BIM benefits capture that recognises this to usefully inform implementation strategy development. Journal: Construction Management and Economics Pages: 551-566 Issue: 10 Volume: 37 Year: 2019 Month: 10 X-DOI: 10.1080/01446193.2018.1476728 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1476728 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:10:p:551-566 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: David Oswald Author-X-Name-First: David Author-X-Name-Last: Oswald Author-Name: Tiendung Le Author-X-Name-First: Tiendung Author-X-Name-Last: Le Title: Embedding occupational health and safety in the procurement and management of infrastructure projects: institutional logics at play in the context of new public management Abstract: The research explored the approaches used by government agencies (as client organizations) to drive occupational health and safety (OHS) performance improvements in publicly funded infrastructure construction projects in Australia. Semi-structured interviews were conducted with 32 representatives of clients and contractors with direct and recent experience of delivering large public infrastructure projects. Interviews explored the procurement approaches taken, and the use of incentives and performance measurement. Data was subjected to inductive analysis to identify emergent concepts and themes relating to the way that New Public Management (NPM) influences the commercial management of infrastructure construction projects, with particular reference to OHS impacts. The concept of institutional logics was utilised as a theoretical frame to understand clients’ behaviour in the commercial management of infrastructure projects. Client behaviour was consistent with elements of NPM and reflected a managerialist logic in the pursuit of efficiency, the use of targets, incentives and performance measurement. However, a strong professional service logic was also found to drive active client behaviour in relation to the management of OHS. Understanding the institutional logics driving client OHS practices is an important theoretical development that can stimulate reflexive practice which may create an impetus for change. Journal: Construction Management and Economics Pages: 567-583 Issue: 10 Volume: 37 Year: 2019 Month: 10 X-DOI: 10.1080/01446193.2018.1551617 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1551617 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:10:p:567-583 Template-Type: ReDIF-Article 1.0 Author-Name: Ruolan Gao Author-X-Name-First: Ruolan Author-X-Name-Last: Gao Author-Name: Jicai Liu Author-X-Name-First: Jicai Author-X-Name-Last: Liu Title: Selection of government supervision mode of PPP projects during the operation stage Abstract: During the operation stage of public-private partnership (PPP) projects, investors may engage in opportunistic behaviour in pursuit of their own profits. In order to curb this kind of behaviour, this article analyses the selection of government supervision mode based on evolutionary game theory taking the perspective of government supervision. The results show that government supervision mode is closely related to the probability of identifying investors’ speculative behaviour through outcome-oriented supervision. When the probability of identifying such behaviour is relatively high, the equilibrium strategy of investors and governmental supervision institutions is (not to behave opportunistically, outcome-oriented supervision). In contrast, if the probability is relatively low, there is no set of evolutionarily stable strategies (ESS); rather, a periodic behavioural pattern is formed. In this scenario, the strategies ultimately chosen by both sides relate to initial states and the payoffs of the options. Furthermore, determinants and some recommendations for government supervision are proposed, providing a reference for efficient governance. Journal: Construction Management and Economics Pages: 584-603 Issue: 10 Volume: 37 Year: 2019 Month: 10 X-DOI: 10.1080/01446193.2018.1564347 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1564347 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:10:p:584-603 Template-Type: ReDIF-Article 1.0 Author-Name: Natalya Sergeeva Author-X-Name-First: Natalya Author-X-Name-Last: Sergeeva Author-Name: Stuart D. Green Author-X-Name-First: Stuart D. Author-X-Name-Last: Green Title: Managerial identity work in action: performative narratives and anecdotal stories of innovation Abstract: Innovation is invariably accepted as a central component of construction sector competitiveness. Yet, there remains a paucity of empirical research, which explores the gap between the way innovation is promoted in the policy discourse and how it is interpreted in practice. We follow the “narrative turn” in organization studies to explore the ways in which senior executives in the UK construction sector ascribe themselves with informal roles while advocating the cause of innovation. Empirical data is derived from narrative interviews with 32 senior executives who self-identify as “innovation champions”. When talking about innovation, the respondents were found to oscillate between performative narratives of innovation and more personalized stories derived from their own experience. The narratives were invariably pre-rehearsed often to the point of being monotonous. In contrast, the personalized stories tended to be engaging and emotionally laden. The tendency for senior executives to oscillate between narratives and stories is seen as an important means through which they search for meaning while at the same time legitimizing their self-identities as “innovation champions”. Of particular note is the way in which senior managers self-ascribe themselves with informal roles which are notably at odds with those described in more formalized narratives. Journal: Construction Management and Economics Pages: 604-623 Issue: 10 Volume: 37 Year: 2019 Month: 10 X-DOI: 10.1080/01446193.2019.1566625 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1566625 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:10:p:604-623 Template-Type: ReDIF-Article 1.0 Author-Name: Eric Fosu Oteng-Abayie Author-X-Name-First: Eric Fosu Author-X-Name-Last: Oteng-Abayie Author-Name: John Bosco Dramani Author-X-Name-First: John Bosco Author-X-Name-Last: Dramani Title: Time-frequency domain causality of prime building cost and macroeconomic indicators in Ghana: implications for project selection Abstract: According to the Ghana Statistical Service, construction activity generated US$3.8 billion in 2014, representing about 12.7% of nominal GDP. A key factor that most investors in the construction sector consider in project selection is cost which has escalated over the years. Therefore, we examine the co-movements and causality in the time and frequency domains between the prime building cost index (PBCI) and its disaggregates on one hand and inflation and exchange rate on the other hand in Ghana. The findings revealed that the degree of co-movement between PBCI and inflation was significant at the 5% level and occurred over the long-run, indicating that construction cost drives inflation. The degree of co-movement between the prime build cost index and exchange rate occurred within the short term. These co-movements have policy implications for substituting inflation and exchange rates in project costing by investors in Ghana. The co-movement between the PBCI and inflation in the medium to higher frequencies suggests that inflation risk-averse investors should consider short-term projects. Again, the short to medium frequency co-movements between the PBCI and exchange rate indicates that investors should consider exchange rate risk in long-term projects. Journal: Construction Management and Economics Pages: 243-256 Issue: 5 Volume: 37 Year: 2019 Month: 5 X-DOI: 10.1080/01446193.2018.1514125 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1514125 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:5:p:243-256 Template-Type: ReDIF-Article 1.0 Author-Name: Lizet Kuitert Author-X-Name-First: Lizet Author-X-Name-Last: Kuitert Author-Name: Leentje Volker Author-X-Name-First: Leentje Author-X-Name-Last: Volker Author-Name: Marleen H. Hermans Author-X-Name-First: Marleen H. Author-X-Name-Last: Hermans Title: Taking on a wider view: public value interests of construction clients in a changing construction industry Abstract: For financial and strategic reasons, public and semi-public construction clients increasingly depend on private parties to carry out public service delivery. They subcontract operational responsibilities to private parties while remaining socio-politically responsible for ensuring public values. Public administration literature mainly addresses the importance of procedural and performance values in safeguarding public values. However, safeguarding the quality of the built environment also requires a focus on product values. In this study, we aim to increase the understanding of the meaning and significance of public values in the daily practice of public construction clients and identify the challenges they face in commissioning these seemingly opposing values. A set of semi-structured interviews with the public administrators of a variety of public and semi-public construction client organizations in the Netherlands shows that both internal and external factors influence the collaborative practices between clients and contractors. This causes a value shift from an emphasis on procedural values to managing performance and product values, indicating that clients need to take on a wider view on public values. Six main public value dilemmas were found that complicate the task of developing an open, transparent and sustainable long-term client–contractor relationship. The current contractual system, however, lacks the flexibility to facilitate this product-based value view in construction. Journal: Construction Management and Economics Pages: 257-277 Issue: 5 Volume: 37 Year: 2019 Month: 5 X-DOI: 10.1080/01446193.2018.1515496 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1515496 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:5:p:257-277 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Grill Author-X-Name-First: Martin Author-X-Name-Last: Grill Author-Name: Kent Nielsen Author-X-Name-First: Kent Author-X-Name-Last: Nielsen Author-Name: Regine Grytnes Author-X-Name-First: Regine Author-X-Name-Last: Grytnes Author-Name: Anders Pousette Author-X-Name-First: Anders Author-X-Name-Last: Pousette Author-Name: Marianne Törner Author-X-Name-First: Marianne Author-X-Name-Last: Törner Title: The leadership practices of construction site managers and their influence on occupational safety: an observational study of transformational and passive/avoidant leadership Abstract: More than 20% of all reported occupational accidents in Europe in 2015 occurred within the construction industry. Leadership is an imperative antecedent to occupational safety. Transformational leadership is considered a central aspect of safety-promoting leadership and passive/avoidant leadership is considered a central aspect of poor safety leadership. This study aimed to comprehensively elucidate concrete, real-life transformational and passive/avoidant leadership behaviours through context-specific descriptions of day-to-day interactions between construction site managers and employees. A mixed method design was applied, combining structured observations of construction site managers, with questionnaire responses from construction employees. With this design, common method bias was eliminated. The results provide context-specific examples of transformational and passive/avoidant leadership behaviour. High proportions of observed transformational leadership was found to predict high construction site safety. High proportions of observed passive/avoidant leadership was found to predict low construction site safety. The proportion of transformational leadership behaviour was higher among site managers in Sweden than in Denmark, indicating that national cultural context may be an antecedent to safety leadership among construction site managers. Applying less passive/avoidant leadership and more transformational leadership appears to be an effective way for construction site managers to improve occupational safety in the industry. Journal: Construction Management and Economics Pages: 278-293 Issue: 5 Volume: 37 Year: 2019 Month: 5 X-DOI: 10.1080/01446193.2018.1526388 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1526388 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:5:p:278-293 Template-Type: ReDIF-Article 1.0 Author-Name: Susanna Hedborg Bengtsson Author-X-Name-First: Susanna Author-X-Name-Last: Hedborg Bengtsson Title: Coordinated construction logistics: an innovation perspective Abstract: Coordinated construction logistics is an increasingly discussed topic in the Swedish construction industry. It is suggested as a means to increase efficiency in transportation, decrease material usage, coordinate health and safety on-site, etc. Much research on construction logistics has been done from a supply chain management perspective, often highlighting construction logistics as a necessary rational tool to improve efficiency in construction industry. However, could there be other ways to study this phenomenon? The purpose of this paper is to map empirically found coordinated construction logistics models and explore them as different types of innovation. The findings suggest that coordinated construction logistics models should be regarded as not being a fully embedded innovation as they have not yet changed the processes in the way they set out to do initially. Furthermore, differences are identified between company-based models, project-based models and system-based models, and suggest that differences in, for example, development, impact and objectives should be regarded both when conducting research on and when implementing coordinated construction logistics in practice. Finally, it is concluded that commitment, communication and cooperation are important when implementing coordinated construction logistics, which is in line with findings within the supply chain management literature. Journal: Construction Management and Economics Pages: 294-307 Issue: 5 Volume: 37 Year: 2019 Month: 5 X-DOI: 10.1080/01446193.2018.1528372 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1528372 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:5:p:294-307 Template-Type: ReDIF-Article 1.0 Author-Name: Abdollah Noorizadeh Author-X-Name-First: Abdollah Author-X-Name-Last: Noorizadeh Author-Name: Kamran Rashidi Author-X-Name-First: Kamran Author-X-Name-Last: Rashidi Author-Name: Antti Peltokorpi Author-X-Name-First: Antti Author-X-Name-Last: Peltokorpi Title: Categorizing suppliers for development investments in construction: application of DEA and RFM concept Abstract: Supplier development plays a significant role in the cost, quality and delivery improvements of construction projects. However, there is limited research on analytical methods of categorizing and prioritizing a high number of suppliers for effective allocation of scarce development resources. This research aims to develop an objective model to categorize a general contractor’s suppliers. To do so, we use three concepts from different research backgrounds – recency, frequency and monetary value (RFM); data envelopment analysis (DEA); and the customer pyramid – and add the number of projects (P) shared with each supplier as a context-related variable to build a novel RFMP model. The model categorizes suppliers into four levels of the supplier pyramid, utilizing historical data on supplier–contractor transactions. To test the model in practice, we adopt a case study of an international construction company in Finland. The results reveal that a supplier’s RFMP score reflects its contribution to the contractor’s business; therefore, development investments should vary, based on a supplier’s position in the supplier pyramid. This research contributes to the knowledge on supply chain management in construction by combining three approaches – RFM, DEA and the customer pyramid – into a single objective model to categorize suppliers for effective development investments. Journal: Construction Management and Economics Pages: 487-506 Issue: 9 Volume: 36 Year: 2018 Month: 9 X-DOI: 10.1080/01446193.2017.1416151 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1416151 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:9:p:487-506 Template-Type: ReDIF-Article 1.0 Author-Name: J. Sacilotto Author-X-Name-First: J. Author-X-Name-Last: Sacilotto Author-Name: M. Loosemore Author-X-Name-First: M. Author-X-Name-Last: Loosemore Title: Chinese investment in the Australian construction industry: the social amplification of risk Abstract: Chinese companies are investing heavily in overseas construction and property assets. In Australia, and in many other countries such as the United States and United Kingdom, this has generated an emotive and polarized debate about the risks and opportunities posed to local industry and to wider national interests. To explore the social and cognitive mechanisms which people are using to make sense of this new global phenomenon, Kasperson’s Social Amplification of Risk Framework (SARF) was mobilized, through semi-structured interviews with senior Australian construction industry leaders. The results show that the SARF is a valuable lens to explore perceptions of risk and opportunity associated with Chinese Foreign Direct Investment (FDI), although it represents a rather linear view and underplays the importance of power, collaboration and social media in forming perceptions. They also show that senior practitioners in the Australian construction industry are taking a highly rational, commercial and pragmatic approach to increasing FDI. Despite some concerns around non-compliant materials, labour standards and safety standards, Chinese FDI is seen as inevitable and crucial to the development of Australia’s construction industry. Surprisingly, given negative media coverage of Chinese FDI in Australia and a lack of experience in working with Chinese investors, we found little evidence for the social amplification or attenuation of risk. Knee-jerk regulatory reactions which are advocated by many groups are generally seen as risky and we conclude that the nature of Chinese – Australian business experiences over the near future will have a major effect on whether those perceptions eventuate as negative or positive. It is recommended that the best way to mitigate any risks and maximize the opportunities is not to withdraw and oppose Chinese FDI but to build collaborative links to improve direct interactions between Australian and Chinese firms, underpinned by targeted risk and opportunity management protocols. Journal: Construction Management and Economics Pages: 507-520 Issue: 9 Volume: 36 Year: 2018 Month: 9 X-DOI: 10.1080/01446193.2018.1457222 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1457222 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:9:p:507-520 Template-Type: ReDIF-Article 1.0 Author-Name: Jessica Kaminsky Author-X-Name-First: Jessica Author-X-Name-Last: Kaminsky Author-Name: Kasey Faust Author-X-Name-First: Kasey Author-X-Name-Last: Faust Title: Infrastructure epistemologies: water, wastewater and displaced persons in Germany Abstract: Recent years have seen historically unprecedented global disaster migration; in 2016 Germany received 1.3 million displaced individuals. Regardless of past resources and future potential, disaster migrants are a new, vulnerable population. This new population increases demand for water and wastewater infrastructure services, despite being temporarily unable to pay for services. As such, this kind of sudden population increase is a resiliency challenge for the receiving infrastructure systems. Qualitative analysis of 1,884 open-ended survey responses was blended with a statistical analysis to discover how and why the German public perceives water and sanitation services have been provided to the disaster migrants. Unprompted, 36% (112/314) of respondents referenced at least one of three infrastructure epistemologies, including water and wastewater as a service, as a basic need, and as a human right. These epistemologies share statistically significant relationships with how long respondents feel water and wastewater should be provided to displaced persons. A temporally limited, normative perception of water and sanitation as a humanitarian good functions to enable water and wastewater infrastructure to deliver a high level of service despite the significant disruption of the large and vulnerable population influx, and has practical implications for the structure of cost recovery. Journal: Construction Management and Economics Pages: 521-534 Issue: 9 Volume: 36 Year: 2018 Month: 9 X-DOI: 10.1080/01446193.2018.1462499 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1462499 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:9:p:521-534 Template-Type: ReDIF-Article 1.0 Author-Name: Cecília Gravina da Rocha Author-X-Name-First: Cecília Gravina Author-X-Name-Last: da Rocha Author-Name: Sergio Kemmer Author-X-Name-First: Sergio Author-X-Name-Last: Kemmer Title: Integrating product and process design in construction Abstract: Product modularity namely the notion that products can be decomposed into parts (or modules) has been widely applied in manufacturing but not in construction, precluding this industry to also benefit from it. The narrow definition of a module, which is often simplistically equated to a sub-assembly produced off-site, and the lack of integration between product and process design, which is typical in construction, are argued to be two root causes of such problem. This paper starts by discussing the operational implications of misaligned decisions in these two domains in an empirical study addressing a high-rise apartments building project. Seven guidelines are then devised using a Design Science Research (DSR) approach for integrating product (product modularity and modules) and process (work structure and work packages) design. The results indicate that product modularity can be applied for improving operations regardless of the construction method(s) used. Yet, a revised understanding of modules (as a material, a component, a non-volumetric or a volumetric sub-assembly) is needed in addition to a coordinated product and process design, particularly for traditional construction. Journal: Construction Management and Economics Pages: 535-543 Issue: 9 Volume: 36 Year: 2018 Month: 9 X-DOI: 10.1080/01446193.2018.1464198 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1464198 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:9:p:535-543 Template-Type: ReDIF-Article 1.0 Author-Name: Shabnam Kabiri Author-X-Name-First: Shabnam Author-X-Name-Last: Kabiri Author-Name: Will Hughes Author-X-Name-First: Will Author-X-Name-Last: Hughes Title: The interplay between formal and informal elements in analysing situations of role conflict among construction participants Abstract: The interplay of formal and informal factors in construction teams influences the enactment of roles and the individuals who fulfil those roles. With a specific focus on a phenomenon called role conflict, the aim is to explore if and how the interaction of formal and informal elements would lead to situations of role conflict. This phenomenon proved to lead to frustration, tension and employee burnout. An analytical model of role interaction was developed, which disentangles formal and informal elements that shape role interactions. Qualitative data was collected through semi-structured interviews, project documents and observations. Four cases of role conflict are presented here. Contract, as a formal element, and participant’s values and interests, as informal elements, appeared to be the most important factor shaping participants’ expectations and behaviours. The analysis in this study showed that if a participant who faces role conflict is able to influence the formal elements in favour of his or her informal elements, then he or she may experience less frustration. At a more general level, the results suggest that increasing formality can increase participants’ frustration, which then would decrease the likelihood of collaboration. As the theoretical contribution, this research extends organizational role theory to deal with informal and formal aspects. Taking into account formal sources enables the study of how roles are institutionally governed while including informal sources allows for the idea that some of the aspects of the role, even in the context of work role, are socially constructed. Journal: Construction Management and Economics Pages: 651-665 Issue: 12 Volume: 36 Year: 2018 Month: 12 X-DOI: 10.1080/01446193.2018.1472794 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1472794 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:12:p:651-665 Template-Type: ReDIF-Article 1.0 Author-Name: Pablo Ballesteros-Pérez Author-X-Name-First: Pablo Author-X-Name-Last: Ballesteros-Pérez Author-Name: Stefán Thor Smith Author-X-Name-First: Stefán Thor Author-X-Name-Last: Smith Author-Name: Josephine Gwen Lloyd-Papworth Author-X-Name-First: Josephine Gwen Author-X-Name-Last: Lloyd-Papworth Author-Name: Peter Cooke Author-X-Name-First: Peter Author-X-Name-Last: Cooke Title: Incorporating the effect of weather in construction scheduling and management with sine wave curves: application in the United Kingdom Abstract: The impact of (adverse) weather is a common cause of delays, legal claims and economic losses in construction projects. Research has recently been carried out aimed at incorporating the effect of weather in project planning; but these studies have focussed on either a narrow set of weather variables, or a very limited range of construction activities or projects. A method for processing a country’s historical weather data into a set of weather delay maps for some representative standard construction activities is proposed. Namely, sine curves are used to associate daily combinations of weather variables to delay and provide coefficients for expected productivity losses. A complete case study comprising the construction of these maps and the associated sine waves for the UK is presented along with an example of their use in building construction planning. Findings of this study indicate that UK weather extends project durations by an average of 21%. However, using climatological data derived from weather observations when planning could lead to average reductions in project durations of 16%, with proportional reductions in indirect and overhead costs. Journal: Construction Management and Economics Pages: 666-682 Issue: 12 Volume: 36 Year: 2018 Month: 12 X-DOI: 10.1080/01446193.2018.1478109 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1478109 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:12:p:666-682 Template-Type: ReDIF-Article 1.0 Author-Name: Perry Forsythe Author-X-Name-First: Perry Author-X-Name-Last: Forsythe Title: Extending and operationalizing construction productivity measurement on building projects Abstract: Measuring construction productivity in an accurate, repeatable and reliable way represents a significant problem at a building project level of enquiry. The research develops a measurement framework that balances simplified data gathering against explanatory ability. It aims to assist analytically driven process improvement. Debate and discourse are used to draw upon the extant literature in creating a logic-based flow of ideas to develop the framework. Targeted use of empirical cost and site process data from case studies are presented to punctuate the discourse. The derived approach advocates multifactor measurement inclusive of labour and temporary production infrastructure inputs, set against Gross Floor Area outputs. Emphasis is placed on separately measuring homogenous and heterogeneous parts of work processes. A reductionist approach is used to operationalize measurement where projects are categorized according to fitness-for-purpose criteria and links made between systems, activities and tasks. Emphasizing measurement of homogenous parts of the work is new to the literature. It enables delineated measurement between work involving mass economies of scale (homogenous work), versus customized work (heterogeneous work). The approach enables improved benchmarking, diagnostic and predicative options. A course of ongoing research is provided to assist ongoing development and implementation. Journal: Construction Management and Economics Pages: 683-699 Issue: 12 Volume: 36 Year: 2018 Month: 12 X-DOI: 10.1080/01446193.2018.1480834 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1480834 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:12:p:683-699 Template-Type: ReDIF-Article 1.0 Author-Name: Shobha Ramalingam Author-X-Name-First: Shobha Author-X-Name-Last: Ramalingam Author-Name: Ashwin Mahalingam Author-X-Name-First: Ashwin Author-X-Name-Last: Mahalingam Title: Knowledge coordination in transnational engineering projects:a practice-based study Abstract: Several multinational engineering firms offshore the delivery of engineering design or structural detail drawings to their globally distributed delivery centres. Studies have reported knowledge-sharing challenges when such work is co-ordinated across boundaries. This study takes a practice-based approach to explore knowledge-coordinating challenges across two multinational engineering firms that offshore projects to their global delivery centres in India. Data was collected from six infrastructure projects in the two delivery centres through direct observations augmented with real-time interviews and reviews of e-mails and project documents. This data was analysed qualitatively using ethnographic-coding techniques. Empirical findings identified a set of eight coordinating practices, many of which were emergent, which the teams creatively recombined and enacted as co-ordinating mechanisms that spanned organisational boundaries. Seven practices served to transfer knowledge and one practice transformed knowledge across onshore and offshore units. The study contributes to our understanding of co-ordinating by identifying emergent and informal coordinating practices in offshored construction projects and provides insights to practitioners on the boundary spanning capabilities of these practices. Journal: Construction Management and Economics Pages: 700-715 Issue: 12 Volume: 36 Year: 2018 Month: 12 X-DOI: 10.1080/01446193.2018.1498591 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1498591 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:12:p:700-715 Template-Type: ReDIF-Article 1.0 Author-Name: Roberto Pietroforte Author-X-Name-First: Roberto Author-X-Name-Last: Pietroforte Title: Toward More Sustainable Infrastructure: Project Evaluation for Planners and Engineers Journal: Construction Management and Economics Pages: 1242-1244 Issue: 12 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.641503 File-URL: http://hdl.handle.net/10.1080/01446193.2011.641503 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:12:p:1242-1244 Template-Type: ReDIF-Article 1.0 Author-Name: Vaughan Coffey Author-X-Name-First: Vaughan Author-X-Name-Last: Coffey Title: Quality Management in Construction Projects Journal: Construction Management and Economics Pages: 1244-1246 Issue: 12 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.645492 File-URL: http://hdl.handle.net/10.1080/01446193.2011.645492 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:12:p:1244-1246 Template-Type: ReDIF-Article 1.0 Author-Name: Olli Teriö Author-X-Name-First: Olli Author-X-Name-Last: Teriö Author-Name: Kalle Kähkönen Author-X-Name-First: Kalle Author-X-Name-Last: Kähkönen Title: Developing and implementing environmental management systems for small and medium-sized construction enterprises Abstract: Environmental aspects are gradually becoming factors of importance for construction businesses, their operations and their management. These factors can be seen as new change makers for construction management itself. New criteria need to be taken into account when structuring construction activities, in decision making, and throughout the production control. Instances of construction management solutions that also encapsulate environmental aspects are likely to appear. A contractor’s environmental management system (EMS) is an example of such an instance. As a management solution an EMS is targeted at minimizing a contractor’s environmental impacts. An experiment has been carried out where an EMS solution was formed and tested for small and medium-sized contractors. Fifteen small and medium-sized construction companies were involved. Along with the action research approach, a set of workshops with company people were arranged for EMS structuring and for its testing. Within these experiments the researcher acted as a developer and inside observer. The proposed EMS solution presents the structuring of environmental aspects for management attention. Moreover, this structuring can be used as a basis for a formal environmentally conscious management system. All companies involved in the research have started to use the EMS solution or its parts. Journal: Construction Management and Economics Pages: 1183-1195 Issue: 12 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.645493 File-URL: http://hdl.handle.net/10.1080/01446193.2011.645493 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:12:p:1183-1195 Template-Type: ReDIF-Article 1.0 Author-Name: Les Ruddock Author-X-Name-First: Les Author-X-Name-Last: Ruddock Author-Name: Steven Ruddock Author-X-Name-First: Steven Author-X-Name-Last: Ruddock Title: Evaluation of trends in the UK construction industry using growth and productivity accounts Abstract: For an assessment of the productivity performance of construction at the industry level, the quality of any analysis can be improved by the availability and use of detailed data on the basic components of the industry’s production function. The EU KLEMS Growth and Productivity Accounts comprise a dataset that provides a rich source of information on the sources of growth by industry, one of which is the construction industry (ISIC 45), since the 1970s for European Union countries and other major economies. The database allows a breakdown of factor inputs by the categorization of capital inputs into asset types and labour inputs into components such as skill levels to provide more precise measurement of sources of growth at industry level. The UK construction sector forms the focal point of the analysis and the results of this analysis provide evidence of a steady increase in the growth of ICT and improved labour skills usage and a relatively high rate of total factor productivity for the UK construction industry. Journal: Construction Management and Economics Pages: 1229-1239 Issue: 12 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.645494 File-URL: http://hdl.handle.net/10.1080/01446193.2011.645494 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:12:p:1229-1239 Template-Type: ReDIF-Article 1.0 Author-Name: Lorraine Sheppard Author-X-Name-First: Lorraine Author-X-Name-Last: Sheppard Title: Improving Healthcare through Built Environment Infrastructure Journal: Construction Management and Economics Pages: 1241-1242 Issue: 12 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.647827 File-URL: http://hdl.handle.net/10.1080/01446193.2011.647827 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:12:p:1241-1242 Template-Type: ReDIF-Article 1.0 Author-Name: Roberta Pellegrino Author-X-Name-First: Roberta Author-X-Name-Last: Pellegrino Author-Name: Luigi Ranieri Author-X-Name-First: Luigi Author-X-Name-Last: Ranieri Author-Name: Nicola Costantino Author-X-Name-First: Nicola Author-X-Name-Last: Costantino Author-Name: Giovanni Mummolo Author-X-Name-First: Giovanni Author-X-Name-Last: Mummolo Title: A real options-based model to supporting risk allocation in price cap regulation approach for public utilities Abstract: Price cap regulation of public utilities is based on an incentive mechanism to prevent monopolistic infrastructure firms from charging excessive prices. The challenge of this regulation mechanism is to define incentives able to avoid abnormal profits of firms and simultaneously increase quality of service and promote investment projects. A new risk-based approach to support the definition of the fair incentive mechanism as between the regulator, the community and the firm is proposed. The methodology is based on the combined use of real options theory and Monte Carlo simulation. The methodology is then applied to the Italian water market where the regulator adopts a ‘hybrid’ price cap mechanism that gives monopolistic firms the incentive to implement investment projects for reducing the actual infrastructural gap in the water supply system. The results reveal the capability of the proposed model to support public decision makers at the negotiation stage to define the incentive scheme and investment plan able to increase the quality of service allowing a fair risk allocation among parties. Journal: Construction Management and Economics Pages: 1197-1207 Issue: 12 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.647828 File-URL: http://hdl.handle.net/10.1080/01446193.2011.647828 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:12:p:1197-1207 Template-Type: ReDIF-Article 1.0 Author-Name: Irina Brodetskaia Author-X-Name-First: Irina Author-X-Name-Last: Brodetskaia Author-Name: Rafael Sacks Author-X-Name-First: Rafael Author-X-Name-Last: Sacks Author-Name: Aviad Shapira Author-X-Name-First: Aviad Author-X-Name-Last: Shapira Title: A workflow model for systems and interior finishing works in building construction Abstract: Modelling the flow of systems and interior finishing works in building construction has been hampered by the inability of traditional critical path modelling to reflect features of these works such as uncertainty, instability, non-linear and interrupted value-adding processes and re-entrant flow. Drawing on empirical data collected in a work study of a large residential project, a novel workflow model is proposed that explicitly models the flows of products and crews at a fine-grained level. The overall model includes a trade workflow model with a module for each work-package type, and a project level model in which multiple trade modules are embedded. The model was tested through implementation of a simulation of a prototypical construction project involving seven work-packages performed in a 20-storey residential tower with 120 customized apartments. The modelled flows of crews through the test building reflected the same behavioural features observed in construction projects. The model enables evaluation of the impact of management policies on production flow at different levels of detail. It is useful as a research tool and for future development of construction management software. Journal: Construction Management and Economics Pages: 1209-1227 Issue: 12 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.647829 File-URL: http://hdl.handle.net/10.1080/01446193.2011.647829 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:12:p:1209-1227 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Forthcoming events Journal: Construction Management and Economics Pages: 1261-1262 Issue: 12 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.649558 File-URL: http://hdl.handle.net/10.1080/01446193.2011.649558 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:12:p:1261-1262 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Editorial Journal: Construction Management and Economics Pages: 1181-1181 Issue: 12 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.650424 File-URL: http://hdl.handle.net/10.1080/01446193.2011.650424 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:12:p:1181-1181 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Editorial Board Journal: Construction Management and Economics Pages: ebi-ebi Issue: 12 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.650483 File-URL: http://hdl.handle.net/10.1080/01446193.2011.650483 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:12:p:ebi-ebi Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Referees for Volume 29 (2011) Journal: Construction Management and Economics Pages: 1247-1257 Issue: 12 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.650484 File-URL: http://hdl.handle.net/10.1080/01446193.2011.650484 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:12:p:1247-1257 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Author and Book Review Index Journal: Construction Management and Economics Pages: 1259-1260 Issue: 12 Volume: 29 Year: 2011 X-DOI: 10.1080/01446193.2011.650485 File-URL: http://hdl.handle.net/10.1080/01446193.2011.650485 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:29:y:2011:i:12:p:1259-1260 Template-Type: ReDIF-Article 1.0 Author-Name: M. George Author-X-Name-First: M. Author-X-Name-Last: George Author-Name: M. Loosemore Author-X-Name-First: M. Author-X-Name-Last: Loosemore Title: Site operatives’ attitudes towards traditional masculinity ideology in the Australian construction industry Abstract: There is a widely accepted assumption in the construction literature that the industry is highly masculinised. However, there has been a surprising lack of empirical evidence around workers’ own attitudes towards masculinity in the sector. Addressing this lack of research, a survey to measure construction site operatives’ attitudes towards traditional masculinity ideology was undertaken in Australia using the Male Role Norms Inventory Scale-Short Form (MRNI-SF). It is found that the focus of attitudes towards masculinity in the construction industry may be shifting to reflect trends in the wider population and may be more inclusive and less hegemonic than has been previously argued. It is also found that the focus of masculinity in the construction industry is closely related to the physical and high-risk nature of work and that sexuality and humour may also be an important source of masculine identity. These results are important since they contribute a more nuanced understanding of the dimensions and exact nature of attitudes towards masculinity in the construction industry. It is concluded that future research into the impact of masculinity in areas such as gender diversity, safety and mental health would benefit from a more inclusive theoretical lens which recognises the dynamic nature of masculinity and which highlights the institutional legacies of past hegemonies that have to be challenged to move the industry forward. Journal: Construction Management and Economics Pages: 419-432 Issue: 8 Volume: 37 Year: 2019 Month: 8 X-DOI: 10.1080/01446193.2018.1535713 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1535713 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:8:p:419-432 Template-Type: ReDIF-Article 1.0 Author-Name: Craig S. Thomson Author-X-Name-First: Craig S. Author-X-Name-Last: Thomson Author-Name: Mohamed A. El-Haram Author-X-Name-First: Mohamed A. Author-X-Name-Last: El-Haram Title: Is the evolution of building sustainability assessment methods promoting the desired sharing of knowledge amongst project stakeholders? Abstract: Building sustainability assessment methods (BSAM’s) seek to help project stakeholders understand the predicted and actual sustainability performance of their buildings but are often applied reactively and isolated from project decisions. The last decade has seen BREEAM at the forefront of evolving assessment practice towards a framework approach to help shape project decisions and promote stakeholder learning. The research explores the nature and extent this transition is being realized in practice within four case studies applying BREEAM spanning a 15-year period. Process and knowledge mapping techniques are applied to explore the flow of knowledge required to enable sustainable decisions, stimulate the sharing of understanding, mediation of views and to promote learning amongst stakeholders. Evidence suggested that when applied in progressive projects that the flow of knowledge is strongest when supported by sustainability leadership, a framework approach aligned with project management, an improvement and engagement culture and a strategy for promoting knowledge flow. As practice matures care is needed to ensure engagement remains high and stakeholders are not isolated from the flow of knowledge as projects increasingly rely on sustainability advisors thus losing the opportunity to learn and shape decisions. Journal: Construction Management and Economics Pages: 433-460 Issue: 8 Volume: 37 Year: 2019 Month: 8 X-DOI: 10.1080/01446193.2018.1537502 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1537502 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:8:p:433-460 Template-Type: ReDIF-Article 1.0 Author-Name: Kaixun Sha Author-X-Name-First: Kaixun Author-X-Name-Last: Sha Title: Incentive strategies for construction project manager: a common agency perspective Abstract: According to the principal-agent theory, the agent should be motivated to behave in a manner consistent with the principal’s requirements. By expanding the focus from the bilateral principal-agent relationship within the firm to the triangular relationship between the client, the construction company and its project manager, this study seeks to explore a new way in which construction firms determining incentive strategies for their construction project managers (CPMs). A common agency model of ‘one servant of two masters’ is established while some negative/positive factors are identified, including rent-seeking effect, collusion effect and check-and-balance effect between the three parties. An autonomy-incentive grid is developed in which one can distinguish four alternative strategies. Implementation costs of each strategy in different scenarios are qualitatively assessed and a set of incentive strategies suitable for different scenarios are determined according to the complicatedness of the project and the type of the client. The model of ‘one servant of two masters’ may provide conceptual insights into incentive strategies for CPMs, and provide practical guidelines for construction firms, but at the same time, it needs testing, verifying and improving in the future practice. Journal: Construction Management and Economics Pages: 461-471 Issue: 8 Volume: 37 Year: 2019 Month: 8 X-DOI: 10.1080/01446193.2018.1554255 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1554255 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:8:p:461-471 Template-Type: ReDIF-Article 1.0 Author-Name: Festival Godwin Boateng Author-X-Name-First: Festival Godwin Author-X-Name-Last: Boateng Title: A brief case for an organizational grounding for structural safety in the construction sector Journal: Construction Management and Economics Pages: 472-473 Issue: 8 Volume: 37 Year: 2019 Month: 8 X-DOI: 10.1080/01446193.2019.1591629 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1591629 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:8:p:472-473 Template-Type: ReDIF-Article 1.0 Author-Name: Wael Khalil Shadid Author-X-Name-First: Wael Khalil Author-X-Name-Last: Shadid Title: A framework for managing organizations in complex environments Abstract: The complex environments of today’s markets makes managing organizations in complexity and turbulence a concern for senior managers, and necessitate developing a dynamic strategic framework to cope with complexity in managing organizations. This paper demonstrates a study that was conducted to value a structured set of management principles and sub-elements by a panel of experts to develop a conceptual framework to manage in complex and very high dynamic environments. The panel consisted of 22 senior level managers of grade “A” companies in the construction industry in Qatar State using a two-round Delphi technique. The study developed two frameworks. The first framework is for managing complexity in the construction sector. The second one is the primary general framework, which forms a basis for a generalized framework for other industries. This study participates in developing valuable management practices in complex environments to tackle uncertainty, unpredictability, disorder, rapid changes and non-linearity, which would be of great help for leaders, senior managers and practitioners who operate in complex environments. Journal: Construction Management and Economics Pages: 182-202 Issue: 4 Volume: 36 Year: 2018 Month: 4 X-DOI: 10.1080/01446193.2017.1343483 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1343483 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:4:p:182-202 Template-Type: ReDIF-Article 1.0 Author-Name: Faruk Buyukyoran Author-X-Name-First: Faruk Author-X-Name-Last: Buyukyoran Author-Name: Selin Gundes Author-X-Name-First: Selin Author-X-Name-Last: Gundes Title: Optimized real options-based approach for government guarantees in PPP toll road projects Abstract: The uncertainty associated with future traffic levels in Build–Operate–Transfer toll road projects lead to difficulties in obtaining finance and thus to unsuccessful bids. In order to increase the attractiveness of projects for investors, governments usually provide several types of guarantees such as Minimum Revenue Guarantees (MRGs). In many cases, challenges associated with the valuation of this uncertainty force governments to provide excessive guarantees, placing an increased burden on the public budget. Based on this problem, a real-option-based model is presented for the identification of optimum upper and lower boundaries of compound MRG and Maximum Revenue Cap (MRC) options which establish a fair risk allocation structure. The proposed model uses an optimization approach in which high levels of guarantees in initial years are compensated by the transfer of excess revenues obtained by the private investor in late years. The optimum upper and lower boundaries of compound MRG and MRC options are identified using the proposed model. Results reveal that the emerging net guarantee amount generated by using any pair values of the MRG and MRC that remain in the identified interval not only maintains the attractiveness of project for private investors but also restrains government contingent liabilities. Thus, the identified interval of MRG and MRC enables the structuring of a flexible bargaining environment for both parties. Journal: Construction Management and Economics Pages: 203-216 Issue: 4 Volume: 36 Year: 2018 Month: 4 X-DOI: 10.1080/01446193.2017.1347267 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1347267 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:4:p:203-216 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Tansey Author-X-Name-First: Paul Author-X-Name-Last: Tansey Author-Name: John P. Spillane Author-X-Name-First: John P. Author-X-Name-Last: Spillane Author-Name: Tara Brooks Author-X-Name-First: Tara Author-X-Name-Last: Brooks Title: Creating opportunities in the face of an environmental jolt: exploring turnaround strategizing practices within large Irish construction contractors Abstract: Firms that face organizational decline choreographed from an environmental jolt must seek new ways of creating opportunities in order to successfully turnaround. As such, the identification of pertinent turnaround strategies becomes increasingly important for senior management. Within the strategy-as-practice scholarly, there have been recent calls to move beyond empirical “isolationism” and to connect with other larger social phenomena; while across the turnaround literature there have been calls to explore the process and micro-structure of turnaround strategies in cyclical environments. To address this research gap, the purpose of the study is to adopt a tall ontology by blending the strategy-as-practice lens with the organizational decline and turnaround lens. By drawing on five exploratory case studies of large Irish construction contractors, the central objective is thus to explore firms’ turnaround strategizing practices during an environmental jolt. In order to advance our tall ontology, we developed a turnaround strategizing process model (and propositions) that integrates our findings, and which offers the fundamental building blocks of a new blended theory. We find that successful turnaround attempts entail the simultaneous interaction of non-aggressive cost retrenchment actions and non-extensive internationalization. The case studies further suggest that during a prolonged environmental jolt, cost retrenchment is more often a long-term strategy. Lastly, the findings provide valuable support for practitioners in developing a successful turnaround response, and in aiding the selection and timing of operational and strategic actions. Journal: Construction Management and Economics Pages: 217-241 Issue: 4 Volume: 36 Year: 2018 Month: 4 X-DOI: 10.1080/01446193.2017.1368679 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1368679 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:4:p:217-241 Template-Type: ReDIF-Article 1.0 Author-Name: Roine Leiringer Author-X-Name-First: Roine Author-X-Name-Last: Leiringer Author-Name: Andy Dainty Author-X-Name-First: Andy Author-X-Name-Last: Dainty Title: Plugging into the big debates of the day Journal: Construction Management and Economics Pages: 181-181 Issue: 4 Volume: 36 Year: 2018 Month: 4 X-DOI: 10.1080/01446193.2018.1446489 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1446489 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:4:p:181-181 Template-Type: ReDIF-Article 1.0 Author-Name: Micael Thunberg Author-X-Name-First: Micael Author-X-Name-Last: Thunberg Author-Name: Anna Fredriksson Author-X-Name-First: Anna Author-X-Name-Last: Fredriksson Title: Bringing planning back into the picture – How can supply chain planning aid in dealing with supply chain-related problems in construction? Abstract: There are several supply chain-related problems facing the construction industry, such as poor construction site logistics, lack of communication and trust. These problems can jeopardize construction projects through delays and cost overruns. Supply chain planning, a part of supply chain management (SCM), can be used as a tool to deal with these problems. The purpose of this paper is to study how linkages between common supply chain-related problems in construction can be illustrated and to demonstrate how they could be resolved through supply chain planning. Firstly, we identify how the linkages between common problems can be illustrated, and secondly the role of supply chain planning in resolving these problems. A conceptual model is developed that was verified using three cases with Swedish gypsum and kitchen supply chains. The model is shown to be useful in illustrating how supply chain problems occurring at executional level on-site are related to problems originating in lack of planning at company/pre-construction level. The study thus demonstrates how supply chain planning can aid in resolving supply chain problems. The paper contributes by bringing planning back into the picture and by showing how supply chain planning can help to adopt SCM in construction. Journal: Construction Management and Economics Pages: 425-442 Issue: 8 Volume: 36 Year: 2018 Month: 8 X-DOI: 10.1080/01446193.2017.1394579 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1394579 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:8:p:425-442 Template-Type: ReDIF-Article 1.0 Author-Name: Tan Hai Dang Nguyen Author-X-Name-First: Tan Hai Dang Author-X-Name-Last: Nguyen Author-Name: Nicholas Chileshe Author-X-Name-First: Nicholas Author-X-Name-Last: Chileshe Author-Name: Raufdeen Rameezdeen Author-X-Name-First: Raufdeen Author-X-Name-Last: Rameezdeen Title: External stakeholder strategic actions in construction projects: a Vietnamese study Abstract: Although understanding the influence of external stakeholders is crucial to achieving project success, little attention has been given to investigate their specific influence strategies. Based on a modified theoretical framework, we conducted a multiple-case study to explore common combinations and sequencings of specific actions that these stakeholders take to affect construction projects. Seven specific influence strategies were found: (i) inputs withholding, (ii) inputs compromising, (iii) communication, (iv) direct action, (v) coalition building, (vi) conflict escalation and (vii) credibility building. Stakeholders combined the last five strategies in three pairs persuading decision makers to take action. Coalition building - communication was the most prevalent combination that stakeholders use to influence decision-makers. The combination of communication and credibility building was found in cases having environmental disputes. Direct action and conflict escalation were exerted together in projects affecting the locals adversely. Some common patterns of stakeholder strategic actions were also observed. First, direct action came into existence after communication, followed by conflict escalation. Second, after establishing their credibility via persuasive evidence, experts’ judgements and the like, stakeholders used those outcomes to communicate to decision-makers. We emphasize the need for full and honest engagement with stakeholders to prevent their adverse influence on construction projects. Journal: Construction Management and Economics Pages: 443-458 Issue: 8 Volume: 36 Year: 2018 Month: 8 X-DOI: 10.1080/01446193.2018.1432866 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1432866 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:8:p:443-458 Template-Type: ReDIF-Article 1.0 Author-Name: Hsien-Hung Herman Yeh Author-X-Name-First: Hsien-Hung Herman Author-X-Name-Last: Yeh Title: How the capital structure of firms is determined over business cycles: further evidence from the construction industry of Taiwan Abstract: This paper uses the panel data regression model to study the Taiwanese construction industry during the period 1982–1995 because during this period, Taiwan’s gross domestic product shows a structural change in economic growth trends over three business cycles. This design allows us to examine whether the effects of firm characteristics and economic growth on capital structure vary with macroeconomic conditions and across periods with changing economic growth trends. First, the results show that the effect of macroeconomic conditions on capital structure is counter-cyclical. Second, the effects of firm characteristics on capital structure can vary with macroeconomic conditions, although firm characteristics do not have a direct effect on capital structure. Third, the effects of firm characteristics on capital structure can vary across periods with changing economic growth trends. Finally, economic growth does not have a direct effect on capital structure. However, the effect of economic growth on capital structure can vary with macroeconomic conditions and across periods with changing economic growth trends. The findings of this study can be a helpful reference for financial managers, creditors, investors and government policy-makers in emerging countries. Journal: Construction Management and Economics Pages: 459-471 Issue: 8 Volume: 36 Year: 2018 Month: 8 X-DOI: 10.1080/01446193.2018.1435896 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1435896 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:8:p:459-471 Template-Type: ReDIF-Article 1.0 Author-Name: Yongqiang Chen Author-X-Name-First: Yongqiang Author-X-Name-Last: Chen Author-Name: Wenqian Wang Author-X-Name-First: Wenqian Author-X-Name-Last: Wang Author-Name: Shuibo Zhang Author-X-Name-First: Shuibo Author-X-Name-Last: Zhang Author-Name: Jingya You Author-X-Name-First: Jingya Author-X-Name-Last: You Title: Understanding the multiple functions of construction contracts: the anatomy of FIDIC model contracts Abstract: Construction contracts, such as FIDIC model contracts, are relatively complex and cumbersome, and their composition needs to be better understood. This research uses a multi-functional approach that is widely recognized in the contract literature, and anatomizes FIDIC model contracts in order to gain a holistic and comprehensive understanding of them. Moreover, this research comparatively analyses the distribution of the three functions, namely control, coordination and adaptation, in four forms of FIDIC model contracts to explore how project delivery systems (PDSs) affect contract design. After a classification framework that includes three functions and ten subclasses was established, the FIDIC 1999 series model contracts were coded sentence by sentence using content analysis. The results show that the three functions are all non-trivially reflected in construction contracts and are influenced by project complexity. Regarding different PDSs, the complexity of contract control is relatively rigid; the complexity of contract coordination is largely influenced by PDSs; and the impact of PDSs on the complexity of adaptation provisions depends on the sub-class. The conclusions may help scholars and practitioners understand construction contracts from a functional perspective, and offer references for contract designers to reasonably consider the distribution of the three functions in construction contracts. Journal: Construction Management and Economics Pages: 472-485 Issue: 8 Volume: 36 Year: 2018 Month: 8 X-DOI: 10.1080/01446193.2018.1449955 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1449955 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:8:p:472-485 Template-Type: ReDIF-Article 1.0 Author-Name: Amy Javernick-Will Author-X-Name-First: Amy Author-X-Name-Last: Javernick-Will Title: Rationale: the necessary ingredient for contributions to theory and practice Journal: Construction Management and Economics Pages: 423-424 Issue: 8 Volume: 36 Year: 2018 Month: 8 X-DOI: 10.1080/01446193.2018.1487910 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1487910 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:8:p:423-424 Template-Type: ReDIF-Article 1.0 Author-Name: Ricardo Leoto Author-X-Name-First: Ricardo Author-X-Name-Last: Leoto Author-Name: Gonzalo Lizarralde Author-X-Name-First: Gonzalo Author-X-Name-Last: Lizarralde Title: Challenges for integrated design (ID) in sustainable buildings Abstract: It is often argued that integrated design (ID) is a powerful way to enhance collaboration in construction projects. This collaboration is seen as a way of improving innovation to create more sustainable buildings. Contrary to the traditional silo-type and linear design process, ID is based on upfront stakeholder involvement and a holistic approach to project decision-making. Although ID’s premises are theoretically-founded, a close empirical look at its practices shows that numerous challenges compromise its results and efficiency. This study examines the ID process through an iterative process that includes the construction of a conceptual framework and its empirical validation. We examine three green construction projects in Canada. Based on the analysis of 26 interviews with key project stakeholders and more than 198 construction documents, the study assembles – and ultimately applies – a multi-lens framework based on four themes: the fragmented nature of construction; risk perception; stakeholders’ commitment; and efficiency in the design process. Results show that three tensions arise in ID practices: between collaboration and process efficiency, between short-term and long-term goals, and between integrated methods and traditional ones. The study sheds light on ID limits and reveals how stakeholders can improve their interactions to design more sustainable buildings. Journal: Construction Management and Economics Pages: 625-642 Issue: 11 Volume: 37 Year: 2019 Month: 11 X-DOI: 10.1080/01446193.2019.1569249 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1569249 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:11:p:625-642 Template-Type: ReDIF-Article 1.0 Author-Name: Yousaf Ali Author-X-Name-First: Yousaf Author-X-Name-Last: Ali Author-Name: Muhammad Sabir Author-X-Name-First: Muhammad Author-X-Name-Last: Sabir Author-Name: Noor Muhammad Author-X-Name-First: Noor Author-X-Name-Last: Muhammad Title: A comparative input-output analysis of the construction sector in three developing economies of South Asia Abstract: Construction is commonly regarded as one of the major industries of an economy that is receiving a significant attention in the developing countries. This paper uses the Asian Development Bank (ADB) input-output database at constant prices for the selected Asian countries, i.e. Bangladesh, Sri Lanka and Nepal to analyze and compare the performance of the construction sector in these economies. The novelty of this research is the application of multiple linkages methods. First, the standard measures of the backward and forward linkages are used to examine the induced output created by the demand push and supply pull effects of the construction industry. Second, the concept of Hypothetical Extraction Method (HEM) is applied to extract a sector hypothetically from an economic system and then to examine the influence of that extraction on the rest of the economy. The results indicate that the construction sector has a strong backward and weak forward linkages for all the three economies. Furthermore, results reveal that the ‘pull effect’ is very significant in these countries while the ‘push effect is very insignificant. With respect to the identification of the key sectors, the findings of the traditional methods are very different from those of the hypothetical extraction methods. Journal: Construction Management and Economics Pages: 643-658 Issue: 11 Volume: 37 Year: 2019 Month: 11 X-DOI: 10.1080/01446193.2019.1571214 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1571214 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:11:p:643-658 Template-Type: ReDIF-Article 1.0 Author-Name: M. van den Boomen Author-X-Name-First: M. Author-X-Name-Last: van den Boomen Author-Name: G. Leontaris Author-X-Name-First: G. Author-X-Name-Last: Leontaris Author-Name: A. R. M. Wolfert Author-X-Name-First: A. R. M. Author-X-Name-Last: Wolfert Title: Replacement optimization of ageing infrastructure under differential inflation Abstract: Ageing public infrastructure assets necessitate economic replacement analysis. A common replacement problem concerns an existing asset challenged by a replacement option. Classic techniques obtained from the domain of engineering economics are the mainstream approach to replacement optimization in practice. However, the validity of these classic techniques is built on the assumption that life cycle cash flows of a replacement option are repetitive. Differential inflation undermines this assumption and therefore more advanced replacement optimization techniques are required under these circumstances. These techniques are found in the domain of operations research and require linear or dynamic programming (LP/DP). Since LP/DP techniques are complex and time-consuming, the current study develops an alternative model for replacement optimizations under differential inflation. This approach builds on the classic capitalized equivalent replacement technique. The alternative model is validated by comparison with a DP model showing to be equally accurate for a case with characteristics that apply to many infrastructure assets. Journal: Construction Management and Economics Pages: 659-674 Issue: 11 Volume: 37 Year: 2019 Month: 11 X-DOI: 10.1080/01446193.2019.1574977 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1574977 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:11:p:659-674 Template-Type: ReDIF-Article 1.0 Author-Name: Ying Hong Author-X-Name-First: Ying Author-X-Name-Last: Hong Author-Name: Ahmed W. A. Hammad Author-X-Name-First: Ahmed W. A. Author-X-Name-Last: Hammad Author-Name: Ali Akbarnezhad Author-X-Name-First: Ali Author-X-Name-Last: Akbarnezhad Title: Impact of organization size and project type on BIM adoption in the Chinese construction market Abstract: Building Information Modelling (BIM) is perceived as an effective tool for improving the delivery and coordination of construction projects. The Chinese construction sector has demonstrated significant interest in implementing the 3-dimensional modelling-based process. BIM adoption is influenced by several factors which can either be operational or strategic related. Factors which can have a significant impact include the size of the construction organization and the type of projects that the organization has to deliver (i.e. building vs infrastructure projects). This study aims to evaluate the effect of project type and size on BIM adoption in the Chinese market, via an adoption model which analyses factors impacting the adoption decision. The study examines 200 samples collected from the Chinese construction industry, split equally between infrastructure and building construction data groups, as well as SMEs and large organizations. The collected data are first analyzed by principal component analysis and then through a Structural Equation Modelling-based multiple group analysis. Results demonstrate that essential factors such as operational risks are considered by small organization, whereas large organizations focus on implementation challenges. Implementation benefits and challenges are significant on the adoption decision in infrastructure organizations, but not in building organizations. In addition, the study reveals that “technical support” is an important factor when it comes to BIM adoption among all types of organizations, regardless of the organization’s size and project type delivered. Journal: Construction Management and Economics Pages: 675-691 Issue: 11 Volume: 37 Year: 2019 Month: 11 X-DOI: 10.1080/01446193.2019.1575515 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1575515 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:11:p:675-691 Template-Type: ReDIF-Article 1.0 Author-Name: Paul W. Chan Author-X-Name-First: Paul W. Author-X-Name-Last: Chan Title: Revisiting basics: theoretically-grounded interesting research that addresses challenges that matter Journal: Construction Management and Economics Pages: 1-10 Issue: 1 Volume: 38 Year: 2020 Month: 1 X-DOI: 10.1080/01446193.2019.1702251 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1702251 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:1:p:1-10 Template-Type: ReDIF-Article 1.0 Author-Name: David Oswald Author-X-Name-First: David Author-X-Name-Last: Oswald Title: Safety indicators: questioning the quantitative dominance Abstract: Safety indicators aim to provide information about the condition or state of safety within an organization. Typically, construction practitioners and researchers have focused on quantifying these indicators to provide precise measurement. It is argued that there has been a tendency to focus on the quantity, whilst ignoring qualitative indicators that can also provide valuable insights into the state of safety. Precise measurement has arguably been intensified by ‘borrowing’ leading indicators from the field of economics, which use quantitative frameworks. It is raised that the well-documented statistical limitations surrounding leading and lagging indicators should not be merely viewed as threats to reliability but should be considered as opportunities to further understand the state of safety through the development of appropriate qualitative indicators. A quantitative-only framework may be appropriate in the field of economics; however, this essay challenges the assumption that a similar approach can be implemented within the complex context of construction safety management. A call for researchers and practitioners to consider the qualitative indicators of safety; these can provide powerful insights into both why the state of safety is positive or negative, and how to help future accident prevention. Journal: Construction Management and Economics Pages: 11-17 Issue: 1 Volume: 38 Year: 2020 Month: 1 X-DOI: 10.1080/01446193.2019.1605184 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1605184 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:1:p:11-17 Template-Type: ReDIF-Article 1.0 Author-Name: Mustafa Selçuk Çıdık Author-X-Name-First: Mustafa Selçuk Author-X-Name-Last: Çıdık Author-Name: David Boyd Author-X-Name-First: David Author-X-Name-Last: Boyd Title: “Shared sense of purposefulness”: a new concept to understand the practice of coordinating design in construction Abstract: Construction management literature sees the collective task of coordinating design as being about the “‘integration’” of “fragmented” discipline-specific design tasks/outputs, thus overlooking the important role of social interactions. This is not only conceptually problematic but also presents a practical management problem. As a response, a practice-based approach, which relies on a “becoming” ontology, is adopted for a practical explanation of design coordination for more effective design management. The adopted methodology suggests that design develops as a result of unfolding (path-dependent) individual actions and interdisciplinary interactions. Based on this, the concept of a “shared sense of purposefulness” is proposed to refer to the temporary and precarious organizational state of a design team in which each of the interacting team members has achieved a state of purposefulness to resume individual action. Hence, design coordination in construction is redefined as continuously re-establishing and maintaining “a shared sense of purposefulness”. The concept’s usefulness for understanding the practice of design coordination is demonstrated using data collected from a project in the UK. The discussion enables fresh insights into the everyday operation of design coordination. It is concluded that the proposed conception paves a way forward both for the research and practice in construction design management. Journal: Construction Management and Economics Pages: 18-31 Issue: 1 Volume: 38 Year: 2020 Month: 1 X-DOI: 10.1080/01446193.2019.1593471 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1593471 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:1:p:18-31 Template-Type: ReDIF-Article 1.0 Author-Name: Hazel Ponton Author-X-Name-First: Hazel Author-X-Name-Last: Ponton Author-Name: Allan Osborne Author-X-Name-First: Allan Author-X-Name-Last: Osborne Author-Name: Neill Thompson Author-X-Name-First: Neill Author-X-Name-Last: Thompson Author-Name: David Greenwood Author-X-Name-First: David Author-X-Name-Last: Greenwood Title: The power of humour to unite and divide: a case study of design coordination meetings in construction Abstract: Design coordination meetings are the formal discussion venues that support interdisciplinary group interaction during the construction process. Social behaviour needs to be recognized, understood, and evaluated by group members if meetings are to be productive. The role of humour during the practice of coordinating building design has not previously been studied. A non-participant observation method was used to collect qualitative data from consecutive contractor-led design team meetings during a live building project. Using a 360° panoramic video-recording camera, episodes of humour were captured and collated into packets of rich data. These packets were then organized, structured, and analysed using NVivo computer-assisted qualitative data analysis software. The results of the analysis showed that instances of humour do not happen at random but at specific times when they performed distinct functions to facilitate the design coordination process. One notable example was the role of humour in helping to form a cohesive team that was able to manage conflict successfully and thus engender a positive cultural environment. The inclusive findings of the study have demonstrated that humour is a functional aspect of group dynamics during the coordination of design in construction that can influence social interaction and task-related performance. Journal: Construction Management and Economics Pages: 32-54 Issue: 1 Volume: 38 Year: 2020 Month: 1 X-DOI: 10.1080/01446193.2019.1656339 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1656339 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:1:p:32-54 Template-Type: ReDIF-Article 1.0 Author-Name: Daniella Troje Author-X-Name-First: Daniella Author-X-Name-Last: Troje Author-Name: Pernilla Gluch Author-X-Name-First: Pernilla Author-X-Name-Last: Gluch Title: Populating the social realm: new roles arising from social procurement Abstract: Employment requirements, as part of social procurement, are increasingly used in construction procurement as a tool to mitigate issues of exclusion on the job market. To create a better understanding how employment requirements nurtures a new type of actor, here named the “employment requirement professional” (ERP), the aim of this paper is to study how this role is framed in terms of work practices and professional identity. Building on 21 semi-structured interviews in the Swedish construction sector, a detailed account of who works with employment requirements, how and why they conduct their work is provided. The findings show how ERPs mediate between contrasting interests when they create new social procurement roles and practices; how they enact different approaches to promote social sustainability, how their roles are formed by multiple and reciprocal lines of actions, and how they make sense of who they are and what type of work they engage in. The research contributes to a discussion on effects from social procurement in construction and the emergence of a new professional role, their identity and work practices. Journal: Construction Management and Economics Pages: 55-70 Issue: 1 Volume: 38 Year: 2020 Month: 1 X-DOI: 10.1080/01446193.2019.1597273 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1597273 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:1:p:55-70 Template-Type: ReDIF-Article 1.0 Author-Name: Tara Brooks Author-X-Name-First: Tara Author-X-Name-Last: Brooks Author-Name: Lloyd Scott Author-X-Name-First: Lloyd Author-X-Name-Last: Scott Author-Name: John P. Spillane Author-X-Name-First: John P. Author-X-Name-Last: Spillane Author-Name: Katy Hayward Author-X-Name-First: Katy Author-X-Name-Last: Hayward Title: Irish construction cross border trade and Brexit: Practitioner perceptions on the periphery of Europe Abstract: The United Kingdom (UK) Brexit vote of June 2016 has created unprecedented uncertainty in the construction industry in Ireland but little research to date has been undertaken on existing construction trading patterns and the potential effects of regulatory divergence and other non-tariff barriers in Ireland in this context. In response, this study uses mixed methods to fill this gap in knowledge. The experience of nine construction industry interviewees is probed – five based in Northern Ireland (in the UK) and four from Ireland, which will remain in the EU after the UK leaves. The researchers’ analysis of the qualitative data generated themes which were tested through investigation of the 101 eligible responses gathered through an online questionnaire. Our findings demonstrate that the construction trade in Ireland is highly mobile, currently trading extensively North – South and East – West. The physical barrier of the Irish Sea is less of a hindrance to trade than the regulatory barrier of the Irish border. Trade from peripheral areas is drawn to economic centres in Dublin and GB. In the view of the respondents, Brexit will impose further non-tariff barriers, although it is difficult to predict and plan for these barriers. Journal: Construction Management and Economics Pages: 71-90 Issue: 1 Volume: 38 Year: 2020 Month: 1 X-DOI: 10.1080/01446193.2019.1679382 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1679382 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:1:p:71-90 Template-Type: ReDIF-Article 1.0 Author-Name: Martine van den Boomen Author-X-Name-First: Martine Author-X-Name-Last: van den Boomen Author-Name: Matthijs T. J. Spaan Author-X-Name-First: Matthijs T. J. Author-X-Name-Last: Spaan Author-Name: Yue Shang Author-X-Name-First: Yue Author-X-Name-Last: Shang Author-Name: A. R. M. Wolfert Author-X-Name-First: A. R. M. Author-X-Name-Last: Wolfert Title: Infrastructure maintenance and replacement optimization under multiple uncertainties and managerial flexibility Abstract: Infrastructure maintenance and replacement decisions are subject to uncertainties such as regular asset degradation, structural failure, and price uncertainty. In the engineering domain, Markov Decision Processes (MDPs) typically focus on uncertainties regarding asset degradation and structural failure. While the literature in the engineering domain stresses the importance of addressing price uncertainties, it does not substantiate the observations of such uncertainties through optimization modeling. By contrast, real option analyses (ROAs) that originate from the financial domain address price uncertainties but generally disregard asset degradation and structural failure. Accordingly, this piece of current research brings both domains closer together and proposes an optimization approach that incorporates the flexibility to choose between multiple successive intervention strategies, regular asset degradation, structural failure and multiple price uncertainties. A practical result of the current research is a realistic approach to optimization modeling in which state space reduction is achieved by combining prices into portfolios. The current research obtains transition probabilities from existing price data. This approach is demonstrated using a case study of a water authority in the Netherlands and confirms the premise that price fluctuations may influence short-term maintenance and replacement decisions. Journal: Construction Management and Economics Pages: 91-107 Issue: 1 Volume: 38 Year: 2020 Month: 1 X-DOI: 10.1080/01446193.2019.1674450 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1674450 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:1:p:91-107 Template-Type: ReDIF-Article 1.0 Author-Name: M. Loosemore Author-X-Name-First: M. Author-X-Name-Last: Loosemore Author-Name: S. Reid Author-X-Name-First: S. Author-X-Name-Last: Reid Title: The social procurement practices of tier-one construction contractors in Australia Abstract: Social procurement is becoming an increasingly important requirement in the delivery of private- and public- sector construction projects across the world, yet there is relatively little research done in this area. Mobilising Furneaux and Barraket’s social procurement typology, semi-structured interviews were conducted with senior managers from eight tier-one contractors in the Australian construction industry to explore and classify the types of social procurement strategies used in projects, the types of social value created and the barriers to implementation. Documentary data were collected in the form of company policies and contract requirements. Results demonstrate the conceptual merit of Furneaux and Barraket’s typology in a construction industry context by highlighting different constraints on social value creation for each type of social procurement. These results also indicate that approaches to social procurement in the Australian construction industry are generally driven by a philosophy of risk mitigation rather than opportunity maximisation, and are confined to low-value and low-risk construction activities and are constrained by a lack of existing and new supply chain social-value creation capacity. Construction industry social value chains are fragile in Australia, and it is concluded that in building the sector’s significant untapped capacity to deliver social value to the communities in which it builds, priority should be given to three main strategies: third sector capacity building; barrier-to-entry reduction and skills development in managing new cross-sector collaborations among public, private and third sector organisations. Journal: Construction Management and Economics Pages: 183-200 Issue: 4 Volume: 37 Year: 2019 Month: 4 X-DOI: 10.1080/01446193.2018.1505048 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1505048 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:4:p:183-200 Template-Type: ReDIF-Article 1.0 Author-Name: Anne Toppinen Author-X-Name-First: Anne Author-X-Name-Last: Toppinen Author-Name: Miska Sauru Author-X-Name-First: Miska Author-X-Name-Last: Sauru Author-Name: Satu Pätäri Author-X-Name-First: Satu Author-X-Name-Last: Pätäri Author-Name: Katja Lähtinen Author-X-Name-First: Katja Author-X-Name-Last: Lähtinen Author-Name: Anni Tuppura Author-X-Name-First: Anni Author-X-Name-Last: Tuppura Title: Internal and external factors of competitiveness shaping the future of wooden multistory construction in Finland and Sweden Abstract: In transitioning to a renewable material-based bio economy, growing public and industry interest is apparent for using wooden multistory construction (WMC) as a sustainable urban housing solution in Europe, but its business implications are not well understood. In our study, we evaluate, which internal and external factors of competitiveness are shaping the future of WMC, especially in the context of Finland and Sweden. Based on a multi-level perspective of socio-technical transitions, we conducted a three-stage dissensus-based Delphi study. The identified internal and external factors affecting the future competitiveness of the WMC business emphasize the importance of skilled architects and builders and the role of standardized building systems. Based on our results, the key aspects influencing the future competitiveness of WMC in the region are related to the development of technical infrastructure and project-based business networks, while additional changes in regulatory framework are perceived as less important. We conclude that towards 2030, the strong cognitive rules founded in the concrete-based building culture in these countries is likely to inhibit the dynamics of the socio-technical regime level. A change is also needed in the WMC business culture towards more open cross-sectoral collaboration and new business networks between different-sized players. Journal: Construction Management and Economics Pages: 201-216 Issue: 4 Volume: 37 Year: 2019 Month: 4 X-DOI: 10.1080/01446193.2018.1513162 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1513162 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:4:p:201-216 Template-Type: ReDIF-Article 1.0 Author-Name: Alolote I. Amadi Author-X-Name-First: Alolote I. Author-X-Name-Last: Amadi Author-Name: Anthony Higham Author-X-Name-First: Anthony Author-X-Name-Last: Higham Title: Putting context to numbers: a geotechnical risk trajectory to cost overrun extremism Abstract: The study investigates the cause of the unusually high cost overruns experienced in highway project delivery in the tropical wetland setting of the Niger Delta region of Nigeria. An empirical profiling of cost overrun research reveals the predominance of mono-method studies, all of which are underlain by positivism. The study argues that such positivist philosophies, although methodologically valid, cannot adequately provide in-depth understanding of the contextual cost overrun drivers in highway organisations. Using a mix of methods, the paper examines the contribution of geotechnical risks to the extreme cost overruns experienced on Niger Delta’s highway projects, and demonstrates the relevance of context in cost overrun research. Adopting a geotechnical narrative, data sourced from 61 highway projects along with 16 interviews conducted with highway agencies in the region is analysed. The results of the analysis identified that poor project governance and procurement practices, have inhibited the competent management of geotechnical risk, creating a propensity for extreme cost overruns on highway projects. The study submits the phenomenon of cost overruns in public infrastructure projects is underlain by a complexity of contextual social constructs, which would have been overlooked in positivists studies. Cost overrun research, therefore, needs to be contextually and numerically anchored. Journal: Construction Management and Economics Pages: 217-237 Issue: 4 Volume: 37 Year: 2019 Month: 4 X-DOI: 10.1080/01446193.2018.1513656 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1513656 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:4:p:217-237 Template-Type: ReDIF-Article 1.0 Author-Name: Simon D. Smith Author-X-Name-First: Simon D. Author-X-Name-Last: Smith Title: Safety first? Production pressures and the implications on safety and health Abstract: The prominence of production, schedule, cost and economic wellbeing in government policy and review is explored and contrasted with the status of safety. The connection between productivity as an objective and safety as a constraint is reviewed, though it can be concluded that in spite of widespread belief of a connection there is very little empirical causal evidence for high production pressure causing negative effects on safety. Nevertheless, the inverse is mooted, that high levels of safety has had a negative impact on productivity in construction. This possibility is discussed in the context of government rhetoric which tends to be highly critical of construction’s economic shortcomings yet quite silent on the matter of its safety successes. The essay concludes with a possible vision for the future that allows safety and productivity to be re-positioned in terms of their potential symbiosis. Journal: Construction Management and Economics Pages: 238-242 Issue: 4 Volume: 37 Year: 2019 Month: 4 X-DOI: 10.1080/01446193.2018.1537501 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1537501 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:4:p:238-242 Template-Type: ReDIF-Article 1.0 Author-Name: Ian Stewart Author-X-Name-First: Ian Author-X-Name-Last: Stewart Author-Name: Peter Fenn Author-X-Name-First: Peter Author-X-Name-Last: Fenn Author-Name: Elika Aminian Author-X-Name-First: Elika Author-X-Name-Last: Aminian Title: Human research ethics – is construction management research concerned? Abstract: Construction Management Research (CMR) depends upon human beings participating in research, the quality of treatment of participants having direct effect on the quality of their participation, in turn that of the research itself, making treatment of humans and the ethical dilemmas that can ensue an important area of competence for CM (Construction Management) researchers. Does the growing field of CMR demonstrate appropriate concern for human research ethics? Evidence of typical CMR research is taken from the online Cooperative Network for Building Researchers (CNBR), particularly a search for “informed consent” collateral. It was found that there was little concern with human research ethics, which we argue is also evident in the lack of research on this matter in CMR-related literature, or any reference to these matters in the relevant professional and institutional bodies. Reasons as to why this might be are proposed. The consequences of the apparent level of concern are that participants can be exposed to “wrongs”, despite pressures for compliance from institutional ethics boards. However, the discipline of critically evaluating human research approach through a framework of ethical considerations is not only morally correct, at least according to the morality that is concerned for consequences to participants, but is also objectively useful to researchers, improving the reliability and validity of their research and lowering barriers to participation. Journal: Construction Management and Economics Pages: 665-675 Issue: 11-12 Volume: 35 Year: 2017 Month: 12 X-DOI: 10.1080/01446193.2017.1315151 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1315151 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:11-12:p:665-675 Template-Type: ReDIF-Article 1.0 Author-Name: Meghdad Attarzadeh Author-X-Name-First: Meghdad Author-X-Name-Last: Attarzadeh Author-Name: David K.H. Chua Author-X-Name-First: David K.H. Author-X-Name-Last: Chua Author-Name: Michael Beer Author-X-Name-First: Michael Author-X-Name-Last: Beer Author-Name: Ernest L.S. Abbott Author-X-Name-First: Ernest L.S. Author-X-Name-Last: Abbott Title: Options-based negotiation management of PPP–BOT infrastructure projects Abstract: The success of public–private partnership (PPP)–build–operate–transfer (BOT) projects largely depends on effectively mitigating the impact of a variety of risks and uncertainties, especially those influencing the revenue over time. Revenue instability is one of the main obstacles of PPP form of procurement. Government support, which is established as a clause in the concession agreement, should be carefully designed and well formulated. Options which arise from certain clauses in the contract are more valuable for risky projects. The purpose of this paper’s proposed model is to evaluate early fund generation options and also to calculate equitable bounds for a guaranteed revenue for the project sponsor under uncertainty and risk. The model is specially designed to alleviate the concern of revenue risk. To illustrate its applicability the methodology is then applied to a freeway PPP project and a power plant PPP project in Iran. The results show that the value of these options can indeed be significant and by applying the proposed systematic negotiation mechanism both public and private sectors can take advantage of its flexibility at the negotiation table. The proposed mechanisms can facilitate negotiations on the verge of a break down as well as accelerating ongoing negotiations that have become moribund. Journal: Construction Management and Economics Pages: 676-692 Issue: 11-12 Volume: 35 Year: 2017 Month: 12 X-DOI: 10.1080/01446193.2017.1325962 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1325962 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:11-12:p:676-692 Template-Type: ReDIF-Article 1.0 Author-Name: Xiancun Hu Author-X-Name-First: Xiancun Author-X-Name-Last: Hu Author-Name: Chunlu Liu Author-X-Name-First: Chunlu Author-X-Name-Last: Liu Title: Slacks-based data envelopment analysis for eco-efficiency assessment in the Australian construction industry Abstract: Eco-efficiency as an important indicator for sustainability assessment can describe an integrated manner of economic growth, resource conservation and environmental protection. However, the current research could not correctly assess eco-efficiency and mostly utilize qualitative methods. This paper presents a new method called slacks-based Data Envelopment Analysis (DEA) to assess eco-efficiency based on directly and systematically dealing with the slacks of reducing resource consumption and minimizing environmental impacts, together with adding production value. Two DEA models are respectively, defined using inter-temporal and window benchmark techniques, so as to compare eco-efficiency results in temporal and spatial dimensions and then identify production benchmarks and gaps. Efficiency change and technological change, which are two driving forces for eco-efficiency change, are also investigated through a production-theoretical decomposition analysis. Data from the Australian construction industry from 1990 to 2013 are employed to specify the two DEA models. The research results illustrate that the construction industries in the Australian regions showed significant increases in eco-efficiency during the research period, but the gaps among them were increased due to the severe underperformance of technological change. This research primarily provides a innovative pathway for accurate eco-efficiency assessment and quantitative identification of reducing resource consumption, minimizing environmental impacts and adding production value. The developed research framework is generic and can assist worldwide construction projects, organizations and industries to measure, compare and assess eco-efficiency systematically. Journal: Construction Management and Economics Pages: 693-706 Issue: 11-12 Volume: 35 Year: 2017 Month: 12 X-DOI: 10.1080/01446193.2017.1325963 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1325963 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:11-12:p:693-706 Template-Type: ReDIF-Article 1.0 Author-Name: Daniel Sage Author-X-Name-First: Daniel Author-X-Name-Last: Sage Title: Thinking with materialities in construction management: a response to Alexander Styhre Abstract: Alexander Styhre recently challenged Construction Management and Engineering (CME) scholarship to develop a stronger contribution to debates around materiality in mainstream management and organization studies. The rationale for his challenge is that CME scholars have a unique engagement with an important materiality – the built environment – that affords them a significant, yet largely unrealized, potential to inform wider debates about the materiality of social and organizational life. In my response here I do not disagree with Styhre’s overall argument. Instead I critically reflect, via a discussion of two themes implicit within his proposals – hiddenness and managerial power – on the rather unitary formulation of his argument. In so doing I do not so much seek to flag up challenges as to enliven his proposals by discussing the breadth of opportunities for contribution presented to CME academics in engaging with materialities with general management and organization scholarship. Journal: Construction Management and Economics Pages: 657-662 Issue: 11-12 Volume: 35 Year: 2017 Month: 12 X-DOI: 10.1080/01446193.2017.1348612 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1348612 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:11-12:p:657-662 Template-Type: ReDIF-Article 1.0 Author-Name: Michelle Turner Author-X-Name-First: Michelle Author-X-Name-Last: Turner Author-Name: Christina M. Scott-Young Author-X-Name-First: Christina M. Author-X-Name-Last: Scott-Young Author-Name: Sarah Holdsworth Author-X-Name-First: Sarah Author-X-Name-Last: Holdsworth Title: Promoting wellbeing at university: the role of resilience for students of the built environment Abstract: Resilience is positively linked to academic engagement and achievement, and contributes to students’ mental health and wellbeing. Research was undertaken to measure the resilience of students undertaking studies in the built environment, identify the factors which contribute to high or low levels of student resilience and explore the relationship between resilience and wellbeing. Survey data were collected from 410 undergraduate students from Melbourne, Australia. Results identified that of the six components of resilience, students scored highest on building networks, staying healthy, interacting cooperatively and living authentically, and lowest in maintaining perspective. Experience, university policy and the interaction between the university, work and home environments was found to contribute to student resilience. Results also identified that resilience is an antecedent of student wellbeing. A conceptual model of resilience and student wellbeing is presented which draws on the ecological systems model. Universities can actively support student wellbeing by fostering resilience. Resilience can be developed by embedding resilience-building strategies within course structures, learning activities and assessment tasks. Universities can implement policies and procedures and offer assets and resources which create a learning environment that supports resilience-building behaviour. Journal: Construction Management and Economics Pages: 707-718 Issue: 11-12 Volume: 35 Year: 2017 Month: 12 X-DOI: 10.1080/01446193.2017.1353698 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1353698 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:11-12:p:707-718 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Title: Thinking with Daniel Sage: some final remarks Journal: Construction Management and Economics Pages: 663-664 Issue: 11-12 Volume: 35 Year: 2017 Month: 12 X-DOI: 10.1080/01446193.2017.1371418 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1371418 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:11-12:p:663-664 Template-Type: ReDIF-Article 1.0 Author-Name: Andy Dainty Author-X-Name-First: Andy Author-X-Name-Last: Dainty Author-Name: Roine Leiringer Author-X-Name-First: Roine Author-X-Name-Last: Leiringer Title: Editorial Journal: Construction Management and Economics Pages: 655-656 Issue: 11-12 Volume: 35 Year: 2017 Month: 12 X-DOI: 10.1080/01446193.2017.1396718 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1396718 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:11-12:p:655-656 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Indexes for Volume 35 (2017) Journal: Construction Management and Economics Pages: 719-719 Issue: 11-12 Volume: 35 Year: 2017 Month: 12 X-DOI: 10.1080/01446193.2017.1400155 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1400155 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:11-12:p:719-719 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Indexes for Volume 35 (2017) Journal: Construction Management and Economics Pages: 720-724 Issue: 11-12 Volume: 35 Year: 2017 Month: 12 X-DOI: 10.1080/01446193.2017.1403092 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1403092 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:11-12:p:720-724 Template-Type: ReDIF-Article 1.0 Author-Name: Richard Fellows Author-X-Name-First: Richard Author-X-Name-Last: Fellows Author-Name: Anita M. M. Liu Author-X-Name-First: Anita M. M. Author-X-Name-Last: Liu Title: ‘What does this mean’? Sensemaking in the strategic action field of construction Abstract: Debate continues over the nature of the construction industry as a conglomeration, its boundaries (n.b., whether design is included), how it operates and with what objectives. Fragmentation remains a widely cited detriment to performance. However, the evolving development of field theory, notably, strategic action fields (SAF), provides a new and more embracing perspective that focuses on relationships and context that argues for mapping and analyses of network relationships between actors to provide a richer picture. The diversity of actors on any construction project, especially in increasingly ‘enterprise’ environments and the, consequent, operating processes accentuate atomism, individual goals and lack of integration. Thus, construction projects have very different meanings for each actor. The sensemaking perspective gives insights into how the actors, individually and collectively, interpret the myriad signals that they perceive to determine meaning and invoke action within their network of relationships in SAF. This study undertakes a critical review of theory and literature concerning sensemaking within networks of actors that constitute the SAF of construction to explore how those perspectives may be applied and the consequences for actors, processes and products. The underpinning concept is that those two perspectives – SAF and sensemaking – are vertically complimentary. It is found that, although little empirical study has been done in applying those bodies of theory to construction, the perspectives have considerable potential for application to enhance understanding of construction project processes and contexts, inter-relationships within and between the networks of participants, their actions and understandings – and, thereby, enhancement of performance in its broadest sense. Journal: Construction Management and Economics Pages: 578-596 Issue: 8-9 Volume: 35 Year: 2017 Month: 9 X-DOI: 10.1080/01446193.2016.1231409 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1231409 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:8-9:p:578-596 Template-Type: ReDIF-Article 1.0 Author-Name: Aaron Opdyke Author-X-Name-First: Aaron Author-X-Name-Last: Opdyke Author-Name: Florence Lepropre Author-X-Name-First: Florence Author-X-Name-Last: Lepropre Author-Name: Amy Javernick-Will Author-X-Name-First: Amy Author-X-Name-Last: Javernick-Will Author-Name: Matthew Koschmann Author-X-Name-First: Matthew Author-X-Name-Last: Koschmann Title: Inter-organizational resource coordination in post-disaster infrastructure recovery Abstract: Despite significant advances in strengthening post-disaster recovery efforts, misaligned strategy and inefficient resource allocation are far too often the norm for infrastructure reconstruction. To examine the inter-organizational networks that form to coordinate resources for infrastructure reconstruction, we employed social network analysis in 19 communities in the Philippines following Super Typhoon Haiyan, at 6 and 12 months post-disaster. To build these networks, we analysed interview, field observation and documentation data collected from non-governmental organizations, local governments and communities. A survey questionnaire was also administered to organizations working in selected communities to validate networks. Results from network analysis established that information was the most commonly shared resource by organizations, followed by financial, material and human resources. Government agencies had the highest actor centralities; however, qualitative data suggest that these roles were the result of obligatory consultations by international organizations and lacked legitimacy in practice. Findings further demonstrate that networks become more decentralized over time as actors leave and roles become more established, influenced by short-term expatriate contracts and the termination of United Nations supported cluster coordination. Findings could help organizations strengthen humanitarian response efforts by attending to resource allocation and knowledge sharing with other organizations. Journal: Construction Management and Economics Pages: 514-530 Issue: 8-9 Volume: 35 Year: 2017 Month: 9 X-DOI: 10.1080/01446193.2016.1247973 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1247973 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:8-9:p:514-530 Template-Type: ReDIF-Article 1.0 Author-Name: Cristina Poleacovschi Author-X-Name-First: Cristina Author-X-Name-Last: Poleacovschi Author-Name: Amy Javernick-Will Author-X-Name-First: Amy Author-X-Name-Last: Javernick-Will Author-Name: Tony Tong Author-X-Name-First: Tony Author-X-Name-Last: Tong Title: The link between knowledge sharing connections and employee time savings: A social network analysis Abstract: Social network research has shown that knowledge sharing connections facilitate access to valuable resources. However, little is known about which knowledge sharing connections save knowledge seekers the most time on their daily tasks. To address this gap, this research analyses knowledge sharing connections that provide time savings, measured as the time individuals saved on daily tasks as a result of receiving knowledge from other employees. The research evaluates time savings based on the strength of connection, the network distance between the seeker and provider and the provider’s centrality in the network. To conduct this study, the research team analysed a data-set of 10,849 knowledge sharing dyads reported through a survey administered in one department in a large construction and engineering organization. Data were analysed using social network analysis and multiple regression quadratic assignment procedure. Results showed that stronger connections were assessed as more beneficial for time savings, especially when the connections were with central actors who had higher closeness centrality scores. Knowledge seekers also had a higher assessment of time savings when they were closer (in terms of network distance) to the knowledge provider. These results show that knowledge network reach and strong knowledge connections are essential for achieving everyday work efficiency. Furthermore, the results add to theories of strong and weak connections by showing that strong ties are favourable for achieving time savings in the context of construction and engineering organizations. Journal: Construction Management and Economics Pages: 455-467 Issue: 8-9 Volume: 35 Year: 2017 Month: 9 X-DOI: 10.1080/01446193.2017.1287414 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1287414 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:8-9:p:455-467 Template-Type: ReDIF-Article 1.0 Author-Name: Robert G. Boutilier Author-X-Name-First: Robert G. Author-X-Name-Last: Boutilier Author-Name: Michal Zdziarski Author-X-Name-First: Michal Author-X-Name-Last: Zdziarski Title: Managing stakeholder networks for a social license to build Abstract: When construction projects are halted or slowed by conflicts with stakeholders, they have lost their social license. Social licenses are granted by stakeholder networks, which include community groups, among others. Project managers would benefit from approaches that can predict which groups or coalitions within the stakeholder network have sufficient influence and motivation to delay progress and that can suggest interventions to reduce that risk. We present an integration of theories and methods that has been successfully used in the extractive industries to maintain a high level of social license. We define the social license concept, noting its embeddedness in stakeholder theory and the resource dependence view of the firm, and how it has been elaborated enough to become measurable. Then we integrate it with social network analysis and methods for quantifying stakeholders’ issues and concerns. Key benefits are the ability to identify minority clusters that have sufficient influence to dominate the majority and the specification of network interventions to raise the level of social license. We use an example of a proposed housing project to illustrate how the proposed approach produces practical stakeholder relations strategies for gaining and maintaining a social license to build. Journal: Construction Management and Economics Pages: 498-513 Issue: 8-9 Volume: 35 Year: 2017 Month: 9 X-DOI: 10.1080/01446193.2017.1289229 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1289229 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:8-9:p:498-513 Template-Type: ReDIF-Article 1.0 Author-Name: Eleni Papadonikolaki Author-X-Name-First: Eleni Author-X-Name-Last: Papadonikolaki Author-Name: Alexander Verbraeck Author-X-Name-First: Alexander Author-X-Name-Last: Verbraeck Author-Name: Hans Wamelink Author-X-Name-First: Hans Author-X-Name-Last: Wamelink Title: Formal and informal relations within BIM-enabled supply chain partnerships Abstract: Supply chain management (SCM) and building information modelling (BIM) are innovations that focus on integration. Recent literature suggests performance benefits from combining these innovations. Within supply chain (SC) partnerships, that use BIM – hereinafter called BIM-enabled SC partnerships – various formal and informal dimensions influence the inter-organizational relations. To understand such partnerships, a mixed method approach featuring case studies and social networks analysis (SNA) was deployed. SNA was an analytic approach to explore the complex relations within two Dutch BIM-enabled projects. The inter-organizational relations were asymmetrical and formal in Case A, emphasizing transactions, whereas in Case B, they were asymmetrical and informal, emphasizing relations. The transactional-oriented partnership had greater control over contractual issues, but their formal relations were not sufficient for diffusing BIM-related knowledge across the chain. Conversely, the relational-oriented partnership engaged the partners in BIM by informal means, e.g. dense communication and BIM-related peer-learning across all tiers. Symmetric and jointly fostered formal and informal relations contribute to SC integration. The study extends the knowledge base of SCM and BIM, by offering real-world data on their combination. Besides providing new insights into SNA deployment for BIM-related research, it also offers a novel constructivist and inter-organizational perspective on the old concept of SCM. Journal: Construction Management and Economics Pages: 531-552 Issue: 8-9 Volume: 35 Year: 2017 Month: 9 X-DOI: 10.1080/01446193.2017.1311020 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1311020 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:8-9:p:531-552 Template-Type: ReDIF-Article 1.0 Author-Name: Alberto De Biasio Author-X-Name-First: Alberto Author-X-Name-Last: De Biasio Author-Name: Alex Murray Author-X-Name-First: Alex Author-X-Name-Last: Murray Title: The social network of the UK PPP secondary equity market – returns and competition in an emerging market Abstract: In recent years, the UK’s private finance initiative secondary equity market has increased in size and maturity as primary investors, principally contractors, liquidate their stakes. As an emerging unlisted market, research challenges include the availability of timely and comprehensive information about equity transactions, as well as established methods for their interpretation and comparison. Data on transactions between 1998 and 2012, collected in the European Services Strategy Unit PPP equity database, are used to map this market and analysed using network theory. Active sellers and buyers are identified providing insight on the levels of competition. Following Granovetter’s conceptualization of SNA, actors operating in the secondary equity market (buyers and sellers of SPV equity – contractors, equity funds, banks, institutional investors amongst others) are characterized in terms of out-degree centrality, increasing with the number of actors within a seller’s ego network. The ties created through equity sales are applied in the formation of the market network. The notion that out-degree centrality of sellers can improve overall financial returns is examined with data on initial equity investment and sale values. Isolating returns on equity based on capital appreciation for a sample of transactions reveals that annualized return on equity is seemingly not improved by higher out-degree centrality, when compared to average returns. A more general contribution is provided through the visualization of the network of equity transactions in this emerging market. Journal: Construction Management and Economics Pages: 468-481 Issue: 8-9 Volume: 35 Year: 2017 Month: 9 X-DOI: 10.1080/01446193.2017.1324998 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1324998 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:8-9:p:468-481 Template-Type: ReDIF-Article 1.0 Author-Name: Calvin Keung Author-X-Name-First: Calvin Author-X-Name-Last: Keung Author-Name: Liyin Shen Author-X-Name-First: Liyin Author-X-Name-Last: Shen Title: Network strategy for contractors’ business competitiveness Abstract: Establishing a cooperative network has emerged as a strategy for contractors to improve their business competitiveness, which can affect a construction business and sustain its future growth opportunities. A survey was conducted in Hong Kong to test the relationships between contractors’ network performance and successful business competitiveness based on the project networks they build. A network strategy was developed by examining the relationships between the network techniques and the network outcomes. The network techniques support contractors’ network, whereas the network outcomes contribute to competitiveness attributes. The findings demonstrate that the key network techniques of supporting information exchange and organizing project communication are highly significant predictors of the business competitiveness attributes (BCA). The network technique of creating learning capacity is positively associated with contractors’ bidding performance and competitive strategies. Interestingly, the techniques of sharing knowledge and promoting networking culture insignificantly contribute to a number of the BCA. The developed network strategy reveals that the key network techniques significantly support contractors’ network performance and that the consequent network outcomes give rise to the BCA, which in turn stimulate contractors’ business competitiveness. Several practical suggestions are offered for contractors to improve their business competitiveness through interfirm cooperation between project network members. Journal: Construction Management and Economics Pages: 482-497 Issue: 8-9 Volume: 35 Year: 2017 Month: 9 X-DOI: 10.1080/01446193.2017.1329539 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1329539 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:8-9:p:482-497 Template-Type: ReDIF-Article 1.0 Author-Name: Kerry London Author-X-Name-First: Kerry Author-X-Name-Last: London Author-Name: Zelinna Pablo Author-X-Name-First: Zelinna Author-X-Name-Last: Pablo Title: An actor–network theory approach to developing an expanded conceptualization of collaboration in industrialized building housing construction Abstract: Our aim is to examine the value of selected actor–network theory (ANT) elements in contributing to the development of an expanded theoretical and empirical conceptualization of collaboration in industrialized building construction for the housing sector. A review of collaboration meta-analyses literature from different disciplines suggests that collaboration is still commonly portrayed in a limited way as a strategy of integration driven in a top-down manner by a “convenor” of human stakeholders in ways that privilege simplified notions of coherence. We use specific ANT concepts empirically grounded in five case studies of innovative housing construction projects to describe an expanded conceptualization of the infrastructure of actor-networks. We examined a range of issues with respect to collaboration in industrialized building particularly in relation to network formation and disintegration. As the collaboration networks formed they sought coherence but not conformity and aimed for the management of tensions between integration and separation as well as stabilization and destabilization. This expanded conceptualization of collaboration describes the material-semiotic characteristics arranged around industrialized building technologies that are simultaneously stabilizing yet disruptive and proposes new ways by which the ideal of integration can be pursued in a fundamentally fragmented industry. Journal: Construction Management and Economics Pages: 553-577 Issue: 8-9 Volume: 35 Year: 2017 Month: 9 X-DOI: 10.1080/01446193.2017.1339361 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1339361 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:8-9:p:553-577 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Pryke Author-X-Name-First: Stephen Author-X-Name-Last: Pryke Author-Name: Sulafa Badi Author-X-Name-First: Sulafa Author-X-Name-Last: Badi Author-Name: Lena Bygballe Author-X-Name-First: Lena Author-X-Name-Last: Bygballe Title: Editorial for the special issue on social networks in construction Journal: Construction Management and Economics Pages: 445-454 Issue: 8-9 Volume: 35 Year: 2017 Month: 9 X-DOI: 10.1080/01446193.2017.1341052 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1341052 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:8-9:p:445-454 Template-Type: ReDIF-Article 1.0 Author-Name: Christopher Nigel Preece Author-X-Name-First: Christopher Nigel Author-X-Name-Last: Preece Author-Name: Che Maznah Mat Isa Author-X-Name-First: Che Maznah Author-X-Name-Last: Mat Isa Author-Name: Hamidah Mohd Saman Author-X-Name-First: Hamidah Mohd Author-X-Name-Last: Saman Author-Name: Che Khairil Che Ibrahim Author-X-Name-First: Che Khairil Author-X-Name-Last: Che Ibrahim Title: Development of entry location, entry timing and entry mode decision model for construction firms in international markets Abstract: The international market expansion process involves a combination of many strategic entry decisions. Most previous studies have dealt with entry location, entry timing and entry mode (ELETEM) decisions in an isolated way by considering one dimension or a combination of dimensions in particular. Although there have been various models relating to international market entry decisions, there is currently no model that attempts to integrate the factors linking the ELETEM decisions for construction firms. The purpose is to determine a linkage between the ELETEM decisions by incorporating the factors that are mutually inclusive and have significant influence on these decisions. Forty-five (45) Malaysian contractors undertaking projects in international markets responded to the survey. The findings suggested that the mutually inclusive and significant factors (MISFs) influencing the ELETEM decisions were: the firm’s ability to assess market signals and opportunities, the firm’s resources and the firm’s experience in similar works. It was observed that the firms had adopted long-term strategies, repositioned their knowledge from research and development activities and readapted their resources and experience in their global operations. The findings led to the development of the ELETEM decision model to guide interested firms in making better decisions for their future international ventures. Journal: Construction Management and Economics Pages: 236-257 Issue: 4-5 Volume: 34 Year: 2016 Month: 5 X-DOI: 10.1080/01446193.2015.1084429 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1084429 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:4-5:p:236-257 Template-Type: ReDIF-Article 1.0 Author-Name: Kevin M. Swarts Author-X-Name-First: Kevin M. Author-X-Name-Last: Swarts Author-Name: Kim Lehman Author-X-Name-First: Kim Author-X-Name-Last: Lehman Author-Name: Gemma K. Lewis Author-X-Name-First: Gemma K. Author-X-Name-Last: Lewis Title: The use of social customer relationship management by building contractors: evidence from Tasmania Abstract: Despite its ever-increasing popularity with consumers and businesses, many organizations are still unsure how to effectively use social media in a marketing context. One way in which building firms can use social media is as a customer relationship management (CRM) tool to improve customer engagement and satisfaction (known as social CRM). In order to explore how social CRM (SCRM) can be used, and is being used by building firms, semi-structured interviews with accredited building practitioners were utilized to collect data on SCRM use in the sector. The data were analysed to determine the factors that influence social media use, the extent of SCRM use, and the ways in which building contractors are using SCRM. It was found that builders are using social media to manage client relationships, but to a limited extent due to the complex nature of the builder–client relationship and a lack of perceived trustworthiness. Building firms favoured a transactional approach to social media use, and preferred not to use formal social media strategies. Builders are also reluctant to use social media to assist them in segmenting customers by their value to the firm. For effective social media use, builders may consider two main issues: SCRM strategy and customer-value segmentation to develop profitable customer relationships. Journal: Construction Management and Economics Pages: 302-316 Issue: 4-5 Volume: 34 Year: 2016 Month: 5 X-DOI: 10.1080/01446193.2015.1133919 File-URL: http://hdl.handle.net/10.1080/01446193.2015.1133919 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:4-5:p:302-316 Template-Type: ReDIF-Article 1.0 Author-Name: Magnus Hellström Author-X-Name-First: Magnus Author-X-Name-Last: Hellström Author-Name: Robin Wikström Author-X-Name-First: Robin Author-X-Name-Last: Wikström Author-Name: Magnus Gustafsson Author-X-Name-First: Magnus Author-X-Name-Last: Gustafsson Author-Name: Hanna Luotola Author-X-Name-First: Hanna Author-X-Name-Last: Luotola Title: The value of project execution services: a problem and uncertainty perspective Abstract: Like services in general project execution services ought to be marketed and sold based on the value they add rather than the cost they accrue. Project services are typically complex and abstract, and hence their benefits are difficult to directly explicate. The aim is to investigate how contractors and suppliers can overcome this dilemma and exercise value-based selling in terms of the typical services they provide. A design science inspired study was used to create a service configurator addressing the dilemma. At the same time the configurator provided a means for studying the value identification and communication process in six sales projects. It is concluded that contractors and suppliers ought to approach customer value by looking for problems that create uncertainty in the underlying investment and to match them with suitable services. Key in communicating the value of the services is to focus on creating certainty as to the parties’ ability to cope with the uncertainty in the investment with the help of these services. Journal: Construction Management and Economics Pages: 272-285 Issue: 4-5 Volume: 34 Year: 2016 Month: 5 X-DOI: 10.1080/01446193.2016.1151062 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1151062 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:4-5:p:272-285 Template-Type: ReDIF-Article 1.0 Author-Name: Niamh Murtagh Author-X-Name-First: Niamh Author-X-Name-Last: Murtagh Author-Name: Aeli Roberts Author-X-Name-First: Aeli Author-X-Name-Last: Roberts Author-Name: Richard Hind Author-X-Name-First: Richard Author-X-Name-Last: Hind Title: The role of environmental sustainability in marketing of small architectural design practices Abstract: Environmental sustainability in construction is a pressing concern. Despite their importance to the industry, and evident differences from large organizations in business strategy, markets and challenges, the literature has little to say about how small architectural design firms view the marketing potential of improved environmental sustainability. The aim is to address this gap by examining practitioner experience of sustainability and marketing in small architectural design practices. Semi-structured interviews were conducted with 16 such practices. A critical interpretive stance was adopted in analysis, drawing on the theoretical framings of service-dominant logic (SDL) and relationship marketing. Sustainable design is part of the co-creation of value in architecture, enhancing the value proposition beyond a cost basis. Its inclusion contributed to business development through referrals. Taken together, co-creation of value and asymmetry of knowledge between professional and client drive the conclusion that the architectural designer has primary responsibility in guiding clients towards greater environmental sustainability. This responsibility and the role of sustainability in business development were not necessarily recognized by the designers. Insights from SDL challenge assumptions that cost and lack of client demand prevent greater sustainability in design. Journal: Construction Management and Economics Pages: 258-271 Issue: 4-5 Volume: 34 Year: 2016 Month: 5 X-DOI: 10.1080/01446193.2016.1151063 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1151063 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:4-5:p:258-271 Template-Type: ReDIF-Article 1.0 Author-Name: Grant R.W. Mills Author-X-Name-First: Grant R.W. Author-X-Name-Last: Mills Author-Name: Kamran Razmdoost Author-X-Name-First: Kamran Author-X-Name-Last: Razmdoost Title: Managing value co-creation/destruction: a longitudinal education capital programme/project case study Abstract: Drawing on a longitudinal empirical study of an education capital programme/project, value interactions are investigated at the interface between programme customers, project stakeholders and construction providers. Empirical evidence is provided that value formation is not only associated with value co-creation, but also with value co-destruction. The case study showed that a mature and synergistic network relationship (that successfully aligned the expectations of a strong key account management team (KAM team), multi-headed customer and wider project stakeholders) could, if not well managed, turn into incongruent relationships, relationship uncoupling and resource withdrawal. These findings suggest that project managers must drive strong KAM team relationships, so that they can align and adapt to customer requirements, and control the response to often changing wider stakeholder expectations. Journal: Construction Management and Economics Pages: 286-301 Issue: 4-5 Volume: 34 Year: 2016 Month: 5 X-DOI: 10.1080/01446193.2016.1187284 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1187284 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:4-5:p:286-301 Template-Type: ReDIF-Article 1.0 Author-Name: Florence Yean Yng Ling Author-X-Name-First: Florence Yean Yng Author-X-Name-Last: Ling Author-Name: Shan Li Author-X-Name-First: Shan Author-X-Name-Last: Li Title: Business models for foreign firms offering construction-related consultancy services in China Abstract: Many foreign firms are expected to enter China’s growing construction market. The objectives are to: (i) identify the extent to which Porter’s generic business strategies and practices are adopted by local Chinese architectural, engineering and construction firms (Chinese firms) and foreign firms offering construction-related consultancy services in China (foreign firms); (ii) investigate the extent to which Porter’s generic strategies contribute to firms’ competitiveness in China; and (iii) propose a business model framework for construction services in China. Using a structured questionnaire, data were collected via mail and face-to-face interviews. In total, 37 and 45 completed questionnaires were received from foreign and Chinese firms, respectively. Both foreign and Chinese firms adopt Porter’s differentiation and focus strategies to a significant extent. Foreign firms emphasize value offerings that incorporate superior design, technology and quality significantly more than Chinese firms. The findings show that Porter’s cost leadership and differentiation strategies are significantly correlated with firms’ competitiveness, especially the practices relating to cutting suppliers’ prices, reconfiguring the value chain, providing innovative services and offering comprehensive services. To help them succeed in China, it is recommended that foreign firms develop their business models based on the framework developed here. Journal: Construction Management and Economics Pages: 218-235 Issue: 4-5 Volume: 34 Year: 2016 Month: 5 X-DOI: 10.1080/01446193.2016.1189585 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1189585 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:4-5:p:218-235 Template-Type: ReDIF-Article 1.0 Author-Name: Hedley Smyth Author-X-Name-First: Hedley Author-X-Name-Last: Smyth Author-Name: Richard Fellows Author-X-Name-First: Richard Author-X-Name-Last: Fellows Author-Name: Anita Liu Author-X-Name-First: Anita Author-X-Name-Last: Liu Author-Name: Wilco Tijhuis Author-X-Name-First: Wilco Author-X-Name-Last: Tijhuis Title: Editorial for the Special Issue on Business Development and Marketing in Construction Journal: Construction Management and Economics Pages: 205-217 Issue: 4-5 Volume: 34 Year: 2016 Month: 5 X-DOI: 10.1080/01446193.2016.1199370 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1199370 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:4-5:p:205-217 Template-Type: ReDIF-Article 1.0 Author-Name: Kamran Razmdoost Author-X-Name-First: Kamran Author-X-Name-Last: Razmdoost Author-Name: Grant Mills Author-X-Name-First: Grant Author-X-Name-Last: Mills Title: Towards a service-led relationship in project-based firms Abstract: Project-based firms increasingly apply practices that are in line with relationship marketing (RM), which is a shift from individuality to mutuality, and service-dominant logic (SDL), which is a shift from a focus on goods exchange to an emphasis on service exchange. These firms also adopt value co-creation processes, benefiting from both RM and SDL views. However, their overall transition towards RM, SDL and/or both is not clearly understood. Therefore, the research aim is to explain how and why project-based firms have moved away from transitional marketing. A retrospective action research between 2002 and 2009 provides process data on how a single main contractor adapted their marketing approach over five publicly funded projects within the oil, gas and petrochemical industries. The findings show that the uniqueness and dynamics of projects necessitate the adoption of both SDL and RM, a view that is entitled the service-led relationship here. This transition occurs through services expansion, multi-level distributed interactions and process-oriented performance management in projects. The firm enabled the transition through the evolution of both institutional mechanisms such as contracts and organizational structure, and people attributes such as capabilities and culture. Journal: Construction Management and Economics Pages: 317-334 Issue: 4-5 Volume: 34 Year: 2016 Month: 5 X-DOI: 10.1080/01446193.2016.1200106 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1200106 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:4-5:p:317-334 Template-Type: ReDIF-Article 1.0 Author-Name: F.K.T. Cheung Author-X-Name-First: F.K.T. Author-X-Name-Last: Cheung Author-Name: E. Kurul Author-X-Name-First: E. Author-X-Name-Last: Kurul Author-Name: A.H. Oti Author-X-Name-First: A.H. Author-X-Name-Last: Oti Title: A case study of hybrid strategies to create value for a contracting business in the education sector in England and Wales Abstract: Successful hybrid strategies adopt service marketing principles although the adoption of those principles by construction marketers is not apparent. Through an interpretive inquiry approach attempting to capture multiple views in a case of successful strategic programmes for the primary school market, various value co-creation elements of the programmes are assessed according to four axioms of service-dominant (S-D) logic. The strategic programmes were found to create value by (1) developing new skills and knowledge, building relationships to leverage skills and close the knowledge gaps; (2) enhancing interactions through customer engagement, dialogue creation and enrichment, the use of BIM technologies and social networks; (3) strengthening many-to-many relationships through supply chain integration; and (4) assisting individual customers to define their value propositions and to evaluate them through free self-service systems, and products and services inquiries. Further research is needed to assess how customers value the various co-creation elements identified in the paperevidence for applying the generic value co-creation principles to marketing in construction. Journal: Construction Management and Economics Pages: 335-352 Issue: 4-5 Volume: 34 Year: 2016 Month: 5 X-DOI: 10.1080/01446193.2016.1200107 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1200107 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:4-5:p:335-352 Template-Type: ReDIF-Article 1.0 Author-Name: Siobhan Morrison Author-X-Name-First: Siobhan Author-X-Name-Last: Morrison Author-Name: Ian Trushell Author-X-Name-First: Ian Author-X-Name-Last: Trushell Title: Payment for offsite goods and materials: the Scottish perspective Abstract: Materials are a critical element within the construction industry yet- the conditions and legality surrounding their ownership remains an area of uncertainty. The difficulty in ascertaining ownership is often found in the instances of payment, delivery and complex contractual relationships. Additionally, the nature of the construction industry whereby raw materials are purchased within a supply chain and are incorporated into the fabric of buildings or goods often creates further confusion. The importance of ownership is most apparent in the instance of disputes or insolvencies, both of which are regular occurrences within the construction industry and in the management of a project regarding cash flow and programme. To inform the position and stance of Scots Law in relation to ownership of materials it is necessary to evaluate current law regarding ownership of materials in Scotland through the undertaking of a literature review which establishes the prevailing legal structure. Conclusions and recommendations propose that parties of a construction contract, for which Scots Law is applicable, are aware of current law surrounding the intricate matter regarding ownership of materials in Scots Law Journal: Construction Management and Economics Pages: 679-687 Issue: 10 Volume: 34 Year: 2016 Month: 10 X-DOI: 10.1080/01446193.2016.1200738 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1200738 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:10:p:679-687 Template-Type: ReDIF-Article 1.0 Author-Name: Liisa Naar Author-X-Name-First: Liisa Author-X-Name-Last: Naar Author-Name: Natalia Nikolova Author-X-Name-First: Natalia Author-X-Name-Last: Nikolova Author-Name: Perry Forsythe Author-X-Name-First: Perry Author-X-Name-Last: Forsythe Title: Innovative construction and the role of boundary objects: a Gehry case study Abstract: Physical objects have long been used in addressing the challenges involved in constructing innovative buildings, yet their significance for collaborative problem solving in inter-organizational projects is rarely acknowledged. The aim of this research is to investigate what happens when a project team has to collaboratively innovate to address radical design challenges in a construction setting. We focus on the role of a full-scale mock-up of a façade in transforming the design intent for a building by Frank Gehry into design realization. The concept of boundary objects is used as an analytical lens via a case study methodology utilizing non-participant observation of weekly meetings and workshops over a period of 10 months covering client, consultant and contractor involvement. The research shows the role of mock-ups in radical construction settings is in tension along three delivery dimensions: performance, aesthetic and technical construction. Task completion competed with the requirements for experimentation around innovative problem solving with the how to construct it problem left unresolved. The findings suggest that co-location and synchronicity are critical conditions for collaborative and innovative problem solving in radical construction contexts. Project teams need to create open-ended ‘moments’ for iterating critical objects and the interactions that take place around them. Journal: Construction Management and Economics Pages: 688-699 Issue: 10 Volume: 34 Year: 2016 Month: 10 X-DOI: 10.1080/01446193.2016.1201206 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1201206 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:10:p:688-699 Template-Type: ReDIF-Article 1.0 Author-Name: Keith Cattell Author-X-Name-First: Keith Author-X-Name-Last: Cattell Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Author-Name: Peter Edwards Author-X-Name-First: Peter Author-X-Name-Last: Edwards Title: Stress among South African construction professionals: a job demand-control-support survey Abstract: Research into workplace stress in the construction industry has been dominated by studies undertaken in Hong Kong, England and Australia, with relatively little attention having been paid to African countries. A purposively selected sample of thirty-six construction professionals (comprising architects, project managers, construction managers, engineers and quantity surveyors) based in Cape Town, South Africa, were surveyed regarding their perceptions about, and experiences of, workplace stress. The purpose was to identify and rank job demand, job control and job support factors and to analyse these by gender and professional grouping, both in terms of how respondents perceived them, as well as in terms of how frequently they had experienced them. The main finding was that respondents’ perceptions about the importance of job demand, job control and job support factors were largely consistent with their own experience of these factors. Distinguishing between perceptions and experience of stressors and moderators of stress was, however, considered valuable because the fact that differences were found indicates the need for precision in the design of scales. The highest ranked factors were, respectively, ‘critical time constraints’, ‘volume of work’ and ‘adequate compensation (salary)’. Women and men ranked items differently, as did the various professional groups. The main conclusions were that the construction project environment is a time-pressured, complex, environment in which work-life balance is negatively affected, particularly for women. Control over the type, flow and volume of work were perceived to be the main moderators of stress, whilst salary and career path opportunities were perceived to be the main job support moderators of stress. The applicability of using the job demand–control–support framework was confirmed given that the main stressors, control and support moderators were found to be to be largely consistent with the findings of previous studies. Future research taking a gendered approach should anticipate issues important to female respondents and should consider the benefits of qualitative methods. The design of research focusing on construction professionals should consider using the project team as the unit of analysis to ensure that the influence of the interconnectedness of participants’ roles is taken into account. Journal: Construction Management and Economics Pages: 700-723 Issue: 10 Volume: 34 Year: 2016 Month: 10 X-DOI: 10.1080/01446193.2016.1203967 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1203967 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:10:p:700-723 Template-Type: ReDIF-Article 1.0 Author-Name: Ahmed Abdelaty Author-X-Name-First: Ahmed Author-X-Name-Last: Abdelaty Author-Name: Hyungseok David Jeong Author-X-Name-First: Hyungseok David Author-X-Name-Last: Jeong Author-Name: Bryan Dannen Author-X-Name-First: Bryan Author-X-Name-Last: Dannen Author-Name: Francis Todey Author-X-Name-First: Francis Author-X-Name-Last: Todey Title: Enhancing life cycle cost analysis with a novel cost classification framework for pavement rehabilitation projects Abstract: Life cycle cost analysis (LCCA) procedures have been used over the past decades to justify the choice of one pavement design alternative over the others. However, many ambiguities associated with the life cycle cost input values, such as the discount rate and future cost estimates have questioned the credibility of the analysis results. Another unrecognized source of errors in pavement LCCA is the misunderstanding of pavement treatment costs when historical costs are typically used for estimating those costs. The historical costs of pavement rehabilitation projects typically include a significant amount of non-pavement-related costs, which may result in a wrong LCCA if not treated appropriately. This paper addresses this specific point of error and proposes a solution to eliminating this error by using a novel cost classification framework that successfully differentiates mainline roadway costs from non-pavement cost items. A case study using Monte Carlo simulation is conducted to evaluate the probabilistic LCCA results. The results of the case study indicate that the conventional approach of using total rehabilitation project costs in LCCA may even lead to a wrong investment decision. The findings of this study will help practitioners and researchers better understand the nature of pavement rehabilitation project cost distributions. Journal: Construction Management and Economics Pages: 724-736 Issue: 10 Volume: 34 Year: 2016 Month: 10 X-DOI: 10.1080/01446193.2016.1205206 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1205206 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:10:p:724-736 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Editorial Journal: Construction Management and Economics Pages: 677-678 Issue: 10 Volume: 34 Year: 2016 Month: 10 X-DOI: 10.1080/01446193.2016.1208352 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1208352 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:10:p:677-678 Template-Type: ReDIF-Article 1.0 Author-Name: Benjamin Lasshof Author-X-Name-First: Benjamin Author-X-Name-Last: Lasshof Author-Name: Christian Stoy Author-X-Name-First: Christian Author-X-Name-Last: Stoy Title: Estimation models for heating energy and electricity costs Abstract: Heating energy and electricity represent a significant proportion of the overall financial expenditures over the life cycle of buildings and play a decisive role in the assessment of ecological quality. To ensure ecological and economical sustainability, the planning and construction of energy efficient buildings have become increasingly important. The present study introduces statistical models for the estimation of energy costs during the planning process as well as for the purpose of monitoring and controlling costs during operation including a wide range of facility types. Based on a data sample of 206 occupied facilities located in Germany, regression models are presented in detail including significant predictor variables. The provision of correctly specified models as well as a consistent and unbiased estimation beyond the employed data is verified by validation tests. The practical significance of the determined variables is presented by the calculation of various scenarios. The best estimation accuracy is indicated for regression models with transformed response and predictor variables achieving mean absolute percentage errors of 20.5% (heating energy) and 20.7% (electricity), respectively. An extension of the data sample, a consideration of further facility types, and an implementation of additional statistical methods may be considered by future approaches to improve the estimation accuracy. Journal: Construction Management and Economics Pages: 622-640 Issue: 9 Volume: 34 Year: 2016 Month: 9 X-DOI: 10.1080/01446193.2016.1190025 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1190025 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:9:p:622-640 Template-Type: ReDIF-Article 1.0 Author-Name: Keith Townsend Author-X-Name-First: Keith Author-X-Name-Last: Townsend Author-Name: Rebecca Loudoun Author-X-Name-First: Rebecca Author-X-Name-Last: Loudoun Author-Name: Katherine Markwell Author-X-Name-First: Katherine Author-X-Name-Last: Markwell Title: The role of line managers in creating and maintaining healthy work environments on project construction sites Abstract: The focus of this article is healthy work environments in project-based construction work, and particularly a sub-element of the work environment, the food environment. Although it is well accepted that stressful work environments negatively impact on organisational and individual health indices and project construction produces some of the most severe work environments in the modern industrial landscape, the role of line managers in creating these environments is largely unknown. Healthy work environments are explored in this article because they contribute to the development of many ‘behavioral’ diseases such as Type 2 diabetes and cardiovascular disease, both of which are known problems amongst construction workers. Qualitative data were collected from eighty project-based construction workers and mangers on six large civil engineering construction projects in Brisbane, Australia. Unanimous views were expressed by all interviewees that managers should not and do not influence food choices on-site. However, results also revealed clear examples of managers making decisions about food environments, work and time pressures and permitted and discouraged behaviours on-site that impact on food choices. These findings indicate limited awareness of healthy work environments in construction with the impact of management actions being largely unrecognised and unintended. It suggests with more informed management decision-making, eating habits in construction are likely to improve. Journal: Construction Management and Economics Pages: 611-621 Issue: 9 Volume: 34 Year: 2016 Month: 9 X-DOI: 10.1080/01446193.2016.1195911 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1195911 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:9:p:611-621 Template-Type: ReDIF-Article 1.0 Author-Name: Fiona C. Saunders Author-X-Name-First: Fiona C. Author-X-Name-Last: Saunders Author-Name: Andrew H. Sherry Author-X-Name-First: Andrew H. Author-X-Name-Last: Sherry Author-Name: Andrew W. Gale Author-X-Name-First: Andrew W. Author-X-Name-Last: Gale Title: Dualities and dilemmas: contending with uncertainty in large-scale safety-critical projects Abstract: Uncertainty is a fact of project life. Most decisions that are made on a safety-critical project involve uncertainty, the consequences of which may be highly significant to the safe and timely delivery of the project. Based on interviews with project management practitioners on nine large-scale civil nuclear and aerospace projects, we explore how uncertainty emerges, and how project management practitioners identify, analyse and act on it. We make three important contributions. First, we present three approaches – structural, behavioural and relational – that individuals and organizations can adopt when contending with project uncertainty. Secondly, we characterize nine dualities at play in the management of project uncertainty and thirdly, we identify key differences between how civil nuclear and aerospace project managers confront project uncertainty, which have important implications for how projects might be organized in both these industry sectors. Drawing attention to the structural, behavioural and relational approaches to project uncertainty and the tensions that manifest themselves in each approach should enable the project management community to make progress in environments of high uncertainty where situations are often complex, rapidly changing and confusing, and yet where, for reasons of safety, failure is not an option. Journal: Construction Management and Economics Pages: 657-675 Issue: 9 Volume: 34 Year: 2016 Month: 9 X-DOI: 10.1080/01446193.2016.1196824 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1196824 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:9:p:657-675 Template-Type: ReDIF-Article 1.0 Author-Name: Rafael Sacks Author-X-Name-First: Rafael Author-X-Name-Last: Sacks Title: What constitutes good production flow in construction? Abstract: The notion of production flow is not well understood in the context of construction. A coherent, consistent theoretical model of flow would have practical value as it would support development of better approaches to managing production within and across projects and of measures of flow quality needed to implement them. A literature review and analysis of existing conceptualizations of flow in manufacturing and in construction lead to formulation of a model of construction flow that has three interrelated but distinct axes: project portfolio, process and operations flows. A tentative set of ideal conditions for good flow was formulated with regard to each of these three primary flows. The review, the summary model and the set of conditions provide a basis for further research and development of a comprehensive model of flow in construction and a definition of what constitutes good flow. Journal: Construction Management and Economics Pages: 641-656 Issue: 9 Volume: 34 Year: 2016 Month: 9 X-DOI: 10.1080/01446193.2016.1200733 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1200733 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:9:p:641-656 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Statement of Retraction Journal: Construction Management and Economics Pages: 676-676 Issue: 9 Volume: 34 Year: 2016 Month: 9 X-DOI: 10.1080/01446193.2016.1202485 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1202485 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:9:p:676-676 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Editorial Journal: Construction Management and Economics Pages: 609-610 Issue: 9 Volume: 34 Year: 2016 Month: 9 X-DOI: 10.1080/01446193.2016.1204802 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1204802 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:9:p:609-610 Template-Type: ReDIF-Article 1.0 Author-Name: Carlos Andrés Zapata Quimbayo Author-X-Name-First: Carlos Andrés Author-X-Name-Last: Zapata Quimbayo Author-Name: Carlos Armando Mejía Vega Author-X-Name-First: Carlos Armando Author-X-Name-Last: Mejía Vega Author-Name: Naielly Lopes Marques Author-X-Name-First: Naielly Lopes Author-X-Name-Last: Marques Title: Minimum revenue guarantees valuation in PPP projects under a mean reverting process Abstract: Minimum revenue guarantees, where the government assumes a portion of the traffic risk to guarantee a minimum level of revenue and profitability to the investors, is a standard risk mitigation mechanism for Public-Private Partnership contracts. Typically, valuation models for these guarantees assume that traffic volume follows a geometric Brownian motion under the Real Options Approach. However, this is often done without testing whether this assumption is reasonable or not. In this article, statistical tests are applied to check the validity of this assumption and show how toll road traffic can be modelled under alternate models, such as Mean Reverting processes, if the geometric Brownian motion assumption is rejected. In that sense, this approach is applied to the case of a toll road concession in Colombia where a Mean Reverting process is used to model the traffic. Finally, it is showed that this model is a valid tool for defining the fair value of the minimum amount of revenue secured by the government. Journal: Construction Management and Economics Pages: 121-138 Issue: 3 Volume: 37 Year: 2019 Month: 3 X-DOI: 10.1080/01446193.2018.1500024 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1500024 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:3:p:121-138 Template-Type: ReDIF-Article 1.0 Author-Name: Abolfazl Farahani Author-X-Name-First: Abolfazl Author-X-Name-Last: Farahani Author-Name: Holger Wallbaum Author-X-Name-First: Holger Author-X-Name-Last: Wallbaum Author-Name: Jan-Olof Dalenbäck Author-X-Name-First: Jan-Olof Author-X-Name-Last: Dalenbäck Title: Optimized maintenance and renovation scheduling in multifamily buildings – a systematic approach based on condition state and life cycle cost of building components Abstract: Proactive maintenance strategies in principle are devised to control degradation and sustain optimal performance of building components. While realizing the technical necessities, they also serve as an instrument towards multiple and often conflicting objectives during financial constraints. An optimal proactive maintenance strategy therefore should comprise a multiannual maintenance action plan optimized on different criteria corresponding to owners’ objectives under existing constraints. This study offers a systematic approach based on a condition-deterioration model to address the complexity involved in decision making regarding optimized maintenance and renovation planning. Life-cycle cost analysis in form of Equivalent Annual Cost (EAC) is used for the economic assessment of maintenance/renovation scenarios. In this paper, the model is used to compare the economy of different maintenance/renovation plans in a chosen scenario in order to determine the optimal maintenance interval for a single and a combination of building components. Two façade elements, windows and façade rendering, are used to illustrate the application of the proposed method. This method is intended to help decision makers at both design and post-construction phases in the choice of both building components and maintenance/renovation strategies. Journal: Construction Management and Economics Pages: 139-155 Issue: 3 Volume: 37 Year: 2019 Month: 3 X-DOI: 10.1080/01446193.2018.1512750 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1512750 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:3:p:139-155 Template-Type: ReDIF-Article 1.0 Author-Name: Mike Rafferty Author-X-Name-First: Mike Author-X-Name-Last: Rafferty Author-Name: Phillip Toner Author-X-Name-First: Phillip Author-X-Name-Last: Toner Title: Thinking like Capital markets – Financialisation of the Australian Construction Industry Abstract: The concept of financialisation has not yet become a major subject in mainstream construction economics research. This is surprising since construction risk, risk management and project financing have long been important issues for researchers and practitioners. This paper introduces the concept of financialisation, outlines its causes in the construction industry and identifies some effects. An important dimension of financialisation in the construction industry can be seen in the growing conversion of illiquid built assets into liquid financial instruments that have become a distinct global asset class. These liquid construction assets have become important to current risk management and profit strategies of developers, major construction firms and capital market investors. Five key drivers of financialisation in the construction industry are identified. The article finds that a principal effect of financialisation in construction is to intensify competition for access to global capital, which in turn reinforces long-established tendencies for risk shifting in the contractual chain. The Australian construction industry has been an early adopter of the key drivers of financialisation and is used in this article as a case study. In developing the case study analysis the article also draws on observations by major Australian construction industry associations and financial institutions. Journal: Construction Management and Economics Pages: 156-168 Issue: 3 Volume: 37 Year: 2019 Month: 3 X-DOI: 10.1080/01446193.2018.1513163 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1513163 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:3:p:156-168 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Title: Close entanglements: aligning the construction and finance industries Abstract: The construction industry has two major institutional supporters in (1) the sovereign state, whose political entities render affordable housing and the supply of credit a core component in modern statecraft, and (2) the finance industry, which rely on the construction industry for high-quality collateral in forms of real estate, and which also expand the stock of credit in the economy. In this finance capital creation role, the finance industry makes many construction industry projects realizable and attractive investment objects. Construction management scholarship has neither ignored nor understated governance issues, but closer attention should be given to the intimate relationships and co-dependencies across formal industry boundaries. The article stresses how the expansion of the securities industry has been a key mechanism for integrating construction and finance industries more closely, offering various joint benefits that materialize as both desirable and more cumbersome and unanticipated economic consequences. The article argues, however, that while securitization increased the stock of finance capital and the liquidity, the Global Financial Crisis of 2008 indicated that this new integration of construction finance and the state resulted in an unstable and risky nexus. That nexus has since been consolidated, but the open question is whether it has been stabilized. Journal: Construction Management and Economics Pages: 169-178 Issue: 3 Volume: 37 Year: 2019 Month: 3 X-DOI: 10.1080/01446193.2018.1517941 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1517941 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:3:p:169-178 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Author Index for Volume 36 (2018) Journal: Construction Management and Economics Pages: 182-182 Issue: 3 Volume: 37 Year: 2019 Month: 3 X-DOI: 10.1080/01446193.2019.1576401 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1576401 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:3:p:182-182 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: List of Reviewers for Volume 36 (2018) Journal: Construction Management and Economics Pages: 179-181 Issue: 3 Volume: 37 Year: 2019 Month: 3 X-DOI: 10.1080/01446193.2019.1585096 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1585096 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:3:p:179-181 Template-Type: ReDIF-Article 1.0 Author-Name: Henrik Szentes Author-X-Name-First: Henrik Author-X-Name-Last: Szentes Title: Reinforcing cycles involving inter- and intraorganizational paradoxical tensions when managing large construction projects Abstract: In recent years, scholars have shown a growing interest in combining control and flexibility when organizing and managing large construction projects, in contrast with the traditional focus on control. Prior research recognizes that there is a paradoxical tension between control and flexibility, meaning that, while both approaches make sense individually, they appear impossible to combine. Large construction projects are interorganizational, which means that tensions between interorganizational control/flexibility coexist with tensions between intraorganizational direction/empowerment, but the interplay and possible reinforcing cycles involving the two tensions have rarely been investigated in prior research. A multiple case study of four large construction projects with three rounds of interviews show how intraorganizational direction/empowerment can influence interorganizational control/flexibility and vice versa, and demonstrate both vicious and virtuous reinforcing cycles that involve the two types of tensions. Therefore, contributing to the project management and construction management literature, it is argued that employing a systemic approach when studying interorganizational projects is essential. A systemic paradox perspective can reveal interdependencies between tensions at different organizational interfaces, improve the understanding of how individuals in all managerial positions interplay, and explain how reinforcing cycles emerge and develop; this is important to recognize when organizing, staffing and managing large construction projects. Journal: Construction Management and Economics Pages: 125-140 Issue: 3 Volume: 36 Year: 2018 Month: 3 X-DOI: 10.1080/01446193.2017.1315826 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1315826 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:3:p:125-140 Template-Type: ReDIF-Article 1.0 Author-Name: Fred Sherratt Author-X-Name-First: Fred Author-X-Name-Last: Sherratt Title: Shaping the discourse of worker health in the UK construction industry Abstract: The UK construction industry is in poor health, statistics show rates of occupational illness significantly higher than for workers in any other industry. Recently, the scope of occupational health management on large sites has increased as public health has become included within the organizational remit. Concerns have been raised around the consequences of this development, its close relationships to Corporate Social Responsibility, and how this is now shaping the wider discourse. To explore this phenomenon, a critical discourse analysis of UK “construction worker health” has been carried out, using the public-facing data of ten large UK contractors. Findings show that “public” has now overtaken “occupational”, the latter restricted to legal compliance presented as corporate citizenship, the former championed as evidence of benevolent organizational values. Yet public health concerns are limited to those of lifestyle and individual responsibility, whilst more complex issues around the social determinants of health as associated with work are missing from the discourse, separating organizations from the impacts of their work on their workers. A contemporary mapping of “construction worker health” is developed for consideration by industry and academics to support future health initiatives and research. Journal: Construction Management and Economics Pages: 141-152 Issue: 3 Volume: 36 Year: 2018 Month: 3 X-DOI: 10.1080/01446193.2017.1337916 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1337916 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:3:p:141-152 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Author-Name: Rajen Govender Author-X-Name-First: Rajen Author-X-Name-Last: Govender Author-Name: Peter Edwards Author-X-Name-First: Peter Author-X-Name-Last: Edwards Author-Name: Keith Cattell Author-X-Name-First: Keith Author-X-Name-Last: Cattell Title: Work-related contact, work–family conflict, psychological distress and sleep problems experienced by construction professionals: an integrated explanatory model Abstract: Contemporary communication technology blurs the boundaries between work–life and family–life environments, through after-hours, work-related contact. We examined the relationship between work contact, work–family conflict and consequent outcomes of psychological distress and sleep problems experienced by South African construction professionals. An integrated model of these factors was proposed and tested using path analysis and responses from 630 survey respondents. Work experience, gender, domestic situation and employment status explain the relationship between job autonomy and control, job pressures, and work contact, which were hypothesized to multivariately explain their negative effects. The final integrated model was a good fit to the data. The results indicate that the antecedents of work–family conflict are job autonomy and control, job pressure and work contact. Psychological distress is determined by work–family conflict, work experience, and job pressure. Sleep problems are influenced by work–family conflict, work contact and psychological distress. An important insight gained is the pivotal role played by job pressure, directly and indirectly, in work stress outcomes. Interventions aimed at reducing psychological distress and sleep problems among construction professionals should target the boundary permeability of work contact and work–family conflict, particularly for less experienced, female and junior professionals with low job control but high job pressure. Journal: Construction Management and Economics Pages: 153-174 Issue: 3 Volume: 36 Year: 2018 Month: 3 X-DOI: 10.1080/01446193.2017.1341638 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1341638 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:3:p:153-174 Template-Type: ReDIF-Article 1.0 Author-Name: Jan Bröchner Author-X-Name-First: Jan Author-X-Name-Last: Bröchner Title: Construction economics and economics journals Abstract: It has been asked whether construction economics has achieved the position of an academic (sub-)discipline. The main question addressed here is if there are signs of a widening gap between construction economics and mainstream economics. Full text searches in three top economics journals and in Construction Management and Economics have been performed, as well as an analysis of how a broader range of economics journals have combined the construction industry topic with other topics. Results include that authors in the three top economics journals never cite articles in Construction Management and Economics, although citations in the opposite direction are frequent. Economics journals in general are found to combine the Journal of Economic Literature L74 code (Construction) mostly with codes from financial economics, macroeconomics and economic development. For 2013–2016, the strongest new combinations with construction are with Firm Behaviour – Empirical Analysis, Accounting and Climate – Natural Disasters and their Management. Finally, the importance for construction economists of access to big data is emphasized. Journal: Construction Management and Economics Pages: 175-180 Issue: 3 Volume: 36 Year: 2018 Month: 3 X-DOI: 10.1080/01446193.2017.1410197 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1410197 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:3:p:175-180 Template-Type: ReDIF-Article 1.0 Author-Name: Henrik C. J. Linderoth Author-X-Name-First: Henrik C. J. Author-X-Name-Last: Linderoth Title: From visions to practice – The role of sensemaking, institutional logic and pragmatic practice Abstract: The emergence of a new technology like BIM is often connected with extensive discussions of industrial and organizational development and change. However, predicting the use trajectory of a technology has always been a difficult task. In understanding the adoption and use of information and communication technology (ICT), the way that people make sense of a technology is an important component. Even if sensemaking varies over time, studies of sensemaking processes over longer periods are rare. This paper has two aims. First, to develop a conceptual framework of how the development of sensemaking processes shapes the adoption and use of ICT. Second, to discuss the implications of this for research and practice, with a specific focus on the adoption and use of BIM. The research involves a case study of 12 years of telemedicine use in a Swedish county. These results are compared with contemporary BIM studies. The overall conclusion is that the use of technology is heavily shaped by the sensemaking of significant actor groups. This is grounded both an institutional logic and daily practice in relation to the benefits or disadvantages the group perceives from the use of the technology. Journal: Construction Management and Economics Pages: 324-337 Issue: 6 Volume: 35 Year: 2017 Month: 6 X-DOI: 10.1080/01446193.2016.1250930 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1250930 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:6:p:324-337 Template-Type: ReDIF-Article 1.0 Author-Name: Hossein Karimi Author-X-Name-First: Hossein Author-X-Name-Last: Karimi Author-Name: Timothy R. B. Taylor Author-X-Name-First: Timothy R. B. Author-X-Name-Last: Taylor Author-Name: Paul M. Goodrum Author-X-Name-First: Paul M. Author-X-Name-Last: Goodrum Title: Analysis of the impact of craft labour availability on North American construction project productivity and schedule performance Abstract: The North American construction industry has experienced periods of craft shortages for decades. While this problem has received significant attention from researchers, less attention has been given to quantifying the impact of availability of craft labour on project performance. The primary contribution of the current work to the body of knowledge is the quantification of the relationship between craft labour availability and project performance, as measured by project productivity and schedule. Data from 97 construction projects completed in the U.S. and Canada between 2001 and 2014 were collected from two industry databases. The primary analysis shows that projects that experienced craft shortages underwent substantial and statistically lower productivity compared to projects that did not. The analysis also shows a significant growth in schedule overrun due to the craft labour shortages among the same population of projects. Further exploration by means of several regression analyses shows a statistically significant correlation between increased craft recruiting difficulty and lower project productivity and also higher schedule overruns in both project databases. The results are confirmed across both databases and serve as informative models that provide valuable insight for project management teams to perceive the risk that lack of skills poses on project productivity and time performance. Understanding the level of impact that craft shortages are having through robust statistical analyses is a first step in developing the motivation for industry leaders, communities and construction stakeholders to address this challenge. Journal: Construction Management and Economics Pages: 368-380 Issue: 6 Volume: 35 Year: 2017 Month: 6 X-DOI: 10.1080/01446193.2017.1294257 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1294257 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:6:p:368-380 Template-Type: ReDIF-Article 1.0 Author-Name: Andrea Yunyan Jia Author-X-Name-First: Andrea Yunyan Author-X-Name-Last: Jia Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Mengnan Xu Author-X-Name-First: Mengnan Author-X-Name-Last: Xu Author-Name: Baizhan Li Author-X-Name-First: Baizhan Author-X-Name-Last: Li Author-Name: Alistair Gibb Author-X-Name-First: Alistair Author-X-Name-Last: Gibb Title: Institutions and institutional logics in construction safety management: the case of climatic heat stress Abstract: We employed a Glaserian grounded theory approach to explore the gap between behavioural safety and its unsatisfactory outcomes. Data were collected through ethnographic studies on the practice of managing heat stress on thirty-six construction sites in Hong Kong and Chonqing in mainland China. Two core concepts, institutions and institutional logics, are generated and defined to explain why safety rules do not necessarily produce safety behaviours. At society level, we explicated two pairs of institutional logics: the religion logics (Confucianism vs. pragmatism) and the market logics (rational market vs. individualism). At project organizational level, two logics of processing safety in production are explicated: a protection logic in the Chongqing context and a production logic in the Hong Kong context. The concepts and sub-concepts are compared to existing business literature for clarification of scopes. Empirical findings of the study suggest safety intervention needs to redirect its focus from promoting safety alone to addressing the institutional logics of the entire organization and its societal context practised by multiple levels of actors. We conclude that safety research would benefit from redirecting its focus of analysis from discourses, interviews or surveys to authenticated cases reconstructed through triangulation of actors’ discourses at multiple levels of an organization, third-party observation, physiological data and objective measurement of the work environment. Methodologically, this paper provides a detailed guidance for conducting grounded theory research with a focus of conceptualization. Journal: Construction Management and Economics Pages: 338-367 Issue: 6 Volume: 35 Year: 2017 Month: 6 X-DOI: 10.1080/01446193.2017.1296171 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1296171 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:6:p:338-367 Template-Type: ReDIF-Article 1.0 Author-Name: Grane Mikael Gregaard Rasmussen Author-X-Name-First: Grane Mikael Gregaard Author-X-Name-Last: Rasmussen Author-Name: Per Langaa Jensen Author-X-Name-First: Per Langaa Author-X-Name-Last: Jensen Author-Name: Stefan Christoffer Gottlieb Author-X-Name-First: Stefan Christoffer Author-X-Name-Last: Gottlieb Title: Frames, agency and institutional change: the case of benchmarking in Danish construction Abstract: This study examines change and the sources influencing the formulation and diffusion of policies in construction. The change examined is the introduction of a benchmarking policy initiative in the Danish construction industry. Using institutional theory with emphasis on the concepts of frames and framings, we show how strategically motivated actors are able to frame policy problems in ways that disclose the mixture of motives, interests and institutional mechanisms at play in change processes. In doing so, we contribute to the literature on the role of agency in institutional change and the framing of policy problems. We conclude by highlighting how insights gained from the framing perspective present a challenge to the dominant comprehensive rationalist view of the policy process and the formulation and implementation of reform initiatives. Journal: Construction Management and Economics Pages: 305-323 Issue: 6 Volume: 35 Year: 2017 Month: 6 X-DOI: 10.1080/01446193.2017.1298824 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1298824 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:6:p:305-323 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Corrigendum Journal: Construction Management and Economics Pages: 381-381 Issue: 6 Volume: 35 Year: 2017 Month: 6 X-DOI: 10.1080/01446193.2017.1319650 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1319650 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:6:p:381-381 Template-Type: ReDIF-Article 1.0 Author-Name: Erik Poirier Author-X-Name-First: Erik Author-X-Name-Last: Poirier Author-Name: Daniel Forgues Author-X-Name-First: Daniel Author-X-Name-Last: Forgues Author-Name: Sheryl Staub-French Author-X-Name-First: Sheryl Author-X-Name-Last: Staub-French Title: Collaboration through innovation: implications for expertise in the AEC sector Abstract: Collaboration is key for successful delivery of building projects in the Architecture, Engineering and Construction (AEC) sector. Innovative project delivery approaches developed over the past two decades envision new ways of collaborating and specifically aim at improving the performance of and value generated by this key economic sector. Collaboration, however, remains an ill-defined and highly amorphous concept. This makes it difficult to investigate and consequently develop a body of knowledge, which is central to defining a field of expertise in this area. The aim of this investigation is to explore the notion of an expertise in collaboration in the AEC sector and the implications of these innovative project delivery approaches on this expertise. The concept of collaboration is developed across five core entities: structure, process, agents, artefacts and context. These entities are then framed through a critical realist lens to lay the groundwork for a body of knowledge of collaboration in the AEC sector. The impact of the current shift to these innovative approaches is investigated within this framing. The findings set a course of action to develop a body of knowledge and a field of expertise on collaboration in the AEC sector. Journal: Construction Management and Economics Pages: 769-789 Issue: 11 Volume: 34 Year: 2016 Month: 11 X-DOI: 10.1080/01446193.2016.1206660 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1206660 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:11:p:769-789 Template-Type: ReDIF-Article 1.0 Author-Name: Malena Ingemansson Havenvid Author-X-Name-First: Malena Ingemansson Author-X-Name-Last: Havenvid Author-Name: Kajsa Hulthén Author-X-Name-First: Kajsa Author-X-Name-Last: Hulthén Author-Name: Åse Linné Author-X-Name-First: Åse Author-X-Name-Last: Linné Author-Name: Viktoria Sundquist Author-X-Name-First: Viktoria Author-X-Name-Last: Sundquist Title: Renewal in construction projects: tracing effects of client requirements Abstract: Several studies identify clients as important drivers of innovation in the construction industry. How clients contribute to innovation is however less investigated. In two case studies of health care construction projects, we investigate how client requirements create renewal in the form of intra- as well as inter-project effects. Using an inter-organizational framework of actors, resources and activities (the ARA model), it is possible to identify a variation of effects. The paper concludes that both client requirements and their associated renewal effects are results of interaction in time as well as space. Renewal effects crossing individual projects are dependent on relationships among two or more actors that continue to interact in subsequent projects. In addition, these effects relate to several dimensions of interaction and include how actors relate in new ways, how resources are combined and how activities are organized. Thus, by adopting an interactive perspective, it is possible to reveal how construction clients can contribute to renewal such as innovation and learning, directly and indirectly, within and across projects. Finally, we suggest that managers need to consider the role of long-term business relationships in achieving increased renewal in construction. Journal: Construction Management and Economics Pages: 790-807 Issue: 11 Volume: 34 Year: 2016 Month: 11 X-DOI: 10.1080/01446193.2016.1208364 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1208364 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:11:p:790-807 Template-Type: ReDIF-Article 1.0 Author-Name: Sui Pheng Low Author-X-Name-First: Sui Pheng Author-X-Name-Last: Low Author-Name: Shang Gao Author-X-Name-First: Shang Author-X-Name-Last: Gao Author-Name: Mohammad Matin Mohdari Author-X-Name-First: Mohammad Matin Author-X-Name-Last: Mohdari Title: Marketing importance and marketing performance measurement of architecture firms in Singapore: an exploratory study Abstract: While marketing is a known element of successful practice, architects are yet to be convinced of its full potential. Little was known about the marketing practice in architectural firms in Singapore. Attempts were made to determine the realities of formalized marketing approaches and their importance to architectural firms in Singapore through a questionnaire survey (where 95 architectural firms participated) and follow-up interviews. A total of 34 usable responses were collected. This was investigated using the ‘Architecture Business Development Process’ as a framework, which found evidence to suggest that marketing has been recognized as an important component of architectural practice in Singapore. The results show that the adoption of the ‘marketing concept’ in the architecture profession is still in its formative stages. Architectural firms – and small and medium ones in particular – need to fully capitalize on this area of business knowledge in order to influence, command and understand the market for them to remain financially viable as a practice. Despite little attention being paid to measuring the performance of marketing outcomes, almost all the respondents and interviewees acknowledged its increasing importance. With greater corporate governance, these firms are beginning to realize the significance of marketing, and are evaluating their practices to ride the market for success. This move indicates a positive step in bridging the disparities between architecture practice and design. Journal: Construction Management and Economics Pages: 739-750 Issue: 11 Volume: 34 Year: 2016 Month: 11 X-DOI: 10.1080/01446193.2016.1211719 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1211719 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:11:p:739-750 Template-Type: ReDIF-Article 1.0 Author-Name: Ashwini Konanahalli Author-X-Name-First: Ashwini Author-X-Name-Last: Konanahalli Author-Name: Lukumon O. Oyedele Author-X-Name-First: Lukumon O. Author-X-Name-Last: Oyedele Title: Emotional intelligence and British expatriates’ cross-cultural adjustment in international construction projects Abstract: Today’s internationalized business demands global mindset, intercultural sensitivity and the ability to skilfully negotiate through cross-cultural interactions. Therefore, the overall aim was to investigate the influence of emotional intelligence (EI) on cross-cultural adjustment (CCA) of British expatriates working on International Architectural, Engineering and Construction assignments in Sub-Saharan Africa, China, Middle East and Indian Sub-Continent. Specifically, the causal relationship between EI and three facets of CCA i.e. work, general and interaction adjustment was explored. A sequential exploratory mixed methods design was adopted. These include extensive review of existing literature, eighteen unstructured interviews, and questionnaire survey of 191 British expatriates operating in 29 different countries from the four regions under investigation. Structural equation modelling was used to assess the causal relationship between EI and CCA. Results show that EI accounted for 91, 64 and 24% of the variance in work, interaction and general adjustment respectively. Overall, the model was able to explain 60% variance in CCA, suggesting that EI competencies play a huge role in facilitating an expatriate understand and adapt to host country culture. The findings would help decision-makers (HR managers) during expatriate selection process, in understanding that along with technical skills, it is the emotional competencies that are crucial in assisting expatriates adjust to foreign way of life. Journal: Construction Management and Economics Pages: 751-768 Issue: 11 Volume: 34 Year: 2016 Month: 11 X-DOI: 10.1080/01446193.2016.1213399 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1213399 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:11:p:751-768 Template-Type: ReDIF-Article 1.0 Author-Name: Hafiz A. Alaka Author-X-Name-First: Hafiz A. Author-X-Name-Last: Alaka Author-Name: Lukumon O. Oyedele Author-X-Name-First: Lukumon O. Author-X-Name-Last: Oyedele Author-Name: Hakeem A. Owolabi Author-X-Name-First: Hakeem A. Author-X-Name-Last: Owolabi Author-Name: Saheed O. Ajayi Author-X-Name-First: Saheed O. Author-X-Name-Last: Ajayi Author-Name: Muhammad Bilal Author-X-Name-First: Muhammad Author-X-Name-Last: Bilal Author-Name: Olugbenga O. Akinade Author-X-Name-First: Olugbenga O. Author-X-Name-Last: Akinade Title: Methodological approach of construction business failure prediction studies: a review Abstract: Performance of bankruptcy prediction models (BPM), which partly depends on the methodological approach used to develop it, has virtually stagnated over the years. The methodological positions of BPM studies were thus investigated. Systematic review was used to search and retrieve 70 journal articles and doctoral theses. Their “general methods” and “philosophical underpinnings” were investigated using summary of findings tables and meta-analysis. “General methods” results showed positive trends in terms of techniques being used, error cost consideration and model validation, with some use of skewed data being the main drawback. For “philosophical underpinnings”, positivism paradigm was discovered to be at the core of BPM studies. This is deemed inadequate because of the need to consider industries’ dynamism, financial variables flaws and social factors which actually lead to the financial status of firms. The pragmatism paradigm using mixed method is proposed. A research design framework for executing the proposed methodology is presented. This will help BPM developers go through more rigorous and robust methodology to deliver better and more valid models. Limitations of study include not reviewing studies not reported in English language and impact of different countries’ accounting practices on ratios. Limited availability of theses’ database resulted in reviewing only four theses. Journal: Construction Management and Economics Pages: 808-842 Issue: 11 Volume: 34 Year: 2016 Month: 11 X-DOI: 10.1080/01446193.2016.1219037 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1219037 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:11:p:808-842 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Editorial Journal: Construction Management and Economics Pages: 737-738 Issue: 11 Volume: 34 Year: 2016 Month: 11 X-DOI: 10.1080/01446193.2016.1228177 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1228177 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:11:p:737-738 Template-Type: ReDIF-Article 1.0 Author-Name: Farook R. Hamzeh Author-X-Name-First: Farook R. Author-X-Name-Last: Hamzeh Author-Name: Farah Faek Author-X-Name-First: Farah Author-X-Name-Last: Faek Author-Name: Hasnaa AlHussein Author-X-Name-First: Hasnaa Author-X-Name-Last: AlHussein Title: Understanding improvisation in construction through antecedents, behaviours and consequences Abstract: Improvisation is a deliberate, spontaneous and rational decision-making process that helps address emerging issues or unplanned work. Traditional management avoids relying on improvisation as it indicates deviation from the pre-planned procedures and standards. However, improvisational practices continue to exist within numerous uncertain environments such as construction where improvised actions emerge even though they are not encouraged. The purpose of this study is to develop a better understanding of the improvisational practices occurring in construction and recognize the factors contributing to successful improvisation. This study elucidates antecedents, behaviours and consequences of improvisation in various construction operations. Surveys were conducted among different construction professionals to understand improvisation on real-life construction projects. Statistical analyses show that personal experience and the type of organization a person works for have a significant effect on the outcomes of improvisation. In addition, results highlight the most frequent antecedents that trigger the need for improvisation to complete a certain task. The outcomes of this study can help managers and decision makers in the construction industry identify personal, organizational and other specific characteristics that may improve the practice of improvisation for complementing planning processes rather than undermining them. Journal: Construction Management and Economics Pages: 61-71 Issue: 2 Volume: 37 Year: 2019 Month: 2 X-DOI: 10.1080/01446193.2018.1497189 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1497189 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:2:p:61-71 Template-Type: ReDIF-Article 1.0 Author-Name: Mohd Azrai Azman Author-X-Name-First: Mohd Azrai Author-X-Name-Last: Azman Author-Name: Carol K. H. Hon Author-X-Name-First: Carol K. H. Author-X-Name-Last: Hon Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Boon Liat Lee Author-X-Name-First: Boon Liat Author-X-Name-Last: Lee Author-Name: Bo Xia Author-X-Name-First: Bo Author-X-Name-Last: Xia Title: A Meta-frontier method of decomposing long-term construction productivity components and technological gaps at the firm level: evidence from Malaysia Abstract: There is a need for a better approach to measure construction productivity rigorously, multilaterally, longitudinally and decomposed into its components. In response, this paper offers a robust approach to analysing construction productivity at the firm level that has been lacking in the industry to date, by measuring the Total Factor Productivity (TFP) of 37 public-listed Malaysian construction firms over 14 years (2003–2016), based on the Färe-Primont index. In comparing different groups of building, civil and specialist construction firms, this is the first application of a meta-frontier framework to capture the technological gaps involved. Based on the construction firms’ financial data, it is found that TFP improvement generally occurs due to Technical Efficiency (TE) and Scale-Mix Efficiency (SME) (largely scope economies), and significant technological gaps exist among different groups. Moreover, the industry suffered a decline in technologically related production environment over the period – prompting the conclusion that long-term policy engagement should focus on technological improvements. The paper provides a robust approach to analysing construction productivity at the firm level that also can be used for accessing productivity components and technological gaps in construction and other industries. Journal: Construction Management and Economics Pages: 72-88 Issue: 2 Volume: 37 Year: 2019 Month: 2 X-DOI: 10.1080/01446193.2018.1506139 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1506139 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:2:p:72-88 Template-Type: ReDIF-Article 1.0 Author-Name: Jessica Kaminsky Author-X-Name-First: Jessica Author-X-Name-Last: Kaminsky Title: The global influence of national cultural values on construction permitting Abstract: This research discovers how national level culture shapes construction permitting across 62 nations. Hofstede’s cultural dimensions explain variability in components of World Bank’s dealing with Construction Permits index, which measures the number of required permitting procedures, the required time in days, the cost as a percentage of a standardized warehouse value, and a permitting quality index. After controlling for gross domestic product, statistically significant relationships between permitting time and Hofstede’s Uncertainty Avoidance and Masculinity-Femininity dimensions emerged. Hofstede’s Power Distance Index shared statistically significant relationships with the number of procedures required for permitting, and a limited relationship with the cost of permitting. These data provide empirical evidence that different cultural preferences lead to different construction permitting practices, and allow the construction community to better understand the culturally shaped ways in which permits govern projects. This builds the theory of social sustainability of infrastructure, which seeks to generalize ways to match construction practice to societal preferences to improve community and project outcomes. For example, policy makers may use the results presented here to shape more culturally appropriate construction permitting regulations. In another example, construction firms may use these results to navigate permitting challenges they encounter on global projects. Journal: Construction Management and Economics Pages: 89-100 Issue: 2 Volume: 37 Year: 2019 Month: 2 X-DOI: 10.1080/01446193.2018.1506140 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1506140 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:2:p:89-100 Template-Type: ReDIF-Article 1.0 Author-Name: Awad S. Hanna Author-X-Name-First: Awad S. Author-X-Name-Last: Hanna Author-Name: Karim A. Iskandar Author-X-Name-First: Karim A. Author-X-Name-Last: Iskandar Author-Name: Wafik Lotfallah Author-X-Name-First: Wafik Author-X-Name-Last: Lotfallah Title: Benchmarking project performance: a guideline for assessing vulnerability of mechanical and electrical projects to productivity loss Abstract: Loss of productivity is a contentious issue that has a profound impact on modern construction, yet existing literature provides no quantitative, data-driven method to compare the productivity of different construction projects or to assess their vulnerability to productivity loss. A new mathematically derived metric, called the “Risk of Productivity Loss (RPL)” score, provides such a method. RPL is a function of multiple distinct productivity factors. The RPL score is developed from a dataset of 166 electrical and mechanical projects, which collectively amount to 7.2 million labour hours. This large sample size makes the RPL score a reliable productivity benchmark for the electrical and mechanical construction industries due to their labour-intensive nature. The higher the RPL score, the higher the risk that a given project will suffer from productivity losses. To supplement the mathematical formula presented, objective data-based weights for multiple key productivity factors have been identified, reducing the subjectivity that affects many of the existing weighting assessment methods. RPL provides the industry with a single metric that allows tracking and assessment of productivity for multiple projects at a time so that a contractor may assess the successful reduction of productivity risk factors within the projects in their company. Journal: Construction Management and Economics Pages: 101-111 Issue: 2 Volume: 37 Year: 2019 Month: 2 X-DOI: 10.1080/01446193.2018.1513160 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1513160 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:2:p:101-111 Template-Type: ReDIF-Article 1.0 Author-Name: Russell Kenley Author-X-Name-First: Russell Author-X-Name-Last: Kenley Title: CME Forum: a response to “Construction flow index: a metric of production flow quality in construction” Abstract: The study of types of flow in construction is a relatively new field. This paper reviews the work of Sacks et al. and reveals that they have applied a production-line metaphor with recognition of two production flows. Process flow: locations are equated with products moving down a production line. Operations flow: work crews are equated to work stations. Their work proposes an index of the quality of production flow in construction, but the research design has three significant flaws: the skilled interpretation of flow-line charts is not in turn applied to the interpretation of their example charts; the conceptual framework does recognize that the underlying metaphor requires levels of detail in both location and task that is not supported in their analysis. The meaning of “quality of flow” in this context is not defined. This debate raises important epistemological questions for those working in lean construction and location-based management. While the concept of “production flow quality” is important, the Sacks et al. methodology does not address the detailed planning of individual crews. It is only possible to apply the production-line metaphor if micro-management is adopted as detailed planning. Journal: Construction Management and Economics Pages: 112-119 Issue: 2 Volume: 37 Year: 2019 Month: 2 X-DOI: 10.1080/01446193.2018.1535712 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1535712 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:2:p:112-119 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Benson Teck Heng Lim Author-X-Name-First: Benson Teck Heng Author-X-Name-Last: Lim Title: Mapping corporate social responsibility strategies in the construction and engineering industry Abstract: Interest in corporate social responsibility (CSR) is growing in response to societal and regulatory demands that construction businesses contribute positively to the environments and communities in which they build. While, CSR research in the construction and engineering industry is progressing there has been little research into whether and how firms in this industry operationalize CSR, how they incorporate CSR into their business vision, leadership and mission and strategies and what forms these strategies take. In addressing these gaps in knowledge, a survey of 104 firms from across the construction and engineering industry and its supply chain in Australia and New Zealand was undertaken. The results indicate that CSR in construction and engineering firms is largely informal, unsophisticated, compliance driven and in its early stages of development. There is little strategic focus in CSR initiatives and the potential social capital derived from better strategic relationships with communities appears to be largely wasted. Conceptually, it is concluded that there is a need to adapt current models of CSR practice, developed in a permanent business context, to reflect the transitional, nomadic and project-based nature of construction. Current models of CSR are inadequate at explaining how firms operating in the construction industry need to practically adjust and adapt their CSR strategies to fit with the constantly changing political, social, cultural, environmental and economic profiles of local communities and the requirements of clients and local governments. Journal: Construction Management and Economics Pages: 67-82 Issue: 2 Volume: 36 Year: 2018 Month: 2 X-DOI: 10.1080/01446193.2017.1326616 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1326616 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:2:p:67-82 Template-Type: ReDIF-Article 1.0 Author-Name: Anne Kokkonen Author-X-Name-First: Anne Author-X-Name-Last: Kokkonen Author-Name: Anne Live Vaagaasar Author-X-Name-First: Anne Live Author-X-Name-Last: Vaagaasar Title: Managing collaborative space in multi-partner projects Abstract: Collaboration across company borders in multi-partner construction projects has proven to be challenging. An increasing number of projects aim to strengthen such collaboration by collocating project members from different companies in the same physical space. Yet we know little about the management practices required for taking advantage of such a collaborative space. To begin to remedy this shortcoming, we present an in-depth case study of a hospital construction project that applied a collaborative space and focus on the management practices influencing this space. With the help of affordance theory, we identified two types of management practices and show how they transform across project phases. These management practices included designing the physical elements of the collaborative space, and creating shared collaboration practices for the space. We contribute to the construction management literature by taking the first step in conceptualizing the connections between space, management and collaboration practices in the context of multi-partner projects. We suggest managers to consider carefully what kind of collaboration practices the space is expected to enhance and plan the physical and social space to support it. Journal: Construction Management and Economics Pages: 83-95 Issue: 2 Volume: 36 Year: 2018 Month: 2 X-DOI: 10.1080/01446193.2017.1347268 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1347268 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:2:p:83-95 Template-Type: ReDIF-Article 1.0 Author-Name: Anthony T. Odoemena Author-X-Name-First: Anthony T. Author-X-Name-Last: Odoemena Author-Name: Masahide Horita Author-X-Name-First: Masahide Author-X-Name-Last: Horita Title: A strategic analysis of contract termination in public–private partnerships: implications from cases in sub-Saharan Africa Abstract: The paper examines empirically what contributes to the problem of contract termination in public–private partnerships (PPPs) from the perspectives of theories on contracts, transaction costs and industrial organizations. Based on a theoretical exploration of a model of the holdup and underinvestment problems, we identified the profit-sharing mechanism as the contract type that most predisposes a PPP to the inefficiencies that lead to contract termination. We then conducted an empirical examination of a data-set of PPP contracts in sub-Saharan Africa. Using rough sets theory and the logic of explanatory power, we found that contract type outweighs other factors, such as sector and nationality, in the explanation of contract termination. Journal: Construction Management and Economics Pages: 96-108 Issue: 2 Volume: 36 Year: 2018 Month: 2 X-DOI: 10.1080/01446193.2017.1361039 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1361039 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:2:p:96-108 Template-Type: ReDIF-Article 1.0 Author-Name: Hylton Olivieri Author-X-Name-First: Hylton Author-X-Name-Last: Olivieri Author-Name: Olli Seppänen Author-X-Name-First: Olli Author-X-Name-Last: Seppänen Author-Name: Ariovaldo Denis Granja Author-X-Name-First: Ariovaldo Author-X-Name-Last: Denis Granja Title: Improving workflow and resource usage in construction schedules through location-based management system (LBMS) Abstract: Critical Path Method (CPM), a planning and controlling technique, is widely used in the construction industry. However, CPM is criticized for its lack of workflow and inability to schedule continuous resource usage. Location-Based Management System (LBMS) fill these gaps and has been implemented in many construction projects. We propose that LBMS will improve schedules and project performance, addressing CPM’s main shortcomings. This study is composed of three case studies. CPM schedules were analyzed and were improved using LBMS tools. The resulting schedules show improved workflows, crew balancing, resource usage and had fewer interruptions, without affecting project duration. Furthermore, LBMS schedules were optimized with only a few scheduling operations and fewer planning elements. The computational benefit of LBMS increases with the number of locations and tasks in a schedule. Project managers will benefit from a simpler scheduling process and better resource flow. Journal: Construction Management and Economics Pages: 109-124 Issue: 2 Volume: 36 Year: 2018 Month: 2 X-DOI: 10.1080/01446193.2017.1410561 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1410561 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:2:p:109-124 Template-Type: ReDIF-Article 1.0 Author-Name: Roberta Apa Author-X-Name-First: Roberta Author-X-Name-Last: Apa Author-Name: Silvia Rita Sedita Author-X-Name-First: Silvia Rita Author-X-Name-Last: Sedita Title: How (do) internal capabilities and the geography of business networks shape the performance of contractors in public procurement tenders? Evidence from the construction industry Abstract: Public procurement tenders (PPTs) represent one of the largest sources of income for construction companies; the identification of factors that could favour the winning of these projects becomes more and more interesting. Our work aims to explore how firm-specific capabilities (project management, project administration and innovation) and the geography of its business network shape the success of contractors in winning PPTs, measured as the average value of projects won by the firms. We propose an empirical study of contractors involved in public procurement projects in the construction industry in three Italian regions from 2008 to 2012 employing a fuzzy set qualitative comparative analysis. This methodology allows analysing how different combinations of causal conditions contribute to an outcome. Our research highlights that there are three successful strategies for firms attempting to obtain high-value PPT projects: (1) invest in high-level project management capabilities, engage in business networks with distant clients and intensify innovation capacity; (2) invest in high-level project administration capabilities, engage in business networks with local clients and suppliers (within 100 km), report a large number of certifications and show a high innovation capacity; and (3) invest in growth strategies to increase the size of the company. Journal: Construction Management and Economics Pages: 404-419 Issue: 7 Volume: 35 Year: 2017 Month: 7 X-DOI: 10.1080/01446193.2017.1287926 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1287926 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:7:p:404-419 Template-Type: ReDIF-Article 1.0 Author-Name: Chris Harty Author-X-Name-First: Chris Author-X-Name-Last: Harty Author-Name: Roine Leiringer Author-X-Name-First: Roine Author-X-Name-Last: Leiringer Title: The futures of construction management research Abstract: Construction management is an internationally recognized area of research with an established and growing community of academics. It has grown from largely “research consultancy” activities to additionally attracting significant amounts of academic research funding and has, partially, moved away from its applied, engineering dominated origins to increasingly engage with, and contribute to, mainstream academic debates in business and management, economics and the social sciences. It has, as such, become an academic field in its own right. However, recent dynamics within both university institutions and national economies are changing the landscape of construction management research (CMR). A blurring of traditional university boundaries, reprioritization of research funding and increasing emphasis on national and international rankings have led to increased pressure on individual academics and the community they constitute. Drawing on scenario development we ask what, in the face of a turbulent environment, might the futures of CMR be? Four potential futures for CMR are outlined, depicted as four potential scenarios: convergence, retrenchment, disappearance and hybridization. These describe potential outcomes from the institutional dynamics currently at play. The intention is neither to predict the future, nor to prioritize one scenario over another, but to open a debate on the institutional pressures the field is facing, and what the outcomes might be. Journal: Construction Management and Economics Pages: 392-403 Issue: 7 Volume: 35 Year: 2017 Month: 7 X-DOI: 10.1080/01446193.2017.1306089 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1306089 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:7:p:392-403 Template-Type: ReDIF-Article 1.0 Author-Name: Abderisak Adam Author-X-Name-First: Abderisak Author-X-Name-Last: Adam Author-Name: Göran Lindahl Author-X-Name-First: Göran Author-X-Name-Last: Lindahl Title: Applying the dynamic capabilities framework in the case of a large public construction client Abstract: Public clients in the construction sector face a number of challenges in designing, procuring and managing major construction projects. The client’s role in bringing about project delivery has more recently been emphasized, particularly with respect to developing capabilities that facilitate the coordinating of projects through its different phases. In line with these developments, this paper sets out to examine the management of capabilities in a client organization through the lens of the dynamic capabilities framework. In particular, what is investigated is how the client organization senses, seizes and transforms opportunities. In pursuit of this objective, an exploratory case study approach is adopted which examines one of Sweden’s largest public client organizations. The study explores the concept of dynamic capabilities and its applicability to the public construction context. Although the usefulness of dynamic capabilities as an interpretive framework is recognized, it is suggested that the concept of dynamic capabilities is inadequate for addressing the specific context in which public client organizations operate. Particularly with respect to the project-based characteristic of these organizations and the difficulty in framing what constitutes “competitive advantage” for public organizations. Journal: Construction Management and Economics Pages: 420-431 Issue: 7 Volume: 35 Year: 2017 Month: 7 X-DOI: 10.1080/01446193.2017.1309441 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1309441 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:7:p:420-431 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Author-Name: Rajen Govender Author-X-Name-First: Rajen Author-X-Name-Last: Govender Author-Name: Peter Edwards Author-X-Name-First: Peter Author-X-Name-Last: Edwards Title: Condom use by South African construction workers Abstract: Consistent and proper condom use is pivotal in preventing HIV infection. HIV prevalence in South Africa is among the highest in the world, with the construction industry especially affected, yet little is known about condom use by construction workers and the determinants thereof. Data were gathered from 512 site-based workers in the Western Cape. A theoretical model explaining condom use as a function of demographic factors, HIV knowledge, substance usage and risky sexual behaviour (excluding condom use) was proposed and tested using regression and structural equations modelling. The findings indicated that age, gender and level of education were indirect determinants of condom use, with higher levels of education predicting better AIDS-related knowledge. Higher levels of risky sexual behaviour were associated with more frequent use of condoms, suggesting greater awareness of risk. Condom use was adversely affected by greater alcohol and drug use, probably as a result of diminished capacity to assess risk. Finally, lower and not higher levels of AIDS-related knowledge were associated with better condom use, suggesting that improved knowledge of HIV transmission may work contrary to safe sex practice if it lulls the person into a false sense of confidence. Recommendations for targeted workplace interventions are proposed. Journal: Construction Management and Economics Pages: 432-444 Issue: 7 Volume: 35 Year: 2017 Month: 7 X-DOI: 10.1080/01446193.2017.1311019 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1311019 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:7:p:432-444 Template-Type: ReDIF-Article 1.0 Author-Name: Chris Ivory Author-X-Name-First: Chris Author-X-Name-Last: Ivory Title: The prospects for a production management body of knowledge in business schools: response to Koskela (2017) “Why is management research irrelevant?” Abstract: This article is a response to Lauri Koskela’s recent piece in Construction Management and Economics (“Why is management research irrelevant?” 35(1–2): 4–23) which reflects on the relationship between academic research and management practice in business schools. In particular, Koskela asks why production management research and teaching has disappeared from the business school agenda and why management research has failed to produce a consistent body of knowledge that is of use to management practice. In this article, I try to provide some alternative perspectives on the present and past contexts of management theory and production research. I argue that production research, if not teaching, is alive and well and the site of theory generation, problem-focused research and innovation. I also question the veracity and wisdom of a creating “body of knowledge” in relation to management research and practice-even if it were possible, which I believe it is not. My assessment of the state of research in business schools, at least in the U.K. and the U.S. and notwithstanding a lack of consensus over how to approach management research, is that it is eclectic and vibrant and of much more use to practicing managers in that state. Journal: Construction Management and Economics Pages: 385-391 Issue: 7 Volume: 35 Year: 2017 Month: 7 X-DOI: 10.1080/01446193.2017.1323111 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1323111 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:7:p:385-391 Template-Type: ReDIF-Article 1.0 Author-Name: Roine Leiringer Author-X-Name-First: Roine Author-X-Name-Last: Leiringer Author-Name: Andy Dainty Author-X-Name-First: Andy Author-X-Name-Last: Dainty Title: On the right to disagree, healthy debates and moving forward Journal: Construction Management and Economics Pages: 383-384 Issue: 7 Volume: 35 Year: 2017 Month: 7 X-DOI: 10.1080/01446193.2017.1328769 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1328769 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:7:p:383-384 Template-Type: ReDIF-Article 1.0 Author-Name: Marco Alvise Bragadin Author-X-Name-First: Marco Alvise Author-X-Name-Last: Bragadin Author-Name: Kalle Kähkönen Author-X-Name-First: Kalle Author-X-Name-Last: Kähkönen Title: Schedule health assessment of construction projects Abstract: Several factors can contribute to the success of construction projects. A sound and good quality construction schedule is considered to be one of them. The quality of schedules has been a research topic only for a few efforts and amongst them construction-oriented research is even more rare. Methodical grounds for assessing schedule quality have been studied via literature study for the development of appropriate solutions to assess the quality of construction schedules. These findings combined with the experiences from practical implementations have resulted in the definition of a metric to measure schedule quality for construction projects. It includes 75 schedule requirements classified into 5 groups: general requirements, construction process, schedule mechanics, cost and resources and control process. This structure forms a core for the developed method to assess construction schedule quality termed as Schedule Health Assessment. The developed method has also the purpose of assisting project planners to produce and maintain good quality schedules starting from the project initiation until its completion, as via using the method to detect deficiencies of project schedules and other critical issues having importance with respect to schedule maintenance. Journal: Construction Management and Economics Pages: 875-897 Issue: 12 Volume: 34 Year: 2016 Month: 12 X-DOI: 10.1080/01446193.2016.1205751 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1205751 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:12:p:875-897 Template-Type: ReDIF-Article 1.0 Author-Name: Jean-Charles Fiolet Author-X-Name-First: Jean-Charles Author-X-Name-Last: Fiolet Author-Name: Carl Haas Author-X-Name-First: Carl Author-X-Name-Last: Haas Author-Name: Keith Hipel Author-X-Name-First: Keith Author-X-Name-Last: Hipel Title: Risk-chasing behaviour in on-site construction decisions Abstract: Risk-chasing behaviour in on-site construction decision-making can result in illogical decisions and, thus, significant project losses. Accordingly, the authors conducted a set of experiments in order to detect the existence of such behaviour under a range of typical project conditions within a set of common situations. Fifty-three project leaders participated in the experiments by making choices framed by a set of 24 questions. Each question related to a known behavioural tendency, included the influence of an external parameter, and contained information from which expected values could be derived. Participants were well distributed by geography, age and experience. Contrary to the common perception that construction decision-makers are relentlessly risk-averse, they demonstrated risk-chasing behaviour when the decision occurred in over-budget project conditions. Younger participants were even more risk chasing in such conditions. Understanding and identifying where such behaviour occurs could ultimately lead to the development of means of avoiding the resulting losses. Journal: Construction Management and Economics Pages: 845-858 Issue: 12 Volume: 34 Year: 2016 Month: 12 X-DOI: 10.1080/01446193.2016.1207790 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1207790 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:12:p:845-858 Template-Type: ReDIF-Article 1.0 Author-Name: Mesut Pala Author-X-Name-First: Mesut Author-X-Name-Last: Pala Author-Name: Francis Edum-Fotwe Author-X-Name-First: Francis Author-X-Name-Last: Edum-Fotwe Author-Name: Kirti Ruikar Author-X-Name-First: Kirti Author-X-Name-Last: Ruikar Author-Name: Chris Peters Author-X-Name-First: Chris Author-X-Name-Last: Peters Author-Name: Nathan Doughty Author-X-Name-First: Nathan Author-X-Name-Last: Doughty Title: Implementing commercial information exchange: a construction supply chain case study Abstract: The concept of electronic trading (e-trading) has transformed supply chain interactions in many industries, yet little research explored its implementation by Architecture, Engineering and Construction (AEC) supply chain firms. E-trading relies on commercial information exchange by supply chain partners which is generally adopted through intermediary technology partners (Hub Providers) to facilitate the accurate and timely communication of transactional data between buyers and supplier. A case study was conducted to explore the challenges and barriers to implementation of cross-firm commercial information exchange. The study primarily involved investigation of the interfaces between software development and organizational functions assisting with the electronic exchange of commercial information (eCIX) implementation. Findings from the case study show that implementation of commercial information exchange is not an easy task with several themes of factors to be considered during delivery of such projects, namely technical, coordination, integration and organizational. The study contributes to the knowledge and deployment of e-trading solutions within the context of AEC firms, and should be of interest to the practitioners contemplating similar projects. Journal: Construction Management and Economics Pages: 898-918 Issue: 12 Volume: 34 Year: 2016 Month: 12 X-DOI: 10.1080/01446193.2016.1211718 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1211718 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:12:p:898-918 Template-Type: ReDIF-Article 1.0 Author-Name: Jun Wang Author-X-Name-First: Jun Author-X-Name-Last: Wang Author-Name: Wenchi Shou Author-X-Name-First: Wenchi Author-X-Name-Last: Shou Author-Name: Xiangyu Wang Author-X-Name-First: Xiangyu Author-X-Name-Last: Wang Author-Name: Peng Wu Author-X-Name-First: Peng Author-X-Name-Last: Wu Title: Developing and evaluating a framework of total constraint management for improving workflow in liquefied natural gas construction Abstract: Liquefied natural gas projects are complex and full of variability. Their plan reliability is affected by constraints arising from engineering, supply chains and construction site. Effective management of these constraints is critical to reducing project uncertainties and improve workflow. However, current approaches for constraint removal are fragmented and heavily rely on human’s commitments because the underlying data for decision-making are static and outdated. In order to tackle this problem, this paper proposes a framework of total constraint management (TCM), which consists of three main parts: constraint modelling, constraint monitoring and constraint removal. Information technologies (i.e. building information modelling, radio frequency identification, barcoding, laser scanning and photogrammetry) are also discussed and incorporated into the TCM framework so as to make it more practical and effective. A laboratory-based experiment was developed to demonstrate and evaluate the framework. The results showed that successful implementation of TCM could significantly improve construction workflow and productivity. Journal: Construction Management and Economics Pages: 859-874 Issue: 12 Volume: 34 Year: 2016 Month: 12 X-DOI: 10.1080/01446193.2016.1227460 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1227460 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:12:p:859-874 Template-Type: ReDIF-Article 1.0 Author-Name: Pablo Ballesteros-Pérez Author-X-Name-First: Pablo Author-X-Name-Last: Ballesteros-Pérez Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: Estimating the number of new and repeated bidders in construction auctions Abstract: The number of new bidders – bidders from whom there is no previous registered participation – is an important variable in most bid tender forecasting models, since the unknown competitive profile of the former strongly limits the predictive accuracy of the latter. Analogously, when a bidder considers entering a bid or when an auctioneer is handling a procurement auction, assessing the likely proportion of experienced bidders is considered an important aspect, as some strategic decisions or even the awarding criteria might differ. However, estimating the number of bidders in a future auction that have not submitted a single bid yet is difficult, since there is no data at all linking their potential participation, an essential requirement for the implementation of any forecasting or estimation method. A practical approach is derived for determining the expected proportion of new bidders to frequent bidders as a function of the population of potential bidders. A multinomial model useful for selective and Open tendering is proposed and its performance is validated with a dataset of actual construction auctions. Final remarks concern the valuable information provided by the model to an enduring unsolved bidding problem and the prospects for new research continuations. Journal: Construction Management and Economics Pages: 919-934 Issue: 12 Volume: 34 Year: 2016 Month: 12 X-DOI: 10.1080/01446193.2016.1231408 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1231408 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:12:p:919-934 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Editorial Journal: Construction Management and Economics Pages: 843-844 Issue: 12 Volume: 34 Year: 2016 Month: 12 X-DOI: 10.1080/01446193.2016.1240843 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1240843 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:12:p:843-844 Template-Type: ReDIF-Article 1.0 Author-Name: Hannes Lindblad Author-X-Name-First: Hannes Author-X-Name-Last: Lindblad Title: Black boxing BIM: the public client’s strategy in BIM implementation Abstract: Building information modelling (BIM) is widely discussed in both industry and academia and studies have argued that public clients play an important role in industry’s implementation of BIM. While public client initiatives have gained much interest in previous research, there is still a lack of knowledge exploring the public clients’ role and choice of strategies when implementing BIM with the aim to change industry. Based on a case study of BIM implementation at the largest infrastructure client in Sweden, this paper applies the theory sociology of translation to explore the role of the public client as a driver for industry change and the strategy used during this process. The case study shows how the public client tries to influence its own organization and the construction industry as a whole. Findings show that the main strategy for enrolling actors to implement BIM is to demand its use in the procurement of all construction projects, thereby attempting to establish the BIM issue as a Black Box. A Black Box, a locked network element, which includes associated inscriptions aimed at prescribing BIM use in projects conducted by this client. The acceptance of this Black Box has however been problematic, resulting in a diverse influence on the demand for BIM in procured construction projects. Journal: Construction Management and Economics Pages: 1-12 Issue: 1 Volume: 37 Year: 2019 Month: 1 X-DOI: 10.1080/01446193.2018.1472385 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1472385 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:1:p:1-12 Template-Type: ReDIF-Article 1.0 Author-Name: Leentje Volker Author-X-Name-First: Leentje Author-X-Name-Last: Volker Title: Looking out to look in: inspiration from social sciences for construction management research Abstract: In reaction to the recent call for critical debate in the field of construction management research, I argue that we should embrace the richness of adjacent fields of study in order to dynamically develop our own and face the plethora of contemporary societal challenges that exist in our industry. I introduce the concepts of other-than-rational thinking in decision-making and multiplicity in management responses as examples of inspirational sources from social sciences that would contribute to truly understanding the driving forces of construction management processes. I connect these concepts to contemporary studies in construction management and share my experiences with several positive collaborative approaches in conducting construction management research. Journal: Construction Management and Economics Pages: 13-23 Issue: 1 Volume: 37 Year: 2019 Month: 1 X-DOI: 10.1080/01446193.2018.1473619 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1473619 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:1:p:13-23 Template-Type: ReDIF-Article 1.0 Author-Name: M. van den Boomen Author-X-Name-First: M. Author-X-Name-Last: van den Boomen Author-Name: M. T. J. Spaan Author-X-Name-First: M. T. J. Author-X-Name-Last: Spaan Author-Name: R. Schoenmaker Author-X-Name-First: R. Author-X-Name-Last: Schoenmaker Author-Name: A. R. M. Wolfert Author-X-Name-First: A. R. M. Author-X-Name-Last: Wolfert Title: Untangling decision tree and real options analyses: a public infrastructure case study dealing with political decisions, structural integrity and price uncertainty Abstract: Managerial flexibility in infrastructure investment and replacement decisions adds value. Real options analysis (ROA) captures this value under uncertain market prices. The concept of ROA is that future unfavourable payoffs can be deferred as soon as more information about market prices becomes available. The popularity of ROA is seen in a growing number of case studies on real assets. Despite its increasing popularity, ROA has not gained a foothold in public infrastructure decision making. One of the difficulties in the application of ROA is the required estimation of market variables. To avoid this, a simplified but not correct version of ROA is easily applied, referred to as a Decision Tree Approach (DTA) to ROA. Another difficulty is that infrastructure assets are subject to other types of uncertainties, defined here as asset uncertainties. This study investigates the value of managerial flexibility in a public infrastructure replacement decision. The uncertainty drivers are the strength of a bridge, political decisions regarding traffic flow and the price development of construction costs. Three valuation approaches are compared: DTA, ROA and the DT approach to ROA. Although it is complex, ROA certainly adds value in public infrastructure decision making when market price uncertainty is prevalent. However, in the absence of reasonable estimates of market variables, the DT approach to ROA is the best alternative. In the absence of market price uncertainties, ROA should be avoided DTA is to be preferred. Journal: Construction Management and Economics Pages: 24-43 Issue: 1 Volume: 37 Year: 2019 Month: 1 X-DOI: 10.1080/01446193.2018.1486510 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1486510 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:1:p:24-43 Template-Type: ReDIF-Article 1.0 Author-Name: Jing Du Author-X-Name-First: Jing Author-X-Name-Last: Du Author-Name: Dong Zhao Author-X-Name-First: Dong Author-X-Name-Last: Zhao Author-Name: Ou Zhang Author-X-Name-First: Ou Author-X-Name-Last: Zhang Title: Impacts of human communication network topology on group optimism bias in Capital Project Planning: a human-subject experiment Abstract: Capital projects are critical to the world’s economy. Despite the advancement of prediction techniques, capital projects still suffer from overly optimistic plans, i.e. tight budgets and schedules. This article focuses on understanding this issue from the perspective of optimism bias, i.e. a psychological bias toward the inclination to be overly optimistic about the chance of success. We hypothesize that human communication network topologies are strong predictors of harmful optimism bias at the group level in project planning. A human-subject experiment was performed to test group optimism bias levels under different communication network topologies. We recruited 103 subjects to estimate the cost of an artificial power plant project. The communication networks were manipulated to reflect different topologies. The subjects’ estimates were compared to a Monte Carlo simulation result based on real historical data to quantify the level of optimism bias at the group level. Preliminary results find that certain human communication network topology leads to more realistic estimates, possibly due to a process of updating individual judgement based on peers’ judgements. The findings of this study are expected to urge further theoretical investigations into the development of simple yet effective decision support systems to reduce decision-making bias in capital project planning. Journal: Construction Management and Economics Pages: 44-60 Issue: 1 Volume: 37 Year: 2019 Month: 1 X-DOI: 10.1080/01446193.2018.1508848 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1508848 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:37:y:2019:i:1:p:44-60 Template-Type: ReDIF-Article 1.0 Author-Name: Susanna Vass Author-X-Name-First: Susanna Author-X-Name-Last: Vass Author-Name: Tina Karrbom Gustavsson Author-X-Name-First: Tina Karrbom Author-X-Name-Last: Gustavsson Title: Challenges when implementing BIM for industry change Abstract: Public clients have been identified as drivers of architectural, engineering and construction (AEC) industry change through their implementation of building information modelling (BIM). Yet, little is known of this implementation process and the associated challenges. This study aims to increase the understanding of what intra- and inter-organizational challenges that arise when a large Swedish public infrastructure client implements BIM to change the work practices of the actors in the Swedish AEC industry. The IT business value model allows for understanding the public client’s implementation of BIM as an IT-supported change process and for understanding the associated intra- and inter-organizational challenges. The findings show nine categories of intra- and inter-organizational challenges related to, for example, demanding BIM in procurement and creating incentives for BIM implementation. The findings show that intra-organizational challenges related to a top-down implementation of BIM, while inter-organizational challenges related to a bottom-up implementation. The impact of these challenges on the public client’s ability to drive AEC industry change by implementing BIM is discussed. The findings contribute with the client perspective to studies on BIM implementation and with an increased understanding of the challenges associated with implementing IT-supported change processes. Journal: Construction Management and Economics Pages: 597-610 Issue: 10 Volume: 35 Year: 2017 Month: 10 X-DOI: 10.1080/01446193.2017.1314519 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1314519 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:10:p:597-610 Template-Type: ReDIF-Article 1.0 Author-Name: Mattias Jacobsson Author-X-Name-First: Mattias Author-X-Name-Last: Jacobsson Author-Name: Henrik C.J. Linderoth Author-X-Name-First: Henrik C.J. Author-X-Name-Last: Linderoth Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Title: The role of industry: an analytical framework to understand ICT transformation within the AEC industry Abstract: Despite wide-ranging research on information and communication technologies (ICT) in the Architecture, Engineering and Construction (AEC) industry, little is known about the role that industry plays in the adoption and use of ICT. Based on observations of how the drivers for ICT use seem to be inconsistent with the industry’s central characteristics, and drawing on information systems (IS) research that demonstrates the role of shared systems of meaning, the purpose here is to develop an analytical framework that explains how industry shapes the adoption and use of ICT. Building on a theoretically driven approach and a case study, a framework is first sketched and then substantiated through empirical illustrations. Three dimensions of industry are highlighted: the socio-cognitive environment, the market and production environment and institutional actors. It is explained how the interplay of these dimensions shapes the way the industry functions, which in turn influence the adoption and use of ICT. The outcomes of the interplay can either be aligned or misaligned with ICT, which explains why certain aligned applications are rapidly adopted, whereas other applications are not. The primary implication is that the framework can aid in analysing the need for structural adaptation when trying to achieve ICT-induced change. Journal: Construction Management and Economics Pages: 611-626 Issue: 10 Volume: 35 Year: 2017 Month: 10 X-DOI: 10.1080/01446193.2017.1315148 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1315148 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:10:p:611-626 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Jemma Bridgeman Author-X-Name-First: Jemma Author-X-Name-Last: Bridgeman Title: Corporate volunteering in the construction industry: motivations, costs and benefits Abstract: Corporate volunteering is a growing global phenomenon. Despite the size and significance of the construction industry, there has been no research into corporate volunteering in this sector which presents special challenges around its highly transitionary, temporary, regulated and project-based culture. To address this gap in knowledge and to answer the need for more scholarship and sector-specific insights in this field, the motives, benefits and costs of corporate volunteering for construction businesses and the volunteers that work for them are explored. Through an in-depth single case study of one of the UK’s largest construction industry corporate volunteering programmes, it is shown that at an individual level, it is not always altruism that motives people to volunteer. Volunteers in construction are also motivated by other factors such as loyalty to their organization, profession and industry, relational/networking opportunities and the reinforcement of technical skills and personal satisfaction derived from helping others which is not normally afforded in work. At a business level the main benefits of volunteering are reputational advantage, recruitment and new skills and access to new knowledge and capabilities. Conceptually, the results indicate that systems theory, empowerment theory, life span theory and social exchange theory would be useful theoretical lenses to take research in this new area of corporate social responsibility forward. It is concluded that further research is needed into different types of volunteering programmes and whether individual benefits experienced by volunteers translate into commercial benefits for the organizations involved. Journal: Construction Management and Economics Pages: 641-653 Issue: 10 Volume: 35 Year: 2017 Month: 10 X-DOI: 10.1080/01446193.2017.1315150 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1315150 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:10:p:641-653 Template-Type: ReDIF-Article 1.0 Author-Name: Athena Roumboutsos Author-X-Name-First: Athena Author-X-Name-Last: Roumboutsos Author-Name: Ancor Suárez Alemán Author-X-Name-First: Ancor Author-X-Name-Last: Suárez Alemán Author-Name: Robert Ågren Author-X-Name-First: Robert Author-X-Name-Last: Ågren Title: Construction firms in public–private partnerships: a place to grow Abstract: Public–Private Partnerships (PPPs) constitute a crucial vehicle in delivering infrastructure. In the transport sector the primary project sponsors are construction companies, which over the last few decades have transformed to strong international actors. In order to study growth strategies stemming from the PPP agreement, a conceptual game theoretic model built on four institutional rationalities (legal, political and scientific in addition to economic) driving economic behaviour is presented. The model indicates that the prevailing strategies are training, acquisitions and step-outs. The former strategy is less efficient than the other two with respect to the single project. The latter two suggest the likelihood of “unproductive investments” influencing infrastructure quality and social benefits. All three strategies lead to market concentration, which has been evidenced in the market. The model only considers construction firm strategies and does not weight the relative importance of the operation phase with respect to the construction one. This would be an extension to the model, which would then also consider operator strategies. In its present form, the model indicates the conditions leading to “unproductive investments” and market concentration and provides the grounds to formulate policy guidelines to limit adverse effects. Journal: Construction Management and Economics Pages: 627-640 Issue: 10 Volume: 35 Year: 2017 Month: 10 X-DOI: 10.1080/01446193.2017.1319573 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1319573 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:10:p:627-640 Template-Type: ReDIF-Article 1.0 Author-Name: Sulafa Badi Author-X-Name-First: Sulafa Author-X-Name-Last: Badi Title: Public sustainable-energy requirements and innovation in UK PFI school projects Abstract: In a bid to understand the relationship between public sector clients’ sustainable energy requirements and innovation, this paper describes a study examining the requirement development process in four private finance initiative (PFI) school projects. A case study approach was adopted to enable a greater understanding of the public sector clients’ activities at the front end of the design process, particularly focusing on requirement identification and the effect of the requirement on private sector actors’ pursuit of an innovative sustainable design. The findings have shown that incentive effects of the requirements are often weak in PFI projects, particularly in relation to the requirement’s specificity and achievability, the inability of requirements such as BREEAM to promote energy efficiency and the low weighting of environmental sustainability on PFI bid evaluation criteria. Taken together, these results offer insight into public authorities in relation to the necessary conditions for the use of requirements as an effective contractual mechanism to encourage innovation for sustainable energy. Journal: Construction Management and Economics Pages: 218-238 Issue: 4 Volume: 35 Year: 2017 Month: 4 X-DOI: 10.1080/01446193.2016.1237034 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1237034 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:4:p:218-238 Template-Type: ReDIF-Article 1.0 Author-Name: F. T. T. Phua Author-X-Name-First: F. T. T. Author-X-Name-Last: Phua Title: Does the built-environment industry attract risk-taking individuals? Abstract: This exploratory research examines whether or not those attracted to professional-level occupations in the built-environment industry are innately physical risk-takers and hence potentially, thereby, more likely to countenance or contribute to physically risky workplace climates. Using individual-level data, the occupational attractiveness of the built-environment industry subsectors of construction management and architecture are each found positively and significantly to be predicted by physical risk-taking propensity, but not by a comparator risk-taking propensity, gambling. Conversely, the occupational attractiveness of a comparator profession in financial services is found to be significantly predicted by gambling risk-taking propensity, but not by physical risk-taking propensity. Although exploratory, our finding that two key professions in the built-environment industry are each discretely found to be attractive to physical risk-takers suggests not only that constituent occupations within the industry, but that the industry as a whole might perhaps engender a self-reinforcing suboptimal workplace safety climate. Accordingly, constituent subsectors of the industry may need both separately and collectively to consider the phenomenon of physical risk-taking propensity amongst the professionals it attracts in order effectively to set and manage the site work-place safety climate that such professionals are ultimately responsible for creating and delivering in a sector fraught with physical risks for site workers. Journal: Construction Management and Economics Pages: 207-217 Issue: 4 Volume: 35 Year: 2017 Month: 4 X-DOI: 10.1080/01446193.2016.1237776 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1237776 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:4:p:207-217 Template-Type: ReDIF-Article 1.0 Author-Name: Hatice Çiğdem Demirel Author-X-Name-First: Hatice Çiğdem Author-X-Name-Last: Demirel Author-Name: Wim Leendertse Author-X-Name-First: Wim Author-X-Name-Last: Leendertse Author-Name: Leentje Volker Author-X-Name-First: Leentje Author-X-Name-Last: Volker Author-Name: Marcel Hertogh Author-X-Name-First: Marcel Author-X-Name-Last: Hertogh Title: Flexibility in PPP contracts – Dealing with potential change in the pre-contract phase of a construction project Abstract: Public Private Partnerships (PPPs) cover a range of possible relationships between public and private parties. PPP contracts are typically used in contexts of great uncertainty, such as large construction and infrastructure projects that are realized over a longer period of time. Hence, a major challenge in PPPs is to keep construction progress cost-efficient and on schedule, under continuously changing circumstances. One way to achieve this is through clever contracting, by proactively anticipating potential change in the planning phase and providing flexible contract mechanisms that enable an effective response. The purpose of this article is to discuss potential changes and the subsequent requirement of flexibility in PPP contracts. By flexibility, we mean the ability of the contract to deal with changing circumstances. We set out to do so by studying the available literature on the subject and by analysing the case study of the Blankenburgverbinding in the Netherlands, a Design, Build, Finance and Maintain (DBFM) project that is currently in its planning phase based on 32 interviews. Our main findings are that the timely and accurate recognition of potential changes, combined with the availability of flexible coping mechanisms, provide the stakeholders with a better understanding of the challenges they face in realizing their aims in the pre-contract phase of projects. This understanding helps to better prepare a PPP contract for potential changes. Journal: Construction Management and Economics Pages: 196-206 Issue: 4 Volume: 35 Year: 2017 Month: 4 X-DOI: 10.1080/01446193.2016.1241414 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1241414 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:4:p:196-206 Template-Type: ReDIF-Article 1.0 Author-Name: Kerstin Hemström Author-X-Name-First: Kerstin Author-X-Name-Last: Hemström Author-Name: Leif Gustavsson Author-X-Name-First: Leif Author-X-Name-Last: Gustavsson Author-Name: Krushna Mahapatra Author-X-Name-First: Krushna Author-X-Name-Last: Mahapatra Title: The sociotechnical regime and Swedish contractor perceptions of structural frames Abstract: To deepen the understanding of the sociotechnical regime that directs the selection of structural frames in multifamily buildings in Sweden, we study the perceptions of contractor representatives. Contract managers (CMs) employed at contractor firms were interviewed regarding their role, the selection of the structural frame and how they perceived different options. The results show that CMs largely influence the selection of the structural frame in multifamily buildings, which are guided by the established concrete-based sociotechnical regime. The regime is maintained through cognitive rules regarding structural frame options and the alignment of skills of construction professionals. Because of their influence and their investments in the skills of construction workers, CMs make important contributions to maintain the regime and the concrete path dependency. Furthermore, the regime varies in strength in different locations. Some locations carry a strong norm to cast concrete frames on site. This makes it more difficult to deviate from the established practice. In other locations, wood-promoting initiatives have changed the cognitive rules associated with the regime. Nonetheless, the sociotechnical regime makes the selection of concrete structural frames beneficial. This prevents wood-framed multifamily buildings from entering common usage, even though such buildings can contribute to mitigating climate change. Journal: Construction Management and Economics Pages: 184-195 Issue: 4 Volume: 35 Year: 2017 Month: 4 X-DOI: 10.1080/01446193.2016.1245428 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1245428 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:4:p:184-195 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Let’s get critical! A call for critical reviews and essays Journal: Construction Management and Economics Pages: 183-183 Issue: 4 Volume: 35 Year: 2017 Month: 4 X-DOI: 10.1080/01446193.2017.1296624 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1296624 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:4:p:183-183 Template-Type: ReDIF-Article 1.0 Author-Name: Anna-Maija Hietajärvi Author-X-Name-First: Anna-Maija Author-X-Name-Last: Hietajärvi Author-Name: Kirsi Aaltonen Author-X-Name-First: Kirsi Author-X-Name-Last: Aaltonen Title: The formation of a collaborative project identity in an infrastructure alliance project Abstract: Inter-organizational projects struggle to build a sense of joint belonging and a culture of cooperation. In evaluating the social processes of collaboration in inter-organizational projects, organizational identity is considered a core concept. To extend existing knowledge of how collaborative identity is formed in inter-organizational infrastructure projects, the study investigates how the specific characteristics of temporary organizations (time, team, task and context) influence identity formation activities. A case study of the first Finnish infrastructure alliance project identifies six key activities supporting the formation of collaborative project identity: (1) articulating a joint vision for collaborative project identity; (2) converging on mutual conceptions of collaborative project alliance philosophy; (3) attaining a shared collaborative mentality; (4) designing ways of working with multiple identities; (5) attaining distinctiveness and (6) legitimizing activities. The findings indicate that identity formation activities are context-dependent, and that the formation of organizational identity differs between temporary and permanent organizations. The findings illuminate how managers can build a collaborative project identity. Journal: Construction Management and Economics Pages: 1-21 Issue: 1 Volume: 36 Year: 2018 Month: 1 X-DOI: 10.1080/01446193.2017.1315149 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1315149 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:1:p:1-21 Template-Type: ReDIF-Article 1.0 Author-Name: Lars Peter Andersen Author-X-Name-First: Lars Peter Author-X-Name-Last: Andersen Author-Name: Line Nørdam Author-X-Name-First: Line Author-X-Name-Last: Nørdam Author-Name: Thomas Joensson Author-X-Name-First: Thomas Author-X-Name-Last: Joensson Author-Name: Pete Kines Author-X-Name-First: Pete Author-X-Name-Last: Kines Author-Name: Kent J. Nielsen Author-X-Name-First: Kent J. Author-X-Name-Last: Nielsen Title: Social identity, safety climate and self-reported accidents among construction workers Abstract: The construction industry has one of the highest frequencies of work-related accidents. We examined whether construction workers predominantly identify themselves in terms of their workgroup or in terms of the construction site. In addition, we examined the associations between social identity and safety climate, and how these constructs are associated with work-related accidents. The analyses were based on questionnaire responses from 478 construction workers from two large construction sites, and the methods involved structural equation modeling. Results showed that the workers identified themselves primarily with their workgroup, and to a lesser degree with the construction site. Social identity and safety climate were related both at the workgroup and construction site levels, meaning that social identity may be an antecedent for safety climate. The association between social identity and safety climate was stronger at the workgroup level than at the construction site level. Finally, safety climate at both levels was inversely associated with self-reported accidents, with the strongest association at the workgroup level. A focus on improving safety climate, particularly by integrating initiatives at both the workgroup and management level, may have the potential to improve safety performance and thus decrease the risk of accidents and injuries on construction sites. Journal: Construction Management and Economics Pages: 22-31 Issue: 1 Volume: 36 Year: 2018 Month: 1 X-DOI: 10.1080/01446193.2017.1339360 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1339360 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:1:p:22-31 Template-Type: ReDIF-Article 1.0 Author-Name: Antti Peltokorpi Author-X-Name-First: Antti Author-X-Name-Last: Peltokorpi Author-Name: Hylton Olivieri Author-X-Name-First: Hylton Author-X-Name-Last: Olivieri Author-Name: Ariovaldo Denis Granja Author-X-Name-First: Ariovaldo Denis Author-X-Name-Last: Granja Author-Name: Olli Seppänen Author-X-Name-First: Olli Author-X-Name-Last: Seppänen Title: Categorizing modularization strategies to achieve various objectives of building investments Abstract: Modularization has recently attracted considerable interest among academics and practitioners. In the construction industry, several modular solutions have been introduced and examined; however, hardly any study comprehensively classifies the different modularization strategies according to their possibility to achieve various objectives of building investments. This research aims to develop a framework for identifying and classifying modularization strategies in construction according to their suitability to achieve the specific outcomes intended for a building or its subsystem. Using the literature on product modularity, product platforms and production strategies as a basis, this study has developed a theoretical framework that proposes connections between the main objectives of a building investment and the dimensions of modularization strategies. The framework is elaborated by testing the propositions, based on an empirical analysis of nine real-life case studies. The findings reveal that modularization can be a suitable approach to develop an innovative design solution; improve a project’s quality, cost and schedule performance; and enable flexibility in building use and maintenance. However, suggestions for achieving these objectives vary from project organization-driven to collaborative, integrated or supplier-driven modularization strategies. Developers, owners, contractors and module suppliers can use the framework when positioning and developing their roles in the construction supply chain. Journal: Construction Management and Economics Pages: 32-48 Issue: 1 Volume: 36 Year: 2018 Month: 1 X-DOI: 10.1080/01446193.2017.1353119 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1353119 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:1:p:32-48 Template-Type: ReDIF-Article 1.0 Author-Name: Viktoria Sundquist Author-X-Name-First: Viktoria Author-X-Name-Last: Sundquist Author-Name: Lars-Erik Gadde Author-X-Name-First: Lars-Erik Author-X-Name-Last: Gadde Author-Name: Kajsa Hulthén Author-X-Name-First: Kajsa Author-X-Name-Last: Hulthén Title: Reorganizing construction logistics for improved performance Abstract: Previous research indicates that logistics reorganizing can contribute to improved performance in the construction industry. In this paper, the opportunities for such reorganizing are investigated by focusing on the connection between logistics operations at the construction site and operations undertaken before building materials land at sites. The aims of the study are: (1) to empirically explore strategic actions to reorganize construction logistics by improving the connections between on-site and off-site logistics, and (2) to develop a theoretical framework for analysis of potential options for reorganizing. The empirical inquiry involves a case study of a logistics specialist’s efforts to reorganize on-site logistics and the associated consequences for off-site operations. The study is based on 28 interviews with representatives of 13 organizations. The study provides two types of contributions. First, the theoretical framework, rooted in industrial network theory, enables analysis of reorganizing of activities, resources and actors to improve logistics performance. Second, the empirical study shows that a logistics specialist can improve on-site logistics substantially. However, such reorganizing requires adjustments of off-site logistics that may be resource demanding. Therefore, effective connecting of on-site and off-site operations calls for extended interaction between the actors in terms of joint planning and exchange of information. Journal: Construction Management and Economics Pages: 49-65 Issue: 1 Volume: 36 Year: 2018 Month: 1 X-DOI: 10.1080/01446193.2017.1356931 File-URL: http://hdl.handle.net/10.1080/01446193.2017.1356931 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:36:y:2018:i:1:p:49-65 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Editorial Journal: Construction Management & Economics Pages: 651-653 Issue: 8 Volume: 20 Year: 2002 X-DOI: 10.1080/01446190220000147550 File-URL: http://hdl.handle.net/10.1080/01446190220000147550 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:8:p:651-653 Template-Type: ReDIF-Article 1.0 Author-Name: W. K. Fu Author-X-Name-First: W. K. Author-X-Name-Last: Fu Author-Name: Derek S. Drew Author-X-Name-First: Derek S. Author-X-Name-Last: Drew Author-Name: H. P. Lo Author-X-Name-First: H. P. Author-X-Name-Last: Lo Title: The effect of experience on contractors' competitiveness in recurrent bidding Abstract: This paper considers the relationship between bidding competitiveness, organizational learning and experience and it measures the effect of contractors' bidding experience on competitiveness in recurrent bidding, a notion that conceptualizes a continuous decision-making process in which experiential learning plays a key role. The data analysis demonstrates that contractors who bid more frequently over a six-year period are more competitive than contractors who bid occasionally. It is found that greater bidding competitiveness is positively correlated with the frequency of bidding attempts. An analysis of contractors' bidding performance on a pairwise basis supports this finding. Not only does the pairwise analysis show that the bidding competitiveness of experienced contractors who bid frequently is greater, but also that experienced contractors' bidding attempts fall within a relatively small competitiveness range when compared with that of contractors who only bid occasionally. A key finding of this paper is the existence of some experienced contractors, who may be perceived as being ‘experienced market players’, having the attribute of a more competitive and consistent bidding performance. This research should be useful to procurers looking to prequalify contractors on the basis of experience and to contractors in analysing their bidding performance and/or their competitors' bidding performance. Journal: Construction Management & Economics Pages: 655-666 Issue: 8 Volume: 20 Year: 2002 X-DOI: 10.1080/0144619022000014060 File-URL: http://hdl.handle.net/10.1080/0144619022000014060 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:8:p:655-666 Template-Type: ReDIF-Article 1.0 Author-Name: H. Zhang Author-X-Name-First: H. Author-X-Name-Last: Zhang Author-Name: C. M. Tam Author-X-Name-First: C. M. Author-X-Name-Last: Tam Author-Name: Jonathan J. Shi Author-X-Name-First: Jonathan J. Author-X-Name-Last: Shi Title: Simulation-based methodology for project scheduling Abstract: This paper describes a discrete-event simulation that incorporates the critical path method (CPM) in generating comprehensive information for construction project scheduling or planning. An activity-based graphical model able to consider complexities in construction, for example, unbalanced logical dependencies, unbalanced resource involvements and repetitive activity operation is proposed. An activity scanning (AS)-based forward pass algorithm for early-time information and a backward search algorithm for late-time information are developed. The simulation results that include both resource utilization statistics and late-time information (i.e. latest start or finish time and total float (TF)) of every activity for each cycle of operation cannot be easily achieved through traditional simulation or CPM. Illustrations demonstrate the advantages of the activity-based graphical model and the impacts of resource allocation policies on the schedule. The proposed methodology aims at widening the application of construction simulation by providing float time information and enhanced modelling capability. Journal: Construction Management & Economics Pages: 667-678 Issue: 8 Volume: 20 Year: 2002 X-DOI: 10.1080/0144619022000014088 File-URL: http://hdl.handle.net/10.1080/0144619022000014088 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:8:p:667-678 Template-Type: ReDIF-Article 1.0 Author-Name: Alan Griffith Author-X-Name-First: Alan Author-X-Name-Last: Griffith Title: Key considerations for developing corporate and operational approaches for managing the small building works portfolio of large client organizations Abstract: Many large organizations, which act in the capacity of clients to the construction industry, own and occupy extensive, diverse and often geographically dispersed property estates. To maintain their upkeep and use, these estates often require very considerable annual expenditure on maintenance, alterations, refurbishment and small-scale new building works. Activities encompassing these types form the category of small building works, a sub-sector of the construction industry which amounts to around £9 billion, or 20%, of annual UK total construction output. The effective management of small building works in the context of any organization with large property holdings is essential, as better management of the small building works portfolio can contribute significantly to the business of the organization. This paper contributes new data and adds to the synthesis of findings from research studies into small works, supported by governmental and industry sources and conducted over a 10-year period. It aims to assist in the development of corporate and operational approaches for managing the small building works portfolio of large organizations by highlighting key considerations. These are linked to a dynamic control cycle, or system, to assist organizations in implementing practice based on the considerations made. Journal: Construction Management & Economics Pages: 679-687 Issue: 8 Volume: 20 Year: 2002 X-DOI: 10.1080/0144619022000014042 File-URL: http://hdl.handle.net/10.1080/0144619022000014042 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:8:p:679-687 Template-Type: ReDIF-Article 1.0 Author-Name: Stephen Fox Author-X-Name-First: Stephen Author-X-Name-Last: Fox Author-Name: Laurence Marsh Author-X-Name-First: Laurence Author-X-Name-Last: Marsh Author-Name: Graham Cockerham Author-X-Name-First: Graham Author-X-Name-Last: Cockerham Title: Constructability rules: guidelines for successful application to bespoke buildings Abstract: It is widely recognized that building design has a significant impact on construction productivity and quality. Constructability rules are one way of transferring construction knowledge to building designers. These rules are statements, such as ‘design for minimum time below ground’, which encapsulate a specific aspect of construction best practice. Although constructability rules are relatively easy to formulate and/or obtain, there is little evidence of their successful application. Indeed, architects continue to be held responsible for productivity and quality problems because of their lack of construction knowledge. This paper reports research that informed and included the development of guidelines for successful application of constructability rules to bespoke buildings - those being buildings that are designed to fulfil the requirements of one particular client and/or a single specific location. Findings suggest that there are actions that can be taken to widen the application of rules and increase their success. Potential sources for rules are described. Guidelines are introduced, and information about how they can be actioned by different construction organizations is provided. Journal: Construction Management & Economics Pages: 689-696 Issue: 8 Volume: 20 Year: 2002 X-DOI: 10.1080/01446190210163606 File-URL: http://hdl.handle.net/10.1080/01446190210163606 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:8:p:689-696 Template-Type: ReDIF-Article 1.0 Author-Name: Andrew Agapiou Author-X-Name-First: Andrew Author-X-Name-Last: Agapiou Title: Perceptions of gender roles and attitudes toward work among male and female operatives in the Scottish construction industry Abstract: The predominant image of construction is that of a male-dominated industry requiring brute strength and a good tolerance for outdoor conditions, inclement weather and bad language. Reconciling this image with women's participation in the construction industry is problematic. However, there are early signs of a cultural shift in the industry. This paper presents an empirical review of wome's roles within the industry and the ways in which people make sense of their working experience when traditional gender roles are challenged. Based on qualitative research, the study found that men in the industry regarded as the gatekeepers are now finding ways to respond to and make sense of a changing workplace, and the realities that women are now actively encouraged to participate, legally protected against discrimination and more highly represented in non-traditional areas of the construction industry. Women are also findings ways as apprentices and tradespeople to position themselves within this new environment. They identify ways of working that are more likely to ensure a smooth experience for themselves. While the stimulus for the changing face of the workplace is the notion of gender equality, the responses are not gender neutral. All players are trying to negotiate ways to integrate each other into a new environment in a manner which allows them to comfortably reconcile issues of gender. Journal: Construction Management & Economics Pages: 697-705 Issue: 8 Volume: 20 Year: 2002 X-DOI: 10.1080/0144619021000024989 File-URL: http://hdl.handle.net/10.1080/0144619021000024989 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:8:p:697-705 Template-Type: ReDIF-Article 1.0 Author-Name: Low Sui Pheng Author-X-Name-First: Low Sui Author-X-Name-Last: Pheng Author-Name: Tan Sui Ling Gracia Author-X-Name-First: Tan Sui Ling Author-X-Name-Last: Gracia Title: Relationship marketing: a survey of QS firms in Singapore Abstract: In spite of the misperceptions of marketing in some quantity surveying (QS) firms, QS firms have generally embraced the general concepts of relationship marketing (RM) as part of their business strategy because relationships are considered to be important to a service-oriented business. However, this practice could be improved by adopting a more comprehensive approach to RM, such as the adoption of total relationship marketing (TRM) principles in their organizations. The focus of this study is to examine the perceptions and practices of RM of QS firms in the Singapore construction industry. Survey findings from 22 QS firms were examined in this study. The findings suggest that QS firms can focus on RM and TRM, with traditional marketing principles forming the basis of their marketing efforts. Journal: Construction Management & Economics Pages: 707-721 Issue: 8 Volume: 20 Year: 2002 X-DOI: 10.1080/0144619022000014051 File-URL: http://hdl.handle.net/10.1080/0144619022000014051 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:8:p:707-721 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Book reviews Journal: Construction Management & Economics Pages: 723-728 Issue: 8 Volume: 20 Year: 2002 X-DOI: 10.1080/0144619022000035030 File-URL: http://hdl.handle.net/10.1080/0144619022000035030 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:8:p:723-728 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Forthcoming events Journal: Construction Management & Economics Pages: 743-743 Issue: 8 Volume: 20 Year: 2002 X-DOI: 10.1080/014461902321114056 File-URL: http://hdl.handle.net/10.1080/014461902321114056 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:20:y:2002:i:8:p:743-743 Template-Type: ReDIF-Article 1.0 Author-Name: Martine Buser Author-X-Name-First: Martine Author-X-Name-Last: Buser Author-Name: Veronica Carlsson Author-X-Name-First: Veronica Author-X-Name-Last: Carlsson Title: What you see is not what you get: single-family house renovation and energy retrofit seen through the lens of sociomateriality Abstract: Representing 30% of the energy consumption in Sweden, the built environment is a clear contender for climate mitigation initiatives. The substantial stock of single-family houses presents ample opportunities to engage in energy-saving refurbishments. However, despite political pressure, only a minority of these refurbishments includes low-energy retrofit. To explain this slow take-off, studies have mostly focused on the necessity to better link new technical solutions with user needs and behaviours. We propose to extend this analysis to a broader set of actors including the craftsmen contracted to carry out the refurbishments and the houses themselves with their specific features and characteristics. To do so, we build our contribution on the concept of sociomateriality. This perspective argues that technological artefacts are socially constructed, but recognizes that materiality also has a role to play. Drawing on the experiences of 24 small craftsman firms, 8 houses as well as their owners, our method comprises interviews, workshops and participant observation complemented by an in-depth case study. The results show many differentiated representations of the renovation process under scrutiny. All these representations need to be understood and to a certain degree aligned in order to achieve successful retrofits. Journal: Construction Management and Economics Pages: 276-287 Issue: 5 Volume: 35 Year: 2017 Month: 5 X-DOI: 10.1080/01446193.2016.1250929 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1250929 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:5:p:276-287 Template-Type: ReDIF-Article 1.0 Author-Name: Edward Goh Author-X-Name-First: Edward Author-X-Name-Last: Goh Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: The impacts of industrialization on construction subcontractors: a resource based view Abstract: Industrialization of the construction process is increasing around the world due to its potential to improve safety, sustainability, effectiveness, productivity and efficiency. While there has been research into the impacts of various forms of industrialized construction on the construction sector, surprisingly there has been little research into the impacts on subcontractors. The lack of subcontractor’s voice in the industrialization debate is important to address since they operate at the coalface of the industry where the impacts of such changes will have a significant impact. The resource based view of the firm (RBV) is used as a theoretical lens to study these potential impacts through interviews with senior executives and managers of six major subcontracting firms which have worked with off-site bathroom pod technologies in Australia. It is found that the key subcontractor resources affected by this off-site technology are human, financial, intellectual and social and that subcontractors will need to pursue strategies which develop new skills, knowledge, networks and deeper supply chain collaborations if they are to turn the potential risks associated with off-site into potential opportunities to achieve competitive advantage. Journal: Construction Management and Economics Pages: 288-304 Issue: 5 Volume: 35 Year: 2017 Month: 5 X-DOI: 10.1080/01446193.2016.1253856 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1253856 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:5:p:288-304 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Michelle Turner Author-X-Name-First: Michelle Author-X-Name-Last: Turner Title: Promoting construction workers’ health: a multi-level system perspective Abstract: Construction workers suffer poor mental and physical health. To address this, organizations have implemented behavioural health promotion programmes. However, targeting workers’ lifestyle behaviour without addressing relevant environmental factors is unlikely to produce significant or sustained improvement. An ecological perspective offers a different way of understanding the determinants of health, reflecting the interplay of factors at multiple levels and the dynamic, reciprocal and non-linear relationships between them. Qualitative data collected during focus groups and in interviews with workers and managers were analysed to explore factors impacting the effectiveness of a health promotion programme implemented at two work sites in Queensland, Australia. A qualitative causal loop diagram identifying determinants of construction workers’ health behaviour was developed. The findings suggest that the adoption of healthy behaviours is influenced by factors operating at and between individual, family, workplace and industry levels. These factors suggest key leverage points that can be addressed in the design of future health promotion interventions for the construction industry. The research provides qualitative evidence of the need to consider workers’ health in a holistic way and develop multi-level strategies to produce improved health behaviour and outcomes in the construction industry. Journal: Construction Management and Economics Pages: 239-253 Issue: 5 Volume: 35 Year: 2017 Month: 5 X-DOI: 10.1080/01446193.2016.1274828 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1274828 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:5:p:239-253 Template-Type: ReDIF-Article 1.0 Author-Name: Valerie Francis Author-X-Name-First: Valerie Author-X-Name-Last: Francis Title: What influences professional women’s career advancement in construction? Abstract: Research on professional women’s careers in the construction industry has focused on explanations for their under-achievement and the barriers they experience, many of which are outside their personal control. However, some women are progressing, so it is important to understand what facilitates this process. Using a theoretical framework, involving individual, interpersonal and organizational factors, a cross-sectional correlational field study involving 456 professional women investigated the effect of a range of variables on career advancement. Individual factors rather than interpersonal and organizational factors were found to have the greatest influence on women’s career progression. This finding, contrary to previous women in construction research, indicates a “contest”, rather than “sponsored”, career mobility path. The research contributes to the understanding of the career advancement of women, highlighting issues with previous research which has identified mentoring, networks and other organizational support mechanisms as valuable to women’s advancement. It provides evidence that promotional processes have a potential gender bias, and while networks, mentoring and other forms of organizational support do not assist women with promotion, they are a valuable deterrent to women’s departure from an industry struggling with low female participation and retention. Journal: Construction Management and Economics Pages: 254-275 Issue: 5 Volume: 35 Year: 2017 Month: 5 X-DOI: 10.1080/01446193.2016.1277026 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1277026 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:35:y:2017:i:5:p:254-275 Template-Type: ReDIF-Article 1.0 Author-Name: Anders Pousette Author-X-Name-First: Anders Author-X-Name-Last: Pousette Author-Name: Marianne Törner Author-X-Name-First: Marianne Author-X-Name-Last: Törner Title: Effects of systematic work preparation meetings on safety climate and psychosocial conditions in the construction industry Abstract: The aim of this study was to evaluate the effect of an intervention comprising education and support in performing frequent and structured work preparation meetings with broad participation. Such work preparation meetings were expected to have positive effects on safety climate by emphasizing the value of safety at the work site, and on perceived influence at work. The study was a longitudinal, matched before and after questionnaire study, with six construction sites within a large Swedish construction company, randomly assigned to the intervention or the comparison group. Contrary to expectations, the intervention group reported a decrease in safety climate, while this increased in the comparison group. Perceived influence at work showed a tendency to decrease at the interventions sites. Frequent work preparation meetings may provide ample opportunity for obtaining perceptual safety climate cues. But the effect is dependent on how these meetings are performed, and what priorities are conveyed. Journal: Construction Management and Economics Pages: 355-365 Issue: 6 Volume: 34 Year: 2016 Month: 6 X-DOI: 10.1080/01446193.2016.1189584 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1189584 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:6:p:355-365 Template-Type: ReDIF-Article 1.0 Author-Name: Tara Brooks Author-X-Name-First: Tara Author-X-Name-Last: Brooks Author-Name: John Spillane Author-X-Name-First: John Author-X-Name-Last: Spillane Author-Name: Paul Tansey Author-X-Name-First: Paul Author-X-Name-Last: Tansey Author-Name: Caroline Hendron Author-X-Name-First: Caroline Author-X-Name-Last: Hendron Title: The impact of the recent economic recession on the operation of the NEC contract in Northern Ireland Abstract: In May 2006, the New Engineering Contract (NEC) contract was introduced as the preferred contract for Northern Ireland public sector works. This was subsequently followed by the 2007 economic crash and ensuing recession, which continues to affect the Northern Ireland Construction Industry, to a greater extent than the remainder of the United Kingdom. However, use of the NEC contract has increased during this period, particularly in the public sector. There has been debate in the literature regarding the impact of the NEC contract on adversarial behaviour, but little consideration of the impact of external economic factors on the use of the NEC contract. Using a sequential mixed method approach, the study aims to fill this gap in knowledge through examination of the impact the economic downturn has had on the operation of the NEC contract in Northern Ireland. Qualitative and quantitative findings show that the demands placed by the NEC contract, and the effects of the economic recession, have exerted opposing forces on contract implementation, thus hindering its execution. The findings can lead to a deeper understanding, in the context of both industry and academia, of situations where a lack of resources may negatively impact the operation of the NEC contract. Journal: Construction Management and Economics Pages: 393-417 Issue: 6 Volume: 34 Year: 2016 Month: 6 X-DOI: 10.1080/01446193.2016.1194522 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1194522 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:6:p:393-417 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Corrigendum Journal: Construction Management and Economics Pages: 432-432 Issue: 6 Volume: 34 Year: 2016 Month: 6 X-DOI: 10.1080/01446193.2016.1197500 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1197500 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:6:p:432-432 Template-Type: ReDIF-Article 1.0 Author-Name: Abigail Robson Author-X-Name-First: Abigail Author-X-Name-Last: Robson Author-Name: David Boyd Author-X-Name-First: David Author-X-Name-Last: Boyd Author-Name: Niraj Thurairajah Author-X-Name-First: Niraj Author-X-Name-Last: Thurairajah Title: Studying ‘cost as information’ to account for construction improvements Abstract: Contractors throughout the construction supply chain develop and use cost information. By treating ‘cost as information’, insights are generated into how cost information is created and flows from work carried out to a client cost. A case study of a main contractor’s supply chain involved semi-structured interviews, workshops and document reviews. We considered whether contractors’ current costing practices used for the purpose of pricing and cost control could support decision-making about improvements through the supply chain. The results show that firms recognize that current costing practices do not provide a good representation of work carried out. Cost information that is useful in a narrative that seeks to improve site operations is either not created or hidden in layers of assumptions and lost as it does not cross the boundaries between organizations. This implies that the implementation of current practices of costing in building information modelling will not increase the effectiveness of modelling construction costs for the purpose of improvements. However, cost information that is useful in decision-making about improvements could be created. This could be achieved but requires a systemic change, where new representations of cost are tied to work processes used within more stable procurement relationships. Journal: Construction Management and Economics Pages: 418-431 Issue: 6 Volume: 34 Year: 2016 Month: 6 X-DOI: 10.1080/01446193.2016.1200734 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1200734 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:6:p:418-431 Template-Type: ReDIF-Article 1.0 Author-Name: Ruwini Edirisinghe Author-X-Name-First: Ruwini Author-X-Name-Last: Edirisinghe Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Title: Exploring the potential for the use of video to communicate safety information to construction workers: case studies of organizational use Abstract: Legislation requires employers to provide health and safety (H&S) training to workers and communicate safety rules, policies and procedures to them in a way they understand. As the construction industry has an increasingly multicultural and multilingual workforce, conventional written and verbal safety communication is of limited effectiveness. CodeSafe Solutions, has developed an innovative method of communicating H&S information to field-based workers using digital media. The potential of the system was explored and two organizations in the Australian construction industry were used. Qualitative data from in-depth interviews of safety managers and workers involved in system implementation and quantitative data such as incident reports and video usage were analysed. Managers perceived the CodeSafe system to be beneficial and well received by workers. In one organization, the introduction of the CodeSafe system coincided with a reduction in injury rates. However, causal inferences about the impact of the system cannot be made. Workers involved in making the films believed films would be an effective communication tool. However, barriers to implementation of the technology include workers’ reluctance to use personal smart phones, limited internet connectivity, and organizational and national regulations on mobile phone use on construction sites. Journal: Construction Management and Economics Pages: 366-376 Issue: 6 Volume: 34 Year: 2016 Month: 6 X-DOI: 10.1080/01446193.2016.1200736 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1200736 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:6:p:366-376 Template-Type: ReDIF-Article 1.0 Author-Name: Michelle Turner Author-X-Name-First: Michelle Author-X-Name-Last: Turner Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Title: Work–life fit: identification of demand and resource typologies within a systems framework Abstract: Work–life fit occurs when people have the resources required to meet demands such that role performance (both at work and in non-work life domains) is effective. Interviews were conducted with 59 construction workers based in Melbourne, Australia to explore how demands and resources were experienced. Using a systems framework, data were analysed using thematic analysis. Results identified two demand typologies associated with demand-to-demand interaction. Demands operating as ‘influencers’ have a major impact on the conditions of the interdependent demand, while demands operating as ‘creators’ generate a new demand and shape the conditions of that demand. One resource typology related to resource–demand interaction was identified. ‘Enabling resources’ enable an individual to manage multiple demands across multiple domains, and may also enable an individual to manage multiple demands within a single domain. A new conceptual contribution is made to an area in which theory is under-developed, by adopting a systems approach to understanding the dynamic interactions between demands and resources. A lack of fit is damaging for the individual; therefore, it is useful to know that demands and resources are interdependent and these interdependencies will vary according to individuals. Using a systems approach to understanding demands and resources will be helpful to organizations seeking to support workers to achieve optimal work–life fit. Journal: Construction Management and Economics Pages: 377-392 Issue: 6 Volume: 34 Year: 2016 Month: 6 X-DOI: 10.1080/01446193.2016.1200737 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1200737 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:6:p:377-392 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: Editorial Journal: Construction Management and Economics Pages: 353-354 Issue: 6 Volume: 34 Year: 2016 Month: 6 X-DOI: 10.1080/01446193.2016.1204800 File-URL: http://hdl.handle.net/10.1080/01446193.2016.1204800 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:34:y:2016:i:6:p:353-354 Template-Type: ReDIF-Article 1.0 Author-Name: Timur Narbaev Author-X-Name-First: Timur Author-X-Name-Last: Narbaev Author-Name: Alberto De Marco Author-X-Name-First: Alberto Author-X-Name-Last: De Marco Author-Name: Nurlan Orazalin Author-X-Name-First: Nurlan Author-X-Name-Last: Orazalin Title: A multi-disciplinary meta-review of the public–private partnerships research Abstract: Public-private partnerships (PPP) research is very diverse. This field of research covers different topics across multiple disciplines and is disseminated in many journals. This has led to numerous review studies with a single discipline focus that apply mostly subjective or descriptive analyses. With the purpose of providing an integrated overview of all the disciplines that involve PPP and uncovering connections between these, this research provides an extensive PPP literature meta-review that uses objective bibliometric measures on 1970 articles from 773 journals. The methodology involves ranking journals, identifying topical trends over 1989–2018, and clustering the literature to create a PPP knowledge map with associated research domains. The findings reaffirm that PPP is not only a multi-disciplinary research area but also a self-contained meta-discipline that integrates some allied disciplines with their foundational theories. The PPP meta-discipline is largely dominated by Construction Management and Economics (CME), Public Administration and Management, and Transportation Research disciplines, and integrates emerging topics such as sustainability, governance and stakeholders management. This study contributes to the CME scholarly community as it offers the first comprehensive meta-analysis of PPP literature and helps understanding PPP under the lens of a multi-disciplinary perspective. Journal: Construction Management and Economics Pages: 109-125 Issue: 2 Volume: 38 Year: 2020 Month: 2 X-DOI: 10.1080/01446193.2019.1643033 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1643033 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:2:p:109-125 Template-Type: ReDIF-Article 1.0 Author-Name: Wang Pu Author-X-Name-First: Wang Author-X-Name-Last: Pu Author-Name: Fei Xu Author-X-Name-First: Fei Author-X-Name-Last: Xu Author-Name: Ruoxun Chen Author-X-Name-First: Ruoxun Author-X-Name-Last: Chen Author-Name: Rui Cunha Marques Author-X-Name-First: Rui Cunha Author-X-Name-Last: Marques Title: PPP project procurement model selection in China: does it matter? Abstract: Procurement models play a key role in determining the success of a public–private–partnership (PPP) project because they can help the government select the best bidder. Yet, few studies have systematically examined the selection of different procurement models. A content analysis is performed to discuss the institutional and legal framework along with the features of different procurement models in China. A multinomial logistic regression model is then applied to empirically investigate the relationship between the selection of different procurement models and the internal characteristics of the projects, including the investment, duration, operation mode, sector and region. Besides, a questionnaire survey to Chinese officials participating in PPP project procurement is conducted to identify the critical factors affecting the selection preferences. The regression analysis shows that the PPP project procurement model selection in China varies significantly with the internal characteristics of the projects. Moreover, the three most important factors identified are the laws and regulations, internal characteristics of the projects and advice from consultant agencies. These results indicate that the PPP project procurement model selection in China does matter. Helpful policy suggestions for the governments of China and other countries are also provided. Journal: Construction Management and Economics Pages: 126-139 Issue: 2 Volume: 38 Year: 2020 Month: 2 X-DOI: 10.1080/01446193.2019.1596291 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1596291 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:2:p:126-139 Template-Type: ReDIF-Article 1.0 Author-Name: Nunzia Carbonara Author-X-Name-First: Nunzia Author-X-Name-Last: Carbonara Author-Name: Roberta Pellegrino Author-X-Name-First: Roberta Author-X-Name-Last: Pellegrino Title: The role of public private partnerships in fostering innovation Abstract: Despite the prevailing view in the studies on public private partnerships (PPPs) on the potentiality of PPP models for stimulating innovation, existing studies fail to provide a full understating of the relationship between PPP characteristics and innovation, namely they do not explain whether and to what extent some characteristics of PPP are more likely to foster innovation rather than others. This paper aims at providing answers to the following key research questions: Which are the PPP features that favour innovation? How should a PPP be properly structured in order to foster innovation? With this aim, drawing upon the main streams of studies on innovation, we develop a conceptual framework on the relationship between PPP and innovation and formulate the research hypotheses. An econometric analysis is then applied to empirically test the hypotheses using a dataset of 290 PPP projects spanning different countries and sectors, extracted by the World Bank PPI Database. Findings reveal that the arrangement of PPP projects; the market, contract and network structure, as well as government supports, may affect innovation. These results provide foundations to elaborate managerial implications for the future implementation of PPP projects, showing how PPP features have to be structured in order to foster innovation. Journal: Construction Management and Economics Pages: 140-156 Issue: 2 Volume: 38 Year: 2020 Month: 2 X-DOI: 10.1080/01446193.2019.1610184 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1610184 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:2:p:140-156 Template-Type: ReDIF-Article 1.0 Author-Name: Nastaran Tavakoli Author-X-Name-First: Nastaran Author-X-Name-Last: Tavakoli Author-Name: Seyed Hossein Hosseini Nourzad Author-X-Name-First: Seyed Hossein Author-X-Name-Last: Hosseini Nourzad Title: Win-win pricing method for BOT projects using a simulation-based evolutionary optimization Abstract: Several failures have been reported in maintaining the Build-Operate-Transfer (BOT) projects viability through their life cycle. BOT contracts are one of the popular tools to respond to fund deficiencies in infrastructure projects, thus it is crucial to determine optimum concession terms for them. In previous research, the value of social benefits has mostly been neglected in the decision-making process, which results in unfair distribution of benefits between the government and the concessionaire. Therefore, a pricing framework based on a Simulation Multi-Objective Optimization (SMOO) method is developed in this research which includes the value of social benefits as well as the effects of uncertainties in BOT projects. The application of the model to a real-world project confirms that it presents a win-win solution in which the benefits of the two contracting parties are simultaneously maximized compared to the results obtained by using conventional methods. The results confirm the contribution of this research to reach a consensus on concession price and to keep the project viability as a result of its ability to cope with the high volatilities through simulation techniques. Furthermore, it can help the decision-makers to either seek a balance between both sides’ interests or determine the concession price based on their preferential strategies. Journal: Construction Management and Economics Pages: 157-171 Issue: 2 Volume: 38 Year: 2020 Month: 2 X-DOI: 10.1080/01446193.2019.1657234 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1657234 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:2:p:157-171 Template-Type: ReDIF-Article 1.0 Author-Name: Jeroen van der Meer Author-X-Name-First: Jeroen Author-X-Name-Last: van der Meer Author-Name: Andreas Hartmann Author-X-Name-First: Andreas Author-X-Name-Last: Hartmann Author-Name: Aad van der Horst Author-X-Name-First: Aad Author-X-Name-Last: van der Horst Author-Name: Geert Dewulf Author-X-Name-First: Geert Author-X-Name-Last: Dewulf Title: Multi-criteria decision analysis and quality of design decisions in infrastructure tenders: a contractor’s perspective Abstract: Design decision-making in infrastructure tenders is a challenging task for contractors due to limited time and resources. Multi-criteria decision analysis (MCDA) promises to support contractors in dealing with this challenge. However, the ability of MCDA to ensure decision quality in the specific context of infrastructure tenders has gained little attention. By undertaking a longitudinal case study on early design decisions in a tender for a design-build project in the Netherlands the relationship between MCDA and decision quality is investigated. The case results show that in the early tender phase the decision making very much relies on the experience and knowledge of engineers. If MCDA is inappropriately used in such a context it can create impressions of soundly underpinned evaluations of design options while neglecting uncertainties and leading to low-quality decision. Although MCDA defines the “what” is required for structuring the decision problem, it does not support decision-makers in the “how” to do it. The explicit consideration of decision quality elements in MCDA can support the “how” and can create awareness for decision makers concerning importance, scope and uncertainty of criteria. Journal: Construction Management and Economics Pages: 172-188 Issue: 2 Volume: 38 Year: 2020 Month: 2 X-DOI: 10.1080/01446193.2019.1577559 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1577559 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:2:p:172-188 Template-Type: ReDIF-Article 1.0 Author-Name: Ayirebi Dansoh Author-X-Name-First: Ayirebi Author-X-Name-Last: Dansoh Author-Name: Samuel Frimpong Author-X-Name-First: Samuel Author-X-Name-Last: Frimpong Author-Name: Goodenough Dennis Oppong Author-X-Name-First: Goodenough Dennis Author-X-Name-Last: Oppong Title: Exploring the dimensions of traditional authority influencing stakeholder management at the pre-construction stage of infrastructure projects Abstract: In many parts of the world, traditional authorities influence the pre-construction stakeholder management process on infrastructure projects. In this conceptual article, we sought to explore the dimensions of traditional authority that influence stakeholder management at the pre-construction stage, using the case of Ghana. Twenty-nine different issues related to traditional authority were identified through a systematic literature review. Then, through a narrative focus group discussion, the issues were validated, revised and condensed into 21 items. Through thematic analysis, the issues were clustered into four dimensions of traditional authority influences: power and role of traditional leadership; expectations of traditional leadership; project impacts on community resources; and impact of religious and cultural values. Through a further abstraction of the results, we identified six patterns of influence that emerge from the interaction between traditional authorities and other stakeholders, viz.: compromise; uncertainty; instability; power and role suppression; acculturation; and polarization. The findings provide a starting point for theorizing the influence of traditional authority on pre-construction stakeholder management. The findings also provide project managers with information for the development of practical strategies for managing the influence of traditional authorities to ensure an effective stakeholder management process at the pre-construction stage of infrastructure projects. Journal: Construction Management and Economics Pages: 189-206 Issue: 2 Volume: 38 Year: 2020 Month: 2 X-DOI: 10.1080/01446193.2019.1589647 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1589647 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:2:p:189-206 Template-Type: ReDIF-Article 1.0 Author-Name: Satish Kumar Viswanathan Author-X-Name-First: Satish Kumar Author-X-Name-Last: Viswanathan Author-Name: Kamalendra Kumar Tripathi Author-X-Name-First: Kamalendra Kumar Author-X-Name-Last: Tripathi Author-Name: Kumar Neeraj Jha Author-X-Name-First: Kumar Neeraj Author-X-Name-Last: Jha Title: Influence of risk mitigation measures on international construction project success criteria – a survey of Indian experiences Abstract: Despite globalisation bringing diverse opportunities for construction firms from developing countries, executing international construction projects entails many risks. Several past studies illustrate the risks faced by firms in international construction projects and recommend various risk mitigation measures without revealing their effect on project success criteria. In order to fill this knowledge gap, this study aims to test the influence of identified risk mitigation measures on project success criteria. To achieve this, nine risk mitigation measures and three project success criteria—cost performance, schedule performance and firm’s performance—were identified through a literature review. After verifying the identified risk mitigation measures and project success criteria with a preliminary study, a questionnaire was administered to experts who possess adequate knowledge in international construction projects. The collected data from 105 questionnaires were analyzed, grouped and modelled using factor analysis and structural equation modelling (SEM). Application of factor analysis to identify the correlated risk mitigation measures extracted three risk mitigation factors, namely pre-project planning, local participation and contract selection. Furthermore, the influence of risk mitigation factors on project success criteria is hypothesized and tested using SEM. Amongst the identified risk mitigation factors, local participation emerges as the most influencing factor on project success criteria followed by contract selection and pre-project planning. The generated model would enable construction firms from India and similar developing countries to focus on identified risk mitigation factors to achieve improved project success criteria and project management success. Journal: Construction Management and Economics Pages: 207-222 Issue: 3 Volume: 38 Year: 2020 Month: 3 X-DOI: 10.1080/01446193.2019.1577987 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1577987 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:3:p:207-222 Template-Type: ReDIF-Article 1.0 Author-Name: K. Chandrashekhar Iyer Author-X-Name-First: K. Chandrashekhar Author-X-Name-Last: Iyer Author-Name: Ratnesh Kumar Author-X-Name-First: Ratnesh Author-X-Name-Last: Kumar Author-Name: Surya Prakash Singh Author-X-Name-First: Surya Prakash Author-X-Name-Last: Singh Title: Understanding the role of contractor capability in risk management: a comparative case study of two similar projects Abstract: In the construction industry, contractor prequalification is used for measuring contractor capability and selecting capable contractors for the successful execution of projects. Research emphasizes that contractor capability and risk management are critical for project success and have a correlation. However, observations suggest that risks are not considered during prequalification and even prequalified contractors perform poorly causing project failures. Such observations indicate a research gap for which this research explores the role of contractor capability in risk management at the project level. The analysis uses a comparative case study of risk management in two similar ongoing projects having different contractors. It reveals that the contractor capability assessed during prequalification is an attribute of an organization; while the capability required to mitigate risks and execute work is an attribute of a project. When risks materialize, the capability of a contractor may reduce and the capability required to mitigate risks in a project may increase. This will create a deficit of resources resulting in poor performance by the contractor. Therefore, criteria for prequalification must be decided considering risks scenarios for projects and contractors to screen out marginally qualified contractors and increase chances of project success. Journal: Construction Management and Economics Pages: 223-238 Issue: 3 Volume: 38 Year: 2020 Month: 3 X-DOI: 10.1080/01446193.2019.1590614 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1590614 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:3:p:223-238 Template-Type: ReDIF-Article 1.0 Author-Name: Thaís da C. L. Alves Author-X-Name-First: Thaís da C. L. Author-X-Name-Last: Alves Author-Name: Yoshua Neuman Author-X-Name-First: Yoshua Author-X-Name-Last: Neuman Author-Name: Kenneth D. Walsh Author-X-Name-First: Kenneth D. Author-X-Name-Last: Walsh Author-Name: Kim LaScola Needy Author-X-Name-First: Kim LaScola Author-X-Name-Last: Needy Author-Name: Rufaidah AlMaian Author-X-Name-First: Rufaidah Author-X-Name-Last: AlMaian Title: Highly effective companies in supplier quality surveillance practices: a quantitative analysis Abstract: Results presented are part of a larger mixed-mode study on supplier quality practices focusing on the cross-analysis of interviews, focus groups, and a questionnaire, which collected actual data about timing, costs, practices, and non-conformances associated with purchase orders (POs) from Engineering Procure and Construct (EPC) projects for four material types considered relevant to projects built by EPC contractors based in the United States. The present discussion specifically focuses on the analysis of the non-parametric dataset obtained from the POs to investigate a subset of companies labelled as highly effective companies (HECs). This contribution is unique as it used a mixed-mode approach to collect data beyond construction sites and investigate the product/supplier side of construction processes to advance knowledge of how materials can be sent to construction project sites free of defects and rework and indicates practices that contribute to this goal. When compared to other companies in the dataset, HECs engage in more hours of observation in suppliers’ facilities, communicate more often with suppliers, put more effort and time in the planning stages of the project, use more practices related to supplier quality surveillance and supplier quality management, and find non-conformances earlier in the project. Journal: Construction Management and Economics Pages: 239-258 Issue: 3 Volume: 38 Year: 2020 Month: 3 X-DOI: 10.1080/01446193.2019.1590613 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1590613 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:3:p:239-258 Template-Type: ReDIF-Article 1.0 Author-Name: David Espinoza Author-X-Name-First: David Author-X-Name-Last: Espinoza Author-Name: Javier Rojo Author-X-Name-First: Javier Author-X-Name-Last: Rojo Author-Name: Arturo Cifuentes Author-X-Name-First: Arturo Author-X-Name-Last: Cifuentes Author-Name: Jeremy Morris Author-X-Name-First: Jeremy Author-X-Name-Last: Morris Title: DNPV: a valuation methodology for infrastructure and Capital investments consistent with prospect theory Abstract: Traditional valuation methods such as net present value (NPV) utilize increased discount rates to account for risk, in the process introducing a time bias effect that promotes short-termism. Application of NPV often discourages much needed infrastructure projects that require large capital investments yet are slow to generate positive cashflows. NPV also downplays the significance of future liabilities and can lead to risk misallocation amongst investment partners and stakeholders. The decoupled net present value (DNPV) method introduces the risk-as-a-cost concept that prices the risk of obtaining lower-than-expected cashflows and thus represents investors’ compensation for bearing such risks. Capturing the loss-aversion attitudes described by prospect theory, DNPV provides a transparent and consistent valuation framework for long-term investments by: (i) calculating expected values of cashflow components using their probability characterizations, (ii) defining the cost of risk (market and non-market) as the expected downside value, (iii) subtracting/adding the cost of risk from/to expected revenues/expenditures, and (iv) discounting the results using risk-free rates. DNPV’s power is illustrated by re-analyzing a 42-year toll-road concession initially evaluated using NPV and real options. The case study shows how explicit risk quantifications could be used to better structure the concession and reallocate risks among stakeholders. Journal: Construction Management and Economics Pages: 259-274 Issue: 3 Volume: 38 Year: 2020 Month: 3 X-DOI: 10.1080/01446193.2019.1648842 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1648842 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:3:p:259-274 Template-Type: ReDIF-Article 1.0 Author-Name: Sidar Çınar Author-X-Name-First: Sidar Author-X-Name-Last: Çınar Title: Construction labour, subcontracting and masculinity: “construction is a man’s job” Abstract: This study examines how construction workers construct their male identity on the basis of their job requirements. A qualitative field research comprising in-depth interviews was conducted with 32 construction workers in Diyarbakır to examine subcontracting in Turkey’s construction sector. The findings show that by defining construction labour in terms of physical capacity, an outcome of the labour conditions shaped by the practice of subcontracting, construction work have become naturalised as a man’s job. The findings also illustrate how construction produces different masculinities that intersect with the understanding of working class shaped by the role of men being the head of the family rather than a single notion of manhood shaped by physical working conditions. Nevertheless, the male worker culture that feeds off different masculinities still retains the power to dominate and exclude women as workers from the construction site, e.g. through means of sexual harassment. Journal: Construction Management and Economics Pages: 275-290 Issue: 3 Volume: 38 Year: 2020 Month: 3 X-DOI: 10.1080/01446193.2019.1690155 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1690155 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:3:p:275-290 Template-Type: ReDIF-Article 1.0 Author-Name: Yasuhiro Kotera Author-X-Name-First: Yasuhiro Author-X-Name-Last: Kotera Author-Name: Pauline Green Author-X-Name-First: Pauline Author-X-Name-Last: Green Author-Name: David Sheffield Author-X-Name-First: David Author-X-Name-Last: Sheffield Title: Work-life balance of UK construction workers: relationship with mental health Abstract: Although the importance of work-life balance (WLB) is related to occupational psychological outcomes in many countries and industries, these relationships have not been explored in UK construction industry, a major sector of the UK economy. This workforce suffers from high rates of mental health problems and low help-seeking. Accordingly, the purposes of this study were to explore relationships between WLB, mental health, attitudes towards mental health problems, along with work schedules. One hundred and forty-four UK workers in the construction industry completed measures of those three constructs. WLB was negatively associated with mental health problems and mental health attitudes. Mental health attitudes did not mediate the relationship between WLB and mental health problems with a small effect size. WLB was the strongest predictor of mental health problems. Mental health problems scores differed by work pattern groups; day time workers had poorer mental health than mixed workers. Findings will help UK construction workers, employers, and organizational researchers deepen their understanding of WLB and identify better solutions to poor WLB and mental health. Journal: Construction Management and Economics Pages: 291-303 Issue: 3 Volume: 38 Year: 2020 Month: 3 X-DOI: 10.1080/01446193.2019.1625417 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1625417 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:3:p:291-303 Template-Type: ReDIF-Article 1.0 Author-Name: Amy Javernick-Will Author-X-Name-First: Amy Author-X-Name-Last: Javernick-Will Author-Name: Ashwin Mahalingam Author-X-Name-First: Ashwin Author-X-Name-Last: Mahalingam Author-Name: John E. Taylor Author-X-Name-First: John E. Author-X-Name-Last: Taylor Title: Ray Levitt: professor, practitioner and pathfinder Journal: Construction Management and Economics Pages: 305-307 Issue: 4 Volume: 38 Year: 2020 Month: 4 X-DOI: 10.1080/01446193.2020.1730922 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1730922 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:4:p:305-307 Template-Type: ReDIF-Article 1.0 Author-Name: Matthew R. Hallowell Author-X-Name-First: Matthew R. Author-X-Name-Last: Hallowell Author-Name: Siddharth Bhandari Author-X-Name-First: Siddharth Author-X-Name-Last: Bhandari Author-Name: Wael Alruqi Author-X-Name-First: Wael Author-X-Name-Last: Alruqi Title: Methods of safety prediction: analysis and integration of risk assessment, leading indicators, precursor analysis, and safety climate Abstract: Construction safety prediction is an emerging field where various forms of information and analytical techniques are used to predict the likelihood or severity of a future injury. A review of this literature reveals that even though the approaches are used for the same goal of predicting future safety outcomes, they are modeled independently and exclusively from one another. To organize thinking in safety prediction, the literature is organized into four operationally-defined predictive families: (1) safety risk assessment, which considers the characteristics and dangers of the work; (2) precursor analysis, which considers the conditions of the workers; (3) leading indicators, which consider the quantity of safety management activities; and (4) safety climate assessments, which considers worker perceptions of safety. Additionally, a unified model is proposed where the four families are considered together and opportunities for synergy and cross-validation are exploited. Researchers may benefit from this model as they create points of departure, propose and test novel approaches, and attempt to contextualize their findings within the existing body of literature. Furthermore, practitioners may use the model to make more accurate and robust safety predictions that account for the interconnectedness of the work attributes, human resources, and management strategies that affect safety. Journal: Construction Management and Economics Pages: 308-321 Issue: 4 Volume: 38 Year: 2020 Month: 4 X-DOI: 10.1080/01446193.2019.1598566 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1598566 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:4:p:308-321 Template-Type: ReDIF-Article 1.0 Author-Name: Daniel M. Hall Author-X-Name-First: Daniel M. Author-X-Name-Last: Hall Author-Name: Jennifer K. Whyte Author-X-Name-First: Jennifer K. Author-X-Name-Last: Whyte Author-Name: Jerker Lessing Author-X-Name-First: Jerker Author-X-Name-Last: Lessing Title: Mirror-breaking strategies to enable digital manufacturing in Silicon Valley construction firms: a comparative case study Abstract: In construction, the mirroring of knowledge with tasks increasingly limits firm-level abilities to identify and pursue systemic innovation opportunities. Recent research identifies how integration strategies enable individual projects to break from this trap, but much less is known about potential strategic action of firms to enable systemic innovation. To explore this, a longitudinal comparative case study examines how three entrepreneurial firms – DPR construction, RAD Urban, and Project Frog – in the San Francisco Bay Area describe their own strategic evolution and restructuring of firm boundaries over the past five years to enable greater adoption of digital manufacturing. Each firm has developed a different approach – relational, project-based spinoff; vertical integration; or digital systems integration. Benefits and challenges are identified for each. The approaches are theorized as a form of strategic mirror-breaking intended to redefine the current paradigm of knowledge and task dependencies. They enable the firms to develop products with new system architectures and access more opportunities for innovation in digitally-enabled manufacturing. The paper concludes with discussion of how the identification and characterization of strategies for mirror-breaking enriches understanding of integration for systemic innovation in construction at the firm level. The paper identifies common themes for digitally-enabled manufacturing including the limitations of the current industry structure, the emergence of new hybrid positions, and the opportunity for platforms to provide longitudinal integration. Journal: Construction Management and Economics Pages: 322-339 Issue: 4 Volume: 38 Year: 2020 Month: 4 X-DOI: 10.1080/01446193.2019.1656814 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1656814 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:4:p:322-339 Template-Type: ReDIF-Article 1.0 Author-Name: Iris D. Tommelein Author-X-Name-First: Iris D. Author-X-Name-Last: Tommelein Title: Design science research in construction management: multi-disciplinary collaboration on the SightPlan system Abstract: As a tribute to Ray Levitt’s early computer science contributions, this paper presents the research methodology he and I in close collaboration with Barbara Hayes-Roth followed to develop the SightPlan system. This research methodology falls under the umbrella of what is known as “design science.” Design science concerns itself with designing and making artefacts to fulfil a purpose, and then testing and validating that they indeed are fit-for-purpose. Design science does not belong in the category of physical science or of fundamental science; instead, it falls in the category of the sciences of the artificial. This paper describes the methodological steps pursued in design science and in parallel illustrates how these steps were instantiated and what artefacts were produced in the course of developing the SightPlan system, a blackboard expert system that lays out temporary facilities on construction sites. The aims of this paper are to recognise Ray’s work as an advisor and researcher, reflect on and promote the use of design science in construction management and economics and thereby participate in the ongoing discussion on research methods in this journal, and illustrate to scholars in this field that research is an opportunistic endeavour. Journal: Construction Management and Economics Pages: 340-354 Issue: 4 Volume: 38 Year: 2020 Month: 4 X-DOI: 10.1080/01446193.2020.1718723 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1718723 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:4:p:340-354 Template-Type: ReDIF-Article 1.0 Author-Name: John Kunz Author-X-Name-First: John Author-X-Name-Last: Kunz Author-Name: Martin Fischer Author-X-Name-First: Martin Author-X-Name-Last: Fischer Title: Virtual design and construction Abstract: Virtual Design and Construction (VDC) is the use of integrated multi-disciplinary performance models of design-construction projects to support explicit and public business objectives. Professor Levitt’s Virtual Design Team (VDT) project provided a fundamental point of departure of this work: the organisation model provides a central theoretical and practical element in the VDC framework. VDC models are virtual because they are computer-based descriptions of the project. This paper summarises the VDC framework that integrates an organisation perspective with perspectives that are implicit in VDT, including 3D Building Information Model (BIM) product models of a product to be designed, built and operated – typically a physical facility – management by objectives, Lean production management and the social method of Integrated Concurrent Engineering (ICE). Thus, VDC project models emphasise those aspects of the project that can be designed and managed, i.e., the product (typically a building or plant facility), the organisation that will define, design, construct and operate it, and the process that the organisation teams will follow. Many companies and hundreds of professionals now use VDC methods, and they consistently find that they improve project and business performance. Journal: Construction Management and Economics Pages: 355-363 Issue: 4 Volume: 38 Year: 2020 Month: 4 X-DOI: 10.1080/01446193.2020.1714068 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1714068 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:4:p:355-363 Template-Type: ReDIF-Article 1.0 Author-Name: Mahesh Balasubramani Author-X-Name-First: Mahesh Author-X-Name-Last: Balasubramani Author-Name: Ashwin Mahalingam Author-X-Name-First: Ashwin Author-X-Name-Last: Mahalingam Author-Name: W. Richard Scott Author-X-Name-First: W. Richard Author-X-Name-Last: Scott Title: Imitation and adaptation: lessons from a case study of a metro rail project in India Abstract: Oversight arrangements which articulate technical, contractual and organizational decisions in a project domain constitute project governance. In the light of rapid globalization and an increasing number of complex, pluralistic and heterogeneous projects, the need for contingent project governance arrangements which bridge both stability and temporality of project decisions is emphasized in the literature. Nevertheless, inadequate attention has been paid to study how these governance arrangements are actually set up on contemporary projects. We use a combination of institutions-based and practice-based lenses to develop arguments on how governance arrangements are initially selected and replicated or revised, thereby leading to the emergence of order in project governance structures. We gather empirical evidence by qualitatively studying the shaping of project governance structures in a metro rail project in India. Our data show how the project promoters drew from the Delhi Metro’s governance structures to make technical, contractual and organizational decisions in the Chennai Metro, and then contested or stabilized these structures within the project field through situated interactions. Consequently, we identify 11 underlying mechanisms of sustenance and change of governance arrangements and project norms. By bridging both generic and contextual governance perspectives, the study underlines the role of situated “governing” in (re)creating governance structures. Journal: Construction Management and Economics Pages: 364-382 Issue: 4 Volume: 38 Year: 2020 Month: 4 X-DOI: 10.1080/01446193.2019.1619932 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1619932 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:4:p:364-382 Template-Type: ReDIF-Article 1.0 Author-Name: Geert Dewulf Author-X-Name-First: Geert Author-X-Name-Last: Dewulf Author-Name: Michael J. Garvin Author-X-Name-First: Michael J. Author-X-Name-Last: Garvin Title: Responsive governance in PPP projects to manage uncertainty Abstract: Despite the awareness that uncertainty impacts projects with long time horizons, public-private partnership (PPP) research has not extensively examined the operations phase of such projects where interactions between public and private counterparties will be frequent and long-term while subject to a changing environment. Accordingly, two distinct but related investigations examining how governance strategies can address uncertainty in PPP projects are presented. The first identified contractual mechanisms for risk sharing formed during the shaping phase of a broad set of PPP projects; a majority of these mechanisms were strategically designed to address risks as they unfold so counterparty project managers can rely on current information and circumstances during risk resolution. The second explored the emergence of relational mechanisms over time, which revealed that project managers had to consistently adjust established relational approaches to respond to unforeseen events in PPPs. The findings of both studies illustrate the necessity for responsiveness and complementarity of contractual and relational mechanisms in PPPs. Further, the mechanisms uncovered demand project management agility and flexibility as well as improved relational strategies, which is aligned with the emphasis on learning and adaptation in the broader, contemporary project management literature. Consequently, principles from project management 2.0 such as empowering competent project managers and shared global awareness are likely to enhance responsive PPP governance and warrant further exploration. Journal: Construction Management and Economics Pages: 383-397 Issue: 4 Volume: 38 Year: 2020 Month: 4 X-DOI: 10.1080/01446193.2019.1618478 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1618478 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:4:p:383-397 Template-Type: ReDIF-Article 1.0 Author-Name: Paul S. Chinowsky Author-X-Name-First: Paul S. Author-X-Name-Last: Chinowsky Author-Name: Amy Javernick-Will Author-X-Name-First: Amy Author-X-Name-Last: Javernick-Will Title: High-value, collaborative networks Abstract: Networks that generate collaboration and innovative ideas on a regular basis are characterized in this paper as high-value, collaborative networks. The initiation and development of these networks outside of the confines of a formal organization is analyzed in the context of the Engineering Project Organization Society (EPOS). The society, initiated by Professor Raymond Levitt, has existed for 15 years and continues to grow while retaining a core group of founding members. We conducted and analyzed interviews with society members to develop a framework that describes how individuals can form a core with sufficient pull to enable a network to form, stabilize and grow. The framework provides a perspective on how networks sustain through its individual members, the environment in which the network exists, and the rewards individuals obtain from being part of the network. Each of these elements by itself is insufficient to develop network stability; rather, it is the combination of a stable network core and continuous reinforcement of value from the network that serves to preserve and expand network membership. The development of the framework will benefit both academic and professional contexts by highlighting the key elements required to introduce and sustain a dynamic knowledge network. Journal: Construction Management and Economics Pages: 398-408 Issue: 4 Volume: 38 Year: 2020 Month: 4 X-DOI: 10.1080/01446193.2019.1607513 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1607513 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:4:p:398-408 Template-Type: ReDIF-Article 1.0 Author-Name: Raymond E. Levitt Author-X-Name-First: Raymond E. Author-X-Name-Last: Levitt Title: Rejoinder to the Festschrift Journal: Construction Management and Economics Pages: 409-411 Issue: 4 Volume: 38 Year: 2020 Month: 4 X-DOI: 10.1080/01446193.2020.1729490 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1729490 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:4:p:409-411 Template-Type: ReDIF-Article 1.0 Author-Name: Ghang Lee Author-X-Name-First: Ghang Author-X-Name-Last: Lee Author-Name: André Borrmann Author-X-Name-First: André Author-X-Name-Last: Borrmann Title: BIM policy and management Journal: Construction Management and Economics Pages: 413-419 Issue: 5 Volume: 38 Year: 2020 Month: 5 X-DOI: 10.1080/01446193.2020.1726979 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1726979 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:5:p:413-419 Template-Type: ReDIF-Article 1.0 Author-Name: Ajibade A. Aibinu Author-X-Name-First: Ajibade A. Author-X-Name-Last: Aibinu Author-Name: Eleni Papadonikolaki Author-X-Name-First: Eleni Author-X-Name-Last: Papadonikolaki Title: Conceptualizing and operationalizing team task interdependences: BIM implementation assessment using effort distribution analytics Abstract: Building Information Modelling (BIM) is a technological innovation currently at the forefront of digital transformation in the built environment. To achieve satisfactory outcomes with BIM, adopters need to find the most appropriate implementation strategy that is economically efficient. The research discussed here explores why and how distribution of effort spent on various tasks over project life cycle can be used as a metric for assessing and improving the performance of BIM implementation. Using quantitative data collected from a single in-depth case study of a BIM-enabled design and build project and subsequent interviews with three project actors and 11 BIM experts, to validate and triangulate the findings, we explore the use of effort data to analyze and visualize effort distribution patterns. The visualizations revealed the dynamics of team collaboration and task interdependences in BIM-enabled work and their impact on effort distribution. Lack of timely input by the contractor, subcontractors and suppliers influenced unusual patterns in the distribution of efforts indicating potential sources of inefficiency and unnecessary costs in the BIM process; thereby revealing the pivotal role of procurement structure and suggesting the need for timely involvement of key project participants. The contribution of this work is twofold. Methodologically, effort distribution analytics can provide insights that managers can use to improve BIM implementation process. Theoretically, the findings can be used to support informed decision-making, control cost, optimize resources, manage cash flow and to structure fees. Journal: Construction Management and Economics Pages: 420-446 Issue: 5 Volume: 38 Year: 2020 Month: 5 X-DOI: 10.1080/01446193.2019.1623409 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1623409 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:5:p:420-446 Template-Type: ReDIF-Article 1.0 Author-Name: Adeyemi Akintola Author-X-Name-First: Adeyemi Author-X-Name-Last: Akintola Author-Name: Senthilkumar Venkatachalam Author-X-Name-First: Senthilkumar Author-X-Name-Last: Venkatachalam Author-Name: David Root Author-X-Name-First: David Author-X-Name-Last: Root Title: Understanding BIM’s impact on professional work practices using activity theory Abstract: Recent critiques of the BIM literature describe it as largely devoid of critical theoretical perspectives and theorization capable of explaining the nature of change in work practices in a holistic manner. In response, the authors argue that, from a theoretical standpoint, implementing BIM within professional work practices (as activity systems) induces their evolution through dysfunctions created within the systems and their resolution. Cases of professional organizations in South Africa that have implemented BIM within their organization and in multi-organizational projects helped to develop new theoretical insights into how professional work practices evolve using activity theory-based re-description of the data. Changes in professional work practices were analyzed sequentially within the framework, confirming theoretical propositions and revealing the dynamics between and within the interconnected system of actors, their object, tools, rules guiding work, roles they assume and the stakeholders. Essentially, the findings imply that the implementation of BIM significantly changes work practices within organizations, but gradually and over time. This supports an evolutionary, rather than a radical or revolutionary, view of BIM-induced change. This theoretical perspective could explain future dimensions of change in professional work practices involving BIM, and indeed similar work mediating tools. Journal: Construction Management and Economics Pages: 447-467 Issue: 5 Volume: 38 Year: 2020 Month: 5 X-DOI: 10.1080/01446193.2018.1559338 File-URL: http://hdl.handle.net/10.1080/01446193.2018.1559338 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:5:p:447-467 Template-Type: ReDIF-Article 1.0 Author-Name: Hannes Lindblad Author-X-Name-First: Hannes Author-X-Name-Last: Lindblad Author-Name: Jacob Rudolphsson Guerrero Author-X-Name-First: Jacob Rudolphsson Author-X-Name-Last: Guerrero Title: Client’s role in promoting BIM implementation and innovation in construction Abstract: Innovation is often viewed as vital in addressing future demands on the construction industry, but innovation implementation is also considered challenging in this fragmented, project-based industry. In order to address the challenges, client organisations are commonly acknowledged as key actors in driving construction innovation. However, the details of what the client role constitutes is less clear, and the question of whether innovation should be mainly client-led or supplier-led is debated. The purpose in this paper is to explore different roles public client organisations can enact to promote innovation. To fulfil this purpose, an explorative case study has been conducted at the largest transport infrastructure client in Sweden; exploring two initiatives which have simultaneously been deployed to promote innovation. The studied organisation is on the one hand trying to influence the industry to implement Building Information Modelling (BIM), adopting a BIM policy and actively influencing the supply chain, while on the other hand promoting innovation through policies aimed at providing more flexibility in projects, enabling suppliers to propose new solutions and emphasising market competition. Even though the overarching goals are similar, promote innovation, the research finds that the simultaneous use of the policies create intra-organisational tension within the client organisation. The findings provide insights into the different roles clients can enact in promoting innovation, and contribute to the understanding of clients as a key actor for promoting innovation in the construction industry. Journal: Construction Management and Economics Pages: 468-482 Issue: 5 Volume: 38 Year: 2020 Month: 5 X-DOI: 10.1080/01446193.2020.1716989 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1716989 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:5:p:468-482 Template-Type: ReDIF-Article 1.0 Author-Name: Dale Steinhardt Author-X-Name-First: Dale Author-X-Name-Last: Steinhardt Author-Name: Karen Manley Author-X-Name-First: Karen Author-X-Name-Last: Manley Author-Name: Louise Bildsten Author-X-Name-First: Louise Author-X-Name-Last: Bildsten Author-Name: Kristian Widen Author-X-Name-First: Kristian Author-X-Name-Last: Widen Title: The structure of emergent prefabricated housing industries: a comparative case study of Australia and Sweden Abstract: Prefabricated housing is a disruptive innovation struggling to take hold in a traditional complex product system (CoPS). It is quicker to produce and has improved environmental performance compared to traditional housing. CoPS have more dense and complex network connections than commodity industries, making disruptive innovation more difficult. Effective relational capabilities can achieve the coordination necessary to address this challenge. The prefabricated housing industry needs to develop a structure that drives these capabilities. Using a case study methodology, the structure of the industry is examined in two contrasting countries, namely Australia and Sweden, as they represent an early and late stage of industry emergence, respectively. A new framework is proposed for this purpose, enabling a repeatable, orderly and comprehensive disaggregation of industry structure to examine the latent drivers of relational capability. The main empirical contribution is to (1) describe an industry that is yet to be formally recognized by national statistical agencies and (2) show how the adoption of prefabricated housing can be accelerated. The study found that younger industries need a focused industry association with diverse membership to act as an effective system integrator. Journal: Construction Management and Economics Pages: 483-501 Issue: 6 Volume: 38 Year: 2020 Month: 6 X-DOI: 10.1080/01446193.2019.1588464 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1588464 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:6:p:483-501 Template-Type: ReDIF-Article 1.0 Author-Name: Mehrdad Arashpour Author-X-Name-First: Mehrdad Author-X-Name-Last: Arashpour Author-Name: Amin Heidarpour Author-X-Name-First: Amin Author-X-Name-Last: Heidarpour Author-Name: Ali Akbar Nezhad Author-X-Name-First: Ali Author-X-Name-Last: Akbar Nezhad Author-Name: Zahra Hosseinifard Author-X-Name-First: Zahra Author-X-Name-Last: Hosseinifard Author-Name: Nicholas Chileshe Author-X-Name-First: Nicholas Author-X-Name-Last: Chileshe Author-Name: Reza Hosseini Author-X-Name-First: Reza Author-X-Name-Last: Hosseini Title: Performance-based control of variability and tolerance in off-site manufacture and assembly: optimization of penalty on poor production quality Abstract: Defects and quality problems in off-site manufacturing of building parts are caused by different variables. Subsequently, rework is required during on-site subassembly aggregation. Rework and tampering with prefabricated parts has implications including suboptimal structural/non-structural performance, delays and increased costs. Currently there is a gap in the off-site construction literature in developing effective interventions to reflect on variability in operations of subassembly manufacturers. On this basis, and in the first step of the current research, point clouds of the as-built status of parts are generated by laser scanners and compared with the as-designed status represented by Building Information models (BIM). Then, optimization modelling is used for development of a balanced penalty and incentive (PI) scheme to minimize variability. For this purpose, total expenditure on variability reduction is offset by revenues generated from penalties on poor quality. This optimization-based research contributes to the off-site construction literature by providing cost-effective solutions to quality problems. Furthermore, models and findings are of practical importance to off-site manufacturers by encouraging precision and discouraging discrepancy. Journal: Construction Management and Economics Pages: 502-514 Issue: 6 Volume: 38 Year: 2020 Month: 6 X-DOI: 10.1080/01446193.2019.1616789 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1616789 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:6:p:502-514 Template-Type: ReDIF-Article 1.0 Author-Name: Abbas Hassan Author-X-Name-First: Abbas Author-X-Name-Last: Hassan Author-Name: Khaled El-Rayes Author-X-Name-First: Khaled Author-X-Name-Last: El-Rayes Title: Quantifying the interruption impact of activity delays in non-serial repetitive construction projects Abstract: Available scheduling models for repetitive construction projects can be classified as serial or non-serial. Serial models assume that each repetitive activity is limited to have only one predecessor and one successor, while non-serial models enable repetitive activities to have multi predecessors and successors. Activity delays in serial and non-serial repetitive projects often cause work interruptions for successor activities and project delays. This paper presents the development of a novel scheduling model for both serial and non-serial repetitive construction projects to quantify the impact of any activity delay on interrupting the crew work continuity of its successors. An application example of a repetitive construction project from the literature is analyzed to illustrate the use of the model and its computations. This analysis illustrates the novel capabilities of the model in: (1) calculating a new float to identify the duration that each activity can be delayed without causing interruption in the crew work continuity of any of its successors; and (2) quantifying the impact of unexpected activity delay on interrupting the crew work continuity of its successors. These capabilities enable construction planners to analyze and minimize the impact of unexpected activity delays on interrupting the crew work continuity of all its successors. Journal: Construction Management and Economics Pages: 515-533 Issue: 6 Volume: 38 Year: 2020 Month: 6 X-DOI: 10.1080/01446193.2019.1657922 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1657922 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:6:p:515-533 Template-Type: ReDIF-Article 1.0 Author-Name: Ahmed Wa Hammad Author-X-Name-First: Ahmed Wa Author-X-Name-Last: Hammad Author-Name: Hanna Grzybowska Author-X-Name-First: Hanna Author-X-Name-Last: Grzybowska Author-Name: Monty Sutrisna Author-X-Name-First: Monty Author-X-Name-Last: Sutrisna Author-Name: Ali Akbarnezhad Author-X-Name-First: Ali Author-X-Name-Last: Akbarnezhad Author-Name: Assed Haddad Author-X-Name-First: Assed Author-X-Name-Last: Haddad Title: A novel mathematical optimisation model for the scheduling of activities in modular construction factories Abstract: Modular construction has been reported to lead to a number of advantages when contrasted with conventional construction approaches, including time and cost savings, along with reduced environmental impacts. Given that the operations involved in modular construction take place within a controlled environment, an integral factor that impacts the productivity of works involved is the timely scheduling of the associated activities. Unlike conventional on-site construction methods, operations in modular construction take place in a sequential and linear manner, with large dependence on adequate resource allocation to specific workstations. In a bid to address the lack of mathematical optimisation methods that target the scheduling of operations in a modular factory setting, this paper proposes a novel mixed integer non-linear programming model for optimising the scheduling of modular construction activities on the shop floor of modular factories. The impact of scheduling of resources, such as overhead cranes, and the distance between stations to which activities are scheduled are factored in the proposed method. The solution approach presented for solving the scheduling problem involves the linearisation of the model to enable the use of efficient off-the-shelf solvers. A realistic case study is implemented, and an extensive computational experiment is also conducted to test the robustness and tractability of the proposed method. The performance of the model is also contrasted with a commonly adopted heuristic, with the model producing project durations reductions that are 43% less than that of the heuristic. Journal: Construction Management and Economics Pages: 534-551 Issue: 6 Volume: 38 Year: 2020 Month: 6 X-DOI: 10.1080/01446193.2019.1682174 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1682174 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:6:p:534-551 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Suhair Alkilani Author-X-Name-First: Suhair Author-X-Name-Last: Alkilani Author-Name: Robert Mathenge Author-X-Name-First: Robert Author-X-Name-Last: Mathenge Title: The risks of and barriers to social procurement in construction: a supply chain perspective Abstract: Social procurement policies place new requirements on subcontractors to create employment opportunities for people suffering disadvantage. However, the subcontractor’s voice is largely absent from the social procurement debate, despite employing the majority of people in the construction industry. Addressing this gap in social procurement research, a survey of seventy Australian subcontractors was undertaken to explore perceived barriers to integrating six disadvantaged groups targeted by social procurement policies into the construction workforce (Indigenous people, people suffering disability, women, disengaged youth, migrants and refugees, ex-offenders). Results indicate that rather than reducing disadvantage for the most marginalised groups in society, satisficing behaviour in complying with emerging social procurement policies could have the opposite effect. Subcontractors see significant business risks associated with safety, productivity and costs with disengaged youth being perceived as the highest risk cohort, followed by migrants and refugees, people suffering disability, ex-offenders, women and Indigenous workers and employment priorities reflect these perceptions. Perceived barriers to employment vary significantly across these groups with smaller and younger firms perceiving the greatest barriers – particularly for women and Indigenous workers. Practically, the results highlight the potential risks which social procurement policies present to vulnerable people if they are introduced without sufficient support and regard for an industry’s culture, structure and capacity to deliver. Conceptually, taking this research forward, the results highlight the potential value of cross-sector collaboration and intersectionality as theoretical frameworks to better understand how these groups experience working in the construction sector. Journal: Construction Management and Economics Pages: 552-569 Issue: 6 Volume: 38 Year: 2020 Month: 6 X-DOI: 10.1080/01446193.2019.1687923 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1687923 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:6:p:552-569 Template-Type: ReDIF-Article 1.0 Author-Name: Rochelle Ade Author-X-Name-First: Rochelle Author-X-Name-Last: Ade Author-Name: Michael Rehm Author-X-Name-First: Michael Author-X-Name-Last: Rehm Title: Reaching for the stars: green construction cost premiums for Homestar certification Abstract: The assumption that undertaking certification, using a green building rating tool, will increase capital construction cost has been well studied in commercial buildings with mixed results, but less attention has been given to the much larger residential sector. This paper studies New Zealand’s Homestar residential green building rating tool and estimates the cost premium associated with 6-Homestar certification by analyzing the actual capital construction costs of 718 newly built homes in Auckland, New Zealand. To undertake this research, the authors contacted and collected actual capital construction costs from builders and developers of recently constructed single-family homes across Auckland. Given the sensitive nature of property-level construction cost data, this study marks the first development and application of hedonic cost modelling to analyses actual construction costs of single-family homes. The authors find a 12% cost premium for 6-Homestar certification, comprising an 11% hard cost premium and 1% in additional soft costs. Journal: Construction Management and Economics Pages: 570-580 Issue: 6 Volume: 38 Year: 2020 Month: 6 X-DOI: 10.1080/01446193.2019.1640370 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1640370 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:6:p:570-580 Template-Type: ReDIF-Article 1.0 Author-Name: Richard Fellows Author-X-Name-First: Richard Author-X-Name-Last: Fellows Author-Name: Anita M. M. Liu Author-X-Name-First: Anita M. M. Author-X-Name-Last: Liu Title: Borrowing theories: contextual and empirical considerations Abstract: Emerging disciplines, such as Construction Management/Economics, inevitably borrow theory and methods from other, more mature disciplines. In doing so, both the content of the borrowed theory and the contexts in which it has been used as well as the new context in which it will be used are fundamental concerns. Contexts have determined the content of theories and impact their applications – including validities and reliability of results and findings. Through a review of leading literature on theory borrowing, this Note discusses the major issues involved and suggests considerations and precautions to ensure good research practice when borrowing theory – content, context, and methods. Journal: Construction Management and Economics Pages: 581-588 Issue: 7 Volume: 38 Year: 2020 Month: 7 X-DOI: 10.1080/01446193.2020.1727541 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1727541 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:7:p:581-588 Template-Type: ReDIF-Article 1.0 Author-Name: Sumati Ahuja Author-X-Name-First: Sumati Author-X-Name-Last: Ahuja Author-Name: Natalia Nikolova Author-X-Name-First: Natalia Author-X-Name-Last: Nikolova Author-Name: Stewart Clegg Author-X-Name-First: Stewart Author-X-Name-Last: Clegg Title: Professional identity and anxiety in architect-client interactions Abstract: Large-scale construction projects increasingly have powerful and knowledgeable clients as project owners with whom professionals, such as architects, must interact. In such contexts, clients may have a significant impact on the constitution of a coherent and stable professional identity. Based on qualitative interviews with 50 architects across four large multidisciplinary professional service firms (PSFs) located in Sydney, Australia, supplemented by ethnographic observations, this article explores how architects constitute their identity in interactions with clients. The findings led us to conceptualise professional–client interactions in terms of two overarching discursive strategies deployed by architects in attempts to manage clients that are powerful and knowledgeable: best for client and best for project. We illustrate the anxieties that architects experience and suggest that attempts to secure professional identity may result in (re)producing an enduring sense of anxiety with unintended consequences for project outcomes and organisational performance. Journal: Construction Management and Economics Pages: 589-602 Issue: 7 Volume: 38 Year: 2020 Month: 7 X-DOI: 10.1080/01446193.2019.1703019 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1703019 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:7:p:589-602 Template-Type: ReDIF-Article 1.0 Author-Name: Stefan Christoffer Gottlieb Author-X-Name-First: Stefan Christoffer Author-X-Name-Last: Gottlieb Author-Name: Nicolaj Frederiksen Author-X-Name-First: Nicolaj Author-X-Name-Last: Frederiksen Author-Name: Christian Koch Author-X-Name-First: Christian Author-X-Name-Last: Koch Author-Name: Christian Thuesen Author-X-Name-First: Christian Author-X-Name-Last: Thuesen Title: Hybrid organisations as trading zones: responses to institutional complexity in the shaping of strategic partnerships Abstract: Hybrid organisations have been touted as solutions to a range of societal problems. In a construction context, strategic partnerships, as a particular type of hybrid organisation, have given promises of increased productivity and innovation through business models combining logics and governance structures from both the public and private sectors. Little is however known about how strategic partnerships are established and develop throughout their lifespan by combining different logics in response to institutional complexity. Drawing on a study of a public client’s efforts to create cost efficient services, we analyse the formation of two strategic partnerships as emerging hybrid organisations in the intersection between a market logic, a project logic, a community logic, and an administrative logic. It is shown how different logics are mobilised in the dynamic shaping of the partnerships in response to moments of institutional complexity. On this background, we discuss how the contours of two different forms of hybrid organisation emerged, even though the partnerships initially operated and responded similarly to the institutional demands. On this basis, it is concluded that strategic partnerships can be seen as “trading zones” that follow different trajectories in coping with institutional demands, and hence the development of hybrid organisational forms. Journal: Construction Management and Economics Pages: 603-622 Issue: 7 Volume: 38 Year: 2020 Month: 7 X-DOI: 10.1080/01446193.2020.1738514 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1738514 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:7:p:603-622 Template-Type: ReDIF-Article 1.0 Author-Name: Federica Pascale Author-X-Name-First: Federica Author-X-Name-Last: Pascale Author-Name: Efthimia Pantzartzis Author-X-Name-First: Efthimia Author-X-Name-Last: Pantzartzis Author-Name: Ilias Krystallis Author-X-Name-First: Ilias Author-X-Name-Last: Krystallis Author-Name: Andrew D. F. Price Author-X-Name-First: Andrew D. F. Author-X-Name-Last: Price Title: Rationales and practices for dynamic stakeholder engagement and disengagement. Evidence from dementia-friendly health and social care environments Abstract: Latest developments in stakeholder management literature focus on dynamic stakeholder engagement and disengagement practices, and how these are facilitated towards reaching systemic outcomes. However, limited evidence support that this network-level approach can positively influence project success. The paper analyses this issue by considering the practices (how and when), rationales (why) and outcomes (so what) that evolve in the dynamic management of external stakeholders in dementia-friendly environments. This is a crucial area to explore as the ageing population and rising dementia prevalence has increased the need to engage external stakeholders, such as people living with dementia, to develop dementia-friendly health and social environments. The empirical study of the 2013/2014 Department of Health National Dementia Capital Investment Programme involved a statistical and qualitative analysis of 98 pilot projects’ final lessons learnt reports. The analysis advances the dynamic process of timely engaging and disengaging external stakeholders in a context not previously explored in the literature related to dementia-friendly environments. Eight recurring practices and six rationales, the latter characterized by their temporal dimension, are presented in a processual model of stakeholder management. Journal: Construction Management and Economics Pages: 623-639 Issue: 7 Volume: 38 Year: 2020 Month: 7 X-DOI: 10.1080/01446193.2019.1679383 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1679383 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:7:p:623-639 Template-Type: ReDIF-Article 1.0 Author-Name: Bhavana Pandit Author-X-Name-First: Bhavana Author-X-Name-Last: Pandit Author-Name: Alex Albert Author-X-Name-First: Alex Author-X-Name-Last: Albert Author-Name: Yashwardhan Patil Author-X-Name-First: Yashwardhan Author-X-Name-Last: Patil Title: Developing construction hazard recognition skill: leveraging safety climate and social network safety communication patterns Abstract: Poor hazard recognition skill is a widespread issue in the construction industry. Therefore, an understanding of factors that influence the development of hazard recognition skill among workers is fundamental to effective safety management. Based on social learning theory which suggests that individuals learn efficiently by observing, interacting, and emulating others in workplaces, the current article reports findings from a larger study that examined the effect of safety climate and social-network safety communication patterns on the hazard recognition skill demonstrated by workers. More specifically, building upon previously reported findings presented in Pandit et al. which suggests that maintaining a more positive safety climate can lead to superior hazard recognition levels, the current article presents additional results examining the effect of safety climate and social-network safety communication patterns—maintained by workers—on the demonstrated hazard recognition skill. The study involved recruiting construction crews from 57 projects in the United States where safety climate and social-network safety communication data were gathered using questionnaire surveys—which was then followed by a hazard recognition activity. The results suggest that, apart from the safety climate, social-network safety communication patterns are positively related to the demonstrated hazard recognition skill. In addition, evidence of an interaction effect was found—suggesting that establishing a positive safety climate and maintaining higher levels of safety communication can yield synergistic benefits. Journal: Construction Management and Economics Pages: 640-658 Issue: 7 Volume: 38 Year: 2020 Month: 7 X-DOI: 10.1080/01446193.2020.1722316 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1722316 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:7:p:640-658 Template-Type: ReDIF-Article 1.0 Author-Name: Arto Reiman Author-X-Name-First: Arto Author-X-Name-Last: Reiman Author-Name: Louise Møller Pedersen Author-X-Name-First: Louise Author-X-Name-Last: Møller Pedersen Author-Name: Seppo Väyrynen Author-X-Name-First: Seppo Author-X-Name-Last: Väyrynen Author-Name: Olli Airaksinen Author-X-Name-First: Olli Author-X-Name-Last: Airaksinen Author-Name: Erja Sormunen Author-X-Name-First: Erja Author-X-Name-Last: Sormunen Author-Name: Tuula Räsänen Author-X-Name-First: Tuula Author-X-Name-Last: Räsänen Title: Multi-organisational approach to safety training: the case of a Finnish Safety Training Park Abstract: Studies across trades suggest that occupational accident and injury rates and costs are higher than average in the construction industry. There is a need for innovative and cost-effective occupational safety approaches. The Finnish construction industry and its key stakeholders have introduced a new safety training concept, called the Safety Training Park (STP). The STP consists of full-scale training points that use new training methods to stimulate individual safe behaviour and to improve safety climate within workgroups and companies. The Safety Training Park in Northern Finland (STPNF) was designed, constructed, and financed through a collaborative process that included over 80 organizations. A realistic evaluation approach was applied to document the effectiveness of STPNF training from individual and organizational perspectives. Results indicate that the dialogical STP approach with several information sharing channels fits the target groups. Evidence regarding effectiveness at the organizational level is also discussed. Cost-benefit calculations show that the multi-organizational coalition model enables efficient occupational safety and health training with reasonable costs. Journal: Construction Management and Economics Pages: 659-672 Issue: 7 Volume: 38 Year: 2020 Month: 7 X-DOI: 10.1080/01446193.2019.1675893 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1675893 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:7:p:659-672 Template-Type: ReDIF-Article 1.0 Author-Name: Vacharapoom Benjaoran Author-X-Name-First: Vacharapoom Author-X-Name-Last: Benjaoran Author-Name: Vachara Peansupap Author-X-Name-First: Vachara Author-X-Name-Last: Peansupap Title: Grid-based construction site layout planning with Particle Swarm Optimisation and Travel Path Distance Abstract: Many temporary facilities are required during on-site construction operations of most projects. They must be situated in convenient locations as ease of access can have a significant impact on the efficiency and safety of the construction project. The feasible locations and layouts that satisfy all specified conditions and constraints can still be very large in number; thus, optimal layout planning can be very challenging, even for experienced engineers. A model for solving the construction site layout problem (CSLP) is proposed. A grid system is implemented to simulate sites and facilities more realistically. This model incorporates an algorithm that imitates and calculates the distances of typical travel paths of workers between a pair of facilities during construction operations. In addition, Particle Swarm Optimisation is adopted to solve the problem model. The prototype program was developed and tested on a real construction project case. The results show that the model was able to lay out the site efficiently and optimally. The resulting layouts were better than those from engineers and conventional distance calculation methods. Journal: Construction Management and Economics Pages: 673-688 Issue: 8 Volume: 38 Year: 2020 Month: 8 X-DOI: 10.1080/01446193.2019.1600708 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1600708 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:8:p:673-688 Template-Type: ReDIF-Article 1.0 Author-Name: Mohamed Matar Author-X-Name-First: Mohamed Author-X-Name-Last: Matar Author-Name: Hesham Osman Author-X-Name-First: Hesham Author-X-Name-Last: Osman Author-Name: Maged Georgy Author-X-Name-First: Maged Author-X-Name-Last: Georgy Author-Name: Azza Abou-Zeid Author-X-Name-First: Azza Author-X-Name-Last: Abou-Zeid Author-Name: Moheeb Elsaid Author-X-Name-First: Moheeb Author-X-Name-Last: Elsaid Title: Evaluating the environmental performance of pipeline construction using systems modelling Abstract: Environmental performance criteria currently represent major decision factors in civil engineering projects, including pipeline construction. This paper presents a framework based on systems modelling and multicriteria decision analysis (MCDA) that captures different setups of pipeline installation techniques and the environmental impacts expected from different execution scenarios. A model is developed via SysML using the principles of systems modelling and engineering to capture the interactions of the pipeline as a product, the installation technique utilized, together with the environment. A TOPSIS-based MCDA module permits selecting the optimum alternative among construction alternatives. Open cut trenching and microtunneling are exemplified and a case study is provided where both techniques are evaluated in terms of environmental impacts. The contribution of this work is providing a structured and versatile framework that properly captures the interactions of different pipeline installation techniques and the environment, enabling the quantification of environmental impacts to a high degree of precision. The capacity to model different scenarios allows comparison and selection of the most suitable alternative. Journal: Construction Management and Economics Pages: 689-714 Issue: 8 Volume: 38 Year: 2020 Month: 8 X-DOI: 10.1080/01446193.2019.1605185 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1605185 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:8:p:689-714 Template-Type: ReDIF-Article 1.0 Author-Name: Mohammad A. Ammar Author-X-Name-First: Mohammad A. Author-X-Name-Last: Ammar Title: Resource optimisation in line of balance scheduling Abstract: The Critical Path Method (CPM) has failed practically for scheduling repetitive projects and Line Of Balance (LOB) has emerged as an alternative for scheduling such projects. Because of the size of most repetitive projects, efficient resource management plays a vital role in their successful implementation. However, resource levelling and allocation have not been formally investigated in repetitive projects. Heuristic methods and optimization techniques have been traditionally used to solve resource scheduling problems like the latter. Although heuristic methods can handle large-size projects, they do not guarantee optimal solutions. In this paper, resource levelling and allocation problems under LOB scheme are modelled as an optimization problem that guarantees optimal solutions. Resource continuity and logical dependency between activities are maintained where constant activity progress rate is assumed. An example project is used to demonstrate the details of model formulation. A complete solution for the range of feasible project durations is obtained as a Time-Resource Trade-Off curve. A pipeline project is used to validate the developed model revealing that the developed model is superior. The proposed model provides contractors with a complete picture for resource usage along with the range of feasible project durations from which the optimal alternative can be selected. Journal: Construction Management and Economics Pages: 715-725 Issue: 8 Volume: 38 Year: 2020 Month: 8 X-DOI: 10.1080/01446193.2019.1606924 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1606924 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:8:p:715-725 Template-Type: ReDIF-Article 1.0 Author-Name: Amir R. Hessami Author-X-Name-First: Amir R. Author-X-Name-Last: Hessami Author-Name: Vahid Faghihi Author-X-Name-First: Vahid Author-X-Name-Last: Faghihi Author-Name: Amy Kim Author-X-Name-First: Amy Author-X-Name-Last: Kim Author-Name: David N. Ford Author-X-Name-First: David N. Author-X-Name-Last: Ford Title: Evaluating planning strategies for prioritizing projects in sustainability improvement programs Abstract: Programs to improve the sustainability of building infrastructures often consist of project portfolios that need to be prioritized in an appropriate chronological fashion to maximize the program’s benefits. This is particularly important when a revolving-fund approach is used to leverage savings from the initial projects to pay for later improvements. The success of the revolving-fund approach is dependent on the appropriate prioritization of projects. Competing performance measures and scarce resources make this task of project prioritization during the planning stage a complex and challenging endeavour. The current study examined the impact of different project prioritization strategies for revolving-fund sustainability program performance. A novel modeling approach for sustainability decision-analysis was developed using the system dynamics method, and the model was calibrated using a campus sustainability improvement program at a major university. The model was applied to evaluate the effects of five common project-prioritization strategies on three program-performance measures, across a wide range of initial investment levels. For the university case study, we found that the strategy of prioritizing projects according to decreasing benefit/cost ratio performed best. The research demonstrated that using a system dynamics model can allow sustainability program managers to make better-informed sequencing decisions, leading to a financially and environmentally successful program implementations. Journal: Construction Management and Economics Pages: 726-738 Issue: 8 Volume: 38 Year: 2020 Month: 8 X-DOI: 10.1080/01446193.2019.1608369 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1608369 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:8:p:726-738 Template-Type: ReDIF-Article 1.0 Author-Name: Jing Zhang Author-X-Name-First: Jing Author-X-Name-Last: Zhang Author-Name: Fangjian Chen Author-X-Name-First: Fangjian Author-X-Name-Last: Chen Author-Name: X.-X. Yuan Author-X-Name-First: X.-X. Author-X-Name-Last: Yuan Title: Comparison of cost and schedule performance of large public projects under P3 and traditional delivery models: a Canadian study Abstract: Cost overrun and schedule delay are pervasive in large public infrastructure projects in Canada and there is an ongoing debate over the root causes of these delivery risks and how best to mitigate them. Since public-private partnerships (P3s) have been long touted as an effective mitigating measure, this study aimed to provide comparative empirical evidence to explore this claim. By collecting cost and schedule data at three key milestones (decision to build, contract awarding and substantial completion) from 39 traditional projects and 27 P3 projects across Canada between 2004 and 2016, the study develops an innovative longitudinal profiling approach to inform the debate about the causes of cost overruns in large public projects. Statistical analyses of the collected data unambiguously demonstrate that P3s outperform non-P3 traditional delivery models during the construction stage in both cost overrun and schedule delay. However, substantial budget underestimation is found in the strategic decision-making process of both models of project delivery. Results from the study also provide solid objective grounds for the development of advanced value-for-money assessment methodology. Journal: Construction Management and Economics Pages: 739-755 Issue: 8 Volume: 38 Year: 2020 Month: 8 X-DOI: 10.1080/01446193.2019.1645344 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1645344 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:8:p:739-755 Template-Type: ReDIF-Article 1.0 Author-Name: Ahmed W. A. Hammad Author-X-Name-First: Ahmed W. A. Author-X-Name-Last: Hammad Title: A multi-objective construction site layout planning problem solved through integration of location and traffic assignment models Abstract: Effective construction site layout planning is imperative for ensuring the productivity and safety of construction operations during the various phases of a project. Contrary to previous studies where the focus has been merely on the location decisions of operating facilities, this study examines the site layout planning problem from the perspective of incorporating planning considerations for on-land traffic assignment on site. The site layout planning problem is thus solved by accounting for location decisions, on-land material handling equipment choices, and traffic assignment on the site’s ground during construction. A sustainable site layout is ensured through minimizing noise pollution measured at noise-sensitive receivers located around the construction site, minimizing the cost of the layout adopted, as well as minimizing the total travel time of on-land equipment traversing between the positioned temporary facilities. The problem is initially formulated as a bi-level model and then later reformulated into a single-level model based on a justified relaxation. To handle the multi-objective nature of the resulting problem, the augmented ϵ-constraint approach is utilized to generate the non-dominated Pareto front. Applied to a realistic case, the results of the proposed bi-level model demonstrate that errors of up to 55% in total system travel time can be avoided when traffic assignment on-site is considered. Journal: Construction Management and Economics Pages: 756-772 Issue: 8 Volume: 38 Year: 2020 Month: 8 X-DOI: 10.1080/01446193.2019.1659510 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1659510 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:8:p:756-772 Template-Type: ReDIF-Article 1.0 Author-Name: Gerard H. Dericks Author-X-Name-First: Gerard H. Author-X-Name-Last: Dericks Author-Name: Florence T. T. Phua Author-X-Name-First: Florence T. T. Author-X-Name-Last: Phua Title: The occupational attractiveness of the built environment and the roles of individualism and collectivism: a hidden source of conflict and gender imbalance? Abstract: The success of built environment projects is closely dependent on strong collective cooperation. Yet abundant anecdotal and academic evidence attests to weak collective cooperation within the industry. To date, no research in the built environment has investigated either the individual-level differences in individualism/collectivism that affect cooperativeness, or how gender may interact with these individual-level traits. In this research we seek to make a positive contribution by using the individual rather than organization as the unit of analysis. We first test the possibility that the built environment may in fact attract uncooperative individuals who are more individualistic than collectivist with respect to two specimen subsectors, i.e. construction management and architecture. At the same time we also employ a nuanced distinction between horizontal and vertical facets of individualism/collectivism, and assess potential interactions with gender. Using individual-level data (N=548), we find that both the architecture and construction management subsectors are occupationally attractive to individuals from opposing ends of the horizontal and vertical individualism/collectivism spectrums, and that these traits interact with gender. We argue that our findings both expose an individual-level source of poor collective cooperation in the built environment industry, and underscore the need to address persistently low female recruitment and retention rates. Journal: Construction Management and Economics Pages: 773-788 Issue: 9 Volume: 38 Year: 2020 Month: 9 X-DOI: 10.1080/01446193.2020.1757732 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1757732 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:9:p:773-788 Template-Type: ReDIF-Article 1.0 Author-Name: Christina M. Scott-Young Author-X-Name-First: Christina M. Author-X-Name-Last: Scott-Young Author-Name: Michelle Turner Author-X-Name-First: Michelle Author-X-Name-Last: Turner Author-Name: Sarah Holdsworth Author-X-Name-First: Sarah Author-X-Name-Last: Holdsworth Title: Male and female mental health differences in built environment undergraduates Abstract: The construction industry faces skills shortages and growing mental health issues which have stimulated a research focus on the underrepresentation of female employees and on its tough macho-culture and stressful working conditions. Evidence of sex differences in construction workers’ mental health is starting to emerge, with women and younger workers experiencing the greatest levels of distress. This study takes an upstream perspective on construction human resources to explore sex differences in mental health and resilience in the early career pipeline of emerging built environment (BE) professionals. A survey of 384 BE undergraduates was conducted using the DASS-21 measure of mental health and the Resilience at University scale to explore the psychological adjustment of first and final year student cohorts. Data were analysed using descriptive statistics, independent samples t-tests, and regression. Compared to first year students, female students’ mental health appeared to have deteriorated across the four-year degree, whereas, male students’ overall mental health improved. The results suggest that the construction classroom may be operating as a microcosm of the cultural environment faced by women in society in general and in the construction industry with its macho culture filtering back into the university sector. These findings suggest the need for greater attention to sex and gender differences in mental health. It is recommended that construction educators and employers partner together to proactively affect culture change by addressing gender bias early, by consciously creating a female-friendly, inclusive culture which emphasises a sense of belonging, and by providing gender-appropriate support systems and resilience training for emerging construction professionals. Journal: Construction Management and Economics Pages: 789-806 Issue: 9 Volume: 38 Year: 2020 Month: 9 X-DOI: 10.1080/01446193.2020.1748213 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1748213 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:9:p:789-806 Template-Type: ReDIF-Article 1.0 Author-Name: Bingsheng Liu Author-X-Name-First: Bingsheng Author-X-Name-Last: Liu Author-Name: Qi Wang Author-X-Name-First: Qi Author-X-Name-Last: Wang Author-Name: Guangdong Wu Author-X-Name-First: Guangdong Author-X-Name-Last: Wu Author-Name: Junwei Zheng Author-X-Name-First: Junwei Author-X-Name-Last: Zheng Author-Name: Ling Li Author-X-Name-First: Ling Author-X-Name-Last: Li Title: How family-supportive supervisor affect Chinese construction workers’ work-family conflict and turnover intention: investigating the moderating role of work and family identity salience Abstract: Work-family conflict and high turnover intention of construction workers have been and will continue to be significant concerns in the construction industry. To explore antecedents of work-family conflict and identify which workers are more likely to exit their organisations when they experience work-family conflict, this study examines how family-supportive supervisor (FSS) affects construction workers’ work-family conflict and turnover intention, and how identity salience moderates the relationship between work-family conflict and turnover intention. Data were collected from a sample of 271 construction workers. The results revealed that family-supportive supervisor reduced work-to-family conflict (WFC) and family-to-work conflict (FWC), which in turn predicted turnover intention. The results further suggested that construction workers with low work identity salience or high family identity salience were more likely to exit their organisation when they experienced WFC. Moreover, workers with high work identity salience reported a greater level of turnover intention when they experienced FWC. Findings will help managers in construction organisations deepen their understanding of work-family conflict. Journal: Construction Management and Economics Pages: 807-823 Issue: 9 Volume: 38 Year: 2020 Month: 9 X-DOI: 10.1080/01446193.2020.1748892 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1748892 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:9:p:807-823 Template-Type: ReDIF-Article 1.0 Author-Name: Jeppe Z. N. Ajslev Author-X-Name-First: Jeppe Z. N. Author-X-Name-Last: Ajslev Author-Name: Christian D. Wåhlin-Jacobsen Author-X-Name-First: Christian D. Author-X-Name-Last: Wåhlin-Jacobsen Author-Name: Mikkel Brandt Author-X-Name-First: Mikkel Author-X-Name-Last: Brandt Author-Name: Jeppe L. Møller Author-X-Name-First: Jeppe L. Author-X-Name-Last: Møller Author-Name: Lars L. Andersen Author-X-Name-First: Lars L. Author-X-Name-Last: Andersen Title: Losing face from engagement – an overlooked risk in the implementation of participatory organisational health and safety initiatives in the construction industry Abstract: Participatory designs are regarded as a positive way to develop and execute organisational health and safety interventions in the construction industry. While most studies focus on effect measures, little is known about process-related factors shaping the outcomes of interventions. In this article, the authors suggest that success in implementing organisational interventions is tied to microsocial mechanisms that affect whether engagement and creativity materialise into improvements. In this regard, interaction within intervention activities has been overlooked as relevant data sources. To exemplify how these may be useful, video-recorded interactions between participants in an intervention workshop setting are analysed. The framework focuses on threats to the participants’ face (i.e. their public self-image), the participants “facework”, and on how social action is oriented to deontic, epistemic and emotional domains of order. The analysis shows how threats to the participants’ faces arise in interaction, diverting the focus of discussions away from the aim of the workshops; developing initiatives to improve employees’ health and safety. The analysis highlights that participatory interventions may be ineffective if potential face threats are not mitigated and managed actively. We suggest that the manager-facilitator-employee communicational design should be an area of increased focus. Journal: Construction Management and Economics Pages: 824-839 Issue: 9 Volume: 38 Year: 2020 Month: 9 X-DOI: 10.1080/01446193.2020.1759811 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1759811 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:9:p:824-839 Template-Type: ReDIF-Article 1.0 Author-Name: Johan Ninan Author-X-Name-First: Johan Author-X-Name-Last: Ninan Author-Name: Ashwin Mahalingam Author-X-Name-First: Ashwin Author-X-Name-Last: Mahalingam Author-Name: Stewart Clegg Author-X-Name-First: Stewart Author-X-Name-Last: Clegg Author-Name: Shankar Sankaran Author-X-Name-First: Shankar Author-X-Name-Last: Sankaran Title: ICT for external stakeholder management: sociomateriality from a power perspective Abstract: External stakeholder support is critical to the success of megaprojects, necessitating strategic engagement, often using Information and Communications Technology (ICT). We conducted 30 semi-structured interviews with a megaproject team and analysed their social media communications with the project community. The findings show three ICT practices used for managing external stakeholders: visualisation, simulation and social mediatisation. Taking a sociomateriality lens we demonstrate how these practices are used for diverse unintended uses to manage external stakeholders. Anchored in a dimensions of power framework, we discuss how these ICT practices were strategically used for persuading, framing and hegemonizing external stakeholders in megaprojects. Theoretically, we highlight the role of ICT for managing external stakeholders over the current use of improving the competitive advantage of internal stakeholders. Practically, social media is used to articulate practices in all the strategic roles, positioning it in a role as a critical ICT tool for external stakeholder management in infrastructure megaprojects. Journal: Construction Management and Economics Pages: 840-855 Issue: 9 Volume: 38 Year: 2020 Month: 9 X-DOI: 10.1080/01446193.2020.1755047 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1755047 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:9:p:840-855 Template-Type: ReDIF-Article 1.0 Author-Name: George Papachristos Author-X-Name-First: George Author-X-Name-Last: Papachristos Author-Name: Nishesh Jain Author-X-Name-First: Nishesh Author-X-Name-Last: Jain Author-Name: Esfandiar Burman Author-X-Name-First: Esfandiar Author-X-Name-Last: Burman Author-Name: Nici Zimmermann Author-X-Name-First: Nici Author-X-Name-Last: Zimmermann Author-Name: Xiaoying Wu Author-X-Name-First: Xiaoying Author-X-Name-Last: Wu Author-Name: Pei Liu Author-X-Name-First: Pei Author-X-Name-Last: Liu Author-Name: Dejan Mumovic Author-X-Name-First: Dejan Author-X-Name-Last: Mumovic Author-Name: Borong Lin Author-X-Name-First: Borong Author-X-Name-Last: Lin Author-Name: Mike Davies Author-X-Name-First: Mike Author-X-Name-Last: Davies Author-Name: Andrew Edkins Author-X-Name-First: Andrew Author-X-Name-Last: Edkins Title: Low carbon building performance in the construction industry: a multi-method approach of system dynamics and building performance modelling Abstract: The construction industry contributes significantly to energy consumption and carbon emissions. Moreover, people spend more time inside buildings, so their health is increasingly influenced by indoor environmental conditions. When considered through these lenses, the concept of total building performance can span energy consumption, the associated CO2 emissions, and indoor environmental quality (IEQ). At the individual project level, building underperformance with respect to energy and IEQ is frequent, and the ex post performance gap is partially attributed to the construction project management and operations phase of the building lifecycle. This underperformance motivates the research of this paper into the construction process outcomes in terms of energy performance and IEQ, and ways to reduce the performance gap. The paper develops a multi-methodology framework to analyse the effect of building development project process on energy performance and IEQ from an operations management perspective. The framework couples system dynamics modelling of construction project management to building performance modelling. The paper details the way they are coupled, the application steps and data requirements, so that they can be applied on a case by case basis. The aim is to combine operations management to building performance disciplines and deliver insights for industry practitioners and policy makers. Journal: Construction Management and Economics Pages: 856-876 Issue: 9 Volume: 38 Year: 2020 Month: 9 X-DOI: 10.1080/01446193.2020.1748212 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1748212 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:9:p:856-876 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Francesco Daniele Author-X-Name-First: Francesco Author-X-Name-Last: Daniele Author-Name: Benson T. H. Lim Author-X-Name-First: Benson T. H. Author-X-Name-Last: Lim Title: Integrating ex-offenders into the Australian construction industry Abstract: Contributing to the development of employment requirements as an emerging theme in social procurement theory and addressing the evidence vacuum in social procurement research and policy relating to the employment of ex-offenders, the results of a survey of 94 sub-contractors in the Australian construction industry are reported. Results indicate a relatively positive attitudes towards the employment of ex-offenders compared to other industries but also numerous barriers to sustainable employment identified. These include: perceived risks of re-offending; general behavioural problems; and lack of appropriate job skills. Considerable variations exist in perceptions of risk and practices in employing ex-offenders between trades, firm size and past experiences of hiring ex-offenders. It is concluded that policy makers cannot treat the construction industry or ex-offenders as a homogeneous whole and that negative stigmas need to be challenged through supply chain education and capacity-building programmes which provide knowledge, resources and wrap-around support services to enable the successful integration into the construction industry. Theoretically, the results spotlight the potential value of feminist theory in exploring how perceptions of ex-offenders might vary across different disadvantaged groups targeted by social procurement policies. Theories of cross sector collaboration could also be usefully mobilised to explore how new shared practices can be developed between the many organisations involved in reintegrating ex-offenders into employment. Journal: Construction Management and Economics Pages: 877-893 Issue: 10 Volume: 38 Year: 2020 Month: 10 X-DOI: 10.1080/01446193.2019.1674449 File-URL: http://hdl.handle.net/10.1080/01446193.2019.1674449 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:10:p:877-893 Template-Type: ReDIF-Article 1.0 Author-Name: Donna Bridges Author-X-Name-First: Donna Author-X-Name-Last: Bridges Author-Name: Elizabeth Wulff Author-X-Name-First: Elizabeth Author-X-Name-Last: Wulff Author-Name: Larissa Bamberry Author-X-Name-First: Larissa Author-X-Name-Last: Bamberry Author-Name: Branka Krivokapic-Skoko Author-X-Name-First: Branka Author-X-Name-Last: Krivokapic-Skoko Author-Name: Stacey Jenkins Author-X-Name-First: Stacey Author-X-Name-Last: Jenkins Title: Negotiating gender in the male-dominated skilled trades: a systematic literature review Abstract: Occupations in the skilled trades are highly segregated with women comprising 1–3% of this workforce in Western nations. We report on a systematic review of 26 articles, from 1998 to 2019, which explored women’s recruitment and retention in the skilled trades. Two research questions underpinned the review; the first identified challenges and barriers, the second identified success factors. Furthermore, the review examines why percentages of tradeswomen remain lower than those of women in professional occupations within the industry. The literature included in this review focuses on the barriers to women’s employment without sufficient emphasis on solutions to overcoming those barriers. The most common explanation for the problems of recruitment and attrition made in the literature is the failure of the masculine culture to change. However, we found little theoretical examination of masculinity and masculine culture beyond the hegemonic binary. Whilst many of the barriers exist for all women in construction, we argue that two distinct factors impact women in the skilled trades more than women in other occupations in the industry. These are the gendered body and informal and unregulated employment practices. These significant points of difference shed light on the future focus for research about women in the skilled trades. Journal: Construction Management and Economics Pages: 894-916 Issue: 10 Volume: 38 Year: 2020 Month: 10 X-DOI: 10.1080/01446193.2020.1762906 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1762906 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:10:p:894-916 Template-Type: ReDIF-Article 1.0 Author-Name: Lameck Onsarigo Author-X-Name-First: Lameck Author-X-Name-Last: Onsarigo Author-Name: Kevin Duncan Author-X-Name-First: Kevin Author-X-Name-Last: Duncan Author-Name: Alan Atalah Author-X-Name-First: Alan Author-X-Name-Last: Atalah Title: The effect of prevailing wages on building costs, bid competition, and bidder behaviour: evidence from Ohio school construction Abstract: The Davis-Bacon Act and other state prevailing wage laws are instituted to, among other things, protect local compensation standards from possible degradations associated with public construction and create a level playing field for all competing contractors. The impact of prevailing wages on the cost of construction projects to the taxpayers is an issue that continues to be debated at the state and federal levels. In this paper, data from recent school construction projects in Ohio are used to examine the impact of federal prevailing wage standards on construction costs and bid competition. Results from the examination of all bids and winning bids indicate that prevailing wage requirements do not have a statistically significant effect on building costs or the level of bid competition. Results from endogenous treatment estimators provide additional evidence that the prevailing wage policy does not increase costs or limit competition. Additional analysis of all bids indicates that the cost-reducing effect of increased competition is stronger on projects covered by the prevailing wage policy. Journal: Construction Management and Economics Pages: 917-933 Issue: 10 Volume: 38 Year: 2020 Month: 10 X-DOI: 10.1080/01446193.2020.1723806 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1723806 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:10:p:917-933 Template-Type: ReDIF-Article 1.0 Author-Name: Ruixue Zhu Author-X-Name-First: Ruixue Author-X-Name-Last: Zhu Author-Name: Xiancun Hu Author-X-Name-First: Xiancun Author-X-Name-Last: Hu Author-Name: Chunlu Liu Author-X-Name-First: Chunlu Author-X-Name-Last: Liu Title: Structural analysis of inter-industrial linkages: an application to the Australian construction industry Abstract: With the rapid growth in economic and technological development, the linkage of the construction industry with the economy has changed in the past decades, which may have generated corresponding changes in other industries. This study sheds new light on the measurement of structural changes in the inter-industrial linkages of an industry using the Leontief model and the Ghosh model based on the hypothetical extraction method. The Australian national input–output tables provided in the World Input–Output Database are employed as an empirical study exploring the influence of construction linkages on other industries’ production input and output. The results indicate that construction effects have become weaker in relation to promoting economic growth, although the mining and quarrying industry and some service industry activities demonstrate strong and positive backward and forward linkages with the construction industry in Australia. This research provides an approach for measuring corresponding changes in other industries caused by one industry’s inter-industrial changes. Journal: Construction Management and Economics Pages: 934-946 Issue: 10 Volume: 38 Year: 2020 Month: 10 X-DOI: 10.1080/01446193.2020.1785627 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1785627 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:10:p:934-946 Template-Type: ReDIF-Article 1.0 Author-Name: Diletta Colette Invernizzi Author-X-Name-First: Diletta Colette Author-X-Name-Last: Invernizzi Author-Name: Giorgio Locatelli Author-X-Name-First: Giorgio Author-X-Name-Last: Locatelli Author-Name: Naomi J. Brookes Author-X-Name-First: Naomi J. Author-X-Name-Last: Brookes Title: Characterising nuclear decommissioning projects: an investigation of the project characteristics that affect the project performance Abstract: Historically, project management research on infrastructure has mostly focused on its planning, design and construction. However, globally, more and more infrastructure, such as nuclear power plants, bridges, dams or oil rigs, are reaching their end-of-life and will soon need to be decommissioned. Decommissioning projects are long, complex and range from small projects to multi-billion megaprojects. Their costs keep increasing, while there is a limited understanding of why this happens. Nuclear Decommissioning Projects and Programmes (NDPs) are the unit of analysis of this article, due to the relevance of this sector and the number of public information available. The aim is to identify the NDP characteristics that mostly affect the NDP performance in terms of cost and time. Findings from the application of content analysis on the information collected through 35 interviews with senior practitioners highlight the importance of several NDP characteristics, including the need to have detailed knowledge of the site conditions, a good relationship with the regulatory authorities, the availability of storage facilities and stable funding. Journal: Construction Management and Economics Pages: 947-963 Issue: 10 Volume: 38 Year: 2020 Month: 10 X-DOI: 10.1080/01446193.2020.1775859 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1775859 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:10:p:947-963 Template-Type: ReDIF-Article 1.0 Author-Name: Susanna Hedborg Author-X-Name-First: Susanna Author-X-Name-Last: Hedborg Author-Name: Tina Karrbom Gustavsson Author-X-Name-First: Tina Author-X-Name-Last: Karrbom Gustavsson Title: Developing a neighbourhood: exploring construction projects from a project ecology perspective Abstract: As a consequence of ongoing urbanisation, construction projects are likely to be performed in multi-project contexts. Zooming out from the single project and focussing on the context in which construction projects are performed is suggested as a way to broaden our understanding and develop new theory. The empirical case in focus here, which is studied as a project ecology, is the development of a major urban development district, where several interdependent construction projects have been initiated in sequence and in parallel in a limited geographical area. This case poses several challenges to the developers (construction clients) who are performing their projects simultaneously, and literally, as neighbours. Therefore, we zoom out from the single construction project and put the project in a wider context on a macro level, to increase the understanding of the context in which construction projects are performed. The theoretical lens of social capital helps us zoom in on the interdependencies that develop over time, going beyond traditional, contractual and vertical relationships. Based on empirical material, including interviews and meeting observations, the findings indicate that the developers have to coordinate horizontal interdependencies between projects. The findings also show that the construction client’s role has been extended from initiating and delivering the project mission to also having a collaborator role between projects, where ambidexterity is required. Journal: Construction Management and Economics Pages: 964-976 Issue: 10 Volume: 38 Year: 2020 Month: 10 X-DOI: 10.1080/01446193.2020.1805479 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1805479 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:10:p:964-976 Template-Type: ReDIF-Article 1.0 Author-Name: Carter B. Casady Author-X-Name-First: Carter B. Author-X-Name-Last: Casady Author-Name: David Baxter Author-X-Name-First: David Author-X-Name-Last: Baxter Title: Pandemics, public-private partnerships (PPPs), and force majeure | COVID-19 expectations and implications Abstract: The novel coronavirus (COVID-19) pandemic is placing unprecedented stress on public-private partnerships (PPPs), creating the real possibility of widespread project failures. The disruption and potential collapse of multiple PPP projects will likely trigger force majeure contractual provisions, but the applicability and efficacy of these generic catch-all clauses remain in question. This critical note therefore discusses the implications of force majeure contractual conditions on PPPs in the COVID-19 epoch. We first define the concept of force majeure as it pertains to pandemics. Next, we review a select number of international policies for such events, outlining their key features and glaring shortcomings. Then, we use Novia Scotia’s Highway 104 Twinning Project as an illustrative case example of improved force majeure risk management. Finally, after reflecting on the three ironies of construction crisis management, we outline the need for swift trust in PPPs during this current pandemic and conclude by calling for a comprehensive revision of force majeure contract provisions. Journal: Construction Management and Economics Pages: 1077-1085 Issue: 12 Volume: 38 Year: 2020 Month: 12 X-DOI: 10.1080/01446193.2020.1817516 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1817516 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:12:p:1077-1085 Template-Type: ReDIF-Article 1.0 Author-Name: Fred Sherratt Author-X-Name-First: Fred Author-X-Name-Last: Sherratt Author-Name: Simon Sherratt Author-X-Name-First: Simon Author-X-Name-Last: Sherratt Author-Name: Chris Ivory Author-X-Name-First: Chris Author-X-Name-Last: Ivory Title: Challenging complacency in construction management research: the case of PPPs Abstract: Public-Private Partnerships (PPPs) are joint ventures in which the private sector works in partnership with government bodies to deliver public sector projects with the intention to deliver them more quickly, efficiently and with better value for money. They are also one of the most contentious project delivery mechanisms to have been mobilised in recent decades. Research has demonstrated the lack of realised value within many such projects, yet construction management academics continue to examine ways of increasing, implementing and optimising this approach in practice, even encouraging its adoption worldwide despite growing social and political dissatisfaction. Here, we go beyond what we see as myopic construction management perspectives, placing our body of work firmly within wider economic, political and social contexts. We challenge uncritical academic compliance with a process that demonstrably contributes to economic inequalities, opportunism and exploitation. We confront the lack of criticality in construction management research of PPPs, and call for construction management academics to broaden their research focus and engage in more robust critique and analysis of construction systems, as they are realised in practice. Journal: Construction Management and Economics Pages: 1086-1100 Issue: 12 Volume: 38 Year: 2020 Month: 12 X-DOI: 10.1080/01446193.2020.1744674 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1744674 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:12:p:1086-1100 Template-Type: ReDIF-Article 1.0 Author-Name: Dayna Rodger Author-X-Name-First: Dayna Author-X-Name-Last: Rodger Author-Name: Nicola Callaghan Author-X-Name-First: Nicola Author-X-Name-Last: Callaghan Author-Name: Craig S. Thomson Author-X-Name-First: Craig S. Author-X-Name-Last: Thomson Title: The loosening control of social housing: creating a holistic retrofit system for an ageing population through the lens of governmentality Abstract: With social housing providing accommodation to the most vulnerable individuals within society it is recognised as a key priority area which has the potential to deliver holistic integration across a range of service providers. A need is emerging to examine the nexus between the energy, housing, health and social care sectors to understand how these separate but interlinked policy agendas are integrated in practice. Presented are the findings of interviews conducted with 24 key stakeholders under a thematic analysis, exploring the key themes and prevalent trends which shape the challenges to creating a holistic retrofit system within social housing for the improved wellbeing of older people, through the lens of governmentality. The analysis revealed that the ideological barriers presented prevent a holistic retrofit process and inhibit the potential to create successful collaboration within the healthy ageing agenda. The retrofit of domestic housing is centred around the concept of sustainability; however, the ideological prioritisation of economic considerations over people has created an increased pressure on resources, favouring ease and cost cutting over communication, collaboration, and efficiency. Significant change must occur within governance and organisational structures; increasing flexibility and alliances, creating a viable means of interaction to create solutions and improve implementation. Journal: Construction Management and Economics Pages: 1101-1121 Issue: 12 Volume: 38 Year: 2020 Month: 12 X-DOI: 10.1080/01446193.2020.1752925 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1752925 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:12:p:1101-1121 Template-Type: ReDIF-Article 1.0 Author-Name: Sara Hajikazemi Author-X-Name-First: Sara Author-X-Name-Last: Hajikazemi Author-Name: Kirsi Aaltonen Author-X-Name-First: Kirsi Author-X-Name-Last: Aaltonen Author-Name: Tuomas Ahola Author-X-Name-First: Tuomas Author-X-Name-Last: Ahola Author-Name: Wenche Aarseth Author-X-Name-First: Wenche Author-X-Name-Last: Aarseth Author-Name: Bjorn Andersen Author-X-Name-First: Bjorn Author-X-Name-Last: Andersen Title: Normalising deviance in construction project organizations: a case study on the collapse of Carillion Abstract: In 2018, the Construction giant Carillion went into compulsory liquidation costing the UK taxpayers an estimated £148m. According to our analysis performed on the case, the demise of Carillion was the result of accumulation of failures and normalisation of deviations from good practice. The purpose of this study is to better understand how deviance can become the norm such that actors in the context of the construction organisations such as Carillion, come to adopt deviant practices rather than respecting their accepted industry codes and ethos. This study is based on an in-depth analysis of publicly available data on the case of Carillion. Our aim is to better understand the process of normalisation of deviance and its potential effect on organisations. Our analysis of the case revealed three specific types of normalised deviance: late payments to suppliers, aggressive accounting and payment of high dividends to shareholders despite the troubled financial status of the firm. The results of our work contribute to theory by showing that normalisation of deviance is a gradual process which can be influenced by actors both within the focal organisation as well as actors in its environment. The managerial implications highlight the need for all actors in the construction sector to become more aware of the normalising deviance process and its potential negative effects, which can be mitigated by stronger adherence to controls in the external environment in which the organisation operates. Journal: Construction Management and Economics Pages: 1122-1138 Issue: 12 Volume: 38 Year: 2020 Month: 12 X-DOI: 10.1080/01446193.2020.1804069 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1804069 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:12:p:1122-1138 Template-Type: ReDIF-Article 1.0 Author-Name: George Denny-Smith Author-X-Name-First: George Author-X-Name-Last: Denny-Smith Author-Name: Megan Williams Author-X-Name-First: Megan Author-X-Name-Last: Williams Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: Assessing the impact of social procurement policies for Indigenous people Abstract: Governments of highly developed western nations with colonised Indigenous populations such as Australia, Canada and South Africa are increasingly turning to social procurement policies in an attempt to solve social inequities between Indigenous people and other citizens. They seek to use policies and funds attached to infrastructure development and construction to encourage private sector companies to provide training, employment and business opportunities for Indigenous people in the communities in which construction occurs. This paper outlines the rise of these policies and their origins, and critiques their connection to Indigenous people’s human rights, impact measurement, evaluation and accountability mechanisms. In doing so this paper also explores benefits and potential of social procurement policies, as well as risks. Drawing on insights from an Aboriginal-developed evaluation framework, Ngaa-bi-nya, and Indigenous Standpoint Theory, this paper highlights Indigenous peoples’ definitions of value and outlines their relevance to social procurement. Introducing the notion of cultural counterfactuals into social impact measurement research, it also offers a new conceptual framework to enable policymakers and practitioners to more accurately account for social procurement value and impact, including Indigenous people’s notions of social value. Journal: Construction Management and Economics Pages: 1139-1157 Issue: 12 Volume: 38 Year: 2020 Month: 12 X-DOI: 10.1080/01446193.2020.1795217 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1795217 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:12:p:1139-1157 Template-Type: ReDIF-Article 1.0 Author-Name: Lei Ju Author-X-Name-First: Lei Author-X-Name-Last: Ju Author-Name: Wanyu Zhao Author-X-Name-First: Wanyu Author-X-Name-Last: Zhao Author-Name: Chunlin Wu Author-X-Name-First: Chunlin Author-X-Name-Last: Wu Author-Name: Haofan Li Author-X-Name-First: Haofan Author-X-Name-Last: Li Author-Name: Xin Ning Author-X-Name-First: Xin Author-X-Name-Last: Ning Title: Abusive supervisors and employee work-to-family conflict in Chinese construction projects: how does family support help? Abstract: Work to family conflict (WFC) experienced by employees working in the construction industry has received significant attention from researchers. However, workplace bullying and incivility are rarely considered in relation to WFC, and even more rarely in the context of Chinese construction. Consequently, this study aims to examine how abusive supervisors can influence WFC for employees. Through two surveys of Chinese construction workers, this study analyses the mediation effect of employee psychological distress, and the moderation mechanism of employee family support on the relationship between abusive supervision and employee WFC. The findings show that abusive supervision is positively related to employee WFC, and employees’ psychological distress mediates this relationship significantly. Employee family support moderates the direct and indirect relationship between abusive supervision and employee WFC. Understanding how abusive supervision influences employee WFC is useful for both its theoretical and practical implications, particularly in effectively relieving employee work pressure, reducing the transfer of individual stress into the family domain, promoting employee well-being, and improving construction project performance. Journal: Construction Management and Economics Pages: 1158-1178 Issue: 12 Volume: 38 Year: 2020 Month: 12 X-DOI: 10.1080/01446193.2020.1817962 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1817962 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:12:p:1158-1178 Template-Type: ReDIF-Article 1.0 Author-Name: Regine Grytnes Author-X-Name-First: Regine Author-X-Name-Last: Grytnes Author-Name: Dylan E. Tutt Author-X-Name-First: Dylan E. Author-X-Name-Last: Tutt Author-Name: Lars Peter Sønderbo Andersen Author-X-Name-First: Lars Peter Sønderbo Author-X-Name-Last: Andersen Title: Developing safety cooperation in construction: between facilitating independence and tightening the grip Abstract: Cooperation about safety and joint responsibility between managers and workers is one of the cornerstones of health and safety work. However, attempts at ensuring safety in the workplace run the risk of focussing on formalities and compliance rather than on joint engagement in safety. Drawing on an understanding of safety as practice, this study attempts to empirically unpack the difference between cooperation as engaging with local knowledges and the disciplining of unsafe behaviour. The research involved an ethnographic study at two large construction sites in Denmark and follows empirical examples of how safety breaches are identified, catalogued, and revealed later on at safety meetings. Managers saw this as an attempt to engage the workers. However, the workers saw this as a punitive way of criticizing their work at a distance. They felt that this practice of moving safety from the construction site and in to meeting rooms ran counter to aims of establishing engaging and effective safety practices close to the work. Efforts to engage workers in safer ways of working should therefore acknowledge the integrated nature of safety practice and the value placed on independence, discretion and negotiation when developing cooperation about workplace safety. Journal: Construction Management and Economics Pages: 977-992 Issue: 11 Volume: 38 Year: 2020 Month: 11 X-DOI: 10.1080/01446193.2020.1726978 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1726978 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:11:p:977-992 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Ron Wakefield Author-X-Name-First: Ron Author-X-Name-Last: Wakefield Author-Name: Derek Walker Author-X-Name-First: Derek Author-X-Name-Last: Walker Title: The client’s role in promoting work health and safety in construction projects: balancing contracts and relationships to effect change Abstract: It is increasingly expected that public sector clients embed work health and safety (WHS) into procurement and project management practices for infrastructure/engineering construction projects. Client practices in relation to the management of WHS were examined in a longitudinal case study conducted in a public infrastructure programme of work in Australia. Control mechanisms for WHS at the client-contractor boundary were explored over a 12-month period. Interviews were held with representatives of client and contractor organisations. Formal control mechanisms were implemented. Initially, the implementation of formal controls created tension at the client-contractor interface as it was interpreted as signalling a lack of trust and client interference with contractors’ processes. However, these tensions were alleviated through the development of interpersonal relationships between client and contractor personnel at a local project level. The resolution of issues at the client-contractor interface was facilitated by individuals who engaged in boundary spanning behaviours to facilitate knowledge sharing and coordination of effort on both sides. Relationship-based control mechanisms supplemented the use of formal controls and enhanced the client’s ability to influence contractors’ WHS practices. The study provides important new knowledge regarding the client’s role in driving WHS performance in infrastructure/engineering construction projects. Journal: Construction Management and Economics Pages: 993-1008 Issue: 11 Volume: 38 Year: 2020 Month: 11 X-DOI: 10.1080/01446193.2020.1778758 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1778758 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:11:p:993-1008 Template-Type: ReDIF-Article 1.0 Author-Name: Michelle Turner Author-X-Name-First: Michelle Author-X-Name-Last: Turner Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Title: Examining the interaction between bodily pain and mental health of construction workers Abstract: Construction work is physically demanding, and incidences of physical injury and work disability are high. This study explores musculoskeletal bodily pain and the impact this has on construction workers’ mental health. A mixed-method approach incorporated survey and interview data. Sixty-seven construction workers completed a survey consisting of work ability and mental health measures. Eighteen workers who completed a survey participated in an interview exploring the occurrence and management of body pain, and the impact of pain on mental health. Survey findings indicated that participants whose pain had originated from work had significantly higher levels of depression, anxiety, and stress severity. Findings also revealed that depression, anxiety, and stress had a negative relationship with work ability indicators, suggesting that work ability is likely to decline when workers experience poor mental health. Key themes emerging from the interview data comprised of the expectation of pain, managing pain, impact of pain on mental health, pressure to work with pain, work ability and planning for the future, and the stigma of mental health. A conceptual model is presented which illustrates the relationship between work tasks, pain, mental health, and work ability. The model identifies that anticipated and experienced bodily pain creates harmful psychological demands for workers which impacts on their mental health. Journal: Construction Management and Economics Pages: 1009-1023 Issue: 11 Volume: 38 Year: 2020 Month: 11 X-DOI: 10.1080/01446193.2020.1791920 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1791920 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:11:p:1009-1023 Template-Type: ReDIF-Article 1.0 Author-Name: Alex Albert Author-X-Name-First: Alex Author-X-Name-Last: Albert Author-Name: Idris Jeelani Author-X-Name-First: Idris Author-X-Name-Last: Jeelani Author-Name: Kevin Han Author-X-Name-First: Kevin Author-X-Name-Last: Han Title: Developing hazard recognition skill among the next-generation of construction professionals Abstract: Globally, a large number of safety hazards remain unrecognised in construction workplaces. These unrecognised safety hazards are also likely to remain unmanaged and can potentially cascade into unexpected safety incidents. Therefore, the development of hazards recognition skill – particularly among the next-generation of construction professionals – is vital for injury prevention and safe work-operations. To foster the development of such skill, the current investigation examined the effect of administering a hazard recognition intervention to students seeking to enter the construction workforce. First, prior to introducing the intervention, the pre-intervention hazard recognition skill of the participating students was measured. Next, the intervention that included a number of programme elements was introduced. The programme elements included (1) visual cues to promote systematic hazard recognition, (2) personalised hazard recognition performance feedback, (3) visual demonstration of common hazard recognition search weaknesses, and (4) diagnosis of hazard search weaknesses using metacognitive prompts. Finally, the post-intervention skill demonstrated by the student participants was measured and compared against their pre-intervention performance. The results suggest that the intervention was effective in improving the hazard recognition skill demonstrated by the next-generation of construction professionals. The observed effect was particularly prominent among those that demonstrated relatively lower levels of skill in the pre-intervention phase. The research also unveiled particular impediments to hazards recognition that the participants experienced. Journal: Construction Management and Economics Pages: 1024-1039 Issue: 11 Volume: 38 Year: 2020 Month: 11 X-DOI: 10.1080/01446193.2020.1797133 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1797133 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:11:p:1024-1039 Template-Type: ReDIF-Article 1.0 Author-Name: Santhosh Loganathan Author-X-Name-First: Santhosh Author-X-Name-Last: Loganathan Author-Name: Perry Forsythe Author-X-Name-First: Perry Author-X-Name-Last: Forsythe Title: Unravelling the influence of teamwork on trade crew productivity: a review and a proposed framework Abstract: Research in construction labour productivity (CLP) has paid little attention to the social and behavioural aspects of onsite, physical, construction trade crews. The mainstream organisational and management literature provides an alternative line of inquiry where trade crews can be conceptualised as teams. By taking this perspective, the behaviours and interdependencies among crew members can be more readily understood in terms of influences on CLP. Using a structured review methodology, a conceptual framework is developed in stages by merging the concepts of teamwork and CLP. The framework begins with a broad scaffolding that draws together two established models: the input-mediators-output model and the big five framework. The more detailed and explanatory contribution uses these from the literature to identify a set of task-focussed and relationship-focussed team processes. A key benefit of the framework is that crew teamwork can be used as a means of mediating what was previously many separate CLP variables. Importantly, the proposed framework views teamwork in the context of trade crews as against viewing teamwork as a professional or managerially focussed phenomenon. To this end, this paper advances three research propositions and methodological possibilities which in future research could be tested to tailor the framework for best fit. Journal: Construction Management and Economics Pages: 1040-1060 Issue: 11 Volume: 38 Year: 2020 Month: 11 X-DOI: 10.1080/01446193.2020.1795900 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1795900 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:11:p:1040-1060 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Rowan Braham Author-X-Name-First: Rowan Author-X-Name-Last: Braham Author-Name: Yuan Yiming Author-X-Name-First: Yuan Author-X-Name-Last: Yiming Author-Name: Chris Bronkhorst Author-X-Name-First: Chris Author-X-Name-Last: Bronkhorst Title: Relational determinants of construction project outcomes: a social network perspective Abstract: In contributing a missing qualitative dimension to the emerging relationship-based approach to construction project management, social network theories are used to present a thematic analysis of interviews with senior construction project managers. The results provide new insights into the key stakeholders and social structures which determine construction project outcomes in the design and construct procurement context. They show that from a socio-structural perspective, a design and construct project can be broadly divided into four main stages: project scope/feasibility; tendering/estimating; design development/project planning; construction/handover. Key relational structures linked to project outcomes, both within and between stages, are discussed and the results show that the relationships between actors in different stages are as important as within each stage. Project managers perform an especially critical bridging role in developing a consistent project narrative and language which links project stages together. It is concluded that as lead indicators of project outcomes, the socio-structural concepts of bridging, centrality, structural equivalence and clustering can provide a valuable theoretical and practical foundation to further explore the emergent but as yet under-theorised relationship-based approach to project management. Journal: Construction Management and Economics Pages: 1061-1076 Issue: 11 Volume: 38 Year: 2020 Month: 11 X-DOI: 10.1080/01446193.2020.1776350 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1776350 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:38:y:2020:i:11:p:1061-1076 Template-Type: ReDIF-Article 1.0 Author-Name: Thayla Zomer Author-X-Name-First: Thayla Author-X-Name-Last: Zomer Author-Name: Andy Neely Author-X-Name-First: Andy Author-X-Name-Last: Neely Author-Name: Rafael Sacks Author-X-Name-First: Rafael Author-X-Name-Last: Sacks Author-Name: Ajith Parlikad Author-X-Name-First: Ajith Author-X-Name-Last: Parlikad Title: Exploring the influence of socio-historical constructs on BIM implementation: an activity theory perspective Abstract: Building Information Modelling (BIM) has been widely seen as bringing a paradigm change to the construction industry. However, scholars have acknowledged that neither widespread BIM implementation nor the envisaged systemic changes within the sector have taken place. Despite acknowledging that the industry’s conditions and embedded contexts shape innovation diffusion, existing studies have not explored in any depth “how” the context might influence the episode of change when a new technology is introduced and the new practices accompanying that technology and old practices co-evolve. By adopting activity theory, its concepts of contradictions and multiple layers within the activity system, in this paper, we explore the interaction between situated and existing practices, or the “how” of implementation; that is, how the activity system is questioned and redefined during an episode of technological change. Drawing on data from multiple case studies, our findings demonstrate that situated practices related to the definition of information requirements, and the production and the handover of information were re-enacted following institutionalised socio-historical constructs (e.g. norms, rules, division of labour) at the industry and organisational levels. The findings provide insights regarding the inertia in the transformation of the sector as also deriving from re-enactments of socio-historical constructs that mediate the institutionalisation of situated practices. Our findings reveal re-enactment as part of the transformation process and contribute to calls for more realistic views on BIM implementation. Journal: Construction Management and Economics Pages: 1-20 Issue: 1 Volume: 39 Year: 2021 Month: 1 X-DOI: 10.1080/01446193.2020.1792522 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1792522 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:1:p:1-20 Template-Type: ReDIF-Article 1.0 Author-Name: Hannes Lindblad Author-X-Name-First: Hannes Author-X-Name-Last: Lindblad Author-Name: Tina Karrbom Gustavsson Author-X-Name-First: Tina Author-X-Name-Last: Karrbom Gustavsson Title: Public clients ability to drive industry change: the case of implementing BIM Abstract: Public clients are proposed as key actors in driving construction industry change towards a more sustainable, efficient and productive industry. Based on how they procure consultants and contractors, it is argued that public clients have the power and are in the position to act as “innovation supporters” and “change agents.” However, the client’s role as a driver of change and innovation is oversimplified and there is a need for further investigation into the client’s ability to drive industry change. This paper presents a case study of a public client’s initiative to drive industry change through the implementation of Building Information Modelling (BIM). We do this by investigating the process of intra-organisational change at the public client by mapping the client’s absorptive capacity for change. The case study shows difficulties in turning the external knowledge into actual transformation when implementing a systemic innovation such as BIM. Findings contribute to the literature on public clients as drivers of change and innovation in construction and are relevant to research on public clients as drivers for industry change and innovation and to research on BIM as a game changer. Journal: Construction Management and Economics Pages: 21-35 Issue: 1 Volume: 39 Year: 2021 Month: 1 X-DOI: 10.1080/01446193.2020.1807032 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1807032 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:1:p:21-35 Template-Type: ReDIF-Article 1.0 Author-Name: Sulafa Badi Author-X-Name-First: Sulafa Author-X-Name-Last: Badi Author-Name: Edward Ochieng Author-X-Name-First: Edward Author-X-Name-Last: Ochieng Author-Name: Mohamed Nasaj Author-X-Name-First: Mohamed Author-X-Name-Last: Nasaj Author-Name: Maria Papadaki Author-X-Name-First: Maria Author-X-Name-Last: Papadaki Title: Technological, organisational and environmental determinants of smart contracts adoption: UK construction sector viewpoint Abstract: This study aims to identify the factors that influence the adoption of smart contracts in the UK construction sector. A deductive questionnaire-based approach informed by the technology-organisation-environment (TOE) model is adopted. The framework is comprised of twelve independent variables and one dependent variable of smart contracts use intention. Ten hypotheses are developed to statistically test the causal relationships between the eleven variables of the research model. The study adopts a convenience sampling approach, with the population of interest being primarily drawn from among UK construction practitioners. The results generated from linear regression analysis suggest that the following four factors have a significant influence on the adoption of smart contracts: supply chain pressure, competitive pressure, top management support, and observability. The descriptive statistics obtained also offer a greater understanding of the perceptions and attitudes towards smart contracts across the UK construction sector. The results demonstrate the usefulness of a perception-based model that utilises the TOE framework to assess facets that influence the adoption of smart contracts. The study contributes to innovation diffusion studies in construction project management and supports “early adopters” at the footfall of the technology’s diffusion curve. Journal: Construction Management and Economics Pages: 36-54 Issue: 1 Volume: 39 Year: 2021 Month: 1 X-DOI: 10.1080/01446193.2020.1819549 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1819549 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:1:p:36-54 Template-Type: ReDIF-Article 1.0 Author-Name: Racha Chahrour Author-X-Name-First: Racha Author-X-Name-Last: Chahrour Author-Name: Mian Atif Hafeez Author-X-Name-First: Mian Atif Author-X-Name-Last: Hafeez Author-Name: Ahmad Mohammad Ahmad Author-X-Name-First: Ahmad Mohammad Author-X-Name-Last: Ahmad Author-Name: Hashim Ibnauf Sulieman Author-X-Name-First: Hashim Ibnauf Author-X-Name-Last: Sulieman Author-Name: Huda Dawood Author-X-Name-First: Huda Author-X-Name-Last: Dawood Author-Name: Sergio Rodriguez-Trejo Author-X-Name-First: Sergio Author-X-Name-Last: Rodriguez-Trejo Author-Name: Mohamad Kassem Author-X-Name-First: Mohamad Author-X-Name-Last: Kassem Author-Name: Khalid Kamal Naji Author-X-Name-First: Khalid Kamal Author-X-Name-Last: Naji Author-Name: Nashwan Dawood Author-X-Name-First: Nashwan Author-X-Name-Last: Dawood Title: Cost-benefit analysis of BIM-enabled design clash detection and resolution Abstract: Building Information Modelling (BIM) is increasingly deployed as part of the processes in Architecture, Engineering and Construction (AEC) industry projects. While the benefits of BIM have been extensively proclaimed, explicit justification in terms of direct cost savings for BIM implementation on real-life projects, particularly for clash detection BIM workstream, are not well documented. This paper proposes and demonstrates a methodology to prove how BIM-based clash detection leads to cost savings. A schema is developed based on literature review and industrial expertise to quantify cost savings achieved by the utilisation of BIM-based clash detection and resolution. This paper provides validation of the proposed schema on a major infrastructure project. The developed schema includes the categorisation of identified clashes based on stakeholder involvement and required actions. The validation used the estimated cost of clashes were those not resolved before site operations took place. This schema simplifies both the categorisation and cost estimation of clashes in design. Estimated savings yielded 20% of contract value using the schema, for the multi-million-dollar project case study, thus extending evidence of BIM savings and benefits. The schema improves the existing process and valorises clash detection, thus allowing stakeholders to conduct a cost-benefit analysis. In addition, the categorisation methodology allows prioritising on the most costly clashes, and draw lessons learnt for further projects. This schema opens the path towards a systematic methodology to appraise the benefits of different BIM uses or processes. Journal: Construction Management and Economics Pages: 55-72 Issue: 1 Volume: 39 Year: 2021 Month: 1 X-DOI: 10.1080/01446193.2020.1802768 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1802768 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:1:p:55-72 Template-Type: ReDIF-Article 1.0 Author-Name: Joonas Lehtovaara Author-X-Name-First: Joonas Author-X-Name-Last: Lehtovaara Author-Name: Olli Seppänen Author-X-Name-First: Olli Author-X-Name-Last: Seppänen Author-Name: Antti Peltokorpi Author-X-Name-First: Antti Author-X-Name-Last: Peltokorpi Author-Name: Pekka Kujansuu Author-X-Name-First: Pekka Author-X-Name-Last: Kujansuu Author-Name: Max Grönvall Author-X-Name-First: Max Author-X-Name-Last: Grönvall Title: How takt production contributes to construction production flow: a theoretical model Abstract: Takt production has recently received increased attention in both the construction industry and academia. However, the research on takt production has focused on documenting single successful cases, while attempts to holistically explore the impact of takt production on construction production flow are scarce. To address this knowledge gap, this study aimed to build a theoretical model of how takt production contributes to construction production flow. A qualitative multiple-case study was conducted to validate propositions based on a literature review, and the results were discussed and synthesized in the form of a theoretical model. The findings indicate that while takt production is a viable method to increase flow, it requires significant effort in terms of planning, control, and continuous improvement. While having a positive impact on process flow (location flow), the effects on operations flow (trade flow) are contradictory. The study has implications for further comprehensive evaluation of the effects of takt production on construction production flow while facilitating more predictable, systemic implementation of takt production across projects. Journal: Construction Management and Economics Pages: 73-95 Issue: 1 Volume: 39 Year: 2021 Month: 1 X-DOI: 10.1080/01446193.2020.1824295 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1824295 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:1:p:73-95 Template-Type: ReDIF-Article 1.0 Author-Name: Paul W Chan Author-X-Name-First: Paul W Author-X-Name-Last: Chan Title: Editorial Journal: Construction Management and Economics Pages: 97-98 Issue: 2 Volume: 39 Year: 2021 Month: 2 X-DOI: 10.1080/01446193.2021.1880157 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1880157 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:2:p:97-98 Template-Type: ReDIF-Article 1.0 Author-Name: Joris Scharpff Author-X-Name-First: Joris Author-X-Name-Last: Scharpff Author-Name: Daan Schraven Author-X-Name-First: Daan Author-X-Name-Last: Schraven Author-Name: Leentje Volker Author-X-Name-First: Leentje Author-X-Name-Last: Volker Author-Name: Matthijs T. J. Spaan Author-X-Name-First: Matthijs T. J. Author-X-Name-Last: Spaan Author-Name: Mathijs M. de Weerdt Author-X-Name-First: Mathijs M. Author-X-Name-Last: de Weerdt Title: Can multiple contractors self-regulate their joint service delivery? A serious gaming experiment on road maintenance planning Abstract: The next step in the use of innovative, dynamic and performance-based contracts for service delivery by contractors could be use of monetary incentives to stimulate self-regulation of the network. Because it is currently unclear how performance-based payments in network tenders can effectively encourage network members to coordinate their own operations, a serious game was performed that simulates road maintenance planning to study changes in decision making and the emergence of network coordination. The experiments show that monetary incentives influence decision making, but their effect may be opposite to their intended aim and can lead to a competitive network. It was, however, also found that this competitiveness is not shown in networks where members are familiar with each other. This leads to the conclusion that penalty-based incentive mechanisms probably interfere with self-regulation and that the social dimension of contractor collaboration is paramount to the success of network-based contracting of construction activities. Journal: Construction Management and Economics Pages: 99-116 Issue: 2 Volume: 39 Year: 2021 Month: 2 X-DOI: 10.1080/01446193.2020.1806336 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1806336 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:2:p:99-116 Template-Type: ReDIF-Article 1.0 Author-Name: Rui Wang Author-X-Name-First: Rui Author-X-Name-Last: Wang Author-Name: Wenxue Lu Author-X-Name-First: Wenxue Author-X-Name-Last: Lu Author-Name: Yuxin Wei Author-X-Name-First: Yuxin Author-X-Name-Last: Wei Title: Owners’ use of contract-based power in construction project transactions: restrictions from process specificity and uncertainty Abstract: Little is known about what restrictions make owners unable to use or give up using contract-based power in construction project transactions. To examine this issue, this research explores the effects of process specificity on owners’ contract design and power use during contract execution as well as the moderating role of uncertainty in these effects using empirical data from 327 construction project transactions in China. The results show that owners can use coercive and legitimate powers based on contractual control while using reward and legitimate powers based on contractual coordination. The increase in process specificity (a special version of asset specificity in construction project transactions) encourages owners to intensify ex ante contract design while restricting their ex post coercive power use based on contractual control. Behavioural uncertainty weakens owners’ tendency to intensify contractual control with increasing process specificity, restricting their contractual-control-based power use. However, task uncertainty strengthens (rather than restricts) owners’ tendency to intensify contract design and power use when process specificity increases. These findings can help practitioners understand how the attributes of construction project transactions are related to transaction costs to affect owners’ contract-based power use, thereby avoiding ineffective power use. Journal: Construction Management and Economics Pages: 117-132 Issue: 2 Volume: 39 Year: 2021 Month: 2 X-DOI: 10.1080/01446193.2020.1830423 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1830423 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:2:p:117-132 Template-Type: ReDIF-Article 1.0 Author-Name: Phuoc Luong Le Author-X-Name-First: Phuoc Luong Author-X-Name-Last: Le Author-Name: Imen Jarroudi Author-X-Name-First: Imen Author-X-Name-Last: Jarroudi Author-Name: Thien-My Dao Author-X-Name-First: Thien-My Author-X-Name-Last: Dao Author-Name: Amin Chaabane Author-X-Name-First: Amin Author-X-Name-Last: Chaabane Title: Integrated construction supply chain: an optimal decision-making model with third-party logistics partnership Abstract: Studies have confirmed the benefits of using Third-party logistics (TPL) for efficient construction management, especially in large projects. Nevertheless, there is a dearth of decision-making models evaluating the exact role of TPL providers as drivers for supply chain (SC) integration and optimisation. This study aims to develop a decision-making model for construction supply chain (CSC) optimisation, with possible TPL integration. The proposed model considers two types of purchased materials (type-1 and type-2) and assists the main contractor in determining construction supply chain management (CSCM) strategies, including supplier selection, order quantity determination, and TPL use evaluation. Using the model, the main contractor can take advantage of the TPL provider’s warehouse and order larger quantities, if necessary, to obtain lower prices offered by suppliers. Through case examples in Canada, we find that the proposed model performs better in optimising total SC cost, as compared to the model without TPL. Model validations also show that TPL can be conditionally used to improve construction logistics performance and to meet practical requirements targeting issues in the construction industry. Journal: Construction Management and Economics Pages: 133-155 Issue: 2 Volume: 39 Year: 2021 Month: 2 X-DOI: 10.1080/01446193.2020.1831037 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1831037 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:2:p:133-155 Template-Type: ReDIF-Article 1.0 Author-Name: Kai Guo Author-X-Name-First: Kai Author-X-Name-Last: Guo Author-Name: Limao Zhang Author-X-Name-First: Limao Author-X-Name-Last: Zhang Author-Name: Tao Wang Author-X-Name-First: Tao Author-X-Name-Last: Wang Title: Concession period optimisation in complex projects under uncertainty: a public–private partnership perspective Abstract: Concession period is decisive in public–private partnership (PPP) projects, particularly for complex projects. A systematic approach incorporating real option analysis (ROA) is proposed to optimise the concession under uncertainty. Options are explored to manage uncertainty in the long concession of PPP projects and an optimisation principle is proposed for the concession optimisation. Sensitivity analysis and case comparison are suggested to test the validity of the optimised concession. Applicability of the approach is tested with a PPP utility tunnel case, in which options to expand and recoup are investigated. Important findings include: (1) interests of participants are balanced through the optimisation, the investment value of the project is increased; (2) profit-sharing mechanism is identified as the most important factor, and a prudent design of it can effectively manage uncertainty; (3) option to recoup can optimise the concession period without harming private developer's interest. This research's novelty lies in (a) exploring the management flexibility and identifying potential options in the concession period of PPP projects; (b) a hybrid approach with the integration of ROA and Sobal-based global sensitivity analysis is proposed to perform the concession optimisation; (c) the profit-risk allocation between participants in PPP projects is balanced under the optimisation principle. Journal: Construction Management and Economics Pages: 156-172 Issue: 2 Volume: 39 Year: 2021 Month: 2 X-DOI: 10.1080/01446193.2020.1849752 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1849752 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:2:p:156-172 Template-Type: ReDIF-Article 1.0 Author-Name: Jing Zhang Author-X-Name-First: Jing Author-X-Name-Last: Zhang Author-Name: Xian-Xun Yuan Author-X-Name-First: Xian-Xun Author-X-Name-Last: Yuan Title: Stochastic modelling of maintenance flexibility in Value for Money assessment of PPP road projects Abstract: Maintenance flexibility has been promoted as a value driver for long-term public–private partnerships (PPPs). However, the value and risk associated with this value driver have not been properly quantified in the Value for Money (VfM) assessment literature. To bridge the gap, a novel stochastic modelling methodology is proposed to characterize the complex interactions among the lifecycle cost (LCC), performance deterioration and maintenance strategies. Four different maintenance strategies are designed to emulate the practice in the traditional and PPP delivery methods. The LCC includes the direct maintenance cost, user cost, residual value, and payment deduction, the last three often being neglected in VfM assessments. Simulation-based optimization and dynamic programming analysis are used to determine the probability distributions of the LCC and the VfM. A hypothetical highway PPP project under an availability payment model is selected as a case study. The results show that maintenance flexibility is indeed able to reduce the LCC for the private party. However, this private efficiency, if not properly regulated, could cause a reduced asset residual value and an increased user cost, making the public party worse off. In addition, for all potential maintenance strategies, the public sector is found to retain significant lifecycle cost risk, largely in the form of user cost. Journal: Construction Management and Economics Pages: 173-191 Issue: 2 Volume: 39 Year: 2021 Month: 2 X-DOI: 10.1080/01446193.2020.1855666 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1855666 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:2:p:173-191 Template-Type: ReDIF-Article 1.0 Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Rita Peihua Zhang Author-X-Name-First: Rita Author-X-Name-Last: Peihua Zhang Author-Name: Christine Räisänen Author-X-Name-First: Christine Author-X-Name-Last: Räisänen Author-Name: Yang Miang Goh Author-X-Name-First: Yang Author-X-Name-Last: Miang Goh Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Author-Name: Siddharth Bhandari Author-X-Name-First: Siddharth Author-X-Name-Last: Bhandari Title: Special issue: what have we learnt from the COVID-19 global pandemic: improving the construction industry’s abilities to foresee, respond to and recover from future endemic catastrophes Journal: Construction Management and Economics Pages: 192-197 Issue: 2 Volume: 39 Year: 2021 Month: 2 X-DOI: 10.1080/01446193.2020.1869480 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1869480 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:2:p:192-197 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: List of Reviewers for Construction Management and Economics 2020 Journal: Construction Management and Economics Pages: i-iii Issue: 2 Volume: 39 Year: 2021 Month: 2 X-DOI: 10.1080/01446193.2021.1876423 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1876423 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:2:p:i-iii Template-Type: ReDIF-Article 1.0 Author-Name: Jeppe L. Møller Author-X-Name-First: Jeppe L. Author-X-Name-Last: Møller Author-Name: Pete Kines Author-X-Name-First: Pete Author-X-Name-Last: Kines Author-Name: Johnny Dyreborg Author-X-Name-First: Johnny Author-X-Name-Last: Dyreborg Author-Name: Lars L. Andersen Author-X-Name-First: Lars L. Author-X-Name-Last: Andersen Author-Name: Jeppe Z. N. Ajslev Author-X-Name-First: Jeppe Z. N. Author-X-Name-Last: Ajslev Title: The competences of successful safety and health coordinators in construction projects Abstract: The construction industry is among the most hazardous industries, with a fatality rate in Europe 3.4 times higher than average. While the occupational safety and health (OSH) coordinator has been a key actor in European efforts proposed to improve OSH in the industry since 1992, it is important to study the competences needed for the successful coordination of OSH in the construction industry. Existing literature on OSH coordinator competences are examined, and an expert survey is used to identify the competences characterising the most successful coordinators in Denmark. Finally, observational case studies of the perceived most successful coordinators in the Danish construction industry are used to exemplify the newly identified competences. The most frequently mentioned competences, not covered in previous research, are “innovativeness,” “having overview,” “persistency,” “thoroughness,” “sociability,” and “being systematic.” The results demonstrate the important “practice of knowing,” rather than possessing formal knowledge, education, and/or skills. The most important practice of knowing for the coordinators is likely that of the ability to transfer knowledge into practice. Future research, education and legal requirement in this field could benefit from a focus on what practices of knowledge actually work in real-life settings, rather than focussing on idealistic notions of these qualities. Journal: Construction Management and Economics Pages: 199-211 Issue: 3 Volume: 39 Year: 2021 Month: 3 X-DOI: 10.1080/01446193.2020.1818800 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1818800 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:3:p:199-211 Template-Type: ReDIF-Article 1.0 Author-Name: Rikard Sandberg Author-X-Name-First: Rikard Author-X-Name-Last: Sandberg Author-Name: Martin Löwstedt Author-X-Name-First: Martin Author-X-Name-Last: Löwstedt Author-Name: Christine Räisänen Author-X-Name-First: Christine Author-X-Name-Last: Räisänen Title: Working in a loosely coupled system: exploring practices and implications of coupling work on construction sites Abstract: The conceptualization of construction as a loosely coupled system has been widely used to explain behaviour within the industry. In this article, we revisit the concept by exploring what it means to work at the micro-level within this system. Adopting a practice lens, this study focuses on the daily work of site managers, a category of workers who often have been described to have a hub-like role in construction projects. The findings highlight how their work consists of activities that can be seen as mundane, yet simultaneously fill an important coupling function in the projects, which we conceptualize as coupling work. Coupling work denotes a managerial work practice through which site managers use slack from the parent organization to tighten site-activities. However, they do so in a particular way that tightens the projects closer to their own authority which, in turn, sustains organizational loose coupling. The study contributes to debates on change and development in construction by showing how coupling work is produced and reproduced to preserve the autonomy and control of site managers. Journal: Construction Management and Economics Pages: 212-226 Issue: 3 Volume: 39 Year: 2021 Month: 3 X-DOI: 10.1080/01446193.2020.1849751 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1849751 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:3:p:212-226 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Joanne Osborne Author-X-Name-First: Joanne Author-X-Name-Last: Osborne Author-Name: Dave Higgon Author-X-Name-First: Dave Author-X-Name-Last: Higgon Title: Affective, cognitive, behavioural and situational outcomes of social procurement: a case study of social value creation in a major facilities management firm Abstract: While there is an emerging body of research on social procurement in construction, there is little empirical research from a facilities management perspective. This is despite the enormous untapped potential of the facilities management sector to create social value in the communities in which they operate. To address this gap in research, this paper presents an in-depth case study of an innovative social procurement initiative developed by a major Australian facilities management organisation. Integrating research in the fields of employment studies, facilities management and social value, it provides new empirical evidence of the significant affective, cognitive, behavioural and situational social value outcomes which can be generated through facilities management. These are best achieved through new hybrid partnerships between business, government, not-for-profit, community and educational organisations which create shared value, underpinned by a common interest in maximising social value for the communities involved. More research is needed into the types of attributes, skills and resources that facilitate such outcomes, the attributes of organisations most likely to be able to collaborate and the types of cross-sector partnerships which work. Journal: Construction Management and Economics Pages: 227-244 Issue: 3 Volume: 39 Year: 2021 Month: 3 X-DOI: 10.1080/01446193.2020.1851035 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1851035 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:3:p:227-244 Template-Type: ReDIF-Article 1.0 Author-Name: Melissa Candel Author-X-Name-First: Melissa Author-X-Name-Last: Candel Author-Name: Tina Karrbom Gustavsson Author-X-Name-First: Tina Author-X-Name-Last: Karrbom Gustavsson Author-Name: Per-Erik Eriksson Author-X-Name-First: Per-Erik Author-X-Name-Last: Eriksson Title: Front-end value co-creation in housing development projects Abstract: As a result of local governance, municipalities and housing developers work together to define housing development projects and to co-create value propositions. The purpose of this study is to explore how value propositions are co-created during the front-end of housing development projects and how this affects housing developers’ ability to drive change and innovation. The value co-creation process is explored through interviews, documents and observations in a case study of an urban development programme in Sweden. The findings illustrate how emerging conflicts and the process of resolving them are central drivers for value co-creation between these actors. However, conflicts that are not managed and resolved constructively can lead to the co-destruction of value. In this study we illustrate how value co-creation processes that precede procurement limit the flexibility of housing developers and determine the scope for value that can be realised. Journal: Construction Management and Economics Pages: 245-260 Issue: 3 Volume: 39 Year: 2021 Month: 3 X-DOI: 10.1080/01446193.2020.1851037 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1851037 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:3:p:245-260 Template-Type: ReDIF-Article 1.0 Author-Name: Naielly Lopes Marques Author-X-Name-First: Naielly Lopes Author-X-Name-Last: Marques Author-Name: Carlos de Lamare Bastian-Pinto Author-X-Name-First: Carlos de Lamare Author-X-Name-Last: Bastian-Pinto Author-Name: Luiz Eduardo Teixeira Brandão Author-X-Name-First: Luiz Eduardo Teixeira Author-X-Name-Last: Brandão Title: Crossing the Brownian Bridge: valuing infrastructure capacity expansion policies as real options Abstract: In countries where transportation infrastructure is underdeveloped, newly built facilities tend to attract and increase demand. This can lead to situations where future traffic levels exceed the concession capacity limit, and additional investments in expansion is required. One common solution is to mandate this investment as a firm obligation in concession contracts, either after a set number of years or when demand reaches capacity. In this article, we show why these policies are suboptimal and propose a model that combines flexible capacity expansion decisions with conditional term extensions. We model this flexibility under the real options approach and the project value uncertainty during the life of the concession as a Brownian Bridge. As a novel contribution, we take into account the fact that concession revenues are bounded by the current traffic capacity of the road, which represents an upper absorbing barrier that has implications for the expansion decision. As a numerical application, this model is applied to a typical toll road project in Brazil. The results show that flexible expansion policies, coupled with conditional term extensions, have significant advantages. These findings can be of use to government officials involved in developing policies to attract private investment in public infrastructure projects. Journal: Construction Management and Economics Pages: 261-276 Issue: 3 Volume: 39 Year: 2021 Month: 3 X-DOI: 10.1080/01446193.2020.1863439 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1863439 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:3:p:261-276 Template-Type: ReDIF-Article 1.0 Author-Name: Petteri Uusitalo Author-X-Name-First: Petteri Author-X-Name-Last: Uusitalo Author-Name: Eelon Lappalainen Author-X-Name-First: Eelon Author-X-Name-Last: Lappalainen Author-Name: Olli Seppänen Author-X-Name-First: Olli Author-X-Name-Last: Seppänen Author-Name: Ergo Pikas Author-X-Name-First: Ergo Author-X-Name-Last: Pikas Author-Name: Antti Peltokorpi Author-X-Name-First: Antti Author-X-Name-Last: Peltokorpi Author-Name: Nikolai Menzhinskii Author-X-Name-First: Nikolai Author-X-Name-Last: Menzhinskii Author-Name: Mikko Piitulainen Author-X-Name-First: Mikko Author-X-Name-Last: Piitulainen Title: To trust or not to trust: is trust a prerequisite for solving design quality problems? Abstract: Low trust levels among project parties are generally believed to harm construction project performance, but the role of trust in the context of information flow and solving design quality problems (DQP) remains understudied. Whereas lean design management research highlights the importance of managing information flow, few studies have investigated the association between trust, information flow and DQP (or any combination thereof). This exploratory study investigates the association between trust and information flow in design projects and how these factors influence design quality. The paper presents a conceptual framework based on existing research on building design management and trust in a project context. The framework is elaborated on and validated using a single case study approach with multiple sites. The results indicate that even though the trust trend in the project is somewhat negatively connected to the overall amount of work and work in progress of DQP, increasing trust is not a prerequisite for solving DQP and that owners and contractors can have opposite opinions on the trust level. This study contributes to ongoing discussions about trust, information flow and design management and suggests that teams should focus on improving communication and collaboration to compensate for low trust levels. Journal: Construction Management and Economics Pages: 279-297 Issue: 4 Volume: 39 Year: 2021 Month: 4 X-DOI: 10.1080/01446193.2020.1865553 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1865553 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:4:p:279-297 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Author-Name: Rita Peihua Zhang Author-X-Name-First: Rita Author-X-Name-Last: Peihua Zhang Author-Name: Peter Edwards Author-X-Name-First: Peter Author-X-Name-Last: Edwards Title: An investigation of work-related strain effects and coping mechanisms among South African construction professionals Abstract: Construction is a demanding work environment. Many construction professionals experience workplace stress, leading to physiological, psychological and sociological strain effects. They adopt a variety of coping mechanisms to manage these effects. A purposive sample of 36 construction professionals (architects, project managers, construction managers, civil engineers and quantity surveyors) in Cape Town, South Africa, were surveyed regarding their perceptions of workplace strain effects and stress counter measures. The Mann–Whitney and Kruskal–Wallis non-parametric tests were used for data analysis. The findings show that the highest-ranked strain effects in terms of impact were (in descending order): “frustration”, “fatigue”, “strain on personal relationships”, “strain on professional relationships”, and “anger/irritability”. Male professionals identified greater fatigue and frustration effects than females; while females felt a greater lack of self-confidence. The highest-ranked coping mechanisms in terms of impact were “travel”, “non-competitive sporting activity”, “music”, “increased caffeine intake”, and “walking”. Males preferred more intensive physical activities than did females. Architects experienced anxiety more frequently than other professional groups. This study confirms important strain effects experienced by construction professionals and highlights the nature and effectiveness of counter measures. Limitations of the study include its exploratory nature and small sample size. Future research should establish the associations between strain effects and coping measures, in terms of how construction organizations can better support wellbeing among their professional employees. Journal: Construction Management and Economics Pages: 298-322 Issue: 4 Volume: 39 Year: 2021 Month: 4 X-DOI: 10.1080/01446193.2020.1870045 File-URL: http://hdl.handle.net/10.1080/01446193.2020.1870045 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:4:p:298-322 Template-Type: ReDIF-Article 1.0 Author-Name: Marc van den Berg Author-X-Name-First: Marc Author-X-Name-Last: van den Berg Author-Name: Hans Voordijk Author-X-Name-First: Hans Author-X-Name-Last: Voordijk Author-Name: Arjen Adriaanse Author-X-Name-First: Arjen Author-X-Name-Last: Adriaanse Title: BIM uses for deconstruction: an activity-theoretical perspective on reorganising end-of-life practices Abstract: Despite that Building Information Modelling (BIM) is often praised as a whole life-cycle methodology, possibilities for deconstruction are consistently overlooked. This study demonstrates what those possibilities may be. Previous studies showed that: deconstruction practices pose several site-based challenges; BIM implementations may help practitioners to address such challenges; and activity theory offers a framework to understand BIM implementations. We aimed to explore how deconstruction practices can be reorganised with BIM by applying an activity-theoretical perspective to a rather unique case-study. The selected case concerned the deconstruction of a nursing home so that many of its elements could be reused to construct a school. During this project, we implemented BIM in three essential activities: analysing existing conditions, labelling of reusable elements and planning deconstruction. The implementations resolved initial problems related with the use of traditional drawings, schedules and instructions. They nevertheless also triggered several additional problems that we attempted to address in successive steps. The organisation of the activities so evolved, which culminated in the formation of three new BIM uses for deconstruction: “3D existing conditions analysis,” “reusable elements labelling” and “4D deconstruction simulation”. These concepts complement existing BIM use taxonomies and can be appropriated in future deconstruction projects. Journal: Construction Management and Economics Pages: 323-339 Issue: 4 Volume: 39 Year: 2021 Month: 4 X-DOI: 10.1080/01446193.2021.1876894 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1876894 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:4:p:323-339 Template-Type: ReDIF-Article 1.0 Author-Name: Mahmoud Ershadi Author-X-Name-First: Mahmoud Author-X-Name-Last: Ershadi Author-Name: Peter Davis Author-X-Name-First: Peter Author-X-Name-Last: Davis Author-Name: Mohammad Tanvi Newaz Author-X-Name-First: Mohammad Tanvi Author-X-Name-Last: Newaz Title: Important academic interventions for promoting resilience: The perception of construction management undergraduates Abstract: Academic institutions play a prominent role in nurturing resilience skills in their graduates especially in fields, such as construction management (CM), which deal with a challenging work environment. Although resilience is a well-established topic in the literature, there is still a paucity of research that examines the importance of academic resilience interventions in the CM discipline. To address this research gap, this study aims to analyse the importance of academic resilience interventions (ARI) from the perception of CM students. First, the literature on ARIs in relevant contexts was reviewed followed by a quantitative survey to obtain the viewpoints of undergraduates undertaking CM programs in Australia. This paper is based on the survey data collected from 105 undergraduate students from five universities. Applying an exploratory factor analysis (EFA), three latent variables were found: (1) industry engagement; (2) raising awareness; and (3) readiness and empowerment to represent the identified ARIs. An importance analysis using the 2D quadrant method revealed that the ARI measures labelled “site visits,” “role model,” and “self-assessment” from the industry engagement aspect (factor1), “role-playing” from the raising awareness aspect (factor2), and “case study” from the readiness and empowerment aspect (factor3) are the most important ARIs from the perception of students. An independent-samples t-test revealed that there is no significant difference between the perception of male and female students on the importance of each ARI. The study provides an enhanced understanding of resilience interventions that can be leveraged for improving the CM curricula. Journal: Construction Management and Economics Pages: 340-355 Issue: 4 Volume: 39 Year: 2021 Month: 4 X-DOI: 10.1080/01446193.2021.1876896 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1876896 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:4:p:340-355 Template-Type: ReDIF-Article 1.0 Author-Name: Colin C. Williams Author-X-Name-First: Colin C. Author-X-Name-Last: Williams Author-Name: Aysegul Kayaoglu Author-X-Name-First: Aysegul Author-X-Name-Last: Kayaoglu Title: Explaining the supply of home repair and renovation services in the undeclared economy: lessons from Europe Abstract: Three competing theories have been used to explain participation in the undeclared economy. A structuralist perspective asserts that workers are pushed into undeclared work because of their “exclusion” from the declared economy. Two alternative theoretical perspectives assert that undeclared operators voluntarily “exit” the declared economy. Neo-liberals depict undeclared workers as rational economic actors and institutional theorists represent them more as social actors who disagree with the formal rules. To evaluate these competing theories in relation to the supply of undeclared home repair and renovation services, data are reported from a 2019 Eurobarometer survey involving 27,565 face-to-face interviews in 28 European countries. The finding is that 9.4% did so solely due to their exclusion from declared work. 19.8% participated purely for reasons associated with the rational economic actor perspective and 28.6% only for motives associated with the social actor perspective. 42.2% did so for a mixture of motives. Using probit regression analysis, the characteristics of those supplying undeclared home repair and renovation services and doing so for each rationale are revealed. The theoretical outcome is a call to view these perspectives not as competing but complementary. The policy outcome is to reveal the different policy initiatives required to tackle each of the rationales for supplying undeclared home repair and renovation services. Journal: Construction Management and Economics Pages: 356-368 Issue: 4 Volume: 39 Year: 2021 Month: 4 X-DOI: 10.1080/01446193.2021.1878545 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1878545 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:4:p:356-368 Template-Type: ReDIF-Article 1.0 Author-Name: Lars Peter Sønderbo Andersen Author-X-Name-First: Lars Peter Sønderbo Author-X-Name-Last: Andersen Author-Name: Regine Grytnes Author-X-Name-First: Regine Author-X-Name-Last: Grytnes Title: Different ways of perceiving risk and safety on construction sites and implications for safety cooperation Abstract: Construction is a dangerous industry when it comes to workplace injuries, and workers' unsafe behaviour accounts for 80–90% of the injuries. How risk is perceived by individuals and groups affects safety behaviour, and this study examined how different occupational groups on construction sites perceived safety and risk and how these perceptions influenced behaviours and practices related to safety cooperation. Over a period of 4 months, 36 semi-structured interviews and 36 days of observations were carried out with different occupational groups at two construction sites. The results showed that a rational way of perceiving safety and risks was most prominent among project managers, whereas an intuitive way of perceiving safety and risks was prominent among workers. Furthermore, foremen at the two sites voiced a perception of safety and risk that was ‘in between' these two approaches. The results also showed that the differences in perceptions of risk and safety had implications for safety cooperation at the sites which arguably lead to unsafe safety behaviour/practice. Acknowledging and integrating different perceptions of risk and safety could be a valuable starting point for construction safety management and could improve cooperation about safety. Journal: Construction Management and Economics Pages: 419-431 Issue: 5 Volume: 39 Year: 2021 Month: 5 X-DOI: 10.1080/01446193.2021.1904516 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1904516 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:5:p:419-431 Template-Type: ReDIF-Article 1.0 Author-Name: Una Obiose Kriston Nwajei Author-X-Name-First: Una Obiose Kriston Author-X-Name-Last: Nwajei Title: How relational contract theory influence management strategies and project outcomes: a systematic literature review Abstract: Despite growing interest in Relational Contracting (RC), few studies have comprehensively investigated the qualities required for a successful RC project. Macneil’s ten norms are principles of behaviour in contracts based on the application of relational contract theory and play an essential role in the formation and agreement of parties and their commitment to means and objectives. In contributing a missing dimension to the RC approach in construction, the purpose of this research is to conduct a systematic review of studies of relational contracting to answer the question: In what ways can the influence of RC theory be observed in the management strategies and outcomes of relational projects? Macneil's norms are used to provide a link between strategies and outcomes as a way of understanding RC and its influence on collaboration between the project actors in determining project outcomes. The results provide new insights with a view of consolidating extant literature and contributing through mapping practice back to theory. Findings show that the norms are evident in projects but with varied application and realisation in practice. This paper offers managerial implications and future research directions to investigate and capture the part played by the norms as mechanisms in construction projects. Journal: Construction Management and Economics Pages: 432-457 Issue: 5 Volume: 39 Year: 2021 Month: 5 X-DOI: 10.1080/01446193.2021.1913285 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1913285 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:5:p:432-457 Template-Type: ReDIF-Article 1.0 Author-Name: Anne Klitgaard Author-X-Name-First: Anne Author-X-Name-Last: Klitgaard Author-Name: Stefan Christoffer Gottlieb Author-X-Name-First: Stefan Christoffer Author-X-Name-Last: Gottlieb Author-Name: Kjeld Svidt Author-X-Name-First: Kjeld Author-X-Name-Last: Svidt Title: The researcher as audience and storyteller: challenges and opportunities of impression management in ethnographic studies Abstract: The use of ethnographic methods in construction management research is increasing as a means of revealing local and often unspoken ways of knowing and achieving new insights into the enduring challenges of the industry. Impression management activities, however, challenge the ethnographic researcher. Impression management happens when observees act in a different way than they would routinely, due to the presence of an audience. In the paper, we draw on data collected as a part of a wider ethnographic study to illustrate how the relationship between observer and observees can be understood through the lens of impression management. In particular, we show how the researcher assumes a dual role as both an audience and a storyteller in ethnographic studies. The researcher can thus be seen as an audience for the observees in their attempts to present themselves as agreeable and perform accordingly in front of the researcher as well as each other. This happens in part, as the observees attribute the researcher the role as storyteller, knowing that accounts of their practice and performance may be communicated to the research community and the industry in general. While impression management complicates the relationship between the observees and the observer, and can be seen as a potential source of bias, we also suggest that it presents an opportunity for increased empirical robustness of ethnographic findings if acknowledged. Journal: Construction Management and Economics Pages: 383-397 Issue: 5 Volume: 39 Year: 2021 Month: 5 X-DOI: 10.1080/01446193.2021.1913286 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1913286 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:5:p:383-397 Template-Type: ReDIF-Article 1.0 Author-Name: Linh N. K. Duong Author-X-Name-First: Linh N. K. Author-X-Name-Last: Duong Author-Name: Jason X. Wang Author-X-Name-First: Jason X. Author-X-Name-Last: Wang Author-Name: Lincoln C. Wood Author-X-Name-First: Lincoln C. Author-X-Name-Last: Wood Author-Name: Torsten Reiners Author-X-Name-First: Torsten Author-X-Name-Last: Reiners Author-Name: Mona Koushan Author-X-Name-First: Mona Author-X-Name-Last: Koushan Title: The value of incremental environmental sustainability innovation in the construction industry: an event study Abstract: Investment in the innovation of environmental sustainability in construction has been encouraged due to the industry's resource-intensity. However, it remains unclear how to convince shareholders and construction companies to invest in environmental innovations. This research used the event study method with a sample of 129 announcements in the construction industry from 2011 to 2017 to investigate the relationship between incremental environmental sustainability innovation and the stock market reactions of construction firms. The research finds evidence that the stock market reaction has a strong positive relationship with these announcements. There is also evidence for a relationship between strategic alliance, capital turnover, and the project start date with the stock market reaction. The results provide insight into the benefits of incremental innovations in the construction industry and extend the literature of environmental sustainability innovation by considering contributing factors that affect the relationship between environmental sustainability innovation and firm performance. They provide a useful reference for shareholders to integrate environmental sustainability innovation into their business strategies and allocate their resources more efficiently. Journal: Construction Management and Economics Pages: 398-418 Issue: 5 Volume: 39 Year: 2021 Month: 5 X-DOI: 10.1080/01446193.2021.1901950 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1901950 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:5:p:398-418 Template-Type: ReDIF-Article 1.0 Author-Name: Laura Rodríguez-Labajos Author-X-Name-First: Laura Author-X-Name-Last: Rodríguez-Labajos Author-Name: Craig S. Thomson Author-X-Name-First: Craig S. Author-X-Name-Last: Thomson Author-Name: Geraldine O’Brien Author-X-Name-First: Geraldine Author-X-Name-Last: O’Brien Title: Applying constructivist grounded theory in co-production research: a case study exploring its potential and lessons for construction management research Abstract: The last decade has seen a drive within construction management (CM) research for greater collaboration between academia and practice to improve the impact and relevance of research. Co-production, where academics and practitioners are engaged in framing the research problem, theory building, research design and problem solving, provides potential for engaged research which achieves mutual benefits in terms of theory and practice outcomes. To benefit from this trend, CM researchers require to revisit their established approaches. Under explored in CM research, this study identifies the potential of applying constructivist grounded theory (CGT) as an approach that enhance co-production research. The paper provides reflexive accounts of what makes CGT a suitable approach for co-production and presents a synthesis of its application in practice, reflecting on its strengths and weaknesses in the context of co-production. The applicability of the approach is illustrated through a case study on facilities performance measurement in the NHS. CGT contributed in the questioning of the scope and underlying assumptions leading to co-produced research which provided theoretical insight which underpinned guidance for future development by NHS Scotland. The findings indicate that CGT is a well-established, rigorous and reliable approach that is viable for conducting co-production research. Journal: Construction Management and Economics Pages: 369-382 Issue: 5 Volume: 39 Year: 2021 Month: 5 X-DOI: 10.1080/01446193.2021.1894654 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1894654 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:5:p:369-382 Template-Type: ReDIF-Article 1.0 Author-Name: Katharina N. Jeschke Author-X-Name-First: Katharina N. Author-X-Name-Last: Jeschke Author-Name: Susanne Boch Waldorff Author-X-Name-First: Susanne Boch Author-X-Name-Last: Waldorff Author-Name: Johnny Dyreborg Author-X-Name-First: Johnny Author-X-Name-Last: Dyreborg Author-Name: Pete Kines Author-X-Name-First: Pete Author-X-Name-Last: Kines Author-Name: Jeppe Z. N. Ajslev Author-X-Name-First: Jeppe Z. N. Author-X-Name-Last: Ajslev Title: Complaining about occupational safety and health: a barrier for collaboration between managers and workers on construction sites Abstract: Collaborative safety practices between construction site managers and workers are considered essential in occupational safety and health (OSH). However, establishing joint OSH engagement between managers and workers is still a challenge. Little is known about how managers and workers’ “complaining” about OSH affects collective OSH action and the quality of manager-worker relations. Drawing on an understanding of complaining as “boundary work”, this study empirically analyses how managers and workers’ verbalisations either downplay (collaboration) or build (demarcation) boundaries. Interviews and observations between managers and workers were carried out on a construction project in Denmark to identify why and how complaining is used. A typology consisting of four “complaining” mechanisms was developed, highlighting their associated relational dynamics: (1) Shifting responsibility for advancing OSH, (2) Defending oneself against strained working conditions, (3) Dealing strategically with criticism, and (4) Blaming other occupational groups. Complaining about OSH as boundary work – both collaboration and demarcation – between managers and workers furthers professional fragmentation and conflicts OSH collaboration, yet it occurs in a “safe space” for professional disagreement. We suggest that these communicational aspects and associated relational dynamics should be an area of increased focus in order to promote managers and workers’ OSH collaboration. Journal: Construction Management and Economics Pages: 459-474 Issue: 6 Volume: 39 Year: 2021 Month: 6 X-DOI: 10.1080/01446193.2021.1924388 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1924388 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:6:p:459-474 Template-Type: ReDIF-Article 1.0 Author-Name: Rita Peihua Zhang Author-X-Name-First: Rita Peihua Author-X-Name-Last: Zhang Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Title: Work-family role blurring and conflict among South African construction professionals Abstract: A research model was proposed investigating the relationships between work demand, role blurring, work-to-family conflict, and health and wellbeing consequences, and the model was tested on registered South African construction professionals. Structural equation modelling (SEM) was used to analyze the data collected from an online survey. The research results show that work pressure is a salient antecedent to all role blurring activities, i.e. after-hours work contact, pre-occupation with work, and multi-tasking between job tasks and family tasks whilst at home. Work hours directly predict work contact but indirectly affect pre-occupation and multi-tasking via the mediating role of work contact. All role blurring activities are positively associated with construction professionals’ experience of work-to-family conflict, which subsequently leads to depression and sleep problems. The results also show that depression affects the quality of sleep and construction professionals are likely to use alcohol consumption to cope with sleep problems. However, depression was found to be negatively associated with alcohol consumption, which calls for a more fine-grained analysis of the relationship. The study highlights the importance of appropriate work design with manageable workloads and reasonable work hours, and the promotion of boundary tactics for reducing work–family role blurring and conflict experienced by construction professionals. Journal: Construction Management and Economics Pages: 475-492 Issue: 6 Volume: 39 Year: 2021 Month: 6 X-DOI: 10.1080/01446193.2021.1916973 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1916973 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:6:p:475-492 Template-Type: ReDIF-Article 1.0 Author-Name: Nurul Elma Kordi Author-X-Name-First: Nurul Elma Author-X-Name-Last: Kordi Author-Name: Sheila Belayutham Author-X-Name-First: Sheila Author-X-Name-Last: Belayutham Author-Name: Che Khairil Izam Che Ibrahim Author-X-Name-First: Che Khairil Izam Author-X-Name-Last: Che Ibrahim Title: Mapping of social sustainability attributes to stakeholders’ involvement in construction project life cycle Abstract: In construction, greater emphasis is often placed on the economic and environmental aspects of sustainability, rather than social. Nonetheless, neglecting one of the sustainable pillars in construction, especially social sustainability, can lead to issues such as poor security and health. Previous studies on social sustainability in construction were mostly conducted in isolated contexts, where inadequate attention was placed on stakeholders’ responsibility throughout project life cycle. Therefore, this study aims to establish the social sustainability attributes in construction, subsequently relating this concept to two key aspects of construction: project life cycle and stakeholder involvement. This systematic literature review-based study has established nine main attributes with 20 sub-attributes, where Health and Safety was found to be the most dominant attribute, whilst Human Rights is the least acclaimed attribute for social sustainability. Further, the mapping of social attributes against the varying degrees of stakeholder involvement at different phases of project life cycle provides a definable understanding of social sustainability in construction, through the three elements of attributes, stakeholders, and project life cycle. The mapping would enable project clients to prioritise the selection of social sustainability attributes (what/how), relevant to their projects by engaging with relevant stakeholders (who) throughout construction project life cycle (when). Journal: Construction Management and Economics Pages: 513-532 Issue: 6 Volume: 39 Year: 2021 Month: 6 X-DOI: 10.1080/01446193.2021.1923767 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1923767 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:6:p:513-532 Template-Type: ReDIF-Article 1.0 Author-Name: Jakob Brinkø Berg Author-X-Name-First: Jakob Brinkø Author-X-Name-Last: Berg Author-Name: Christian Thuesen Author-X-Name-First: Christian Author-X-Name-Last: Thuesen Author-Name: Sidsel Katrine Ernstsen Author-X-Name-First: Sidsel Katrine Author-X-Name-Last: Ernstsen Author-Name: Per Anker Jensen Author-X-Name-First: Per Anker Author-X-Name-Last: Jensen Title: Reconfiguring the construction value chain: analysing key sources of friction in the business model archetypes of AEC companies in strategic partnerships Abstract: Lack of innovation and productivity in the construction industry compared to other industries is often explained by the institutionalised roles and fragmented nature of the construction value chain. Closer connections and collaboration (such as strategic partnerships) among architecture, engineering and construction (AEC) companies and across the values chain is often prescribed as a strategy to improve the performance of the construction industry. However, the institutional roles of AEC companies and their archetypical business models serve as important reference points for the sector. How these business models interact, and the friction created when they come in close contact is not well researched and understood. This paper identifies business models archetypes for architect, engineer, contractor and materials supplier based on workshops and interviews with practitioners. Friction is identified in and between the business models of AEC companies engaging in strategic partnerships. The analysis shows that architect archetypes face friction with regard to their profit formula and could benefit from profit sharing. The engineering archetypes face friction in their processes since they have to coordinate with specialists from other companies. Contractor and supplier archetypes face friction in their profit formula since the open books force them to alter business practices. Journal: Construction Management and Economics Pages: 533-548 Issue: 6 Volume: 39 Year: 2021 Month: 6 X-DOI: 10.1080/01446193.2021.1925134 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1925134 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:6:p:533-548 Template-Type: ReDIF-Article 1.0 Author-Name: Mahmoud Ershadi Author-X-Name-First: Mahmoud Author-X-Name-Last: Ershadi Author-Name: Marcus Jefferies Author-X-Name-First: Marcus Author-X-Name-Last: Jefferies Author-Name: Peter Davis Author-X-Name-First: Peter Author-X-Name-Last: Davis Author-Name: Mohammad Mojtahedi Author-X-Name-First: Mohammad Author-X-Name-Last: Mojtahedi Title: Project management offices in the construction industry: a literature review and qualitative synthesis of success variables Abstract: Today’s project management offices (PMOs) in the construction sector need to be equipped with breakthrough capabilities necessary for making a difference in multi-project management. Although there is an upward trend in academic research on PMOs, a comprehensive framework of potential success variables is still lacking in the literature. This research aims to assess the extant literature from the perspective of the construction sector to provide a single consolidated overview of potential PMO success variables. A systematic search process was adopted to retrieve publications and narrow them down to eligible studies followed by a qualitative synthesis. A set of 32 success variables was synthesized and inductively categorized under four emerging themes of (1) establishing PM infrastructure, (2) promoting PM practices, (3) PMO structuring, and (4) organizational support. This set of variables refers to three kinds of functional, structural, and contextual variables characterizing potential features of successful construction PMOs. These variables were compared between the construction industry and other industries to reflect contextual contrasts and similarities. A research agenda was proposed to encourage empirical studies on examining success variables. This study contributes to an improved understanding of PMO success variables in the construction industry and directs future research towards the most important topics. Journal: Construction Management and Economics Pages: 493-512 Issue: 6 Volume: 39 Year: 2021 Month: 6 X-DOI: 10.1080/01446193.2021.1916052 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1916052 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:6:p:493-512 Template-Type: ReDIF-Article 1.0 Author-Name: Xiuqin Wang Author-X-Name-First: Xiuqin Author-X-Name-Last: Wang Author-Name: Bing Wang Author-X-Name-First: Bing Author-X-Name-Last: Wang Author-Name: Yantao Xu Author-X-Name-First: Yantao Author-X-Name-Last: Xu Author-Name: Lanmin Shi Author-X-Name-First: Lanmin Author-X-Name-Last: Shi Title: A chance constrained programming method to determine optimal capital structure for privatized infrastructure Abstract: Capital structure optimization is an important aspect to ensure the success of public–private partnership (PPP) financing. Existing optimization methods fail to provide certain confidence level of the optimization result of PPP capital structure. The aim of this paper to optimize the capital structure of PPP projects by developing a chance-constrained programming (CCP) method with a certain confidence level under project risks. The results show that compared with existing methods, CCP method yields a greater optimal equity share, smaller NPV value, and higher confidence level depending on private sector’s risk preference. Besides, the optimal equity share is mainly determined by banks’ requirement and government regulation on commitment and it shrinks as banks’ risk preference grows. Theoretical calculation and simulation technique were adopted to make the result more convincing. The paper can help the private sector to more reasonably and reliably determine the optimal capital structure according to their risk preference. Journal: Construction Management and Economics Pages: 579-594 Issue: 7 Volume: 39 Year: 2021 Month: 7 X-DOI: 10.1080/01446193.2021.1930081 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1930081 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:7:p:579-594 Template-Type: ReDIF-Article 1.0 Author-Name: Ditte P. Gerding Author-X-Name-First: Ditte P. Author-X-Name-Last: Gerding Author-Name: Hans (J. W. F.) Wamelink Author-X-Name-First: Hans (J. W. F.) Author-X-Name-Last: Wamelink Author-Name: Els M. Leclercq Author-X-Name-First: Els M. Author-X-Name-Last: Leclercq Title: Implementing circularity in the construction process: a case study examining the reorganization of multi-actor environment and the decision-making process Abstract: Circularity aims to make waste obsolete by both closing and narrowing resource loops and by extending the lifespan of materials and products. This fundamentally different approach to construction practices necessitates a completely different method of organising the construction process. The rounds of decision-making undertaken by different actors at particular moments in the construction process have a significant role to play in this regard. Consequently, this research aims to analyse current circular practices for both the multi-actor environment and the decision-making process. An analytical framework is developed based on the theoretically-informed assumption that actors are responsible for decision-making and that circular strategies are an effective means through which to integrate circularity within the construction process. This analytical framework is applied to three circular building cases in the Netherlands, by drawing upon stakeholder interviews and documentation. It can be concluded that: some conventional actors have acquired knowledge on circularity; and that there is an emergent group of expert actors specialising in circularity. Both types of actors are a prerequisite for implementing circular strategies at both the beginning and end-of-life phase of a building; and should be involved early on to influence decision-making on circularity, especially concerning the long-lived layers of a building. Journal: Construction Management and Economics Pages: 617-635 Issue: 7 Volume: 39 Year: 2021 Month: 7 X-DOI: 10.1080/01446193.2021.1934885 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1934885 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:7:p:617-635 Template-Type: ReDIF-Article 1.0 Author-Name: John N. Connaughton Author-X-Name-First: John N. Author-X-Name-Last: Connaughton Author-Name: William H. Collinge Author-X-Name-First: William H. Author-X-Name-Last: Collinge Title: Trialling a new approach to interdisciplinary collaboration in UK construction: A projects-as-practice analysis Abstract: This paper investigates the emergence of collaboration on a UK construction project pioneering a novel form of project procurement (Integrated Project Insurance: IPI). Using a projects-as-practice lens and an action research approach, examination of linked episodes of project activity chart the unfolding of collaboration praxis in an IPI context through the frequent interplays of praxis (situated doings), practice (rules, values, policies) and practitioners working together. The analysis focuses on important requirements in IPI: that project practitioners, supported by a facilitator, collaborate to develop joint solutions to project requirements and share responsibility for them. Findings show how practitioners understood how to collaborate through the progressive enactment of working together rather than by developing a prior agreement about what collaboration would involve. Thus, the doing of collaboration mattered more than sayings about it in how practitioners created meaning in developing new collaboration praxis. Through this enactment the facilitator role is understood more as a practitioner in the development of collaboration praxis than solely as a convenor of collaboration. Findings also show how the micro-activities of practitioners may be illuminated using a projects-as-practice lens combined with a focus on interconnected episodes of project life to understand the emergence of praxis on construction projects. Journal: Construction Management and Economics Pages: 595-616 Issue: 7 Volume: 39 Year: 2021 Month: 7 X-DOI: 10.1080/01446193.2021.1933558 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1933558 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:7:p:595-616 Template-Type: ReDIF-Article 1.0 Author-Name: Sambo Lyson Zulu Author-X-Name-First: Sambo Lyson Author-X-Name-Last: Zulu Author-Name: Farzad Khosrowshahi Author-X-Name-First: Farzad Author-X-Name-Last: Khosrowshahi Title: A taxonomy of digital leadership in the construction industry Abstract: Businesses in the construction industry are experiencing pressure to modernize by embracing digital technologies. Like any other change initiative, digital transformation requires that leaders are at the forefront of their organizations’ pursuit for digital innovation. Therefore, the purpose of this study was to explore the different leadership approaches exhibited by construction industry leaders in influencing their organizations’ digital paths. Qualitative data collected from 41 construction industry professionals were analysed using an inductive thematic analysis approach. The main finding was a taxonomy of digital leadership types characterized under six themes: proactive and forward-thinking; supportive; uncoordinated; cautious; resistant and visionless and undriven leaders. These themes provide an insight into how leaders influence the digital transformation paths in organizations. As far as the authors are aware, this study is the first that developed a taxonomy of digital leadership approaches in the construction industry. This is a valuable step in understanding leaders’ influence in driving digital transformation in the construction industry. Thus, the taxonomy of digital leadership can be used to evaluate leadership styles and attitude towards digitalization. The findings are also a platform for further studies on digital leadership in construction. Journal: Construction Management and Economics Pages: 565-578 Issue: 7 Volume: 39 Year: 2021 Month: 7 X-DOI: 10.1080/01446193.2021.1930080 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1930080 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:7:p:565-578 Template-Type: ReDIF-Article 1.0 Author-Name: David Boyd Author-X-Name-First: David Author-X-Name-Last: Boyd Title: A critical inquiry into the hyperreality of digitalization in construction Abstract: The built environment is literally and metaphorically concrete but its creation from conception through design and construction involves many levels of abstraction. This spectrum of activities between concrete and abstract is complex and unexplored in construction but it will be shown that a deep understanding of this is required to make successful buildings in a modern age of digitalization. Abstraction is the simplification of an entity with a degree of generalization of purpose and causality but also used to promote the idealization of the entity. When abstractions are believed to be real then there are conditions of hyperreality. This article unpacks the nature of abstraction in the creation of the built environment through three vignettes of practice; considering: drawings, project planning and building modelling. Abstraction has been key to making buildings but is growing in significance because of building information modelling. The themes of loss of meaning, loss of control and loss of perspective are used to show that digitalization involves creating a dangerous illusion of the connection between data and reality thus creating a problematic hyperreality. This can be avoided by stronger thinking, more openness about abstractions and less exaggeration of their performance. Journal: Construction Management and Economics Pages: 549-564 Issue: 7 Volume: 39 Year: 2021 Month: 7 X-DOI: 10.1080/01446193.2021.1904515 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1904515 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:7:p:549-564 Template-Type: ReDIF-Article 1.0 Author-Name: Rita Peihua Zhang Author-X-Name-First: Rita Peihua Author-X-Name-Last: Zhang Author-Name: Sarah Holdsworth Author-X-Name-First: Sarah Author-X-Name-Last: Holdsworth Author-Name: Michelle Turner Author-X-Name-First: Michelle Author-X-Name-Last: Turner Author-Name: Mary Myla Andamon Author-X-Name-First: Mary Myla Author-X-Name-Last: Andamon Title: Does gender really matter? A closer look at early career women in construction Abstract: Despite the increasing number of women studying built environment degrees in higher education, the construction industry has not seen an increase in the percentage of female professionals. Women’s experiences in the early stages of their career have a critical influence on their future career intentions, including leaving the industry. This study was motivated to explore the transition experiences from university into work for early career female professionals working in the Australian construction industry. Nineteen interviews were conducted to collect qualitative data which was thematically analysed. Findings indicate that women are primarily driven by an intrinsic motivation to pursue construction careers. Women have both positive and negative experiences during their transition processes. The positive transition experiences are attributed to supportive and respectful relationships with colleagues and the availability of and access to structured graduate or cadetship training programs. Regarding negative experiences, findings suggest that apart from common challenges associated with transition for all entrants, women must contend with additional gender-based challenges. Many participants intend to stay in construction for the next five years but have concerns about the possibility of combining work and family when they decide to have children and how their careers might be affected. The research provides important practical implications for construction organizations in terms of improving women’s transition experience into the industry, maintaining their interest in construction careers and enhancing subsequent retention. Journal: Construction Management and Economics Pages: 669-686 Issue: 8 Volume: 39 Year: 2021 Month: 8 X-DOI: 10.1080/01446193.2021.1948087 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1948087 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:8:p:669-686 Template-Type: ReDIF-Article 1.0 Author-Name: Devindi Geekiyanage Author-X-Name-First: Devindi Author-X-Name-Last: Geekiyanage Author-Name: Thanuja Ramachandra Author-X-Name-First: Thanuja Author-X-Name-Last: Ramachandra Title: Running costs indices for commercial buildings using the hedonic price imputation approach: a case of Sri Lanka Abstract: Running expenses of a building consume a substantial share of its total life cycle cost and range between 70 and 80% in commercial buildings. Despite this, investment decisions are primarily based on construction costs due to the absence of a reliable estimate or forecast of costs in-use. In such a context, having running cost indices that incorporate building characteristics would enable investors to predict the running costs of a building at the early phase. This study is aimed at developing running cost indices for commercial buildings by taking Sri Lanka as a case. The running costs and building characteristics data were collected from a sample of 46 commercial buildings and analyzed using the hedonic price imputation approach, which enables the prediction of costs in absence of cost/quantity data. The hedonic indices developed in the study shows an increasing trend of running costs with varying degree of 0.37, 0.30, and 0.28% quarterly for offices, banks, and all commercial buildings, respectively. This prediction of trend would assist commercial developers to capture the movement of the running costs of commercial buildings and thereby optimize the running costs in the early design stage. This study further highlights the hedonic price imputation approach as a promising method for constructing index values where there is no adequate and reliable historical cost data. Journal: Construction Management and Economics Pages: 704-721 Issue: 8 Volume: 39 Year: 2021 Month: 8 X-DOI: 10.1080/01446193.2021.1950790 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1950790 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:8:p:704-721 Template-Type: ReDIF-Article 1.0 Author-Name: Mahavadi Dhanshyam Author-X-Name-First: Mahavadi Author-X-Name-Last: Dhanshyam Author-Name: Samir K. Srivastava Author-X-Name-First: Samir K. Author-X-Name-Last: Srivastava Title: Governance structures for public infrastructure projects: Public–private management regimes, contractual forms and innovation Abstract: The choice of appropriate governance structures for public infrastructure projects is a major challenge for governments. The extant literature provides ample theoretical support to analyse various public–private management regimes for public infrastructure service delivery, but there is little discussion on the innovation incentives of specific contractual forms and their welfare implications under different management regimes. Our research aims at providing answers to the following research questions: who should manage different tasks in public infrastructure delivery – public, private or public–private partnership (PPP)?; how should these tasks be managed to foster innovation and enhance welfare?. We explore these using a multi-period analytical model that analyses innovation incentives induced by six contractual forms under five management regimes. We derive conditions under which specific governance structures maximise welfare. Our analysis reveals that PPPs induce optimal innovation and maximise welfare if governed through revenue-sharing concessions for user-payment type services and fixed-price annuity type contracts for no-user-payment type services. The risk share of the private partner and the shadow cost of public funds strengthen the case for PPPs while transaction costs weaken it. These results generate novel insights for policymakers to design effective governance structures and set new research directions in public infrastructure governance. Journal: Construction Management and Economics Pages: 652-668 Issue: 8 Volume: 39 Year: 2021 Month: 8 X-DOI: 10.1080/01446193.2021.1938162 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1938162 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:8:p:652-668 Template-Type: ReDIF-Article 1.0 Author-Name: Yuting Chen Author-X-Name-First: Yuting Author-X-Name-Last: Chen Author-Name: Yongqiang Chen Author-X-Name-First: Yongqiang Author-X-Name-Last: Chen Author-Name: Hedley Smyth Author-X-Name-First: Hedley Author-X-Name-Last: Smyth Author-Name: Yongcheng Fu Author-X-Name-First: Yongcheng Author-X-Name-Last: Fu Title: Enforcement against contract violation in Chinese construction projects: impacts of trust and perceived intentionality Abstract: Violations happen frequently in construction projects due to opportunistic intentions and/or the lack of awareness of obligations and/or honest attempts to react to unforeseen circumstances. Dealing with contract violations plays an important role in managing projects. The aim of the research is to investigate the impact of trust, analyzed in terms of the goodwill-based and competence-based trust, on both contract and social enforcement after a contract violation. A questionnaire survey, partially based on semi-structured interviews, was used for data collection. All the data is from the Chinese construction industry since it provides a fertile context to explore the research questions. The results show that: 1) reputation is used as social enforcement in practice and the severity of it is reflected by the scope of the disclosure, 2) the two dimensions of trust have opposite influences on the severity of contract and social enforcement via different mediating effects of perceived intentionality. Specifically, goodwill-based trust reduces the severity of enforcement via decreasing perceived intentionality, while competence-based trust increases the severity of enforcement by increasing perceived intentionality. A comprehensive and nuanced understanding for managing contract violation is generated in this research, which will help project managers to manage the contract violation and the interfirm relationships more effectively. Journal: Construction Management and Economics Pages: 687-703 Issue: 8 Volume: 39 Year: 2021 Month: 8 X-DOI: 10.1080/01446193.2021.1950789 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1950789 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:8:p:687-703 Template-Type: ReDIF-Article 1.0 Author-Name: Daniel Sage Author-X-Name-First: Daniel Author-X-Name-Last: Sage Author-Name: Chloé Vitry Author-X-Name-First: Chloé Author-X-Name-Last: Vitry Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Author-Name: Sarah Barnard Author-X-Name-First: Sarah Author-X-Name-Last: Barnard Title: Towards a new theory of construction innovation: a socio-material analysis of classification work Abstract: There has been a longstanding concern among construction scholars and practitioners in classifying construction innovations, whether as “incremental” or “radical,” “technological” or “organizational,” “product” or “process”. In this paper we extend this interest in classification to examine what classification work accomplishes within construction innovation practices. Instead of addressing the validity of innovation categories as objective representations we explore how innovations are classified within everyday interactions that shape how they proliferate. Our approach is informed by socio-material theories of classification, communication and innovation, particularly those from Actor-Network Theory (ANT) and Ventriloquial Analysis (VA). Empirically, our approach is developed through an analysis of how a single innovation – a large format concrete block – was classified within a single warranty approval meeting as it entered the UK housing market. Our analysis explains how such classification work is dynamically constituted by formal and informal classificatory acts that involve displacements of human agency that shape how construction innovations proliferate. Classification work is thus shown to make a vital difference to how construction innovation is accomplished and can be understood. Journal: Construction Management and Economics Pages: 637-651 Issue: 8 Volume: 39 Year: 2021 Month: 8 X-DOI: 10.1080/01446193.2021.1938160 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1938160 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:8:p:637-651 Template-Type: ReDIF-Article 1.0 Author-Name: Anna af Hällström Author-X-Name-First: Anna Author-X-Name-Last: af Hällström Author-Name: Petra Bosch-Sijtsema Author-X-Name-First: Petra Author-X-Name-Last: Bosch-Sijtsema Author-Name: León Poblete Author-X-Name-First: León Author-X-Name-Last: Poblete Author-Name: Rasmus Rempling Author-X-Name-First: Rasmus Author-X-Name-Last: Rempling Author-Name: Mats Karlsson Author-X-Name-First: Mats Author-X-Name-Last: Karlsson Title: The role of social ties in collaborative project networks: A tale of two construction cases Abstract: Collaborative project delivery models (CPDMs) are increasing in popularity as infrastructure construction projects become more complex and grow in scale and scope. CPDMs build on high levels of trust, information exchange and formal contractual relations, creating complex relationships between actors in the project network. The literature emphasizes the procurement phase and contractual aspects of CPDMs; however, few studies explicitly focus on the role of social relationships in CPDM projects. Social network theory has recently been introduced in the architecture, engineering and construction industry industry to study relationships between network actors, but the role of social ties within CPDM project networks is still unclear. Through two qualitative case studies, we have analyzed the role of social ties in projects applying a CPDM contract. The empirical evidence of 41 semi-structured interviews and observations points to aspects that affect the development of social ties in CPDMs, such as initial project setup, project identification, perception of actors, resource sharing and shared space, as well as the importance of formal and informal ties for supporting collaborative project practices. The evidence shows how social ties develop into negative or positive bonds affecting the level of collaboration. This study contributes by emphasizing the interplay between project networks using CPDMs and social ties. Journal: Construction Management and Economics Pages: 723-738 Issue: 9 Volume: 39 Year: 2021 Month: 9 X-DOI: 10.1080/01446193.2021.1949740 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1949740 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:9:p:723-738 Template-Type: ReDIF-Article 1.0 Author-Name: Wang Pu Author-X-Name-First: Wang Author-X-Name-Last: Pu Author-Name: Fei Xu Author-X-Name-First: Fei Author-X-Name-Last: Xu Author-Name: Rui Cunha Marques Author-X-Name-First: Rui Cunha Author-X-Name-Last: Marques Title: A bibliometric and meta-analysis of studies on public–private partnership in China Abstract: China is one of the countries with the highest public-private partnership (PPP) experience. Although numerous studies on PPP in China have been published in different international journals in the past decades, few relevant reviews have been found. In this research, a bibliometric analysis of 139 peer-reviewed articles on PPP in China is performed to reveal the research evolution and trend. Besides, a meta-analysis of 111 empirical articles among the total 139 articles is conducted using multinomial logistic regression to examine how data characteristics and analytical features have been utilized in this area. The major findings suggest that, first, many studies are published in the subject areas of Business, Management and Accounting, and Engineering, and most topics are discussed from the micro-level perspective. Second, the issues in the procurement phase lack enough attention. Third, for studies with different research themes, how data characteristics and analytical features have been utilized significantly differ. In general, how PPP studies are approached in China contrasts with the global PPP research. Future research directions are proposed. The research contributes to the global PPP body of knowledge and methodology by providing the first quantitative review of studies on PPP in China and by combining the research methods. Journal: Construction Management and Economics Pages: 773-789 Issue: 9 Volume: 39 Year: 2021 Month: 9 X-DOI: 10.1080/01446193.2021.1958356 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1958356 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:9:p:773-789 Template-Type: ReDIF-Article 1.0 Author-Name: Róisín Murphy Author-X-Name-First: Róisín Author-X-Name-Last: Murphy Author-Name: Oluwasegun Seriki Author-X-Name-First: Oluwasegun Author-X-Name-Last: Seriki Title: The impact of environmental turbulence on the strategic decision-making process in Irish quantity surveying (QS) professional service firms (PSFs) Abstract: Construction firms operate within a business environment characterized by uncertainty and a lack of predictability, increasing the complexity of strategic decision-making. Construction contractor firms’ strategic response to environmental turbulence is appropriately documented but evidence regarding Construction Professional Service Firms (CPSF’S) remains scarce. CPSF’s are characteristically different from contractor organizations due to the intangibility of services and high knowledge intensity. The purpose of the study is to ascertain the impact of environmental turbulence on strategic decision-making process characteristics in CPSF’s, specifically Irish Quantity Surveying (QS) practices. Using a mixed-methods research strategy, data collected over two dissimilar stages on the economic cycle is presented. A comparative analysis over time exposes the varied impact of environmental turbulence on strategy process characteristics, however, a notable shift in the strategic choice is evident. An emergent approach to strategizing coupled with a move from written strategic plans is evident, while competitor analysis remains superficial. A taxonomy of the strategic decision-making process is derived from the empirical data which uniquely highlights the role of path dependence for CPSFs. The paper provides theoretical advancement in the discipline of CPSF strategy and also identifies a crucial component for consideration in driving transformational change required across the sector. Journal: Construction Management and Economics Pages: 739-758 Issue: 9 Volume: 39 Year: 2021 Month: 9 X-DOI: 10.1080/01446193.2021.1952632 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1952632 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:9:p:739-758 Template-Type: ReDIF-Article 1.0 Author-Name: Mattias Jacobsson Author-X-Name-First: Mattias Author-X-Name-Last: Jacobsson Author-Name: Henrik C. J. Linderoth Author-X-Name-First: Henrik C. J. Author-X-Name-Last: Linderoth Title: Newly graduated students’ role as ambassadors for digitalisation in construction firms Abstract: This study furthers the understanding of newly graduated students’ role in construction firms’ efforts to better use digital technologies. The aim is to increase the understanding of the role that newly graduated students play in digital transformation in construction firms. The study is based on 18 semi-structured interviews and three focus group interviews with new graduates and construction managers in Sweden’s three largest construction firms. The results show that despite having relevant skills, new graduates play a limited role when they are first recruited, as they struggle to close the “knowledge-experience gap”. Gradually, whilst familiarising themselves with how things are done, they act as ambassadors for digitalisation and contribute to the modification of senior colleagues’ beliefs about how technology could be used. However, this development is hampered by them getting caught-up in messy everyday activities, which forces them – like other staff – to prioritise urgent issues over important ones. An observed lack of established practices for how to make use of students’ skills hampers their involvement further. It has been suggested that urgency might not only be a problem, but a solution in that it is possible to increase the sense of urgency around new way of working with digital technologies. Journal: Construction Management and Economics Pages: 759-772 Issue: 9 Volume: 39 Year: 2021 Month: 9 X-DOI: 10.1080/01446193.2021.1955398 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1955398 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:9:p:759-772 Template-Type: ReDIF-Article 1.0 Author-Name: Yujia He Author-X-Name-First: Yujia Author-X-Name-Last: He Author-Name: Lei Shi Author-X-Name-First: Lei Author-X-Name-Last: Shi Author-Name: Zhongfu Li Author-X-Name-First: Zhongfu Author-X-Name-Last: Li Title: The combined effect of marginal social and private benefit on the socially optimal equity structure of PPP projects Abstract: Although bundling in public–private partnership (PPP) projects fosters cost savings in the provision of public services, such savings might come at the expense of social benefits due to the low quality of non-contractible services and the incompleteness of the contract. A game model is presented to analyse how the equity allocation between private partners—typically, building firms and operating firms—indirectly influences their incentives, in order to improve the quality of non-contractible services. The findings show that the equity structure can effectively compensate for the incompleteness of the contract. When the equity structure is privately negotiated by private partners whose only concern is private benefits, a loss of social benefits due to the low quality of non-contractible services occurs because the penalties are not enforceable. A socially optimal equity structure, which depends on the combined effects of marginal social and private benefits, plays a role in aligning these social and private benefits, thereby providing private partners with appropriate incentives to improve non-contractible services. These findings provide insights into the regulation of the equity structure for PPP projects providing services in diverse sectors. Journal: Construction Management and Economics Pages: 807-823 Issue: 10 Volume: 39 Year: 2021 Month: 10 X-DOI: 10.1080/01446193.2021.1974503 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1974503 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:10:p:807-823 Template-Type: ReDIF-Article 1.0 Author-Name: Michelle Turner Author-X-Name-First: Michelle Author-X-Name-Last: Turner Author-Name: Sarah Holdsworth Author-X-Name-First: Sarah Author-X-Name-Last: Holdsworth Author-Name: Christina M. Scott-Young Author-X-Name-First: Christina M. Author-X-Name-Last: Scott-Young Author-Name: Kara Sandri Author-X-Name-First: Kara Author-X-Name-Last: Sandri Title: Resilience in a hostile workplace: the experience of women onsite in construction Abstract: Women working onsite in construction contend with multiple work hazards arising from the masculine-based work culture. Resilience has been proposed as an important asset for trades and semi-skilled women to manage work hazards and retain work focus. An explanatory sequential research design incorporating survey and interview data was used to explore the resilience of women. One hundred and sixty-eight Australian trades and semi-skilled women completed the Employee Resilience Scale and forty-three of these participants were interviewed. Survey results indicate that participants had a high level of employee resilience, suggesting a strong ability to adapt and succeed in a challenging work environment. Thematic analysis of the interview data identified that resilience is considered as a mandatory capability by women working onsite to manage gendered workplace hazards and attain career success. The findings indicate that these women had high levels of resilience despite little to no support from their workplace. Given its importance, it is recommended that resilience development be included in apprenticeship programs to support retention and career success for tradeswomen. Developing the resilience of semi-skilled women requires more consideration from the industry given their precarious employment status and career pathway. More broadly, the results reiterate that more needs to be done to provide a safe working environment for women working onsite. Rather than relying on women to navigate hostile workplaces, construction employers must protect the safety and health of all workers irrespective of gender. Journal: Construction Management and Economics Pages: 839-852 Issue: 10 Volume: 39 Year: 2021 Month: 10 X-DOI: 10.1080/01446193.2021.1981958 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1981958 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:10:p:839-852 Template-Type: ReDIF-Article 1.0 Author-Name: Craig S. Thomson Author-X-Name-First: Craig S. Author-X-Name-Last: Thomson Author-Name: Tina Karrbom Gustavsson Author-X-Name-First: Tina Author-X-Name-Last: Karrbom Gustavsson Author-Name: Andrew Karvonen Author-X-Name-First: Andrew Author-X-Name-Last: Karvonen Title: Grand challenges facing our cities: where construction management research meets the urban field Journal: Construction Management and Economics Pages: 874-878 Issue: 10 Volume: 39 Year: 2021 Month: 10 X-DOI: 10.1080/01446193.2021.1972400 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1972400 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:10:p:874-878 Template-Type: ReDIF-Article 1.0 Author-Name: Victor Eriksson Author-X-Name-First: Victor Author-X-Name-Last: Eriksson Author-Name: Kajsa Hulthén Author-X-Name-First: Kajsa Author-X-Name-Last: Hulthén Author-Name: Viktoria Sundquist Author-X-Name-First: Viktoria Author-X-Name-Last: Sundquist Author-Name: Anna Fredriksson Author-X-Name-First: Anna Author-X-Name-Last: Fredriksson Author-Name: Mats Janné Author-X-Name-First: Mats Author-X-Name-Last: Janné Title: The role of public actors in construction logistics: effects on and of relational interfaces Abstract: Public actors are increasingly enforcing the use of specifically designed construction logistics setups (CLS) to cope with logistical challenges and minimising disturbances on third parties in large construction projects. The organising of these CLS is contingent on the interaction among several types of actors. The purpose of the paper is to advance the understanding of the design and use of CLS and the distribution of various outcomes of such arrangements on the actors involved. The paper analyses the role of public actors in the initiating of CLS and how this affects the relational interfaces in the CLS triad of developers, contractors and logistics service providers, and the outcomes of their interactions. First, the main reason for a public actor to initiate a CLS is not cost, productivity or innovativity gains, but to decrease disturbances on third parties. Second, developers and contractors are forced to use the CLS initiated by the public actor. This makes them take on a forced customer role, explaining why these actors are often resistant to adopt to a certain CLS. Third, ripple effects, such as unintended costs and productivity impacts, occur in the construction supply chain because of the use of CLS. Journal: Construction Management and Economics Pages: 791-806 Issue: 10 Volume: 39 Year: 2021 Month: 10 X-DOI: 10.1080/01446193.2021.1970785 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1970785 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:10:p:791-806 Template-Type: ReDIF-Article 1.0 Author-Name: Yanqing Fang Author-X-Name-First: Yanqing Author-X-Name-Last: Fang Author-Name: Emmanuel Itodo Daniel Author-X-Name-First: Emmanuel Itodo Author-X-Name-Last: Daniel Author-Name: Shuquan Li Author-X-Name-First: Shuquan Author-X-Name-Last: Li Title: Conceptual framework for lean construction ambidexterity in project-based organizations Abstract: Lean construction (LC) is widely used to eliminate waste in the construction industry. However, few studies have focussed on LC capabilities. In the absence of a theoretical foundation, the equal treatment of inherent rigidity and flexibility has received little attention. This critical literature review answered the following research questions: What is the current understanding of the two characteristics of LC? Is there a theoretical explanation for their relationship? How can LC capabilities be realized in a project-based organization? The results revealed the lack of a clear definition of LC capabilities. The study posits that LC capabilities involve ambidexterity. Ambidexterity embodies the LC philosophy, principles, and methods, with a focus on resolving the paradoxical tensions in LC projects. Ambidexterity was found to be a two-dimensional paradox comprising exploitative and exploratory capabilities. It emphasizes the achievement of a balance between the two capabilities. The proposed model indicates that LC project-based organizations provide the ideal context for the development of ambidexterity. This study uses a paradoxical lens to introduce the notion of LC capabilities as ambidexterity. This research contributes to the current knowledge and future applications of organizational ambidexterity theory to LC capability development. In addition, it will enable practitioners to understand and manage the paradoxical tensions in LC projects. The proposed framework can guide the creation of an ideal LC project-organization environment. Journal: Construction Management and Economics Pages: 824-838 Issue: 10 Volume: 39 Year: 2021 Month: 10 X-DOI: 10.1080/01446193.2021.1978516 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1978516 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:10:p:824-838 Template-Type: ReDIF-Article 1.0 Author-Name: Konrad Graser Author-X-Name-First: Konrad Author-X-Name-Last: Graser Author-Name: Aniko Kahlert Author-X-Name-First: Aniko Author-X-Name-Last: Kahlert Author-Name: Daniel M. Hall Author-X-Name-First: Daniel M. Author-X-Name-Last: Hall Title: DFAB HOUSE: implications of a building-scale demonstrator for adoption of digital fabrication in AEC Abstract: The Architecture, Engineering and Construction (AEC) industry finds itself in an accelerating shift towards the use of more digital fabrication (DFAB) technologies. DFAB promises great advantages in AEC, but its adoption is so far lagging and there are few examples of building projects employing DFAB at scale. To facilitate DFAB adoption, we need to identify its challenges and opportunities of in the project context and understand its implications beyond project boundaries. To do this, this paper conducts a single case study on DFAB HOUSE, the first project to introduce several fundamentally new DFAB technologies to construct a fully functional building. Using Qualitative Content Analysis, we provide an overview of the challenges to consider and the strategies available to successfully adopt DFAB technologies in construction projects, establishing a socio-technical framework for DFAB adoption in AEC projects. We find that full-scale projects are an effective exploration method of DFAB in AEC, implementation at scale increases acceptance of DFAB in AEC, and projects are instrumental in establishing an emergent praxis of DFAB. Journal: Construction Management and Economics Pages: 853-873 Issue: 10 Volume: 39 Year: 2021 Month: 10 X-DOI: 10.1080/01446193.2021.1988667 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1988667 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:10:p:853-873 Template-Type: ReDIF-Article 1.0 Author-Name: Phuong H. D. Nguyen Author-X-Name-First: Phuong H. D. Author-X-Name-Last: Nguyen Author-Name: Dai Q. Tran Author-X-Name-First: Dai Q. Author-X-Name-Last: Tran Author-Name: Sai P. K. Bypaneni Author-X-Name-First: Sai P. K. Author-X-Name-Last: Bypaneni Title: Exploring the impact of project size on design-bid-build and design-build project delivery performance in highways Abstract: The highway construction industry has been increasingly using design-build (D-B) project delivery because of its documented benefits. Only limited studies, if any, have compared D-B and traditional design-bid-build (D-B-B) project performance based on the size of projects. The existing gap was addressed by investigating the cost growth, schedule growth, and construction intensity of highway projects delivered under D-B-B and D-B with the project sizes ranging from $2 million to greater than $100 million. These projects were collected from six state departments of transportations in the U.S. with mature D-B programs. Several statistics tests including t-test, Welch’s test, and Mann–Whitney U-test were used to analyze 3888 completed highway construction projects. The results show that D-B produced a lower cost growth than D-B-B in the project size of over $10 million while D-B-B projects had lower cost growth than D-B projects in the project size from $2 million to $10 million. D-B projects also produced less schedule growth than D-B-B projects across all groups of project size. D-B-B projects had a faster work pace than D-B projects in the project size from $2 million to $10 million. The findings contribute to the project delivery body of knowledge by reporting statistically empirical comparisons between D-B-B and D-B project performance controlled by the project size. The findings may help highway agencies better understand how D-B performs under the different sizes of projects in terms of cost growth, schedule growth, and construction intensity. Journal: Construction Management and Economics Pages: 879-893 Issue: 11 Volume: 39 Year: 2021 Month: 11 X-DOI: 10.1080/01446193.2021.1993289 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1993289 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:11:p:879-893 Template-Type: ReDIF-Article 1.0 Author-Name: Raghu Dharmapuri Tirumala Author-X-Name-First: Raghu Author-X-Name-Last: Dharmapuri Tirumala Author-Name: Neeraj Dangol Author-X-Name-First: Neeraj Author-X-Name-Last: Dangol Author-Name: Piyush Tiwari Author-X-Name-First: Piyush Author-X-Name-Last: Tiwari Author-Name: Paulo Vaz-Serra Author-X-Name-First: Paulo Author-X-Name-Last: Vaz-Serra Title: Comparative analysis of outcomes under PPP and traditional modes of delivery: a study of schools in Melbourne Abstract: Public Private Partnership (PPP) arrangements are perceived as compelling alternatives to traditional infrastructure development to raise finances and improve efficiency. However, with the substantial improvement in the provision of services through traditionally developed infrastructure, the benefits of PPP implementation need to be continually evaluated. This research investigates three categories of outcomes (educational, stakeholder satisfaction, and general outcomes) for schools in Melbourne implemented under PPP arrangement to those implemented under a traditional procurement method. Data Envelopment Analysis is used to assess the efficiency of these outcomes, based on the consumption of teaching, financial and physical resources. The results indicate that there is no substantial difference between the performance of both arrangements. While the schools implemented under the PPP arrangement have provided better education outcomes, the traditional schools perform better in stakeholder satisfaction and general outcomes. The results indicate that the policymakers need to evaluate infrastructure based PPP arrangements more closely and align with the desired outcomes. Journal: Construction Management and Economics Pages: 894-911 Issue: 11 Volume: 39 Year: 2021 Month: 11 X-DOI: 10.1080/01446193.2021.1994147 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1994147 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:11:p:894-911 Template-Type: ReDIF-Article 1.0 Author-Name: Hasan Murat Ertuğrul Author-X-Name-First: Hasan Murat Author-X-Name-Last: Ertuğrul Author-Name: Burak Pirgaip Author-X-Name-First: Burak Author-X-Name-Last: Pirgaip Title: The nexus between construction investment and economic development: evidence from MENA countries Abstract: Although the literature is replete with studies that signify the role of the construction industry in economic development, the complexity of the relationship still deserves attention and calls for a regional perspective as well as more robust empirical evidence. To fill this gap, we scrutinise the nexus between construction investment and economic development for the Middle East and North Africa (MENA) region by employing second generation panel data modelling tools. We do so with a focus on top ten developing economies in the region, namely, Saudi Arabia, Turkey, Iran, United Arab Emirates, Egypt, Iraq, Qatar, Algeria, Kuwait, and Morocco, between 1970 and 2019. We find that there is an inverted U-shaped pattern, in line with Bon’s proposition, implying that the share of construction investments started to decline at some point in time as the economic growth reached a certain threshold. We argue that MENA countries should reconsider their construction-induced growth policies and incorporate alternative options supported by innovative and environmental-friendly technologies to attach much more importance to the role of construction in future economic development plans. Journal: Construction Management and Economics Pages: 932-947 Issue: 11 Volume: 39 Year: 2021 Month: 11 X-DOI: 10.1080/01446193.2021.1998919 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1998919 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:11:p:932-947 Template-Type: ReDIF-Article 1.0 Author-Name: Wenqian Guo Author-X-Name-First: Wenqian Author-X-Name-Last: Guo Author-Name: Wenxue Lu Author-X-Name-First: Wenxue Author-X-Name-Last: Lu Author-Name: Xinran Gao Author-X-Name-First: Xinran Author-X-Name-Last: Gao Author-Name: Feifei Cai Author-X-Name-First: Feifei Author-X-Name-Last: Cai Title: How interpersonal ties affect interorganizational trust in construction projects: role differences and cross-level effects Abstract: Interorganizational trust significantly impacts performance, while distrust leads to high costs. How to effectively build interorganizational trust is critical, whereas few studies point out how boundary spanners, as representatives of the interaction between two organisations, affect interorganizational trust. The authors put forward a trust-building mechanism to verify whether interpersonal ties (obligatory ties, instrumental ties, and affective ties) promote interorganizational trust through the establishment of interpersonal trust and compare the differences in trust-building mechanisms between different boundary spanners (project leaders and team members). By adopting structural equation modelling and regression analysis, the data of 271 questionnaires from the construction industry in China reveal that as for team members, cognitive and affective trust significantly mediate the relationship between interpersonal ties and interorganizational trust. But as for project leaders, only cognitive trust has a significant mediating effect. This cross-level mechanism to answer how interpersonal ties affect interorganizational trust further enriches social embeddedness theory. Meanwhile, by distinguishing the differences of trust-building mechanisms between different boundary spanners, the research on stakeholders’ trust-building mechanisms can also be expanded. Journal: Construction Management and Economics Pages: 912-931 Issue: 11 Volume: 39 Year: 2021 Month: 11 X-DOI: 10.1080/01446193.2021.1994148 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1994148 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:11:p:912-931 Template-Type: ReDIF-Article 1.0 Author-Name: Ramin Asadi Author-X-Name-First: Ramin Author-X-Name-Last: Asadi Author-Name: Suzanne Wilkinson Author-X-Name-First: Suzanne Author-X-Name-Last: Wilkinson Author-Name: James Olabode Bamidele Rotimi Author-X-Name-First: James Olabode Bamidele Author-X-Name-Last: Rotimi Title: Towards contracting strategy usage for rework in construction projects: a comprehensive review Abstract: Rework has been the core of attention for several years in the industry and academia as it affects the performance of projects. However, the trend of rework academic papers indicates an increasing rate in recent years; the overall research lacks a comprehensive review of the implemented theories and proposed models to explore further directions for rework management. Thus, to achieve a better understanding of rework it is necessary to perform an extensive review. This research aims to explore various insights from rework-related articles, discuss major research areas, and identify gaps for future studies looking closely at construction contracts. The selected articles are from three databases: “Scopus, Web of Science, Google Scholar”. The findings are categorized into six study areas: sources of rework, models and solutions, management and strategies, theories and techniques, rework impacts, and factors affecting rework. The analysis of the employed techniques across these topics showed that System Dynamic Modelling, Action Research, Analytic Hierarchy Process, and Regression have been used more frequently than other methods. The comprehensive review also shed light on the new ways of thinking, analyzing, and controlling the impacts of the rework. This paper proposes the assessment of rework causes in the conditions of contract which provides opportunities for improvement of the construction contracts. Journal: Construction Management and Economics Pages: 953-971 Issue: 12 Volume: 39 Year: 2021 Month: 12 X-DOI: 10.1080/01446193.2021.2004609 File-URL: http://hdl.handle.net/10.1080/01446193.2021.2004609 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:12:p:953-971 Template-Type: ReDIF-Article 1.0 Author-Name: David Oswald Author-X-Name-First: David Author-X-Name-Last: Oswald Author-Name: Léon olde Scholtenhuis Author-X-Name-First: Léon olde Author-X-Name-Last: Scholtenhuis Author-Name: Trivess Moore Author-X-Name-First: Trivess Author-X-Name-Last: Moore Author-Name: Simon Smith Author-X-Name-First: Simon Author-X-Name-Last: Smith Title: Construction defects, danger, disruption and disputes: a systemic view of the construction industry post-Grenfell Journal: Construction Management and Economics Pages: 949-952 Issue: 12 Volume: 39 Year: 2021 Month: 12 X-DOI: 10.1080/01446193.2021.2015973 File-URL: http://hdl.handle.net/10.1080/01446193.2021.2015973 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:12:p:949-952 Template-Type: ReDIF-Article 1.0 Author-Name: Mustafa Selçuk Çıdık Author-X-Name-First: Mustafa Selçuk Author-X-Name-Last: Çıdık Author-Name: Stephen Phillips Author-X-Name-First: Stephen Author-X-Name-Last: Phillips Title: Buildings as complex systems: the impact of organisational culture on building safety Abstract: High-risk buildings can be considered as complex systems involving various social actors and technology, which draws attention to the organisational and social underpinnings of their safety. This research draws on complex systems theory and high reliability organisations (HRO) literature to develop insights into the cultural aspects of safety management and regulation of high-risk buildings. Ten semi-structured interviews were undertaken to explore the opinions and experiences of built environment professionals in England about the ongoing regulatory changes regarding high-risk buildings following the tragic fire at Grenfell Tower. The findings expose some aspects of the organisational culture that underpin the safety-related behaviour in high-risk building life cycle in England, which are incompatible with those that underpin HRO. The findings also show how the studied regulatory changes are subsumed by this organisational culture and fail to deliver their intention. Hence, the paper establishes organisational culture of the building life cycle as a key consideration for safety management and regulation of high-risk buildings. The conclusion calls for future regulatory, practical and research efforts to develop a better appreciation of the organisational culture, and to aim for measures to cultivate a culture that enables collective mindfulness. Journal: Construction Management and Economics Pages: 972-987 Issue: 12 Volume: 39 Year: 2021 Month: 12 X-DOI: 10.1080/01446193.2021.1966816 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1966816 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:12:p:972-987 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: List of Reviewers for Construction Management and Economics 2021 Journal: Construction Management and Economics Pages: i-iv Issue: 12 Volume: 39 Year: 2021 Month: 12 X-DOI: 10.1080/01446193.2021.2020536 File-URL: http://hdl.handle.net/10.1080/01446193.2021.2020536 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:12:p:i-iv Template-Type: ReDIF-Article 1.0 Author-Name: Tara Brooks Author-X-Name-First: Tara Author-X-Name-Last: Brooks Author-Name: Joseph G. Gunning Author-X-Name-First: Joseph G. Author-X-Name-Last: Gunning Author-Name: John P. Spillane Author-X-Name-First: John P. Author-X-Name-Last: Spillane Author-Name: John Cole Author-X-Name-First: John Author-X-Name-Last: Cole Title: Regulatory decoupling and the effectiveness of the ISO 9001 quality management system in the construction sector in the UK – a case study analysis Abstract: Construction quality defects are a widespread and recurrent industry problem; the ISO 9001 Quality Management System (QMS) has been proposed as a tool to improve construction quality. It is one of the most widely adopted management systems worldwide and is a prerequisite for many construction tenders. Institutional theory uses the concept of regulatory decoupling to probe “performative” implementation of a standard or regulation; this theory has not to date been applied to ISO 9001 QMS implementation in the construction industry. In this context, the aim of this research is to investigate the extent of regulatory decoupling and its impact on the effectiveness of implementation of the ISO 9001 QMS in 3 case study construction organizations. 34 interviews are undertaken across three case study organizations and analyzed using an abductive grounded theory approach. In all three case study organizations, regulatory decoupling between the operation of the companies and their ISO 9001 system is taking place. Disconnection of the QMS to quality “on the ground” is evident. A model showing factors that foster regulatory decoupling is produced. The picture of compliance is complex and continually evolving. The study concludes with recommendations for industry to reconnect QMS systems to site operation and management. Journal: Construction Management and Economics Pages: 988-1005 Issue: 12 Volume: 39 Year: 2021 Month: 12 X-DOI: 10.1080/01446193.2021.1983186 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1983186 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:39:y:2021:i:12:p:988-1005 Template-Type: ReDIF-Article 1.0 Author-Name: Anna-Therése Järvenpää Author-X-Name-First: Anna-Therése Author-X-Name-Last: Järvenpää Author-Name: Per Erik Eriksson Author-X-Name-First: Per Erik Author-X-Name-Last: Eriksson Author-Name: Johan Larsson Author-X-Name-First: Johan Author-X-Name-Last: Larsson Title: Exploring a public client’s control systems in infrastructure projects from a relationship history perspective Abstract: Using a proper control system is vital to ensure that project delivery is satisfactory for the client. Prior research has identified relationship history as a potentially vital contingency factor in organizational control, but there is a lack of research on how relationship history affects how different control systems function in project-based contexts. In the Swedish infrastructure market, increased demand has resulted in a need for increased supply capacity. This has spurred new entrants that have no relationship history with the major client, the Swedish Transport Administration. The purpose is therefore to compare how the client’s control systems function in construction projects with familiar (known to the client) and unfamiliar (new to the client) contractors. The case study involves 32 interviews conducted in six infrastructure projects, three with unfamiliar contractors. Findings show that relationship history heavily influences how the control systems function, especially bureaucratic and clan control. The new contractors are unaccustomed with the client’s extensive use of bureaucratic control and perceive it as less suitable in design-build contracts. Furthermore, the lack of relationship history reduces the opportunity to use clan control from the beginning of a project, due to unfamiliarity with both the client and the control system. Journal: Construction Management and Economics Pages: 56-71 Issue: 1 Volume: 40 Year: 2022 Month: 1 X-DOI: 10.1080/01446193.2021.2014064 File-URL: http://hdl.handle.net/10.1080/01446193.2021.2014064 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:1:p:56-71 Template-Type: ReDIF-Article 1.0 Author-Name: Andreas Ekeskär Author-X-Name-First: Andreas Author-X-Name-Last: Ekeskär Author-Name:  Malena I. Havenvid Author-X-Name-First:  Malena I. Author-X-Name-Last: Havenvid Author-Name: Tina Karrbom Gustavsson Author-X-Name-First: Tina Author-X-Name-Last: Karrbom Gustavsson Author-Name: Per Erik Eriksson Author-X-Name-First: Per Erik Author-X-Name-Last: Eriksson Title: Construction logistics in a multi-project context: coopetition among main contractors and the role of third-party logistics providers Abstract: As a part of supply chain management (SCM) initiatives to improve performance and productivity in construction projects, the use of construction logistics setups (CLSs) operated by third-party logistics (TPL) providers have increased. CLSs are often used in complex multi-project contexts, such as urban development districts, where extensive coordination of actors, resources, and activities is needed. The purpose of this paper is twofold: to investigate how main contractors engage in horizontal relationships with each other when coordinating activities and resources within and across projects in a multi-project context, and to investigate what role a TPL provider assumes when engaging in relationships with main contractors in a multi-project context. The findings are based on a case study of an urban development district with a mandatory TPL-operated CLS, and we apply the industrial network approach. In this multi-project context, the main contractors engage in coopetitive relationships, coordinating activities and resources within and across projects. The TPL provider coordinates actors, resources, and activities, facilitating smoother production by managing logistics and mediating coopetitive relationships. This can be understood as a multi-project coordination role and extends the role SCM can play in construction. In that role, a TPL provider can minimise tensions between coopetitive actors across a multitude of horizontal relationships and projects. Journal: Construction Management and Economics Pages: 25-40 Issue: 1 Volume: 40 Year: 2022 Month: 1 X-DOI: 10.1080/01446193.2021.2012815 File-URL: http://hdl.handle.net/10.1080/01446193.2021.2012815 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:1:p:25-40 Template-Type: ReDIF-Article 1.0 Author-Name: Richmond Juvenile Ehwi Author-X-Name-First: Richmond Juvenile Author-X-Name-Last: Ehwi Author-Name: Kwadwo Oti-Sarpong Author-X-Name-First: Kwadwo Author-X-Name-Last: Oti-Sarpong Author-Name: Reyhaneh Shojaei Author-X-Name-First: Reyhaneh Author-X-Name-Last: Shojaei Author-Name: Gemma Burgess Author-X-Name-First: Gemma Author-X-Name-Last: Burgess Title: Offsite Manufacturing Research: A Systematic Review of Methodologies Used Abstract: Debates regarding research methodologies in construction, engineering and management (CEM) literature are long-standing. However, in the growing literature on offsite manufacturing (OSM), such debates are lacking and some studies conflate different components of research methodologies such as research design, methods, data sources, data types, and analytical techniques. This study examines the components of research methodologies reported in the OSM literature and how they compare with the established relationships between the key components of research methodologies. We analyse 74 articles on OSM sampled from 26 journals and find that quantitative methods, case studies, primary data, bibliometric database and modelling are the most preferred methodological approaches. The methodological components reported also cohere with established relationships between components of research methodology, other than the relationship between research methods and data sources. The findings reveal a growing hybridisation of research designs, data sources and analytical techniques, which suggests that methodological plurality is emerging in the OSM literature. This re-echoes concerns regarding the dominance of quantitative methods and the limited use of theory in CEM research, and consequently highlights the need for diversity in methodologies to expand knowledge boundaries. Journal: Construction Management and Economics Pages: 1-24 Issue: 1 Volume: 40 Year: 2022 Month: 1 X-DOI: 10.1080/01446193.2021.2007537 File-URL: http://hdl.handle.net/10.1080/01446193.2021.2007537 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:1:p:1-24 Template-Type: ReDIF-Article 1.0 Author-Name: Ingrid Svensson Author-X-Name-First: Ingrid Author-X-Name-Last: Svensson Author-Name: Pernilla Gluch Author-X-Name-First: Pernilla Author-X-Name-Last: Gluch Title: Materiality in action: the role of objects in institutional work Abstract: Public property owners currently face a great backlog of renovation work at the same time as there is a need to build new, increase cost-efficiency, and comply with new environmental regulations on energy efficiency. To manage these challenges many public property owners have initiated change processes to develop new strategic ways of working with their properties, often aligned with a project portfolio approach. This involves a quite radical shift of practices in these organizations, which requires individuals to engage in institutional work. Recent studies have highlighted how institutional work is shared between humans and objects. To increase understanding of objects’ role in institutional work through which public property owners develop new practices that support a holistic, long-term, and sustainable property management, we analyzed observational data of strategy project meetings in three Swedish public property owner organizations. Findings show how objects have an active role in institutional work through acts of attacking, justifying, and/or safeguarding to maintain, create and/or disrupt institutions. Objects take on multiple roles and both unite and divide human actors as well as evoke emotions that guide actions. Three types of agency are highlighted: relational, discursive, and emotional. Increased knowledge on the role of objects in institutional work and how objects (can) influence human agency assists actors in making better-informed decisions in strategic change processes. Journal: Construction Management and Economics Pages: 41-55 Issue: 1 Volume: 40 Year: 2022 Month: 1 X-DOI: 10.1080/01446193.2021.2014063 File-URL: http://hdl.handle.net/10.1080/01446193.2021.2014063 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:1:p:41-55 Template-Type: ReDIF-Article 1.0 Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Author-Name: Sara Brorström Author-X-Name-First: Sara Author-X-Name-Last: Brorström Author-Name: Pernilla Gluch Author-X-Name-First: Pernilla Author-X-Name-Last: Gluch Title: The valuation of housing in low-amenity and low purchasing power city districts: social and economic value entangled by default Abstract: Urban development projects are based on both calculative practices, in order to render investments in new housing profitable, and on a broader assessment of the value of amenities, qualities associated with housing units such as access to parks and shopping facilities, while not directly being included in presumptive buyers’ prices or rents but still affecting the prices or rents paid because amenities affect market demand. This condition is particularly cumbersome in low-income city districts, and/or in city districts with “negative” amenities, such as visible street crime and a substandard quality of schooling. A study of an urban development project in a “particularly socially vulnerable” city district in Sweden shows how municipally-owned real estate companies and private construction companies need to collaborate with authorities (e.g. the police) and municipal boards (e.g. the education board) to advocate investment in amenities. In order to increase housing stock evaluations, local housing market attractiveness, and the housing welfare of residents in blighted city districts, urban development projects must include, in substantive ways, a variety of perspectives, competencies, and formal decision-making authorities. Journal: Construction Management and Economics Pages: 72-86 Issue: 1 Volume: 40 Year: 2022 Month: 1 X-DOI: 10.1080/01446193.2021.2018719 File-URL: http://hdl.handle.net/10.1080/01446193.2021.2018719 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:1:p:72-86 Template-Type: ReDIF-Article 1.0 Author-Name: Johan Larsson Author-X-Name-First: Johan Author-X-Name-Last: Larsson Author-Name: Per Erik Eriksson Author-X-Name-First: Per Erik Author-X-Name-Last: Eriksson Author-Name: Sofia Lingegård Author-X-Name-First: Sofia Author-X-Name-Last: Lingegård Author-Name: Anna-Therése Järvenpää Author-X-Name-First: Anna-Therése Author-X-Name-Last: Järvenpää Title: Innovation outcomes and processes in infrastructure projects – a comparative study of Design-Build and Design-Build-Maintenance contracts Abstract: Innovation is often seen as essential for long-term development in the construction industry, but its actual outcomes and processes in construction projects require more attention. Many studies on procurement strategies and delivery systems have focussed on the public transport infrastructure sector, whereas most construction innovation scholars have addressed the innovation phenomenon in construction generally. Thus, the purpose of this study is to compare how two delivery systems, design-build (DB) and design-build-maintenance (DBM), influence project-level innovation. Findings are based on empirical data from a multiple case study of six infrastructure projects, three with DB contracts and three with DBM contracts, in which 12 innovations are identified, described, and compared. The findings show that various kinds of innovations in terms of outcomes and processes are implemented in infrastructure projects, and that the delivery system do effect both dimensions. Long maintenance responsibilities tend to spur contractors to engage in early exploration of sustainable solutions that could be of long-term benefit. The research contributes to procurement literature by exemplifying how delivery systems influence both the outcomes and processes of project-level innovations. It also increases our knowledge about construction innovation as a multi-dimensional phenomenon. Journal: Construction Management and Economics Pages: 142-156 Issue: 2 Volume: 40 Year: 2022 Month: 2 X-DOI: 10.1080/01446193.2021.2024864 File-URL: http://hdl.handle.net/10.1080/01446193.2021.2024864 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:2:p:142-156 Template-Type: ReDIF-Article 1.0 Author-Name: Roine Leiringer Author-X-Name-First: Roine Author-X-Name-Last: Leiringer Author-Name: Stefan Christoffer Gottlieb Author-X-Name-First: Stefan Christoffer Author-X-Name-Last: Gottlieb Author-Name: Yan Fang Author-X-Name-First: Yan Author-X-Name-Last: Fang Author-Name: Xiaoyu Mo Author-X-Name-First: Xiaoyu Author-X-Name-Last: Mo Title: In search of sustainable construction: the role of building environmental assessment methods as policies enforcing green building Abstract: Over the past 20 years, building environmental assessment methods (BEAMs) have been promoted as a means to achieve more sustainable and environmentally friendly (green) buildings, as well as more sustainable practices in the building process at large. These schemes have come to be considered as effective mechanisms to transform building markets and are seen to play a significant role in the mainstreaming of green building practices. In many countries, BEAMs are now used as policy instruments and are increasingly being mandated across a variety of public, but also private, sector projects. In this paper, we examine BEAMs as policy instruments and explore their potential to affect change in construction. Drawing on the theory of strategic action fields, and using the case of HK-BEAM, we discuss the origins, development and application of BEAMs and the limited impact that their mandate has on construction practice. The paper concludes with reflections on the need to further our understanding of how the construction sector works and who has the power, and the will, to make changes in construction practice happen. Journal: Construction Management and Economics Pages: 104-122 Issue: 2 Volume: 40 Year: 2022 Month: 2 X-DOI: 10.1080/01446193.2021.2021259 File-URL: http://hdl.handle.net/10.1080/01446193.2021.2021259 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:2:p:104-122 Template-Type: ReDIF-Article 1.0 Author-Name: Joao Soliman-Junior Author-X-Name-First: Joao Author-X-Name-Last: Soliman-Junior Author-Name: Patricia Tzortzopoulos Author-X-Name-First: Patricia Author-X-Name-Last: Tzortzopoulos Author-Name: Mike Kagioglou Author-X-Name-First: Mike Author-X-Name-Last: Kagioglou Title: Designers’ perspective on the use of automation to support regulatory compliance in healthcare building projects Abstract: Automation has been long explored to improve regulatory compliance during building design. Despite substantial research efforts on developing means to enable this process, there has been limited success in practical implementations. Designers’ inputs are often undervalued in such developments, leading to solutions that are not effectively incorporated into the design process. This issue is even more difficult in healthcare projects due to their complexity and convoluted regulatory frameworks. In this paper, we describe how designers perceive the use of automation to support regulatory compliance in healthcare projects, through the analysis of a series of semi-structured interviews. We found that regulatory documents have a large influence on design and their compliance often consists of an unformalised process in practice. Furthermore, we identified that subjectivity is perceived in requirements as needed due to the creativity involved in design, whereas automation can be understood as liberating in this context depending on how it is used. Improvement needs focussing on the revision of the regulatory framework as well as on software development have been highlighted by participants during the interviews, which led to the proposition of recommendations to help achieve their benefits in practice. Journal: Construction Management and Economics Pages: 123-141 Issue: 2 Volume: 40 Year: 2022 Month: 2 X-DOI: 10.1080/01446193.2021.2022176 File-URL: http://hdl.handle.net/10.1080/01446193.2021.2022176 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:2:p:123-141 Template-Type: ReDIF-Article 1.0 Author-Name: Alireza Sharafi Author-X-Name-First: Alireza Author-X-Name-Last: Sharafi Author-Name: Mohsen Sadegh Amalnick Author-X-Name-First: Mohsen Sadegh Author-X-Name-Last: Amalnick Author-Name: Ata Allah Taleizadeh Author-X-Name-First: Ata Allah Author-X-Name-Last: Taleizadeh Title: Optimal readjustment of contract variables and the financial outcome of PPP projects in the operation period Abstract: Contract readjustment and renegotiation are inevitable in PPP projects. Tolls, concession length, and government subsidies are the three main variables that provide a set of Pareto payoffs for the private sector and the government during the operation period. This study provides a bargaining approach based on game theory to fairly determine the payoff parties and optimally readjust the contract variables. Unlike previous studies, this model provides a unique optimal solution in all three negotiation areas including Pareto-compensation bargaining, Pareto-improving bargaining, and Pareto-sharing bargaining. The results indicate that the initial forecast range of private profit and expected payoff parties based on the actual performance have significant impacts on the final output. Contrary to popular belief, receiving a higher guarantee from the government in the contract can lead to a reduction in the private's share during the operation period, if excess profits are made. Similarly, reducing the profit cap in the contract can benefit the private sector in the case of a profit shortfall. This model can support strategic renegotiations and provide a fair and optimal structure to readjust contract variables which will facilitate and expedite the decision-making process. Journal: Construction Management and Economics Pages: 87-103 Issue: 2 Volume: 40 Year: 2022 Month: 2 X-DOI: 10.1080/01446193.2021.2007536 File-URL: http://hdl.handle.net/10.1080/01446193.2021.2007536 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:2:p:87-103 Template-Type: ReDIF-Article 1.0 Author-Name: Ming Hu Author-X-Name-First: Ming Author-X-Name-Last: Hu Author-Name: Eero Nippala Author-X-Name-First: Eero Author-X-Name-Last: Nippala Author-Name: Kari Kallioharju Author-X-Name-First: Kari Author-X-Name-Last: Kallioharju Author-Name: Sofie Pelsmakers Author-X-Name-First: Sofie Author-X-Name-Last: Pelsmakers Title: Monte Carlo simulation approach to understand the cost variance for energy retrofit projects: comparative study of Finland and the United States Abstract: Energy-efficient building is often characterised with higher construction costs. There is a large variance in energy-efficient building construction costs, especially in retrofit projects. A lack of understanding of cost variance and ambiguity of cost-optimal practices has impeded the adoption of energy retrofit practices globally. To respond to such a knowledge gap, a comparative study was conducted on energy retrofit projects on residential buildings in Finland and the United States. A Monte Carlo simulation was used to determine the coefficient of variation for construction costs and the potential reasons behind the variations. The specific aims of this study are (a) to gain a deeper understanding of construction cost variances in energy retrofit projects, (b) to identify the most influential cost items, and (c) to understand the correlations among different cost items. For this analysis, a database including 10 Finnish buildings and 7 US buildings was created, and actual construction cost data was collected. The results showed the following: (1) US projects had a larger total construction cost variance with highly skewed distribution, and Finnish energy retrofit projects had a cost distribution similar to conventional retrofit projects; (2) the two most significant construction cost factors for both countries were non-energy related cost items and the building envelope, rather than the mechanical system (heating and ventilation) as commonly perceived; and (3) the larger construction cost variance in the United States may be associated with the unfamiliarity of energy-efficient technologies and varied construction methods in different regions. The insights and suggestions derived from those findings are discussed in the conclusion. Journal: Construction Management and Economics Pages: 207-222 Issue: 3 Volume: 40 Year: 2022 Month: 3 X-DOI: 10.1080/01446193.2022.2034906 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2034906 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:3:p:207-222 Template-Type: ReDIF-Article 1.0 Author-Name: Mina Jowkar Author-X-Name-First: Mina Author-X-Name-Last: Jowkar Author-Name: Alenka Temeljotov-Salaj Author-X-Name-First: Alenka Author-X-Name-Last: Temeljotov-Salaj Author-Name: Carmel Margaret Lindkvist Author-X-Name-First: Carmel Margaret Author-X-Name-Last: Lindkvist Author-Name: Marit Støre-Valen Author-X-Name-First: Marit Author-X-Name-Last: Støre-Valen Title: Sustainable building renovation in residential buildings: barriers and potential motivations in Norwegian culture Abstract: Retrofit of existing housing increases the possibility of meeting Sustainable Development Goals. Improving quality of life, minimising energy consumption and increasing productivity in buildings process with the aim of affordable housing (social, environmental, and economic sustainability) set new demands for renovation amongst residential housing in Norway. Most studies to date emphasised on mitigation of CO2 emissions in building sector through building renovations. However, recent studies started evaluating why such renovation plans may not be considered by property owners. This study investigates potential barriers and motivations for Sustainable Building Renovations (SBR) from house-owners’ perspective and discusses the role of urban Facility Management (FM) in promoting SBR. Results from a questionnaire survey with 341 citizens in Trondheim city, Norway, confirm economic issues as the main barrier for SBR with respondents suggesting different forms of financial support to resolve these barriers. Social engagement of citizens with public/private partners and neighbours illustrates the collective motivation for SBR. This requires an intermediary role like urban FM engaging citizens to co-create their needs in urban areas with public/private sectors. The output of this study helps to promote urban FM engaging with SBR targets through renovation of neighbourhoods. Journal: Construction Management and Economics Pages: 161-172 Issue: 3 Volume: 40 Year: 2022 Month: 3 X-DOI: 10.1080/01446193.2022.2027485 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2027485 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:3:p:161-172 Template-Type: ReDIF-Article 1.0 Author-Name: An Thi Hoai Le Author-X-Name-First: An Thi Hoai Author-X-Name-Last: Le Author-Name: Niluka Domingo Author-X-Name-First: Niluka Author-X-Name-Last: Domingo Author-Name: Eziaku Rasheed Author-X-Name-First: Eziaku Author-X-Name-Last: Rasheed Author-Name: Kenneth Park Author-X-Name-First: Kenneth Author-X-Name-Last: Park Title: Strategic collaboration in managing existing buildings in New Zealand's state schools: school managers' perspectives Abstract: Collaboration has been considered one of the keys for effectively managing state school properties in New Zealand, with participants combining their abilities to solve challenges and achieve common goals. However, this is challenging due to the multiple stakeholders involved (Ministry staff, external consultants, school boards), process fragmentation, and the stakeholders’ diversity of knowledge. This research aims to develop a collaboration maturity model with process areas, criteria in each process area and rating levels. The criteria were identified from interviews with school managers and then used in a questionnaire survey to investigate the maturity levels of criteria in the collaboration. The assessment results provide insights into the problems or lowest scores criteria that are most needed for improvement. Based on the findings, improvement initiatives have been discussed. From school managers’ perspective, the empirical findings can be translated into actionable knowledge in a way that helps the top management review their collaboration policies regarding staff training, funding allocation, reporting system and information technology. Journal: Construction Management and Economics Pages: 173-185 Issue: 3 Volume: 40 Year: 2022 Month: 3 X-DOI: 10.1080/01446193.2022.2027486 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2027486 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:3:p:173-185 Template-Type: ReDIF-Article 1.0 Author-Name: Pekka Rajala Author-X-Name-First: Pekka Author-X-Name-Last: Rajala Author-Name: Antti Ylä-Kujala Author-X-Name-First: Antti Author-X-Name-Last: Ylä-Kujala Author-Name: Tiina Sinkkonen Author-X-Name-First: Tiina Author-X-Name-Last: Sinkkonen Author-Name: Timo Kärri Author-X-Name-First: Timo Author-X-Name-Last: Kärri Title: Profitability in construction: how does building renovation business fare compared to new building business Abstract: In recent decades, energy-efficiency improvements and ageing dwelling stocks have grown the renovation need in many countries. This research compares the profitability of building renovation companies and companies specializing in new construction using financial statement analysis and analysis of variance. Profitability is assessed through EBITDA and return on assets (ROA). Debt to equity (D/E) ratio as a solvency measure supports the analysis. The findings show micro and small companies in the new building sector have a statistically significant advantage in EBITDA over renovation in same size groups; projects in the renovation sector appear to be more complex, especially in terms of design, causing cost overruns. The more cyclical nature of new construction, however, equalizes EBITDA differences over time. Medium-size companies overall had the lowest EBITDA following the 2008–2009 financial crisis. ROA was generally higher for the renovation sector highlighting the more capital-intensive nature of new construction; unsold apartments and land for future projects hold capital, which results in higher D/E ratios. D/E ratios also revealed that both sectors have faced the COVID-19 pandemic less indebted compared to the 2008–2009 financial crisis. Since both sectors’ profitability has been decreasing during the research period (2005–2019), actions are needed especially in the renovation sector, which has an increasingly important role in developed societies. Journal: Construction Management and Economics Pages: 223-237 Issue: 3 Volume: 40 Year: 2022 Month: 3 X-DOI: 10.1080/01446193.2022.2032228 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2032228 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:3:p:223-237 Template-Type: ReDIF-Article 1.0 Author-Name: Per Anker Jensen Author-X-Name-First: Per Anker Author-X-Name-Last: Jensen Author-Name: Liane Thuvander Author-X-Name-First: Liane Author-X-Name-Last: Thuvander Author-Name: Paula Femenias Author-X-Name-First: Paula Author-X-Name-Last: Femenias Author-Name: Henk Visscher Author-X-Name-First: Henk Author-X-Name-Last: Visscher Title: Sustainable building renovation – strategies and processes Journal: Construction Management and Economics Pages: 157-160 Issue: 3 Volume: 40 Year: 2022 Month: 3 X-DOI: 10.1080/01446193.2022.2045717 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2045717 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:3:p:157-160 Template-Type: ReDIF-Article 1.0 Author-Name: Bani Feriel Brahmi Author-X-Name-First: Bani Feriel Author-X-Name-Last: Brahmi Author-Name: Souad Sassi Boudemagh Author-X-Name-First: Souad Author-X-Name-Last: Sassi Boudemagh Author-Name: Ilham Kitouni Author-X-Name-First: Ilham Author-X-Name-Last: Kitouni Author-Name: Aliakbar Kamari Author-X-Name-First: Aliakbar Author-X-Name-Last: Kamari Title: IPD and BIM-focussed methodology in renovation of heritage buildings Abstract: Complexity in the sustainable renovation of heritage buildings requires adoption of more sophisticated technologies and project management models to deal with the contradiction between sustainable design and heritage values preservation, as well as enhancing process productivity and final performance. This research aims to assess the application of several Integrated Project Delivery (IPD) strategies and tools through Building Information Modelling (BIM), determining shared collaborative practices across the projects and the level to which the teams were able to implement the tools and processes effectively to enhance sustainability aspects and efficiency of renovating heritages. The research adopts a mixed methodology, Qualitative Comparative Analysis triangulating the collected data. An intensive review of related literature is carried out, besides data collection and analysis of four real-world heritage cases (in different contexts). The research study enables a comprehensive and systematic exploration of the potential use of IPD and BIM within the development of an analytical framework consisting of a set of defined variables including 50 criteria, classified into 15 categories, and grouped into five thematic strands (people, process, policy, technology, and product). The findings reveal that IPD and BIM simultaneous use allows integrating heritage values into holistic decision-making frameworks attaining high-performance outcomes in heritage renovations. Journal: Construction Management and Economics Pages: 186-206 Issue: 3 Volume: 40 Year: 2022 Month: 3 X-DOI: 10.1080/01446193.2021.1933557 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1933557 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:3:p:186-206 Template-Type: ReDIF-Article 1.0 Author-Name: Ramy Khalef Author-X-Name-First: Ramy Author-X-Name-Last: Khalef Author-Name: Gasser G. Ali Author-X-Name-First: Gasser G. Author-X-Name-Last: Ali Author-Name: Islam H. El-adaway Author-X-Name-First: Islam H. Author-X-Name-Last: El-adaway Author-Name: Ghada M. Gad Author-X-Name-First: Ghada M. Author-X-Name-Last: Gad Title: Managing construction projects impacted by the COVID-19 pandemic: a contractual perspective Abstract: The Coronavirus Disease (COVID-19) had severe, unforeseen, and prolonged implications on construction projects as well as many other industries. This resulted in severe effect on the supply of material, manufacturing, availability of human resources, and other factors which collectively negatively affected construction processes. To this end, there is a lack of comprehensive studies and understanding concerning that the contractual implications and remedies associated with the COVID-19 pandemic. This paper addresses this knowledge gap. The authors utilise a multi-step research methodology that comprised: (1) studying the contractual interpretation of COVID-19 under the American Institute of Architects (AIA) A-201-2017 as a widely used standard form of contract in the United States; (2) determining the associated contractual remedies for COVID-19; (3) comparing how the aforementioned two issues are handled under the Federation of International Construction Engineers (FIDIC) Red Book 2017, as being a much utilised international standard form of contract that is adopted by the World Bank; (4) developing guidelines and recommendations to be used by owners, contractors, project managers, and contract administrators in planning, handling, and mitigating the contractual implications of the current pandemic; (5) investigating the applicable legal doctrines and principles; and (6) solidifying the research steps and overall research outcomes using the input of legal experts who also helped investigate the relevant common law legal principles that could be associated with COVID-19. The results of this research should promote effective and efficient project management practices under the current new normal and similar interrelated conditions. Journal: Construction Management and Economics Pages: 313-330 Issue: 4 Volume: 40 Year: 2022 Month: 4 X-DOI: 10.1080/01446193.2022.2031238 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2031238 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:4:p:313-330 Template-Type: ReDIF-Article 1.0 Author-Name: Ali Vahabi Author-X-Name-First: Ali Author-X-Name-Last: Vahabi Author-Name: Farnad Nasirzadeh Author-X-Name-First: Farnad Author-X-Name-Last: Nasirzadeh Author-Name: Anthony Mills Author-X-Name-First: Anthony Author-X-Name-Last: Mills Title: Influence of briefing clarity on construction projects: a fuzzy hybrid simulation approach Abstract: Predicting brief clarity and assessing its impact on project performance at an early stage of the project delivery can aid in mitigating possible cost overruns and delays. However, this is extremely challenging because of two main issues: the complexity of multiple interrelationships between factors influenced by the briefing process, and the lack of data at the early stage of the project delivery. This study proposes a hybrid simulation approach that addresses these issues and models the influence of briefing clarity on project cost and time performance. This was achieved by developing a system dynamics (SD) model of the briefing process. The initial brief clarity is predicted using a fuzzy control system. The fuzzy outcomes were compiled into the SD model, and the obtained hybrid model was validated. Finally, the model was applied to refurbishment projects to evaluate its efficiency. The implication for the refurbishment projects shows that by clearly defining the brief, it significantly reduces the detailed design and construction cost and duration. The results confirm that the proposed hybrid method can be effective in evaluating the impact of briefing clarity on project performance, particularly at an early stage where there is a lack of project data. Journal: Construction Management and Economics Pages: 278-295 Issue: 4 Volume: 40 Year: 2022 Month: 4 X-DOI: 10.1080/01446193.2022.2037148 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2037148 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:4:p:278-295 Template-Type: ReDIF-Article 1.0 Author-Name: Wolfgang Grenzfurtner Author-X-Name-First: Wolfgang Author-X-Name-Last: Grenzfurtner Author-Name: Martin Rudberg Author-X-Name-First: Martin Author-X-Name-Last: Rudberg Author-Name: Richard Mayrhofer Author-X-Name-First: Richard Author-X-Name-Last: Mayrhofer Author-Name: Kristina Loike Author-X-Name-First: Kristina Author-X-Name-Last: Loike Author-Name: Manfred Gronalt Author-X-Name-First: Manfred Author-X-Name-Last: Gronalt Title: Performance measurement and management practices of on-site activities in industrialized housebuilding Abstract: Measuring the performance of construction site processes is an essential for the continuous improvement in building production efficiency. However, little is known about how this is done by industrialized housebuilding (IHB) companies. The purpose of this paper was to extend the body of knowledge of IHB to on-site performance measurement and management (PMM), thereby identifying reference practices and potential areas for improvement in order to prepare the field for the further development of significant performance management systems (PMS). A multiple case study by means of semi-structured interviews with company managers of eight companies within the IHB sector from three Central European countries has been conducted. The results show that the companies, to a greater or lesser extent, collect data on: customer satisfaction, environmental protection and CO2 emissions, operating efficiency, productivity, quality and work safety. The data can be used to perform performance measurements that provide feedback on these criteria. Reference practices of performance measurements and their benefit are identified. Digital tools are increasingly being used for data collection on construction sites, although paper-based tools such as site and working time reports are still in use. The findings establish a basis for the further development of PMS within the IHB sector. Journal: Construction Management and Economics Pages: 239-253 Issue: 4 Volume: 40 Year: 2022 Month: 4 X-DOI: 10.1080/01446193.2022.2037147 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2037147 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:4:p:239-253 Template-Type: ReDIF-Article 1.0 Author-Name: Joonas Lehtovaara Author-X-Name-First: Joonas Author-X-Name-Last: Lehtovaara Author-Name: Olli Seppänen Author-X-Name-First: Olli Author-X-Name-Last: Seppänen Author-Name: Antti Peltokorpi Author-X-Name-First: Antti Author-X-Name-Last: Peltokorpi Title: Improving construction management with decentralised production planning and control: exploring the production crew and manager perspectives through a multi-method approach Abstract: Decentralised, autonomous planning and control is a potential avenue of improvement in several fields, including construction. However, research on this topic, particularly involving the production crew viewpoint, remains scarce within the construction production management domain. This study explores the effects of decentralisation (and in contrast, effects of centralisation) for construction production planning and control (PP&C) from the combined perspectives of production crews and managers, and utilises these viewpoints to suggest improvements for PP&C practices. The study answers the following research questions: How do decentralisation/centralisation affect construction PP&C practices when considering both the production crew and manager perspectives? and Based on the aforementioned perspectives, how may construction PP&C practices overall be improved? To achieve holistic assessment, the research is conducted as a multi-method comparative case study using survey-based social network analysis (SNA) and semi-structured interviews. The results show that decentralised PP&C offers several benefits—such as improved transparency, conflict resolution, commitment, and lower stress—while allowing a proactive building of resilience, trust, ownership and autonomy for crews. In its current applied form, however, the approach does not fully reach the worker level. Regardless of the approach that is used, production crews perceive PP&C as decentralised, while managers perceive PP&C as having centralised structures. This gap between perceptions forms barriers for effective PP&C that must be properly addressed. Eight improvement suggestions are constructed to improve PP&C, that generally emphasise more deliberate decentralisation but that also indicate the necessity of partial central planning and control. Journal: Construction Management and Economics Pages: 254-277 Issue: 4 Volume: 40 Year: 2022 Month: 4 X-DOI: 10.1080/01446193.2022.2039399 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2039399 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:4:p:254-277 Template-Type: ReDIF-Article 1.0 Author-Name: Jeroen van der Meer Author-X-Name-First: Jeroen Author-X-Name-Last: van der Meer Author-Name: Andreas Hartmann Author-X-Name-First: Andreas Author-X-Name-Last: Hartmann Author-Name: Aad van der Horst Author-X-Name-First: Aad Author-X-Name-Last: van der Horst Author-Name: Geert Dewulf Author-X-Name-First: Geert Author-X-Name-Last: Dewulf Title: Raising risk awareness in multi-criteria design decisions for integrated design and construction tenders Abstract: Awareness of design risks is essential for preparing integrated design and construction tenders as decisions in this phase can have serious consequences once the project is awarded. The practice of multi-criteria decision analysis (MCDA) promises to support contractors in dealing with risks in the decision-making process. However, due to limited time and resources in a tender, risks involved in design alternatives are often overlooked and the selection of alternatives is mainly based on the decision-makers’ knowledge and experience. This raises the question how decision makers can become aware of the risks in the tender phase of projects. Following a design science research approach three interventions to raise risk awareness are identified and validated in the context of an infrastructure tender in the Netherlands. These interventions are (1) a general list of defined criteria to identify those criteria that correspond with the characteristics of the tender; (2) mapping identified project risks on criteria and assign a bandwidth score; (3) evaluation of the quality of the decision process by scoring elements of decision quality. Based on these interventions three design rules are proposed to increase the transparency of decision problems and the understanding of choices and, by doing so, create awareness for risks involved in design alternatives. Journal: Construction Management and Economics Pages: 296-312 Issue: 4 Volume: 40 Year: 2022 Month: 4 X-DOI: 10.1080/01446193.2022.2030063 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2030063 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:4:p:296-312 Template-Type: ReDIF-Article 1.0 Author-Name: Laurie Galardo Author-X-Name-First: Laurie Author-X-Name-Last: Galardo Author-Name: Mélanie Trottier Author-X-Name-First: Mélanie Author-X-Name-Last: Trottier Title: How supervisor, co-worker, and spousal social support influences the experience of workload and work-family conflict: results from a survey of construction workers in Québec Abstract: This study investigates the effects of three different sources of social support (supervisor, co-workers, and spouse) on experienced workload and on work-family conflict (WFC) among a population of on-site construction workers in Québec, Canada. The findings of this study contribute to current knowledge by providing evidence of the means by which social support most influences WFC experienced by on-site construction workers (e.g. through workload modulation). More precisely, the study contributes to the literature by demonstrating that social support at work—despite its being limited by so-called masculine culture at the workplace—is instrumental to reduce the adverse effects of workload on WFC. In total, 811 workers in the Québec construction industry took part in this cross-sectional study. Results of mediation analysis show that all sources of social support reduce WFC by diminishing the perception of workload. However, even though workers report less social support from their supervisors than from their spouses, indirect effect analysis shows that supervisor social support is the source that most reduces the perception of workload and, in turn, WFC. Results of the ratio comparison indicate that supervisor and co-worker social support have more important direct impacts on WFC, whereas spousal social support has a more important indirect impact on WFC through a reduction in workload, suggesting that organizations need to foster social support at work (e.g. by promoting a culture of support) in order to ensure that work-family balance is valued at the workplace. Journal: Construction Management and Economics Pages: 331-342 Issue: 4 Volume: 40 Year: 2022 Month: 4 X-DOI: 10.1080/01446193.2022.2037674 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2037674 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:4:p:331-342 Template-Type: ReDIF-Article 1.0 Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Robyn Keast Author-X-Name-First: Robyn Author-X-Name-Last: Keast Author-Name: Jo Barraket Author-X-Name-First: Jo Author-X-Name-Last: Barraket Title: A typology of social procurement champions in the construction and engineering industry Abstract: Social procurement is re-emerging as an innovative collaborative policy tool for governments around the world to leverage their construction supply chains to help them address intransigent social problems such as long-term unemployment. Such policies challenge deeply rooted institutional norms and structures in the construction industry and research shows that they are being championed by a small and largely undefined group of social procurement professionals who suffer significant role conflict and ambiguity. Contributing new insights to this nascent research, this paper traces etymological definitions of champion roles, merging them with organisational theory to present a new typology of social procurement champions in the construction industry. Drawing on a thematic analysis of snowballed interviews with fifteen recognised champions of social procurement in the Australian construction industry, findings highlight four distinct types of social procurement champion: champions of organisations; champions of the concept; champions of people; and champions of a solution. It is found that there is no one pure type of social procurement champion. Rather, champions have to adapt their social procurement roles to the highly dynamic and varied organisation contexts in which they operate. These findings advance the emerging social procurement debate within and outside construction by highlighting the many different roles which are needed to implement social innovations like social procurement into a project-based industry like construction. It is concluded that organisations which see this as one person’s responsibility are likely to fail in implementing these new policy reforms. Journal: Construction Management and Economics Pages: 391-405 Issue: 5 Volume: 40 Year: 2022 Month: 5 X-DOI: 10.1080/01446193.2022.2043554 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2043554 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:5:p:391-405 Template-Type: ReDIF-Article 1.0 Author-Name: Ingrid Svensson Author-X-Name-First: Ingrid Author-X-Name-Last: Svensson Title: Exploring the connection between emotions, artefacts and institutional work: the case of institutional change for public facilities management Abstract: Public facilities management (PFM) is currently moving from being an institution driven by ad-hoc practices to now introducing long-term and strategic practices. During this institutional change, human actors engage in institutional work to create new practices. However, old practices seem to be maintained within PFM to a large extend. Why? Data were collected through case studies in two public facilities management organizations, an interview study in eight organizations from the institution of PFM and a workshop with representatives from the institutional field of PFM. Findings show how the changing institutional setting for the institution of PFM produce negative emotions. To manage these, human actors engage in institutional work and here they employ artefacts as means to drive change. These artefacts functioned in various ways to reduce negative feelings by inducing a sense of safety (as soft blankets), by enabling the avoidance of dealing with ‘the truth’ (as shields) and by offering hope (as a vision of perfect future). Thereby, they did not take part in creating change, as much as they took part in maintaining current practices. The unintended consequences of the usage of artefacts, explain why practices are maintained during institutional change for PFM. Journal: Construction Management and Economics Pages: 343-358 Issue: 5 Volume: 40 Year: 2022 Month: 5 X-DOI: 10.1080/01446193.2022.2053997 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2053997 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:5:p:343-358 Template-Type: ReDIF-Article 1.0 Author-Name: David Oswald Author-X-Name-First: David Author-X-Name-Last: Oswald Author-Name: Helen Lingard Author-X-Name-First: Helen Author-X-Name-Last: Lingard Author-Name: Rita Peihua Zhang Author-X-Name-First: Rita Peihua Author-X-Name-Last: Zhang Title: How transactional and transformational safety leadership behaviours are demonstrated within the construction industry Abstract: Transactional and transformational safety leadership have been repeatedly found to be important for safety. Yet how transactional and transformational leadership behaviours are most effectively demonstrated can be dependent on the context and industry. Using an ethnographic approach, supervisor safety leadership was explored across eleven construction sites in Australia. The findings revealed that, within the construction site context, contingent reward, idealised influence, and management-by-exception behaviours demonstrated by supervisors closely aligned with their definitions in Full-Range Leadership Theory (FRLT). These three types of leadership behaviour reflect observation of supervisors’ positive actions, which included: praising workers for good safety performance; proactively anticipating and attending to safety issues; and consistently leading-by-example with safety, even at times of significant production pressure. Other theoretically described dimensions of leadership behaviour, i.e. individual consideration, inspirational motivation, and intellectual stimulation, were not directly reflected in observed supervisors’ behaviour in the way they are conceptualised in FRLT. The existence of a good supervisor-worker relationship enabled workers to comfortably raise safety issues, think creatively about how to undertake work safely, and talk to their supervisor if they were experiencing personal problems. These are motivational, intellectual, and empathetic elements of leadership, which do not directly align with the way leadership behaviours are conceptualised in mainstream FRLT. The study suggests that, in the construction worksite context, leadership behaviours may take a form that differs from theoretical ideal types and that ethnographically attained insights into supervisors’ interactions with workers can contribute to understanding transformational and transactional leadership in practical terms. Journal: Construction Management and Economics Pages: 374-390 Issue: 5 Volume: 40 Year: 2022 Month: 5 X-DOI: 10.1080/01446193.2022.2053998 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2053998 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:5:p:374-390 Template-Type: ReDIF-Article 1.0 Author-Name: Tamima S. Elbashbishy Author-X-Name-First: Tamima S. Author-X-Name-Last: Elbashbishy Author-Name: Gasser G. Ali Author-X-Name-First: Gasser G. Author-X-Name-Last: Ali Author-Name: Islam H. El-adaway Author-X-Name-First: Islam H. Author-X-Name-Last: El-adaway Title: Blockchain technology in the construction industry: mapping current research trends using social network analysis and clustering Abstract: Blockchain represents an evolving technology for distributed and secure recording and sharing of information. Meanwhile, blockchain has thrived in banking, finance, and supply chain; its usage within the construction industry is still in its infancy. To this end, the existing literature falls short in providing comprehensive quantitative understanding, within a systems-based analytic context, of the factors affecting blockchain utilization in construction applications. This paper fills this knowledge gap. The authors: (1) conducted an extensive literature review on blockchain implementation in the construction domain; (2) identified a list of 41 factors affecting blockchain implementation in construction projects categorized in four categories: challenges, needs, requirements, and capabilities; (3) utilized a social network analysis (SNA) approach on a database of 111 publications to quantitatively analyze the literature as related to the aforementioned factors; and (4) performed clustering analysis on the SNA graphs to determine the combinations of factors that are most likely co-occurring in research publications. SNA results indicate that while the most investigated factor was “increased trust and transparency between project parties”, the least studied factors included: “cash upfront funding system”, “change payment processes and procedures”, “smart contracts design errors”, “cryptocurrency fluctuations”, “lack of sufficiently skilled personnel”, and “increased awareness and capabilities of personnel”. Also, clustering outcomes highlight that some combinations of factors are not well-represented in current scholarly efforts. Such imbalance and consequent knowledge gaps may contribute to the actual implementation rate of blockchain in construction applications. Ultimately, this paper provides a roadmap for potential future directions of blockchain construction-related research. Journal: Construction Management and Economics Pages: 406-427 Issue: 5 Volume: 40 Year: 2022 Month: 5 X-DOI: 10.1080/01446193.2022.2056216 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2056216 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:5:p:406-427 Template-Type: ReDIF-Article 1.0 Author-Name: Richard Brett Author-X-Name-First: Richard Author-X-Name-Last: Brett Author-Name: Derek Thomson Author-X-Name-First: Derek Author-X-Name-Last: Thomson Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Title: Exploring craft in construction with short-term ethnography: reflections on a researcher’s prior insight Abstract: Ethnography offers a route to knowing about the everyday activities of construction workers, but its long duration is not always suited to the site environment or the researcher’s resources and the workers themselves are constantly changing. Short-term ethnography is an alternative to the traditional format that permits a shorter length of fieldwork activity in return for intense engagement between the researcher and their participants. The rich points that make up an ethnographic account need to be actively sought in short-term ethnography. This can be achieved by utilizing the prior construction experiences of the researcher. The researcher enters the field with an emic insight that can be used to seek out events and allows the production of meaningful ethnography from a shorter, more intense fieldwork period, learning much from individual workers before they move on. Engagement extends beyond the onsite interactions through the use of video cameras to record everyday activities. Examples from two short-term ethnographies of two deliberately different sites explain how, in the search for craft traits among construction workers, the fieldworker is able to mobilize emic insight and craft theory to seek out rich points in everyday events which are typically serendipitous in nature. This account serves to provide a demonstration of how the very real tensions between the limitations of project context as a field site and the need for methodological rigour can be reconciled through careful attention to reflexive ethnographic practice. Journal: Construction Management and Economics Pages: 359-373 Issue: 5 Volume: 40 Year: 2022 Month: 5 X-DOI: 10.1080/01446193.2022.2046827 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2046827 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:5:p:359-373 Template-Type: ReDIF-Article 1.0 Author-Name: Ying Gao Author-X-Name-First: Ying Author-X-Name-Last: Gao Author-Name: Xiaoyu Liu Author-X-Name-First: Xiaoyu Author-X-Name-Last: Liu Author-Name: Shuibo Zhang Author-X-Name-First: Shuibo Author-X-Name-Last: Zhang Author-Name: Jinyue Zhang Author-X-Name-First: Jinyue Author-X-Name-Last: Zhang Author-Name: Qing Guo Author-X-Name-First: Qing Author-X-Name-Last: Guo Title: BIM application and collaboration in construction projects: a perspective of the Chinese construction market Abstract: Although building information modelling (BIM) is endowed with the potential for collaboration, the nature of the relationship between BIM application and collaboration has not been well-elaborated. This research classifies collaboration into the two dimensions of cooperation and coordination and empirically tests a model to understand not only the effect of BIM application on collaboration in construction projects but also the moderating effects of fairness perception and contract specificity. Using 296 samples from the Chinese construction industry, this research reveals the existence of a positive relationship between BIM application and collaboration. In addition, fairness perception weakens the relationship between BIM application and both collaboration dimensions of cooperation and coordination, while contract specificity strengthens the effect of BIM application on the coordination dimension only. These findings offer new insights through a nuanced understanding of the nature of the relationship between BIM application and collaboration, providing useful guidance for BIM application in the construction industry. Journal: Construction Management and Economics Pages: 429-441 Issue: 6 Volume: 40 Year: 2022 Month: 6 X-DOI: 10.1080/01446193.2022.2080240 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2080240 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:6:p:429-441 Template-Type: ReDIF-Article 1.0 Author-Name: Rickard Andersson Author-X-Name-First: Rickard Author-X-Name-Last: Andersson Author-Name: Martine Buser Author-X-Name-First: Martine Author-X-Name-Last: Buser Title: From waste to resource management? Construction and demolition waste management through the lens of institutional work Abstract: The European Union has issued action plans to reduce the production of construction waste and increase the reuse and recycling of materials in the hope of triggering a rapid transition towards a Circular Economy (CE). The management of construction and demolition waste, however, struggles to apply these measures. Our purpose, therefore, is to analyse how different actors involved in the management of waste could contribute to transform existing practices so that they respond to the shifting demands of legislation and support CE. To understand how this transformation work is performed, we build on the concept of institutional work, which enables us to describe how actors, rather than accepting institutions as permanent and immovable, contribute to their development by creating, maintaining or disrupting the existing institution. Drawing on qualitative research methods, we collected empirical data through 31 semi-structured interviews, observations of meetings and site visits. Our results show that whereas the production of waste is somewhat reduced, and the sorting of fractions improved, the institutional work performed is not sufficient to translate sustainability into new economic values. Although the work performed legitimizes CE principles and enables new initiatives, it mostly fails to change normative associations and to define new rules of action that support CE. Journal: Construction Management and Economics Pages: 477-496 Issue: 6 Volume: 40 Year: 2022 Month: 6 X-DOI: 10.1080/01446193.2022.2081989 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2081989 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:6:p:477-496 Template-Type: ReDIF-Article 1.0 Author-Name: Yuanxin Zhang Author-X-Name-First: Yuanxin Author-X-Name-Last: Zhang Author-Name: Zeyu Wang Author-X-Name-First: Zeyu Author-X-Name-Last: Wang Author-Name: Wenhao Lin Author-X-Name-First: Wenhao Author-X-Name-Last: Lin Author-Name: R. Edward Minchin Author-X-Name-First: R. Edward Author-X-Name-Last: Minchin Author-Name: Xiaolong Xue Author-X-Name-First: Xiaolong Author-X-Name-Last: Xue Title: Understanding the slow diffusion of alternative delivery systems using interpretive structural modelling Abstract: The slow uptake of the alternative delivery systems (ADSs) can potentially waste an astronomical amount of precious public funds that can be used to meet other critical needs (e.g. education and healthcare). The existing literature mainly focussed on performance evaluation of the ADSs and few provided decision support to select ADSs matching a particular project’s characteristics or external environment. Nonetheless, there lacks of research exploring the slow diffusion of ADSs, especially a deep understanding of the interaction mechanisms of the influencing factors. This research aims to increase the use of ADSs in practice. To achieve the objective, based on the data retrieved from literature, case study and interviews, this study, therefore, aims to: identify the internal and external influencing factors; reveal the interplays of these factors using interpretive structural modelling (ISM) and analyse the driving and dependence power of the factors based on Matrice d’Impacts Croisés-Multiplication Appliquée á un Classement analysis (MICMAC). Based on the 25 identified factors, the ISM built a hierarchical structural model, which reveals the interaction mechanism of the factors and the fundamental factors. The MICMAC analysis discovered the high driving, high dependent, transitive/linkage and independent factors on the diffusion of ADSs. The findings contribute to the body of knowledge about what and how the factors influencing the slow diffusion of ADSs and help contractor administrators formulate effective strategies to improve the usage of ADSs. Journal: Construction Management and Economics Pages: 459-476 Issue: 6 Volume: 40 Year: 2022 Month: 6 X-DOI: 10.1080/01446193.2022.2081990 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2081990 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:6:p:459-476 Template-Type: ReDIF-Article 1.0 Author-Name: Paul Bowen Author-X-Name-First: Paul Author-X-Name-Last: Bowen Author-Name: Kamal Yakubu Author-X-Name-First: Kamal Author-X-Name-Last: Yakubu Author-Name: Rajen Govender Author-X-Name-First: Rajen Author-X-Name-Last: Govender Title: Predictors of moderate to high risk of alcohol harm among site-based South African construction workers Abstract: Alcohol consumption is an accepted part of many social and cultural practices, but excessive alcohol consumption is a global public health concern. Aside of its detrimental effects on health, it is linked to HIV-related health behaviours such as unprotected sex, multiple/concurrent sexual partnerships, and lower levels of HIV testing. Little is known about the association between alcohol use and HIV-related heath behaviours in construction. Using data from 450 workers drawn from 18 construction sites in the Western Cape, the Alcohol Use Disorders Identification Test (AUDIT) was used to predict alcohol risk of harm as a function of demographic characteristics and sex-related behaviours among workers. Binary logistic regression determined factors associated with increased risk of alcohol harm. The most proximal factor predicting risk of alcohol harm was the frequency of alcohol or drug use before and/or during sex, followed by attitude towards condom use, education, and HIV testing behaviour. Future research efforts should develop a better appreciation of the role of sex-related alcohol expectancies in explaining harmful alcohol use, and intervention management practices should focus on this. Journal: Construction Management and Economics Pages: 442-458 Issue: 6 Volume: 40 Year: 2022 Month: 6 X-DOI: 10.1080/01446193.2022.2080241 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2080241 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:6:p:442-458 Template-Type: ReDIF-Article 1.0 Author-Name: Daniela Dietz Viana Author-X-Name-First: Daniela Dietz Author-X-Name-Last: Viana Author-Name: Carlos Torres Formoso Author-X-Name-First: Carlos Torres Author-X-Name-Last: Formoso Author-Name: Fernanda Saidelles Bataglin Author-X-Name-First: Fernanda Saidelles Author-X-Name-Last: Bataglin Title: Requirements for developing production planning and control systems for engineer-to-order industrialized building systems Abstract: Several efforts for industrializing construction have been made in different countries, and there has been a growing demand for engineer-to-order (ETO) industrialized building systems. In this context, products are unique for specific clients, as customer orders are placed at the design stage. There are many challenges for planning and controlling those building systems, due to the high level of complexity involved. The aim of this research is to propose a set of core requirements for production planning and control systems in ETO industrialized building systems. The methodological approach adopted in this investigation was design science research. It was based on a literature review on different planning and control models, and also on an empirical study carried out in a steel fabricator company. The proposed set of requirements is aligned with the management-as-organizing approach, challenging some traditional project management assumptions, including the use of metrics and practices that are not suitable for the high degree of complexity that exists in ETO environments. As a practical contribution, the requirements can be used by ETO construction supplier companies to support the conception and development of planning and control systems. Journal: Construction Management and Economics Pages: 638-652 Issue: 7-8 Volume: 40 Year: 2022 Month: 8 X-DOI: 10.1080/01446193.2022.2062778 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2062778 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:7-8:p:638-652 Template-Type: ReDIF-Article 1.0 Author-Name: Zofia K. Rybkowski Author-X-Name-First: Zofia K. Author-X-Name-Last: Rybkowski Author-Name: Paz Arroyo Author-X-Name-First: Paz Author-X-Name-Last: Arroyo Author-Name: Kristen Parrish Author-X-Name-First: Kristen Author-X-Name-Last: Parrish Title: Assessment of current target value design practices: consistencies and inconsistencies of application Abstract: Target Value Design (TVD) refers to the application of Target Costing (TC) to the delivery of projects with the involvement of owners, architects, engineers, and constructors (OAEC). TVD has been adopted by the construction community to avoid project cost overruns while simultaneously improving value. TVD implementation involves a number of practices: clearly identify owner value, develop an inclusive interdisciplinary team organization, provide appropriate financial and contractual incentives, create a culture of respect, and steer to cost and value targets with TVD tools. While application of TVD has grown, not all results are as favourable as they might be. It is possible that TVD application may be piecemeal at times—potentially because the impacts of individual practices are unknown. This paper explores a fundamental research question: how consistent or inconsistent is the application of TVD principles, practices, and tools? To address this question, the authors reviewed 29 academic publications on TVD, surveyed 14 TVD practitioners through an anonymous on-line survey, and hosted two open-ended focus groups with 6 TVD facilitators. Results indicate that some—but not all—TVD practices are consistently being implemented, which may suggest one cause for observed variability of outcomes. Journal: Construction Management and Economics Pages: 598-617 Issue: 7-8 Volume: 40 Year: 2022 Month: 8 X-DOI: 10.1080/01446193.2022.2037146 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2037146 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:7-8:p:598-617 Template-Type: ReDIF-Article 1.0 Author-Name: The Editors Title: To trust or not to trust: is trust a prerequisite for solving design quality problems? Journal: Construction Management and Economics Pages: 653-653 Issue: 7-8 Volume: 40 Year: 2022 Month: 8 X-DOI: 10.1080/01446193.2022.2076392 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2076392 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:7-8:p:653-653 Template-Type: ReDIF-Article 1.0 Author-Name: Lauri Koskela Author-X-Name-First: Lauri Author-X-Name-Last: Koskela Author-Name: Iris D. Tommelein Author-X-Name-First: Iris D. Author-X-Name-Last: Tommelein Author-Name: Carlos T. Formoso Author-X-Name-First: Carlos T. Author-X-Name-Last: Formoso Author-Name: Rafael Sacks Author-X-Name-First: Rafael Author-X-Name-Last: Sacks Title: Festschrift honouring Dr. Glenn Ballard Journal: Construction Management and Economics Pages: 497-506 Issue: 7-8 Volume: 40 Year: 2022 Month: 8 X-DOI: 10.1080/01446193.2022.2076391 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2076391 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:7-8:p:497-506 Template-Type: ReDIF-Article 1.0 Author-Name: Ergo Pikas Author-X-Name-First: Ergo Author-X-Name-Last: Pikas Author-Name: Lauri Koskela Author-X-Name-First: Lauri Author-X-Name-Last: Koskela Author-Name: Olli Seppänen Author-X-Name-First: Olli Author-X-Name-Last: Seppänen Title: Causality and interpretation: a new design model inspired by the Aristotelian legacy Abstract: Building design and design management practices are beset by many problems to which satisfactory solutions have not yet emerged. The recognition of the Aristotelian legacy on design theorization has given rise to the proposition that the development of a new design concept that integrates the technical and social aspects of design might provide a general solution. This study aims to chart the intellectual history of the design discipline, clarify core design terms, concepts, and relationships, and propose a design model that integrates technical and social phenomena. An integrative literature review is a basis for the assessment and synthesis of representative literature and the construction of the new design model. The new design model, presenting the integrated design process structure for technical and social design activities, is the main contribution of this study. The model was constructed based on the identification of design theory core elements and relationships and the ancient design theories (the method of analysis and rhetoric). Journal: Construction Management and Economics Pages: 507-525 Issue: 7-8 Volume: 40 Year: 2022 Month: 8 X-DOI: 10.1080/01446193.2021.1934884 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1934884 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:7-8:p:507-525 Template-Type: ReDIF-Article 1.0 Author-Name: Nuno Gil Author-X-Name-First: Nuno Author-X-Name-Last: Gil Title: Megaprojects: a meandering journey towards a theory of purpose, value creation and value distribution Abstract: This paper departs from a reflection of how my time as a doctoral student in the late nineties with the lean construction group at U.C. Berkeley influenced my (ongoing) research journey. I first recall how those early years led to my core empirical and theoretical interests on the management of ‘megaprojects’ - the project-based, multi-party contexts that are set up by one or more organisational actors with the aim of developing capital-intensive, long-lived infrastructure resources. I also analyse the challenges that I faced in the pursuit of a theoretical perspective with power to predict and explain empirical regularities on megaproject behaviour, and thus capable of illuminating the pervasiveness of major cost and schedule slippages as well as scope creep. As well as this, I discuss how the discovery of Elinor Ostrom’s commons governance theory was a watershed in my research journey. Then, drawing from organisational governance literature, I introduce and illustrate a model of the evolution of the governance structure of a megaproject over the project life cycle. I harness this model to draw inferences on megaproject organisational boundaries, on megaproject behaviour, and on how megaprojects create both economic and social value. Further, after conceptualising a megaproject as a purposeful interorganizational form of organising capital production, I discuss feedback loops and contingency variables that affect the gap between intended and realised project behaviour. I conclude with a discussion on how to leverage an organisational perspective of megaprojects to realise the potential of capital investment in new infrastructure to create value, as well as to engender trust in megaprojects, and thus mend their fractured relationship with society.Each era’s theories and prevailing arguments, in part, reflect the preoccupations of the times and coevolve with them1 Journal: Construction Management and Economics Pages: 562-584 Issue: 7-8 Volume: 40 Year: 2022 Month: 8 X-DOI: 10.1080/01446193.2021.1946832 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1946832 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:7-8:p:562-584 Template-Type: ReDIF-Article 1.0 Author-Name: Cecilia Gravina da Rocha Author-X-Name-First: Cecilia Author-X-Name-Last: Gravina da Rocha Author-Name: Samuel Korb Author-X-Name-First: Samuel Author-X-Name-Last: Korb Author-Name: Rafael Sacks Author-X-Name-First: Rafael Author-X-Name-Last: Sacks Title: Work structuring and product design for customized repetitive projects Abstract: Ballard’s concept of work structuring for production planning in construction can be applied to improve production flow in construction projects formed by repetitive units with extensive customization. Customization can increase the value of repetitive units (apartments in a building, houses in an allotment, or stores in a shopping mall) forming a project, by meeting clients’ specific requirements. However, in traditional construction production systems, it commonly causes delays, stoppages, rework, increased amounts of work in progress, and excessive movement of crews and materials. The problem has been thoroughly documented and various production systems have been designed to address the trade-off between flow and value. We identify five such systems, which were originally developed following exploratory design science principles. In this work, we analyse and compare them using nine metrics to assess their performance in terms of flow and value, and to explore the role of work structuring in customized projects. The systems with the most effective flow are the Fit-Out Company and the Ecosystem Platform systems. The analysis led to the theoretical proposition of a hybrid production system called Product/Process Modularization, which may be applied and tested in the future. Journal: Construction Management and Economics Pages: 526-547 Issue: 7-8 Volume: 40 Year: 2022 Month: 8 X-DOI: 10.1080/01446193.2021.1936100 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1936100 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:7-8:p:526-547 Template-Type: ReDIF-Article 1.0 Author-Name: Jardar Lohne Author-X-Name-First: Jardar Author-X-Name-Last: Lohne Author-Name: Olav Torp Author-X-Name-First: Olav Author-X-Name-Last: Torp Author-Name: Bjørn Andersen Author-X-Name-First: Bjørn Author-X-Name-Last: Andersen Author-Name: Sigmund Aslesen Author-X-Name-First: Sigmund Author-X-Name-Last: Aslesen Author-Name: Lena Bygballe Author-X-Name-First: Lena Author-X-Name-Last: Bygballe Author-Name: Trond Bølviken Author-X-Name-First: Trond Author-X-Name-Last: Bølviken Author-Name: Frode Drevland Author-X-Name-First: Frode Author-X-Name-Last: Drevland Author-Name: Atle Engebø Author-X-Name-First: Atle Author-X-Name-Last: Engebø Author-Name: Roar Fosse Author-X-Name-First: Roar Author-X-Name-Last: Fosse Author-Name: Hans Thomas Holm Author-X-Name-First: Hans Thomas Author-X-Name-Last: Holm Author-Name: Lars Kristian Hunn Author-X-Name-First: Lars Kristian Author-X-Name-Last: Hunn Author-Name: Bo Terje Kalsaas Author-X-Name-First: Bo Terje Author-X-Name-Last: Kalsaas Author-Name: Ole Jonny Klakegg Author-X-Name-First: Ole Jonny Author-X-Name-Last: Klakegg Author-Name: Vegard Knotten Author-X-Name-First: Vegard Author-X-Name-Last: Knotten Author-Name: Kai Haakon Kristensen Author-X-Name-First: Kai Haakon Author-X-Name-Last: Kristensen Author-Name: Nils Olof Emanuel Olsson Author-X-Name-First: Nils Olof Emanuel Author-X-Name-Last: Olsson Author-Name: Asbjørn Rolstadås Author-X-Name-First: Asbjørn Author-X-Name-Last: Rolstadås Author-Name: John Skaar Author-X-Name-First: John Author-X-Name-Last: Skaar Author-Name: Fredrik Svalestuen Author-X-Name-First: Fredrik Author-X-Name-Last: Svalestuen Author-Name: Hajnalka Vaagen Author-X-Name-First: Hajnalka Author-X-Name-Last: Vaagen Author-Name: Paulos Wondimu Author-X-Name-First: Paulos Author-X-Name-Last: Wondimu Author-Name: Ola Laedre Author-X-Name-First: Ola Author-X-Name-Last: Laedre Title: The emergence of lean construction in the Norwegian AEC industry Abstract: Lean construction has inspired the AEC industry globally over the last decades, and this manifests within a wide array of contexts. The purpose of this paper is to provide a narrative-based qualitative analysis of the emergence and impact of Lean construction on a national level, notably in the Norwegian AEC industry. The analysis is based on the concept of paradigm shift and on empirical knowledge in the form of narratives. The narratives of practitioners and researchers provide deep insights into how Lean Construction has inspired the Norwegian AEC industry and academia, respectively. The reflections indicate that the introduction of the Lean construction principles and tools in the Norwegian AEC industry has depended on promoters who have been convinced about its advantages. The role of active promoters – in particular Dr. Glenn Ballard – is underlined as key to successful introduction of Lean Construction. Key cultural features of the Norwegian AEC industry are emphasized as important success factors. Lean Construction in Norway needs to be understood as a phenomenon occurring within a setting that is generally advantageous but also following an effort carried out on several levels. Key elements that can be used within other contexts are (1) the existence of promoters, (2) cooperation between industry and academic circles, (3) a high degree of trust and (4) a predominance of bottom-up organizations within the industry with few levels of hierarchy. Journal: Construction Management and Economics Pages: 585-597 Issue: 7-8 Volume: 40 Year: 2022 Month: 8 X-DOI: 10.1080/01446193.2021.1975041 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1975041 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:7-8:p:585-597 Template-Type: ReDIF-Article 1.0 Author-Name: Jan A. Elfving Author-X-Name-First: Jan A. Author-X-Name-Last: Elfving Title: A decade of lessons learned: deployment of lean at a large general contractor Abstract: The purpose of this paper is to describe lean experiments from a period that lasted over a decade. The aim is to provide insights for both industry practitioners and academics concerning what worked and what did not work and to discuss barriers to avoid when taking academic concepts to industry. What makes this paper unique is that we are following the developments inside one company, Skanska Finland, uninterrupted for over a decade. Dr Glenn Ballard was closely involved in the developments and deployments throughout the journey. The paper confirms earlier findings of managing variability prior to other process improvements. At the same time, it is important to understand the minimum organisational level needed when developing and deploying lean methods. During our journey, the most successful deployment was the Last Planner System®; it has been both robust against market turns but also it has been possible to deploy it project-by-project. Thus, there is no need to wait until the whole company or a large part of it has understood the concept before deployment can start. Supplier development requires a wider scope than just a single project or the duration of a project for successful deployment. The weak or less sustainable deployment of logistics solutions in the construction industry may be because it requires industry-level technology standardisation and data platforms. Journal: Construction Management and Economics Pages: 548-561 Issue: 7-8 Volume: 40 Year: 2022 Month: 8 X-DOI: 10.1080/01446193.2021.1938161 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1938161 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:7-8:p:548-561 Template-Type: ReDIF-Article 1.0 Author-Name: Chuanni He Author-X-Name-First: Chuanni Author-X-Name-Last: He Author-Name: Min Liu Author-X-Name-First: Min Author-X-Name-Last: Liu Author-Name: Thais da C. L. Alves Author-X-Name-First: Thais da C. L. Author-X-Name-Last: Alves Author-Name: Natalie M. Scala Author-X-Name-First: Natalie M. Author-X-Name-Last: Scala Author-Name: Simon M. Hsiang Author-X-Name-First: Simon M. Author-X-Name-Last: Hsiang Title: Prioritizing collaborative scheduling practices based on their impact on project performance Abstract: Collaborative scheduling (CS) and related practices impact the performance of construction projects which can be measured by key performance indicators (KPIs). However, little is known about which of these practices are implemented and how their combined implementation might impact KPIs. The objectives of this research are to identify perceptions of CS practices that drive project performance, define CS practices used by industry that impact KPIs, and establish practices that are more commonly implemented and have a higher potential to positively impact KPIs. The research team conducted a nationwide survey in the United States and obtained 241 usable responses. Utilizing an information theory approach to measure the uncertainty of implementation and impact of each practice, the research built a set of Chow–Liu tree models to determine the most efficient sequence of actions to improve CS. Results indicate that meeting owners’ expectation throughout the life-cycle of the project from design through construction and commissioning, using the schedule to support a strong project culture, and an effective communication plan were the top CS levers for overall KPI improvement. An innovative method was developed to help construction project managers discover the value of each CS practice, the relation between CS practices, and CS practices’ influence to project KPIs so that managers can improve KPIs efficiently by prioritizing their CS practices according to their own project needs. Journal: Construction Management and Economics Pages: 618-637 Issue: 7-8 Volume: 40 Year: 2022 Month: 8 X-DOI: 10.1080/01446193.2022.2048042 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2048042 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:7-8:p:618-637 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2085313_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220804T044749 git hash: 24b08f8188 Author-Name: Beibei Qin Author-X-Name-First: Beibei Author-X-Name-Last: Qin Author-Name: Stuart D. Green Author-X-Name-First: Stuart D. Author-X-Name-Last: Green Title: The micro-practices of project organizing in the Chinese construction sector: a sensemaking perspective Abstract: The organization of construction in the People’s Republic of China has over recent decades undergone radical restructuring. The announcement of Deng Xiaoping’s Open Door strategy in 1978 marked the beginning of the transition towards the espoused socialist market economy and the progressive introduction of market mechanisms. Existing research tends to focus on the derivation of “critical success factors” rather than the lived realities of those directly involved. In contrast, the current paper adopts a sensemaking perspective that privileges the transient roles and identities of those involved in the micro-processes of project organizing. The empirical focus lies on the sensemaking narratives of middle managers within three state-owned construction enterprises in the Chongqing city region. The findings illustrate how market mechanisms such as bidding and tendering play out in complex ways involving hybrid arrangements between new and pre-existing ways of working. The terminology of project management is seen to have played a performative role in establishing the “project” as the essential unit around which the socialist market is organized. Middle managers are further found to maintain multiple identities in response to the experienced paradoxes of the socialist market economy. The research provides new insights into the micro-processes of project organizing in China with broader implications for transitional economies elsewhere. Journal: Construction Management and Economics Pages: 655-675 Issue: 9 Volume: 40 Year: 2022 Month: 9 X-DOI: 10.1080/01446193.2022.2085313 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2085313 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:9:p:655-675 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2099561_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220804T044749 git hash: 24b08f8188 Author-Name: Nannan Wang Author-X-Name-First: Nannan Author-X-Name-Last: Wang Author-Name: Hongmei Wang Author-X-Name-First: Hongmei Author-X-Name-Last: Wang Author-Name: Kui Zhang Author-X-Name-First: Kui Author-X-Name-Last: Zhang Title: The dynamics of changes in PPP projects – a meta-case analysis approach Abstract: Changes in public-private partnership (PPP) projects are inevitable and often lead to project failure, hence, the management of changes in PPP projects are more challenging than with traditional projects. The complex nature of changes in PPP projects, however, lacks systematic investigation and a quantitative approach in current literature. To fill this gap, this study considers the development process of major changes in PPP projects from a whole-life cycle perspective. The findings reveal significant relationships between causes and negative change results, as well as the enlarged interactive effects of certain causes. Most of the negative changes occur at the operational stage and vary across different types of project and regions, but the pre-contract stage is the most critical stage to prevent future negative changes. Hence, more proactive change management strategies are suggested for the government decision makers and project managers. This study contributes to the body of knowledge in PPP literature by providing a meta-case analysis approach, which can improve the accuracy of case selection and facilitate statistical analysis. The findings can help the researchers and practitioners to better understand the nature of changes and manage them in a more efficient way. Journal: Construction Management and Economics Pages: 727-742 Issue: 9 Volume: 40 Year: 2022 Month: 9 X-DOI: 10.1080/01446193.2022.2099561 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2099561 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:9:p:727-742 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2098990_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220804T044749 git hash: 24b08f8188 Author-Name: Petter Haglund Author-X-Name-First: Petter Author-X-Name-Last: Haglund Author-Name: Martin Rudberg Author-X-Name-First: Martin Author-X-Name-Last: Rudberg Author-Name: Ahmet Anil Sezer Author-X-Name-First: Ahmet Anil Author-X-Name-Last: Sezer Title: Organizing logistics to achieve strategic fit in building contractors: a configurations approach Abstract: Previous research indicates that the success of logistics solutions in building projects depends on how they are organized in accordance with the logistics context, which is determined by building contractors’ competitive priorities, product characteristics, and production process choices. Taking a configurations approach, the purpose of this paper is to describe the fit between the logistics context and the organizing of logistics at a strategic level. A conceptual research framework is derived from literature postulating an influence of the logistics context on the organizing of logistics. The framework is applied to four cases by the means of strategic profiling, which provides a snapshot of the fit in the cases’ logistics configurations. The findings indicate that the type of production process influences the degree to which logistics decisions should be made centrally and that the degree of standardization and pre-engineering influence the degree to which logistics processes should be formalized. The main contributions are the identification of logistics configuration variables and the description of the fit between building contractors’ logistics context and the organizing of logistics. For managerial practice, a logistics configuration profiling template was developed that can be used as a tool in the logistic strategy process. Journal: Construction Management and Economics Pages: 711-726 Issue: 9 Volume: 40 Year: 2022 Month: 9 X-DOI: 10.1080/01446193.2022.2098990 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2098990 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:9:p:711-726 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2094434_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220804T044749 git hash: 24b08f8188 Author-Name: Juan Francisco Azcarate-Aguerre Author-X-Name-First: Juan Francisco Author-X-Name-Last: Azcarate-Aguerre Author-Name: Mira Conci Author-X-Name-First: Mira Author-X-Name-Last: Conci Author-Name: Markus Zils Author-X-Name-First: Markus Author-X-Name-Last: Zils Author-Name: Peter Hopkinson Author-X-Name-First: Peter Author-X-Name-Last: Hopkinson Author-Name: Tillmann Klein Author-X-Name-First: Tillmann Author-X-Name-Last: Klein Title: Building energy retrofit-as-a-service: a Total Value of Ownership assessment methodology to support whole life-cycle building circularity and decarbonisation Abstract: The regulatory drive to accelerate the clean energy and circular economy transitions in the European building stock is currently failing to overcome systemic implementation barriers. These barriers include high initial investment costs, misaligned financial incentives among stakeholders, and the relatively low cost of less sustainable energy and materials. A Product-Service Systems (PSS) approach could successfully overcome many of these barriers by (1) outsourcing capital investment, as well as financial and technical risks, (2) providing shared economic incentives to collaborating stakeholders, and (3) retaining extended producer responsibility and ownership over materials and products. However, PSS is still not seen as a viable business model when compared to both a standard “ownership” contract and a “no-retrofit” scenario. This paper proposes a Total Value of Ownership (TVO) method to evaluate the financial performance of a building energy retrofit in terms of Net Present Value, comparing a matrix of scenarios. Results show that – when accounting for capital and opportunity costs tied to alternative investments, internalising externalities, and monetising soft values such as user productivity and property value – a PSS model can deliver the highest NPV. Furthermore, results show that a PSS alternative can act as a positive future-proofing strategy to safeguard the building owner’s position in the face of uncertain future market indicators and carbon taxation. Recommendations for policymakers, investors, financiers, building owners, and end-users are presented to identify the economic value of PSS contracts, leading to better-informed decisions which can accelerate deep energy retrofit of the building stock. Journal: Construction Management and Economics Pages: 676-689 Issue: 9 Volume: 40 Year: 2022 Month: 9 X-DOI: 10.1080/01446193.2022.2094434 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2094434 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:9:p:676-689 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2098508_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220804T044749 git hash: 24b08f8188 Author-Name: Firehiwot Kedir Author-X-Name-First: Firehiwot Author-X-Name-Last: Kedir Author-Name: Qian Chen Author-X-Name-First: Qian Author-X-Name-Last: Chen Author-Name: Daniel M. Hall Author-X-Name-First: Daniel M. Author-X-Name-Last: Hall Author-Name: Bryan T. Adey Author-X-Name-First: Bryan T. Author-X-Name-Last: Adey Author-Name: Richard Boyd Author-X-Name-First: Richard Author-X-Name-Last: Boyd Title: Formative scenario analysis of the factors influencing the adoption of industrialised construction in countries with high housing demand – the cases of Ethiopia, Kenya, and South Africa Abstract: The use of industrialised construction can help meet the growing housing demand for developing economies in Africa. In order to understand future scenarios for accelerated adoption of industrialised construction, it is necessary to identify the influencing factors. To do so, this paper conducts a formative scenario analysis which is a literature- and expert-based method, focussing on three countries that have high housing demands, i.e. Ethiopia, Kenya, and South Africa. The resulting analysis consists of three parts. The first is the identification of nineteen internal and external influencing factors. These factors range from product performance to policies and regulations. The second is the illustration of the importance of each factor as a function of its relationship with the other factors. The third is the description of three possible scenarios the adoption of industrialised construction may take in the three investigated countries. The findings show that the most important accelerators for the adoption of industrialised construction come from governments’ commitment to invest in future construction and incentivize companies to adopt industrial construction methods and for these companies to produce competitive products. The specific adoption policies to be implemented, however, depend greatly on the specific situation. Journal: Construction Management and Economics Pages: 690-710 Issue: 9 Volume: 40 Year: 2022 Month: 9 X-DOI: 10.1080/01446193.2022.2098508 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2098508 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:9:p:690-710 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2110273_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Duy Tan Nguyen Author-X-Name-First: Duy Tan Author-X-Name-Last: Nguyen Author-Name: Phuoc Luong Le Author-X-Name-First: Phuoc Luong Author-X-Name-Last: Le Title: Twenty-year application of logistics and supply chain management in the construction industry Abstract: The last decades have seen a growing interest in construction management amongst scholars, particularly, in how to apply supply chain management (SCM) strategies to improve logistics efficiency and project performance. Nevertheless, there is a lack of systematic literature reviews (SLRs) which integrate multiple quantitative methods to synthesise the literature on construction logistics and supply chain management (CLSCM) and analyse their trends during the last two decades. In this work, we concurrently deploy the rigorous six-step SLR protocol together with co-citation analysis, factor analysis, multidimensional scaling-based fuzzy k-means clustering, and keyword extraction and co-occurrence analysis to ascertain and examine clusters of CLSCM application. The results show that there are six established research clusters in CLSCM, namely, logistics and SCM for prefabricated construction, construction procurement, construction supply chain integration, green construction SCM, reverse logistics in construction and onsite construction logistics. Amongst these clusters, construction supply chain integration plays the most integral role. Informed by this ascertained knowledge structure, we explore the research trends during the period reviewed, propose a conceptual framework for CLSCM and suggest research avenues. Journal: Construction Management and Economics Pages: 796-834 Issue: 10 Volume: 40 Year: 2022 Month: 10 X-DOI: 10.1080/01446193.2022.2110273 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2110273 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:10:p:796-834 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2110602_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Jessica Borg Author-X-Name-First: Jessica Author-X-Name-Last: Borg Author-Name: Christina M. Scott-Young Author-X-Name-First: Christina M. Author-X-Name-Last: Scott-Young Title: Contributing factors to turnover intentions of early career project management professionals in construction Abstract: The construction industry is facing global skills shortages, with demand for certain roles (such as project managers) projected to outstrip supply over the next decade. With the industry serving as the backbone of the economy in many countries, this projected lack of skilled construction professionals poses dire consequences. This qualitative study investigated the early career transition of project management (PM) professionals into the construction industry. Semi-structured interviews were conducted with 18 employer representatives and 20 early career professionals to ascertain the factors affecting the turnover intentions of early career PM professionals in construction. From the perspective of the early participants in this study, the major factors affecting their intentions to leave were related to workplace culture: (i) bad workplace behaviour; (ii) high levels of work-related stress; and (iii) poor work-life balance. While employers also noted that bullying and long working hours contributed to early career PM professionals’ intentions to leave the industry, they believed that the key contributing factor was that young employees were seeking higher salaries. These findings on the need to improve workplace culture have the potential to positively influence the issue of early career retention within the construction industry. Journal: Construction Management and Economics Pages: 835-853 Issue: 10 Volume: 40 Year: 2022 Month: 10 X-DOI: 10.1080/01446193.2022.2110602 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2110602 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:10:p:835-853 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2108863_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Suhair Alkilani Author-X-Name-First: Suhair Author-X-Name-Last: Alkilani Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: Project performance measurement for small-and-medium sized construction contractors in the Jordanian construction industry Abstract: This article addresses a gap in construction project performance measurement research from the perspective of small-medium-sized construction contractors in developing countries. Focussing on small-medium-sized contractors in the Jordanian construction industry, a survey of 231 Jordanian construction professionals was undertaken to investigate how different project stakeholders, intra and extra-organisational relationships and financial and non-financial measures support or hinder the delivery of project outcomes. Using exploratory factor analysis (EFA), confirmatory factor analysis (CFA) and Partial Least Squares Structural Equation Modelling (PLS-SEM) an integrated theoretical performance measurement model was developed and tested which contributes to the advancement of construction project performance measurement research in a number of ways. First, it shows that small-medium-sized contractor project performance is a multi-dimensional, dynamic and contested construct which is bounded by environmental and organisational constraints, and inseparable from mainstream business performance. Second, it shows that performance is measured by six project-related constructs (project cost, time, quality, health and safety, environmental sustainability, and socio-economic performance) and three business-related constructs (profitability, client satisfaction and consultant satisfaction). Third, it shows that four intra-organisational groups of variables (leadership, management capabilities, human resource management and technical capabilities, resources and processes) have a significant impact on the overall project and business performance. Fourth, it shows that four extra-organisational groups of variables (client performance, consultant performance, supplier performance and external attributes) have a significant direct impact on project performance, but no moderating impact was found. Journal: Construction Management and Economics Pages: 743-769 Issue: 10 Volume: 40 Year: 2022 Month: 10 X-DOI: 10.1080/01446193.2022.2108863 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2108863 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:10:p:743-769 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2109699_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Viet-Ngu Hoang Author-X-Name-First: Viet-Ngu Author-X-Name-Last: Hoang Author-Name: Joko Purnomo Raharjo Author-X-Name-First: Joko Purnomo Author-X-Name-Last: Raharjo Author-Name: Connie Susilawati Author-X-Name-First: Connie Author-X-Name-Last: Susilawati Title: Meta-frontier efficiency analysis of real estate and construction firms in Indonesia Abstract: Improving the productive efficiency (also called technical efficiency) of real estate and construction firms (RECFs) is essential to tackle the sustained shortage of housing supply and the increasing unaffordability of housing in developing countries. However, there are few studies that focus on this issue in the context of developing countries; and available literature focuses mainly on firms listed on stock markets. Our study employs the meta-frontier framework to measure the efficiency of 832 small, medium, and large RECFs across Indonesia from 2012 to 2016, using a data envelopment analysis technique. The meta-frontier framework allows for different production technologies and different business environments operated by firms of different sizes. Under the specification of group-specific production frontiers, large firms obtain the highest average efficiency scores (0.694), followed by medium firms (0.529), and small firms (0.479). The technology gaps between the meta-frontier and the group-frontiers for small and medium firms are relatively large, suggesting that the overall industry would be able to achieve remarkable efficiency improvement if firms could access technologies used by more efficient firms. Our results also show that determinants of the efficiency vary across firm groups, suggesting that policy and managerial interventions tailored to each group would have more impact on the overall productive efficiency of the entire industry. Journal: Construction Management and Economics Pages: 770-780 Issue: 10 Volume: 40 Year: 2022 Month: 10 X-DOI: 10.1080/01446193.2022.2109699 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2109699 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:10:p:770-780 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2110272_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Conghan Wang Author-X-Name-First: Conghan Author-X-Name-Last: Wang Author-Name: Shuibo Zhang Author-X-Name-First: Shuibo Author-X-Name-Last: Zhang Author-Name: Ying Gao Author-X-Name-First: Ying Author-X-Name-Last: Gao Author-Name: Bo Li Author-X-Name-First: Bo Author-X-Name-Last: Li Title: Trust repair in the aftermath of conflict occurrence in construction subcontracting: an intergroup contact perspective Abstract: Although trust repair after conflict occurrence is significant for effective work and sustainable relationships in construction subcontracting and contact is inevitable, researchers have yet to examine the relationship between contact quality and trust repair after conflict occurrence. This study investigates the effect of contact quality on Party A’s trust repair after conflict occurrence and the mediating mechanisms of that effect. The authors conducted a questionnaire survey to collect data for hypotheses testing, receiving 310 valid questionnaires from general contractors and subcontractors engaged in construction projects. The results reveal the positive effect of contact quality on Party A’s trust repair after conflict occurrence and the mediating roles of Party A’s feeling of threat and Party B’s self-disclosure in that effect. This study contributes to the trust research and intergroup contact theory. It also offers suggestions for construction subcontracting practitioners to facilitate trust repair after conflict occurrence. Journal: Construction Management and Economics Pages: 781-795 Issue: 10 Volume: 40 Year: 2022 Month: 10 X-DOI: 10.1080/01446193.2022.2110272 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2110272 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:10:p:781-795 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_1983187_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Kell Jones Author-X-Name-First: Kell Author-X-Name-Last: Jones Author-Name: Luigi Mosca Author-X-Name-First: Luigi Author-X-Name-Last: Mosca Author-Name: Jennifer Whyte Author-X-Name-First: Jennifer Author-X-Name-Last: Whyte Author-Name: Andrew Davies Author-X-Name-First: Andrew Author-X-Name-Last: Davies Author-Name: Jacqueline Glass Author-X-Name-First: Jacqueline Author-X-Name-Last: Glass Title: Addressing specialization and fragmentation: product platform development in construction consultancy firms Abstract: Construction product platforms provide the opportunity to improve productivity in construction projects while maintaining heterogeneity of output. The growing literature on construction product platforms describes how product suppliers develop product platforms either top-down or bottom-up, independently from project delivery. Through a single case study of a consultancy firm, this paper shows how a specialist consultancy firm operating in the construction sector developed their own product platform on projects while iteratively developing and augmenting their delivery capabilities. Distinguishing between activity integration, coordination, and consolidation, the platform development process highlights how vertical and horizontal consolidation of capabilities within the engineering phase of delivery enables early resolution of both product and process specifications. This means that vertical coordination between engineering and manufacturing phases can be managed by a fully specified contract, rather than acquisition. The analysis of the case shows how construction can be more closely aligned with the linear and sequential models found in manufacturing through clarifying and distinguishing the roles of engineering, manufacturing, finishing and sub-assembly. Journal: Construction Management and Economics Pages: 918-933 Issue: 11-12 Volume: 40 Year: 2022 Month: 12 X-DOI: 10.1080/01446193.2021.1983187 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1983187 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:11-12:p:918-933 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2153501_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: The Editors Title: List of Reviewers for Construction Management and Economics 2022 Journal: Construction Management and Economics Pages: i-iii Issue: 11-12 Volume: 40 Year: 2022 Month: 12 X-DOI: 10.1080/01446193.2022.2153501 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2153501 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:11-12:p:i-iii Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2154040_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Paul W. Chan Author-X-Name-First: Paul W. Author-X-Name-Last: Chan Title: Reflections from the Editor-in-Chief: confronting emerging challenges with important and interesting research in Construction Management and Economics Journal: Construction Management and Economics Pages: 1003-1005 Issue: 11-12 Volume: 40 Year: 2022 Month: 12 X-DOI: 10.1080/01446193.2022.2154040 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2154040 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:11-12:p:1003-1005 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2108093_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Lilly Rosander Author-X-Name-First: Lilly Author-X-Name-Last: Rosander Title: Same same but different: dynamics of a pre-procurement routine and its influence on relational contracting models Abstract: To improve the performance of construction projects, the use of relational contracting (e.g. Project Partnering, Alliancing, Early Contractor Involvement, Integrated Project Delivery) has increased among public clients in the last few decades. Despite widespread use, there are still large variations in contracting arrangements. In addition, the outcome of relational contracting remains unpredictable. The aim of this paper is to investigate how these variations may originate from internal dynamics and practices in the project-based client organisation. Adapting organisational routines as an analytical lens, the study investigates the pre-procurement routine applied to develop project-specific relational contracting models (e.g. contract schemes, reward systems, and award criteria) for large construction projects in the Swedish Transport Administration. The study contributes to research on organisational routines in project-based settings, illustrating how flexible enactment of a pre-procurement routine may balance two conflicting organisational goals: centralisation of procurement and project-level flexibility. However, while mitigating conflicting goals, the routine enactments create a variation in project-specific procurement models that hampers long-term goals of predictability and shared practices of relational contracting. Consequently, findings indicate that public clients seeking to transform contracting practices must increase their ability to develop procurement routines that can balance organisational goals and simultaneously benefit long-term goals. Journal: Construction Management and Economics Pages: 955-972 Issue: 11-12 Volume: 40 Year: 2022 Month: 12 X-DOI: 10.1080/01446193.2022.2108093 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2108093 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:11-12:p:955-972 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2037144_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Johan Ninan Author-X-Name-First: Johan Author-X-Name-Last: Ninan Author-Name: Natalya Sergeeva Author-X-Name-First: Natalya Author-X-Name-Last: Sergeeva Author-Name: Graham Winch Author-X-Name-First: Graham Author-X-Name-Last: Winch Title: Narrative shapes innovation: a study on multiple innovations in the UK construction industry Abstract: The nature of the construction industry is different from other sectors due to the unique and temporary nature of projects which makes incremental improvements difficult necessitating the need to understand the practice of innovation. This research aims to explore the role of narratives in shaping innovation, as these provide a way to manage the tensions prevalent in the industry. We study 133 innovations across different construction projects in the UK and seek to understand the role of narratives in motivating these innovations. For instance, “innovations that enable project completion,” “innovations that improve productivity,” “innovations in health and safety” and “innovations in sustainability” are discussed. Whilst we acknowledge that factors such as incentives and rewards can motivate innovation, we argue that narratives shape or guide innovation in a particular direction. Since construction projects are interorganizational and multileveled, the industry-level narratives need to be adopted by firms to enable innovations at project sites. Innovators actively look for areas where they can intervene, and narratives improve the visibility of some areas thereby guiding innovations to them. Journal: Construction Management and Economics Pages: 884-902 Issue: 11-12 Volume: 40 Year: 2022 Month: 12 X-DOI: 10.1080/01446193.2022.2037144 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2037144 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:11-12:p:884-902 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2015795_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Brian Andreas Author-X-Name-First: Brian Author-X-Name-Last: Andreas Author-Name: Scott Fernie Author-X-Name-First: Scott Author-X-Name-Last: Fernie Author-Name: Andrew Dainty Author-X-Name-First: Andrew Author-X-Name-Last: Dainty Title: Understanding policy and change: using a political economy analysis framework Abstract: The gap between the intent and the impact of policy for construction in the UK has been well established both in academic literature and in public discourse, contributing to repeated calls for transformation of the industry. The apparent failure of policy was investigated, taking policy at sector level as the unit of analysis. The objective was to both generate insight into the policy process and to establish a theoretical framework. Anticipating that the use of language, and the conflicting meanings attached to it by individual actors, is critical, an interpretive, abductive, research design was adopted. Twenty semi-structured interviews were carried out with a cross-section of industry actors. Methods of political economy analysis, used in other contexts, were adopted as the starting point for abduction. Analysis revealed flawed assumptions amongst stakeholders regarding the extent of the agency of central government in implementing change across such a heterogeneous and loosely coupled sector. Political economy analysis shows the impact of structural and institutional features on the sector in a systemic and holistic way, providing a template and visual model which supports collaborative and reflexive working, and forming a foundation for further research into policy for construction both in the UK and elsewhere. Journal: Construction Management and Economics Pages: 865-883 Issue: 11-12 Volume: 40 Year: 2022 Month: 12 X-DOI: 10.1080/01446193.2021.2015795 File-URL: http://hdl.handle.net/10.1080/01446193.2021.2015795 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:11-12:p:865-883 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_1980896_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Oscar Lundberg Author-X-Name-First: Oscar Author-X-Name-Last: Lundberg Author-Name: Daniel Nylén Author-X-Name-First: Daniel Author-X-Name-Last: Nylén Author-Name: Johan Sandberg Author-X-Name-First: Johan Author-X-Name-Last: Sandberg Title: Unpacking construction site digitalization: the role of incongruence and inconsistency in technological frames Abstract: Construction site operations often involve multiple actors with substantial variations in assumptions, expectations, and knowledge about technology. This could impair digitalization, which involves development of socio-cognitive environments that foster use of digital technology in new organizational procedures. Nevertheless, construction industry digitalization research has mainly addressed firm-level transformation of engineering phases and focused on technology, largely ignoring challenges arising from cognitive differences among actors at construction sites. Thus, we report a case study of attempts to spark construction site digitalization through a shared information management system (IMS). Applying technology frame of reference theory, we demonstrate how differences within groups among actors’ frames (inconsistency) shape group-level frame misalignment (incongruence) and thus digitalization outcomes. The IMS was implemented successfully at the focal firm’s headquarter and regional office levels. However, substantial construction site-level frame inconsistency led to misaligned group-level expectations and generated a fragmented socio-cognitive environment that hindered strategic digitalization. In conclusion, socio-cognitive environments at industry, construction site, and group levels recursively shape individual frames, and harmonization of frames is important to realize construction digitalization. Journal: Construction Management and Economics Pages: 987-1002 Issue: 11-12 Volume: 40 Year: 2022 Month: 12 X-DOI: 10.1080/01446193.2021.1980896 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1980896 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:11-12:p:987-1002 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2037145_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Asta Salmi Author-X-Name-First: Asta Author-X-Name-Last: Salmi Author-Name: Jaakko Jussila Author-X-Name-First: Jaakko Author-X-Name-Last: Jussila Author-Name: Mervi Hämäläinen Author-X-Name-First: Mervi Author-X-Name-Last: Hämäläinen Title: The role of municipalities in transformation towards more sustainable construction: the case of wood construction in Finland Abstract: Transformation towards more sustainable construction calls for actions from representatives of different sectors and societal levels. Previous studies have investigated companies and national policies as promoters of change, but neglected municipalities as relevant actors. Municipalities influence construction as they are trailblazers when realizing their own building projects, as well as regulators, whose planning decisions affect local and urban development. We investigate the role of municipalities in driving sustainability transformation in construction, in particular, in relation to wood construction. The empirical study relies on data collected in Finland through a comprehensive survey among municipalities and qualitative interviews. Key factors in municipal considerations are energy efficiency and carbon neutrality goals. Regulations and norms related to construction influence municipal activities as well. We find various drivers (e.g. supportive planning) and barriers (e.g. cost concerns) to wood construction. National programmes promoting wood construction have induced gradual changes and led to some municipal pilot projects. Despite these positive examples, it seems to take time before municipalities adopt wood construction more extensively. Simultaneously, their position at the intersection of different actors and activities involved in construction provides a fruitful base for promoting sustainable construction. Journal: Construction Management and Economics Pages: 934-954 Issue: 11-12 Volume: 40 Year: 2022 Month: 12 X-DOI: 10.1080/01446193.2022.2037145 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2037145 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:11-12:p:934-954 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_1983851_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Maude Brunet Author-X-Name-First: Maude Author-X-Name-Last: Brunet Author-Name: Patrick Cohendet Author-X-Name-First: Patrick Author-X-Name-Last: Cohendet Title: Transforming construction: heterarchical megaproject ecologies and the management of innovation Abstract: As the digital transformation impacts many sectors of the economy, actors in the construction industry—and more specifically in megaproject initiatives—have to adapt to new technologies and processes. Megaprojects are commonly undertaken to build essential infrastructures such as roads, dams, buildings, or even smart cities or districts, and usually involve complex and hybrid organizational forms. Moreover, digitalization transforms megaprojects, presenting megaproject teams with opportunities, but also challenges. This conceptual paper explores the characteristics of heterarchical megaproject ecologies in order to identify ways to address the impacts of the current digital transformation. Our aim is to analyze how a heterarchical form of governance contributes to transforming the management of innovation. While heterarchies can lead to severe dysfunctions, we propose strategies to manage them, paying specific attention to the governance of a common-pool-resource scenario, network roles, knowledge articulation and learning. The main contribution of this paper is to provide a renewed conceptualization of megaproject governance and to propose a conceptual framework that can be used to study the management of innovation in empirical megaproject settings. Journal: Construction Management and Economics Pages: 973-986 Issue: 11-12 Volume: 40 Year: 2022 Month: 12 X-DOI: 10.1080/01446193.2021.1983851 File-URL: http://hdl.handle.net/10.1080/01446193.2021.1983851 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:11-12:p:973-986 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2141432_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Jacqueline Glass Author-X-Name-First: Jacqueline Author-X-Name-Last: Glass Author-Name: Lena E. Bygballe Author-X-Name-First: Lena E. Author-X-Name-Last: Bygballe Author-Name: Daniel Hall Author-X-Name-First: Daniel Author-X-Name-Last: Hall Title: Transforming construction: the multi-scale challenges of changing and innovating in construction Journal: Construction Management and Economics Pages: 855-864 Issue: 11-12 Volume: 40 Year: 2022 Month: 12 X-DOI: 10.1080/01446193.2022.2141432 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2141432 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:11-12:p:855-864 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2033287_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Mustafa Selçuk Çıdık Author-X-Name-First: Mustafa Selçuk Author-X-Name-Last: Çıdık Author-Name: David Boyd Author-X-Name-First: David Author-X-Name-Last: Boyd Title: Value implication of digital transformation: the impact of the commodification of information Abstract: The transforming construction agenda argues that digitalization enables better value by addressing coordination challenges. However, this claim poorly articulates how value is constituted, and ignores the problems with digitalization in real-life practices. The paper presents a finer-grained analysis of the value implications of digitalization in a critical discourse, organized in two parts, using the two value creation logics in construction as proposed by Bygballe and Jahre and the concept of “commodification” as proposed by Prudham. Through a critical literature review, the first part argues that digitalization mainly supports “production value creation logic” focussing on the integration of business processes at an organizational level, while creating challenges for “project value creation logic” by hampering mutual adjustment in situated practices. The second part conceives of digitalization as “commodification of information” to expose the complex set of processes causing digitalization to impact differently on the two value creation logics. It reveals that digitalization elevates the digital exchange value of information above its situated use value, and so, it systematically shifts the social and business contexts of coordination. Thus, digitalization shifts what, how, by whom and to whose advantage, value is created and captured, making it a politicized change with implications for management and policy. Journal: Construction Management and Economics Pages: 903-917 Issue: 11-12 Volume: 40 Year: 2022 Month: 12 X-DOI: 10.1080/01446193.2022.2033287 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2033287 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:40:y:2022:i:11-12:p:903-917 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2135750_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Benjamin Kwaku Ababio Author-X-Name-First: Benjamin Kwaku Author-X-Name-Last: Ababio Author-Name: Weisheng Lu Author-X-Name-First: Weisheng Author-X-Name-Last: Lu Title: Barriers and enablers of circular economy in construction: a multi-system perspective towards the development of a practical framework Abstract: Growing environmental concerns and the threat of resource scarcity have heightened interest in the Circular Economy (CE) concept over the last decade. Nonetheless, implementation of CE practice within the built environment has taken a slower pace in comparison with other industries. A clear understanding of systemic and multilevel aspects of CE, especially in relation to barriers that hinder practical implementation, appears to be lacking within the sector. In light of this, the study aims to examine the existing body of knowledge to elucidate, from a systemic perspective, CE barriers across various levels in construction. To achieve this purpose, a scientometric analysis is used to examine 581 bibliometric-searched filtered articles on CE implementation barriers in construction. Key issues, drivers and potential resolutions are explained using content analysis of specific pre-determined articles. The study finds that critical system levels of CE implementation (micro, meso, and macro levels) are interrelated. However, barriers and drivers at each individual level may differ. Additionally, this paper categorises key barriers to implementing CE-aligned strategies into five main themes, namely: definition and theory misconception, political and legislative, social and cultural, financial and economic, and technological barriers. Based on these, four cross-cutting enablers are established to drive the transition from linear to circular economy in construction. The findings of this study highlight deficiencies and challenges in current research while providing a path for future studies. It provides a convenient point of reference for practitioners, policy makers, and research and development (R&D) institutions on CE implementation within the industry. Lastly, the study raises public awareness on CE barriers and guides the AEC sector to develop intellectual capital to overcome them. Journal: Construction Management and Economics Pages: 3-21 Issue: 1 Volume: 41 Year: 2023 Month: 1 X-DOI: 10.1080/01446193.2022.2135750 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2135750 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:1:p:3-21 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2130384_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Ida Gremyr Author-X-Name-First: Ida Author-X-Name-Last: Gremyr Author-Name: Jenny Bäckstrand Author-X-Name-First: Jenny Author-X-Name-Last: Bäckstrand Author-Name: Anna Fredriksson Author-X-Name-First: Anna Author-X-Name-Last: Fredriksson Author-Name: Gabriella Gatenholm Author-X-Name-First: Gabriella Author-X-Name-Last: Gatenholm Author-Name: Árni Halldórsson Author-X-Name-First: Árni Author-X-Name-Last: Halldórsson Title: Blueprinting construction logistics services for quality improvement Abstract: Construction logistics services can, if implemented with high quality, positively impact both efficiency and sustainability of construction projects. However, present quality management frameworks have not been developed for temporary multi-actor contexts, such as construction, which is largely lacking industrialised processes. Still, construction logistics service providers provide service offerings to temporary settings and could thus benefit from a service quality perspective. Applying this perspective, this study supports the quality improvement of construction logistics services by using a service modularity approach to identify the services to prioritise for improvement. Building on interviews, concept mapping, and a service blueprint of a construction logistics setup, a priority matrix for improvements is developed. The first step in using this matrix is to operationalise the construction logistics setup in modules based on blueprinting. Second, the matrix evaluates the modules against nine empirically derived improvement enablers such as practices and forums for learning, and data measurements enabling the comparison and follow-up of construction logistics services. In conclusion, the priority matrix helps focus the improvements on modules with high likelihood of successful improvements. Improvements that can become sustained over time through the reuse of standardised modules in upcoming projects. Journal: Construction Management and Economics Pages: 60-78 Issue: 1 Volume: 41 Year: 2023 Month: 1 X-DOI: 10.1080/01446193.2022.2130384 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2130384 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:1:p:60-78 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2159202_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Florence Phua Author-X-Name-First: Florence Author-X-Name-Last: Phua Author-Name: Pablo Ballesteros-Pérez Author-X-Name-First: Pablo Author-X-Name-Last: Ballesteros-Pérez Title: Editorial Journal: Construction Management and Economics Pages: 1-2 Issue: 1 Volume: 41 Year: 2023 Month: 1 X-DOI: 10.1080/01446193.2022.2159202 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2159202 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:1:p:1-2 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2140815_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Emilia Nilsson Vestola Author-X-Name-First: Emilia Author-X-Name-Last: Nilsson Vestola Author-Name: Per Erik Eriksson Author-X-Name-First: Per Erik Author-X-Name-Last: Eriksson Title: Engineered and emerged collaboration: vicious and virtuous cycles Abstract: Inter-organizational collaboration within the construction industry consists of both engineered and emerged aspects. Engineered formal practices and emerged informal practices interplay in their influence on the overall success of client-contractor collaboration. This interplay has been recognized but is still understudied and requires further research to increase the understanding of how the interplay functions. To enable the study of the emerged aspects of collaboration we applied a practice-based approach in a longitudinal multiple case study, including four projects for operation and maintenance of road infrastructure. This paper contributes to the literature on collaboration in construction by providing detailed examples of how the interplay between engineered and emerged collaboration may unfold, showing how formal and informal practices contribute to the development of vicious and virtuous cycles of collaboration. Furthermore, our findings indicate that a virtuous cycle of only informal practices can become a weakness if unexpected problems occur. Project managers should therefore be encouraged to implement formal collaboration, even if the project team is already in a virtuous cycle of informal collaboration. Journal: Construction Management and Economics Pages: 79-96 Issue: 1 Volume: 41 Year: 2023 Month: 1 X-DOI: 10.1080/01446193.2022.2140815 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2140815 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:1:p:79-96 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2151024_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Tom B. J. Coenen Author-X-Name-First: Tom B. J. Author-X-Name-Last: Coenen Author-Name: Klaasjan Visscher Author-X-Name-First: Klaasjan Author-X-Name-Last: Visscher Author-Name: Leentje Volker Author-X-Name-First: Leentje Author-X-Name-Last: Volker Title: A systemic perspective on transition barriers to a circular infrastructure sector Abstract: Due to the large use of resources and waste generation, the transition to a circular economy (CE) has become a major sustainability-related topic in construction. Intentions to achieve circularity are shared widely, but developments are slow in practice. This study identifies systemic barriers to the circularity transition from a social-technical systemic perspective. We used the Mission-oriented Innovation System (MIS) framework to provide insights into the problems and potential solutions underlying the circularity mission, the structure of the system and the system dynamics. Based on the analysis of a wide range of policy documents and twenty in-depth interviews with stakeholders in the Dutch infrastructure sector, three vicious cycles were identified that form persistent barriers to the transition: (1) the CE contestation cycle given the contested nature of the circularity mission; (2) the knowledge diffusion cycle given the need to adopt and diffuse knowledge; and (3) the innovation cycle when it comes to procuring and upscaling circular innovations. These barriers all relate to processual, organizational and institutional challenges rather than to technological ones. This indicates that construction managers, policymakers and researchers in the field of infrastructure circularity should shift their focus from specific circular solutions to creating appropriate conditions for changing current and introducing novel processes that facilitate circular ways of doing things. Journal: Construction Management and Economics Pages: 22-43 Issue: 1 Volume: 41 Year: 2023 Month: 1 X-DOI: 10.1080/01446193.2022.2151024 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2151024 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:1:p:22-43 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2137882_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Zhenshuang Wang Author-X-Name-First: Zhenshuang Author-X-Name-Last: Wang Author-Name: Feng Han Author-X-Name-First: Feng Author-X-Name-Last: Han Author-Name: Bo Xia Author-X-Name-First: Bo Author-X-Name-Last: Xia Author-Name: Jingkuang Liu Author-X-Name-First: Jingkuang Author-X-Name-Last: Liu Author-Name: Chengyi Zhang Author-X-Name-First: Chengyi Author-X-Name-Last: Zhang Title: Regional differences and heterogeneity of construction and demolition waste with economic growth: evidence from China Abstract: The reduction of construction and demolition waste (C&DW) has a significant impact on the sustainable development of the construction industry. Differentiated reduction management policy is the key to C&DW reduction management. Based on the calculation of C&DW generation, this paper studies the temporal and spatial evolution characteristics, heterogeneity of C&DW with economic growth, and driving factors of C&DW generation in 30 provinces from 2007 to 2018 by using the methods of standard deviation ellipse model, environmental Kuznets curve (EKC) and geographic detector. The results show that the C&DW generation in China shows an increasing trend, “low in the west, and high in the East” and “high in the South and low in the north,” with significant regional differences. The temporal and spatial distribution of C&DW generation shows a “northeast southwest” trend, and this pattern has a trend of changing to “due north - due south”; C&DW generation increases with the economic growth, and the proportion of “inverted N” provinces is large, which is in the stage of continuous increase in the C&DW generation; The economic output effect of construction industry is the most important factor affecting the spatial distribution of C&DW generation. The impact of C&DW generation in each province has shifted from the single core driving effect of economy to the common guidance of economy and environmental protection. The interaction of different factors has a greater impact on the spatial distribution of C&DW generation than that of each factor alone. Journal: Construction Management and Economics Pages: 44-59 Issue: 1 Volume: 41 Year: 2023 Month: 1 X-DOI: 10.1080/01446193.2022.2137882 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2137882 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:1:p:44-59 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2151025_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Natalie Galea Author-X-Name-First: Natalie Author-X-Name-Last: Galea Author-Name: Abigail Powell Author-X-Name-First: Abigail Author-X-Name-Last: Powell Author-Name: Fanny Salignac Author-X-Name-First: Fanny Author-X-Name-Last: Salignac Title: The role of homosociality in maintaining men’s powerfulness in construction companies Abstract: Over the last few decades, research has largely focused on the processes and practices that act against women in male-dominated industries and the effect this has on their career progression. However, men’s careers are under analysed. This paper flips the gaze, applying a feminist institutionalist lens to examine the practices and rules that shape and enable men’s career progression. This is critical if we are to understand how men’s power in organizations is maintained and perpetuated, arguably at the expense of women’s careers. It draws on data from a rapid ethnographic study of the Australian construction industry, specifically of construction professionals working in two multinational Australian construction companies. The paper finds that men’s career progression routinely operates through homosociality, instrumentally and expressively, via a “sponsor-mobility” principle whereby selected individuals receive higher levels of guidance, access to opportunities and advocacy from their managers. Journal: Construction Management and Economics Pages: 172-182 Issue: 2 Volume: 41 Year: 2023 Month: 2 X-DOI: 10.1080/01446193.2022.2151025 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2151025 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:2:p:172-182 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2124527_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Mohammad Tanvi Newaz Author-X-Name-First: Mohammad Tanvi Author-X-Name-Last: Newaz Author-Name: Mahmoud Ershadi Author-X-Name-First: Mahmoud Author-X-Name-Last: Ershadi Author-Name: Marcus Jefferies Author-X-Name-First: Marcus Author-X-Name-Last: Jefferies Author-Name: Manikam Pillay Author-X-Name-First: Manikam Author-X-Name-Last: Pillay Author-Name: Peter Davis Author-X-Name-First: Peter Author-X-Name-Last: Davis Title: A systematic review of contemporary safety management research: a multi-level approach to identifying trending domains in the construction industry Abstract: Safety management research in construction is pervasive, therefore, a systematic review and a bibliometric mapping process that provides an overview of how recent mainstream research topics are conceptually structured is timely. Undertaking systematic mapping, contemporaneous with a scoping review of construction safety management research, can contribute to a better understanding of research outcomes and predominant topics. This study employed VOSviewer as a bibliometric tool to identify co-author citations, as well as the co-occurrence of key terms within the title, abstract and keywords of the articles. A total of 180 representative studies published in 21 peer-reviewed journals between January 2010 and November 2021 were analysed. A systematic literature review identified a significant focus on conceptualizing safety climate and safety behaviour with a growing interest in applying advanced technologies for improved safety management. Two perspectives were recognized in safety research, i.e. process-driven and people-driven, with the former focussing on accident causation while the latter on underlying the active role of workers’ involvement in safety outcomes. An in-depth discussion of the findings revealed seven trending research domains: safety systems; safety skills; accident causation; safety leadership and communications; safety behaviour and attitude; safety climate and culture; and practices for improving safety performance. This review identified an emerging interest in seeking effective leadership styles and psychological interventions to promote safety culture and behaviour. In terms of practical implications, this study found opportunities to address the gap between theory and practice by adopting systems thinking and using IT for improving safety performance in construction projects. Journal: Construction Management and Economics Pages: 97-115 Issue: 2 Volume: 41 Year: 2023 Month: 2 X-DOI: 10.1080/01446193.2022.2124527 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2124527 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:2:p:97-115 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2127154_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Qinjun Liu Author-X-Name-First: Qinjun Author-X-Name-Last: Liu Author-Name: Yingbin Feng Author-X-Name-First: Yingbin Author-X-Name-Last: Feng Author-Name: Kerry London Author-X-Name-First: Kerry Author-X-Name-Last: London Author-Name: Peng Zhang Author-X-Name-First: Peng Author-X-Name-Last: Zhang Title: Influence of personal characteristics and environmental stressors on mental health for multicultural construction workplaces in Australia Abstract: Exposure to various stressors has resulted in a significant problem of mental health among the construction workforce. A culturally intolerant environment may aggravate mental ill health in a multicultural workplace. However, an underlying structural issue that has not been sufficiently addressed to date is the influence the crucial personal characteristics and environmental stressors have on mental health in the multicultural construction environment. This study aims to examine the role of personal characteristics and environmental stressors in construction workers’ mental health in the multicultural environment. Data were collected using an online questionnaire survey from 252 construction workers in Australia. The structural equation modelling (SEM) technique with partial least-squares estimation (PLS) was adopted to analyze the data. Results showed that workers’ mental health is not only influenced by stressors related to the work environment, but also by individual traits. Increased levels of cultural stressors tend to aggravate the adverse effect of work stressors on mental health. Work stressors are more likely to cause mental ill health for the individuals characterized by a higher level of aggressive, competitive, ambiguous, and impulsive personalities; whilst cultural stressors are less likely to cause mental ill health for those individuals. This research offers an innovative perspective on the relationships between crucial person-environment factors and mental health, and informs the practice of work health and safety in the multicultural construction workplace. Journal: Construction Management and Economics Pages: 116-137 Issue: 2 Volume: 41 Year: 2023 Month: 2 X-DOI: 10.1080/01446193.2022.2127154 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2127154 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:2:p:116-137 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2137880_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Terrelle Hegarty Author-X-Name-First: Terrelle Author-X-Name-Last: Hegarty Author-Name: Sarah Wright Author-X-Name-First: Sarah Author-X-Name-Last: Wright Author-Name: Russell Wordsworth Author-X-Name-First: Russell Author-X-Name-Last: Wordsworth Author-Name: Beverley Lord Author-X-Name-First: Beverley Author-X-Name-Last: Lord Title: Deferential Tailoring: a grounded theory of how women respond and adapt to social conditions and gender-related challenges in the New Zealand construction industry Abstract: In this article we utilize grounded theory to explore women’s experiences in the unique construction industry context that followed the 2010 Canterbury (New Zealand) earthquakes. Data were obtained from 36 semi-structured interviews conducted with women working in a variety of occupations in the construction industry. We identify three inter-related categories: capitalizing on opportunity, demonstrating capability and surface tolerance, which together represent a response process that we label “deferential tailoring”. The deferential tailoring process explains how women intentionally shape their response to industry conditions through self-regulating behaviours that enables them to successfully seize opportunities and manage gender-related challenges in the working environment. Our findings challenge existing research which suggests that women adopt submissive coping strategies to conform to androcentric norms in the construction industry. Instead, we argue that the process of deferential tailoring can empower women to build positive workplace relationships, enhance career development, and help shift perceptions of the value of their work in the industry. Journal: Construction Management and Economics Pages: 138-152 Issue: 2 Volume: 41 Year: 2023 Month: 2 X-DOI: 10.1080/01446193.2022.2137880 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2137880 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:2:p:138-152 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2151022_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20220907T060133 git hash: 85d61bd949 Author-Name: Morwenna F. Fellows Author-X-Name-First: Morwenna F. Author-X-Name-Last: Fellows Author-Name: Florence T. T. Phua Author-X-Name-First: Florence T. T. Author-X-Name-Last: Phua Author-Name: Dylan E. Tutt Author-X-Name-First: Dylan E. Author-X-Name-Last: Tutt Title: Building bridges: the bilingual language work of migrant construction workers Abstract: The construction industry (CI) employs significant numbers of migrant workers, making construction sites multilingual spaces. Workers who do not share a common language work alongside each other, posing issues for safety, integration and productivity. Methods used to overcome these language barriers include the use of bilingual workers as informal interpreters. The prevalence and importance of informal interpreters is recognized in the literature. However, their language work is not well understood, and hence, the research question addressed is: what language work do the informal interpreters do and how? This study uses the theoretical lens of translanguaging to conceptualize communication onsite between speakers of different named languages, emphasizing the flexible and multimodal nature of language in use. An ethnographic approach is adopted, comprising 40 international informal interviews, and observational field notes and material data from the UK. The language work of the informal interpreters is explored through this data and theoretical lens; their language tasks and the nature of their language work is identified, including the use of visuals, gesture, and technology. Far from being straightforward and predictable, the findings show that the scope of their language work varies considerably. In this informal language work, the boundaries between languages and of what constitutes interpretation are blurred. A novel aspect of language work emerges from the data, showing that this often includes mediation. This study clarifies understandings of communication and informal interpretation on multilingual construction sites and these findings could contribute to future best practice on the use of bilingual workers as informal interpreters. Journal: Construction Management and Economics Pages: 153-171 Issue: 2 Volume: 41 Year: 2023 Month: 2 X-DOI: 10.1080/01446193.2022.2151022 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2151022 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:2:p:153-171 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2135749_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Marcus C. T. Fireman Author-X-Name-First: Marcus C. T. Author-X-Name-Last: Fireman Author-Name: Tarcisio Abreu Saurin Author-X-Name-First: Tarcisio Abreu Author-X-Name-Last: Saurin Author-Name: Carlos Torres Formoso Author-X-Name-First: Carlos Torres Author-X-Name-Last: Formoso Author-Name: Lauri Koskela Author-X-Name-First: Lauri Author-X-Name-Last: Koskela Author-Name: Iris D. Tommelein Author-X-Name-First: Iris D. Author-X-Name-Last: Tommelein Title: Slack in production planning and control: a study in the construction industry Abstract: Although buffers of inventories, time, and capacity are commonly recommended to mitigate variability in construction, they abstract away the role played by human agency. This study argues for slack as a socio-technical complement to buffers for dealing with variability. The investigation is based on two case studies conducted in construction projects that adopted the Last Planner® System. Data collection focussed on understanding how slack practices and resources (SPR) were used in production planning and control, and was based on observations, analysis of documents, and interviews. Findings revealed 57 instantiations of slack practices and 8 types of slack resources. Several of these SPR diverge from what are traditionally called buffers, highlighting how the concept of SPR gives visibility to a wider range of variability coping mechanisms. Thus, it is important to make SPR explicit so that managers can reflect on why SPR are necessary, understand how they relate to each other, and assess their unintended consequences. Five propositions are presented, encompassing: how to identify SPR; the variety and general- or context-specific nature of SPR; and the value of maintaining SPR. These propositions contribute to risk management in production planning and control. Journal: Construction Management and Economics Pages: 256-276 Issue: 3 Volume: 41 Year: 2023 Month: 3 X-DOI: 10.1080/01446193.2022.2135749 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2135749 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:3:p:256-276 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2135748_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Patrick Dallasega Author-X-Name-First: Patrick Author-X-Name-Last: Dallasega Author-Name: Felix Schulze Author-X-Name-First: Felix Author-X-Name-Last: Schulze Author-Name: Andrea Revolti Author-X-Name-First: Andrea Author-X-Name-Last: Revolti Title: Augmented Reality to overcome Visual Management implementation barriers in construction: a MEP case study Abstract: Visual Management (VM) is an important Lean method to enhance information flow and reduce waste in construction. However, its adoption is hindered by several barriers. Scientific works mention that emerging technologies can support or replace conventional VM practices, but empirical evidence is missing. Based on an in-depth literature review, we derived the research questions (RQs), arguing if Augmented Reality (AR) could mitigate VM implementation barriers. Thus, a corresponding AR measurement model was developed. Through a case study of mechanical, electrical, and plumbing (MEP) installations in a multi-story apartment building, the RQs were answered using an AR head-mounted display (HMD). To gather the necessary empirical evidence, the data was collected through direct observations on-site and through semi-structured interviews. The study findings show that (1) AR provided time savings and generally satisfactory accuracy levels. (2) AR demonstrably reduced the training effort to better support MEP marking work. (3) The use of AR reduced the resistance to change to adopt VM practices, although concerns were raised about poor ergonomics and work safety risks. Future research activities should consist of investigating the potential of other emerging technologies to overcome the common Lean implementation barriers in construction. Journal: Construction Management and Economics Pages: 232-255 Issue: 3 Volume: 41 Year: 2023 Month: 3 X-DOI: 10.1080/01446193.2022.2135748 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2135748 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:3:p:232-255 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2132523_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Bernard Tuffour Atuahene Author-X-Name-First: Bernard Tuffour Author-X-Name-Last: Atuahene Author-Name: Sittimont Kanjanabootra Author-X-Name-First: Sittimont Author-X-Name-Last: Kanjanabootra Author-Name: Thayaparan Gajendran Author-X-Name-First: Thayaparan Author-X-Name-Last: Gajendran Title: Transformative role of big data through enabling capability recognition in construction Abstract: Big data application is a significant transformative driver of change in the retail, health, engineering, and advanced manufacturing sectors. Big data studies in construction are still somewhat limited, although there is increasing interest in what big data application could achieve. Through interviews with construction professionals, this paper identifies the capabilities needed in construction firms to enable the accrual of the potentially transformative benefits of big data application in construction. Based on previous studies, big data application capabilities, needed to transform construction processes, focussed on data, people, technology, and organisation. However, the findings of this research suggest a critical modification to that focus to include knowledge and the organisational environment along with people, data, and technology. The research findings show that construction firms use big data with a combination strategy to enable transformation by (a) driving an in-house data management policy to rolling-out the big data capabilities; (b) fostering collaborative capabilities with external firms for resource development, and (c) outsourcing big data services to address the capabilities deficits impacting digital transformation. Journal: Construction Management and Economics Pages: 208-231 Issue: 3 Volume: 41 Year: 2023 Month: 3 X-DOI: 10.1080/01446193.2022.2132523 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2132523 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:3:p:208-231 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2124528_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Muaz O. Ahmed Author-X-Name-First: Muaz O. Author-X-Name-Last: Ahmed Author-Name: Islam H. El-adaway Author-X-Name-First: Islam H. Author-X-Name-Last: El-adaway Title: An integrated game-theoretic and reinforcement learning modeling for multi-stage construction and infrastructure bidding Abstract: Construction and infrastructure bidding is a highly competitive and complicated process that entails various uncertainties faced by contractors. The situation is more complex in multi-stage bidding (MSG) where general contractors must deal with the complexity of accounting for the bids of their subcontractors and face a greater threat of falling prey to the winner’s curse (i.e. situation where the winning contractor underestimates the actual cost of the project). Existing research efforts have tackled the issue of the winner’s curse in MSG from the general contractor’s perspective. However, there is a lack of research in developing bidding models that simultaneously aid both general contractors and subcontractors in determining their bid value to mitigate the winner’s curse in MSG. This paper fills this knowledge gap. The authors utilized an interdependent game theory (GT) and reinforcement learning (RL) approach, that includes: formulation of MSG framework; incorporation of two RL algorithms, namely the multiplicative weights and the modified Roth-Erev, to be utilized by subcontractors in preparation of their bids; utilization of MSG game-theoretic bid function for the preparation of the general contractors’ bids for the whole project; development of the MSG-GTRL model; and testing the MSG-GTRL model through simulating various bidding scenarios using a combination of actual and synthetic dataset of infrastructure projects. Results show that integrating GT and RL in MSG bidding enables general contractors and their subcontractors to simultaneously improve their financial state by minimizing the occurrence of negative earnings, and thus, avoiding the winner’s curse in their respective portions of projects. Journal: Construction Management and Economics Pages: 183-207 Issue: 3 Volume: 41 Year: 2023 Month: 3 X-DOI: 10.1080/01446193.2022.2124528 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2124528 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:3:p:183-207 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2156570_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Yousong Wang Author-X-Name-First: Yousong Author-X-Name-Last: Wang Author-Name: Yao Yao Author-X-Name-First: Yao Author-X-Name-Last: Yao Author-Name: Yangbing Zhang Author-X-Name-First: Yangbing Author-X-Name-Last: Zhang Author-Name: Boya Su Author-X-Name-First: Boya Author-X-Name-Last: Su Author-Name: Tongyuan Wu Author-X-Name-First: Tongyuan Author-X-Name-Last: Wu Title: Impact of industrial agglomeration on total factor productivity in the construction industry: evidence from China Abstract: Industrial agglomeration (IA), a common industrial phenomenon, has been verified to have a significant impact on total factor productivity (TFP) in many industries. However, the impact of IA on TFP is seldom investigated in the construction industry, despite the existence of the industrial agglomeration phenomenon in the construction industry. As such, this study aims to probe into the impact of IA on TFP in the construction industry, so as to provide new insights into the industry development and improvement of TFP in the construction industry. Based on the competing results of the agglomeration effect and congestion effect caused by IA, this study proposed three hypotheses on the impact mechanism of IA on TFP in the construction industry. Then, the non-linear regression model and linear regression model were developed to test the hypotheses based on the provincial panel data from 2002 to 2017 in China. The empirical results reveal that IA has a positive linear impact on TFP in the construction industry, and the impact of IA on TFP in the Chinese construction industry during the observed period is in the embryonic stage. Besides, both the firm scale and economic development level have positive impacts on TFP, whereas the specialization structure has a negative impact. Hence, the government can encourage industrial agglomeration in the construction industry to enhance TFP, in order to leverage the knowledge spillovers, labor pool, and other benefits from IA. Journal: Construction Management and Economics Pages: 322-337 Issue: 4 Volume: 41 Year: 2023 Month: 4 X-DOI: 10.1080/01446193.2022.2156570 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2156570 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:4:p:322-337 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2164598_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Islam H. El-adaway Author-X-Name-First: Islam H. Author-X-Name-Last: El-adaway Author-Name: Gasser G. Ali Author-X-Name-First: Gasser G. Author-X-Name-Last: Ali Author-Name: Radwa Eissa Author-X-Name-First: Radwa Author-X-Name-Last: Eissa Author-Name: Mohamad Abdul Nabi Author-X-Name-First: Mohamad Author-X-Name-Last: Abdul Nabi Author-Name: Muaz O. Ahmed Author-X-Name-First: Muaz O. Author-X-Name-Last: Ahmed Author-Name: Tamima Elbashbishy Author-X-Name-First: Tamima Author-X-Name-Last: Elbashbishy Author-Name: Ramy Khalef Author-X-Name-First: Ramy Author-X-Name-Last: Khalef Title: Construction Management and Economics 40th anniversary: investigating knowledge structure and evolution of research trends Abstract: Celebrating Construction Management and Economics's (CME) 40th anniversary, the goal of this paper is to investigate the knowledge structure and evolution of research trends in CME since its inception. The associated objectives include: (1) analyzing CME’s scholarly characteristics; (2) studying CME’s publication output over time; (3) examining interconnectivities between CME’s research trends; and (4) exploring the potential citation impact of recently published CME’s papers. In doing so, this paper implemented a multistep methodology that consists of descriptive assessment, social network analysis (SNA), and predictive machine learning (ML). Results of descriptive assessment showed that CME has witnessed over the years a noticeable growth in the number of publications, citation trends, and collaborative research as depicted increased co-authorship, and that highest percentage of publications were related to “Strategy, Decision Making, Risk, and Finance”, “Project planning and Design” and “Contemporary Issues”. Output of SNA highlights that research areas with the highest interconnectivity included “Strategy, Decision Making, Risk and Finance” and “Project Planning and Design”, and “Labor and Personnel Issues”. Furthermore, predictive ML revealed that CME papers have a high probability of becoming high impact publications. In addition to that, the predictive ML results re-emphasized the outcomes of the performed descriptive assessment by reflecting the importance of “Contemporary Issues”, “Organizational Issues”, “Strategy, Decision Making, Risk, and Finance”, and “Labor and Personnel Issues” as emerging research topics with increased potential impact in the future. Ultimately, this paper benefits all CME stakeholders by quantitatively studying current research patterns, their interconnectivities, and future potential. Journal: Construction Management and Economics Pages: 338-360 Issue: 4 Volume: 41 Year: 2023 Month: 4 X-DOI: 10.1080/01446193.2022.2164598 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2164598 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:4:p:338-360 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2111694_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Sabina Maslova Author-X-Name-First: Sabina Author-X-Name-Last: Maslova Author-Name: Gemma Burgess Author-X-Name-First: Gemma Author-X-Name-Last: Burgess Title: Delivering human-centred housing: understanding the role of post-occupancy evaluation and customer feedback in traditional and innovative social housebuilding in England Abstract: Housing shortages and construction delays characterize the current UK housing crisis, and housing need is not met. Modern methods of construction (MMC) are put forward as a solution to ensure quicker, safer, and greener delivery of new homes and are supported by the government, especially in the social housing sector. The paper explores the post-occupancy evaluation mechanisms used by housing associations delivering homes with traditional and MMC approaches. It argues that, alongside the digital and offsite transformation of housebuilding, the industry needs to reconsider the way customer feedback is collected and what purposes it serves. The paper argues that UK housebuilding in the social housing sector can benefit from re-purposing post-occupancy evaluation (POE) from only measuring customer satisfaction and detecting defects, which is currently the case, to using it to improve housing design and construction quality. This could be done by developing a systematic learning loop from residents of previous projects to the design, development, and construction teams across the housebuilding supply chain. It could particularly benefit housing associations pioneering MMC that, as long-term asset holders of developed houses, have a vested interest in improving the quality of homes and creating a better residential experience. The accumulated knowledge of such customer-centred approaches could also inform MMC technology development and help increase its uptake. However, as the paper further discusses, there are many challenges on the way to effective POE in social housing provision, including the nature of the MMC-based housebuilding supply chain and the industry’s structural factors. Journal: Construction Management and Economics Pages: 277-292 Issue: 4 Volume: 41 Year: 2023 Month: 4 X-DOI: 10.1080/01446193.2022.2111694 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2111694 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:4:p:277-292 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2151023_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Carlos Andres Zapata Quimbayo Author-X-Name-First: Carlos Andres Author-X-Name-Last: Zapata Quimbayo Author-Name: Carlos Armando Mejía Vega Author-X-Name-First: Carlos Armando Author-X-Name-Last: Mejía Vega Title: Credit risk in infrastructure PPP projects under the real options approach Abstract: The purpose of the paper is to provide a method to estimate the credit risk in infrastructure public–private partnership (PPP) projects by using a structural model, the Real Options approach, and the Monte Carlo simulation technique. To do that, previous models are extended under a structural framework for credit risk where the embedded options in the credit agreement such as the option to renegotiate and the option to exit are introduced as well as the uncertainty of the cash flows. In that sense, all the components of expected loss (EL) such as the probability of default, the exposure, and the recovery rate for lenders are modelled and estimated in a PPP toll road project by considering the embedded options as well as the default events. Consequently, it is found that the embedded options improve the recovery rate for lenders and their EL. Additionally, practical insights about the effects of the embedded options in the credit agreement and the probability of default are provided. Journal: Construction Management and Economics Pages: 293-306 Issue: 4 Volume: 41 Year: 2023 Month: 4 X-DOI: 10.1080/01446193.2022.2151023 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2151023 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:4:p:293-306 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2156569_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Taija Puolitaival Author-X-Name-First: Taija Author-X-Name-Last: Puolitaival Author-Name: Kalle Kähkönen Author-X-Name-First: Kalle Author-X-Name-Last: Kähkönen Author-Name: Linda Kestle Author-X-Name-First: Linda Author-X-Name-Last: Kestle Title: The framing of construction management responsibilities in job advertisements in the UK and the USA Abstract: Responsibilities in construction management can be looked at from many perspectives: individually and organizationally, within the organization and outside the organization. They spread from the daily tasks of a site manager to contractual responsibilities of a whole organization forming a wide and complex topic. The aim of this research was to enhance the understanding of construction management responsibilities by looking at how job advertisements frame the responsibilities of construction management professionals. A documentary research approach with genre and content analyses was used to analyze a selection of job advertisements from large main contractors in the UK and the USA qualitatively. The genre analysis revealed that job advertisements present the construction management responsibilities through a breakdown of three levels: the role name, the overview of the work functions and the description of the responsibilities. The qualitative content analysis resulted in a redeveloped definition of construction management and typology of responsibilities. Recommendations are given for job advertisement writers to ensure that the role name, overview of the work functions and description of the responsibilities all align and contain an appropriate amount of accurate information to attract suitable candidates to apply. Journal: Construction Management and Economics Pages: 307-321 Issue: 4 Volume: 41 Year: 2023 Month: 4 X-DOI: 10.1080/01446193.2022.2156569 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2156569 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:4:p:307-321 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2164789_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Kiran Mahasuar Author-X-Name-First: Kiran Author-X-Name-Last: Mahasuar Title: COVID-19 and its impact on Indian construction industry: an event study approach Abstract: COVID-19 has disrupted the normal course of production and livelihood activities across the world. This paper examines the short-term impact of this pandemic on one such strategically important sector, the construction industry of India. This study employs an event study approach to empirically study the market performance and response trends of the construction industry of India to the COVID-19 pandemic. The study finds that COVID-19 has negatively impacted the sector as reflected in the investors’ response during the pandemic window. Through further empirical analysis, we also find that this sector has been affected more vis-à-vis other similar industries. In addition, the study also highlights some broad recommendations and proposes a process framework with prescriptive strategies for relevant stakeholders to smoothen the post-COVID recovery process. Journal: Construction Management and Economics Pages: 428-444 Issue: 5 Volume: 41 Year: 2023 Month: 5 X-DOI: 10.1080/01446193.2022.2164789 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2164789 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:5:p:428-444 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2137881_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Alexander Styhre Author-X-Name-First: Alexander Author-X-Name-Last: Styhre Author-Name: Sara Brorström Author-X-Name-First: Sara Author-X-Name-Last: Brorström Title: Syndicated leadership in urban development projects: the case of the River City Gothenburg project Abstract: Large-scale urban development projects are complex economic and politically shaped activities, and such projects have oftentimes proved to be more costly and demanding more time to complete than is frequently being stipulated from the outset. Based on these conditions, urban development projects demand effective cross-organizational collaborations to optimize the use of available expertise, the capacity to process data and information, and to optimize public interests (being monitored by democratically elected entities in democratic societies). Based on a study of a major urban development project in Gothenburg, Sweden, this article introduces the concept of syndicated leadership, derived from the concept of syndicated investment in the venture capital industry. Syndicated leadership is based on the centralization of decision-making authority and resource allocation to a team of leaders, each representing (in the case examined) a private corporation, a municipality corporation, or a municipality agency having specific responsibilities in the shared urban development project, but also being dependent on the capacity to coordinate and align project activities. As the case indicates, syndicated leadership demands new expertise and communicative capacities and political skills, but when implemented effectively, it holds the promise of avoiding costly and embarrassing urban development project failures as it makes better use of the expertise of the participant organizations and better accommodate public interests. Journal: Construction Management and Economics Pages: 387-401 Issue: 5 Volume: 41 Year: 2023 Month: 5 X-DOI: 10.1080/01446193.2022.2137881 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2137881 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:5:p:387-401 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2104890_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Fred Sherratt Author-X-Name-First: Fred Author-X-Name-Last: Sherratt Author-Name: Andy Dainty Author-X-Name-First: Andy Author-X-Name-Last: Dainty Title: The power of a pandemic: how Covid-19 should transform UK construction worker health, safety and wellbeing Abstract: The world will never be the same again, and neither will the UK construction industry. As one of the few sectors projected to bounce back rapidly from the pandemic, positive rhetoric abounds in the industry press, Government and quasi-governmental bodies about the opportunity that lies ahead to “Build Back Better”. Something else that could and more importantly should never be the same again is the health, safety and wellbeing (HSW) of the UK construction workforce. Pre-Covid-19, UK construction was neither a safe nor a healthy place to work, and transforming this situation is arguably the most important win our industry can secure from this situation. In this essay we argue that the pandemic and associated socio-economic crisis offers a unique, once-in-a-generation opportunity to bounce forward to a “new normal” of healthy, safe and hygienic construction operations, one where the worker’s psychological wellbeing shares the foreground with their physical welfare. This paradigm shift will require a radical redefinition of the matters of concern that shape construction practice, moving away from a focus on sites as the locus of production, to a focus on people. Moreover, we suggest that there is a concurrent obligation on the research community to support such a transition by using the pandemic as a new point of departure for shifting the safety discourse via more critical research approaches. These should question the axioms which currently define the ways in which projects are constituted and managed, and where production takes primacy over the workers that deliver it. Journal: Construction Management and Economics Pages: 379-386 Issue: 5 Volume: 41 Year: 2023 Month: 5 X-DOI: 10.1080/01446193.2022.2104890 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2104890 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:5:p:379-386 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2162096_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: S M Jamil Uddin Author-X-Name-First: S M Jamil Author-X-Name-Last: Uddin Author-Name: Alex Albert Author-X-Name-First: Alex Author-X-Name-Last: Albert Author-Name: Mahzabin Tamanna Author-X-Name-First: Mahzabin Author-X-Name-Last: Tamanna Author-Name: Abdullah Alsharef Author-X-Name-First: Abdullah Author-X-Name-Last: Alsharef Title: YouTube as a source of information: early coverage of the COVID-19 pandemic in the context of the construction industry Abstract: The COVID-19 pandemic has been the largest global crisis in recent decades. Apart from the countless deaths and health emergencies, the pandemic has disrupted several industries—including construction. For example, a significant number of construction projects have been interrupted, delayed, and even abandoned. In such emergencies, information gathering and dissemination are vital for effective crisis management. The role of social media platforms such as YouTube, Facebook, and Twitter, as information sources, in these contexts has received much attention. The purpose of this investigation was to evaluate if YouTube can serve as a useful source of information for the construction industry in emergency situations—such as during the early stages of the COVID-19 pandemic. The assessment was undertaken by distilling the coverage of the COVID-19 pandemic as it relates to the construction industry from the content shared via YouTube by leveraging Latent Dirichlet Allocation (LDA) topic modelling. The investigation also compared the timeline with which relevant content was shared via YouTube and peer-reviewed research articles to make relative assessments. The findings suggest that YouTube offered significant and relevant coverage across six topics that include health and safety challenges, ongoing construction operation updates, workforce-related challenges, industry operations-related guidelines and advocacy, and others. Moreover, compared to the coverage of the COVID-19 pandemic in the research literature, YouTube offered more comprehensive and timely coverage of the pandemic as it relates to the construction industry. Accordingly, industry stakeholders may leverage YouTube as a valuable and largely untapped resource to aid in combating similar emergency situations. Journal: Construction Management and Economics Pages: 402-427 Issue: 5 Volume: 41 Year: 2023 Month: 5 X-DOI: 10.1080/01446193.2022.2162096 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2162096 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:5:p:402-427 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2096250_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Naomi Borg Author-X-Name-First: Naomi Author-X-Name-Last: Borg Author-Name: Christina M. Scott-Young Author-X-Name-First: Christina M. Author-X-Name-Last: Scott-Young Author-Name: Nader Naderpajouh Author-X-Name-First: Nader Author-X-Name-Last: Naderpajouh Author-Name: Jessica Borg Author-X-Name-First: Jessica Author-X-Name-Last: Borg Title: Surviving adversity: personal and career resilience in the AEC industry during the COVID-19 pandemic Abstract: This study aimed to explore the personal and career resilience of project management practitioners working in the Architectural, Engineering, and Construction (AEC) industries and their organizational support in the context of the COVID-19 pandemic. The global pandemic offered a unique opportunity to explore resilience both as a state (using quantitative scales) and as a process (using qualitative responses) in the context of a shared transboundary disturbance in normal routines. A mixed methods approach was used to triangulate quantitative and qualitative data from an online survey which included established scales and open-ended questions. Informed by a total of 121 valid survey responses, hierarchical regression analysis of the scales provided insights into the relationship between career and personal resilience and how personal resilience contributed to greater career resilience and the ability to positively adapt to the pandemic’s consequences. The quantitative analysis was complemented by a thematic analysis of the open-ended responses to identify the forms of organizational support that were important for resilience building during the pandemic. Organizational resources, such as training, mentoring, increased communication, and greater management support fostered employee adaptation to the pandemic shock. Evidence-based recommendations are made for AEC organizations to facilitate better workforce preparation for future adversities through providing effective resilience-promoting support mechanisms. The findings add to the body of knowledge by providing a better understanding of the importance of personal and career resilience and the role of organizational support in the process of resilience-building during adversities. Journal: Construction Management and Economics Pages: 361-378 Issue: 5 Volume: 41 Year: 2023 Month: 5 X-DOI: 10.1080/01446193.2022.2096250 File-URL: http://hdl.handle.net/10.1080/01446193.2022.2096250 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:5:p:361-378 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2169316_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Qiuwen Ma Author-X-Name-First: Qiuwen Author-X-Name-Last: Ma Author-Name: Sai On Cheung Author-X-Name-First: Sai On Author-X-Name-Last: Cheung Author-Name: Shan Li Author-X-Name-First: Shan Author-X-Name-Last: Li Title: Optimum risk/reward sharing framework to incentivize integrated project delivery adoption Abstract: The major benefit of integrated project delivery (IPD) is the involvement of stakeholders at the early stage of the project so that they can all contribute to project development. They would also work cooperatively towards the project goals that they have jointly developed. Moreover, IPD has not taken the market as promised by the aforementioned benefits due to two principal concerns. First, the conventional risk/reward sharing that has been developed for the principal-agent type of relationship has been used. Second, the reward has not been tailored to reflect the stochastic nature of the risks involved. This study proposes a novel risk/reward sharing framework that would alleviate these two concerns. Employing stochastic cooperative game theory and prospect theory as conceptual lenses, a more realistic risk/reward sharing framework is developed for IPD projects. The use of Pareto optimality enables the proposed framework to arrange incentives optimally with due regard to the risk propensity of the contracting parties. Setting the notional sharing approach as a fair starting point, the framework further introduces transfer payments to ensure fairness and retain optimum sharing at the same time. Both features would facilitate the structuring of multi-win sharing incentive to be incorporated with integrated project delivery. The operation of the proposed framework is illustrated by applying it to a real case. Wider adoption of IPD can be expected when the two principal concerns of IPD arrangements are addressed. Journal: Construction Management and Economics Pages: 519-535 Issue: 6 Volume: 41 Year: 2023 Month: 6 X-DOI: 10.1080/01446193.2023.2169316 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2169316 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:6:p:519-535 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2167218_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Algan Tezel Author-X-Name-First: Algan Author-X-Name-Last: Tezel Author-Name: Lauri Koskela Author-X-Name-First: Lauri Author-X-Name-Last: Koskela Title: Off-site construction in highways projects: management, technical, and technology perspectives from the United Kingdom Abstract: With a rich off-site construction (OSC) experience accumulated over the last two centuries, the United Kingdom (UK) is looking up to OSC to deliver its critical infrastructure projects in the next decade. Highway projects are good fits for OSC with their project characteristics. However, the extant OSC literature for highways is mostly about OSC elements’ design performance. Also, the OSC literature is predominantly building sector focused. Addressing this gap, the paper presents the findings of a research project, sponsored by the UK’s National Highways, which aims at understanding what needs to be done to improve the current OSC condition for highways projects in the UK from a management, technical and technological perspective. After a detailed literature review, 20 in-depth interviews with subject experts were conducted. The initial findings were validated through five highways projects as cases and then ranked by two focus groups using the Delphi method. Alongside revealing the current OSC condition, 95 suggestions (43 management-related, 23 technical opportunities, and 29 technology-related) were elicited and ranked by their impact potential. Some of the high-potential suggestions are developing a collaborative OSC decision making framework, a product design mindset, improving OSC digital product libraries, creating mobile OSC factories, and a design options repository. The findings revealed that many OSC challenges identified in the general or building sector focused OSC discussions exist also in the highways sector. It is recommended that the identified high and medium impact potential suggestions are prioritized by practitioners and policy makers to improve the current OSC condition. Journal: Construction Management and Economics Pages: 475-499 Issue: 6 Volume: 41 Year: 2023 Month: 6 X-DOI: 10.1080/01446193.2023.2167218 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2167218 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:6:p:475-499 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2167219_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Nyakundi M. Michieka Author-X-Name-First: Nyakundi M. Author-X-Name-Last: Michieka Author-Name: Noha H. A. Razek Author-X-Name-First: Noha H. A. Author-X-Name-Last: Razek Author-Name: Richard S. Gearhart Author-X-Name-First: Richard S. Author-X-Name-Last: Gearhart Title: Modelling the impact of oil price changes and investment decisions on construction wages in the U.S. Abstract: The U.S. construction industry has been known to employ workers without a college education and provide adequate compensation make ends meet. Today, job quality in the industry has deteriorated to a level where wages are too low, causing workers to rely on U.S. safety net programs. This may be exacerbated by oil price changes, especially in regions where the oil industry is a significant driver of the economy. In this paper, we investigate the effects of oil price dynamics on real wages in the construction industry. A non-linear ARDL and TAR model are used for the empirical exercise which focusses on six top oil producing counties in the U.S. Long-run findings indicate that a 10% increase in oil price increases construction wages by 1.4, 1.2 and 9.3% in Kern, Weld and McKenzie Counties, respectively. Short run estimates indicate that a positive shock to oil prices increases wages in McKenzie County, North Dakota. Results from the TAR model show that the impact of an expansionary monetary policy to increase investment – and accordingly, increase wages – is diluted when oil prices are below the low oil price threshold. Journal: Construction Management and Economics Pages: 500-518 Issue: 6 Volume: 41 Year: 2023 Month: 6 X-DOI: 10.1080/01446193.2023.2167219 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2167219 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:6:p:500-518 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2164934_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Kent J. Nielsen Author-X-Name-First: Kent J. Author-X-Name-Last: Nielsen Author-Name: Marianne Törner Author-X-Name-First: Marianne Author-X-Name-Last: Törner Author-Name: Anders Pousette Author-X-Name-First: Anders Author-X-Name-Last: Pousette Author-Name: Martin Grill Author-X-Name-First: Martin Author-X-Name-Last: Grill Title: National culture and occupational safety – a comparison of worker-level factors impacting safety for Danish and Swedish construction workers Abstract: Denmark and Sweden are societally and regulatory similar countries with large differences in occupational injury rates. Denmark has consistently had twice the rate of reported injuries compared to Sweden and a 45% higher rate of fatal injuries in the construction industry. The current study aims to further investigate the perceived underlying factors responsible for the difference in injury rate between Denmark and Sweden by examining the possible impact on safety climate and safety behaviour of cooperation, perceived organizational support, organizational citizenship behaviour (OCB), planning, safety motivation, and long-term orientation. The paper is based on a questionnaire study completed by 346 construction workers from 48 Swedish construction sites and 465 construction workers from 37 Danish construction sites. The results show that all six predictors were positively related with safety climate and/or safety behaviour in both countries. However, the level of the predictors was generally higher in Sweden, and there was a stronger positive relationship with the outcomes in Sweden than Denmark. Specifically, the valuation of cooperation and OCB, planning and long-term orientation were more dominant in Sweden. These differences illuminate some of the possible factors underlying the difference in injury rate between the Danish and Swedish construction industry. Journal: Construction Management and Economics Pages: 445-456 Issue: 6 Volume: 41 Year: 2023 Month: 6 X-DOI: 10.1080/01446193.2023.2164934 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2164934 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:6:p:445-456 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2165695_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Lynn Vosman Author-X-Name-First: Lynn Author-X-Name-Last: Vosman Author-Name: Tom B. J. Coenen Author-X-Name-First: Tom B. J. Author-X-Name-Last: Coenen Author-Name: Leentje Volker Author-X-Name-First: Leentje Author-X-Name-Last: Volker Author-Name: Klaasjan Visscher Author-X-Name-First: Klaasjan Author-X-Name-Last: Visscher Title: Collaboration and innovation beyond project boundaries: exploring the potential of an ecosystem perspective in the infrastructure sector Abstract: Current societal challenges demand enduring engagement and the implementation of innovations. Unfortunately, the project-based nature of the construction industry fails to offer suitable conditions for innovation and change in terms of building long-term relationships and aligning incentives beyond the project scope. In this paper, we explore the potential of an innovation ecosystem perspective to reach sector-wide goals related to societal challenges in the infrastructure sector. Accordingly, five Dutch infrastructure cases were studied in terms of four characteristics: (1) actor heterogeneity; (2) strategic alignment of actors; (3) alignment with respect to a value proposition; and (4) governance structure. We found that the innovation ecosystem perspective has the potential to contribute to innovation in the sector, especially when specific innovations or knowledge building are pursued. In particular, the long-term perspective to collaboration in relation to addressing societal challenges and the shift to more relational ways of governance were found promising avenues for incorporation in the industry. The innovation ecosystem perspective in infrastructure, however, also poses substantial organizational, cultural, and processual challenges, such as adopting novel practices with respect to collaboration and establishing continuing informal relationships beyond the public procurement context. Journal: Construction Management and Economics Pages: 457-474 Issue: 6 Volume: 41 Year: 2023 Month: 6 X-DOI: 10.1080/01446193.2023.2165695 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2165695 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:6:p:457-474 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2186454_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Vishal Singh Author-X-Name-First: Vishal Author-X-Name-Last: Singh Author-Name: Marzia Bolpagni Author-X-Name-First: Marzia Author-X-Name-Last: Bolpagni Title: Effects of trigger events on innovation behaviour: insights from the data collected from construction professionals during COVID-19 Abstract: During the COVID-19 pandemic, several instances of innovation were reported in construction and other sectors, consistent with previously noted spikes in innovation activities during crises and environmental perturbations. Yet the behavioural mechanisms and factors leading to changes in the innovation behaviour of actors under environmental perturbation are not adequately understood. This paper studies such behavioural mechanisms and factors, building on the Excitable Innovation Behaviour Model (EIBM), which explains the voluntary or coercive change in the innovation behaviour of actors in terms of their stable state needs and excited stated needs. The findings build on data collected through an online survey (N = 266) and interviews (N = 14) during the COVID situation. The results show that environmental perturbations can trigger both an increase and decrease in innovation activities. Actors’ network dependencies, motivation, and years of experience influence their innovation behaviour. Environmental perturbation triggers accelerated alignment and shared prioritization of the needs of the different stakeholders, resulting in commitment and timely actions towards innovation from each stakeholder. Actors’ ability and financial stability at the time of the excitation trigger mediate their innovation behaviour, revealing similarities and differences between EIBM and Fogg’s Behavioural Model of persuasion. The grounding of EIBM in behavioural theories makes it potentially generalizable and compatible with other behavioural models and theories on innovation. The underlying state-change mechanisms in EIBM also make it amenable to developing a parametric and computational model of innovation adoption and diffusion. The research insights will inform innovation management strategies, including technology adoption roadmaps in the construction sector. Journal: Construction Management and Economics Pages: 587-607 Issue: 7 Volume: 41 Year: 2023 Month: 7 X-DOI: 10.1080/01446193.2023.2186454 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2186454 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:7:p:587-607 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2187071_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Shanjing (Alexander) Zhou Author-X-Name-First: Shanjing (Alexander) Author-X-Name-Last: Zhou Author-Name: Luigi Mosca Author-X-Name-First: Luigi Author-X-Name-Last: Mosca Author-Name: Jennifer Whyte Author-X-Name-First: Jennifer Author-X-Name-Last: Whyte Title: How the reliability of external competences shapes the modularization strategies of industrialized construction firms Abstract: Firms modularize as they move into industrialized construction. Prior research highlights the importance of their modularization strategies, arguing that firms can either build the competence for modularization internally or can source them externally. To understand what shapes a firm’s choice to use external competences in its modularization strategy, we studied three leading construction firms. In this multiple case study, Alpha, Beta and Gamma are leaders in Asian markets, using reinforced concrete solutions in high-rise industrialized construction. Where external competences are available, our analyses show the work firms do to make them reliable and that their choice to use external competences is shaped by their reliability. Alpha modularized in a context with little available external competences, so it built new competences in-house; Beta chose to use the externally available manufacturing and assembly competences, using standards, remote monitoring and control of product architectures to make them reliable for their use in modularization; Gamma had available competences in the external context and initially sought to use them, but reliability concerns led to it modularizing by acquiring the firms to bring these competences in-house. Our contribution is to show how ensuring the reliability of external competences shapes modularization strategies. Further, we have identified actions that firms can adopt to make external competences reliable through: (1) use of international standards, (2) quality control procedures, (3) control of product architectures, and 4) acquisition of external competences. We provide implications for practitioners and policy makers seeking to transition to industrialized construction; and discuss new areas for research. Journal: Construction Management and Economics Pages: 608-619 Issue: 7 Volume: 41 Year: 2023 Month: 7 X-DOI: 10.1080/01446193.2023.2187071 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2187071 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:7:p:608-619 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2171450_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Qinjun Liu Author-X-Name-First: Qinjun Author-X-Name-Last: Liu Author-Name: Yingbin Feng Author-X-Name-First: Yingbin Author-X-Name-Last: Feng Author-Name: Kerry London Author-X-Name-First: Kerry Author-X-Name-Last: London Author-Name: Peng Zhang Author-X-Name-First: Peng Author-X-Name-Last: Zhang Title: Coping strategies for work and cultural stressors in multicultural construction workplaces: a study in Australia Abstract: Existing coping theories typically position coping as a reactive approach to managing mental health. Intercultural coping was proposed to positively deal with stressors and alleviate the negative impacts of stressors on mental health outcomes in multicultural workplaces. This study aims to investigate the role of intercultural coping strategies in influencing the relationships between stressors and mental health outcomes in multicultural construction workplaces. Data were collected from 252 construction workers in Australia using online questionnaire survey. Data were analysed using the structural equation modelling (SEM) technique. The results revealed the moderating effect of positive coping strategies on the stressor-psychological outcome relationship. A worker who is open to cultural dissimilarity tends to suffer less the adverse effect of cultural stressors on mental health. A worker with cognitive complexity is less susceptible to the adverse impact of work stressors on mental health. Whereas, a worker who is performance-oriented is more vulnerable to the impact of work stressors on mental health. This study may contribute to the existing body of work by uncovering the moderating role of positive coping strategies and providing targeted and effective coping strategies in multicultural construction workplaces. Journal: Construction Management and Economics Pages: 537-553 Issue: 7 Volume: 41 Year: 2023 Month: 7 X-DOI: 10.1080/01446193.2023.2171450 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2171450 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:7:p:537-553 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2172195_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Fred Sherratt Author-X-Name-First: Fred Author-X-Name-Last: Sherratt Author-Name: Ani Raiden Author-X-Name-First: Ani Author-X-Name-Last: Raiden Title: Taking a new view for researching occupational safety in construction: site safety practice Abstract: The “New View” of occupational safety is gaining increased attention within both the construction industry and its associated academe. With the potential to overcome the current plateau in accident rates and support the further enhancement of occupational safety on sites, the “New View” offers an alternative approach to more traditional command driven safety management and instead takes a sociotechnical perspective, valorising the workers and acknowledging their contributions to the system in the form of adaptability and resilience. Yet empirical research of “New View” thinking and practice within construction is lacking. Meaningful research in this space demands non-positivistic approaches able to reveal nuanced and local insights able to inform and illuminate “New View” practices and the contexts in which they could potentially be implemented on sites. Here, we make a methodological contribution with the aim to advance empirical research in this space. Social practice theory is employed and evaluated as an approach able to make such a useful contribution. Through the exploration and explication of the block of “site safety practice,” we demonstrate the utility of this theoretical approach for “New View” researchers, whilst also making a fundamental contribution to knowledge in the form of insights of the local and situated contexts, in which “New View” thinking could be practically applied. Journal: Construction Management and Economics Pages: 554-575 Issue: 7 Volume: 41 Year: 2023 Month: 7 X-DOI: 10.1080/01446193.2023.2172195 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2172195 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:7:p:554-575 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2181980_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Pablo Ballesteros-Pérez Author-X-Name-First: Pablo Author-X-Name-Last: Ballesteros-Pérez Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Alberto Cerezo-Narváez Author-X-Name-First: Alberto Author-X-Name-Last: Cerezo-Narváez Author-Name: Manuel Otero-Mateo Author-X-Name-First: Manuel Author-X-Name-Last: Otero-Mateo Author-Name: Andrés Pastor-Fernández Author-X-Name-First: Andrés Author-X-Name-Last: Pastor-Fernández Title: Gates’ bidding model (revisited) Abstract: Gates’ (1967) bidding model was one of the earliest proposed for construction bidding. Its most celebrated formula allows for calculating the probability of any bidder submitting the lowest bid when competing against several known competitors. This model has been shown to outperform many recent bidding models. However, it also suffers from important limitations that keep it from being applied in wider contexts. In this paper, we overcome two of such limitations. First, we extend Gates’ model to calculate the probability of a bidder ending in any position other than the first (lowest). Second, we propose an approach for extrapolating the probabilities of all bidders underbidding each other, even in those situations of limited access to historical bidding information. Overcoming these limitations significantly enhances Gates’ model in two ways. First, it allows anticipating the probabilities of winning an auction in best value auctions where bidders who submitted a competitive but not necessarily the lowest bid can still win. Second, our extension allows applying Gates’ formula in situations of incomplete information. This is especially interesting when some bidders have not met in previous auctions and there is no information from them individually underbidding each other. Journal: Construction Management and Economics Pages: 576-586 Issue: 7 Volume: 41 Year: 2023 Month: 7 X-DOI: 10.1080/01446193.2023.2181980 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2181980 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:7:p:576-586 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2192040_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Pekka Rajala Author-X-Name-First: Pekka Author-X-Name-Last: Rajala Author-Name: Antti Ylä-Kujala Author-X-Name-First: Antti Author-X-Name-Last: Ylä-Kujala Author-Name: Tiina Sinkkonen Author-X-Name-First: Tiina Author-X-Name-Last: Sinkkonen Author-Name: Timo Kärri Author-X-Name-First: Timo Author-X-Name-Last: Kärri Title: Building renovation business: the effects of specialization on profitability Abstract: The importance of renovations is widely recognized, for example, due to renovation backlogs in the developed countries. The urbanization megatrend, among many other factors, is still increasing the need for renovations in the long run. One approach to review the renovation issue is the profitability of the companies that will tackle the increasing demand in the sector. By applying mainly quantitative methods, using the 15-year timeframe (2005–2019) and earnings before interest, taxes, depreciation, and amortization (EBITDA) and return on assets (ROA) as measures, this study reviewed the profitability of the building renovation (BR) companies from two perspectives: how does focusing on certain special services (specialized BR) fare compared to focusing on a wide range of services (wide BR) and what are the profitability differences among specialized BR companies? The results show that, when reviewing the research timeframe in total, there are no differences in profitability between wide BR and specialized BR companies. However, an annual review reveals that specialized BR companies are profitability-wise more vulnerable to economic cycles. Among the specialized BR companies, there are several differences in profitability; classically, specialization in a niche market with a deliberate customer base and low competition level is gainful. The research provides new information about an unresearched area encouraging companies to re-think their strategic choices considering service specialization and performance. Journal: Construction Management and Economics Pages: 687-702 Issue: 8 Volume: 41 Year: 2023 Month: 8 X-DOI: 10.1080/01446193.2023.2192040 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2192040 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:8:p:687-702 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2189739_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Thi Binh An Duong Author-X-Name-First: Thi Binh An Author-X-Name-Last: Duong Author-Name: Tho Pham Author-X-Name-First: Tho Author-X-Name-Last: Pham Author-Name: Quang Huy Truong Author-X-Name-First: Quang Huy Author-X-Name-Last: Truong Author-Name: Kevin Nguyen Author-X-Name-First: Kevin Author-X-Name-Last: Nguyen Author-Name: Cong Hiep Pham Author-X-Name-First: Cong Hiep Author-X-Name-Last: Pham Author-Name: Thu-Hang Hoang Author-X-Name-First: Thu-Hang Author-X-Name-Last: Hoang Author-Name: Thanh Hai Pham Author-X-Name-First: Thanh Hai Author-X-Name-Last: Pham Title: Risk in sustainable construction supply chains: construct development and measurement validation Abstract: Although previous studies have focused on different aspects of green/sustainability risk in construction supply chains (SCs) such as identification of risks or the linkage between characteristics of stakeholders and risk assessment, research on this topic is still quite limited. One important reason for this limitation is the absence of valid and reliable measurement of risk, resulting in the impossibility to discriminate between risk constructs. Therefore, the current study is performed to develop and then validate a measurement scale of risk in sustainable construction SCs. The data are collected from a large-scale survey supported by the Japanese government to promote sustainable socioeconomic development for the ASEAN (Association of Southeast Asian Nations) region, with the participation of 283 firms in Vietnam. Exploratory factor analysis (EFA) and confirmatory factor analysis (CFA) are used to test the reliability, convergent validity, and discriminant validity of the risk constructs. The results indicate that all tests strongly support the measurement scale, and seven reliable risk constructs are identified including supply, demand, internal processes, information, financial, time, and environmental risks. This study also presents opportunities for further developing research on risk management (especially the three phases: risk assessment, risk mitigation, and risk monitoring) in sustainable construction SCs. Journal: Construction Management and Economics Pages: 634-650 Issue: 8 Volume: 41 Year: 2023 Month: 8 X-DOI: 10.1080/01446193.2023.2189739 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2189739 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:8:p:634-650 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2189278_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Sina Moradi Author-X-Name-First: Sina Author-X-Name-Last: Moradi Author-Name: Piia Sormunen Author-X-Name-First: Piia Author-X-Name-Last: Sormunen Title: Revisiting the concept of waste and its causes in construction from analytical and conceptual perspectives Abstract: The phenomenon of waste in the construction industry has received considerable attention from the project professionals since the emergence of lean construction. In the research community, however, identifying causes of waste together with waste detection and elimination in the context of construction have been addressed in a limited manner. Moreover, there are very few studies, if any, which have tried to revisit the concept of waste ontologically and to look into the causes of waste through the lens of their relation to other elements in construction projects such as delivery elements and lifecycle phases. Therefore, this study aims to fill this knowledge gap through developing a novel conceptualization of waste and exploring causes of waste in construction projects to reveal their connection to various project attributes. To do so, a systematic literature study was conducted through which relevant studies were located and analysed to achieve the purposes of this study. The findings propose a novel conceptualization of waste and value based on their overlooked components. Moreover, the results present a model which reveals the connection between the identified causes of waste and project attributes (life cycle phases, relevant party, project delivery element, and waste categories in general). The obtained results can be insightful for project practitioners and the research community to reach in-depth understanding of the waste concept. Journal: Construction Management and Economics Pages: 621-633 Issue: 8 Volume: 41 Year: 2023 Month: 8 X-DOI: 10.1080/01446193.2023.2189278 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2189278 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:8:p:621-633 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2190992_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Lilly Rosander Author-X-Name-First: Lilly Author-X-Name-Last: Rosander Author-Name: Anna Kadefors Author-X-Name-First: Anna Author-X-Name-Last: Kadefors Title: Implementing relational contracting in a public client organization: the influence of policy clashes, resources and project autonomy Abstract: Relational contracting models are increasingly being used for large and complex public infrastructure construction projects, but both practices and outcomes still widely vary. When analyzing the causes of failures and successes, most studies have focused on practices at the project level. In this paper, we add to the current understanding of relational contracting in public construction by examining the influence of factors at the organizational and institutional levels. We develop a framework based on theories of policy implementation and analyze two projects piloting a new Early Contractor Involvement model in a large public infrastructure client organization. In this case, a previous marketization policy, prescribing low client involvement in project processes, interfered with the relational contracting policy. This policy clash was not openly acknowledged from the start, despite causing significant confusion and frustration at the project level, but became recognizable largely through its consequences for resource allocation and managerial attention. We conclude that policy ambiguities, combined with a project-based implementation context, produce local interpretations and variations in relational contracting models. When project autonomy is high, industry-level agreements, standards and resources are important to align practices also between projects within the same client organization. Journal: Construction Management and Economics Pages: 651-669 Issue: 8 Volume: 41 Year: 2023 Month: 8 X-DOI: 10.1080/01446193.2023.2190992 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2190992 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:8:p:651-669 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2190993_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Yu-Lin Huang Author-X-Name-First: Yu-Lin Author-X-Name-Last: Huang Author-Name: Tsen-Chin Lin Author-X-Name-First: Tsen-Chin Author-X-Name-Last: Lin Title: Compound deferrable options for the valuation of multi-stage infrastructure investment projects Abstract: Multi-stage planning is common for expanding infrastructure complexes or networks. Previous real-option studies developed a sequential compound call option (SCCO) for evaluating multi-stage infrastructure investment projects, including evaluating abandonment options during individual pre-scheduled investment stages. In practice, however, investment schedules involve risk and uncertainties forcing investors to change plans, raising an important issue regarding investors having more options at each commencement date. This study introduces a new model, the sequential compound deferrable call option (SCDCO), incorporating deferment options for each fold in an n-fold setting and generalizing the exercise of each deferment option into mn periods. A closed-form solution to the valuation of SCDCO is derived accordingly. A real-world case demonstrates that introducing deferment options increases project value, but the marginal benefit of increasing deferment time diminishes. The presence of dedicated assets for the usage of future expansions can also increase project value, but this increase is restricted by deferment options. Furthermore, the investment cost growth with an increase of deferment time rapidly decreases project value and vice versa. Inflation or deflation is therefore important to consider in deferment decisions. Finally, although deferment options only produce limited project value, they have the flexibility to manage risks, changes, and budgetary constraints. Journal: Construction Management and Economics Pages: 670-686 Issue: 8 Volume: 41 Year: 2023 Month: 8 X-DOI: 10.1080/01446193.2023.2190993 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2190993 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:8:p:670-686 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2195195_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Jeppe Zielinski Nguyen Ajslev Author-X-Name-First: Jeppe Zielinski Nguyen Author-X-Name-Last: Ajslev Author-Name: Jeppe Lykke Møller Author-X-Name-First: Jeppe Lykke Author-X-Name-Last: Møller Title: The art of role-switching–positioning practices and the relational roles of OSH coordinators in the Danish construction industry Abstract: The occupational safety and health (OSH) coordinator is an important figure for improving OSH in the construction industry. Working as an OSH coordinator is complicated, and coordinators must attend to many different roles to improve OSH. Recent research has even questioned the effectiveness of OSH professional practice. This points to a need to understand how OSH coordinators position themselves in relation to different roles when performing effective OSH coordination. This study aims to expand upon this question by analyzing how OSH coordinators position themselves in situations leading to the implementation of OSH measures. In the study, practices of OSH coordinators in the Danish construction industry are analyzed by “zooming in” on micro-sociological positioning practices observed during 107 days of ethnographic fieldwork, e.g. speech acts, and by “zooming out” on the links between these positioning practices and the implementation of OSH measures. The study contributes to OSH research and practice in several ways; firstly, the study conceptualizes a typology of practices connected to the relational roles of OSH professionals. Secondly, it expands upon how negotiating for the implementation of OSH measures is a relationally complex matter in which OSH coordinators switch between positioning themselves as alliance builders, authorities, challengers, experts, influencers, and champions. Improving attention and education to accommodate this knowledge may contribute to the creation of more tangible borders around the OSH professional practice, and more impactful OSH practice in terms of implementing measures. Journal: Construction Management and Economics Pages: 703-723 Issue: 9 Volume: 41 Year: 2023 Month: 9 X-DOI: 10.1080/01446193.2023.2195195 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2195195 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:9:p:703-723 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2196431_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Lei Cui Author-X-Name-First: Lei Author-X-Name-Last: Cui Title: Collusion governance strategies under the construction supervision system in China Abstract: The construction supervision system plays an essential role in promoting the development of Chinese construction industry. However, as the core of the supervision system, the supervisor may deviate from duty and collude with the contractor to seek more profits. This paper investigates optimal collusion governance strategies under the prevailing supervision system. This paper develops a game-theoretic framework including an owner, a supervisor and a contractor, wherein all players interact and pursue to maximize their self-profits. The collusion equilibrium and the collusion-proof equilibrium are explored. Since the game contains multiple rounds of strategic interactions, backward induction is applied to ensure subgame perfection. The results show that collusion makes the supervision system not always in the owner’s interests. For projects recommended to implement the supervision system, the boundary condition for the owner applying the supervision system is derived. For projects required mandatory supervision, the owner prefers to let the contractor and supervisor collude under certain conditions and guard against collusive behaviours otherwise. This study contributes to the theory by exploring the effects of covert collusion and optimal governance strategies. In addition, this study can assist the owner in better understanding and managing agent collusion to safeguard the project quality. Journal: Construction Management and Economics Pages: 724-738 Issue: 9 Volume: 41 Year: 2023 Month: 9 X-DOI: 10.1080/01446193.2023.2196431 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2196431 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:9:p:724-738 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2197651_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Bowen Liu Author-X-Name-First: Bowen Author-X-Name-Last: Liu Author-Name: Peng Huang Author-X-Name-First: Peng Author-X-Name-Last: Huang Author-Name: Wenxue Lu Author-X-Name-First: Wenxue Author-X-Name-Last: Lu Title: How to foster contractors’ in-role and extra-role behavior: the role of interpersonal ties and dependence asymmetry Abstract: Boundary spanners of construction projects are representatives of the interaction between the client and the contractor, and their good interpersonal ties are a catalyst for the development of cooperation between the two organizations and play an important role in project success. However, in the existing research, the relationship between interpersonal ties and cooperative behavior is still controversial, and little attention is paid to the individual level of construction projects. Therefore, this study explores the influence mechanism of each dimension of boundary spanners’ interpersonal ties (obligatory ties, instrumental ties, and affective ties) on contractors’ cooperative behavior (in-role and extra-role behavior) and the moderating effect of dependence asymmetry. The data from 248 questionnaires completed by practitioners in the Chinese construction industry show that obligatory ties positively affect contractors’ in-role and extra-role behavior, and the correlation between obligatory ties and in-role and extra-role behavior is positively moderated by dependence asymmetry. Moreover, instrumental ties are positively related to contractors’ in-role and extra-role behavior. However, affective ties only positively affect contractors’ extra-role behavior, and this effect is negatively moderated by dependence asymmetry. These findings have implications for clients and contractors and can help them maintain their relationships, thus improving project performance. Journal: Construction Management and Economics Pages: 739-757 Issue: 9 Volume: 41 Year: 2023 Month: 9 X-DOI: 10.1080/01446193.2023.2197651 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2197651 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:9:p:739-757 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2205158_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Rebecca Dickson Author-X-Name-First: Rebecca Author-X-Name-Last: Dickson Title: What’s it going to take? Lessons learned from COVID-19 and worker mental health in the Australian construction industry Abstract: In Australia, rates of suicide and poor mental health among construction workers were high before the COVID-19 pandemic. “Lock downs”, “restrictions”, “social distancing” and legislative changes responding to the pandemic have likely exacerbated the working conditions that foster poor mental health. This study analyses the way in which workplace health and safety (WHS) is regulated in Australia against the backdrop of existing research relating to the development of Australia’s WHS laws, and the state of mental health of those working in Australia’s construction industry. This study was conducted using a doctrinal research methodology and utilising legal theory. This study assesses the capacity of the Australian WHS regulatory system to protect construction workers’ mental health by examining and interpreting key provisions in Australia’s WHS laws. It then uses a regulatory theory, responsive regulation, to explain the inconsistency between the capacity of those laws to safeguard mental health and the very poor state of mental health of Australia’s construction workers. The conclusion reached is that there is scope to improve current WHS laws to better protect construction workers’ mental health. A recommendation is made, that current WHS laws are changed to prescribe minimum standards of worker mental health, and mandate control measures to minimise and/or eliminate psychosocial risks. It is submitted that these changes in the law will contribute to a changed culture in Australia’s construction sector, which is supportive of mentally healthy workplaces and workers. Journal: Construction Management and Economics Pages: 758-780 Issue: 9 Volume: 41 Year: 2023 Month: 9 X-DOI: 10.1080/01446193.2023.2205158 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2205158 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:9:p:758-780 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2205159_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Frank Ato Ghansah Author-X-Name-First: Frank Ato Author-X-Name-Last: Ghansah Author-Name: Weisheng Lu Author-X-Name-First: Weisheng Author-X-Name-Last: Lu Title: Responses to the COVID-19 pandemic in the construction industry: a literature review of academic research Abstract: Over the past 3 years, the global construction sector has been severely affected by the noxious coronavirus (COVID-19) pandemic. Visionary construction stakeholders, including governments, practitioners, and academia, all have been actively devising strategies to deal with the crisis caused by the pandemic. Despite the rich contributions by academia, an in-depth review of their research works to understand how the pandemic has been handled to position the construction industry for post-pandemic actions and future pandemics is hitherto lacking. Hence, an up-to-date literature review is conducted in this study to better understand this terra incognita. It does so by adopting a six-step thematic analysis of 159 empirical peer-reviewed research articles in relation to COVID-19 on construction. The review discovered a growing research interest from different countries from 2020 to 2022. The existing studies can be put under four major topics, namely the COVID-19 impacts, challenges and opportunities, responding strategies, and post-COVID-19 interventions. A framework consisting of four categories of responding strategies, namely vaccination, personal responsibility of workers, government-instructional practices, and organisation-based approaches, is proposed through the lens of the socio-technical system theory to handle the pandemic crisis in construction. Limitations of the existing studies were further identified. Four pertinent research directions were finally proposed: building upon and testing the proposed COVID-19 response framework, adoption of more advanced innovative strategies to increase productivity amid pandemics and survive the risk of future pandemics, beyond the technological response to COVID-19 in construction, and post-pandemic view of the construction industry. This study contributes to the knowledge body by providing a candid evaluation of the knowledge contributed by academia to deal with the risks of future pandemics in the global construction industry. Journal: Construction Management and Economics Pages: 781-803 Issue: 9 Volume: 41 Year: 2023 Month: 9 X-DOI: 10.1080/01446193.2023.2205159 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2205159 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:9:p:781-803 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2210693_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Cheng Wu Author-X-Name-First: Cheng Author-X-Name-Last: Wu Author-Name: Naomi Brookes Author-X-Name-First: Naomi Author-X-Name-Last: Brookes Author-Name: Christine Unterhitzenberger Author-X-Name-First: Christine Author-X-Name-Last: Unterhitzenberger Author-Name: Nancy Olson Author-X-Name-First: Nancy Author-X-Name-Last: Olson Title: The role of lean information flows in disaster construction projects: exploring the UK’s Covid surge hospital projects Abstract: A substantive body of work in project studies argues that an “information flow” lens is very useful in exploring the project management of construction. This paper posits that this is even more applicable to disaster construction projects and, furthermore, lean information flow may play a role in swiftly delivering the disaster construction project. The paper uses the qualitative empirics of the delivery of the UK’s Covid surge hospital projects to demonstrate that lean information flows were employed in these projects and assisted in enabling delivery at speed. The paper also describes the autopoietic governance conditions that are necessary for lean information flows to flourish in disaster construction projects and the role that trust may play in these conditions. It warns against some of the drawbacks in enabling lean communication through autopoietic governance. Journal: Construction Management and Economics Pages: 840-858 Issue: 10 Volume: 41 Year: 2023 Month: 10 X-DOI: 10.1080/01446193.2023.2210693 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2210693 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:10:p:840-858 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2209667_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Buddhini Ginigaddara Author-X-Name-First: Buddhini Author-X-Name-Last: Ginigaddara Author-Name: Srinath Perera Author-X-Name-First: Srinath Author-X-Name-Last: Perera Author-Name: Yingbin Feng Author-X-Name-First: Yingbin Author-X-Name-Last: Feng Author-Name: Payam Rahnamayiezekavat Author-X-Name-First: Payam Author-X-Name-Last: Rahnamayiezekavat Author-Name: Russell Thomson Author-X-Name-First: Russell Author-X-Name-Last: Thomson Title: Development of offsite construction skill profile prediction models using mixed-effect regression analysis Abstract: Offsite construction (OSC) transfers onsite construction activities to factory-based processes utilising technological advancements, resulting in new and emerging skills while causing some existing skills to be changed and others to be redundant. However, there are no established methods to systematically quantify these OSC skill requirements. This paper presents OSC skill prediction models while highlighting the process of model development for future research. The aim of these models is to predict skills using a comparable measure, manhours/m2. A skill classification with six skill categories was used to analyse OSC skills. Numerical model development methods were reviewed, and mixed-effect regression modelling was selected for model development. The skills data needed for regression modelling was collected using eight case studies. Predominantly panelised and modular OSC projects were used to collect skills data. The skill prediction models were validated using further case study data and an expert forum. Comparatively, modules OSC type requires higher skill quantities than panels, for all the six skill categories analysed. Onsite and offsite skill requirements vary for different OSC types. Additionally, complex, non-linear relationships were recognised between OSC types and the utilisation of their skills. This research presents unique OSC skill prediction models that can provide early-stage advice to policymakers, project planners and manufacturers on OSC skill requirements. It also provides a novel methodology to develop predictive models for specific industry scenarios that have non-linear and complex relationships. Journal: Construction Management and Economics Pages: 820-839 Issue: 10 Volume: 41 Year: 2023 Month: 10 X-DOI: 10.1080/01446193.2023.2209667 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2209667 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:10:p:820-839 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2211179_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Qian Xu Author-X-Name-First: Qian Author-X-Name-Last: Xu Author-Name: Bon-Gang Hwang Author-X-Name-First: Bon-Gang Author-X-Name-Last: Hwang Author-Name: Rui Qi Choo Author-X-Name-First: Rui Qi Author-X-Name-Last: Choo Author-Name: Xian Zheng Author-X-Name-First: Xian Author-X-Name-Last: Zheng Author-Name: Lei Kong Author-X-Name-First: Lei Author-X-Name-Last: Kong Author-Name: Qian-Cheng Wang Author-X-Name-First: Qian-Cheng Author-X-Name-Last: Wang Author-Name: Xuan Liu Author-X-Name-First: Xuan Author-X-Name-Last: Liu Title: Comparison of construction project risks before and during COVID-19 in Singapore: criticality and management strategies Abstract: The outbreak of COVID-19 pandemic has caused worldwide disruption in construction industry. Although an increasing number of construction projects have been resumed, construction industry still faces significant risks due to the pandemic. The comparison of risk factors faced by construction industry before and during the pandemic helps us understand the dynamic risk transformation brought by the pandemic; however, few efforts have been made to understand the risk changes in construction sector. This study assessed the likelihood, impact, and criticality of risks brought by the pandemic in construction industry through a comparative analysis using Singapore as an example and proposed an innovative risk management solution to manage these risks accordingly. Survey questionnaires and semi-structured interviews were adopted. The finding indicated effective relief measures from the government to relieve the contractors’ liability in Singapore. Due to the pandemic, prioritized likelihood of risk occurrence changed from financial risk to labour shortage. Moreover, the finding highlighted that safety and health risks required significant attention, as they were ranked top in both periods. This study aids the understanding of how prioritized risks shifted during the pandemic and enlightens a promising and scalable risk management solution for industry stakeholders to establish better recovery from similar pandemics. Journal: Construction Management and Economics Pages: 875-891 Issue: 10 Volume: 41 Year: 2023 Month: 10 X-DOI: 10.1080/01446193.2023.2211179 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2211179 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:10:p:875-891 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2210695_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Erwin Biersteker Author-X-Name-First: Erwin Author-X-Name-Last: Biersteker Author-Name: Alfons Van Marrewijk Author-X-Name-First: Alfons Van Author-X-Name-Last: Marrewijk Title: Integrating knowledge in infrastructure projects: the interplay between formal and informal knowledge governance mechanisms Abstract: This study focuses upon knowledge governance mechanisms of integrating specialised knowledge on underground utilities in large infrastructure projects. The integration of knowledge is essential for the realisation of such projects. The study explores the formal and informal knowledge governance mechanisms in three large infrastructure projects and compares these mechanisms to reveal their effects on knowledge integration. The findings show that combining reward systems, project culture and trust are targeting the motivation of underground experts to share their knowledge and allocation of authority and project network are mechanisms aimed at the coordination between managers and underground experts to integrate knowledge. We contribute to studies on knowledge governance by enabling further empirical insight in the relationships between formal and informal mechanisms. Journal: Construction Management and Economics Pages: 859-874 Issue: 10 Volume: 41 Year: 2023 Month: 10 X-DOI: 10.1080/01446193.2023.2210695 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2210695 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:10:p:859-874 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2208238_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Michelle Turner Author-X-Name-First: Michelle Author-X-Name-Last: Turner Author-Name: Sarah Holdsworth Author-X-Name-First: Sarah Author-X-Name-Last: Holdsworth Title: Developing resilience: examining the protective factors of early career construction professionals Abstract: Work in construction is highly demanding and stressful. Graduates must navigate these imminent challenges as well as the challenges associated with transition as they enter their new learning environment and seek to establish their professional identity. This research examined how resilience can support the transition of early career construction professionals from university into the workforce. Interviews were conducted with twenty-five participants and data was thematically analyzed. Challenges experienced by participants related to structural and cultural conditions of working in construction as well as the transitional career stage. Internal protective factors of emotional objectivity, reflection, goal setting, and physical and mental health emerged as important in positively responding to workplace adversity. Task-related and emotion-related organizational support were considered as important external protective factors that can facilitate the development of internal protective factors. Yet, formal organizational support was often not provided. Findings can inform the design of work and workplace programs which support this new cohort of workers to adapt to an unfamiliar and demanding work environment, as well as provide guidance to university construction management programs on ways to support the development of internal protective factors of emerging professionals. Furthermore, it is expected that students transitioning from university to work, irrespective of discipline, will progress through the three stages of the liminal experience and its possible that access to protective factors supporting resilience may assist students to positively move through this process. Journal: Construction Management and Economics Pages: 805-819 Issue: 10 Volume: 41 Year: 2023 Month: 10 X-DOI: 10.1080/01446193.2023.2208238 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2208238 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:10:p:805-819 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2214252_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Pernilla Gluch Author-X-Name-First: Pernilla Author-X-Name-Last: Gluch Author-Name: Stina Hellsvik Author-X-Name-First: Stina Author-X-Name-Last: Hellsvik Title: The influence of multiple logics on the work of sustainability professionals Abstract: Organizational aspects, rather than technological ones, often represent the greatest barrier in the transition toward sustainable construction. However, despite sustainability professionals’ recognized role in sustainable development, few studies have focused on such professionals’ work. To understand the intrinsic influence of multiple institutional logics on the work and agency of sustainability professionals, we conducted 31 semi-structured interviews with sustainability professionals in Sweden’s construction industry. Building on the theoretical framework of institutional logics, the findings show how sustainability professionals’ everyday work, depending on the work conditions, is a blend of thankless, rewarding collaborative, and visionary work. In the organizational context of sustainable construction, characterized by dynamism and ambiguity, different institutional logics are combined in different ways to respond to shifting demands and problems. To maintain agency, sustainability professionals need to shift and balance their work depending on which logics are temporarily central. Showcasing how professionals cope with institutional contexts defined by multiple logics, the paper highlights the complexity involved in managing the vastness and ambiguity of sustainability and how it requires individuals to be both flexible and sensitive to the existence of multiple logics in their immediate context. Journal: Construction Management and Economics Pages: 893-909 Issue: 11-12 Volume: 41 Year: 2023 Month: 12 X-DOI: 10.1080/01446193.2023.2214252 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2214252 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:11-12:p:893-909 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2216319_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Xiuqin Wang Author-X-Name-First: Xiuqin Author-X-Name-Last: Wang Author-Name: Shufan Wang Author-X-Name-First: Shufan Author-X-Name-Last: Wang Author-Name: Ying Gao Author-X-Name-First: Ying Author-X-Name-Last: Gao Title: Optimal equity structure of PPP projects when private-sector shareholders’ “investor-contractor” dual roles is considered Abstract: More often than not, in typical public-private partnership (PPP) projects, the construction contractor (CC) and operating contractor (OC) serve as shareholders simultaneously. CC and OC shareholders have different payback periods and paths, which may result in opportunistic risk. Therefore, an optimal equity structure is required to lower this risk. Based on cooperative game theory, a game model was developed to determine the optimal equity structure between CC and OC. The findings indicate that when the relative complexity of PPP project construction is higher than that of operation, CC should be given a higher equity ratio. Conversely, when the relative complexity of PPP project operation is higher, OC should be given a higher equity ratio. When the construction and operation of the project are equally complex, allocating equity ratios according to market value can reduce transaction costs, based on transaction cost theory. The findings also suggest that increasing CC’s equity ratio can effectively motivate them to better complete the construction work in the long run when the benefits of construction quality are significant. As for OC, increasing bonuses is also an effective incentive method. These findings provide insights into the design of the equity structure of PPP projects to enhance their success. Journal: Construction Management and Economics Pages: 910-925 Issue: 11-12 Volume: 41 Year: 2023 Month: 12 X-DOI: 10.1080/01446193.2023.2216319 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2216319 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:11-12:p:910-925 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2218498_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Réka Andersson Author-X-Name-First: Réka Author-X-Name-Last: Andersson Author-Name: Maria Eidenskog Author-X-Name-First: Maria Author-X-Name-Last: Eidenskog Title: Beyond barriers – exploring resistance towards BIM through a knowledge infrastructure framework Abstract: Building information modelling (BIM) is a digital tool that offers the possibility to collect and share a multitude of data about a building and increase collaboration across professional borders. However, the uptake of BIM in the construction industry has been relatively slow, and previous research has shown how BIM creates tensions in the workplace. In this article, we explore the impact of BIM on socio-technical knowledge practices, to understand how these are enabled or restricted by the use of BIM. Through a qualitative case study in Sweden, this article analyses BIM through a knowledge infrastructure framework to explain the relatively slow uptake of BIM in a new light. The results show that BIM lacks embeddedness in governmental and corporate practices and regulations and that it sometimes leads to the marginalization of some professions through changed organizations and the slow process of changing complex knowledge infrastructures. This suggests that a critical discussion of the role of BIM in relation to professional flexibility, construction project process organization and power over technological development is vital for the future development of the construction sector. Journal: Construction Management and Economics Pages: 926-941 Issue: 11-12 Volume: 41 Year: 2023 Month: 12 X-DOI: 10.1080/01446193.2023.2218498 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2218498 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:11-12:p:926-941 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2220832_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Jun Wang Author-X-Name-First: Jun Author-X-Name-Last: Wang Author-Name: Xiaodong Li Author-X-Name-First: Xiaodong Author-X-Name-Last: Li Author-Name: Ashkan Memari Author-X-Name-First: Ashkan Author-X-Name-Last: Memari Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Author-Name: Yuying Zhong Author-X-Name-First: Yuying Author-X-Name-Last: Zhong Author-Name: Baabak Ashuri Author-X-Name-First: Baabak Author-X-Name-Last: Ashuri Title: Data-driven assessment on the corporate credit scoring mechanism for Chinese construction supervision companies Abstract: Construction supervision companies (CSCs) in China are engaged by owners mainly to ensure a project is constructed safely and to the quality standards as required under the law in a supervision system that has existed for decades, their credibility and integrity being vital for project safety assurance and quality control. Recently, the Chinese government has proposed a credit scoring mechanism to assess the credibility of CSCs and requested the incorporation of credit scores into the CSC selection processes for public projects. This study investigates the status quo of the credit scoring mechanism and evaluates how credit scores have impacted the competitiveness of CSCs when bidding for supervising public projects by analyzing the bidding results of 5582 public projects and credit scores of 514 CSCs in Nanjing, the capital city of Jiangsu Province in China. The results show that (1) the average CSC credit scores have followed a downward trend in recent years; (2) the score weights in the selection process have significantly increased and the scores start to impact on bidding results when their weights are at or above 4%; (3) signs of local protectionism have been observed as local CSCs have significantly higher credit scores than non-local CSCs; and (4) high scoring CSCs are more competitive than others in terms of revenue generation. The study provides an insightful understanding of China’s existing credit scoring mechanism and its impact on the selection of CSCs for public sector projects, often a major concern of policymakers, researchers, and industry practitioners. Journal: Construction Management and Economics Pages: 961-975 Issue: 11-12 Volume: 41 Year: 2023 Month: 12 X-DOI: 10.1080/01446193.2023.2220832 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2220832 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:11-12:p:961-975 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2219351_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20230119T200553 git hash: 724830af20 Author-Name: Geoff Woolcott Author-X-Name-First: Geoff Author-X-Name-Last: Woolcott Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Robyn Keast Author-X-Name-First: Robyn Author-X-Name-Last: Keast Author-Name: Dan Chamberlain Author-X-Name-First: Dan Author-X-Name-Last: Chamberlain Title: Addressing youth un/underemployment through construction social procurement: an ecological systems theory perspective Abstract: Young people’s unemployment and underemployment are acknowledged as serious and enduring problems in Australia and globally. Construction is one of the largest employers of young people, and social procurement of construction products and services has significant potential if harnessed to address this problem. This article argues that project-based intermediation offers critical new insights into how social procurement can be implemented in a construction context. Employing a single case study approach, the article uses ecological systems theory and concept mapping to examine the results of focus groups with twelve young people who transitioned to employment in the Australian construction industry through a unique project-based intermediary set up by a major contractor to meet its social procurement requirements. Addressing the current under-theorisation of social procurement research, this article offers new conceptual insights into the socio-ecological networks that influence young people’s successful transition to employment in construction. The findings also provide new practical insights for government policymakers and the construction industry into the potential role that project-based intermediation can play in addressing youth unemployment in the context of emerging social procurement policies in many countries. Journal: Construction Management and Economics Pages: 942-960 Issue: 11-12 Volume: 41 Year: 2023 Month: 12 X-DOI: 10.1080/01446193.2023.2219351 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2219351 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:41:y:2023:i:11-12:p:942-960 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2232889_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20231214T103247 git hash: d7a2cb0857 Author-Name: George Denny-Smith Author-X-Name-First: George Author-X-Name-Last: Denny-Smith Author-Name: Megan Williams Author-X-Name-First: Megan Author-X-Name-Last: Williams Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Author-Name: Riza Yosia Sunindijo Author-X-Name-First: Riza Yosia Author-X-Name-Last: Sunindijo Author-Name: Leanne Piggott Author-X-Name-First: Leanne Author-X-Name-Last: Piggott Title: What social value do Indigenous contractors create? Abstract: Governments have developed Indigenous procurement policies (IPPs) in Australia and other colonised countries with Indigenous populations to collaboratively close socioeconomic inequities experienced by Indigenous communities. These policies are widely used in the construction industry because of the volume of government spending on this sector and its significant social impact. However, recent research argues that Indigenous peoples’ notions of social value are not reflected in IPP designs, implementation, or evaluation frameworks. To investigate this claim, this research uses a holistic Aboriginal evaluation framework called ‘Ngaa-bi-nya’ to investigate how IPPs promote social value creation. Using community-based participatory research principles, semi-structured interviews were held with owners and senior managers of Indigenous construction companies in Australia. Findings highlight how social value is created by IPPs when Indigenous contractors use strategic actions to improve Indigenous socioeconomic outcomes, social and cultural development, create stronger connections in the construction industry and promote self-determination. The findings provide new conceptual and operational insights into how IPPs can create social value through partnerships with Indigenous contractors. The insights can be used by buyers and builders to strengthen social value in their supply chains through new ways of collaborative working to support social value creation. They also highlight potential risks of continuing to design and assess social value without the involvement of stakeholders for whom it is intended. Journal: Construction Management and Economics Pages: 16-34 Issue: 1 Volume: 42 Year: 2024 Month: 1 X-DOI: 10.1080/01446193.2023.2232889 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2232889 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:1:p:16-34 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2239381_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20231214T103247 git hash: d7a2cb0857 Author-Name: Basma Ben Mahmoud Author-X-Name-First: Basma Author-X-Name-Last: Ben Mahmoud Author-Name: Nadia Lehoux Author-X-Name-First: Nadia Author-X-Name-Last: Lehoux Author-Name: Pierre Blanchet Author-X-Name-First: Pierre Author-X-Name-Last: Blanchet Title: Integration mechanisms for material suppliers in the construction supply chain: a systematic literature review Abstract: The construction industry has long been criticized for its fragmented, inefficient, and uncoordinated supply chain. Thus, construction companies are actively looking for new strategies to overcome these issues and to improve their productivity. Supply chain integration is one strategy and many articles have addressed the mechanisms to help integrate the construction supply chain. However, little interest has been paid to material supplier integration despite their important role and their vast experience in the market. Hence, this study aims to identify the mechanisms that could contribute to facilitate material supplier integration in the construction supply chain. A systematic literature review was conducted to uncover the studies on this topic. A total of 310 articles were reviewed and analyzed to first reveal six integration mechanism categories: supplier qualification, supplier development program, contractual and relational policies, information sharing and integration systems, joint team working and problem solving, as well as supplier integration evaluation. Secondly, this study proposes a roadmap to illustrate when these mechanisms should be implemented in a construction project, according to both the project phases and the project delivery system. Finally, research gaps in the field are identified as well as future research directions that could be further explored by researchers and professionals. Journal: Construction Management and Economics Pages: 70-107 Issue: 1 Volume: 42 Year: 2024 Month: 1 X-DOI: 10.1080/01446193.2023.2239381 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2239381 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:1:p:70-107 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2235439_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20231214T103247 git hash: d7a2cb0857 Author-Name: Sujuan Zhang Author-X-Name-First: Sujuan Author-X-Name-Last: Zhang Author-Name: Roine Leiringer Author-X-Name-First: Roine Author-X-Name-Last: Leiringer Author-Name: Graham Winch Author-X-Name-First: Graham Author-X-Name-Last: Winch Title: Procuring infrastructure public-private partnerships: capability development and learning from an owner perspective Abstract: The expanding application of Public-Private Partnerships (PPPs) in infrastructure development and public service delivery has posed numerous commercial challenges for public sector owners (PSOs) regarding their capabilities to initiate, procure and manage PPP projects. This paper starts from the important role of owner project capabilities in infrastructure delivery and explores how PSOs learn to develop new commercial capabilities to match the PPP context. We draw on a qualitative single-case study of a state-owned enterprise in the Chinese context, which at the time of the study was in the early stages of applying the PPP approach in procuring metro line projects. The finding indicates the process of how the PSO learned to establish and develop the necessary owner commercial capabilities to procure infrastructure PPPs for the first time, such as the abilities to define project scope, procure, and manage suppliers. It sheds light on the roles of different types of learning mechanisms – experience accumulation, knowledge articulation, and knowledge codification – on capability development for PPPs over time from an owner perspective. Journal: Construction Management and Economics Pages: 35-53 Issue: 1 Volume: 42 Year: 2024 Month: 1 X-DOI: 10.1080/01446193.2023.2235439 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2235439 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:1:p:35-53 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2236249_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20231214T103247 git hash: d7a2cb0857 Author-Name: Trinh Nguyen Chau Author-X-Name-First: Trinh Author-X-Name-Last: Nguyen Chau Author-Name: Thi Thu Tra Pham Author-X-Name-First: Thi Thu Tra Author-X-Name-Last: Pham Author-Name: Thi Cam Van Ha Author-X-Name-First: Thi Cam Van Author-X-Name-Last: Ha Author-Name: Duy Nguyen Author-X-Name-First: Duy Author-X-Name-Last: Nguyen Title: Corruption, market structure, and industry competition in the Vietnamese construction sector Abstract: The Vietnamese construction sector is arguably the country’s industry most vulnerable to corruption, leading to poor functioning of the sector. This analysis empirically investigates how corruption affects competition in the construction industry, and how different market structures shape different types of corruption and its potentially different impacts. Our empirical models for industry competition are estimated on a panel of 33,045 year-observations using the Fractional Binomial Logit model. The findings demonstrate that corruption reduces competition, and that the effects of corruption depend on the type of corruption and market structure in which firms operate. We find evidence that corruption is characterized by collusion between local authorities and dominant firms in highly concentrated markets, leading to the persistent concentration of the sector in highly corrupt areas. In areas with lower corruption, corruption is characterized by bureaucratic holdups while lowered corruption increases industry competition. Petty corruption is observed in less corrupt areas while it does not affect industry competition. The finding suggests that promoting transparency in public procurement regulatory processes enhances industry competition and mitigates corruption risks associated with different market structures. Additionally, implementing reforms to ensure equitable access to reliable public reporting and services can facilitate a more concentrated yet efficient industry structure. Journal: Construction Management and Economics Pages: 54-69 Issue: 1 Volume: 42 Year: 2024 Month: 1 X-DOI: 10.1080/01446193.2023.2236249 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2236249 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:1:p:54-69 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2226261_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20231214T103247 git hash: d7a2cb0857 Author-Name: Jorge Rueda-Benavides Author-X-Name-First: Jorge Author-X-Name-Last: Rueda-Benavides Author-Name: Douglas Gransberg Author-X-Name-First: Douglas Author-X-Name-Last: Gransberg Author-Name: Mohamed Khalafalla Author-X-Name-First: Mohamed Author-X-Name-Last: Khalafalla Author-Name: Cesar Mayorga Author-X-Name-First: Cesar Author-X-Name-Last: Mayorga Title: Probabilistic cost-based decision-making matrix: IDIQ vs. DBB contracting Abstract: Public departments of transportation (DOTs) are increasingly adopting alternative contracting methods (ACMs), such as Indefinite Delivery/Indefinite Quantity (IDIQ) agreements, to shorten project delivery and increase scheduling flexibility. However, the challenge remains to decide when an IDIQ contract would offer better value for money in a project compared to the conventional Design-Bid-Build (DBB) method. This paper proposes an IDIQ project selection framework that incorporates expected construction costs to identify suitable candidate projects. Historical bid data, an alternate cost indexing system, nonlinear regression analysis, and the Monte Carlo simulation technique are used to create and compare IDIQ and DBB probabilistic construction cost estimates. The study demonstrates the effectiveness of the framework using a single-award IDIQ granted through the Minnesota Department of Transportation (MnDOT) and past bidding information for projects awarded between January 2008 and April 2015. Additionally, the paper acknowledges the limitations of the study, including its reliance on MnDOT data, the exclusion of non-cost factors, and the assumption of project homogeneity. The study also provides valuable recommendations for future research to address these limitations and enhance the understanding and practical implementation of IDIQ contracting in the construction industry. Journal: Construction Management and Economics Pages: 1-15 Issue: 1 Volume: 42 Year: 2024 Month: 1 X-DOI: 10.1080/01446193.2023.2226261 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2226261 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:1:p:1-15 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2181367_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20231214T103247 git hash: d7a2cb0857 Author-Name: Susanna Hedborg Author-X-Name-First: Susanna Author-X-Name-Last: Hedborg Author-Name: Lilly Rosander Author-X-Name-First: Lilly Author-X-Name-Last: Rosander Title: Self-organizing in urban development: developers coordinating between construction projects Abstract: Sustainable urban development districts have become an answer to the challenge of increasing urbanization while decreasing human impact on the environment. Like other domains of public administration, urban development has in recent decades moved towards heterogeneous governance. Urban development becomes project ecologies, where several construction projects are carried out in parallel and in sequence. This paper sheds light on public and private developers’ coordinating between their construction projects and the influence this has on the built environment of urban development districts. The space between projects in project ecologies is relevant to explore further to understand how the long-term goals of urban policy are achieved in practice. Through the theoretical lens of self-organizing, the discussion is informed by a qualitative study of two cases where developers built together in sustainable profiled urban development districts. The paper contributes to construction management research by illustrating how developers play a key role in finalizing the design and construction of new districts through self-organizing. In effect, new urban districts can only be realized through joint efforts and coordination amongst developers. The paper also provides policymakers with insights into how developers become key players in organizing new neighborhoods. Journal: Construction Management and Economics Pages: 116-130 Issue: 2 Volume: 42 Year: 2024 Month: 2 X-DOI: 10.1080/01446193.2023.2181367 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2181367 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:2:p:116-130 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2306213_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20231214T103247 git hash: d7a2cb0857 Author-Name: Craig S. Thomson Author-X-Name-First: Craig S. Author-X-Name-Last: Thomson Author-Name: Tina Karrbom Gustavsson Author-X-Name-First: Tina Author-X-Name-Last: Karrbom Gustavsson Author-Name: Andrew Karvonen Author-X-Name-First: Andrew Author-X-Name-Last: Karvonen Title: Expanding the field: combining construction management and urban studies to address grand societal challenges Journal: Construction Management and Economics Pages: 109-115 Issue: 2 Volume: 42 Year: 2024 Month: 2 X-DOI: 10.1080/01446193.2024.2306213 File-URL: http://hdl.handle.net/10.1080/01446193.2024.2306213 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:2:p:109-115 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2232893_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20231214T103247 git hash: d7a2cb0857 Author-Name: Tina Karrbom Gustavsson Author-X-Name-First: Tina Author-X-Name-Last: Karrbom Gustavsson Author-Name: Anette Hallin Author-X-Name-First: Anette Author-X-Name-Last: Hallin Author-Name: Peter Dobers Author-X-Name-First: Peter Author-X-Name-Last: Dobers Title: Stakeholder involvement in distributed projects: a performative approach to large scale urban sustainable development projects and the case of Stockholm Royal Seaport Abstract: The involvement of stakeholders in large scale urban sustainable development projects (LSUSDP.s) has proven difficult. The stakeholders are distributed across the geographical area, and they have stakes not only in the LSUSDP, but in the geographical location where the project takes place. To understand stakeholder management in “distributed projects”, we propose abandoning the “inside-out” perspective where the project is the point of departure, and focus on the emergence of stakeholders across time. Adopting such a performative, “outside-in,” perspective on the longitudinal and digital study of a LSUSDP, we are able to map how actors became stakeholders in the project through their actions. The paper makes four contributions. First, we reconceptualize stakeholder involvement by adopting a performative perspective, whereby “stakeholders” are envisaged as emergent and non-fixed. Second, we demonstrate how such a reconceptualization may be applied to the analysis of an empirical case. Third, we show that stakeholder involvement is not merely the result of stakeholder management but something that happens over time, through the material and discursive actions of those that become stakeholders. Finally, the paper contributes with an illustration of how the online, digital footprint, of a project may be useful to understand the emergence of a project. Journal: Construction Management and Economics Pages: 148-163 Issue: 2 Volume: 42 Year: 2024 Month: 2 X-DOI: 10.1080/01446193.2023.2232893 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2232893 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:2:p:148-163 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2222190_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20231214T103247 git hash: d7a2cb0857 Author-Name: Robert J Rogerson Author-X-Name-First: Robert J Author-X-Name-Last: Rogerson Author-Name: Bob Giddings Author-X-Name-First: Bob Author-X-Name-Last: Giddings Author-Name: Marcus Jefferies Author-X-Name-First: Marcus Author-X-Name-Last: Jefferies Title: Constructing the future of the city centre: realizing visions Abstract: As cities are being asked to transition to a new future shaped by significant social, economic and environmental challenges, renewed attention is being given to the urban development process, and on how this process has to be more inclusive, and the outcomes more coherent. With past notions of masterplans as a single, fixed visionary document being replaced with guiding strategies, open to interpretation, there is a greater need for different disciplines to engage together throughout the development process. This paper explores opportunities and needs for construction management to be more actively involved in the reshaping of the city centre, from the envisioning of its future to the realization of change. Through the lens of the process of change in four city centres across the world, this paper outlines how discussing construction management could beneficially engage with other urban disciplines to create a shared vision for centres as part of local governance. It argues for construction management adopt a wider spatial and temporal perspective that looks beyond specific buildings, site and projects to situate development in the urban and regional systems and to help be part of the envisioning process. Along with more critical engagement in the policy, design and construction processes for construction management, the paper points to a need for more local sensitivity and adaptation including an appreciation of the contribution of public spaces and a different approach to urban development if the city centre is to be more sustainable in future. Journal: Construction Management and Economics Pages: 131-147 Issue: 2 Volume: 42 Year: 2024 Month: 2 X-DOI: 10.1080/01446193.2023.2222190 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2222190 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:2:p:131-147 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2264969_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20231214T103247 git hash: d7a2cb0857 Author-Name: Lizet Kuitert Author-X-Name-First: Lizet Author-X-Name-Last: Kuitert Author-Name: Jannes Willems Author-X-Name-First: Jannes Author-X-Name-Last: Willems Author-Name: Leentje Volker Author-X-Name-First: Leentje Author-X-Name-Last: Volker Title: Value integration in multi-functional urban projects: a value driven perspective on sustainability transitions Abstract: Sustainable urban development requires the integration of diverse values to achieve multi-functional goals. Blue-Green Infrastructure (BGI) projects can be considered as pioneers in value integration. By combining bureaucratic innovations (BI) and social innovations (SI) these BGI projects are able to reach a more holistic development that is characterised as a value-driven approach for sustainability transitions. In this study on BGI projects, we aim to learn how to deliver multi-functional projects through different interpretation of four factors, i.e. professional culture, governance level, geographical space, and time conception, in various constellations of BI and SI. Results of our cross-case study of four BGI projects in three European countries (the Netherlands, Belgium and Sweden) indicate that project with higher degrees of value integration balance BI and SI in following four ways: (i) heterogeneity in professions in value-decision-making, (ii) multi-level governance embedded in institutional frameworks, (iii) connecting city-wide and neighbourhood levels by boundary spanners, and (iv) having a dynamic time conception. Our findings imply that social innovation experiences on projects has to fit into the bureaucratic environment to achieve true value integration. Journal: Construction Management and Economics Pages: 184-200 Issue: 2 Volume: 42 Year: 2024 Month: 2 X-DOI: 10.1080/01446193.2023.2264969 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2264969 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:2:p:184-200 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2247496_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20231214T103247 git hash: d7a2cb0857 Author-Name: Olli Vigren Author-X-Name-First: Olli Author-X-Name-Last: Vigren Title: Ecosystems in construction management and urban development: a comprehensive review of conceptualizations and contributions Abstract: To solve grand challenges, the collaboration between construction management and urban development professionals is essential. This article proposes that ecosystem conceptualizations can enhance our understanding of collaboration, but how these concepts contribute to this field is unclear. Therefore, a literature review is presented on how ecosystem concepts are operationalized in construction management and urban development research. The article classifies conceptualizations into seven categories and analyzes their potential for contributions to ecosystem theorizing. An ecosystem research agenda is developed, arguing that it can serve as a theoretical bridge between these disciplines. The article also highlights how research on ecosystems in the built environment sector can contribute to management and organization research fields more broadly. Notably, conceptualizations of ecosystems as project-based or location-based are valuable contributions to ecosystem research. Journal: Construction Management and Economics Pages: 164-183 Issue: 2 Volume: 42 Year: 2024 Month: 2 X-DOI: 10.1080/01446193.2023.2247496 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2247496 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:2:p:164-183 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2259015_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Gulnaz Aksenova Author-X-Name-First: Gulnaz Author-X-Name-Last: Aksenova Author-Name: Kwadwo Oti-Sarpong Author-X-Name-First: Kwadwo Author-X-Name-Last: Oti-Sarpong Title: Beyond “platformania” in the construction sector: Conceptualisations and implications of product platformisation in the UK Abstract: The UK government’s recent transformation agenda focused on a Platform approach to Design for Manufacture and Assembly (P-DfMA) has attracted interest from the construction sector. A closer examination of the P-DfMA agenda raises questions about its origins and implications. This paper critically analyses grey sector literature, policy and government-supported reports on P-DfMA to discuss how it has been conceptualised, and the implications for the growing “platformania” in the UK construction sector. To this end, firstly platform conceptualisations are synthesised, and distinctions between product platforms and DfMA are highlighted. Secondly, based on an analysis of policy and related documents, five areas critical to driving the platformisation agenda are identified: Product platform development; digitally designed components; platform leadership and ownership; platform governance; and business models. The critical analysis suggests that product platformisation in the UK construction sector requires two distinct types of platform approaches: the product platform; and a transaction platform or a marketplace for buyers and sellers of the components of product platforms. The implications of both for the strategic organising of construction firms, and the five areas identified, are discussed and synthesised with the evidence from management literature. Practical and policy implications for sector stakeholders are outlined, along with questions for future research on product platformisation in the construction sector. Journal: Construction Management and Economics Pages: 229-250 Issue: 3 Volume: 42 Year: 2024 Month: 3 X-DOI: 10.1080/01446193.2023.2259015 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2259015 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:3:p:229-250 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2260903_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Guy H. Walker Author-X-Name-First: Guy H. Author-X-Name-Last: Walker Author-Name: Simona Foscarin-Kosmetatou Author-X-Name-First: Simona Author-X-Name-Last: Foscarin-Kosmetatou Author-Name: Simon Marr Author-X-Name-First: Simon Author-X-Name-Last: Marr Author-Name: Stephen Gillies Author-X-Name-First: Stephen Author-X-Name-Last: Gillies Author-Name: Paul Lindsay Author-X-Name-First: Paul Author-X-Name-Last: Lindsay Title: Critical essay: sociotechnical construction Abstract: The Houses of Parliament Restoration and Renewal Programme is the UK’s largest ever. The cultural value, funding model, risk profile, and fragility of the building exposes an uncomfortable truth. Construction business-as-usual has become an enterprise risk. Current levels of productivity, health, and wellbeing are not acceptable on a project of such high national importance. The Programme joins calls made in the Farmer Review, Project 13, the Construction Play Book , and now the Building Safety Bill for transformative change. It is in the unique position of being able to proactively drive this change. It is an exemplar project intended to deliver a learning legacy for the sector at large. It is also the first project to show an interest in a new approach called Sociotechnical Construction. The focus of this new approach is the joint optimization of socio/human and technical/organizational factors. The evidence points to these being instrumental in resolving the construction sector’s long-standing productivity and wellbeing paradox. This critical essay describes and defines Sociotechnical Construction, sets out the call to action, and presents the case for why it is needed now. Journal: Construction Management and Economics Pages: 251-265 Issue: 3 Volume: 42 Year: 2024 Month: 3 X-DOI: 10.1080/01446193.2023.2260903 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2260903 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:3:p:251-265 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2227286_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Mohd Azrai Azman Author-X-Name-First: Mohd Azrai Author-X-Name-Last: Azman Author-Name: Nor Nazihah Chuweni Author-X-Name-First: Nor Nazihah Author-X-Name-Last: Chuweni Author-Name: Faridah Muhamad Halil Author-X-Name-First: Faridah Author-X-Name-Last: Muhamad Halil Author-Name: Ku Mohammad Asyraf Ku Azir Author-X-Name-First: Ku Mohammad Asyraf Author-X-Name-Last: Ku Azir Author-Name: Boon L. Lee Author-X-Name-First: Boon L. Author-X-Name-Last: Lee Author-Name: Farah Nazira Juhari Author-X-Name-First: Farah Nazira Author-X-Name-Last: Juhari Author-Name: Martin Skitmore Author-X-Name-First: Martin Author-X-Name-Last: Skitmore Title: The impact of the change in institutional regulation on construction productivity: firm-level evidence in a developing economy Abstract: For many, the business environment is regarded as the main factor determining changes in construction productivity. However, changes in a country’s institutional regulation can contribute to the productivity changes of construction firms over the long term but are often overlooked in construction productivity research. To study the impact of institutional regulation on construction productivity, a sample of 55 public-listed construction Malaysian firms (2009–2020) is used as a case study to estimate total factor productivity (TFP) based on the Geometric-Young Index (GYI). Stochastic Frontier Analysis (SFA) is then used to decompose the TFP-GYI into the technological, environment, technical, scale-mix, and statistical noise components. This is followed by the Generalized Method Moments (GMM) to model the impact of different institutional regulations on TFP and decomposed productivity components. The results indicate that the institutional regulation framework influences construction firms’ TFP. Property rights and the rule of law (PRRL), and budget balance and change in wages (BBCW) have a positive impact on TFP, which largely influences technical efficiency. In addition to uncovering the impact of institutional regulation on construction productivity, namely capital availability and regulatory environment, it is concluded that institutional regulation plays a vital role in determining long-term construction firm productivity and needs to be considered by policymakers in formulating supporting incentives and policies. Journal: Construction Management and Economics Pages: 199-214 Issue: 3 Volume: 42 Year: 2024 Month: 3 X-DOI: 10.1080/01446193.2023.2227286 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2227286 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:3:p:199-214 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2242512_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Viet-Ngu Hoang Author-X-Name-First: Viet-Ngu Author-X-Name-Last: Hoang Author-Name: Connie Susilawati Author-X-Name-First: Connie Author-X-Name-Last: Susilawati Author-Name: Joko Purnomo Raharjo Author-X-Name-First: Joko Purnomo Author-X-Name-Last: Raharjo Title: Analysis of productivity performance of real estate and construction firms in Indonesia Abstract: Sustained total factor productivity (TFP) growth of firms is essential to achieve sustained supply growth, which is necessary to solve the housing shortage and affordability problems. Existing productivity literature focuses on large firms whilst smaller firms make a significant contribution to the total supply. This paper investigates the productivity of 363 Indonesian real estate construction firms of medium and large sizes. We estimate Färe-Primont TFP measures under the meta-frontier framework, accounting for differences in the overall technologies under which each group of firms operates. Results deliver several important findings. First, large firms have higher productivity levels than medium firms, but average productivity levels are very low. Second, the productivity growth of large and medium firms is negative, which contributes to the growth of the housing shortage in Indonesia from 2012 to 2016. Third, in case of easier transfer or spill-over of production technologies between two firm groups, firms could enhance further their efficiency and productivity. Fourth, those factors related to branch numbers, legal structure and experience of doing business have positive correlations with the productivity performance of firms in both large and medium groups. Additionally, medium firms could gain higher productivity by diversifying their income. Importantly, our study shows evidence to support that government subsidies have a positive influence on the productivity level of medium firms. Journal: Construction Management and Economics Pages: 215-228 Issue: 3 Volume: 42 Year: 2024 Month: 3 X-DOI: 10.1080/01446193.2023.2242512 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2242512 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:3:p:215-228 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2260906_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Sulafa Badi Author-X-Name-First: Sulafa Author-X-Name-Last: Badi Title: The role of blockchain in enabling inter-organisational supply chain alignment for value co-creation in the construction industry Abstract: In the construction industry context, misalignments in the supply chain pose significant challenges, hindering successful project delivery. To address these issues, blockchain technology emerges as a promising IT-based solution for achieving supply chain alignment. A conceptual model is developed based on the service-dominant logic theory that explores the impact of blockchain on supply chain alignment and co-created value outcomes within the Business-to-Business (B2B) construction context. Through a questionnaire-based approach, data were collected from 324 respondents in the global construction industry, which was then analyzed using descriptive and inferential statistics. The findings demonstrate the positive impact of implementing blockchain technology on competency, behavioural, process, and expectations alignment among supply chain partners. These improvements in alignment collectively contribute to the realization of supply chain value outcomes. These results emphasize the importance of a comprehensive approach combining technology with alignment efforts to realize blockchain-enabled value co-creation in construction supply chain management. Journal: Construction Management and Economics Pages: 266-288 Issue: 3 Volume: 42 Year: 2024 Month: 3 X-DOI: 10.1080/01446193.2023.2260906 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2260906 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:3:p:266-288 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2181367_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Susanna Hedborg Author-X-Name-First: Susanna Author-X-Name-Last: Hedborg Author-Name: Lilly Rosander Author-X-Name-First: Lilly Author-X-Name-Last: Rosander Title: Self-organizing in urban development: developers coordinating between construction projects Abstract: Sustainable urban development districts have become an answer to the challenge of increasing urbanization while decreasing human impact on the environment. Like other domains of public administration, urban development has in recent decades moved towards heterogeneous governance. Urban development becomes project ecologies, where several construction projects are carried out in parallel and in sequence. This paper sheds light on public and private developers’ coordinating between their construction projects and the influence this has on the built environment of urban development districts. The space between projects in project ecologies is relevant to explore further to understand how the long-term goals of urban policy are achieved in practice. Through the theoretical lens of self-organizing, the discussion is informed by a qualitative study of two cases where developers built together in sustainable profiled urban development districts. The paper contributes to construction management research by illustrating how developers play a key role in finalizing the design and construction of new districts through self-organizing. In effect, new urban districts can only be realized through joint efforts and coordination amongst developers. The paper also provides policymakers with insights into how developers become key players in organizing new neighborhoods. Journal: Construction Management and Economics Pages: 114-128 Issue: 2 Volume: 42 Year: 2024 Month: 2 X-DOI: 10.1080/01446193.2023.2181367 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2181367 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:2:p:114-128 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2306213_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Craig S. Thomson Author-X-Name-First: Craig S. Author-X-Name-Last: Thomson Author-Name: Tina Karrbom Gustavsson Author-X-Name-First: Tina Author-X-Name-Last: Karrbom Gustavsson Author-Name: Andrew Karvonen Author-X-Name-First: Andrew Author-X-Name-Last: Karvonen Title: Expanding the field: combining construction management and urban studies to address grand societal challenges Journal: Construction Management and Economics Pages: 109-113 Issue: 2 Volume: 42 Year: 2024 Month: 2 X-DOI: 10.1080/01446193.2024.2306213 File-URL: http://hdl.handle.net/10.1080/01446193.2024.2306213 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:2:p:109-113 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2232893_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Tina Karrbom Gustavsson Author-X-Name-First: Tina Author-X-Name-Last: Karrbom Gustavsson Author-Name: Anette Hallin Author-X-Name-First: Anette Author-X-Name-Last: Hallin Author-Name: Peter Dobers Author-X-Name-First: Peter Author-X-Name-Last: Dobers Title: Stakeholder involvement in distributed projects: a performative approach to large scale urban sustainable development projects and the case of Stockholm Royal Seaport Abstract: The involvement of stakeholders in large scale urban sustainable development projects (LSUSDP.s) has proven difficult. The stakeholders are distributed across the geographical area, and they have stakes not only in the LSUSDP, but in the geographical location where the project takes place. To understand stakeholder management in “distributed projects”, we propose abandoning the “inside-out” perspective where the project is the point of departure, and focus on the emergence of stakeholders across time. Adopting such a performative, “outside-in,” perspective on the longitudinal and digital study of a LSUSDP, we are able to map how actors became stakeholders in the project through their actions. The paper makes four contributions. First, we reconceptualize stakeholder involvement by adopting a performative perspective, whereby “stakeholders” are envisaged as emergent and non-fixed. Second, we demonstrate how such a reconceptualization may be applied to the analysis of an empirical case. Third, we show that stakeholder involvement is not merely the result of stakeholder management but something that happens over time, through the material and discursive actions of those that become stakeholders. Finally, the paper contributes with an illustration of how the online, digital footprint, of a project may be useful to understand the emergence of a project. Journal: Construction Management and Economics Pages: 146-161 Issue: 2 Volume: 42 Year: 2024 Month: 2 X-DOI: 10.1080/01446193.2023.2232893 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2232893 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:2:p:146-161 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2222190_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Robert J Rogerson Author-X-Name-First: Robert J Author-X-Name-Last: Rogerson Author-Name: Bob Giddings Author-X-Name-First: Bob Author-X-Name-Last: Giddings Author-Name: Marcus Jefferies Author-X-Name-First: Marcus Author-X-Name-Last: Jefferies Title: Constructing the future of the city centre: realizing visions Abstract: As cities are being asked to transition to a new future shaped by significant social, economic and environmental challenges, renewed attention is being given to the urban development process, and on how this process has to be more inclusive, and the outcomes more coherent. With past notions of masterplans as a single, fixed visionary document being replaced with guiding strategies, open to interpretation, there is a greater need for different disciplines to engage together throughout the development process. This paper explores opportunities and needs for construction management to be more actively involved in the reshaping of the city centre, from the envisioning of its future to the realization of change. Through the lens of the process of change in four city centres across the world, this paper outlines how discussing construction management could beneficially engage with other urban disciplines to create a shared vision for centres as part of local governance. It argues for construction management adopt a wider spatial and temporal perspective that looks beyond specific buildings, site and projects to situate development in the urban and regional systems and to help be part of the envisioning process. Along with more critical engagement in the policy, design and construction processes for construction management, the paper points to a need for more local sensitivity and adaptation including an appreciation of the contribution of public spaces and a different approach to urban development if the city centre is to be more sustainable in future. Journal: Construction Management and Economics Pages: 129-145 Issue: 2 Volume: 42 Year: 2024 Month: 2 X-DOI: 10.1080/01446193.2023.2222190 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2222190 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:2:p:129-145 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2264969_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Lizet Kuitert Author-X-Name-First: Lizet Author-X-Name-Last: Kuitert Author-Name: Jannes Willems Author-X-Name-First: Jannes Author-X-Name-Last: Willems Author-Name: Leentje Volker Author-X-Name-First: Leentje Author-X-Name-Last: Volker Title: Value integration in multi-functional urban projects: a value driven perspective on sustainability transitions Abstract: Sustainable urban development requires the integration of diverse values to achieve multi-functional goals. Blue-Green Infrastructure (BGI) projects can be considered as pioneers in value integration. By combining bureaucratic innovations (BI) and social innovations (SI) these BGI projects are able to reach a more holistic development that is characterised as a value-driven approach for sustainability transitions. In this study on BGI projects, we aim to learn how to deliver multi-functional projects through different interpretation of four factors, i.e. professional culture, governance level, geographical space, and time conception, in various constellations of BI and SI. Results of our cross-case study of four BGI projects in three European countries (the Netherlands, Belgium and Sweden) indicate that project with higher degrees of value integration balance BI and SI in following four ways: (i) heterogeneity in professions in value-decision-making, (ii) multi-level governance embedded in institutional frameworks, (iii) connecting city-wide and neighbourhood levels by boundary spanners, and (iv) having a dynamic time conception. Our findings imply that social innovation experiences on projects has to fit into the bureaucratic environment to achieve true value integration. Journal: Construction Management and Economics Pages: 182-198 Issue: 2 Volume: 42 Year: 2024 Month: 2 X-DOI: 10.1080/01446193.2023.2264969 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2264969 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:2:p:182-198 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2247496_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Olli Vigren Author-X-Name-First: Olli Author-X-Name-Last: Vigren Title: Ecosystems in construction management and urban development: a comprehensive review of conceptualizations and contributions Abstract: To solve grand challenges, the collaboration between construction management and urban development professionals is essential. This article proposes that ecosystem conceptualizations can enhance our understanding of collaboration, but how these concepts contribute to this field is unclear. Therefore, a literature review is presented on how ecosystem concepts are operationalized in construction management and urban development research. The article classifies conceptualizations into seven categories and analyzes their potential for contributions to ecosystem theorizing. An ecosystem research agenda is developed, arguing that it can serve as a theoretical bridge between these disciplines. The article also highlights how research on ecosystems in the built environment sector can contribute to management and organization research fields more broadly. Notably, conceptualizations of ecosystems as project-based or location-based are valuable contributions to ecosystem research. Journal: Construction Management and Economics Pages: 162-181 Issue: 2 Volume: 42 Year: 2024 Month: 2 X-DOI: 10.1080/01446193.2023.2247496 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2247496 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:2:p:162-181 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2266760_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Roope Nyqvist Author-X-Name-First: Roope Author-X-Name-Last: Nyqvist Author-Name: Antti Peltokorpi Author-X-Name-First: Antti Author-X-Name-Last: Peltokorpi Author-Name: Olli Seppänen Author-X-Name-First: Olli Author-X-Name-Last: Seppänen Title: Uncertainty network modeling method for construction risk management Abstract: In recent decades, uncertainty management has increasingly elicited attention in construction management research due to increasing project complexity. However, existing management methods have not been able to solve the issues around risk and uncertainty, and regardless of the proposed network-based risk modeling approaches, there are insufficiencies in contemporary methods, such as their practical applicability. This study examined the current state and issues of uncertainty and risk management and proposed a novel uncertainty network model (UNM) as a solution. The uncertainty network model was designed and validated using design science methodology (DSM), drawing on literature and empirical data from interviews, questionnaires, case observations, and case testing. The UNM visually presents project risks, uncertainties, and their interconnections and criticality transforming project stakeholders’ tacit knowledge into an explicit, systematic representation of a project’s uncertainty and risk architecture. Applied to a real-world construction project, the model received positive feedback, demonstrating its effectiveness in enhancing practitioners’ understanding of networked risks and the potential to guide cost-effective risk-control activities by applying a systemic lens to project management. This practical validation showcases the model’s potential in addressing the shortcomings of existing methods and improving construction project risk management. Journal: Construction Management and Economics Pages: 346-365 Issue: 4 Volume: 42 Year: 2024 Month: 4 X-DOI: 10.1080/01446193.2023.2266760 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2266760 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:4:p:346-365 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2262622_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Douglas Comassetto Hamerski Author-X-Name-First: Douglas Comassetto Author-X-Name-Last: Hamerski Author-Name: Tarcisio Abreu Saurin Author-X-Name-First: Tarcisio Abreu Author-X-Name-Last: Saurin Author-Name: Carlos Torres Formoso Author-X-Name-First: Carlos Torres Author-X-Name-Last: Formoso Author-Name: Eduardo Luis Isatto Author-X-Name-First: Eduardo Luis Author-X-Name-Last: Isatto Title: The contributions of the Last Planner System to resilient performance in construction projects Abstract: Although the Last Planner System (LPS) has been successfully used in complex construction projects, previous studies have not investigated how it supports resilient performance (RP), which is crucial for the construction industry. To address this gap, a case study of using the LPS in refurbishment building projects was conducted. The implementation of LPS was analysed in light of seven principles for the design of resilient systems. Sources of data for this analysis involved documents, semi-structured interviews, participant observation, and secondary data. The results pointed out 25 production planning and control practices that contributed to RP, including well-established LPS practices, formalised in the planning standards of the company (32% of the total); formal practices not usually considered as elements of LPS (20%); and informal practices not anticipated by company standards (48%). These findings indicate that although LPS contributes to RP, it must be complemented by other practices, either formal or informal. A set of well-established practices (e.g. hierarchical planning, identification and removal of constraints, collaborative meetings, and use of lagging and leading indicators) are those most logically connected to the principles of design for RP. This study also offers insights into some LPS limitations (e.g. low control frequency and overemphasis on production in relation to other functional dimensions), which indicate opportunities for the development of new production planning and control approaches supportive of RP. Journal: Construction Management and Economics Pages: 328-345 Issue: 4 Volume: 42 Year: 2024 Month: 4 X-DOI: 10.1080/01446193.2023.2262622 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2262622 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:4:p:328-345 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2260909_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Kate V Morland Author-X-Name-First: Kate V Author-X-Name-Last: Morland Author-Name: Dermot Breslin Author-X-Name-First: Dermot Author-X-Name-Last: Breslin Title: Resolving learning paradoxes within a UK new-build housebuilder Abstract: The build quality of new UK homes is negatively affected by poor quality management practices during the construction process. By implementing stringent quality management (QM) standards, housebuilders can improve build quality but implementing these organization-wide changes relies on housebuilder staff, designers and sub-contractors learning new working practices. This paper explores the tensions which emerge within housebuilders, as they implement new QM procedures. A longitudinal qualitative case study was conducted, where time was spent with housebuilder staff in three regional offices, two years apart. Methods include participant observation, semi-structured interviews and a review of organizational documentation. The findings highlight several learning paradoxes which arise at different stages of the housebuilding process and show how actors manage (or cope with) these paradoxes through their daily practices. This includes processes of simplifying and applying, improvising and problem-solving and aggregating and analyzing. Whilst these either-or approaches enable staff to resolve the immediate tensions that arise from different organizational processes, they often fail to meet longer-term learning objectives, detrimentally affecting build quality over time. Without structural changes to the way volume housebuilders annually report to both the UK Government and their shareholders, organizations in the UK housebuilding sector face challenges in reconciling different learning processes. Journal: Construction Management and Economics Pages: 307-327 Issue: 4 Volume: 42 Year: 2024 Month: 4 X-DOI: 10.1080/01446193.2023.2260909 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2260909 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:4:p:307-327 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2260907_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Paul J. Hickey Author-X-Name-First: Paul J. Author-X-Name-Last: Hickey Author-Name: Qingbin Cui Author-X-Name-First: Qingbin Author-X-Name-Last: Cui Title: Tracing the career trajectories of architecture, engineering and construction (AEC) women leaders Abstract: This study delves into the professional trajectories of 20 women leaders Vice President (VP) and above in the U.S. Architecture, Engineering and Construction (AEC) sector. These accomplished women, carefully selected from Engineering News Record’s (ENR's) Top 400 firms, shared their personal stories, discussing both triumphs and challenges influencing their journey to senior corporate positions. This collection of experiences provides valuable insights to identify the root causes of women’s underrepresentation in the industry. Moreover, this investigation aims to create a career roadmap that supports early and mid-career women in their pursuit of success within AEC. Success factors contributing to these women’s rise include a supportive partner, receiving early mentoring and possessing a genuine passion for their projects. Companies seeking to stand out and benefit from innovative outcomes that diversity offers should consider implementing diversity programs and fostering the growth of women throughout their careers. This may involve actively recruiting young women and providing funding for Science, Technology, Engineering and Math (STEM) programs and scholarships for pre-college girls. Identified initiatives hold the potential to increase the number of women entering the industry and reduce the rate of early departures, thus helping to close the workforce shortage gap in the construction sector. Journal: Construction Management and Economics Pages: 289-306 Issue: 4 Volume: 42 Year: 2024 Month: 4 X-DOI: 10.1080/01446193.2023.2260907 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2260907 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:4:p:289-306 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2267137_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Samuel Frimpong Author-X-Name-First: Samuel Author-X-Name-Last: Frimpong Author-Name: Riza Yosia Sunindijo Author-X-Name-First: Riza Yosia Author-X-Name-Last: Sunindijo Author-Name: Cynthia Changxin Wang Author-X-Name-First: Cynthia Changxin Author-X-Name-Last: Wang Author-Name: Elijah Frimpong Boadu Author-X-Name-First: Elijah Frimpong Author-X-Name-Last: Boadu Author-Name: Ayirebi Dansoh Author-X-Name-First: Ayirebi Author-X-Name-Last: Dansoh Author-Name: Carol K. H. Hon Author-X-Name-First: Carol K. H. Author-X-Name-Last: Hon Author-Name: Tak Wing Yiu Author-X-Name-First: Tak Wing Author-X-Name-Last: Yiu Title: Promoting positive mental health among young construction workers: the role of theory Abstract: The post-modern approach to improving young peoples’ mental health emphasizes the need to promote positive mental health. However, research on young construction workers’ mental health has focused mainly on negative mental health, e.g. depression, suicidal ideation, and anxiety, and given far less attention to positive mental health. The aim of this research was to identify the reason for this trend and to propose an agenda for change. Based on the initial assumption that theory-use has contributed to this trend, we utilized the PICO and PRISMA-ScR frameworks to critically review the theoretical and conceptual models in published research on young construction workers’ mental health. Out of 367 articles retrieved, fourteen studies published between 2010 and 2023 qualified for inclusion. Eighteen different theories and frameworks were identified. Generally, studies focused on measuring the prevalence of symptoms of negative mental health. Theories and conceptual frameworks were mostly used to guide the identification of variables associated with negative mental health (e.g. age, workplace stressors, autonomy, etc.) and to explain the relationships among them. The identified theories and conceptual frameworks did not offer a positive conceptualisation of mental health, and as a result, no study theorized positive mental health. We offer a matrix for evaluating theory-use in research. We also identify and discuss the strengths and limitations of the current use of theory in published studies and provide recommendations on how theory-use can be improved to reorient construction research towards the promotion of positive mental health. Journal: Construction Management and Economics Pages: 366-385 Issue: 4 Volume: 42 Year: 2024 Month: 4 X-DOI: 10.1080/01446193.2023.2267137 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2267137 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:4:p:366-385 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2327066_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Federico Dell’Anna Author-X-Name-First: Federico Author-X-Name-Last: Dell’Anna Author-Name: Mauro Berta Author-X-Name-First: Mauro Author-X-Name-Last: Berta Author-Name: Marta Bottero Author-X-Name-First: Marta Author-X-Name-Last: Bottero Author-Name: Gloria Mallia Author-X-Name-First: Gloria Author-X-Name-Last: Mallia Author-Name: Vito Morgese Author-X-Name-First: Vito Author-X-Name-Last: Morgese Title: Multicriteria-decision support for master plan scheduling: urban regeneration of an industrial area in Northern Italy Abstract: Urban regeneration programs involve a series of intricate activities that utilize human, material, and financial resources, executed at varying times and in diverse manners. Within this complex scenario, a major challenge lies in effectively managing concurrent developments across multiple buildings and infrastructure projects, while also harmonizing the interests of all parties engaged in urban regeneration initiatives. This paper introduces a multi-step strategy designed to enhance and streamline urban management amid the multifaceted decision-making processes characteristic of urban regeneration efforts. Specifically, the multi-criteria decision-making model ELECTRE TRI-B is employed to sort the array of basic tasks within a complex transformation endeavor into priority groups based on various evaluative criteria. To ascertain the significance of these criteria and rank each task according to the interests of the stakeholders likely to be impacted, a panel of specialists, including construction experts, economists, and environmental assessors, is convened. Following this, project actions are organized in a Gantt chart reflecting the construction priority determined by the evaluation model. This approach facilitated the temporal organization of master plan activities, incorporating insights from a broad spectrum of experts including municipal technical staff, professionals, and the community at large. The findings indicate that this comprehensive and interactive approach to performance measurement enabled the handling of extensive datasets and the refinement of financial, economic, environmental, and social resources, all while adhering to logical constraints and urban policy demands. Journal: Construction Management and Economics Pages: 476-501 Issue: 5 Volume: 42 Year: 2024 Month: 5 X-DOI: 10.1080/01446193.2024.2327066 File-URL: http://hdl.handle.net/10.1080/01446193.2024.2327066 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:5:p:476-501 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2270080_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Christopher Görsch Author-X-Name-First: Christopher Author-X-Name-Last: Görsch Author-Name: Olli Seppänen Author-X-Name-First: Olli Author-X-Name-Last: Seppänen Author-Name: Antti Peltokorpi Author-X-Name-First: Antti Author-X-Name-Last: Peltokorpi Author-Name: Rita Lavikka Author-X-Name-First: Rita Author-X-Name-Last: Lavikka Title: Task planning and control in construction: revealing workers as early and late planners Abstract: Production planning and control are critical to project success. They are conventionally understood as linking planning and production by coordinating tasks prior to installation work. However, research has highlighted workers as autonomous and decentralized planners of installation work, which challenges conventional management perspectives. Performing task-level planning and control requires resources and effort, reducing the time spent on installation work. This study explores workers’ planning practices by examining the use of higher-level plans and other information sources and by analyzing workers’ information needs and the factors determining them. A survey of Finnish construction workers was conducted. The results show that some workers prefer planning tasks before arriving at the construction site, while others prefer planning tasks during on-site work preparation. Trade- and crew-specific factors influence planning earlier or later and determine the extent to which centralized and decentralized sources and practices are used. Decentralized sources and practices are most often used to meet workers’ information needs, although centralized sources and practices are also used. These findings may help construction stakeholders better understand the information sources and practices used by workers. Thus, task planning and control activities can better meet workers’ information needs, allowing for more time for installation work. Journal: Construction Management and Economics Pages: 431-450 Issue: 5 Volume: 42 Year: 2024 Month: 5 X-DOI: 10.1080/01446193.2023.2270080 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2270080 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:5:p:431-450 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2267140_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Jemma Bridgeman Author-X-Name-First: Jemma Author-X-Name-Last: Bridgeman Author-Name: Martin Loosemore Author-X-Name-First: Martin Author-X-Name-Last: Loosemore Title: Evaluating social procurement: a theoretically informed and methodologically robust social return on investment (SROI) analysis of a construction training initiative developed to reduce the risk of youth homelessness in Wales Abstract: Despite widespread claims about the benefits of social procurement, there is little robust evidence that emerging social procurement policies are achieving their intended outcomes. Addressing this gap in research, this paper presents a case study of a theoretically informed and methodologically robust evaluative social return on investment (SROI) analysis of a construction training initiative developed in Wales to reduce the risk of youth homelessness. Utilising Sen and Nussbaum's Capability Empowerment Approach, the results contribute to social procurement research by providing much needed empirical legitimacy to an under theorised field. Ensuring that new social procurement initiatives developed by the construction industry are theoretically and empirically sound is critical to ensure they are transparent, robust, testable, reliable and replicable in achieving the social outcomes they purport to deliver. Journal: Construction Management and Economics Pages: 387-411 Issue: 5 Volume: 42 Year: 2024 Month: 5 X-DOI: 10.1080/01446193.2023.2267140 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2267140 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:5:p:387-411 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2269434_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Yazan Alzoubi Author-X-Name-First: Yazan Author-X-Name-Last: Alzoubi Author-Name: Giorgio Locatelli Author-X-Name-First: Giorgio Author-X-Name-Last: Locatelli Author-Name: Tristano Sainati Author-X-Name-First: Tristano Author-X-Name-Last: Sainati Title: The ugly side of construction: modern slavery in the 2022 FIFA World Cup program Abstract: Modern slavery is an illegal and unethical practice that is widespread across several sectors, including construction. This article investigates the mechanisms and motivations for employing modern slaves in construction projects and the role of “political will” in fighting it. To this end, using a cross-sectional single case study, the article examines the case of Qatar’s construction of the infrastructure for the 2022 FIFA World Cup—a large construction program in which modern slavery has been extensively documented. Our theoretical lens is the Fraud Triangle Theory (opportunity, pressure, and rationalization), which is rarely used in construction management but is useful for investigating illegal or unethical phenomena. The findings document the various factors contributing to modern slavery, including the kafala system, confiscated passports, debt bondage, contract substitution, salary abuse, program time constraints, cash flow shortage, and weak internal control systems. This article’s key novel theoretical contributions relate to identifying why modern slavery occurs in construction projects using the Fraud Triangle Theory and highlighting the importance of “political will” in fighting modern slavery worldwide. Journal: Construction Management and Economics Pages: 412-430 Issue: 5 Volume: 42 Year: 2024 Month: 5 X-DOI: 10.1080/01446193.2023.2269434 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2269434 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:5:p:412-430 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2277925_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Yuqing Hu Author-X-Name-First: Yuqing Author-X-Name-Last: Hu Author-Name: Carrie S. Dossick Author-X-Name-First: Carrie S. Author-X-Name-Last: Dossick Title: Decoding the dynamics of BIM use practice in construction projects Abstract: Over the past two decades, thought leaders positioned Building Information Modeling (BIM) as a driver to change the Architecture, Engineering, and Construction (AEC) industry. However, instances of unexpected BIM use have surfaced, with projects often shifting from BIM to hybrid or even solely 2D practices midway. What technology use conditions cause these practice-based rejections of BIM use and how these happen have not been fully explored and make BIM cannot fully play its role in a project. To fill this gap, we use structuration theory as a theoretical lens to analyze the interactions between BIM and project teams and explore how three technology use conditions, (interpretive, technological, and institutional), impact the interactions, which finally shape technology use practices. Specifically, a case study method has been selected. The research team attended a project for two years, collected meeting observations, and conducted surveys and interviews to track the emergent and situated BIM use practice in an integrated project setting with technology use conditions that changed over the course of the project. We analyzed how the three technology use conditions impacted the interactions between BIM and project teams in different ways and how these impacted change in different project phases. We conclude that the sustained use of BIM requires the alignment of project organizations with BIM features and alignment with both top-down and bottom-up investment in practice change, which includes motivation for senior management investment in a sustained project team, in individual capability training, and in early planning. Journal: Construction Management and Economics Pages: 451-475 Issue: 5 Volume: 42 Year: 2024 Month: 5 X-DOI: 10.1080/01446193.2023.2277925 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2277925 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:5:p:451-475 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2279743_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Rebecka Lundgren Author-X-Name-First: Rebecka Author-X-Name-Last: Lundgren Author-Name: Riikka Kyrö Author-X-Name-First: Riikka Author-X-Name-Last: Kyrö Author-Name: Stefan Olander Author-X-Name-First: Stefan Author-X-Name-Last: Olander Title: The lifecycle impact and value capture of circular business models in the built environment Abstract: Circular economy (CE) has been of utmost interest in the industry and research community in the preceding years. However, CE is still a nascent research field in the built environment context. As technological advances within CE are slowing, the incorporation of business models into the concept is deemed important to achieve the necessary transition. Circular business models within the built environment should take a holistic perspective and a lifecycle optimization approach. The research aim is twofold, firstly, we aim to contribute to the assessment of impacts of CE business models. Secondly, we aim to establish how real estate development organizations can optimize value capture from adaptive reuse projects. We engage in an in-depth mixed methods case study assessing and comparing two adaptation scopes of a former textile factory to offices. The minor scope includes basic measures to bring the building up to standard, whilst the major scope includes the same, with the addition of space efficiency measures, extended building services, onsite energy production and various circular activities. We find that the major scope consequently captures more of the identified value propositions of the organization than the minor scope. We conclude that more circular activities do not necessarily lead to better environmental performance, however, may lead to higher profit and social gain. The study contributes to existing knowledge of impact assessments, and highlights the complexity of balancing environmental, social and economic impact in the built environment context. The assessment framework may be used by real estate developers prior to investments decisions. Journal: Construction Management and Economics Pages: 527-544 Issue: 6 Volume: 42 Year: 2024 Month: 6 X-DOI: 10.1080/01446193.2023.2279743 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2279743 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:6:p:527-544 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2291082_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Hassan F. Gholipour Author-X-Name-First: Hassan F. Author-X-Name-Last: Gholipour Author-Name: Mohammad Reza Farzanegan Author-X-Name-First: Mohammad Reza Author-X-Name-Last: Farzanegan Author-Name: Mohammed N. Abu Al-Foul Author-X-Name-First: Mohammed N. Author-X-Name-Last: Abu Al-Foul Title: House prices and labour productivity growth: Evidence from OECD countries Abstract: This study examines the association between real house prices and labour productivity growth in 24 OECD countries over the period 1972–2019. By applying the panel fixed effects and Pooled Mean Group-Autoregressive Distributed Lag (PMG-ARDL) estimators, the results show that labour productivity growth is negatively and significantly associated with real house prices. This finding provides empirical support for the ongoing discussion on the adverse impact of excessive housing market activities on productivity. Journal: Construction Management and Economics Pages: 582-589 Issue: 6 Volume: 42 Year: 2024 Month: 6 X-DOI: 10.1080/01446193.2023.2291082 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2291082 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:6:p:582-589 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2279195_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Bismark Duodu Author-X-Name-First: Bismark Author-X-Name-Last: Duodu Author-Name: Damithri Gayashini Melagoda Author-X-Name-First: Damithri Gayashini Author-X-Name-Last: Melagoda Author-Name: Steve Rowlinson Author-X-Name-First: Steve Author-X-Name-Last: Rowlinson Title: Innovation ambidexterity in construction firms: external knowledge antecedents and performance consequences Abstract: Empirical evidence on the external knowledge search behaviour of construction firms and its effects on innovation ambidexterity (IA) and performance is limited. The purpose of this study is to examine the effects of external knowledge sources on IA and the mediating role of IA in the relationship between external knowledge sources and financial performance (FP) in construction firms. It tests the hypotheses developed using survey responses from management personnel in Hong Kong construction firms. The results indicate that knowledge from clients or suppliers has a significant effect on IA. Similarly, knowledge sourced from universities and research institutions has a significant positive impact on IA. However, only knowledge from clients directly affects FP. IA fully mediates the relationships between knowledge from clients, suppliers or universities and research institutions with FP but not the other three sources. While partly validating some existing studies, these findings also extend the current knowledge on the connection between external knowledge sources and IA. This shows how IA can translate external knowledge into financial outcomes, revealing the value of different knowledge sources for firms. The findings provide insights into how construction firms can direct their knowledge searches to enhance ambidexterity and financial outcomes. This study showed the importance of external collaborators for construction firms in achieving IA and FP. It contributes to the theory and practice on the antecedents and outcomes of IA in construction firms and the path-dependent processes to enhance FP through the use of external knowledge to simultaneously pursue exploratory and exploitative innovation. Journal: Construction Management and Economics Pages: 503-526 Issue: 6 Volume: 42 Year: 2024 Month: 6 X-DOI: 10.1080/01446193.2023.2279195 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2279195 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:6:p:503-526 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2287475_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Regis Signor Author-X-Name-First: Regis Author-X-Name-Last: Signor Author-Name: Peter E. D. Love Author-X-Name-First: Peter E. D. Author-X-Name-Last: Love Author-Name: Pablo Ballesteros-Pérez Author-X-Name-First: Pablo Author-X-Name-Last: Ballesteros-Pérez Title: Detecting bid rigging in public auctions for procuring infrastructure projects: formulating the reference scenario for decision-making Abstract: Bid rigging is a fraudulent scheme in procurement auctions resulting in non-competitive bids awarded at prices above the competitive market. Bid rigging is a global problem that wastes public agencies’ resources and taxpayers’ money. While various methods and tools have been developed to detect bid rigging, it remains challenging for public agencies to identify what a competitive baseline auction looks like in the absence of collusion. Such a baseline is commonly known as a reference scenario, which involves analyzing the behavior of honest bids in previous auctions to determine if future bids could be collusive. Research on formulating reliable reference scenarios for bid rigging detection in the auctions of infrastructure projects has received limited attention. Hence, our paper analyses the key criteria required to develop a reference scenario for public agencies to detect bid rigging during an auction. Drawing on data from Brazilian public procurement and oversight agencies, a procedure for composing robust reference scenarios for detecting bid rigging in infrastructure first-priced auctions is presented and discussed. We then test our procedure’s generalizability using data from four countries (Australia, Brazil, Spain, and the United States) in two auction formats (i.e., capped and uncapped). A better understanding of the reference scenario formulation will allow public officials to increase the likelihood of detecting bid rigging when it exists and avoid flagging it as such when no collusive practices are involved. Journal: Construction Management and Economics Pages: 545-563 Issue: 6 Volume: 42 Year: 2024 Month: 6 X-DOI: 10.1080/01446193.2023.2287475 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2287475 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:6:p:545-563 Template-Type: ReDIF-Article 1.0 # input file: RCME_A_2289040_J.xml processed with: repec_from_jats12.xsl darts-xml-transformations-20240209T083504 git hash: db97ba8e3a Author-Name: Bryan W. Franz Author-X-Name-First: Bryan W. Author-X-Name-Last: Franz Author-Name: Joseph Olopade Author-X-Name-First: Joseph Author-X-Name-Last: Olopade Title: Exploring pathways to project success through project delivery team integration: a qualitative comparative analysis Abstract: Integration within project delivery teams can improve project outcomes in the building construction industry. However, integration across multiple firms and disciplines can be more challenging to manage, when compared to functionally organized, or siloed, teams. Given that resources to manage integration are limited and that most teams are only partially integrated in practice, this research seeks to explore pathways for their success. Using data collected from ten completed projects in the U.S., a fuzzy-set qualitative comparative analysis was performed to identify which combinations of six dimensions of integration were sufficient for improved project performance. The analysis revealed six distinct and highly consistent pathways to success, as evaluated by the criteria of being on-budget, on-time, or achieving the planned sustainable certification. Across all pathways, having a single team focus and equitable team relationships were the only dimensions consistently found in pathways leading to desirable project outcomes. Other dimensions, such as co-location, seamless operation across organizational boundaries, and a no-blame culture were found in pathways to both desirable and undesirable project outcomes, depending on their combination with other dimensions. These results contribute to theories on implementing team integration, suggesting that fully integrated teams are not always necessary for success. Instead, integrated teams that can work collaboratively, while still maintaining organizational separation or autonomy, can be as effective. While the study does not enable the identification of all possible pathways to success, it provides guidance to practitioners by highlighting a small subset of pathways, giving greater flexibility in managing integration within their teams. Journal: Construction Management and Economics Pages: 564-581 Issue: 6 Volume: 42 Year: 2024 Month: 6 X-DOI: 10.1080/01446193.2023.2289040 File-URL: http://hdl.handle.net/10.1080/01446193.2023.2289040 File-Format: text/html File-Restriction: Access to full text is restricted to subscribers. Handle: RePEc:taf:conmgt:v:42:y:2024:i:6:p:564-581